HomeMy WebLinkAboutDigester Modifications Messerly Wastewater Treatment Plant
Augusta Richmond GA
DOCUMENT NAME: d\C\e:::.te:.y ~\~ecmtX\~ Me0SCY\Y l01?;\e.u:JQ-\"e,
nectt~ ?\Q~\-
DOCUMENT TYPE:
YEAR: C\15
BOX NUMBER: ~
FILE NUMBER: \L\L\(;)3
NUMBER OF PAGES: l.\d~
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
~~# /~~33
Project Manual
Digester Modifications
Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
BID NO. 99-057
PREPARED FOR:
AUGUSTA-RICHMOND COUNTY COMMISSION
Bob Young, Mayor
Lee N. Beard - District 1
Freddie L. Handy - District 2
Steve Shepard - District 3
Richard Colcough - District 4
Henry L. Brigham - District 5
J. B. Powell - District 6
Jerry Brigham - District 7
Ulmer Bridges - District 8
William H. Mays, III - District 9
William B. Kuhlke, Jr. District 10
AUGUSTA-RICHMOND COUNTY UTiliTIES DEPT.
Max Hicks - Director
September 1998
PREPARED BY:
Freeman & Vaughn Engineering, Inc.
P.o: Box 15027
Augusta, Georgia 30919
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Addendum No.1
April 22, 1999
ADDENDUM NO. 1
to the
BIDDING DOCUMENTS
for
Digester Modifications
Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
All Bidders and other interested parties are hereby notified of the following additions and or
revisions to the plans and specifications for the referenced project.
SPECIFICATIONS
SECTION 00120 - BID PROPOSAL
This section is being reissued with this addendum.
SECTION 02190 - DIGESTER CLEANING
PART 1 - GENERAL
1.02 DESCRIPTION OF WORK:
Change this section to read as follows:
"A. The work under this contract includes all labor, material, chemicals, supplies, equipment,
transportation, water supply, electrical power and other incidentals required for the
removal, dewatering, transportation and disposal of all sludge, grit accumulations, rags,
hair, grease, plastics and other debris present in the six anaerobic digesters and high
pressure water cleaning of the interior walls, floor and piping in the digesters. The
Page 1 of 3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Addendum NO.1
April 22, 1999
Contractor shall remove all digester contents encountered, regardless of composition.
The Contractor shall pay all tipping and/or disposal fees.
B. The Contractor will be paid on a unit price basis for the removal of digester contents
based on the dry weight measure of material removed from the digesters, at the unit
price shown in the Bid Proposal. Tipping and/or disposal fees shall be included in the
unit price for cleaning. Cleaning of interior walls, floor and piping will not be paid as a
separate item but shall be included in the unit price bid for digester cleaning. The basis
of payment for work will be the actual amount of work performed. The Contractor
agrees to make no claim for damages, anticipated profits or otherwise on account of any
difference between the amounts of work actually and the estimated amounts included in
the BID PROPOSAL. The Contractor will not be paid for any work which exceeds 25
percent of the quantity set forth in the Bid Schedule without a change order issued
before the work is performed unless specifically ordered in writing by the Owner.
Sampling and analysis of materials being removed will be provided by the Owner or an
Owner-selected laboratory. Suspended Solids analysis will be the basis for determining
the dry weight of materials removed. The Contractor shall provide weight-tickets for
tare and loaded weight for each load removed from the digesters. Payment will be
made on the basis of dry tons removed."
SECTION 05430 - FIXED ALUMINUM DOME TANK COVER
PART 1 - GENERAL
1.04 DESIGN:, Article I shall be changed to read as follows:
"I. The vertical loads transferred from the roof to the tank shall be in line with the tank
support wall. The transfer of horizontal loads to the tank shall be minimized by means of
a plate attached to the top of the tank wall. Radial forces applied to the tank shall not
exceed 10% of the vertical reactions. If the dome is fixed to the basin wall, the seal shall
be continuous around the circumference of the wall between the dome flashing and the
concrete wall with anchors spaced 12 inches on center."
SECTION 11800 - DIGESTER SLUDGE MIXERS
PART 2 - PRODUCTS
2.01 DRAFT TUBE MIXERS - GENERAL
Add the following to Article B:
"Mixers shall be designed to operate with the digester operating levels of elevation 144.0
minimum and elevation 158.50 maximum."
Page 2 of 3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.97 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Addendum No. 1
April 22, 1999
2.03 COVER MOUNTED DRAFT TUBE DESIGN
Add the following to Article A:
"The center mixer for the fixed cover (Digester No.1) shall be supported from the floor of
the Digester and a water seal arrangement at the point of penetration of the roof shall be
provided for sealing the penetration of the mixer. Coordinate details of mixer support with
the manufacturer of the Digester Cover specified in Section 05430. Provide water supply
piping and necessary control valves for maintenance of the water seal arrangement.
Center mounted mixers shall be equipped with sliding guide supports for internal gas piping
as shown on the drawings. For designs which do not permit this type of support, an
independent support shall be provided for the internal gas piping."
PART 3 - EXECUTION
Add the following Paragraphs to this Section:
"3.06 VIBRATION LIMITATIONS
The mixer manufacturer shall provide equipment which, when installed and operating at
design conditions, will meet ISO 9001 Standard 2372 vibration criteria. The manufacturer
shall demonstrate to the Owner that vibration, as measured at the mixer upper bearing
housing shall not exceed 0.18 inches/see rms."
3.07 WARRANTY
The mixer manufacturer shall warrant each mixer in writing against defects in
workmanship and material for a period of five years or 1 0,000 hours of normal use,
operation and service. The warranty shall be in printed form and apply to all similar units."
END OF ADDENDUM NO.1
Page 3 of 3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
'1
I
I
I
SECTION 00120 - BID PROPOSAL
Addendum NO.1
April 22, 1999
AUGUSTA-RICHMOND COUNTY COMMISSION
MUNICIPAL BUILDING
AUGUSTA, GEORGIA 30911
PROJECT TITLE: DIGESTER MODIFICATIONS
MESSERLY WASTEWATER TREATMENT PLANT
AUGUSTA-RICHMOND COUNTY, GEORGIA
BID ITEM NO.: 99-057
Gentlemen:
The undersigned Bidder, herein referred to as singular and masculine, declares the
following:
1. The only parties interested in the proposal as principals are named herein;
2. He has carefully examined and fully understands the contract documents,
including the drawings and specifications;
3. He understands that information relative to existing structures and underground
utilities as furnished to him on the drawings, Contract Documents or by the
Augusta-Richmond County Utilities Engineer/Director, carries no guarantee
expressed or implied as to its completeness or accuracy and he has made due
allowances therefor;
4. He has made a personal examination of the site of the proposed work and has
satisfied himself as to the actual conditions and requirements of the work;
5. He agrees to hold the Owner harmless for accidents or damages to property;
6. He will comply with all State and Federal regulations pertaining to but not limited to
asbestos containing material removal and disposal, regulations regarding disposal
of all debris and OSHA requirements;
7. He will complete the work in a timely manner. The required time of completion is
indicated in the Bid Proposal Form;
8. He will maintain the site as clean as possible by not allowing debris to accumulate
before making trips to his disposal site. Materials sold for salvage shall not be
accumulated on the project site.;
BID PROPOSAL
00120-1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Addendum No.1
April 22, 1999
9. He will not burn any materials on site without written approval from proper
authorities;
10. He will furnish the Owner with a detailed schedule of demolition and removal,
including disposal sites, names of all subcontractors, State and local license
information;
and hereby proposes and agrees to furnish all materials, labor, skill, equipment, tools,
and other things of every kind and description specified, needed or used for the complete
execution of all work covered by and in conformity with the Plans, specifications, and
other Contract Documents prepared by Freeman & Vauqhn Engineering, Inc., Consulting
Engineers and all Amendments and Addenda thereto, for the sums hereinafter stated.
LUMP SUM PRICES:
The undersigned agrees to provide all labor, materials, and equipment necessary to
perform the work described in the plans, specifications, addenda, etc., all of which
comprise the project manual, for the price of:
1. Digester Cleaning:
960 Tons (Dry Weight Measure) at $ / Ton (Enter Unit Price)
equals Total Price $
2. Replace Cover Digester No. 1 Lump Sum $
3. Paint Cover Digester NO.2 (Interior & Exterior) Lump Sum $
4. Paint Cover Digester NO.3 (Interior & Exterior) Lump Sum $
5. Paint Cover Digester NO.4 (Interior & Exterior) Lump Sum $
6. Paint Cover Digester NO.5 (Interior & Exterior) Lump Sum $
7. Paint Cover Digester NO.6 (Interior & Exterior) Lump Sum $
8. Remove & Replace Mixing System
Digester No. 1 Lump Sum $
9. Remove & Replace Mixing System
Digester No.2 Lump Sum $
10. Remove & Replace Mixing System
Digester NO.4 Lump Sum $
11. Remove & Replace Mixing System
Digester NO.5 Lump Sum $
BID PROPOSAL 00120-2
I
I Addendum NO.1
April 22, 1999
I 12. Remove and Replace Sludge Heating
I System - Digester Control Room 1 Lump Sum $
13. Remove and Replace Sludge Heating
I System - Digester Control Room 2 Lump Sum $
14. Repair 250 SF of Masonry Veneer
I Digester NO.2 Lump Sum $
15. Provide Stone Cover over Digester
I Grounds Lump Sum $
16. Modify Valve Vault Piping Lump Sum $
I Total of Construction (Sum of Items 1 thru 16) $
I
I
I
I
I
I
I
I
I
I
I BID PROPOSAL 00120-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Addendum NO.1
April 22, 1999
Notice to Proceed from the Owner and to complete fully all work within 360 calendar
days. It is also agreed that 45 days are included in the specified contract time for
adverse weather days.
Enclosed herewith is a Bid Bond in the amount of
DOLLARS ($ ) being not less than 10% of the Base Bid. The Bid
Bond must be submitted on the required form provided with the Invitation to Bid.
If this Proposal is accepted within sixty (60) days after the date set for the opening of bids
and the undersigned fails to execute the Contract within ten (10) calendar days after
receipt from the OWNER/Engineer, or if he fails to furnish both a Performance Bond and
Payment Bond, the obligation of the Bid Bond will remain in full force and effect and the
money payable thereon shall be paid into the funds of the Owner as liquidated damages
for such failure; otherwise the obligation of the Bid Bond will be null and void.
This Bid Proposal is respectfully submitted by:
Bidder (Print Name)
Signature (Owner, Partner or
Corp. Officer)
Address
Title
If Corporation, affix seal here
Telephone Number
(SEAL)
BID PROPOSAL
00120-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Addendum NO.1
April 22, 1999
Item
Description
Manufacturer
Installed
Cost
Base
Bid
4. Plug Valves
(Spec Section 15110)
A. Base Bid
B. Substitute:
ALTERNATE NO.1 - HOT OIL HEATING SYSTEM
Under this Alternate the Contractor shall furnish a Hot Oil Packaged Hot Water Heating
System as specified in Section 15625 in lieu of the Packaged Hot Water Heating
System as specified in Section 15620. This alternate supercedes the pricing for Items
8 and 9 in the Bid Schedule should the Owner elect to exercise this alternate:
a. Remove and Replace Sludge Heating
System - Digester Control Room 1
Lump Sum $
b. Remove and Replace Sludge Heating
System - Digester Control Room 2
Lump Sum $
The undersigned agrees that this Proposal may not be revoked or withdrawn after the
time is set for the opening of bids but shall remain open for acceptance for a period of
sixty (60) calendar days following such time.
In case the bidder is given in writing by mail, telegraph, or delivery the Notice of
Acceptance of the Bid Proposal within sixty (60) days after the time for the opening of
bids, the undersigned agrees to execute within ten (10) calendar days a Contract (Form
of Agreement between Contractor and Owner) for the work for the above-stated
compensation and at the same time to furnish and deliver to the Owner a Performance
Bond, Payment Bond, Certificate of Insurance, and Contractor Certification forms in
accordance with the instruction bound in the Project Manual.
The undersigned agrees to commence actual physical work on the site with an adequate
force and equipment within ten (10) calendar days from the date to be specified in the
BID PROPOSAL 00120-5
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Addendum NO.1
April 22, 1999
Schedule of Equipment
The following are designated as major material items to be furnished under the Digester Modifications.
The bidder must bid one of the listed materials by extending the cost to the Base Bid Column and circling
the appropiatemanufacturer. Bidder must also provide pricinq for other listed manufacturers shown in the
proposal or his bid may be considered non-responsive.
Item Description Manufacturer Installed Add(+)Deduct(-) Base
Cost Cost for Bid
Substitution
1 Fixed Aluminum Dome
Tank Cover
(Spec Section 05430)
A. Base Bid
Conservatek I!:!:!...:::::::::::.....:::::::.....::::::::::::. .......:::::::.::::::::::iii:!:!!!:.}:/::::.....:!::ii:i!::1:::1;
B. Substitute: _''''';''$.;00''71'.
2. Digester Mixers ::::~
(S pec Section 1 1 800)
A. Base Bid
WesTech Engi neeri ng, I nc ... "::::::::::::::::m:::::W;:t:::f::::i::r.. j:!ij::::{::J::"\t... ....... "!iiiiiii!'{i?! f:tt
,_~~~i.
B. Substitute:
3. Packaged Hot Water ~~~ :.::nr::::::::::::!:::j:i{:::i:::::j:j):i:)::ji/\:):;?i?
::::::' . . :::::::{}}:!::" "" " ::::it(
Heating System }::::;:;('::::,:::::::):;);:;:;')\i::::i:i::::)::i':/M::i
(Spec Section 1 5620) . . ... .... "
.. .... . .... .
A. Base Bid Cleaver-Brooks
Fulton Boiler
B. Substitute: --
BID PROPOSAL
00120-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Addendum NO.2
April 27, 1999
ADDENDUM NO.2
to the
BIDDING DOCUMENTS
for
Digester Modifications
Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
All Bidders and other interested parties are hereby notified of the following additions and or
revisions to the plans and specifications for the referenced project.
SPECIFICATIONS
SECTION 00120 - BID PROPOSAL
Page No. 00120-5 and 00120-6 are being reissued with this addendum.
SECTION 01002 - SPECIAL CONDITIONS
PART 1 - GENERAL
1.07 PROJECT STAGING:
Add the following:
liAs an alternate to making digesters available on a one-at-a-time basis, the Owner will
allow the Contractor to sequence the work as follows:
1. Clean, modify and place into service Digester NO.1.
Page 1 of 2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 1240100
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Addendum No.2
April 27, 1999
2. Once Digester NO.1 has been commissioned, Digester 2 and 3 may be
removed from service, cleaned, modified and placed into operation together.
3. Once Digesters 1,2 & 3 have been commissioned, clean, modify and place
into service Digester NO.4.
4. Once Digester NO.4 has been commissioned, Digester 5 and 6 may be
removed from service, cleaned, modified and placed into operation together."
SECTION 15050 - PIPING SYSTEMS
PART 3 - EXECUTION
3.06 PIPING SYSTEM MATERIALS:
Change the System for HWR and HWS piping system from "9" to "11".
3.07 PIPING SPECIFICATION:
Svstem 7 shall be changed as follows:
Change pipe "Schedule 20S seamless" to "Schedule 1 OS welded"
Change fittings "ASTM A403-WP316LS" to ASTM A402-WP316LW'
section to read as follows:
END OF ADDENDUM NO.2
Page 2 of 2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Addendum No.2
April 27, 1999
Item
Description
Manufacturer
Installed
Cost
Add(+)Deduct(-)
Cost for
Substitution
Base
Bid
4. Plug Valves
(Spec Section 15110)
A. Base Bid
DeZurik
Pratt
B. Substitute:
'j:::)i:::)))jjjjjj:)j)jjjjj::;j)j:)iijjj)!ji!!iij:)):jjj)j)jij:j:j:!:j:j:i::::i)j:j:
.........".................................
iiIjj~1ii~ij1j11i~I!i!!ii!1iiiiiiiiij~i!iiiii!iijijijjiiiiiiiiiii!i!iiijiiii~j~jj
ALTERNATE NO.1 - HOT OIL HEATING SYSTEM
Under this Alternate the Contractor shall furnish a Hot Oil Packaged Hot Water Heating
System as specified in Section 15625 in lieu of the Packaged Hot Water Heating
System as specified in Section 15620. This alternate supersedes the pricing for Items
12 and 13 inthe Bid Schedule should the Owner elect to exercise this alternate:
a. Remove and Replace Sludge Heating
System - Digester Control Room 1
lump Sum $
b. Remove and Replace Sludge Heating
System - Digester Control Room 2
lump Sum $
The undersigned agrees that this Proposal may not be revoked or withdrawn after the
time is set for the opening of bids but shall remain open for acceptance for a period of
sixty (60) calendar days following such time.
In case the bidder is given in writing by mail, telegraph, or delivery the Notice of
Acceptance of the Bid Proposal within sixty (60) days after the time for the opening of
bids, the undersigned agrees to execute within ten (10) calendar days a Contract (Form
of Agreement between Contractor and Owner) for the work for the above-stated
compensation and at the same time to furnish and deliver to the Owner a Performance
Bond, Payment Bond, Certificate of Insurance, and Contractor Certification forms in
accordance with the instruction bound in the Project Manual.
The undersigned agrees to commence actual physical work on the site with an adequate
force and equipment within ten (10) calendar days from the date to be specified in the
BID PROPOSAL 00120-5
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Addendum NO.2
April 27, 1999
Notice to Proceed from the Owner and to complete fully all work associated with
Digesters 1, 2 , 3 and Digester Control Building NO.1 within 270 calendar days from the
date of the Notice to Proceed. It is also agreed that 30 days are included for adverse
weather days during this phase. The remaining work on the project shall be fully
completed within 450 calendar days from the date of the Notice to Proceed. It is agreed
that 50 days are included in the specified contract time for adverse weather for days.
Liquidated damages as specified in the Agreement will be applied equally to the
completion of the initial phase and the complete project. It is also agreed that 45 days
are included in the specified contract time for adverse weather days.
Enclosed herewith is a Bid Bond in the amount of
DOLLARS ($ ) being not less than 10% of the Base Bid. The Bid
Bond must be submitted on the required form provided with the Invitation to Bid.
If this Proposal is accepted within sixty (60) days after the date set for the opening of bids
and the undersigned fails to execute the Contract within ten (10) calendar days after
receipt from the OWNER/Engineer, or if he fails to furnish both a Performance Bond and
Payment Bond, the obligation of the Bid Bond will remain in full force and effect and the
money payable thereon shall be paid into the funds of the Owner as liquidated damages
for such failure; otherwise the obligation of the Bid Bond will be null and void.
The Bidder acknowledges receipt of Addendum Nos. 1, 2, _' _'
This Bid Proposal is respectfully submitted by:
Bidder (Print Name)
Signature (Owner, Partner or
Corp. Officer)
Address
Title
If Corporation, affix seal here
Telephone Number
(SEAL)
BID PROPOSAL
00120-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Addendum NO.3
April 29, 1999
ADDENDUM NO.3
to the
BIDDING DOCUMENTS
for
Digester Modifications
Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
All Bidders and other interested parties are hereby notified of the following additions and or
revisions to the plans and specifications for the referenced project.
CLARIFICATIONS
1. Thermometers as specified in Section 13615 are required at the discharge of each external
draft tube mixer on the digesters. Thermo-wells are required for all thermometers. The
final location of each will be determined during the submittal process.
2. The attached sketches SK-E708-1 and SK-E708-2 clarify changes required to drawing
number E708.
SPECIFICATIONS
SECTION 11800 - DIGESTER SLUDGE MIXERS
PART 3 - EXECUTION
3.07 WARRANTY
Revise this section as follows:
"The mixer manufacturer shall warrant each mixer in writing against defects in
workmanship and material for a period of five years or 44,000 hours of normal use,
operation and service. The warranty shall be in printed form and apply to all similar units."
END OF ADDENDUM NO.3
Page 1 of 3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
~
-
"'0\/.
JI'.;,
GO Ml
2J
IICP
~1I ~
jl :::~u
'3 A
~
~,
r (X. 1'l
1 f- 1 '-X"'--<>--~
~' ~~!'".
! Tl 1
-~-J
i I p I
", I L; ~ I
. ~:, 1';;;1 " L, ,-
~ ~--'
~~ ,8
r---r I .: 'y~
I ~~!~ox
I I I I
I '-<> "'""-0 xo j
Ii! ~~$~~ J
L...L. cow l.I:lI!:L
000;:--1 f----
'"
"'-'~. ~~5
'---o...Lv
ru
I ~.! r
1~, J ---0:....r-Ti
(9 I ;
*-i~tl !
r
-l:
IZI
-..<'
:-~~
r
RuN
fORvMD
R
HI
1
I 1
I
~1"'1
-<>. )~
f .
'~~--=ll
D'~(STEP COIflRCJo.. .lNCl
RUN
RrvCR~E.
f tllUlP. T ~CC NO.
