Loading...
HomeMy WebLinkAboutSUPPLEMENTAL AGREEMENT AUGUSTA, GEORGIA AND SOUTHERN SERVICES FOR SANITARY SEWER CONNECTION SERVICES TASK ORDER PROGRAM, PHASE II NOTICE OF AWARD G O R GI A Contractor: Southern Services Date: 2/14/2017 Address: 2630 Milledgville Road P.O.Box 5549 Augusta,GA. 36916 Project: SSCP Phase 2- Group 1 Project No: AUD_2015-02 At a meeting of the Augusta, Georgia Commission held on 10/18/2016 , you were awarded the contract for the following project: Sanitary Sewer Connection Service Phase 2 - Group 1 Enclosed please find 4 copies of the Contract Documents for your execution. Please complete the pages, affixing signatures, dates, notary and/or corporate seals, etc. where necessary and return to this office within 10 days from the date of this letter, excluding Legal Holidays. The Certificate of Insurance must be complete. Power of Attorney must be submitted in triplicate; an original and two copies is permissible. Very truly yours, Sylvester Rosier- Project Manger Receipt of this NOTICE OF AWARD is hereby acknowledge this qday of illAte l ,e74,11 p6 V 5 6t1-4-1\e_0\ Sip =co `!�� Contractor 5 By Title Please sign and return one copy of this Notice of Award Acknowledgement to: Augusta Utilities Department Attn: Sylvester Rosier/Marie Corbin,P.E. 360 Bay Street, Suite 180 Augusta, GA 30901 Engineering Division 360 Bay Street,Suite 180-Augusta,GA 30901 (706)312-4132—Fax(706)312-4133 WWW.AUGUSTAGA.GOV This SUMPLEMENTAL AGREEMENT,made on the 6day of `V 1 A P.L ,20 ,to the AGREEMENT,made on the 19th day of JANUARY,2017 by and between AUGUSTA,GEORGIA,BY AND THROUGH THE AUGUSTA-RICHMOND COUNTY COMMISSION,party of the first part,hereinafter called the OWNER, and SOUTHERN SERVICES, party of the second part,hereinafter called the CONTRACTOR. WITNES SETH,that the Contractor and the Owner, for the considerations hereinafter named, agree as follows: ARTICLE I- SCOPE OF THE WORK- The Contractor hereby agrees to furnish all of the materials and all of the equipment and labor necessary,and to perform all of the work shown on the plans and described in the specifications for the project entitled: SANITARY SEWER CONNECTION SERVICE—PHASE 2—GROUP 1 and in accordance with the requirements and provisions of the Contract Documents as defined in the General and Special Conditions hereto attached,which are hereby made a part of this agreement. ARTICLE II-TIME OF COMPLETION The work to be performed under this Contract shall be commenced within 5 business days after the date of written notice by the Owner to proceed.All work shall be substantially completed within 35 business days with all such extensions of time as are provided for in the General Conditions. Substantial completion shall be defined as all lots awarded connected to the city sewer system, all septic tanks abandoned. Final completion shall be 9 days after substantial completion. Final completion shall be defined as a representative of each property has signed off on the completeness and acceptance of work,example included. It is hereby understood and mutually agreed,by and between the Contractor and the Owner,that the date of beginning, rate of progress and the time for completion of the work to be done hereunder are ESSENTIAL CONDITIONS of this contract.Contractor agrees that said work shall be prosecuted regularly, diligently,and uninterruptedly at such rate of progress as will ensure full completion thereof within the time specified.It is expressly understood and agreed by and between the Contractor and the Owner,that the time for completion of the work described herein is a reasonable time for completion of the same, taking into consideration the average climatic range and construction conditions prevailing in this locality. Wage ARTICLE III—PAYMENT (A)The Contract Sum The Owner shall pay to the contractor for the performance of the Contract the amount as stated in the BID FORM and Schedule of Items. No variations shall be made in the amount except as set forth in the specifications attached hereto. (B) Progress Payment On no later than the fifth day of every month,the Contractor shall submit to the Owner's Engineer