Loading...
HomeMy WebLinkAboutSUPPLEMENTAL AGREEMENT BETWEEN AUGUSTA, GEORGIA AND UNIVERSAL PLUMBING FOR SANITARY SEWER FOR SANITARY SEWER CONNECTION PROGRAM This SUMPLEMENTAL AGREEMENT,made on the;Thay of Q(2bkGf ,201 /j,to the AGREEMENT,made on the 11th of July,2017 by and between AUGUSTA,GEORGIA,BY AND THROUGH THE AUGUSTA-RICHMOND COUNTY COMMISSION,party of the first part,hereinafter called the OWNER, and Universal Plumbing, party of the second part,hereinafter called the CONTRACTOR. WITNESSETH,that the Contractor and the Owner, for the considerations hereinafter named, agree as follows: ARTICLE I- SCOPE OF THE WORK- The Contractor hereby agrees to furnish all of the materials and all of the equipment and labor necessary, and to perform all of the work shown on the plans and described in the specifications for the project entitled: SANITARY SEWER CONNECTION SERVICE—PHASE 2—GROUP 2 and in accordance with the requirements and provisions of the Contract Documents as defined in the General and Special Conditions hereto attached,which are hereby made a part of this agreement. ARTICLE II-TIME OF COMPLETION The work to be performed under this Contract shall be commenced within 5 business days after the date of written notice by the Owner to proceed.All work shall be substantially completed within 30 calendar days with all such extensions of time as are provided for in the General Conditions. Substantial completion shall be defined as all lots awarded connected to the city sewer system, all septic tanks abandoned. Final completion shall be 10 days after substantial completion. Final completion shall be defined as a representative of each property has signed off on the completeness and acceptance of work, example included. It is hereby understood and mutually agreed,by and between the Contractor and the Owner,that the date of beginning, rate of progress and the time for completion of the work to be done hereunder are ESSENTIAL CONDITIONS of this contract.Contractor agrees that said work shall be prosecuted regularly, diligently,and uninterruptedly at such rate of progress as will ensure full completion thereof within the time specified.It is expressly understood and agreed by and between the Contractor and the Owner,that the time for completion of the work described herein is a reasonable time for completion of the same, taking into consideration the average climatic range and construction conditions prevailing in this locality. 1 ( Page ARTICLE III—PAYMENT (A)The Contract Sum The Owner shall pay to the contractor for the performance of the Contract the amount as stated in the BID FORM and Schedule of Items. No variations shall be made in the amount except as set forth in the specifications attached hereto. (B) Progress Payment On no later than the fifth day of every month,the Contractor shall submit to the Owner's Engineer an estimate covering the percentage of the total amount of the Contract which has been completed from the start of the job up to and including the last working day of the preceding month, together with such supporting evidence as may be required by the Owner and/or the Engineer.This estimate shall include only the quantities in place and at the unit prices as set forth in the Bid Schedule. On the vendor run following approval of the invoice for payment,the Owner shall after deducting previous payments made,pay to the Contractor 90%of the amount of the estimate on units accepted in place.The 10%retained percentage may be held by the Owner until the final completion and acceptance of all work under the Contract. ARTICLE IV-ACCEPTANCE AND FINAL PAYMENT (A) Upon receipt of written notice that the work is ready for final inspection acceptance,the Engineer shall within 10 days made such inspection, and when he finds the work acceptable under the Contract and the Contract fully performed,he will promptly issue a final certificate,over his own signature,stating that the work required by this Contract has been completed and is accepted by him under the terms and conditions thereof. The contract shall then submittal a final payment request for the entire balance found to be due the Contractor including the retained percentage. This payment shall be paid to the Contractor by the Owner within 30 days