HO. OtscRIPl1OH
101.7:101 OiC[STtR \ ",J,,;ER 1 ,. ,
1011720: OICESTtR : UIl([R 2 ,
------1
"'X721)~ OmS,..R , "'I(€R J 2 i
loIX72CM DIOt:STtR \ ll'XCR . 2 I
W.l'.xJl OIol;(STt~ 2 WIXER , 2 l
WX7:1D2 DlQ,[STtR 2 IrllX(R: 2 2
1111303 OI~ESTtR 2 ll'IIDl J ,
11)(7304 O'OtSTl:R 2 ll'XCA ~ . I
11.7001 OllOE5TEN , III)([A , 'OllO
..17.02 OI~rsTt. . 1oI1.(1:R '- 7000 I
lOC?403 D'C[5TtA . ,,'XrA J 700e
Wlt1_ DIC[SltR . WIX," 4 7000
i 70~
l4Xn01 DICX9T1:R , WillE. 1 I
MX7l102 DOI:C' lEA ~ 11I11[. 2 ,
i '000
"X7~.) IllCl:S ltR , WilER 3 i 7000 l
"'"- ()Ion ltR , II.XOI ~ 7000 I
60... 460V. 4'11 /'-
wt..'Il1EP"C;.c \N
-r-
6'-0.
..""",,,L..,,,,. h'...
.. ~ ...;\.,...,,~I/.
;~.~~i ~:. .::.....~..:"..
.." ,." '" '\"~':'
"
__I:
....~.. ....'.. ..,....
~:~" ~~~::..
-
II ( \. I I j 0 ,.
I lilT! _
1-.-...
OOCIIP'I)(h
/: ~~ i FRflD1AN~~
~VA~Ni.
~ ....... 'rt .... ....... ~ ~'ftlIO MII7
I
I
-
5K-E108--1
~
j Q.flT[.
r;"
SCo<L
1 I!',
. '
i:t~, !
i~, "
~
I
l
I
I
J\ r~~'ll
~ ~(
CLDs( PIJ~IT!u~
U"'J't '''itCH
Jlr-O-l I
I
,~V.
I
01191 Q..OI(
,~
-o..L'>xo
rv
I
p~" $011. rllM D,c;nT(~ CC~rkOL PAN!;'_
OICE'l,,"
H
MI L[\{L
OPrN PDSITl~
LlI1JT $VI'T01
I
'-----~--~-_/
OI(ll;STtll OOHTROL PAN!;l
I
CV7Z0l
I
C\7JDl
CV7JOJ
CV7~
I
CV7W'
CV7'01
CV7'OZ
CV7tOl
I
CV7W1
I
I
"RO\olOC 12' Sl..A0<
'!1) w.o-w ROOf' 'll)
V!1lT1cA1.L Y FlOII T
"/~ !. -0'.
eo.... OBOV. 4W
ft,A'I>1lJ\H[Al)
I
I
I
I
I FRFJDfAN~,
Iv AOO'HNil
I
It, _lI'I,
_'811I _
~ -..,
1/8"."-0' 00I0i
_.1&. ~ll't'\
.~ 'a. 0\ Nql
I
[OVIP.
HO.
DESCRIPnON .01
OI"C$ll:R 1 IHU:' VII(.I/( I
OIotsm 1 lRANSf[R VAlV[ I
ClGESllR 2 INU:T vII., I/( ~
l1I~TVl 2 lllAN,n;R v"~1
OIGE'TliR 4 IHID VAtI/( =:=]
OIotsTtR 4 lllAHSFl:R VA,VI: --J
ClcrSTVl & INLET VIIL\ol: I
OIotSltI< ~ lllANIF'Df VA'VI: !
DlQ[ll!A e IML 1 YIIL II!: l
llIClEliT!;" ) II<Lf'T Vi\(.\I( I
CV720l
~-~-----..-..-....-~-
[)'''LOSioN PROOf' J\JNCllON BOX/' \
(XPLOSION PROOf
I rLEX C~oVIT .
DRAM ruB" "'~R
':...~.::".
caHDW' wtl'Al LA-nON [}[lAj' _
Dl::fST!JQ~ ~ ... .II: ~ rLtlAl1NC IJQQei
.-,..
I ....-CONTINUCtt r;", P'RL:VmJ~
I. OP~' C;.?Sl
'-'\ / OIG[5H:F
r----Er~---':.l.."'X;'- h--
~ ~.U~
I
I
I
OPEN POS::>ON
Uifln ~v;rc.,",
(I
,
~-..f.-:I
' I
l l J
'-----------,,-----
Olc;~~TEI\ COfllTRtJl F
,
ECUIP. I O!$C'~
NC"
CV710~ OICCS":'tl:! IOVn.rT
CV7~l l OIC!:~TtR '\ OUlt.:(,
0\17801 Clct!1'!R, ~ 0IJ11.rT
0\7'01 OtC'tSTtfi ~ C)) 7 ~('7
cV?"'~ DlCrSTtR . 0.'1,['
,
-
r vV700' i OCCCSTI'R · (),.!,(.
1101'.
I PH.
60 Hc
D lP
{ '-;-L
--<.' ~ :;"
- I It'''PfRAl\JR( 0-
1l\ANs~rm.1I, (l-
I
~ ..
NC. OEseRJP nON
1------
nUll ~ DlCl:5TUl I TtMPC:RA ;1.IR[
1117)1\ ()rG'CST€Ft Z TtKD'(R). Jl./Re
'(\"'4,11 OIC(STtR 4 1!..wER^ !lJ.-t
-
T!T7~'" OICCl;t". , T["'CAj,!V~('
'--
ANAEROBIC DIG~SrER MODIFIC.4.TIONS
MESSERLY WASTEWA TER TREATMENT Pi..ll,NT
AUGUSTA-RICHMOND COUNTY, GEORGIA
!
;
t7K- 1:108-2
I
.1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
PROJECT MANUAL
DIGESTER MODIFICATIONS
MESSERLY WASTEWATER TREATMENT PLANT
AUGUSTA-RICHMOND COUNTY
TABLE OF CONTENTS
SECTION & TITLE
PAGE NUMBERS
DIVISION 1 - GENERAL REQUIREMENTS
00100 Advertisement for Bids
00110 Instructions & Information to Bidders
00120 Bid Proposal
00',25 Bid Bond
00130 Notice of Award
00135 Agreement
00140 Performance Bond
00145 Labor & Material Payment Bond
00150 Certificate of Owner's Attorney
00155 Notice to Proceed
00160 Affidavit of Payment of Claims
00170 Certificate of Insurance
01001 General Conditions
01002 Special Conditions
01605 Shipment, Protection and Storage
01660 Installation, Testing and Commissioning
01730 Operating and Maintenance Information
01800 Submittals
01800A Submittal Transmittal Form
01800B Product Data Transmittal Form
00100-1 thru 00100-2
00110-1 thru 00110-4
00120-1 thru 00120-5
00125-1
00130-1
00135-1 thru 00135-3
00140-1 thru 00140-2
00145-1 thru 00145-2
00150-1
00155-1
00160-1
00170-1 thru 00170-2
01001-1 thru 01001-54
01002-1 thru 01002-3
01605-1 thru 01605-2
01660-1 thru 01660-4
01730-1 thru 01730-3
01800-1 thru 01800-5
1 Page
1 Page -
DIVISION 2 - SITE WORK
02050 Demolition
02190 Digester Cleaning
02200 Earthwork
02210 Erosion Control
02050-1 thru 02050-6
02190-1 thru 02190-3
02200-1 thru 02200-14
02210-1 thru 02210-3
DIVISION 3 - CONCRETE
03310 Concrete Work
03310-1 thru 03310-35
TABLE OF CONTENTS
-1-
I F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
I Augusta-Richmond County, Georgia.
DIVISION 4 - MASONRY
I 04200 Unit Masonry 04200-1 thru 04200-41
DIVISION 5 - METALS
I 05430 Fixed Aluminum Dome Tank Cover 05430-1 thru 05430-6
I 05500 Metal Fabrications 05500-1 thru 05500-7
05532 Gratings 05532-1 thru 05532-3
05720 Handrails and Railings 05720-1 thru 05720-4
I DIVISION 6 - WOOD & PLASTICS (Not Used)
I DIVISION 7 - THERMAL & MOISTURE PROTECTION
07900 Joint Sealers 07900-1 thru J7900-5
I DIVISION 8 - DOORS & WINDOWS (Not Used)
I DIVISION 9 - FINISHES
I 09800 Special Coatings 09800-1 thru 09800-24
DIVISION 10 - SPECIAL TIES (Not Used)
I DIVISION 11 - EQUIPMENT
I 11000 General Requirements For Equipment 11000-1 thru 11000-8
11002 Equipment Mounting 11002-1 thru 11002-3
11020 Vibration And Critical Speed Limitations 11020-1 thru 11020-2
I 11800 Digester Mixers 11800-1 thru-111300-7
11815 Digester gas Handling Equipment 1181 5-1 th ru 11815-6
11820 Supernatant Removal Device & Acces.sories _ ' 1.-1820-1 thru 11820-4
I
I DIVISION 12 - FURNISHINGS (Not Used)
DIVISION 13 - SPECIAL CONSTRUCTION
I 13600 Process Instrumentation & Controls-General Provisions 13600-1 thru 13600-12
13615 Process Instrumentation & Controls-Products 13615-1 thru 13615-24
I DIVISION 14 - CONVEYING SYSTEMS (Not Used)
I
TABLE OF CONTENTS -2-
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
DIVISION 15 - MECHANICAL
15010 Mechanical-General Provisions
15050 Piping Systems
15061 Steel Pipe
15062 Ductile Iron Pipe
15066 Copper Pipe
15067 Stainless Steel Piping
15075 Joint Gaskets
15085 Piping Connections
15090 Expansion Joints and Flexible Metal Hose
15095 Piping Appurtenances
15096 Piping Hangers and Supports
15101 Gate Valves
15103 Butterfly Valves
15110 Eccentric Plug Valvus
15116 Synthetic Swing Disc Check Valve
15118 Spring-Loaded Swing Check Valves
15147 Solenoid Valves
15150 Specialty Valves
15153 Pressure Regulating Valves
15180 Control Valve Schedule
15184 Manual Valve & Gate Operators & Operator Appurtenances
15185 Powered Valve & Gate Operators
and Operator Appurtenances
15250 Insulation for Exposed Piping and Equipment
15620 Packaged Hot Water Heating System
15625 Packaged Hot Water Heating System (Alternate No.1)
DIVISION 16 - ELECTRICAL
16000 Electrical - Genral Provisions
16100 600 Volt Motor Control Center
TABLE OF CONTENTS
15001-1 thru 15001-4
15050-1 thru 15050-46
15061-1 thru 15061-6
15062-1 thru 15062-7
15066-1 thru 15066-3
15067 -1 thru 15067-9
15075-1 thru 15075-3
15085-1 thru 15085-6
15090-1 thru 15090-5
15095-1 thru 15095-4
15096-1 thru 15096-12
15101-1 thru 15101-3
15103-1 thru 15103-5
15110-1 thru 15110-3
15116-1 thru 15116-2
15118-1 thru 15118-2
15147-1 th ru 15147-3
15150-1 thru 15150-3
15153-1 thru 15153-4
15180-1 thru 15180-2
15184-12 thru 15184-3
15185-1 thru 15185-12
15250-1 thru 15250-7
15620-1 thru 15620-10
15625-1 thru 15625-10
16000-1 thru 16000-20
1.6100-1 thru 16100-9
-3-
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
SECTION 00100 - ADVERTISEMENT FOR BIDS
Sealed bids for modification of Anaerobic Digesters at the Messerly Wastewater Treatment
Plant, Augusta, Georgia ,hereinafter referred to by project name as:
Bid Item # 99-057
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
will be received by the Augusta-Richmond County Commission, hereinafter referred to as the
OWNER at the office of the Director of Purchasing, Room 605, Municipal Building until 11 :00
a.m. on April 30, 1999, at which time all bids will be publicly opened and read in the presence
of those interested.
The work to be done consists of the following generally described items:
1. Clean 6 existing digesters and demolition of designated piping and equipment.
2. Remove and replace cover of Digester No.1.
3. Upgrade mixing systems for digesters and modify piping system.
4. Remove and replace digester heating and gas systems.
5. Miscellaneous repairs, painting, electrical and HV AC work in digester area.
Plans and specifications are open for public inspection at the office of the Augusta-Richmond
County Utilities Dept., 2760 Peach Orchard Road, Augusta, Georgia; at the Augusta-Richmond
County Purchasing Dept., Room 605 Municipal Building, Augusta, Georgia; and at the following
locations:
F.W. Dodge Division Plan Room
Augusta, Georgia
Augusta Builders Exchange
Augusta, Georgia
Copies of CQntract Documents may be obtained at the Augusta-Richmond COUOJy -Purchasing
Dept., Room 605 Municipal Building, Augusta, Georgia and the office of Freeman_ & Vaughn
Engineering upon a deposit of $150.00 for each half-size set. (Non-refundable). Additional
half-size plans are available for $25.00 (Non-refundable). Addit'ional full-size plans are
available for a deposit of $75.00 (Non-refundable).
All bidders are encouraged to attend a pre-bid conference which will be held at 3:00 P.M. on
Thursday, April 15,1999 in the Conference Room of the Purchasing Department, Room 605
Municipal Building, Augusta, Georgia. Project scheduling, coordination requirements and
questions of interpretation will be addressed at this time.
ADVERTISEMENT FOR BIDS
00100-1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Bids shall be enclosed in a sealed envelope and addressed as follows:
AUGUSTA-RICHMOND COUNTY COMMISSION
c/o Director of Purchasing
Room 605 - Municipal Building
Augusta, Georgia 30911
Mark the outside of the envelope as follows:
Bid Item # 99-057
Digester Modifications - Messerly Wastewater Treatment Plant
Bids must be accompanied by a Bid Bond secured by a surety company, certified check or
cashier's check in an amount equal to at least 10% of the amount of the bid. A contract
performance and payment bond each in the amount of 100% of the contract amount will be
required of the successful bidder.
The Augusta-Richmond County Commission reserves the right to reject any and all bids and to
waive any informalities in the bidding.
It is the wish of the Owner that minority businesses be given the opportunity to bid on the
various parts of the work. This desire on the part of the Owner is not intended to restrict or limit
competitive bidding or to increase the cost of the work. The Owner supports a healthy free
market system that seeks to include responsible businesses and provide ample opportunity for
business growth and development.
Geri Sams, Director of Purchasing
Publish:
Augusta Chronicle - April 5, 12, 19 and 23, 1999
Metro Courier
- April 7, 1999
ADVERTISEMENT FOR BIDS
00100-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 00110 - INSTRUCTION TO BIDDERS
1.01 GENERAL:
All proposals must be presented in a sealed envelope, addressed to the Owner. The
proposal must be filed with the Owner on or before the time stated in the invitation for
bids. Mailed proposals will be treated in every respect as though filed in person and
will be subject to the same requirements.
Proposals received subsequent to the time stated will be returned unopened. Prior to
the time stated any proposal may be withdrawn at the discretion of the bidder, but no
proposal may be withdrawn for a period of sixty (60) days after bids have been
opened, pending the execution of contract with the successful bidder.
1.02 EXAMINATION OF WORK:
Each bidder shall, by careful examination, satisfy himself as to the nature and
location of the work, the conformation of the ground, the character, quality and
quantity of the facilities needed preliminary to and during the prosecution of the work,
the general and local conditions, and all other matters which can in any way affect the
work or the cost thereof under the contract. No oral agreement or conversation with
any officer, agent, or employee of the Owner, either before or after the execution of
the contract, shall affect or modify any of the terms or obligations therein.
1.03 AGENDA AND INTERPRETATIONS:
No interpretation of the meaning of plans, specifications or other prebid documents
will be made to any bidder orally.
Every request for such interpretation should be in writing addressed to Freeman &
Vaughn Engineering, P.O. Box 15845, Savannah, Georgia 31416 Attn: Mitchell E.
~reeman, PE, and to be given consideration must be received at least fivedays prior
to the date fixed for the opening of bids. Any and all such interpretations and any
supplemental instructions will be in the form of written addenda- to the specifications
which, if issued, will be sent by certified mail with return receipt requested to all
prospective bidders (at the respective addresses furnished for such purposes), not
later than three days prior to the date fixed for the opening of bids. Failure of any
bidder to receive any such addendum or interpretation shall not relieve such bidder
from any obligation under his bid as submitted. All addenda so issued shall become
part of the Contract Documents.
INSTRUCTION TO BIDDERS
00110-1
INSTRUCTION TO BIDDERS
00110-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia.
1.04 PREPARATION OF BIDS:
Bids shall be submitted on the forms provided and must be signed by the bidder or
his authorized representative. Any corrections to entries made on bid forms should
be initialed by the person signing the bid.
Bidders must quote on all items appearing on the bid forms, unless specific directions
in the advertisement, on the bid form, or in the special specifications allow for partial
bids. Failure to quote on all items may disqualify the bid. When quotation on all
items are not required, bidders shall insert the words "no bid" where appropriate.
Alternative bids will not be considered unless specifically called for.
Telegraphic bids will not be considered. Modifications to bids already submitted will
be allowed if submitted by telegraph priur to the time fixed in the Invitation for Bids.
Modifications shall be submitted as such, and shall not reveal the total amount of
either the original or revised bids.
Bids by wholly owned proprietorships or partnerships will be signed by all owners.
Bids of corporations will be signed by an officer of the firm and his signature attested
by the secretary thereof who will affix the corporate seal to the proposal.
NOTE: A 10% Bid Bond is required in all cases.
1.05 BASIS OF AWARD:
The bids will be compared on the basis of unit prices, as extended, which will include
and cover the furnishing of all material and the performance of all labor requisite or
proper, and completing of all the work called for under the accompanying contract,
and in the manner set forth and described in the specifications.
Where estimated quantities are included in certain items of the_proposal, they are for
the purpose of comparing bids. While they are believed to be close approximations,
they are not guaranteed. It is the responsibility of the Contractor to check all items of
construction. In case of error in extension of prices in a proposal, unit bid prices shall
govern.
1.06 BIDDER'S QUALIFICATIONS:
No proposal will be received from any bidder unless he can present satisfactory
evidence that he is skilled in work of a similar nature to that covered by the contract
and has sufficient assets to meet all obligations to be incurred in carrying out the
work. He shall submit with his proposal, sealed in a separate envelope, a
FINANCIAL EXPERIENCE AND EQUIPMENT STATEMENT, giving reliable
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
information as to working capital available, plant equipment, and his experience and
general qualifications. The Owner may make such investigations as are deemed
necessary to determine the ability of the bidder to perform the work and the bidder
shall furnish to him all such additional information and data for this purpose as may
be requested. The Owner reserves the right to reject any bid if the evidence
submitted by the bidder or investigation of him fails to satisfy the Owner that such
bidder is properly qualified to carry out the obligations of the contract and to complete
the work contemplated therein. Part of the evidence required above shall consist of a
list of the names and addresses of not less than five (5) firms or corporations for
which the bidder has done similar work.
1.07 PERFORMANCE BOND:
At the time of entering into the contract, the Contractor shall give bond to the Owner
for the use of the Owner and all persons doing work or furnishing skill, tools,
machinery or materials under or for the purpose of such contract, conditional for the
payment as they become due, of all just claims for such work, tools, machinery, skill
and terms, for saving the Owner harmless from all cost and charges' that may accrue
on account of the doing of the work specified, and for compliance with the laws
pertaining thereto. Said bond shall be for the amount of the contract satisfactory to
the Owner and authorized by law to do business in the State of Georgia.
Attorneys-in-fact who sign bonds must file with each copy thereof a certified and
effectively dated copy of the power of attorney.
1.08 REJECT/ON OF B/DS:
These proposals are asked for in good faith, and awards will be made as soon as
practicable, provided satisfactory bids are received. The right is reserved, however,
to waive any informalities in bidding, to reject any and all proposals, or to accept a bid
other than the lowest submitted if such action is deemed to be in the best interest of
the Owner.
~. .' . ~.
1.09 MINORITY AND ECONOMICALLY DISADVANTAGED BUSINESS SUPPORT:
It is the intent of the Augusta-Richmond County Commission to increase the
involvement of qualified minority and economically disadvantaged businesses in the
contracted work of County Government.
In an effort to support this intention, this project is offered to all qualified firms. The
bids will be evaluated based on qualifications, price and construction time. With all
other items being considered equal, the contract, if awarded will be awarded to a
minority and economically disadvantaged firm or a firm that has included such firms
as subcontractors on this project.
INSTRUCTION TO BIDDERS
00110-3
INSTRUCTION TO BIDDERS
00110-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
The bidders shall include with their bid a statement of qualification for themselves
and/or any qualified subcontractors explaining why they should be considered a
minority or economically disadvantaged firm. If the firm does not fall into this
category, no information is necessary.