an estimate covering the percentage of the total amount of the Contract which has been completed from the start of the job up to and including the last working day of the preceding month, together with such supporting evidence as may be required by the Owner and/or the Engineer.This estimate shall include only the quantities in place and at the unit prices as set forth in the Bid Schedule. On the vendor run following approval of the invoice for payment,the Owner shall after deducting previous payments made,pay to the Contractor 90%of the amount of the estimate on units accepted in place.The 10%retained percentage may be held by the Owner until the final completion and acceptance of all work under the Contract. ARTICLE IV-ACCEPTANCE AND FINAL PAYMENT (A) Upon receipt of written notice that the work is ready for final inspection acceptance,the Engineer shall within 10 days made such inspection, and when he finds the work acceptable under the Contract and the Contract fully performed,he will promptly issue a final certificate,over his own signature,stating that the work required by this Contract has been completed and is accepted by him under the terms and conditions thereof. The contract shall then submittal a final payment request for the entire balance found to be due the Contractor including the retained percentage. This payment shall be paid to the Contractor by the Owner within 30 days after the date of the receipt of the final payment request. (B) Before final payment is due,the Contractor shall submit evidence satisfactory to the Engineer that all payrolls, material bills, and other indebtedness connected with work have been paid, except that in case of disputed indebtedness of liens of evidence of payment of all such disputed amounts when adjudicated in cases where such payment has not already been guaranteed by surety bond. (C) The making and acceptance of the final payment shall constitute a waiver of all claims by the Owner, other than those arising from unsettled liens,from faulty work appearing within 12 months after fmal payment, from requirements of the specifications,or from manufacturer's guarantees.It shall also constitute a waiver of all claims by the Contractor except those previously made and still unsettled. (D) If after the work has been substantially completed, full completion thereof is materially delayed through no fault of the Contractor, and the Engineer, so certifies, the Owner shall upon certification of the Engineer,and without terminating the Contract,make payment of the balance due for that portion of the work fully completed and accepted. Each payment shall be made under the terms and conditions governing final payment,except that it shall not constitute a waiver of claims. 21Page 4 IN WITNESS WHEREOF,the parties hereto have executed this Agreement in three(3)counterparts, each of which shall be deemed an original, in the year and day first mentioned'a-bnve.-•--•r--...,....,.,,, ii OWNER: AUGUSTA,GEORGIA p �4•01,wom c't_ AT EST-‘'` ',,„c7 : '"to.9,,T. SEAL r By: k.i ...0 ..' By /. , ., � , ti , OA The Honorable Hardie Davis,Jr. 4 a J.B • hefoo®o E / Mayor Clerk oft 116 Afr. „4`:_�..w..*"itr y • Date: date:, U 1 ,,D,'• A D , Ali ;t � .1 C APPROVED AS TO FORM: DEPARTMENT APPROVAL:, ,,.. By: d" ( By: /tvw )W Thomas D. Wiedmeier Attorney Director,Augusta Utilities Department Date: 3/2 Oh 7 Date: '4/70-.1/17 CONTRACTOR: ‘en,Ne1,j ��� i"i�� ATTEST: �:e tate i }'l,' A/ � , CG = OZ- By� ). c_ _ 1`�..I . i By %__j lS!/Y��... •ti pub .• O Name: ��orl 2 1 ..