after the date of the receipt of the final payment request. (B) Before final payment is due,the Contractor shall submit evidence satisfactory to the Engineer that all payrolls, material bills, and other indebtedness connected with work have been paid, except that in case of disputed indebtedness of liens of evidence of payment of all such disputed amounts when adjudicated in cases where such payment has not already been guaranteed by surety bond. (C) The making and acceptance of the final payment shall constitute a waiver of all claims by the Owner, other than those arising from unsettled liens,from faulty work appearing within 12 months after final payment, from requirements of the specifications,or from manufacturer's guarantees.It shall also constitute a waiver of all claims by the Contractor except those previously made and still unsettled. (D) If after the work has been substantially completed, full completion thereof is materially delayed through no fault of the Contractor, and the Engineer, so certifies, the Owner shall upon certification of the Engineer,and without terminating the Contract,make payment of the balance due for that portion of the work fully completed and accepted. Each payment shall be made under the terms and conditions governing final payment,except that it shall not constitute a waiver of claims. 2IPage IN WITNESS WHEREOF,the parties hereto have executed this Agreement in three(3)counterparts, each of which shall be deemed an original, in the year,and day first nen.tio d. v„e.,,,-_� , I OWNER: AUGUSTA,GEORGIA .. C IWC" Alttitr C4 4)4 SEAL i s �,`� ,` s By: 74744.e/Cs. Ify:c I ro The Honorable Hardie Davis,Jr. ° t W 04'%%orlifeks / s.0 , rl Mayor i Cl off/ it'. o au41i4"on Z . K. / ' Date: r Date 1,4014', ..or 4 f, APPROVED AS TO FORM: '- .,..DEPARTMENT APPROVAL BY i I L Thomas D. Wiedmeier Attorney Director,Augusta Utilities Department Date: '/t //7 Date: 9/( b i 17 CONTRACTOR: '�,,. ATTEST: SEAL __ Name: r� L rn e P Name:G GokdL(L ' Title: '(rPL)IC LQF) Title: . L (i J j- Date: 810\ 11 Date: S )i i 1 i'I 3IPage Bond: 106785399 PERFORMANCE BOND (NOTE: THIS BOND IS ISSUED SIMULTANEOUSLY WITH PAYMENT BOND ON PAGE 6. IN FAVOR OF THE OWNER CONDITIONED FOR THE PAYMENT OF LABOR AND MATERIAL) KNOW ALL MEN BY THESE PRENSENTS: That Universal Plumbing Inc. as Principal, hereinafter called Contractor,and Travelers Casualty& Surety Co of America a corporation organized and existing under the laws of the State of Connecticut .with its principal office in the City of Hartford ,State of Connecticut . as Surety. hereinafter called Surety, are held and firmly bound unto AUGUSTA, GEORGIA BY AND THROUGH THE.AUGUSTA COMMISSION as Obligee,herein after called the Owner, in the penal amount offorty-three thousand four hundred rlianyike(s 43,495 ) for the payment whereof Contractor and Surety hind themselves, their heirs,executors,administrators,successors,and assigns,jointly and severally, firmly by these presents for the faithful performance of a certain written agreement. WI IEREAS.Contract has by said written agreement dated entered in to a contract with Owner for the Sanitary Sewer Connection Services Task Order Program in accordance with the drawings and specifications issued by the Augusta Utilities Department and the Augusta-Richmond County Commission, which contract is by reference made a part hereof', and is hereinafter referred to as the CONTRACT. NOW,THEREFORE,the condition of this obligation is such that,if Contractor shall promptly and faithfully perform said CONTRACT', then this obligation shall he null and void; otherwise it shall remain in full force and effect. The Surety hereby waives notice of any alteration or extension of time made by the Owner. ***Sanitary Sewer Connection Service-Phase 2-Group 2 4 Bond:106785399 Whenever Contractor shall be, and declared by Owner to he in default under the CONTRACT. the Owner having performed Owner's obligations thereunder, the Surety may promptly remedy the default, or shall promptly (i) Complete the CONTRACT in accordance with its terms and conditions,or (2) Obtain a bid or bids for completing the Contract in accordance with its terms and conditions, and upon determination by Surety of the lowest responsible bidder,or, if the Owner