End of Section 00110
I.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Addendum NO.1
April 22, 1999
SECTION 00120 - BID PROPOSAL
AUGUSTA-RICHMOND COUNTY COMMISSION
MUNICIPAL BUILDING
AUGUSTA, GEORGIA 30911
PROJECT TITLE: DIGESTER MODIFICATIONS
MESSERLY WASTEWATER TREATMENT PLANT
AUGUSTA-RICHMOND COUNTY, GEORGIA
BID ITEM NO.: 99-057
Gentlemen:
The undersigned Bidder, herein referred to as singular and masculine, declares the
following:
1. The only parties interested in the proposal as principals are named herein;
2. He has carefully examined and fully understands the contract documents,
including the drawings and specifications;
3. He understands that information relative to existing structures and underground
utilities as furnished to him on the drawings, Contract Documents or by the
Augusta-Richmond County Utilities Engineer/Director, carries no guarantee
expressed or implied as to its completeness or accuracy and he has made due
allowances therefor;
4. He has made a personal examination of the site of the proposed work and has
satisfied himself as to the actual conditions and requirements of the work;
=f"~
5. He agrees to hold the Owner harmless for accidents or damages to property;
6. He will comply with all State and Federal regulations pertaining to but not limited to
asbestos containing material removal and disposal, regulations regarding disposal
of all debris and OSHA requirements;
7. He will complete the work in a timely manner. The required time of completion is
indicated in the Bid Proposal Form;
8. He will maintain the site as clean as possible by not allowing debris to accumulate
_before making trips to his disposal site. Materials sold for salvage shall not be
.;aocumulated on the project site.;
BID PROPOSAL
00120-1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Addendum No. 1
April 22, 1999
9. He will not bum any materials on site without written approval from proper
authorities;
10. He will fumish the Owner with a detailed schedule of demolition and removal,
'including disposal sites, names of all subcontractors, State and local license
information;
and hereby proposes and agrees to furnish all materials, labor, skill, equipment, tools,
and other things of every kind and description specified, needed or used for the complete
execution of all work covered by and in conformity with the Plans, specifications, and
other Contract Documents prepared by Freeman & Vauqhn Enqineerinq, Inc., Consulting
Engineers and all Amendments and Addenda thereto, for the sums hereinafter stated.
LUMP SUM PRICES:
The undersigned agrees to provide all labor, materials, and equipment necessary to
perform the work described in the plans, specifications, addenda, etc., all of which
comprise the project manual, for the price of:
1.
Digester Cleaning:
II 3 S"', ~
~e:
I~ / Ton (Enter Unit Price)
I/OB'/~DO,~
'Total Price $ L JS~, l;............ ~ 5G
960 Tons (Dry Weight Measure) at $
equals
2.
Lump Sum $ ~ot>.ooo,;!!!-
Replace Cover Digester NO.1
3. Paint Cover Digester NO.2 (Interior & Exterior) Lump Sum $ 0"
1(, C? 0{;>6. /""
.
4. Paint Cover Digester NO.3 (Interior & Exterior) Lump Sum $ I "C? 000, ~
.
5. Piint~over Digester NO.4 (Interior & Exterior) Lump Sum $ I (,0 0 CA':> ,,!!t-
,
6. Paint Cover Digester NO.5 (Interior & Exterior) Lump Sum $ o ,,~
IlP . ODO.
7. Paint Cover Digester NO.6 (Interior & Exterior) Lump Sum $ I (po, OOC/, ~
.
8. Remove & Replace Mixing System
Digester No. 1 Lump Sum $ A"I o. 000 ;,~
,
9. Remove & Replace Mixing System
Digester NO.2 Lump Sum $ ~oro CX?O,~
.
10. R~move & Replace Mixing System
Digester NO.4 Lump Sum $ '\ ~ O. 000, Q!/l-'
.
11. Remove & Replace Mixing System
Digester NO.5 Lump Sum $ ~9o. otO, ~
BID PROPOSAL 00120-2
I.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Addendum No. 1
April 22, 1999
12. Remove and Replace Sludge Heating
System - Digester Control Room 1
Lump Sum $
~ 0&1(7. ~
'J,,,, c-OO . ~ -::r"G
,
,; .
13. Remove and Replace Sludge Heating
System - Digester Control Room 2
~O&1&1&1.~
......' ~
Lump Sum $ ~.- -:S-c
14. Repair 250 SF of Masonry Veneer
Digester NO.2
Lump Sum $ I?> ooo,~
.
15. Provide Stone Cover over Digester
Grounds
Lump Sum $ 3(::>.060.".!:-
16. Modify Valve Vault Piping
Lump Sum $
[f3. 0(/0. (7/
.
Total of Construction (Sum of Items 1 thru 16)
$ A., ~ 1-0, U>(). ~
. ,
~.~
- ~
BID PROPOSAL
00120-3
I
I
I
Addendum NO.1
April 22, 1999
I
Schedule of Equipment
I
The followtng are designated as major material items to be furnished under the Digester Modifications.
The bidder must bid one of the listed materials by extending the cost to the Base Bid Column and circling
the appropiatemanufacturer. Bidder must also provide pricinq for other listed manufacturers shown in the
proposal or his bid may be considered non-responsive.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
~
BID PROPOSAL
00120-4
I 04!~7/99
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Tl~ 15:37 F.~ 912+355+9603
~004
FVE
Addendum No.2
April 27, 1999
Item
Description
Manufacturer
Add(+)Dedud(-)
Cost for
Substitution
Base
Bid
Installed
Cost
4. Plug Valves
(Spec Section 15110)
~:~"i_'::':ti'~
A. Sase Bid
Pratt
tt t? ~,~
!m!ff~'t\_
8. Substitute:
!il'~~li!:I~i~i~I~[~II:ll~~~!'~'I.!II!~111
ALTERNATE NO.1 - HOT OIL HEATING SYSTEM
Under this Alternate the Contractor shall furnish a Hot Oil Packaged Hot Water Heating
System as specified in Section 15625 in lieu of the Packaged Hot Water Heating
System as specified in Section 15620. This alternate supersedes the pricing for Items
12 and 13 in the Bid Schedule should the Owner elect to exercise this alternate:
a.
Remove and Replace Sludge Heating
System - Digester Control Room 1
Lump Sum $
-
l '2.-0.00(;).-
.
b.
Remove and Replace Sludge Heating
System - Digester Control Room 2
Lump Sum $
-
I %-C? 000.-
.
The undersigned agrees that this Proposal may not be revoked or withdrawn after the
time is set for the opening of bids but shall remain open for acceptance for a period of
sixty (60) calendar days following such time.
In case the bidder is given in writing by mail, telegraph, or delivery the Notice of
Acceptance of the Bid Proposal within sixty (60) days after the time for the opening of
bids, the undersigned agrees to execute within ten (10) calendar days a Contract (Form
of Agreement between Contractor and Owner) for the work for the above-stated
compensation and at the same time to furnish and deliver to the Owner a Performance
Bond, Payment Bond, Certificate of Insurance, and Contractor Certification forms in
accordance with the instruction bound in the Project Manual.
The undersigned agrees to commence actual physical work on the site with an adequate
force and equipment within ten (10) calendar days from the date to be specified in the
BID PROPOSAL 00120-5
I 04/2i /99
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Tl~ 15:3i FAX 912+355+9603
I4J 005
FVE
Addendum No, 2
April 27, 1999
Notice to Proceed from the Owner and to complete fully all work associated with
Digesters 1.2 , 3 and Digester Control Building NO.1 wIThin 270 calendar days from the
date of the Notice to Proceed. It is also agreed that 30 days are included for adverse
weather days during this phase. The remaining work on the project shall be fully
completed within 450 calendar days from the date of the Notice to Proceed. It is agreed
that ,g.Q days are included in the specified contract time for adverse weather for days.
Liquidated damages as specified in the Agreement will be applied equally to the
completion of the initial phase and the complete project. It is also agreed that 45 days
are included in the specified contract time for adverse weather days.
Enclosed herewith is a Bid Bond in the amount of
DOLLARS ($ ) being not less than 10% of the Base Bid. The Bid
Bond must be submitted on the required form provided with the Invitation to Bid.
If this Proposal is accepted within sixty (60) days after the date set for the opening of bids
and the undersigned fails to execute the Contract within ten (10) calendar days after
receipt from the OWNER/Engineer, or jf he fails to furnish both a Performance Bond and
Payment Bond, the obligation of the Bid Bond will remain in full force and effect and the
money payable thereon shall be paid into the funds of the Owner as liquidated damages
for such failure; otherwise the obligation of the Bid Bond will be null and void.
The Bidder acknowledges receipt of Addendum Nos. 1, 2,.3..., _'
This Bid Proposal is respectfully submitted by:
P.P. Moon and Company, Inc.
Bidder (Print Name)
~eror
Corp. Officer)
2207 Highway 103
West Point,GA 31833
Add ress
President
706-643-1524
Telephone Number
Title
If Corporation, affix seal here
(SEAL)
810 PROPOSAL
00120-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
SECTION 00125 - FORM OF BID BOND'
KNOW ALL MEN BY THESE PRESENTS that we, the undersigned, P. F. Moon and
Company, Inc. I as Principal, and St. Paul Fire and Marine Insurance Canpany I as Surety,
are held firmly bound unto Augusta~Rjchmond County Commission, as Owner, in the
penal sum of: Ten Percent (10%) of Principal's Bid DOLLARS ($ ),
for the payment of which, well and truly to be made, we hereby jointly and severally bind
ourselves, our heirs, executors, administrators, successors and assigns.
Signed, this 30th
day of April ,i-9OO.1999
The condrnon of this obligation is such that whereas the Principal has submitted to
Augusta-Richmond County Commission, a certain Bid, attached hereto and hereby made
a part hereof to enter into a contract in writing for the construction of Digester Modifications-
Messerly Wastewater Treatment P~ant.
NOW, THEREFOR,
(a) If said Bid shall be rejected, or in the alternate,
(b) If said Bid shall be accepted and the Principal shall execute and deliver a contract
in the Form of Contract attached hereto (properly completed in accordance with
said Sid) and shall furnish a bond for his faithful performance of said contract, and
for the payment of all persons performing labor or fumishing materials in
connection therewith. and shall in all other respects perform the agreement created
by the acceptance of said Sid, then this obligation shall be void, otherwise the
same shall remain in force and effect; it being expressly understood and agreed
that the liability of the Surety for any and all claims ,hereunder shall, in no event,
exceed the penal amount of this obligation herein stated.
The Surety, for value received, hereby stipulates and agrees that the' obligations of said
surety and its Sand shall be in no way impaired or affected by any extension of time within
which the Owner may accept such Bid; and said Surety does hereby waive notice of any
such extension.
IN WITNESS WtiEREOF, the Principal and the Surety have hereunto set these hands
and seals, and such of them as are corporations 'have caused theff corporate seals to be
hereto affixed and these presents to be signed by their proper officers, the day and year
first set forth above. 'P . F. Moon an Company, Ine.
L.S.
St. Paul Fire and Marine Insurance Company
(Surety)
SEAL
FORM OF BID BOND
00125-1
I
lbeStPdul
POWER OF ATTORNEY
I
Seaboard Surety Company
St. Paul Fire and Marine Insurance Company
St. Paul Guardian Insurance Company
St. Paul Mercury Insurance Companyy
United States Fidelity and Guaranty Company
Fidelit)' and Guaranty Insurance Company
Fidelity and Guaranty Insurance Underwriters, Inc.
I
I
Power of Attorney No.
20057
Certificate No.
.., 1 "/C ~
.1....L i V ....i
I
KNOW ALL MEN BY THESE PRESENTS: That Seaboard Surety Company is a corporation duly organized under the laws of the State of New York. and that
SI. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company and St. Paul Mercury Insurance Company are corporations duly organized under
the laws of the State of Minnesota. and that United States Fidelity and Guaranty Company is a corporation duly organized under the laws of the State of Maryland, and
that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa, and that Fidelity and Guaranty Insurance
Underwriters. Inc. is a corporation duly organized under the laws of the State of Wisconsin (herein collectively called the "Companies"), and that the Companies do
hereby make, constitute and appoint
I
Travis G. Huffmes, Scott E. Russell, Timothy E. Barnhardt, Charlotte J. Ericson, Thomas M. Beman, Dave Henritze, Dale Sims,
Robert Yarbrough, Terry L. Reynolds, Deanna G. Herron and Brian E. Madden
I
I
of the City of Alpharetta , State Georgia , their true and lawful Attomey(s)-in-Fact,
each in their separate capacity if more than one is named above, to sign its name as surety to, and to execute. seal and acknowledge any and all bonds, undenakings.
contracts and other written instruments in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the
performance of contracts and executing or guaranteeing bonds and undenakings required or permitted in any actions or proceedings allowed by law.
I
IN WITNESS WHEREOF, the Companies have caused this instrument to be signed this
15th
day of
March
1999
I
Seaboard Surety Company
SL Paul Fire and Marine Insurance Company
SL Paul Guardian Insurance Company
SL Paul Mercury Insurance Company
United States Fidelity and Guaranty Company
Fidelity and Guaranty Insurance Company
Fidelity and Guaranty Insurance Underwriters, Inc.
I
MJ- J- ?:> ~V'-
MICHAEL B. KEEGAN, Vice President
I
I
State of Maryland
City of Baltimore
~ R. \.At.~
I
.:_~..~
.~.,::,~'::I., -;.. _,'~'....~ ~~...- ...\"',\.:..
On [his 15th day of March ":'.~\:~-' ,~"':"~,:-1999. ';\~~'~~f~re me, the undersigned officer, personally appeared Michael B. Keegan and
Michael R. McKibben, who acknowledged themselves to_be.theTIfice P-r7s,i,dent ap.ctA;ssistiint Secretary, respectively, of Seaboard Surery Company, Sl. Paul Fire and
Marine Insurance Company, Sl. Paul Guardian Insurance'Company;.:Stk',Pilul J\;ler~~ illsurance Company, United States Fidelity and Guaranty Company, Fidelity and
Guaranty Insurance Company, and Fidelity and Guaranty'InsIJran.d~..Uiide~tc,ts;lnc_and that they, as such, being authorized so to do, executed the foregoing instrument
for the purposes rherein contained by signing the names ohl16 corporations' by themselves as duly authorized officers.
c.c.~ EA.S~*
,,'9"'~~
,:""""
M1CHAEL R. MCKJBBEN. Assistant Secf'et:tl').
I
In Witness Whereof, I hereunto set my hand and official seal.
~tAAh.M.~
I
I
I
I
I
I SECTION 00130 - NOTICE OF AWARD
I TO:
P.F. Moon and Company, Inc.
I
P.O. Box 346 - 2207 Hwy 103
West Point, Georgia 31833
I PROJECT DESCRIPTION:
DIGESTER MODIFICATIONS
MESSERLY WASTEWATER TREATMENT PLANT
AUGUSTA-RICHMOND COUNTY, GEORGIA
I
The Owner has considered the Bid submitted by you for the above described WORK in response to its
I Advertisement for Bids dated April 30, 1999 and Information for Bidders.
You are hereby notified that you BID has been accepted for items in the amount of
I $ 4,370,600.00.
. You have agreed in your Proposal to execute the Agreement and furnish the required Contractor's
I Performance and Payment Bond within ten (10) calendar days from the date of this Notice to you.
lit you fail to execute said Agreement and furnish said Bonds within ten (10) days from the date of this
Notice, said OWNER will be entitled to consider all your rights arising out of the OWNER'S acceptance
of your Bid as abandoned and as forfeiture of your Bid Bond. The Owner will be entitled to such other
I rights as may be granted by law.
You are required to return an acknowledged copy of this NOTICE OF AWARD to the Owner.
I Dated this day of , 1999.
I-
I
BY:
Title:
Acceptance of Notice
I Receipt of the above Notice of Acceptance of the Bid Proposal is hereby acknowledged on this
day of , 1999.
I BY:
I
I NOTICE OF AWARD
I
Title
00130-1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
SECTION 00135 - AGREEMENT
THIS AGREEMENT, made on the !,A:J- day of ~~ ' 19 ~, by and between
AUGUSTA, GEORGIA, BY AND THROUGH n-fE AUGUSTA-RICHMOND COUNTY
COMMISSION, party of the first part, hereinafter called the OWNER, and P.F. Moon and
Company, Inc., party of the second part, hereinafter called the CONTRACTOR.
WITNESSETH: that the Contractor and the Owner, for the considerations hereinafter named,
agree as follows:
ARTICLE I - SCOPE OF WORK:
The Contractor hereby agrees to furnish all of the materials and all of the equipment and labor
necessary, and to perform all of the work shown on the plans and described in the specifications
for the project entitled:
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County
and in accordance with the requirements and provisions of the Contract Documents as defined
in the General and Special Conditions hereto attached, which are hereby made a part of this
agreement.
ARTICLE II - TIME OF COMPLETION - LIQUIDATED DAMAGES:
The work to be performed under this Contract shall be commenced within 10 calendar days after
the date of written notice by the Owner or the Contractor to proceed. All work associated with
Digesters 1, 2 ,3 and Digester Control Building No. 1 shall be completed within 270 calendar
days from the date of the Notice to Proceed with all such extensions of time as are provided for
in the General Conditions. It is agreed that 30 days are included for adverse weather days
during this phase. The remaining work on the project shall be fully completed within 450
calendar days from the date of the Notice to Proceed with all such extensions of time as are
provided for in the General Conditions. It is agreed that 50 days are included in the specified
contract time for adverse weather for days.
It ;s hereby understood and mutually agreed, by and between the Contractor and the Owner,
that the date of beginning, rate of progress and the time for completion of the work to be done
hereunder are ESSENTIAL CONDITIONS of this contract. Contractor agrees that said work
shall be prosecuted regularly, diligently, and uninterruptedly at such rate of progress as will
ensure full completion thereof within the time specified. It is expressly understood and agreed
by and between the Contractor and the Owner, that the time for completion of the work
described herein is a reasonable time for completion of the same, taking into consideration the
average climatic range and construction conditions prevailing in this locality.
AGREEMENT
00135-1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
IF THE CONTRACTOR SHALL NEGLECT, FAIL, OR REFUSE TO COMPLETE THE WORK
WITHIN THE TIME HEREIN SPECIFIED, then the Contractor does hereby agree, as a part of
the consideration for the awarding of this contract, to pay the Owner the sum of Five Hundred
($500.00) Dollars, not as a penalty, but as liquidated damages for such breach of contract as
hereinafter set forth, for each and every calendar day that the Contractor shall be in default after
the time stipulated in the Contract for completing the work.
The said amount is fixed and agreed upon by and between the Contractor and the Owner
because of the impracticability and extreme difficulty of fixing and ascertaining the actual
damages the Owner would, in such event, sustain, and said amounts shall be retained from time
to time by the Owner from current periodical estimates.
It is further agreed that time is of the essence of each and every portion of this Contract and the
specifications wherein a definite portion and certain length of time is fixed for the additional time
is allowed for the completion of any work, the new time limit fixed by extension shall be the
essence of this contract.
ARTICLE 11/ - PAYMENT:
(A) The Contract Sum
The Owner shall pay to the contractor for the performance of the Contract the amount as
stated in the Proposal and Schedule of Items. No variations shall be made in the amount
except as set forth in the specifications attached hereto.
(B) Progress Payment
On no later than the fifth day of every month, the Contractor shall submit to the Owner's
Engineer an estimate covering the percentage of the total amount of the Contract which has
been completed from the start of the job up to and including the last working day of the
preceding month, together with such supporting evidence as may be required by the Owner
and/or the Engineer. This estimate shall include only the quantities in place and at the unit
prices as set forth in the Bid Schedule.
On the vendor run following approval of the invoice for payment, the Owner shall after
deducting previous payments made, pay to the Contractor 90% of the amount of the
estimate on units accepted in place. The 10% retained percentage may be held by the
Owner until the final completion and acceptance of all work under the Contract.
AGREEMENT
00135-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
ARTICLE IV - ACCEPTANCE AND FINAL PAYMENT:
(A) Upon receipt of written notice that the work is ready for final inspection acceptance, the
Engineer shall within 10 days made such inspection, and when he finds the work acceptable
under the Contract and the Contract fully performed, he will promptly issue a final certificate,
over his own signature, stating that the work required by this Contract has been completed
and is accepted by him under the terms and conditions thereof, and the entire balance
found to be due the Contractor, including the retained percentage, shall be paid to the
Contractor by the Owner within 15 days after the date of said final certificate.
(B) Before final payment is due, the Contractor shall submit evidence satisfactory to the
Engineer that all payrolls, material bills, and other indebtedness connected with work have
been paid, except that in case of disputed indebtedness of liens of evidence of payment of
all such disputed amounts when adjudicated in cases where such payment has not already
been guaranteed by surety bond.
(C) The making and acceptance of the final payment shall constitute a waiver of all claims by
the Owner, other than those arising from unsettled liens, from faulty work appearing within
12 months after final payment, from requirements of the specifications, or from
manufacturer's guarantees. It shall also constitute a waiver of all claims by the Contractor
except those previously made and still unsettled.
(0) If after the work has been substantially completed, full completion thereof is materially
delayed through no fault of the Contractor, and the Engineer, so certifies, the Owner shall
upon certification of the Engineer, and without terminating the Contract, make payment of
the balance due for that portion of the work fully completed and accepted.
Each payment shall be made under the terms and conditions governing final payment, except
that it shall not constitute a waiver of claims.
AGREEMENT
00135-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
IN WITNESS WHEREOF, the parties hereto have executed this Agreement in three (3)
counterparts, each of which shall be deemed an original, in the year and day first mentioned
above.
f
--"""~
.....':.9-\CHMO"'~~,~
- ,,~ ........ 00-",
;' ~ 00.. ..... ~""
(SEM ~ ..e ~ o..'~ "
r~ : ... ..t. ~
~ : ~.~
~ . 0 . JII!.