„-_,A i TL Name:71eW. • 1�� '°o:apCoun<�`��``. Title: 7t--2;"3"t,A-eti\--� Title: ' L� I ',it Date: MAP,U k , 1(") Date: .4-+r I- 01 bah q 3IPage Southern Services Awarded Lots-SSCP Phase 2 Group 1 Description Southern 2 1910 Colony Park Rd, Augusta, GA, 30909 1 LS 4 2326 Boykin Rd, Augusta, GA, 30906 1 LS 5 2503 Anthony DeJuan Pkwy, Hephzibah, GA 1 LS 30815 8 2542 Spirit Creek Rd, Hephzibah, GA, 30815 1 LS 10 2568 Anthony DeJuan Parkway, Hephzibah, 1 LS GA 30815 12 2602 Anthony DeJuan Pkwy, Hephzibah, GA 1 LS 30815 14 2609 Teakwood Dr, Hephzibah, GA, 30815 1 LS 17 2616 Carrington Dr, Hephzibah,GA, 30815 1 LS 26 2871 Pepperdine Dr, Hephzibah,GA, 30815 1 LS 32 3002 Hollins Dr, Hephzibah, GA, 30815 1 LS 33 3529 Bullock Avenue,Augusta, GA 30815 1 LS 34 3705 Clayborn Dr, Hephzibah, GA, 30815 1 LS 36 3710 Teakwood Ct, Hephzibah, GA, 30815 1 LS 37 3714 Elmwood Ct, Hephzibah,GA, 30815 1 LS 40 3719 Lynncrest Dr, Hephzibah,GA, 30815 1 LS 41 3721 Beacon Hill Dr, Hephzibah, GA, 30815 1 LS 43 3724 Beacon Hill Dr, Hephzibah, GA, 30815 1 LS 45 3743 Clayborn Dr, Hephzibah, GA, 30815 1 LS 46 3784 Fairington Dr, Hephzibah,GA, 30815 1 LS 48 3791 Fairington Dr, Hephzibah,GA, 30815 1 LS 51 3809 Fairington Dr, Hephzibah,GA, 30815 1 LS 52 3815 Fairington Dr, Hephzibah, GA, 30815 1 LS 53 3824 Fairington Dr, Hephzibah, GA, 30815 1 LS 54 3831 Fairington Dr, Hephzibah, GA, 30815 1 LS 58 3865 Fairington Dr, Hephzibah, GA, 30815 1 LS 59 3910 Fairington Dr, Hephzibah,GA, 30815 1 LS 60 3912 Barnett Crossing,Augusta GA 30909 1 LS 62 3917 Lake Erie Dr, Hephzibah,GA 30815 1 LS 63 3918 Fairington Dr, Hephzibah, GA, 30815 1 LS 64 4124 Country Ln, Hephzibah, GA, 30815 1 LS ■ Total- $75,881.00 ______.......ungq, SOUTH36 OP ID: K2 AC'ORO" CERTIFICATE OF LIABILITY INSURANCE DATE(MM 46.------- 03/071/20172017 ) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(les)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER 706-868-1610 CONTACT Donald Skinner Jr ACRS Insurance NAME' P O Box 2897 (A/C,N,Ext):706 68-1610 I FAX 706-860-5134 ,No): Evans,GA 30809 EMAIL dskinnernachsinsurance.com Donald Skinner Jr ADDRESS: INSURER(S)AFFORDING COVERAGE NAIC 0 INSURER A:Liberty Mutual Insurance 23035 INSURED Southern Services INSURER B:Builders Insurance 012026 P O.Box 5549 Augusta,GA 30916 INSURER c INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. LTR u"so POLICY NUMBER SUBR POLICY EFF POLICY EXP RTYPE OF INSURANCE LIMITS (MMIDDIYYYY) (MMIDDIYYYY) A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE X OCCUR BKS1755867904 03/08/2017 03/08/2018 pREM SEs Ea oNcu ante! $ 300,000 MED EXP(Any one person) $ 15,000 PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER- GENERAL AGGREGATE $ 2,000,000 POLICY JECT LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: $ A AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT 1,000,000 (Ea accident) $ X ANY AUTO BA5970800 03/08/2017 03/08/2018 BODILY INJURY(Per person) $ OWNED SCHEDULED AUTOSEONLY AUTOS BODILY INJURY(Per accident) $ X AUTOS ONLY X AUTOSONLYY PROPERTY DAMAGE $ $ UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ $ B AND WORKERSCOMPENSATIONLIIAABR�T' YINX STATUTE ER PER H ANY PROPRIETORIPARTNERIEXECUTIVE WCV002815313 10/24/2016 10/24/2017 E.L.EACH ACCIDENT $ 1,000,000 (Mandatory nBNHj EXCLUDED? N 1 A 1,000,000 E.L.DISEASE-EA EMPLOYEE $ If yes,describe under 1,00%000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ DESCRIPTION OF OPERATIONS 1 LOCATIONS I VEHCLES (ACORD 101,Additional Remarks Schedule,may be attached W more space is required) CERTIFICATE HOLDER CANCELLATION CITYAUG SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE ' of Augusta THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN The City g ACCORDANCE WITH THE POLICY PROVISIONS. Augusta,GA AUTHORIZEDZ�ED REPRESENTATIVE 1 / ACORD 25(2016/03) ©1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD Bond No. SB 0609602 PREMIUM BASED ON FINAL CONTRACT PRICE PERFORMANCE BOND (NOTE: THIS BOND IS ISSUED SIMULTANEOUSLY WITH PAYMENT BOND ON PAGE 6, IN FAVOR OF THE OWNER CONDITIONED FOR THE PAYMENT OF LABOR AND MATERIAL) KNOW ALL MEN BY THESE PRENSENTS: That George E Petrea,Jr. Inc.dba:Southern Services _ as Principal, hereinafter called Pennsylvania National Mutual Contractor,and Casualty Insurance Company ,a corporation organized and existing under the laws of the State of Pennsylvania with its principal office in the City of Harrisburg ,State of Pennsylvania , asSurety, hereinafter called Surety, are held and firmly bound unto AUGUSTA, GEORGIA BY AND THROUGH TIDE AUGUSTA COMMISSION as Obligee,herein after called the Owner, Seventy Five Thousand Eight in the penal amount of Hundred Eighty One Dollars ($75,881:00 for the payment whereof Contractor and Surety bind themselves,their