elects, upon determination by the Owner and the Surety jointly of the lowest responsible bidder, arrange for a contract between such bidder and Owner, and make available as Work progresses(even though there should be a default a succession of defaults under the contract or contracts of completion arranged under this paragraph)sufficient funds to pay the cost of completion less the balance of the contract price; but not exceeding, including other costs and damages for which the Surety may be liable hereunder, the amount set forth in the first paragraph hereof The term "balance of the contract price,"as used in this paragraph, shall mean the total amount payable by Owner to Contractor under the Contract and any amendments thereto, less the amount properly paid by Owner to Contractor Any suit under this bond must be instituted before the expiration oftwo(2)years from the date on which final payment under the C'ONTRAC'T falls due. No right of action shall accrue on this bond to or for the use of any person or corporation other than the Owner named herein or the heirs, executors, administrators or successors of the Owner. 11 Signed and sealed this day,of August � - - A. n. 2O 17. Witness Universal Plumbing Inc. (Seal) (Contractor) Attest ��'e.)„CUA.Auk-41•.'.-4 JC (Seal) '(Title) C Witness Travelers Casualty&Surety Co.of America, seal) (Surety) — /popv Withers By -- — (Seal) (Tit e •rney InFact 5 WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER .A, POWER OF ATTORNEY TRAVELERSJ Farmington Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance Company Attorney-In Fact No. 230060 Certificate No. 0 0 6 5 4 4 0 7 2 KNOW ALL MEN BY THESE PRESENTS: That Farmington Casualty Company, St. Paul Fire and Marine Insurance Company,St. Paul Guardian Insurance Company,St.Paul Mercury Insurance Company.Travelers Casualty and Surety Company,Travelers Casualty and Surety Company of America,and United States Fidelity and Guaranty Company are corporations duly organized under the laws of the State of Connecticut,that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa,and that Fidelity and Guaranty Insurance Underwriters,Inc.,is a corporation duly organized under the laws of the State of Wisconsin(herein collectively called the"Companies"),and that the Companies do hereby make,constitute and appoint Morris H.Moss.Preston A. Moss.and Ashley L.Smith of the City of Augusta ,State of Georgia ,their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above,to sign,execute,seal and acknowledge any and all bonds,recognizances,conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons,guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. IN WITNESStober WHEREOF,the Compaoni 15 ave caused this instrument to be signed and their corporate seals to be hereto affixed,this 20th day of (� . Farmington Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance Company o .... SG \ SU O,iY! -:, vF,NCF` Ia'•fS.jNf °s ? dr . pot; A, State of Connecticut By: rx '"%.. /r City of Hartford ss. Robert L.Raney, error Vice President 20th October 2015 On this the day of ,before me personally appeared Robert L.Raney,who acknowledged himself to be the Senior Vice President of Farmington Casualty Company, Fidelity and Guaranty Insurance Company,Fidelity and Guaranty Insurance Underwriters,Inc.,St.Paul Fire and Marine Insurance Company,St.Paul Guardian Insurance Company,St.Paul Mercury Insurance Company.Travelers Casualty and Surety Company,Travelers Casualty and Surety Company of America.and United States Fidelity and Guaranty Company,and that he.as such,being authorized so to do,executed the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. A,O,TET In Witness Whereof,I hereunto set my hand and official seal. 1 *TAqQ/LIJ�+ C . My Commission expires the 30th day of June,2016. * /VW° * Marie C.Tetreault,Notary Public s 58440-8-12 Printed in U.S.A. WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER Bond:106785399 LABOR AND MATERIAL PAYMENT BOND (NOTE: THIS BOND IS ISSUED SIMULTANEOUSLY WITH PERFORMANCE BOND ON PAGE 4, IN FAVOR OF THE OWNER CONDITIONED FOR THE PAYMENT OF LABOR AND MATERIAL) KNOW ALL MEN BY THESE PRENSENTS: That Universal Plumbing Inc. as Principal, hereinafter called Contractor,and Travelers Casualty&Surety Co of America ,a