1. :::; ~
. . ....., ~
'l
u~ By:
rJI'~ As its Mayor
CONTRACTOR:P.F. Moon and Company, Inc.,
(SEAL)
BY~
Its '
Address:
P.O. Box 346 - 2207 Hwy 103
West Point, Georgia 31833
ecretary
:t!::;M~- ~
AGREEMENT
00135-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Bond Number 400KA690B
SECTION 00140 - PERFORMANCE BOND
THIS BOND IS EXECUTED TOGETHER WITH ANOTHER BOND IN FAVOR OF THE
OWNER AS OBLIGEE CONDITIONED UPON PERFORMANCE OF THE CONTRACT.
KNOW ALL MEN BY THESE PRESENTS:
That P. F. Moon and Company, rnc. ,as Principal ,hereinafter called
Contractor, and St. Paul Fire and Marine Insurance Canpany , a corporation organized
an existing under the laws of the State of Minnesota , with its principal office inn the
City of St. Paul , State of Minnesota , as Surety, hereinafter called
Surety. are held and firmly bound unto Augusta-Richmond County Commission, as
Obligee hereinafter called Owner, in the penal amount Four million three tumdred seventy thousand
six hundred and no/lOO Dollars ($ 4,370,600.00 ) for the payment whereof
Contractor and Surety bind themselves, their heirs, executors, administrators, successors
and assigns, jointly and severally, firmly by these presents for the faithful performance of
a certain written agreement.
WHEREAS, Contractor has by said written agreement dated entered into
a contract with the Owner for Digester Modifications - Messerly Wastewater
Treatment Plant", Augusta-Richmond County, Georgia
, in accordance with the drawings and specifications issued by Freeman & Vaughn
Engineering, Inc., which contract is by reference made a part hereof, and is hereinafter
referred to as the Contract.
NOW, THEREFORE, the condition of this obligation is such that if the Contractor shall
promptly faithfully perform the Contract, then this obligation shall be null and void;
otherwise it shall remain in full force and effect.
The Surety hereby waives notice of any alteration or extension of time made by the
Owner-.
Whenever the Contractor shall be, and declared by the Owner to b~e in default under the
Contract, the Owner having performed the Owne"r's obligations thereunder, the Surety
may promptly remedy the default, or shall promptly:
1. Complete the Contract in accordance with the terms and conditions, or
2. Obtain a bid or bids for completing the Contract in accordance with the terms and
conditions, and upon determination by Surety of the lowest responsible bidder, or, if
the Owner elects, upon determination by the Owner and Surety jointly of the lowest
responsible bidder, arrange for a contract between such bidder and Owner, and
make available as Work progresses (even though there should be a default or a
succession of defaults under the Contract or contracts of completion arranged
under this paragraph) sufficient funds to pay the cost of completion less the balance
PERFORMANCE BOND
00140-1
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
of the contract price; but not exceeding, including other costs and damages for
which the Surety may be liable hereunder, the amount set forth in the first
paragraph hereof. The term "balance of the contract price" as used in this
paragraph, shall mean the total amount payable by Owner to Contractor under the
Contract and any amendments thereto, less the amount properly paid by the Owner
to the Contractor.
Any suit under this bond must be instituted before the expiration of two (2) years from the
date on which the final payment under the Contract falls due.
No right of action shall accrue on this bond to or for the use of any persons or corporation
other than the Owner named herein or the heirs, executors, administrators or successors
of the Owner.
Signed and sealed this
day of
AD. 1998.
Witness (})VUM t l 91. .jlJU1.fIA,
Attest rr ~~
Witness ~J 6-A-. <~
Witness il~ j], ~
P.F. Moon and Company, Inc.
~
(Title)
St. Paul Fire and Marine
Insurance Company
Surety
(Seal)
(Seal)
(Seal)
Terry L. Reynolds
Attorney-in-Fact
Note: Date of Bond must be prior to date of Contract. If Contractor is partnership, all
partnerSo'Should execute bond.
(Seal)
PERFORMANCE BOND
00140-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 97 12401
North Clarifier Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
BOND NUMBER 400KA6908
SECTION 00145 -LABOR AND MATERIAL PAYMENT BOND
THIS BOND IS EXECUTED TOGETHER WITH ANOTHER BOND IN FAVOR OF THE OWNER
AS OBLIGEE CONDITIONED UPON PERFORMANCE OF THE CONTRACT.
KNOW ALL MEN BY THESE PRESENTS:
That P. F. Moon and compan~. . ,as Pri~cipal, herei~a.fter called Contractor and
St. Paul Fire and Marine Insurance ,corporation organrzed and eXisting under the laws of the
State of Minnesota , with its principal office in the City of St. Paul , State of
Minnesota ,as Surety, hereinafter called Surety, are held and firmly bound unto Augusta-
Richmond County Commission, as Obligee, hereinafter called the Owner, for the use and benefit
of claimants as hereinbelow hundr~fi~ /.lrvln the amount of
Four million three hundred seventy thousand six OOTrars (r4 ,~J70, 600.00 ) for the payment
whereof Contractor and Surety bind themselves, their heirs, executors, administrators,
successors, and assigns, jointly and severally, firmly by these presents.
WHEREAS, the Contractor has by written agreement dated entered into a contract
with Owner for construction of Digester Modifications - Messerly Wastewater
Treatment Plant, Augusta-Richmond County, Georgia in accordance with
drawings and specifications issued by Freeman & Vaughn Engineering, Inc., which contract is by
reference made a part hereof, and is hereinafter referred to as the Contract.
NOW, THEREFORE, the condition of this obligation is such that if the Contractor shall promptly
make payment to all claimants as hereinafter defined, for all labor and materials used or as
reasonably required to use in the performance of the Contract, then this obligation shall be nuil
and void; otherwise it shall remain in full force and effect, subject, however, to the following
conditions:
J
1. A claimant is defined as one having a direct contract with the Contractor or with a
subcontractor for labor, material, ~r' both, used or reasonably required for use in the
performance of the Contract, labor and material being construed as to include that part of
wate&, gas, power, light, heat, oil, gasoline, telephone service or rental of equipment directly
applicable to the Contract..
2. The above named Contractor and SuretY hereby jointly and severally agree with the Owner
that every claimant as herein defined, who has not been paid in full before the expiration of a- - --
period of ninety days after the day on which the last of such claimant's work or labor was
done or performed, or materials was furnished by such claimant, may sue on this bond for
the use of such claimant, prosecute the suit to final judgment for such sum or sums as may
be justly due claimant, and have execution thereon. The Owner shall not be liable '.for the
payment of any costs or expenses of any such suit.
3. No suit or action shall be commenced hereunder by any claimant,
(a) Unless claimant, other than one having direct contact with the Contractor, shall have
given written notice to any two of the following: The Contractor, the Owner, or the Surety
above named, within ninety (90) days after such claimant did or performed the last of the
LABOR AND MATERIAL PAYMENT BOND
00145-1
F&V Project No. 97 12401
North Clarifier Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
work or labor, or furnished the last of the materials for which said claim is made, stating with
substantial accuracy the amount claimed and the name of the party to whom the materials
were furnished, or for whom the work or labor was done or performed. Such notice shall be
served by mailing the same by registered mail or certified mail, postage prepaid, in an
envelope addressed to the Contractor, Owner or Surety, at any place where an office
regularly maintained for the transaction of business, or served in any manner in which legal
process may be served. in the state in which the aforesaid project is located, save that such
service need not be made by a public officer.
(b) After the expiration of one (1) year following the date on which Contractor ceased work.
on said Contract, it being understood, however, that if any limitation embodied in this bond is
prohibited by any law controlling the construction hereof, such limitation shall be deemed to
be amended so as to be equal to the minimum period of limitation permitted by such law.
(c) Other than in a state court of competent jurisdiction in and for the county pr other
political subdivision of the state in which the project, or any part thereof, is situated, or in the
United States District Court for the district in which the project, or any part thereof, is situated,
and not elsewhere.
4. The amount of this bond shall be reduced by and to the extent of any payment or payments
made in good faith hereunder, inclusive of the payment by Surety of mechanic's liens which
may be filed of record against said improvement, whether or not claim for the amount of such
lien be presented under and against this bond.
Signed and sealed this
....
'..
"
Witness 8h1L{)b.t~. ~
Attestr:~~
~tness ~ J: &---:-
Witness !.l)~--- /J ~
day of
A.D. 1998.
P.F. Moon and Company, Inc.
~r
" · (Itle)
(Seal)
(Seal)
St. Paul Fire and Marine
Insurance Company
Surety
~ I-.~ (Seal)
. V (I ) Terry L. Reynolds
Attorney-in-Fact
Note: Date of Bond must be prior to date of Contract. If Contractor is partnership, all partners
should ~xecute bond.
(Seal)
LABOR AND MATERIAL PAYMENT BOND
00145-2
l11eStRlul
POWER,('~< ATTORNEY
Seaboard Surety Company
St. Paul Fire and Marine Insurance Company
St. Paul Guardian Insurance Company
St. Paul Mercury Insurance CompanY)'
United States Fidelity and Guaranty Company
Fidelity and Guarant)' Insurance Company
Fidelity and Guaranty Insurance Underwriters, Inc.
Power of Attorney No.
20057
Certificate No. 119 4 0
KNOW ALL MEN BY THESE PRESENTS: That Seaboard Surety Company is a corporation duly organized under the laws of the State of New York, and that
St. Paul Fire and Marine Insurance Company. St. Paul Guardian Insurance Company and St. Paul Mercury Insurance Company are corporations duly organized under
the laws of the State of Minnesota, and that United States Fidelity and Guaranty Company is a corporation duly organized under the laws of the State of Maryland, and
that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa, and that Fidelity and Guaranty Insurance
Underwriters, Inc. is a corporation duly organized under the laws of the State of Wisconsin (herein collectively called the "Companies"), and that the Companies do
hereby make, constitute and appoint
Travis G. Huffmes, Scott E. Russell, Timothy E. Barnhardt, Charlotte J. Ericson, Thomas M. Beman, Dave Henritze, Dale Sims,
Robert Yarbrough, Terry L. Reynolds, Deanna G. Herron and Brian E. Madden
of the City of Alpharetta , State Georgia , their true and lawful Attorney(s)-in-Fact,
each in their separate capacity if more than one is named above, to sign its name as surety to, and to execute, seal and acknowledge any and all bonds, undertakings,
contracts and other written instruments in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the
performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law.
IN WITNESS WHEREOf', the Companies have caused this instrument to be signed this
15th
day of
March
1999
Seaboard Surety Company
St. Paul Fire and Marine Insurance Company
St. Paul Guardian Insurance Company
St. Paul Mercury Insurance Company
United States Fidelity and Guaranty Company
Fidelity and Guaranty Insurance Company
Fidelity and Guaranty Insurance Underwriters, Inc.
~y~ ~~ @
~~~ j~ ~
~~~G <' ~~ ,,'( 1951
!IIl.Atff&'2 ~~ ~\\ ~~ \ , .f\ f\
A-N~~\,(~~~::\'--\~~~~ ~ R. }Ac.~
State of Maryland ~"l ~ ~y~", ~\--." ~'V
City of BaltImore ~'b ~ ~ '\.~ ~ ~ MICHAEL R. MCKIBBEN. Asslstanl Secretary
On this 15th day of March ~~ ~~192~ ~~e~re me, the undersigned officer. personally appeared Michael B. Keegan and
Michael R. McKibben. who acknowledged themselves to' Q~~Vlt;e P.\~e'ih an""~S~L\i'tant Secretary. respectively, of Seaboard Surety Company, St. Paul Fire and
Marine Insurance Company, St Paul GuardIan Insur~qce<GJlfu6~y(~~p-~U~e~~ t;;surance Company, United States FIdelity and Guaranty Company, Fidelity and
Guaranty Insurance Company. and Fidelity and Guararty\tnsUrnDCI13'tnderwn~rsflnc. and that they. as such. belllg authonzed so to do, executed the foregoing lIlstrument
for the purposes therein contained by signing the names o'f;~ 6'orporatio~by themselves as duly authorized officers.
c,c,~ EAS~r.
<0'<) t:!
if ^'O~R'y '1<!O
co PU8uC
':'"
~ !;)
o~E Cil'f ~
MJ.- J- ;;, ~o/'-
MICHAEL B KEEGAN, V,ce PreSIdent
In Witness Whereof, I hereunto set my hand and official seal.
~t~.~
My Commission expires the 13th day of July, 2002.
REBECCA EASLEY-ONOKALA, Notary Public
This Power of Allorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of Seaboard Surety Company, St. Paul
Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, United States Fidelity and Guaranty Company,
Fidelity and Guaranty Insurance Company, and Fidelity and Guaranty Insurance Underwriters, Inc. on September 2, 1998, which resolutions arc now in full force and
effect, reading as follows:
RESOLVED, that in connection with the fidelity and surety insurance business of the Company, all bonds, undertakings, contracts and other instruments relating
to said business may be signed. executed, and acknowledged by persons or entities appointed as Allorney(s)-in-Fact pursuant to a Power of Allorney issued in
accordance with these resolutions. Said Power(s) of Allorney for and on behalf of the Company may and shall be executed in the name and on behalf of the
Company. either by the Chairman, or the President, or any Vice President, or an Assistant Vice President, jointly with the Secretary or an Assistant Secretary,
under their respective designations. The signature of such officers may be engraved, printed or lithographed. The signature of each of the foregoing officers and
the seal of the Company may be affixed by facsimile 10 any Power of AlIorney or to any cenificate relating thereto appointing AlIorney(s)-in-Fact for purposes
only of executing and attesting bonds and undenakings and other writings obligatory in the nature thereof. and subject to any limitations set fonh therein. any
such Power of Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company, and any such power so
executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to
which it is validly attached; and
RESOLVED FURTHER, that Attorney(s)-in-Fact shall have the power ancl authority. and. in any case. subject to the terms and limitations of the Power of
Allorney issued them, to execute and deliver on behalf of the Company and to allach the seal of the Company to any and all bonds and undertakings, and other
writings obligatory in the nature thereof. and any such instrument executed by such Attorney(s)-in-Fact shall be as binding upon the Company as if signed by an
Executive Officer and sealed and attested to by the Secretary of the Company.
I, Michael R. McKibben, Assistant Secretary of Seaboard Surety Company. St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company,
St. Paul Mercury Insurance Company, United States Fidelity and Guaranty Company. Fidelity and Guaranty Insurance Company, and Fidelity and Guaranty Insurance
Underwriters, Inc. do hereby certify that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies, which is in full force
and effect and has not been revoked.
IN TESTIMONY WHEREOf', I hereunto set my hand this
day of
@
To verify the authenticity of this Power of Attorney, call 1-800-421-3880 and ask for the Power of Attorney clerk. Please refer to the Power of Attorney number,
the above-named individuals and the details of the bond to which the power is attached.
~ R. \v\c.~
. .
Michael R. McKibben, Assistant Secretary
86326 Ed. 3-99 Printed in U.S.A.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 00150 - CERTIFICATE OF OWNER'S ATTORNEY
I, the undersigned , the authorized and acting legal
representative of Augusta-Richmond County Commission do hereby certify as follows:
I have examined the attached Contract(s) and Surety bonds and the manner of execution
thereof, and I am of the opinion that each of the aforesaid agreements has been duly
executed by the proper parties thereto acting through their duly authorized
representatives; that said representatives have full power and authority to execute said
agreements on behalf of the respective parties named thereon; and that the foregoing
agreements constitute valid and legally binding obligations upon the parties executing the
same in accordance with the terms, conditions and provisions thereof.
Date:
CERTIFICATE OF OWNER'S ATTORNEY
00150-1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
II
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 00155 - NOTICE TO PROCEED
TO: Date:
Project:: Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
You are hereby notified to commence work in accordance with the Agreement dated
, 1998, within ten (10) calendar days following this date, the date first
written above, and you are to complete the work within Three Hundred Sixty (360)
consecutive calendar days after the date of this notice. The date set for completion of all
work is therefor I 1998.
By:
Title:
Acceptance of Notice
Receipt of the above Notice to Proceed
is hereby acknowledged and the same is
hereby accepted on this day
of ,1998.
By:
Title: ~
NOTICE TO PROCEED
00155-1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 00160 - AFFIDAVIT OF PAYMENT OF CLAIMS
(CONTRACTOR) THIS DAY
appeared before me, , A Notary Public, in and for _
, arid being by me first duly sworn states that all subcontractors and
suppliers of labor and materials have been paid all sums due them to date for work
performed or material furnished in the performance of the contract between:
(OWNER) and
, 19_, for the construction of
(CONTRACTOR), dated
CONTRACTOR
BY:
TITLE:
DATE:
SEAL OF CONTRACTOR
(If a Corporation)
Subscribed and sworn to before
_ day of ,19_.
My commission expires on the _ day of
,19_
NOTARY PUBLIC
(NOTARY SEAL)
AFFIDAVIT OF PAYMENT OF CLAIMS
00160-1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 12401
Digester Modifications. Messerly Wastewater Treatment Plant
Augusta.Richmond County, Georgia.
SECTION 00170 - CERTIFICATE OF INSURANCE
This is to certify that
Crum & Forster Commercial Insurance
(Insurance Company)
of 901 Int'l Pkwy, Lake Mary, FL
has issued policies of insurance, as identified
(Insurance Co. Address)
by a policy number to the insured name below, and that such policies are in full force and
effect at this time. Furthermore, this is to certify that these policies meet the requirements
described in the Special Conditions of this contract; and its agreed that none of these
policies will be canceled or changed so as to affect this Certificate until ten (10) days after
written notice of such cancellation or change has been delivered to Augusta-Richmond .County
. Commission, Municipal Bldg., Augusta, GA jU~ll
(Client & Client Address) .
1. INSURED P. F. Moon & Co., Inc.
(CONTRACTOR)
2. ADDRESS 2207 Highway 103, P. O. Box 346, West Point, GA 31833
3. PROJECT NAME: Digester Modifications-Messerly Wastewater Treatment Plant
4. PROJECT NUMBER: 9911
5. POLICY NUMBER(S): 5031721881, 1336384062
5530656483, 4086074169.
DATE: September 20. 1999
Crum & Forster Commercial Ins.
INSURANCE COMPANY
ISSUED AT: Alpharetta. GA
k7-f
AUTHORIZED REPRESENTATIVE
ADDRESS 3100 Royal Blvd South, P.O. Box 2190
Alpharetta, GA 30023-2190
CERTIFICATE OF INSURANCE
00170-1
ACORD~
"I$r::mml EI..../fS../AmrnI&Eli..'.1 Adl 1>1 TV'I Kicllrn^KI;.s~~lb~di.i""" DATE (MMIDD/YY)
,.,......~.,~..~..I/m...,~'SI.7i~V....~...,..R'.I7?J....e<r1...,.,I:~.&1.'~.~r:mJ)I}#ttt'M90~l?7i:.' 09/16/99
.. , .;>THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
COMPANIES AFFORDING COVERAGE
PRODUCER
Huffines-Russell & Associates
P.O. Box 2190
Alpharetta GA 30023-2190
Phone No. 770-664-6818 Fax No. 770-475-0341
INSURED
COMPANY
A
Crum & Forster Commercial Ins
COMPANY
B
P. F. Moon and Company, Inc.
2207 Highway 103
P. O. Box 346
West Point GA 31833
COMPANY
C
COMPANY
o
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO All THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
CO
LTR
lYPE OF INSURANCE
POLICY NUMBER
POLICY EFFECTIVE POLICY EXPIRATION
DATE (MM/DD/YY) DATE (MMIDD/YY)
L1MrrS
GENERAL lIABILI1Y
X COMMERCIAL GENERAL LIABllIlY
CLAIMS MADE [!] OCCUR
OWNER'S & CONTRACTOR'S PROT
X XCU Included
5031721881
11/01/98
GENERAL AGGREGATE $ 2 , 000 , 000
11/01/99 PRODUCTS - COMP/OP AGG $ 1,000,000
PERSONAL & ADV INJURY $ 1,000,000
EACH OCCURRENCE $ 1,000,000
FIRE DAMAGE (Anyone fire) $ 50 , 000
MED EXP (Anyone person) $ 5 , 000
PER JOB/PER AGGREGATE
END'T. INCLUDED
A
AUTOMOBILE L1ABILI1Y
X ANY AUTO
ALL OWNED AUTOS
SCHEDULED AUTOS
HIRED AUTOS
NON-OWNED AUTOS
1336384062
11/01/98
11/01/99
COMBINED SINGLE LIMIT
$ 1,000,000
BODILY INJURY
(per person)
BODILY INJURY
(Per accident)
$
PROPERlY DAMAGE $
GARAGE L1ABILI1Y
ANY AUTO
EXCESS lIABILllY
A X UMBRELLA FORM
5530656483
11/01/98
AUTO ONLY - EA ACCIDENT $
OTHER THAN AUTO ONLY:
EACH ACCIDENT $
AGGREGATE $
EACH OCCURRENCE $ 10,000,000
11/01/99 AGGREGATE $ 10,000,000
OTHER THAN UMBRELLA FORM
WORKERS COMPENSATION AND
EMPLOYERS' L1ABILIlY
A THE PROPRIETORl INCL 408 6074169
PARTNERS/EXECUTIVE
OFFICERS ARE: EXCL
OTHER
11/01/98
$
11/01/ 9 9 EL DISEASE - POLICY LIMIT $
EL DISEASE - EA EMPLOYEE $
500,000
500,000
500,000
A PROPERTY
REPLACEMENT COST
5031721881
SPECIAL FORM
11/01/98
11/01/99
PERS PROP
BUILDINGS
$ 160,000
$ 545,000
DESCRIPTION OF OPERATlONSIlOCATlONSNEHICLES/SPECIAL ITEMS
RE: DIGESTER MODIFICATIONS MESSERLY WASTEWATER TREATMENT PLANT. JOB #9911.