heirs,executors,administrators,successors,and assigns,jointly and severally,firmly by these presents for the faithful performance of a certain written agreement, WHEREAS,Contract has by said written agreement dated March 6, 2017 entered in to a contract with Owner for the Sanitary Sewer Connection Services Task Order Program is accordance with the drawings and specifications issued by the Augusta Utilities Department and the Augusta-Richmond County Commission, which contract is by reference made a part hereof, and is hereinafter referred to as the CONTRACT, NOW,THEREFORE,the condition of this obligation is such that,if Contractor shall promptly and faithfully perform said CONTRACT,then this obligation shall be null and void;otherwise it shall remain in full force and;effect. The Surety hereby waives notice of any alteration or extension of time made by the Owner. 4jPa,ge Whenever Contractor shall be, and declared by Owner to be in default under the CONTRACT, the Owner having pet:-formed Owner's obligations thereunder, the Surety may promptly remedy the default,or shall promptly (1) Complete the CONTRACT in accordance with its terms and conditions,or (2) Obtain a bid or bids for completing the Contract in accordance with its terms and conditions, and upon determination by Surety of the lowest responsible bidder,or,if the Owner elects, upon determination by the Owner and the Surety jointly of the lowest responsible bidder, arrange for a contract between such bidder and Owner, and make available as Work progresses(even though there should be a default a succession of defaults under the contract or contracts ofcompletion arranged under this paragraph)sufficient funds to pay the cost of completion less the balance of the contract price,but not exceeding,including other costs and damages for which the Surety may be liable hereunder,the amount set forth in the first paragraph hereof: The teen."balance of the contract price,"as used in this paragraph,shall mean the total amount payable by Owner to Contractor under the Contract and any amendments thereto,less the amount properly paid by Owner to Contractor Any suit under this`bond'must be instituted before the expiration of two(2)years from the date on which final payment under the CONTRACT falls due. No right of action shall accrue on this bond to or for the use of any person or corporation other than the Owner named herein or the heirs,executors,administrators or successors of the Owner. Signed and sealed this 13th day of March A.D.2017; George E. Petrea,Jr. Inc. Witness %Q n dba_Southern Services (Seal) W) -.- wr.rt... 1CV)l i 1 (Con . . ) l ii0Attest Db�.�, 0R - �� ... ..x.:1.1,A.. (Seal) ,(0 Georg E. 'etreae r.(Title) Presides' Pennsylvania National Mutual Witness . ,,e. , / /um Casual Insurance om•an (Seal) - r ( I ) a zer ,... illp ii, Witness By - J _-41tSeal) Mark,l ' rch r )Attor -.NV Pact SIPage Bond No. SB 0609602 LABOR AND MATERIAL PAYMENT BOND (NOTE: THIS BOND IS ISSUED SIMULTANEOUSLY WITH PERFORMANCE BOND ON PAGE 4,IN FAVOR OF THE OWNER.CONDITIONED FOR THE PAYMENT OF LABOR AND MATERIAL) KNOW ALL MEN BY THESE PRENSENTS; That George E. Petrea, Jr. Inc.cdba: Southern Services as Principal, hereinafter called Pennsylvania National Mutual Contractor,and Casualty Insurance Company ,a corporation organized and existing under the laws of the State of Pennsylvania ,with its principal office in the City of Harrisburg ,State of Pennsylvania , as Surety, hereinafter called Surety, are held and firmly bound unto AUGUSTA, GEORGIA BY AND THROUGH THE AUGUSTA COMMISSION as Obligee,herein after called the Owner, Seventy Five Thousand Eight for the use and benefit of claimants as herein below defined,in the amount of Hundred Eighty One Dolllars ($75,881.00 ) for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators,successors,and assigns,jointly and severalty,firmly by these presents. WHEREAS,Contract has by written agreement dated March 6, 2017 entered in to a contract with Owner for the Sanitary Sewer Connection Services Task Order Program io accordance with the drawings and specifications issued by the Augusta Utilities Department and the