corporation organized and existing under the laws of the State of Connecticut ,with its principal office m the City of Hartford State of Connecticut , as Surety, hereinafter called Surety. are held and firmly bound unto AUGUSTA, GEORGIA BY AND THROIJGI I'HIE AUGUSTA COMMISSION as Obligee,herein after called the Owner, for the use and benefit of claimants as herein below defined in the amount of forty-three thousand four hundred ninety-collars 43,495 ) for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators, successors, and assigns,jointly and severally. firmly by these presents. WHEREAS,Contract has by written agreement dated entered in to a contract with Owner for the Sanitary Sewer Connection Services Task Order Program in accordance with the drawings and specifications issued by the Augusta Utilities Department and the Augusta-Richmond County Commission, which contract is by reference made a part hereof, and is hereinafter referred to as the CONI RAC I. NOW, THEREFORE, the condition of this obligation is such that, if the Contractor shall promptly make paytncnt to all claimants as hereinafter defined.for all labor and material used or reasonably required to use in the performance of the CONTRACT,then this obligation shall be void:otherwise it shall remain in full force and effect, subject. however, to the following conditions: (1) A claimant is defined as one having a direct contract with the Contractor or with a subcontractor of the Contractor for labor. material.or both, used or reasonably required for use in the performance of the contract, labor and material being construed as to include that part of water, gas.power. light, heat, oil, gasoline, telephone service or rental of equipment directly applicable to the CONTRACT. (2) The above named Contractor and Surety hereby jointly and severally agree with the Owner that every claimant as herein defined,who has not been paid in full before the expiration of a period of ninety(90)days after the date on which the last of such claimant's work or labor was done or perlirrmed, or materials were furnished by such claimant, may sue on this bond for the use of such claimant,prosecute the suit to final judgment for such sum or sums as may he justly due claimant, and have execution thereon. 'The Owner shall not he liable for the payment of any costs or expenses of any such suit. 6 Bond:106785399 (3) No suit or action shall he commenced hereunder by any claimant. (a) Unless claimant, other than one having a direct contract with the Contractor, shall have given written notice to any two of the following:The Contractor,the Owner,or the Surety above named, within ninety (90) days after such claimant did or performed the last of the work or labor, or furnished the last of the materials for which said claim is made,stating with substantial accuracy the amount claimed and the name of the party to whom the materials were furnished,or for whom the work or labor was done or performed. Such notice shall be served by mailing the same by registered mail or certified mail,postage prepaid, in an envelope addressed to the Contractor, Owner or Surety, at any place where an office regularly maintained for the transaction of business, or served in any manner in which legal process may be served in the state in which the aforesaid project is located, save that such service need not he made by a public officer. (b) After the expiration of one (I) year following the date on which Contractor ceased work on said CONTRACT, it being understood, however, that if any limitation embodied in this bond is prohibited by any law controlling the construction hereof, such limitation shall be deemed to he amended so as to he equal to the minimum period of limitation permitted by such law. (c) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state in which the project.or any part thereof,is situated. or in the United States District Court for the district in which the project,or any part thereof, is situated, and not elsewhere. (4) lite amount of this bond shall he reduced by and to the extent of any payment or payments made in good faith hereunder, inclusive of the payment by Surety of mechanics'liens which may he filed of record against said improvement,whether or not claim for the