AUGU-Ol
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL
~ DAYS WRITTEN NOnCE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,
BUT FAILURE 0 MAIL SUCH NOTICE SHALL IM';\?SE NO OBLIGATION OR L1ABllIlY
AUGUSTA-RICHMOND COUNTY
COMMISSION
MUNICIPAL BUILDING
AUGUSTA, GA 30911
...........,.,........"."..................,.....-..,.,.........,...,...............,.,.
........... ..... - . -., . ..... . .. ... . ,... -. . . - ... .
:,(?ACORDCORPQRATION,.1988\<
........... ......................... ...... ............... -.......... ...
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
NOTE: Please attach Certificate of Insurance form to this page.
CERTIFICATE OF INSURANCE
00170-2
..
~
c . -\
Notwithstanding any provIsion of the general conditions, there shall be no
substitution of materials that are not determined to be equivalent to those
indicated or required in the contract documents without an amendment to the
contract.
..,::0-
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
"
')
~
.i
SECTION 01001 - GENERAL CONDITIONS
ARTICLE I-DEFINITIONS
Wherever used in these General Conditions or in the other Contract Documents the following
terms have the meanings indicated which are applicable to both the singular and plural
,thereof:.J -
Addenda-Any changes, revisions of clarifications of the Contract Documents which have
been duly issued by COUNTY to prospective Bidders prior to the time of opening of Bids.
Agreement-The written agreement between OWNER and CONTRACTOR covering the Work
to be performed: other Contract Documents are attached to the Agreement and made a part
thereof as provided therein.
Application for Payment-The form accepted by PROFESSIONAL which is to be used by
CONTRACTOR in requesting progress or final payments and which is to include such sup-
porting documentation as is required by the Contract Documents.
Bid-The offer or proposal of the bidder submitted on the prescribed form setting forth the
price(s) for the Work to be performed.
Bonds-Bid, performance and payment bonds and other instruments of security furnished by
CONTRACTOR and its Surety in accordance with the Contract Documents.
Change Order--A document recommended by PROFESSIONAL, which is signed by
CONTRACTOR and OWNER and authorizes an addition, deletion or revision in the Work, or
an adjustment in the Contract Price or the Contract Time, issued on or after the Effective
Date of the Agreement.
. Contract Documents-The Agreement, Addenda (which pertain to the Contract DQctlments),
CONTRACroR's Bid (including documentation accompanying the Bid and any post-Bid
documentation submitted prior to the Notice of Award) when attached as an exhibit to the
Agreement, the Bonds, these General Conditions, the Supplementary Conditions, the Plans,
Specifications and the Drawings as the same are more specifically identified in the
Agreement, Certificates of Insurance, Notice of Award, and Change Order duly delivered
after execution of Contract. together with all amendments, modifications and supplements
issued pursuant to paragraphs 3.4 and 3.5 or after the Effective Date of the Agreement.
Contract Price-The moneys payable by OWNER to CONTRACTOR under the Contract
Documents as stated in the Agreement (subject to the provisions of paragraph 11.9.1 in the
case of Unit Price Work).
I
Contract Time-The number of days (computed as provided in paragraph 17.2) or the date
stated in the Agreement for the completion of the Work.
GENERAL CONDITIONS
01001-1
I , . .
.-
..,-'.. ..
CONTRACTOR-The person, firm or corporation with whom OWNER has entered into the
Agreement.
COUNTY-Richmond County, Georgia, or Augusta, Georgia, political subdivisions of the
State of .GeGfgia, the Augusta-Richmond County Commission, and its authorized designees,
agents, or employees.
Day-Either a working day or calendar day as specified in the bid documents. If a calendar
day shall fall on a legal holiday that day will be omitted from the computation, Legal Holidays:
New Year's Day, Martin Luther King Day, Memorial Day, 4th of July, Labor Day, Veterans
Day, Thanksgiving Day and the following Friday, and Christmas Day.
Defective-An adjective which when modifying the word Work refers to Work that is
unsatisfactory, faulty or deficient, or does not conform to the Contract Documents, or does
not meet the requirements of any inspection, reference standard, test or approval referred to
in the Contract Documents, or has been damaged prior to PROFESSIONAL's
recommendation of final payment, unless responsibility for the protection thereof has been
assumed by OWNER at Substantial Completion in accordance with paragraph 14.8 or
14.10).
Drawings-The drawings which show the character and scope of the Work to be performed
and which have been prepared or approved by PROFESSIONAL and are referred to in the
Contract Documents.
Effective Date of the Agreement-The date indicated in the Agreement on which it becomes
effective, but if no such date is indicated it means the date on which the Agreement is signed
by the Mayor of the Augusta, Georgia.
Field Order-A written order issued by PROFESSIONAL that modifies Drawings ~ncl
Specifics.tions, but which does not involve a change in the Contract Price or the-Contract
Time. .-
General Requirements-Sections of Division I of the Specifications.
Laws and Regulations: Laws or Regulations-Laws. rules, regulations, ordinances, codes
and/or orders.
Notice of Award-The written notice by OWNER to the apparent successful bidder stating that
upon compliance by the apparent successful bidder with the conditions precedent
enumerated therein, within the time specified, OWNER will sign and deliver the Agreement.
Notice t~ P~oceed-A written notice given by OWNER to CONTRACTOR (with a copy to
PROFESSIONAL) fixing the date on which the Contract Time will commence to run and on
GENERAL CONDITIONS
01001-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
which CONTRACTOR shall start to perform CONTRACTOR'S obligations under the Contract
Documents.
OWNER- Augusta, Georgia, and the Augusta-Richmond County Commission.
Partial Utilization-Placing a portion of the Work in service for the purpose for which it is
intendee.for-a related purpose) before reaching Substantial Completion for all the-Work.
Professional-The Architectural/Engineering firm or individual or in-house licensed person
designated to perform the design and/or resident engineer services for the Work.
Project-The total construction of which the Work to be provided under the Contract
Documents may be the whole, or a part as indicated elsewhere in the Contract Documents.
Project Area-The area within which are the specified Contract Limits of the improvements
contemplated to be constructed in whole or in part under this Contract.
Project Manager-The professional in charge, serving COUNTY with architectural or
engineering services, his successor, or any other person or persons, employed by said
COUNTY, for the purpose of directing or having in charge the work embraced in this
Contract.
Resident Project Representative-The authorized representative of PROFESSIONAL who is
assigned to the site or any part thereof.
Shop Drawings-All drawings, diagrams, illustrations, schedules and other data which are
specifically prepared by or for CONTRACTOR to illustrate some portion of the Work and all
illustrations, brochures, standard schedules, performance charts, instructions, diagrams and
other information prepared by a Supplier and submitted by CONTRACTOR to illustrate
material or equipment for some portion of the Work.
~. k.
--- :=-
Specificatior:ls- Those portions of the Contract Documents consisting of written technical
descriptions of materials, equipment, construction systems, standards and workmanship as
applied to the Work and certain administrative details applicable thereto.
Subcontractor-An individual, firm or corporation having a direct contract with CONTRACTOR
or with any other SUBCONTRACTOR for the performance of a part of the Work at the site.
Substantial Completion-The Work (or a specified part thereof) has progressed to the point
where, in the opinion of PROFESSIONAL as evidenced by PROFESSIONAL's definitive
certificate of Substantial Completion, it is sufficiently complete, in accordance with the
Contract Documents, so that the Work (or specified part) can be used for the purposes for
which it is intended, or if there be no such certificate issued, when final payment is due in
accordance. wit.h paragraph 14.13. The terms "substantially complete" and "substantially
completed" as applied to any Work refer to Substantial Completion thereof.
GENERAL CONDITIONS
01001-3
Supplementary Conditions-The part of the Contract Documents which amends or
supplements these General Conditions.
Supplier-A manufacturer, fabricator, supplier, distributor, materialman or vendor.
Undergwund Facilities-All pipelines, conduits, ducts, cables, wires, manholes, val:Jlts, tanks,
tunnels or other such facilities or attachments, and any encasement containing such facilities
which have been installed underground to furnish any of the following services or materials,
electricity, gases, steam, liquid petroleum products, telephone or other communications,
cable television, sewage and drainage removal, traffic or other control systems or water.
Unit Price Work-Work to be paid for on the basis of unit prices.
Work-The entire completed construction or the various separately identifiable parts thereof
required to be furnished under the Contract Documents. Work is the result of performing
services, furnishing labor and furnishing and incorporating materials and equipment into the
construction, and furnishing documents, all as required by the Contract Documents.
Work Directive Change-A written directive to CONTRACTOR, issued on or after the Effective
Date of the Agreement and signed by OWNER and recommended by PROFESSIONAL,
ordering an addition, deletion or revision in the Work, or responding to differing or unforeseen
physical conditions under which the Work is to be performed as provided in paragraph 4.2 or
4.3 or to emergencies under paragraph 6.22. A Work Directive Change may not change the
Contract Price or the Contract Time, but is evidence that the parties expect that the change
directed or documented by a Work Directive Change will be incorporated in a subsequently
issued Change Order following negotiations by the parties as to its effect, if any, on the
Contract Price or Contract Time as provided in Article 10. .
Written Amendment-A written amendment of the Contract Documents, signed by OWNER
and CONTRACTOR on or after the Effective Date of the Agreement and norm~lIy ~ealing
with thV1on-engineering or non-technical rather than strictly Work-related aspectS-of the
Contract Documents. --
ARTICLE 2-PRELlMINARY MATTERS
Delivery of Bonds:
2.1. When CONTRACTOR delivers the executed Agreements to OWNER,
CONTRACTOR shall also deliver to OWNER such Bonds as CONTRACTOR may be
required to furnish in accordance with these Contract Documents.
Copies of Documents:
2.2. After the award of the Contract, OWNER shall furnish CONTRACTOR, at no
cost, one (1) complete set of the Contract Documents for execution of the work. Additional
GENERAL CONDITIONS
01001-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
sets of the project manual and drawings and/or individual pages or sheets of the project
manual or drawings will be furnished by COUNTY upon CONTRACTOR's request and at
CONTRACTOR's expense, which will be OWNER's standard charges for printing and
reproduction.
Commencement of Contract Time, Notice to Proceed:
- -
2.3. The Contract Time shall commence as established in the Notice to Proceed. A
Notice to Proceed may be given at any time after the Effective Date of the Contract.
Starting the Project:
2.4. CONTRACTOR shall begin the Work on the date the Contract Time commences.
No Work shall be done prior to the date on which the Contract Time commences. Any Work
performed by CONTRACTOR prior to date on which Contract Time commences shall be at
the sole risk of CONTRACTOR.
Before Starting Construction:
2.5. Before undertaking each part of the Work. CONTRACTOR shall carefully study
and compare the Contract Documents and check and verify pertinent figures shown thereon
and all applicable field measurements. CONTRACTOR shall promptly report in writing to
PROFESSIONAL any conflict, error, ambiguity, or discrepancy which CONTRACTOR may
discover and shall obtain a written interpretation or clarification from PROFESSIONAL before
proceeding with any Work affected thereby. CONTRACTOR shall be liable to OWNER for
failure to report any conflict, effort, ambiguity or discrepancy in the Contract Documents, if
CONTRACTOR knew or reasonably should have known thereof.
2.6. Within ten days after the Effective Date of the Agreement unless otherwise
specified in the General Requirements), CONTRACTOR shall submit to PROFESSIONAL
AND PROJECT MANAGER for review: ~_ ~
- -,
2.6.1. an estimated progress schedule indicating the starting and completion dates of
the var.i().us stages of the Work:
2.6.2. a preliminary schedule of Shop Drawing and Sample submissions: and
2.6.3. a preliminary schedule of values for all of the Work which will include quantities
and prices of items aggregating the Contract Price and will subdivide the Work into
component parts in sufficient detail to serve as the basis for progress payments during
construction. Such prices will include an appropriate amount of overhead and profit
applicable to each item of Work which will be confirmed in writing by CONTRACTOR at the
time of submission.
GENERAL CONDITIONS
01001-5
2.7. Before any Work at the site is started, CONTRACTOR shall deliver to OWNER,
with copies to each additional insured identified in the Supplementary Conditions, an original
policy or certified copies of each insurance policy (and other evidence of insurance which
COUNTY may reasonably request) which CONTRACTOR is required to purchase and
maintain in accordance with Article 5.
-' &.
Pre-construction Conference:
2.8. Before any Work at the site is started, a conference attended by CONTRACTOR,
Project Manager, Professional and others as appropriate will be held to establish a working
understanding among the parties as to the Work and to discuss the schedules referred to in
2.6, procedures for handling Shop Drawings and other submittals, processing applications for
payment and maintaining required records.
Finalizing Schedules:
2.9. At least ten days before submission of the first Application for Payment a
conference attended by CONTRACTOR, PROFESSIONAL and Project Manager and others
as appropriate will be held to finalize the schedules submitted in accordance with paragraph
2.6. CONTRACTOR shall have an additional ten (10) calendar days to make corrections and
adjustments and to complete and resubmit the schedules. No progress payment shall be
made to CONTRACTOR until the schedules are submitted to and acceptable to Project
Manager and PROFESSIONAL as provided below. The finalized progress schedule will be
acceptable to Project Manager and PROFESSIONAL as providing an orderly progression of
the Work to completion within any specified Milestones and the Contract Time, but such
acceptance will neither impose on PROFESSIONAL responsibility for the sequencing,
scheduling or progress of the Work nor interfere with or relieve CONTRACTOR from full
responsibility therefor, The finalized schedule of Shop Drawing submissions and Sample
submissions will be acceptable to PROFESSIONAL as providing a workable arrangement for
reviewing and processing the submissions. CONTRACTOR's schedule of value~ sball be
approveg. by_PROFESSIONAL as to form and substance. -- ~
CONTRACTOR, in addition to preparing an initially acceptable schedule, shall be responsible
for maintaining the schedule, including updating schedule. Schedule updates shall include
progression of work as compared to scheduled progress on work. Schedule updates shall
accompany each pay request.
ARTICLE 3-CONTRACT DOCUMENTS; INTENT,
AMENDING, REUSE
Intent:
3.1. The Contract Documents comprise the entire agreement between OWNER and
CONTRACTOR concerning the Work. The Contract Documents are complementary: what is
GENERAL CONDITIONS
01001-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
.
-
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
called for by one is as binding as if called for by all. The Contract Documents will be
construed in accordance with the law of the State of Georgia.
3.2. It is the intent of the Contract Documents to describe a functionally complete
Project (or part thereof) to be constructed in accordance with the Contract Documents. Any
Work, materials or equipment that may reasonably be inferred from the Contract Documents
or from prevailing custom or trade usage as being required to produce the intended result will
be supplied whether or not specifically called for. When words or phrases which have a well-
known technical or construction industry or trade meaning are used to describe Work,
materials or equipment, such words shall be interpreted in accordance with that meaning.
3.3. Except as otherwise specifically stated in the Contract Documents or as may be
provided by amendment or supplement thereto issued by one of the methods indicated in 3.6
or 3.7, the provisions of the Contract Documents shall take precedence in resolving any
conflict, error, ambiguity or discrepancy between the provisions of the Contract Documents
and the provisions of any such standard, specification, manual, code or instruction (whether
or not specifically incorporated by reference in the Contract Documents)and the provisions of
any such Laws or Regulations application to the performance of the Work (unless such an
interpretation of the provisions of the Contract Documents would result in violation of such
Law or Regulation). Clarifications and interpretations of the Contract Documents shall be
issued by PROFESSIONAL as provided in paragraph 9.4.
3.4. Reference to standards, specifications, manuals or codes of any technical society,
organization or association, or to the Laws or Regulations of any governmental authority,
whether such reference be specific or by implication, shall mean the latest standard,
specification, manual, code or Laws or Regulations in effect at the time of opening of Bids
(or, on the Effective Date of the Agreement if there were no Bids), except as may be
otherwise specifically stated in the Contract Documents.
3.5. If, during the performance of the Work, CONTRACTOR discovers any_conflict,
error, ambiguity or discrepancy within the Contract Documents or between the Contract
Documents and any provision of any such Law or Regulation applicable to the performance
of the Work or of any such standard, specification, manual or code or of any instruction of
any Supplier referred to in 6.7, CONTRACTOR shall so report to PROFESSIONAL in
writing at once and before proceeding with the Work affected thereby shall obtain a written
interpretation or clarification from PROFESSIONAL; however, CONTRACTOR shall not be
liable to OWNER or PROFESSIONAL for failure to report any conflict, error ambiguity or
discrepancy in the Contract Documents unless CONTRACTOR had actual knowledge
thereof or should reasonably have known thereof.
GENERAL CONDITIONS
01001-7
Amending and Supplementing Contract Documents:
3.6. The Contract Documents may be amended to provide for additions. deletions and
revisions in the Work or to modify the terms and conditions thereof in one or more of the
following ways:
- -
3.6.1. a formal Written Amendment,
3.6.2. a Change Order (pursuant to paragraph 10.3), or
3.6.3. a Work Directive Change (pursuant to paragraph 10.4).
As indicated in paragraphs 11.2 and 12.1, Contract Price and Contract Time may only
be changed by a Change Order or a Written Amendment.
3.7. In addition. the requirements of the Contract Documents may be supplemented,
and minor variations and deviations in the Work may be authorized, in one or more of the
following ways:
3.7.1. a Field Order (pursuant to paragraph 9.5).
3.7.2. PROFESSIONAL's approval of a Shop Drawing or sample (pursuant to
paragraphs 6.24 and 6.26), or
3.7.3. PROFESSIONAL's written interpretation or certification (pursuant to paragraph
9.4).
Reuse of documents:
3.8. Neither CONTRACTOR nor any Subcontractor or Supplier or other p~rs.9n or
organizC!1ioQ.performing or furnishing any of the Work under a direct or indirect contract with
OWNER shall have or acquire any title to or ownership rights in any of the Drawings,
Specifications or other documents (or copies oil any thereof) prepared by or bearing the seal
of PROFESSIONAL or PROFESSIONAL's consultant; and they shall not reuse such
Drawings, Specifications or other documents (or copies of any thereof) on extensions of the
Project or any other project without written consent of OWNER and PROFESSIONAL and
specific written verification or adaptation by PROFESSIONAL.
ARTICLE 4-A V AI LABILITY OF LANDS, PHYSICAL
CONDITIONS; REFERENCE POINTS
Availability of Lands:
4.1. OWNER shall furnish as indicated in the Contract Documents, the lands upon
which the Work is to be performed, rights-of-way and easements for access thereto, and
GENERAL CONDITIONS
01001-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
.1
I
I
I
I
I
I
I
I
I
I
I
I
such other lands which are designated for the use of CONTRACTOR. Necessary easements
or rights-of-way will be obtained and expenses will be borne by OWNER. If CONTRACTOR
and OWNER are unable to agree on entitlement to or the amount or extent of any
adjustments in the Contract Price or the Contract Times as a result of any delay in OWNER's
furnishing these lands, rights-of-way or easements, the CONTRACTOR may make a claim
therefor as provided in Articles 11 and 12. The CONTRACTOR shall provide for all
additionaf lands and access thereto that may be required for temporary construction facilities
or storage of materials and equipment.
Physical Conditions:
4.2.1. Explorations and Reports: Reference is made to the Supplementary Conditions
for identification of those reports of explorations and tests of subsurface conditions at or
contiguous to the site that have been utilized in preparing the Contract Documents, and
those drawings of physical conditions in or relating to existing surface or subsurface
structures at or contiguous to the site (except Underground Facilities) that have been utilized
in preparing the Contract Documents.
4.2.2. CONTRACTOR may rely upon the general accuracy of the "technical data"
contained in such reports and drawings. Such "technical data" is identified in the
Supplementary Conditions, Except for such reliance on such "technical data,"
CONTRACTOR may not rely upon or make any claim against OWNER, PROFESSIONAL, or
any of PROFESSIONAL's Consultants with respect to:
4.2.2.1. the completeness of such reports and drawings for CONTRACTOR's
purposes, including, but not limited to, any aspects of the means, methods, techniques,
sequences and procedures of construction to be employed by CONTRACTOR and safety
precautions and programs incident thereto, or
4.2.2.2. other data, interpretations, opinions and information contained in such reports
or shown or indicated in such drawings, or -:_ ~
4.2.2.3. any CONTRACTOR interpretation of or conclusion drawn from any "technical
data" or any such data, interpretations, opinions or information.