Augusta-Richmond, County Commission, which contract is by reference made a part hereof, and is hereinafter referred to as the CONTRACT. NOW, THEREFORE, the condition of this obligation is such that,if the Contractor shall promptly make payment to all claimants as hereinafter defined,for all labor and material used orreasonablyrequired to use in the performance of the CONTRACT,then this obligation shall be void;otherwise it shall remain in full force and effect,subject,however,to the following conditions: (1) A claimant is defined as one having a direct contract with the Contractor or with a subcontractor of the Contractor for labor,material,or both,used or reasonablyrequired for use in the performance of the contract,labor and material being construed as to include that part of water,gas,power,light,heat,oil,gasoline,telephone service or rental of equipment directly applicable to the CONTRACT. (2) The above named Contractor and Surety hereby jointly and severally agree with the Owner that every claimant as herein defined,who has not been paid in full before the expiration of a period of ninety(90)days after the date on which the last of such claimant's work or labor was done or perforated,or materials were furnished by such claimant,may sue on this bond for the use of such claimant,prosecute the suit to final judgment for such sum or sums as may be justly due claimant,and have execution thereon.The Owner shall not be liable for the payment of any costs or expenses of any such suit. Wag (3) No suit or action shall be commenced hereunder by any claimant, (a) Unless claimant,other than one having a direct contract with the Contractor,shall have given written notice to any two of the following:The Contractor,the Owner,or the Surety above named, within ninety (90) days after such claimant did or performed the last of the work or labor,or furnished the last of the materials for which said claim is made,stating with substantial accuracy the amount claimed and the name of the party to whom the materials were furnished,or for whom the work or labor was done or performed.Such notice shall be served by mailing the same by registered mail or certified mail,postage prepaid,in an envelope addressed to the Contractor,Owner or Surety,at anyplace whore an office regularly maintained for the transaction of business,or served in any manner in which legal process may be served in the state in which the aforesaid project is located,save that such service need not be made by a public officer. (b) After the expiration of one(1)year following the date on which Contractor ceased work on said CONTRACT,it being understood, however, that if any limitation embodied in this bond is prohibited by any law controlling the construction hereof, such limitation shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by such law. (c) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state in which the project,or any part thereof,is situated, or in the United States District Court for the district in which the project,or any part thereof,is situated,and not elsewhere. (4) The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith hereunder,inclusive of the payment by Surety of mechanics'liens which may be tiled ofrecord against said improvement,whether or not claim for the amount of such lien be presented under and against this bond. Signed and sealed this 13th day of March A.D.2017, George E. Petrea,Jr., Inc. f-.....2414.44, Witness v., 1J0.�..A.A<, dba: Southern Services (Seal) J P.'n w —Sw.m„ 1' ►Z01`J (Contract.r) i k . Attest Ab))it°.. . 6141 1)'s B%►, ,, . 