amount of such lien be presented under and against this bond. Signed and scaled this tt day of Aug°g� A. D. 20 tr Witness Universal Plumbing Inc (Seal) (Contractor) Attest f. Rt JA--(Seat) (Title) ( Witness Travelers Casualty&Surety Co.of America (Sca I) (Surety) Witness i‘e2 (Seal) (7'iile)Attb ey InFact WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER AA► POWER OF ATTORNEY TRAVELERSJ Farmington Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance Company Attorney-In Fact No. 23006() Certificate No. 006544073 6 KNOW ALL MEN BY THESE PRESENTS: That Farmington Casualty Company, St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company,St.Paul Mercury Insurance Company,Travelers Casualty and Surety Company,Travelers Casualty and Surety Company of America,and United States Fidelity and Guaranty Company are corporations duly organized under the laws of the State of Connecticut, that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa•and that Fidelity and Guaranty Insurance Underwriters,Inc..is a corporation duly organized under the laws of the State of Wisconsin(herein collectively called the"Companies"),and that the Companies do hereby make,constitute and appoint Morris H. Moss.Preston A. Moss.and Ashley L.Smith of the City of Augusta ,State of Georgia .their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above,to sign,execute,seal and acknowledge any and all bonds.recognizances,conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons,guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. IN WITNESS WHEREOF,the Companies have caused this instrument to be signed and their corporate seals to be hereto affixed,this 20th day of October 2015 Farmington Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance Company (I.SUA, Y '�0004,)L s '•Iitaiii:,,, Z!NG.ONS97 ..° yc < 'Y ANO,„ st C rt �yyma f: O `�9t g ti N 1896y � sn , i `- 1951 �, 1,4-tiro. i•SEy'c. AtSSil ALD ' CONN. jr S� `' 4 tti rknC.,C' , ' % ,gyp State of Connecticut By: '� '%'�j City of Hartford ss. Robert L.Raney. enior Vice President On this the 20th day October 2015 of ,before me personally appeared Robert L.Raney,who acknowledged himself to be the SeniorVice President of Farmington Casualty Company. Fidelity and Guaranty Insurance Company,Fidelity and Guaranty Insurance Underwriters,Inc.,St.Paul Fire and Marine Insurance Company.St.Paul Guardian Insurance Company St.Paul Mercury Insurance Company,Travelers Casualty and Surety Company,Travelers Casualty and Surety Company of America.and United States Fidelity and Guaranty Company,and that he•as such,being authorized so to do•executed the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. (TARTL7 /�In Witness Whereof,I hereunto set my hand and official seal. �Q�(� C . My Commission expires the 30th day of June,2016. G�pawl * Marie C.Tetreault.Notary Public O1 58440-8-12 Printed in U.S.A. WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER APPENDIX 1. Bid Document of Awarded Lots 2. Property Owner Acceptance 8IPage AUGUSTA UTILITIES DEPARTMENT Sanitary Sewer Connection Program Phase 2-Group 2 Universal Line Item Address 1 2503 Walsh Ct,Hephzibah,GA,30815 $3,600.00 2 2509 Sand Ridge Ct,Hephzibah,GA,30815 $3,425.00 3 2514 Mickey Drive,Hephzibah,GA 30815 $2,950.00 4 2521 Sand Ridge Ct,Hephzibah,GA,30815 $3,050.00 5 2530 Sand Ridge Ct,Hephzibah,GA,30815 $3,000.00 7 2543 Anthony DeJuan Pkwy,Hephzibah,GA 30815 $2,600.00 8 2547 Anthony DeJuan Parkway,Hephzibah,GA 30815 $2,950.00 9 2568 Spirit Creek Rd,Hephzibah,GA,30815 $2,970.00 10 2570 Anthony DeJuan Pkwy,Hephzibah,GA 30815 $3,200.00 11 2576 Spirit Creek Rd,Hephzibah,GA,30815 $3,325.00 12 2578 Spirit Creek Rd,Hephzibah,GA,30815 $2,800.00 13 2607 Anthony DeJuan Pkwy,Hephzibah,GA 30815 $3,150.00 14 2610 Anthony DeJuan Pkwy,Hephzibah,GA 30815 $2,500.00 15 2610 Sadie Ct,Hephzibah,GA,30815 $3,600.00 16 2611 Sadie Ct,Hephzibah,GA,30815 $2,750.00 17 2612 Carrington Dr,Hephzibah,GA,30815 53,100.00 18 2620 Carrington Dr,Hephzibah,GA,30815 $3,000.00 19 2638 Carrington Dr,Hephzibah,GA,30815 $2,800.00 20 2640 Carrington Dr,Hephzlbah,GA,30815 $2,700.00 21 2803 Harwood Dr,Hephzibah,GA,30815 $1,800.00 22 2804 Harwood Dr,Hephzibah,GA,30815 $3,550.00 23 2810 Harwood Dr,Hephzibah,GA,30815 53,425.00 24 2826 Pepperdine Dr,Hephzlbah,GA,30815 $6,000.00 25 2835 Pepperdine Dr,Hephzibah,GA,30815 $3,000.00 26 2837 Harwood Dr,Hephzlbah,GA,30815 $3,050.00 27 2848 Pepperdine Dr,Hephzibah,GA,30815 $3,300.00 28 2877 Pepperdine Dr,Hephzibah,GA,30815 52,805.00 29 2905 Arrowwood Cir,Hephzibah,GA,30815 $2,900.00 30 2907 Lander Ct,Hephzlbah,GA,30815 $2,300.00 31 2927 Old Tobacco Rd,Hephzibah,GA,30815 53,500,00 32 2938 Arrowwood Cir,Hephzibah,GA,30815 $2,800.00 33 3507 Barker Dr,Hephzibah,GA,30815 $3,300.00 34 3643 Karleen Rd,Hephzibah,GA,30815 $2,700.00 35 3706 Claybom Dr,Hephzlbah,GA,30815 $2,800.00 36 3706 Elmwood Ct,Hephzlbah,GA,30815 $2,600.00 37 3708 Lynncrest Dr,Hephzibah,GA,30815 $2,600.00 38 3713 Hickory Cove Rd,Hephzibah,GA,30815 $2,700.00 39 3715 Clayborn Dr,Hephzibah,GA,30815 $2,300.00 40 3716 Crest Dr,Hephzibah,GA,30815 $3,200.00 41 3731 Fairington Dr,Hephzlbah,GA,30815 $3,650.00 42 3736 Crest Dr,Hephzibah,GA,30815 $2,500.00 43 3736 Fairington Dr,Hephzibah,GA,30815 $2,700.00 44 3741 Fairington Dr,Hephzlbah,GA,30815 $2,700.00 45 3746 Fairington Dr,Hephzibah,GA,30815 54,100.00 46 3758 Fairington Dr,Hephzibah,GA,30815 $4,400.00 47 3762 Fairington Dr,Hephzibah,GA,30815 $5,200.00 48 3778 Fairington Dr,Hephzlbah,GA,30815 $3,720.00 49 3795 Fairington Dr,Hephzibah,GA,30815 $3,450.00 50 3814 Farrington Dr,Hephzibah,GA,30815 $2,970.00 51 3823 Crest Dr,Hephzibah,GA,30815 $2,775.00 52 3824 Crest Dr,Hephzibah,GA,30815 $2,320.00 53 3835 Fairington Dr,Hephzibah,GA,30815 $2,600.00 54 3843 Fairington Dr,Hephzibah,GA,30815 $3,100.00 55 3850 Farrington Dr,Hephzibah,GA,30815 $3,100.00 56 3903 Crest Dr,Hephzibah,GA,30815 $2,300.00 57 3905 Crest Dr,Hephzlbah,GA,30815 $3,125.00 58 4109 Brooton Ct,Hephzibah,GA,30815 $3,370.00 59 4111 Country Ln,Hephzlbah,GA,30815 $3,200.00 60 4112 Country Ln,Hephzlbah,GA,30815 $3,250.00 61 4119 Brooton Ct,Hephzibah,GA,30815 53,820.00 62 4201 Cap Chat St,Hephzlbah,GA,30815 $3,500.00 Total Lots Awarded 16 lots Total Awarded Amount $43,495.00 UTILITIES DEPARTMENT Tom Wiedmeier,P.E. Marie Corbin,P.E. G E' OR G1 A Director Interim Assistant Director Sanitary Sewer Connection Program Final Liability Waiver and Release Address of property for which consent for entry and access being granted: Relationship to property: (i.e., owner, owner's representative, tenant, etc.) OWNER NAME: MAILING ADDRESS: PHONE NUMBER: The undersigned is (are) the owner(s), their representative(s), or otherwise control the real property at the location described above. I, the property owner listed above, participated in the Augusta, Georgia Sanitary Sewer Connection Program, and as such, consented to and authorized employees and authorized representatives of the Augusta Utilities Department, and employees and authorized representatives of Universal Plumbing and/or Southern Services to access my property in order to perform the required actions to complete the following: 1. verify location and depth of my sewer service;verify 2. location and depth of my septic tank; 3 survey my property for the sole purpose of collecting the necessary data to determine if or how I could be connected to the Augusta sewer; abandonment of Septic Tank; 4. rerouting of plumbing to connect to Augusta,Georgia's sewer system;restoration of 5. landscaping and property to original state;and; 6. (Other) 7. I understand and acknowledge that Sanitary Sewer Connection Program (SSCP) is a program through which the Augusta Utilities Department (AUD) engaged plumbers pursuant to RFQ 15- 139A to abandon my septic tank and reroute the plumbing to connect to Augusta's sewer system; I acknowledge that the cost I paid, or have been invoiced and agree to pay, to participate in the SSCP was a flat rate of Ten Dollars ($10.00) to be paid by the property owner, and further that thereafter, the property owner/occupant will receive and be responsible for paying a monthly sewer bill; I understand and acknowledge that the improvements shall remain with the property thus belonging to the property owner and therefore shall become the responsibility of the property owner to maintain. The work will be guaranteed by a one (1) year warranty between the plumber (Universal Plumbing and/or Southern Services) and the homeowner. Augusta shall not be responsible for the maintenance or repair of the private sewer line;