4.2.3. If conditions are encountered, excluding existing utilities, at the site which are
(1) subsurface or otherwise concealed physical conditions which differ materially from those
indicated in the Contract Documents or (2) unknown physical conditions of an unusual
nature, which differ materially from those ordinarily found to exist and generally recognized
as inherent in construction activities of the character provided for in the Contract Documents,
then CONTRACTOR shall give COUNTY notice thereof promptly before conditions are
disturbed and in no event later than 48 hours after first observance of the conditions.
, , 4.2.4. The Project Manager and PROFESSIONAL shall promptly investigate such
conditions, and, if they differ materially and cause an increase or decrease in
GENERAL CONDITIONS
01001-9
CONTRACTOR's cost of, or time required for, performance of any part of the Work, the
Project Manager and PROFESSIONAL shall recommend an equitable adjustment in the
Contract Price or Contract Time, or both. If the Project Manager and PROFESSIONAL
determines that the conditions at the Site are not materially different from those indicated in
the Contract Documents or are not materially different from those ordinarily found and that no
change io the terms of the Contract is justified, the PROFESSIONAL shall notify .
CONTRACTOR of the determination in writing. The Work shall be performed after direction
is provided by the PROFESSIONAL.
Physical Conditions-Underground Facilities:
4.3.1. Shown or Indicated: The information and data shown or indicated in the
Contract Documents with respect to existing Underground Facilities at or contiguous to the
site is based on information and data furnished to OWNER or PROFESSIONAL by OWNERs
of such Underground Facilities or by others. Unless it is otherwise expressly provided in the
Supplementary Conditions:
4.3.1.1. OWNER and PROFESSIONAL shall not be responsible for the accuracy or
completeness of any such information or data: and
4.3.1.2. The cost of all of the following will be included in the Contract Price and
CONTRACTOR shall have full responsibility for reviewing and checking all such information
and data. for locating all Underground Facilities shown or indicated in the Contract
Documents. for coordination of the Work with the OWNERs of such Underground Facilities
during construction. for the safety and protection thereof as provided in paragraph 6.20 and
repairing any damage thereto resulting from the Work, the cost of all of which will be
considered as having been included in the Contract Price.
4.3.2. Not Shown or Indicated. If an Underground Facility is uncovered or re;,vealed at
or contiffilo~s to the site which was not shown or indicated in the Contract Documents and
which CONTRACTOR could not reasonably have been expected to be aware of, -
CONTRACTOR shall, promptly after becoming aware thereof and before performing any
Work affected thereby except in an emergency as permitted by paragraph 6.22), identify the
owner of such Underground Facility and give written notice thereof to that owner and to
OWNER and PROFESSIONAL. PROFESSIONAL will promptly review the Underground
Facility to determine he extent to which the Contract Documents should be modified to
reflect and document the consequences of the existence of the Underground Facility, and the
Contract Documents will be amended or supplemented to the extent necessary. During such
time, CONTRACTOR shall be responsible for the safety and protection of such Underground
Facility as provided in paragraph 6.20. CONTRACTOR shall be allowed an increase in the
Contract Price or an extension of the Contract Time, or both; to the extent that they are
attributable.to the existence of any Underground Facility that was not shown or indicated in
the Contract Documents and which CONTRACTOR could not reasonably have been
GENERAL CONDITIONS
01 001-1 0
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
'1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
expected to be aware of. If the parties are unable to agree as to the amount or length
thereof, CONTRACTOR may make a claim therefor as provided in Articles 11 and 12.
Reference Points:
I
, 4.4. OWNER shall provide Engineering surveys to establish reference points for
construcflon.which in PROFESSIONAL's judgment are necessary to enable CONTRACTOR
to proceed with the Work. CONTRACTOR shall be responsible for laying out the Work
(unless otherwise specified in the General Requirements), shall protect and preserve the
established reference points and shall make no changes or relocations without the prior
written approval of OWNER. CONTRACTOR shall report to PROFESSIONAL whenever any
reference point is lost or destroyed or requires relocation because of necessary changes in
grades or locations, and shall be responsible for the accurate replacement or relocation of
such reference points by professionally qualified personnel.
Asbestos, PCBs, Petroleum, Hazardous Waste or Radioactive Material:
4.5 COUNTY shall be responsible for any Asbestos, PCBs, Petroleum, Hazardous
Waste or Radioactive Material uncovered or revealed at the site which was not shown or
indicated in Drawings or Specifications or identified in the Contract Documents to be within
the scope of the Work and which may present a substantial danger to persons or property
exposed thereto in connection with the Work at the site. COUNTY shall not be responsible
for any such materials brought to the site by CONTRACTOR, Subcontractor, Suppliers or
anyone else for whom CONTRACTOR is responsible.
4.6 CONTRACTOR shall immediately: (i) stop all work in connection with such
hazardous condition and in any area affected thereby (except in an emergency as required
by 6.22). and (ii) notify OWNER and PROFESSIONAL (and thereafter confirm such notice in
writing). OWNER shall promptly consult with PROFESSIONAL concerning the necessity for
OWNER to retain a qualified expert to evaluate such hazardous condition or ta~ c~rrective
action, if.any, CONTRACTOR shall not be required to resume Work in connection with such
hazardous condition or in any such affected area until after OWNER has obtained any
required permits related thereto and delivered to CONTRACTOR special written notice (i)
specifying that such condition and any affected area is or has been rendered safe for the
resumption of Work, or (ii) specifying any special conditions under which such Work may be
resumed safely. If OWNER and CONTRACTOR cannot agree as to entitlement to or the
amount or extent of an adjustment, if any, in Contract Price or Contract Times as a result of
such Work stoppage or such special conditions under which Work is agreed by
CONTRACTOR to be resumed, either party may make a claim therefor as provided in
Articles 11 and 12.
4.7 If after receipt of such special written notice, CONTRACTOR does not agree to
resume such Work based on a reasonable belief it is unsafe, or does not agree to resume
such Work under such special conditions, then CONTRACTOR may order such portion of the
GENERAL CONDITIONS
01001-11
Work that is in connection with such hazardous conditions or in such affected area to be
deleted from the Work. If COUNTY and CONTRACTOR cannot agree as to entitlement to or
the amount or extent of an adjustment, if any, in Contract Price or Contract Times as a result
of deleting such portion of the Work, then either party may make a claim therefor as provided
in Articles \11 and 12. COUNTY may have such deleted portion of the Work performed by
COUN~s own forces or others in accordance with Article 8.
4.7.1 The provisions of 4.2 and 4.3 are not intended to apply to Asbestos,
PCBs, Petroleum, Hazardous Waste or Radioactive Material uncovered or revealed at the
site.
ARTICLE 5-BONDS AND INSURANCE
Performance and Other Bonds:
5.1. CONTRACTOR shall furnish performance and payment Bonds, each in an
amount at least equal to the Contract Price as Security for the faithful performance and
payment of all CONTRACTOR's obligations under the Contract Documents. These Bonds
shall remain in effect at least until one year after the date when final payment becomes due,
except as otherwise provided by Law or Regulation or by the Contract Documents.
CONTRACTOR shall also furnish such other Bonds as are required by the Supplementary
Conditions. All Bonds shall be in the forms prescribed by Law or Reputation or by the
Contract Documents and be executed by such sureties as are named in the current list of
"Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds, and
as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Audit
Staff Bureau of Accounts, U.S. Treasury Department. All Bonds signed by an agent must be
accompanied by a certified copy of the authority to act.
Licensed Sureties and Insurers; Certificates of Insurance
- -
5.2.1 All bonds and insurance required by the Contract Documents to be
purchased and maintained by CONTRACTOR shall be obtained from surety or insurance
companies that are duly licensed or authorized in the State of Georgia to issue bonds or
insurance policies for the limits and coverages so required. All bonds signed by an agent
must be accompanied by a certified copy of authority to act. Such surety and insurance
companies shall also meet such additional requirements and qualifications as may be
provided in the Supplementary Conditions.
5.2.2. CONTRACTOR shall deliver to OWNER, with copies to each additional
insured identified in 5.3, an original or a certified copy of the complete insurance policy for
each policy required, certificates of insurance (and other evidence of insurance requested by
OWNER or any other additional insured) which CONTRACTOR is required to purchase and
maintain in accordance with 5.3.
GENERAL CONDITIONS
01001-12
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
5.2.3. If the surety on any Bond furnished by CONTRACTOR is declared a bankrupt
or becomes insolvent or its right to do business is terminated in any state where any part of
the Project is located or it ceases to meet the requirements of paragraph 5.1.
CONTRACTOR shall within five days thereafter substitute another Bond and Surety, both of
which must.be acceptable to OWNER.
\ .
- ,~
CONTRACTOR's Liability Insurance:
5.3. CONTRACTOR shall purchase and maintain such comprehensive general liability
and other insurance as is appropriate for the Work being performed and furnished and as will
provide protection from claims set forth below which may arise out of or result from
CONTRACTOR's performance and furnishing of the Work and CONTRACTOR's other
obligations under the Contract Documents, whether it is to be performed or furnished by
CONTRACTOR, by any Subcontractor, by anyone directly or indirectly employed by any of
them to perform or furnish any of the Work, or by anyone for whose acts any of them may be
liable:
5.3.1. Claims under workers' or workmen's compensation. disability benefits and other
similar employee benefit acts;
5.3.2. Claims for damages because of bodily injury, occupational sickness or disease,
or death of CONTRACTOR's employees;
5.3.3. Claims for damages because of bodily injury, sickness or disease, or death of
any person other than CONTRACTOR's employees;
5.3.4. Claims for damages insured by personal injury liability coverage which are
sustained (a) by any person as a result of an offense directly or indirectly related to the
employment of such person by CONTRACTOR, or (b) by any other person for any'Other
. -
reason; - -
5.3.5. Claims for damages, other than to the Work itself, because of injury to or
destruction of tangible property wherever located, including loss of use resulting therefrom;
5.3.6. Claims arising out of operation of Laws or Regulations for damages because of
bodily injury or death of any person or for damage to property; and
5.3.7. Claims for damages because of bodily injury or death of any person or property
damage arising out of the ownership, maintenance or use of any motor vehicle.
The insurance required by this paragraph 5.3 shall include the specific coverages and be
written for not less than the limits of liability and coverages provided in the Supplementary
Conditions, or required by law, whichever is greater. The comprehensive general liability
GENERAL CONDITIONS
01001-13
insurance shall include completed operations insurance. All of the policies of insurance so
required to be purchased and maintained lot the certificates or other evidence thereof) shall
contain a provision or endorsement that the coverage afforded will not be canceled,
materially changed or renewal refused until at least thirty days' prior written notice has been
given to OWNER and PROFESSIONAL by certified mail. All such insurance shall remain in
effect un!jl final payment and at all times thereafter when CONTRACTOR may be correcting,
removing io"r replacing defective Work in accordance with paragraph 13.12. In addition,
CONTRACTOR shall maintain such completed operations insurance for at least two years
after final payment and furnish OWNER with evidence of continuation of such insurance at
final payment and one year thereafter.
Contractual Liability Insurance:
5.4. The comprehensive general liability insurance required by paragraph 5.3 will
include contractual liability insurance applicable to CONTRACTOR's obligations under
paragraphs 6.32 and 6.33.
Owner's Liability Insurance:
5.5. OWNER shall be responsible for purchasing and maintaining OWNER's own
liability insurance, and/or Risk Retention Program, and, at OWNER's option, may purchase
and maintain such insurance as will protect OWNER against claims which may arise from
operations under the Contract Documents.
Property Insurance:
5.6. Unless otherwise provided in the Supplementary Conditions, OWNER shall
purchase and maintain property insurance upon the Work at the site to the full insurable
value thereof (subject to such deductible amounts as may be provided in the Supplementary
Conditions or required by Laws and Regulations). This insurance shall include thelnterests
of OWNER, CONTRACTOR, Subcontractors, PROFESSIONAL and PROFESSIONAL's
- -
consultants in the Work, all of whom shall be listed as insureds or additional insured parties,
shall insure against the perils of fire and extended coverage and shall include. "all risk"
insurance for physical loss and damage including theft, vandalism and malicious mischief,
collapse and water damage, and such other perils as may be provided in the Supplementary
Conditions, and shall include damages, losses and expenses arising out of or resulting from
any insured loss or incurred in the repair or replacement of any insured property (including
but not limited to fees and charges of PROFESSIONALs, architects, attorneys and other
PROFESSIONALs). If not covered under the "all risk" insurance or otherwise provided in the
Supplementary Conditions, CONTRACTOR shall purchase and maintain similar property
insurance on portions of the Work stored on and off the site or in transit when such portions
of the Work are to be included in an Application for Payment.
5.7. OWNER shall purchase and maintain such boiler and machinery insurance or
additional property insurance as may be required by the Supplementary Conditions or Laws
GENERAL CONDITIONS
01001-14
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
and Regulations which will include the interests of OWNER, CONTRACTOR,
Subcontractors, PROFESSIONAL AND PROFESSIONAL's consultants in the Work, all of
whom shall be listed as insured or additional insured parties.
5.8. All the policies of insurance (or the certificates or other evidence thereof) required
to be purchased and maintained by OWNER in accordance with paragraphs 5.6 and 5.7 will
contain a"provision or endorsement that the coverage afforded will not be canceled or
materially changed or renewal refused until at least thirty days prior written notice has been
given to CONTRACTOR by certified mail and will contain waiver provisions in accordance
with paragraph of 5.11.2.
5.9. OWNER shall not be responsible for purchasing and maintaining any property
insurance to protect the Interests of CONTRACTOR, Subcontractors or others in the Work to
the extent of any deductible amounts that are provided in the Supplementary Conditions. The
risk of loss within the deductible amount, will be borne by CONTRACTOR, Subcontractor or
ot~ers suffering any such loss and if any of them wishes property insurance coverage within
the limits of such amounts, each may purchase and maintain it at the purchaser's own
expense.
5.10. If CONTRACTOR requests in writing that other special insurance be included in
the property insurance policy, OWNER shall, if possible, include such insurance, and the cost
thereof will be charged to CONTRACTOR by appropriate Change Order or Written
Amendment. Prior to commencement of the Work at the site, OWNER shall in writing advise
CONTRACTOR whether or not such other insurance has been procured by OWNER.
Waiver of Rights:
5.11.1. OWNER and CONTRACTOR waive all rights against each other for all losses
and damages caused by any of the perils covered by the policies of insurance provided in
response to paragraphs 5.6 and 5.7 and other property insurance applicable to the Work,
and also waive aI/such rights against the Subcontractors, PROFESSIONAL, ..:.. _ ~
PROFESSleNAL's consultants and all other parties named as insureds in such policies for
losses and damages so caused. AS required by paragraph 6.11. each subcontract between
CONTRACTOR and a Subcontractor will contain similar waiver provisions by the
Subcontractor in favor of OWNER, CONTRACTOR, PROFESSIONAL, PROFESSIONAL's
consultants and all other parties named as insureds. None of the above waivers shall extend
to the rights that any of the insured parties may have to the proceeds of insurance held by
OWNER as trustee or otherwise payable under any policy so issued.
5.11.2. OWNER and CONTRACTOR intend that policies provided in response to
paragraphs 5.6 and 5.7 shall protect all of the parties insured and provide primary coverage
for all losses and damages caused by the perils covered thereby. Accordingly, all such
policies shall contain provisions'to the effect that in the event of payment of any loss or
damage the insurer will have no rights of recovery against any of the parties named as
insureds additional insureds, and if the insurers require separate waiver forms to be signed
GENERAL CONDITIONS
01001-15
by PROFESSIONAL or PROFESSIONAL's consultant OWNER will obtain the same, and if
such waiver forms are required of any Subcontractor, CONTRACTOR will obtain the same.
Receipt and Application of Proceeds:
5.,j2.- Any insured loss under the policies of insurance required by paragraphs 5.6 and
5.7 will be adjusted with OWNER and made payable to OWNER as trustee for the insureds,
as their interests may appear, subject to the requirements of any applicable mortgage clause
and of paragraph 5.13. OWNER shall deposit in a separate account any money so received,
and shall distribute it in accordance with such agreement as the parties in interest may reach.
If no other special agreement is reached the damaged Work shall be repaired or replaced,
the moneys so received applied on account thereof and the Work and the cost thereof
covered by an appropriate Change Order or Written Amendment.
Receipt and Application of Insurance Proceeds
5.13. OWNER as trustee shall have power to adjust and settle any loss with the
insurers unless one of the parties in interest shall object in writing within fifteen days after the
occurrence of loss to OWNER's exercise of this power. If such objection be made, OWNER
as trustee shall make settlement with the insurers in accordance with such agreement as the
parties in interest may reach. If required in willing by any party in interest, OWNER as trustee
shall, upon the occurrence of an insured loss, give bond for the proper performance of such
duties.
Acceptance of Insurance:
5.14. If OWNER has any objection to the coverage afforded by or other provisions of
the insurance required to be purchased and maintained by CONTRACTOR in accordance
with paragraphs 5.3 and 5.4 on the basis of its not complying with the Contract Documents,
OWNER shall notify CONTRACTOR in writing thereof within ten days of the da!.~ otdelivery
of such ~ertificates to OWNER in accordance with paragraph 2.7. If CONTRACTOf3. has any
objection to the coverage afforded by or other provisions of the policies of insurance required
to be purchased and maintained by OWNER in accordance with paragraphs 5.6 and 5.7 on
the basis of their not complying with the Contract Documents, CONTRACTOR shall notify
OWNER in writing thereof within ten days of the date of delivery, of such certificates to CON-
TRACTOR in accordance with paragraph 2.7. OWNER and CONTRACTOR shall each
provide to the other such additional information in respect of insurance provided by each as
the other may reasonably request. Failure by OWNER or CONTRACTOR to give any such
notice of objection within the time provided shall constitute acceptance of such insurance
purchased by the other as complying with the Contract Documents.
Partial Utilization-Property Insurance:
, 5.15. If OWNER finds it necessary to occupy or use a portion or portions of the Work
prior to Substantial Completion of all the Work, such use or occupancy may be accomplished
GENERAL CONDITIONS
01001-16
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
in accordance with paragraph 14.10; provided that no such use or occupancy shall
commence before the insurers providing the property insurance have acknowledged notice
thereof and in writing effected the changes in coverage necessitated thereby. The insurers
providing the property insurance shall consent by endorsement on the policy or policies, but
the property insurance shall not be canceled or lapse on account of any such partial use or
occupancy.
-4 -
Indemnification
5.16.1. CONTRACTOR shall indemnify and hold harmless COUNTY and its
employees and agents from and against all liabilities, claims, suits, demands, damages,
losses, and expenses, including attorneys' fees, arising out of or resulting from the
performance of its Work, provided that any such liability, claim, suit, demand, damage, loss,
or expense (a) is attributable to bodily injury, sickness, disease or death, or injury to or
destruction of tangible property, including the loss of use resulting therefrom and (b) is
caused in whole or in part by an act or omission of CONTRACTOR, any Subcontractor,
anyone directly or indirectly employed by and of them, or anyone for whose acts any of them
may be liable, whether or not it is caused in whole or in part by the negligence or other fault
of a party indemnified hereunder.
5.16.2. In any and all claims against COUNTY or any of its agents or employees by
any employee of CONTRACTOR, any SUBCONTRACTOR, anyone directly or indirectly
employed by any of them, or anyone for whose acts any of them may be liable, the
indemnification obligation under the previous paragraph shall not be limited in any way as to
the amount or type of damages, compensation or benefits payable by or for CONTRACTOR
or any SUBCONTRACTOR under workmen's compensation acts, disability benefit acts, or
other employee benefit acts.
5.16.3. CONTRACTOR shall indemnify and hold harmless COUNTY and anyone
directly or indirectly employed by it from and against all claims, suits, demands, damages,
,losses expenses (including attorney's fees) arising out of any infringement or patent or
copyrights held by others and shall defend all such claims in connection with any alleged
infringement of such rights.
ARTICLE 6--CONTRACTOR'S RESPONSIBILITIES
6.1. CONTRACTOR shall supervise and direct the Work competently and efficiently,
devoting such attention thereto and applying such skills and expertise as may be necessary
to perform the Work in accordance with the Contract Documents. CONTRACTOR shall be
solely responsible for the means, methods, techniques, sequences and procedures of
construction, but CONTRACTOR shall not be responsible for the negligence of others in the
design or specification of a specific means, method, technique, sequence or procedure of
,construction which is shown or indicated in and expressly required by the Contract
Documents. CONTRACTOR shall be responsible to see that the finished Work complies
accurately with the Contract Documents.
GENERAL CONDITIONS
01001-17
6.2. CONTRACTOR shall keep on the Work at all times during its progress a
competent resident superintendent, who shall not be replaced without whiten notice to
OWNER and PROFESSIONAL except under extraordinary circumstances. The
superintendent will be CONTRACTOR's representative at the site and shall have authority to
. act on behalf of CONTRACTOR. All communications to the superintendent shall be as
binding as if given to CONTRACTOR.
Labor. Materials and Equipment:
6.3. CONTRACTOR shall provide competent, suitably qualified personnel to survey
and layout the Work and perform construction as required by the Contract Documents.
CONTRACTOR shall at all times maintain good discipline and order at the site. Except in
connection with the safety or protection of persons or the Work or property at the site or
adjacent thereto, and except as otherwise indicated in the Contract Documents, all Work at
the site shall be performed during regular v/orking hours, and CONTRACTOR will not permit
evening work or the performance of Work on Saturday, Sunday or any legal holiday without
OWNER's written consent given after prior written notice to PROFESSIONAL.