1 ,ft..VP,' _�( eal) Y\Oi .t1,41 George E. "etrea, 37(Title) President �1 OP Pennsylvania Nationa Mutual Witness (,U' . A 1 i ,100, Casual Insur.face ("mean -al) 0 01107A 1C) Witness —rIMar.1:1 `itch,\(Title) ort ey-i -F ct,- 7'IPage PENNSYLVANIA NATIONAL MUTUAL CASUALTY INSURANCE COMPANY Harrisburg,Pennsylvania POWER OF ATTORNEY Know All Men By these Presents,That PENNSYLVANIA NATIONAL MUTUAL CASUALTY INSURANCE COMPANY,a corporation of the Commonwealth of Pennsylvania,does hereby make,constitute and appoint Mark J.Kirch ,of Lilburn,GA its true and lawful Attorney-in-Fact to make,execute,seal and deliver for and on its behalf,as surety,as its act and deed: ANY AND ALL BONDS AND UNDERTAKINGS PROVIDED THE AMOUNT OF NO ONE BOND OR UNDERTAKING EXCEEDS THE SUM OF TEN MILLION DOLLARS-- -- ------- ($10,000,000.00). Bond Number SB 0609602 Principal:George E. Petrea, Jr., Inc. DBA Southern Services Obligee:Augusta, Georgia by and through the Augusta Commission ALL POWER AND AUTHORITY HEREBY CONFERRED SHALL HEREBY EXPIRE AND TERMINATE WITHOUT NOTICE AT MIDNIGHT ON OCTOBER 31,'2020,AS RESPECTS EXECUTION SUBSEQUENT THERETO. And the execution of such bonds in pursuance of these presents shall be as binding upon said Company as fully and amply,to all intents and purposes,as if they had been duly executed and acknowledged by the regularly elected officers of the Company at its office in Harrisburg, Pennsylvania,in their own proper persons. This appointment is made by and under the authorization of a resolution adopted by the Board of Directors of the Company on October 24,1973 at Harrisburg,Pennsylvania which is shown below and is now in full force and effect. RESOLVED,that(1)the President,any Vice President,the Secretary,or any Department Secretary shall have power to appoint,and to revoke the appointments of,Attorneys-in-Fact or agents with power and authority as defined or limited in their respective powers of attorney,and to execute on behalf of the Company,and affix the Company's seal thereto,bonds,undertakings,recognizance's,contracts of indemnity and other written obligations in the nature thereof or related thereto;and(2)any of such Officers of the Company may appoint and revoke the appointments of joint-control custodians, agents for acceptance of process,and Attorneys-in-Fact with authority to execute waivers and consents on behalf of the Company;and(3)the signature of any such Officer or of any Assistant Secretary or Department Assistant Secretary and the Company seal may be affixed by facsimile to any power of attorney or certification given for the execution of any bond,undertaking,recognizance,contract of indemnity or other written obligation in the nature thereof or related thereto,such signature and seal when so used whether heretofore or hereafter,being hereby adopted by the Company as the original signature of such Officer and the original seal of the Company,to be valid and binding upon the Company with the sameforce and effect as though manuallyaffixed. In Witness Whereof•.PENNSYLVANIA NATIONAL MUTUAL CASUALTY INSURANCE COMPANY has caused these presents to be signed and its corporate seal to be hereto affixed on November 1,2016. PENNSYLVANIA NATIONAL MUTUAL CASUALTY INSURANCE COMPANY Mark F. Id,Vice President-Sure Commonwealth of Pennsylvania,County of Dauphin—ss: On November 1,2016,before me appeared Mark Fitzgerald to me personally known,who being by me duly sworn,did say that he resides in the New Jersey,that he is the Vice President-Surety of PENNSYLVANIA NATIONAL MUTUAL CASUALTY INSURANCE COMPANY,that he is the individual described in and who executed the preceding instrument,and that the seal affixed to said instrument is the corporate seal of said Company,and that said instrument was signed and sealed on behalf of said Company by authority and direction of said Company,and the said office acknowledged said instrument to be the free act and deed of said Company. �► roMMi COMMONWEALTH OF PENNSYLVANIA ; + aye Notarial Seal •NOTARY euauc• Traci A Kiimmich,Notary Public �• City Of Harrisburg,Dauphin County ;.ti3L C • ‘.$,6;11.:1„5e„," My Commission Expires Oct 31,2020 °FMember,Pennsylvania Association of Notaries Notary Public I,Mark Fitzgerald,Vice President-Surety of the PENNSYLVANIA NATIONAL MUTUAL CASUALTY INSURANCE COMPANY,a corporation of the Commonwealth of Pennsylvania,do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney, executed by the said Company,which is still in full force and effect. m ukTu „� 1%4° ptM.e C4w ✓� g�,n.. In Witness Whereof,I have hereunto set my hand and affixed the corporate seal of said Company on March 13, 2017. ,Y twit4 c Ili Vice Preside r)�/ ty ` VAmitiamadio 78-190e(Rev 10/2012)