6.4. Unless otherwise specified in the General Requirements, CONTRACTOR shall
furnish and assume full responsibility for all materials, equipment, labor, transportation,
construction equipment and machinery" tools, appliances, fuel, power, light, heat, telephone,
water, sanitary facilities, temporary facilities and all other facilities and incidentals whether
temporary or permanent necessary for the execution, testing, initial operation, and
completion of the Work as required by the Contract Documents.
6.5. All materials and equipment shall be of good quality and new, except as
otherwise provided m the Contract Documents. If required by PROFESSIONAL,
CONTRACTOR shall furnish satisfactory, evidence including reports of required tests) as to
the kind and quality of materials and equipment. All materials and equipment shaU,,,be
appliedJns.talled, connected, erected, used, cleaned and conditioned in accordanCe with the
instructions of the applicable Supplier except as otherwise provided in the Contract
Documents; but no provision of any such instructions will be effective to assign to
PROFESSIONAL, or any of PROFESSIONAL's consultants, agents or employees, any duty
or authority to supervise or direct the furnishing or performance of the Work or any duty or
authority to undertake responsibility contrary to the provisions of paragraph 9.14 or 9.15.
Adjusting Progress Schedule:
6.6. CONTRACTOR shall submit to PROFESSIONAL for acceptance to the extent
indicated in paragraph 2.9) adjustments in the progress schedule to reflect the impact
thereon of new developments; these will conform generally to the progress schedule then in
effect and additionally will comply with any provisions of the General Requirements
applicable thereto.
GENERAL CONDITIONS
01001-18
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I,
I
I
Substitutes or "Or-Equal" Items:
6.7.1. Whenever materials or equipment are specified or described in the Contract
Documents by using the name of a proprietary item or the name of a particular Supplier the
naming of the item is intended to establish the type, function and quality required. Unless the '
mime is followed by words indicating that no substitution is permitted, materials or equipment
of other Suppliers may be accepted by PROFESSIONAL if sufficient information is submitted
by CONTRACTOR to allow PROFESSIONAL to determine that the material or equipment
proposed is equivalent or equal to that named. The procedure for review by
PROFESSIONAL will include the following as supplemented in the General Requirements.
Requests for review of substitute items of material and equipment will not be accepted by
PROFESSIONAL from anyone other than CONTRACTOR. If CONTRACTOR wishes to
furnish or use a substitute item of material or equipment, CONTRACTOR shall make written
application to PROFESSIONAL for acceptance thereof, certifying that the proposed
substitute will perform adequately the functions and achieve the results called for by the
general design, be similar and of equal substance to that specified and be suited to the same
use as that specified. The application will state that the evaluation and acceptance of the
proposed substitute will not prejudice CONTRACTOR's achievement of Substantial Comple-
tion on time, whether or not acceptance of the substitute for use in the Work will require a
change in any of the Contract Documents (or in the provisions of any other direct contract
with OWNER for work on the Project) to adapt the design to the proposed substitute and
whether or not incorporation or use of the substitute in connection with the Work is subject to
payment of any license fee or royalty. All variations of the proposed substitute from that
specified will be identified in the application and available maintenance, repair and
replacement service will be indicated. The application will also contain an itemized estimate
of all costs that will result directly or indirectly from acceptance of such substitute, including
costs of redesign and claims of other contractors affected by the resulting change, all of
which shall be considered by PROFESSIONAL In evaluating the proposed substitute,
PROFESSIONAL may require CONTRACTOR to furnish at CONTRACTOR's expense
additional data about the proposed substitute.
-
6J.2-T If a specific means, method, technique, sequence or procedure of cO[lstruction
is indicated in or required by the Contract Documents, CONTRACTOR may furnish or utilize
a substitute means, method, sequence, technique or procedure of construction acceptable to
PROFESSIONAL, if CONTRACTOR submits sufficient information to allow PROFESSIONAL
to determine that the substitute proposed is equivalent to that indicated or required by the
Contract Documents. The procedure for review by PROFESSIONAL will be similar to that
provided in paragraph 6.7.1 as applied by PROFESSIONAL and as may be supplemented in
the General Requirements.
6.7.3. PROFESSIONAL will be allowed a reasonable time within which to evaluate
each proposed substitute. PROFESSIONAL will be the sole judge of acceptability and no
substitute will be ordered, installed or utilized without PROFESSIONAL's prior written
acceptance which will be evidenced by either a Change Order or an approved Shop
Drawing. OWNER may require CONTRACTOR to furnish at CONTRACTOR's expense a
GENERAL CONDITIONS
01001-19
special performance guarantee or other surety with respect to any substitute.
PROFESSIONAL will record time required by PROFESSIONAL and PROFESSIONAL's
consultants in evaluating substitutions proposed by CONTRACTOR and in making changes
in the Contract Documents occasioned thereby. Whether or not PROFESSIONAL accepts a
proposed substitute. CONTRACTOR shall reimburse OWNER for the charges of
PROFESSIONAL and PRO'FESSIONAL's consultants for evaluating each proposed
substitute.
Concerning Subcontractors. Suppliers and Others:
6.8.1. CONTRACTOR shall not employ any Subcontractor, Supplier or other person
or organization (including those acceptable to OWNER and PROFESSIONAL as indicated in
paragraph 6.8.2). whether initially or as a substitute, against whom OWNER or
PROFESSIONAL may have reasonable objection. CONTRACTOR shall not be required to
employ any Subcontractor, Supplier or other person or organization to furnish or perform any
of the Work against whom CONTRACTOR has reasonable objection.
6.8.2. If the Supplementary Conditions require the identity of certain Subcontractors,
Suppliers or other persons or organizations including those who are to furnish the principal
items of materials and equipment} to be submitted to OWNER in advance of the specified
date prior to the Effective Date of the Agreement for acceptance by OWNER and
PROFESSIONAL and if CONTRACTOR has submitted a list thereof in accordance with the
Supplementary Conditions, OWNER's or PROFESSIONAL's acceptance (either in writing or
by falling to make written objection thereto by the date indicated for acceptance or objection
In the bidding documents or the Contract Documents} of any such Subcontractor, Supplier or
other person or organization so identified may be revoked on the basis of reasonable
objection after due Investigation, in which case CONTRACTOR shall submit an acceptable
substitute, the Contract Price will be increased by the difference ,n the cost occasioned by
such substitution and an appropriate Change Order will be issued or Written Amendment
signed. No acceptance by OWNER or PROFESSIONAL of any such Subcontractor", Supplier
or other Eerl)on or organization shall constitute a waiver of any right of OWNE~or PROF-
ESSIONAL to reject defective Work. -
6.9. CONTRACTOR shall be fully responsible to OWNER and PROFESSIONAL for
all acts and omissions of the Subcontractors, Suppliers and other persons and organizations
performing or furnishing any of the Work under a direct or indirect contract with
CONTRACTOR just as CONTRACTOR is responsible for CONTRACTOR's own acts and
omissions. Nothing in the Contract Documents shall create any contractual relationship
between OWNER or PROFESSIONAL and any such Subcontractor, Supplier or other person
or organization, nor shall it create any obligation on the part, of OWNER or PROFESSIONAL
to payor to see to the payment of any moneys due any such Subcontractor, Supplier or
other person or organization except as may otherwise be required by Laws ~.rld Regulations.
GENERAL CONDITIONS
01001-20
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
6.10. The divisions and sections of the Specifications and the identifications of any
Drawings shall not control CONTRACTOR in dividing the Work among Subcontractors or
Suppliers or delineating the Work to be performed by any specific trade.
6.11. All Work performed for CONTRACTOR by a Subcontractor will be pursuant to
an appropriate agreement between CONTRACTOR and the Subcontractor which specifically
binds the'Subcontractor to the applicable terms and conditions of the Contract Documents
for the benefit of OWNER and PROFESSIONAL and contains waiver provisions as required
by paragraph 5.11. CONTRACTOR shall pay each Subcontractor a just share of any
insurance moneys received by CONTRACTOR on account of losses under policies issued
pursuant to paragraphs 5.6 and 5.7.
Patent Fees and Royalties:
6.12. CONTRACTOR shall pay all license fees and royalties and assume all
costs incident to the llse in the performance of thr; Work or the incorporation in the Work of
any invention, design, process, product or device which is the subject of patent rights or
copyrights held by others. CONTRACTOR Shall indemnify and hold harmless OWNER and
PROFESSIONAL and anyone directly or indirectly employed by either of them from and
against all claims, damages, losses and expenses including attorneys' fees and court and
arbitration costs arising out of any infringement of patent rights or copyrights incident to the
use in the performance or the Work or resulting from the incorporation in the Work of any
invention, design, process, product or device not specified in the Contract Documents, and
shall defend all such claims in connection with any alleged infringement of such rights.
Permits:
6.13. CONTRACTOR shall obtain and pay for all construction permits, licenses,
governmental charges and inspection fees, and all public utility charges which are applicable
and necessary for the execution of the Work. All permit costs shall be included in the base
bid. Permits, if any that are provided and paid for by OWNER are listed in the Supplementary
ConditioRs. Any delays associated with the permitting process will be considered for time
extensions only and no damages or additional compensation for delay will be allowed.
Laws and Regulations:
6.14.1. CONTRACTOR shall give all notices and comply with all Laws and
Regulations applicable to furnishing and performance of the Work. Except where otherwise
expressly required by applicable Laws and Regulations, neither OWNER nor
PROFESSIONAL shall be responsible for monitoring CONTRACTOR's compliance with any
Laws or Regulations.
6.14.2. If CONTRACTOR observes that any of the Contract Documents are
. contradictory to such laws, rules, and regulations, it will notify the Project Manager promptly
in writing. Any necessary changes shall then be adjusted by an appropriate Change Order.
GENERAL CONDITIONS
01001-21
If CONTRACTOR performs any Work that it knows or should have known to be contrary to
such laws, ordinances, rules, and regulations and without such notice to the Project
Manager, it shall bear all related costs.
Taxes:
- -
6.15. CONTRACTOR shall pay all sales, consumer, use and other similar taxes
required to be paid by CONTRACTOR in accordance with the Laws and Regulations of the
place of the Project which are applicable during the performance of the Work.
Use of Premises:
6.16. CONTRACTOR shall confine construction equipment, the storage of materials
and equipment and the operations of workers to the Project site and land and areas identified
in and permitted by the Contract Documents and other land and areas permitted by Laws
and Regulations, rights-of-way, permits and easements. SONTRACTOR shall not
unreasonably encumber the premises with construction equipment or other materials or
equipment. Any loss or damage to CONTRACTOR's or any Subcontractor's equipment is
solely at the risk of CONTRACTOR. CONTRACTOR shall assume full responsibility for any
damage to any such land or area, or to the owner or occupant thereof or of any land or areas
contiguous thereto, resulting from the performance of the Work. Should any claim be made
against OWNER or PROFESSIONAL by any such owner or occupant because of the
performance of the Work, CONTRACTOR shall promptly attempt to settle with such other
party by agreement or otherwise resolve the claim by arbitration or at law. CONTRACTOR
shall to the fullest extent permitted by Laws and Regulations, indemnify and hold OWNER
harmless from and against all claims, damages, losses and expenses (including, but not
limited to, fees of PROFESSIONALs, architects, attorneys and other professionals and court
and arbitration costs) arising directly, indirectly or consequentially out of any action, legal or
equitable, brought by any such other party against OWNER to the extent based on a claim
arising out of CONTRACTOR's performance of the Work. _
6.17. During the progress of the Work, CONTRACTOR shall keep the premises free
from accumulations of waste materials, rubbish and other debris or contaminates resulting
from the Work. At the completion of the Work CONTRACTOR shall remove all waste
materials, rubbish and debris from and about the premises as well as all tools, appliances,
construction equipment and machinery, and surplus materials, and shall leave the site clean
and ready for occupancy by OWNER. CONTRACTOR shall restore to original condition all
property not designated for alteration by the Contract Documents.
6.18. CONTRACTOR shall not load nor permit any part of any structure to be loaded
in any manner that will endanger the structure, nor shall CONTRACTOR subject any pan of
the Work or adjacent property to stresses or pressures that will endanger them.
GENERAL CONDITIONS
01001-22
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Record Documents:
6.19. Contractor shall keep at the site and in good order one record copy of the
Contract Documents and all Drawings and Specifications. These documents shall be
annotated on a continuing basis to show all changes made during the construction process.
These shall be available to PROFESSIONAL and the Project Manager and shall be
submitted with the Application for Final Payment.
Safety and Protection:
6.20. CONTRACTOR shall be responsible for initiating, maintaining and supervising
all safety precautions and programs in connection with the Work. CONTRACTOR shall
assume all risk of loss for stored equipment or materials, irrespective of whether
CONTRACTOR has transferred the title otthe stored equipment or materials to OWNER.
CONTRACTOR shall take all necessary precautions for the safety of, and shall provide the
necessary protection to prp,vent damage, injury or joss to:
6.20.1. all employees on the Work and other persons and organizations who may be
affected thereby:
6.20.2. all the Work and materials and equipment to be incorporated therein, whether
in storage on or off the site; and
6.20.3. other property at the site or adjacent thereto, including trees, shrubs, lawns,
walks, pavements, roadways, structures, utilities and Underground Facilities not designated
for removal, relocation or replacement in the course of construction.
CONTRACTOR shall comply with all applicable Laws and Regulations of any public body
having jurisdiction for the safety of persons or property or to protect them from damage,
injury or loss; and shall erect and maintain all necessary safeguards for such safety and
protection. CONTRACTOR shall notify OWNERs of adjacent property and of Underground
Facilities-and utility OWNERs when prosecution of the Work may affect them, and shall
cooperate with them in the protection, removal, relocation and replacement of their property,
All damage, injury or loss to any property referred to in paragraph 6.20.2 or 6.20.3 caused,
directly or indirectly, in whole or in part, by CONTRACTOR, any Subcontractor, Supplier or
any other person or organization directly or indirectly employed by any of them to perform or
furnish any the Work or anyone for whose acts any of them may be liable, shall be remedied
by CONTRACTOR (except damage or loss attributable to the fault of Drawings or
Specifications or to the acts or omissions of OWNER or PROFESSIONAL or anyone
employed by either of them or anyone for whose acts either of them may be liable, and not
attributable, directly or indirectly, in whole or in part, to the fault or negligence of CON-
TRACTOR). CONTRACTOR's duties and responsibilities for the safety and protection of the
Work shall continue until such time as all the Work is completed and PROFESSIONAL has
issued a notice to OWNER and CONTRACTOR in accordance, with paragraph 14.13 that the
GENERAL CONDITIONS
01001-23
Work is acceptable (except as otherwise expressly provided In connection with Substantial
Completion).
6.21. CONTRACTOR shall designate a responsible member of its organization whose
duty shall be the prevention of accidents at the site. This person shall be CONTRACTOR's
superintendent unless otherwise designated in writing by CONTRACTOR to the Project
Manager.
Emergencies:
6.22. In emergencies affecting the safety or protection of persons or the Work or
property at the site or adjacent thereto, CONTRACTOR, without special instruction or
authorization from PROFESSIONAL or OWNER, is obligated to act to prevent threatened
damage, injury or loss. CONTRACTOR shall give PROFESSIONAL prompt written notice if
CONTRACTOR believes that any significant changes in the Work or variations from the
Contract Documents have been caused thereby. If PROFESSIONAL determines that a
change In the Contract Documents is required because of the action taken in response to an
emergency, a Work Directive Change or Change Order be issued to document the
consequences of the changes or variations.
6.22.1. CONTRACTOR shall immediately notify PROFESSIONAL of all events
involving personal injuries to any person on the Site, whether or not such person was
engaged in the construction of the Project, and shall file a written report on such person(s)
and any other event resulting in property damage of any amount within five (5) days of the
occurrence.
6.22.2. If PROFESSIONAL determines that a change in the Contract Documents is
required because of the action taken by CONTRACTOR in response to such an emergency,
a Change Order will be issued to document the consequences of such action.
Sb,op_Drawings and Samples:
6.23. After checking and verifying all field measurements, CONTRACTOR shall
promptly submit to PROFESSIONAL for approval, in accordance with the accepted schedule
of submittals, all submittals and samples required by the Contract Documents. All submittals
and samples shall have been checked by and stamped with the approval of CONTRACTOR
and identified as PROFESSIONAL may require. The data shown on or with the submittals
will be complete with respect to dimensions, design criteria, materials and any other
information necessary to enable PROFESSIONAL to review the submittal as required. At the
time of each submission, CONTRACTOR shall give notice to PROFESSIONAL of all
deviations that the submittal or sample may have from the requirements of the Contract
Documents.
6.24. PROFESSIONAL shall review and approve submittals and samples.
Professional's review and approval shall be only for conformance with the design concept of
GENERAL CONDITIONS
01001-24
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
the Project and compliance with the information given in the Contract Documents. The
approval of a separate item as such will not indicate approval of the assembly in which the
item functions. CONTRACTOR will make any COrrections required by PROFESSIONAL and
resubmit the required number of corrected copies until approved. CONTRACTOR's stamp of
approval on any submittal or sample shall constitute its representation to PROFESSIONAL
and County that CONTRACTOR has determined and verified all quantities, ~imensions, field
construction- criteria, materials, catalog numbers, and similar data, and that each submittal or
sample has been reviewed or coordinated with the requirements of the Work and the
Contract Documents.
6.24.1. No Work requiring a submittal or sample submission shall commence until the
submission has been approved by PROFESSIONAL. A copy of each approved submittal
and each approved sample shall be kept in good order by CONTRACTOR at the site and
shall be available to PROFESSIONAL and County staff. Any delays associated with the
submittal process will be considered for time extensions only, and no damages or additional
compensation for delay will be allowed.
6.25.1. Before submission of each Shop Drawing or sample CONTRACTOR shall
have determined and verified all quantities, dimensions, specified performance criteria,
installation requirements, materials, catalog numbers and similar data with respect thereto
and reviewed or coordinated each Shop Drawing or sample with other Shop Drawings and
samples and with the requirements of the Work and the Contract Documents.
6.25.2. At the time of each submission, CONTRACTOR shall give PROFESSIONAL
specific written notice of each variation that the Shop Drawings or samples may have from
the requirements of the Contract Documents, and, in addition, shall cause a specific notation
to be made on each Shop Drawing submitted to PROFESSIONAL for review and approval of
each such variation.
6.26. PROFESSIONAL will review and approve with reasonable promptness Shop
Drawings and samples, but PROFESSIONAL's review and approval will be only for
conformance with the design concept of the Project and for compliance with the information
given in the Contract Documents and shall not extend to means, methods, techniques,
sequences or procedures of construction (except where a specific means, method,
technique, sequence or procedure of construction is indicated in or required by the Contract
Documents) or to safety precautions or programs incident thereto. The review and approval
of a separate item as such will not indicate approval of the assembly in which the item
functions.
6.27. No Work requiring a submittal or sample submission shall commence until the
submission has been approved by PROFESSIONAL. A copy of each approved submittal
and each approved sample shall be kept in good order by CONTRACTOR at the site and
shall be available to PROFESSIONAL and Project Managery staff. Any delays associated
with the submittal process will be considered for time extensions only, and no damages or
additional compensation for delay will be allowed.
GENERAL CONDITIONS
01001-25
6.28. PROFESSIONAL's approval of submittals or samples shall not relieve
CONTRACTOR from responsibility for any variation from the requirements of the Contract
Documents unless CONTRACTOR has in writing called PROFESSIONAL's attention to each
such variation at the time of submission and the Project Manager has given written approval
to the specific deviation; any such approval by PROFESSIONAL shall not relieve
CONTRACTOR from responsibility for errors or omissions in the submittals.
6.29. Where a shop drawing or sample is required by the Contract Documents or the
schedule of shop drawings and sample submissions accepted by PROFESSIONAL as
required, any related work performed prior to Professional's review and approval of the
pertinent submittal will be at the sole expense and responsibility of Contractor.
Continuing the Work:
6.~0. CONTRACTOR shall carry on the Work and adhere to the progress schedule
during all disputes or disagreements with OWNER. No Work shall be delayed or postponed
pending resolution of any disputes or disagreements, except as permitted by paragraph 15.6
or as CONTRACTOR and OWNER may otherwise agree in wilting.
Cleaning Up:
6.31. CONTRACTOR shall maintain the site free from accumulations of waste
materials, rubbish, and other debris or contaminates resulting from the work on a daily basis
or as required. At the completion of the work, CONTRACTOR shall remove all waste
materials, rubbish, and debris from the site as well as all tools, construction equipment and
machinery, and surplus materials and will leave the Site clean and ready for occupancy by
OWNER. All disposal shall be in accordance with applicable laws and regulations. In
addition to any other rights available to OWNER under the Contract Documents,
CONTRACTOR's failure to maintain the site may result in withholding of any a~~ur,1ts due
CONTR6Cl0R. CONTRACTOR will restore to original condition those portions of the site
not designated for alteration by the Contract Documents.
Indemnification:
6.32. To the fullest extent permitted by Laws and Regulations CONTRACTOR shall
indemnify and hold harmless OWNER and PROFESSIONAL and their consultants, agents
and employees from and against all claims, damages, losses and expenses, direct, indirect
or consequential (including but not limited to fees and charges of PROFESSIONALs,
architects, attorneys and other PROFESSIONALs and court and arbitration costs) arising out
of or resulting from the performance of the Work, provided that any such claim, damage, loss
. or expense (a)is attributable to bodily injury, sickness, disease or death, or to injury to or
destruction of tangible property -(other than the Work itself) including the loss of use resulting
therefrom and (b) is caused in whole or in pan by any negligent act or omission of
CONTRACTOR, any Subcontractor, any person or organization directly or indirectly
GENERAL CONDITIONS
01001-26
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I.
I
I
employed by any of them to perform or furnish any of the Work or anyone for whose acts any
of them may be liable, regardless of whether or not it is caused in part by a party indemnified
hereunder or arises by or is imposed by Law and Regulations regardless of the negligence of
any such party.
6.33. In any and all claims against OWNER or PROFESSIONAL or any of their
consultaflts,-agents or employees by any employee of CONTRACTOR, any Subcontractor,
any person or organization directly or indirectly employed by any of them to perform or
furnish any of the Work or anyone for whose acts any of them may be liable, the
indemnification obligation under paragraph 6.32 shall not be limited in any way by any
limitation on the amount or type of damages, compensation or benefits payable by or for
CONTRACTOR or any such Subcontractor or other person or organization under workers' or
workmen's compensation acts. disability benefit acts or other employee benefit acts.
6.34. The obligations of CONTRACTOR under paragraph 6.32 shall not extend to the
liability of PROFESSIONAL, PROFESSIONAL's consultants, agents or employees arising out
of the preparation or approval of maps, drawings, opinions, reports, surveys, Change Orders,
designs or specifications.
ARTICLE 7 ---OTHER WORK
Related Work at Site:
7.1. OWNER may perform other work related to the Project at the site by OWNER's
own forces, have other work performed by ailed OWNERs or let other direct contracts
therefor which shall contain General Conditions similar to these. If the fact that such other
work is to be performed was not noted in the Contract Documents, written notice thereof will
be given to CONTRACTOR prior to starting any such other work: and, if CONTRACTOR
believes that such performance will involve additional expense to CONTRACTOR or requires
additional time and the parties are unable to agree as to the extent thereof. CONTRACTOR
may make a claim therefor as provided in Articles 11 and 12.
- -
7.1.2. CONTRACTOR shall afford each utility owner and other contractor who is a
party to such a direct contract for OWNER, if OWNER is performing the additional work with
OWNER's employees)proper and safe access to the site and a reasonable opportunity for
the introduction and storage of materials and equipment and the execution of such work, and
shall properly connect and coordinate the Work with theirs. CONTRACTOR shall do all
cutting, fitting and patching of the Work that may be required to make its several pans come
together properly and integrate with such other work. CONTRACTOR shall not endanger any
work of others by cutting, excavating or otherwise altering their work and will only cut or alter
their work with the written consent of PROFESSIONAL and the others whose work will be
affected. The duties and responsibilities of CONTRACTOR under this paragraph are for the
benefit of such utility owners and qther contractors to the extent that there are comparable
provisions for the benefit or' CONTRACTOR in said direct contracts between OWNER and
such utility owners and other contractors.
GENERAL CONDITIONS
01001-27
7.2. If any part of CONTRACTOR's Work depends for proper execution or results
upon the work of any such other contractor or utility owner (or OWNER), CONTRACTOR
shall inspect and promptly report to PROFESSIONAL in writing any delays, defects or
deficiencies in such work that render it unavailable or unsuitable for such proper execution
and results. CONTRACTOR's failure so to report will constitute an acceptance of the other
work as fit and proper for integration with CONTRACTOR's Work except for latent or non-
apparent defects and deficiencies in the other work.
Coordination:
7.4. If OWNER contracts with others for the performance of other work on the Project
at the site, the person or organization who will have authority and responsibility for
coordination of the activities among the various prime contractors will be identified in the
Supplementary Conditions, and the specific matters to be covered by such authority and
resp~nsibility will be itemized, and the extent of such authority and responsibilities will be
provided, in the Supplementary Conditions. Unless otherwise provided in the Supplementary
Conditions, neither OWNER nor PROFESSIONAL shall have any authority or responsibility
in respect of such coordination.
ARTICLE 8---0WNER'S RESPONSIBILITIES
8.1. Except as otherwise provided in these General Conditions, COUNTY shall issue
all communications to CONTRACTOR through the Project Manager or PROFESSIONAL.
8.2. In case of termination of the employment of PROFESSIONAL, OWNER shall
appoint a PROFESSIONAL against whom CONTRACTOR makes no reasonable objection,
whose status under the Contract Documents shall be that of the former PROFESSIONAL.
Any dispute in connection with such appointment shall be subject to arbitration.
8..;.3. _ OWNER shall furnish the data required of OWNER under the Contract
Documents promptly and shall make payments to CONTRACTOR promptly after they are
due as provided in paragraphs 14.4 and 14.13.
8.4. OWNER's duties in respect of providing lands and easements and providing
Engineering surveys to establish reference points are set forth in paragraphs 4.1 and 4.4.
Paragraph 4.2 refers to OWNER's identifying and making available to CONTRACTOR copies
of reports of explorations and tests of subsurface conditions at the site and in existing
structures which have been utilized by PROFESSIONAL in preparing the Drawings and
Specifications.
8.5. OWNER's responsibilities in respect of purchasing and maintaining liability and
property insurance are setforth in paragraphs 5.5 through 5.8.
8.6. OWNER is obligated to execute Change Orders as indicated in paragraph 10.3.
GENERAL CONDITIONS
01001-28
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
8.7. OWNER's responsibility in respect of certain inspections, tests and approvals is
set forth in paragraph 13.4.
8.8. In connection with OWNER's right to stop Work or suspend Work, see
paragraphs 13.10 and 15.1. Paragraph 15.2 deals with OWNER's right to terminate services
of CONTRACTOR under certain circumstances.
ARTICLE 9--PROFESSIONAL'S STATUS DURING CONSTRUCTION
Owner's Representative:
9.1. PROFESSIONAL will be OWNER's representative during the construction period.
The duties and responsibilities and the limitations of authority of PROFESSIONAL as
OWNER's representative during construction are set forth in the Contract Documents and
shall not be extended without written consen~ of OWNER and PROFESSIONAL.
Visits to Site:
9.2. PROFESSIONAL will make visits to the site at intervals appropriate to the various
stages of construction to observe the premises and quality of the executed Work and to
determine, in general, if the Work is proceeding in accordance with the Contract Documents.
PROFESSIONAL will not be required to make exhaustive or continuous on-site inspections
to check the quality or quantity of the Work. PROFESSIONAL's efforts will be directed toward
providing for OWNER a greater degree of confidence that the completed Work will conform
to the Contract Documents. On the basis of such visits and on-site observations as an
experienced and qualified design PROFESSIONAL. PROFESSIONAL will keep OWNER
informed of the progress of the Work and will endeavor to guard OWNER against defects
and deficiencies in the Work.
Project Representation:
- -
9.3. If OWNER and PROFESSIONAL agree, PROFESSIONAL will furnish a Resident
Project Representative to assist PROFESSIONAL in observing the performance of the Work.
The duties, responsibilities and limitations of authority of any such Resident Project
Representative and assistants will be as provided in the Supplementary Conditions. If
OWNER designates another agent to represent OWNER at the site who is not
PROFESSIONAL's agent or employee, the duties, responsibilities and limitations of authority
of such other person will be as provided in the Supplementary Conditions.
Clarifications and Interpretations:
9.4. PROFESSIONAL shall issue such written clarifications or interpretations of the
Contract Documents (in the form of Drawings or otherwise) as may be determined
necessary, or as reasonably requested by CONTRACTOR, which shall be consistent with or
GENERAL CONDITIONS
01001-29
reasonably inferable from the overall intent of the Contract Documents. If CONTRACTOR
believes that a written clarification and interpretation entitles it to an increase in the Contract
Price, and/or Contract Time, CONTRACTOR may make a claim as provided for in Articles 11
or 12.
Authorized Variations in Work:
9.5. PROFESSIONAL may authorize minor variations in the Work from the
requirements of the Contract Documents which do not involve an adjustment in the Contract
Price or the Contract Time and are consistent with the overall intent of the Contract
Documents. These may be accomplished by a Field Order and will be binding on OWNER,
and also on CONTRACTOR who shall perform the Work involved promptly. If
CONTRACTOR believes that a Field Order justifies an increase in the Contract Price or an
extension of the Contract Time and the parties are unable to agree as to the amount or
extent thereof. CONTRACTOR may make a claim therefor as provided in Article 11 or 12.
Rejecting Defective Work:
9.6. PROFESSIONAL will have authority to disapprove or reject Work which
PROFESSIONAL believes to be defective, and will also have authority to require special
inspection or testing of the Work as provided in paragraph 13.9, whether or not the Work is
fabricated, installed or completed.
Shop Drawings, Change Orders and Payments:
9.7. In connection with PROFESSIONAL's responsibility for Shop Drawings and
samples, see paragraphs 6.23 through 6.29 inclusive.
9.8. In connection with PROFESSIONAL's responsibilities as to Change Orders, see
Articles 10, 11 and 12.
- ~
9.9. In connection with PROFESSIONAL's responsibilities in respect of Applications
for Payment, etc., see Article 14.
Determinations for Unit Prices:
9.10. PROFESSIONAL will determine the actual quantities and classifications of Unit
Price Work performed by CONTRACTOR. PROFESSIONAL will review with CONTRACTOR
PROFESSIONAL's preliminary determinations on such matters before rendering a whiten
decision thereon (by recommendation of an Application for Payment or otherwise). PROF-
ESSIONAL's written decisions thereon will be final and binding upon OWNER and
CONTRACTOR, unless, within ten days after the date of any such decision, either OWNER
or CONTRACTOR delivers to the other party to the Agreement and to PROFESSIONAL
whiten notice of intention to appeal from such a decision.
GENERAL CONDITIONS
01001-30
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Decisions on Disputes:
9.11. PROFESSIONAL will be the initial interpreter of the requirements of the
Contract Documents and judge of the acceptability of the Work thereunder. Claims, disputes
and other matters relating to the acceptability of the Work or the interpretation of the
requirements of the Contract Documents pertaining to the performance and furnishing of the
Work ana claims under Articles 11 and 12 in respect of changes m the Contract Price or
Contract Time will be referred initially to PROFESSIONAL in writing with a request for a
formal decision in accordance with this paragraph, which PROFESSIONAL will render in
writing within a reasonable time, Written notice of each such claim, dispute and other matter
will be delivered by the claimant to PROFESSIONAL and the other party to the Agreement
promptly (but in no event later than thirty days after the occurrence of the event giving rise
thereto, and written supporting data will be submitted to PROFESSIONAL and the other
party within sixty days after such occurrence unless PROFESSIONAL allows an additional
period of time to ascertain more accurate data in support of the claim.
9.12. When functioning as interpreter and judge under paragraphs 9.10 and 9.11,
PROFESSIONAL will not show partiality to OWNER or CONTRACTOR and will not be liable
in connection with any interpretation or decision rendered in good faith in such capacity. The
rendering of a decision by PROFESSIONAL pursuant to paragraphs 9.10 and 9.11 with
respect to any such claim, dispute or other matter (except any which have been waived by
the making or acceptance of final payment as provided in paragraph 14.16) will be a
condition precedent to any exercise by OWNER or CONTRACTOR of such rights or
remedies as either may otherwise have under the Contract Documents or by Laws or
Regulations in respect of any such claim, dispute or other matter.
Limitations on PROFESSIONAL's Responsibilities:
9.13. Neither PROFESSIONAL's authority to act under this Article or elsewhere in the
Contract Documents, nor any decision made in good faith to exercise such authority shall
give rise to any duty or responsibility of PROFESSIONAL to CONTRACTOR, any
Subcontractor, any of their agents or employees.
9.14. PROFESSIONAL shall not be responsible for the construction means, methods,
techniques, sequences, or procedures or the safety precautions and programs used.
PROFESSIONAL shall not be responsible for CONTRACTOR's failure to perform the Work in
accordance with the Contract Documents.
9.15. PROFESSIONAL shall not be responsible for the acts or omissions of
CONTRACTOR, any Subcontractors, any agents or employees, or any other persons
performing any of the Work.
GENERAL CONDITIONS
01001-31
ARTICLE 10--CHANGES IN THE WORK
10.1. Without invalidating the Contract, OWNER may at any time or from time to time
order additions, deletions, or revisions in the Work. The Project Manager shall provide
CONTRACTOR with a proposal request, identifying the Work to be added, deleted or
revised. .upon receipt, CONTRACTOR shall promptly submit a written proposal for the
changed work prepared in accordance with Articles 11 and 12. If the proposal request calls
only for the deletion of Work, the Project Manager may order the partial suspension of any
Work related to the proposed deletion, in which case CONTRACTOR must cease
performance as directed; CONTRACTOR shall not be entitled to claim lost profits on deleted
work. All changed Work shall be executed under the applicable conditions of the Contract
Documents.
10.2. Additional Work performed by CONTRACTOR without authorization of a Change
Order will not entitle CONTRACTOR to an increase in the Contract Price or an extension of
the Contract Time, except in {he case of an emergency as provided in Article 7. The effect of
this paragraph shall remain paramount and shall prevail irrespective of any conflicting
provisions contained in these Contract Documents.
10.3. Upon agreement as to changes in the Work to be performed, Work performed in
an emergency as provided in Article 6, and any other claim of CONTRACTOR for a change
in the Contract Time or the Contract Price, PROFESSIONAL will prepare a written Change
Order to be signed by PROFESSIONAL and CONTRACTOR and submitted to OWNER for
approval.
10.4. In the absence of an agreement as provided in 11.1.3, OWNER may, at its sole
discretion issue a Work Directive Change to CONTRACTOR. Pricing of the Work Directive
Change will be in accordance with Section 12.1.3. The Work Directive Change will specify a
price, and if applicable a time extension, determined to be reasonable by OWNER. If
CONTRACTOR fails to sign such Work Directive Change, CONTRACTOR may sUQmit a
claim in gccordance with Articles 11 and 12, but CONTRACTOR shall nevertheless be
obligated to fully perform the work as directed by the Construction Change Directive.
10.5. CONTRACTOR shall proceed diligently with performance of the Work as
directed by OWNER, regardless of pending claim actions, unless otherwise agreed to in
writing.
10.6. If notice of any change affecting the general scope of the Work or the provisions
of the Contract Documents (including, but not limited to, Contract Price or Contract Time) is
required by the provisions of any Bond to be given to a surety, the giving of any such notice
will be CONTRACTOR's responsibility, and the amount of each applicable Bond will be
adjusted accordingly.
GENERAL CONDITIONS
01001-32
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
ARTICLE 11-CHANGE OF CONTRACT PRICE
11.1. The Contract Price constitutes the total compensation (subject to written
authorized adjustments) payable to CONTRACTOR for performing the Work. All duties,
responsibilities and obligations assigned to or undertaken by CONTRACTOR shall be at
CONTRACTOR's expense without change in the Contract Price.
... -
11.2. The Contract Price may only be changed by a Change Order or by a Written
Amendment. Any claim for an increase or decrease in the Contract Price shall be based on
written notice delivered by the party making the claim to the other party and to
PROFESSIONAL promptly (but in no event later than thirty days) after the occurrence of the
event giving rise to the claim and stating the general nature of the claim. Notice of the
amount of the claim with supporting data shall be delivered within sixty days after such
occurrence (unless PROFESSIONAL allows an additional period of time to ascertain more
accurate data in support of the claim and shall be accompanied by claimant's written
statement that the amount claimed covers all known amounts (direct, indirect and con-
sequential) to which the claimant is entitled as a result of the occurrence of said event. All
claims for adjustment in the Contract Price shall be determined by PROFESSIONAL in
accordance with paragraph 9.11 if OWNER and CONTRACTOR cannot otherwise agree on
the amount involved. No claim for an adjustment in the Contract Price will be valid if not
submitted in accordance with this paragraph 11.2.
11.3. The value of any Work covered by a Change Order or of any claim for an
adjustment in the Contract Price will be determined by the following procedures:
11.3.1. Designated Unit Price (Field Measure) CONTRACTOR and OWNER recognize
and acknowledge that the quantities shown for those items designated in the Bid Proposal as
unit price items are approximations prepared by OWNER for bid purposes and that the actual
compensation payable to CONTRACTOR for the utilization of such items is based upon the
application of unit prices to the actual quantities of items involved as measured in the field
and required to complete the Work as originally defined in the Contract Documents:
-- -
11.3.2. When it is determined by OWNER that an addition, deletion, or revision to the
Work as defined in these Contract Documents is required and affects the quantities required
for items designed in the Bid Proposal as unit price items, CONTRACTOR and OWNER
agree that the compensation payable to CONTRACTOR for such unit price items shall be
adjusted accordingly by a Change Order based upon the application of the appropriate unit
prices shown in the Bid Proposal to the quantity of the unit price item required to complete
the Work as defined in the Contract Documents.
11.3.3. Other Unit Prices. For items not designated in the bid proposal as unit prices,
OWNER and CONTRACTOR may establish unit prices as agreed on by Change Order.
11.3.4. Lump Sum. When it is determined by OWNER that an addition, deletion or
revision to the Work is required which results in a change in Work designated in the Bid
GENERAL CONDITIONS
01001-33
Proposal as a lump sum item, the amount of increase or decrease in the lump sum price
shall be established by mutual agreement of the parties.
11.3.5. If the pricing methods specified in 11.3 are inapplicable, or if the parties are
. unable to agree on a price for the changed work, a reasonable price for the same shall be
established-by OWNER in accordance with 11.4 and 11.5. OWNER shall then process a
unilateral Change Order, specifying the said reasonable price, in accordance with 11.4
through 11.6. CONTRACTOR shall perform the Work as directed in the Change Order.
11.3.6. Failure on the part of CONTRACTOR to construct any item to plan or
authorized dimensions within the specification tolerances shall result in: reconstruction to
acceptable tolerances at no additional costs to OWNER; acceptance at no pay; or
acceptance at reduced final pay quantity or reduced unit price, all at the discretion of
OWNER. Determinations of aggregate monetary change for items identified as lump sum
quantities shall be made by OWNER based upon an analysis of the scope of
CONTRACTOR's failure to construct to plan or authorized dimen~ions.
Cost of the Work:
11.4. The term Cost of the Work means the sum of all costs necessarily incurred and
paid by CONTRACTOR in the proper performance of the Work. Except as otherwise may be
agreed to in writing by OWNER, such costs shall be in amounts no higher than those
prevailing in the locality of the Project, shall include only the following items and shall not
include any of the costs itemized in paragraph 11.5:
11.4.1. Payroll costs for employees in the direct employ of CONTRACTOR in the
performance of the Work under schedules of job classifications agreed upon by OWNER and
CONTRACTOR. Payroll costs for employees not employed full time on the Work shall be
apportioned on the basis of their time spent on the Work. Payroll costs shall include, but not
be limited to, salaries and wages plus the cost of fringe benefits which shall include social
security_contributions, unemployment, excise and payroll taxes, workers' or workmen's
compensation, health and retirement benefits, bonuses, sick leave, vacation.and holiday pay
applicable thereto. Such employees shall include superintendents and foremen at the site.
The expenses of performing Work after regular working hours, on Saturday, Sunday or legal
holidays, shall be included in the above to the extent authorized by OWNER.
11.4.2. Cost of all materials and equipment furnished and incorporated in the Work,
including costs of transportation and storage thereof, and Suppliers' field services required in
connection therewith. All cash discounts shall accrue to CONTRACTOR unless OWNER
deposits funds with CONTRACTOR with which to make payments, in which case the cash
discounts shall accrue to OWNER. Trade discounts, rebates and refunds and all returns from
sale of surplus materials and equipment shall accrue to OWNER, and CONTRACTOR shall
make provisions so that they may be obtained.
GENERAL CONDITIONS
01001-34
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
11.4.3. Payments made by CONTRACTOR to the Subcontractors for Work performed
by Subcontractors. If required by OWNER. CONTRACTOR shall obtain competitive bids from
Subcontractors acceptable to CONTRACTOR and shall deliver such bids to OWNER who
then determine, with the advice of PROFESSIONAL, which bids will be accepted. If a
subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work
Plus a Fee, the Subcontractor's Cost of the Work shall be determined in the same manner as
CONTRACTOR's Cost of the Work. All subcontracts shall be subject to the other provisions
of the Contract Documents insofar as applicable.
11.4.4. Costs of special consultants (including but not limited to PROFESSIONAL's
architects, testing laboratories, surveyors, attorneys and accountants) employed for services
specifically related to the Work.
11.4.5. Supplemental costs including the following:
11.4.5.1. The proportion of necessary translJortation, travel and subsistence
expenses of CONTRACTOR's employees incurred in discharge of duties con-
nected with the Work.
11.4.5.2. Cost, including transportation and maintenance,of all materials, supplies,
equipment, machinery, appliances, office and temporary facilities at the site and hand tools
not owned by the workers, which are consumed in the performance of the Work, and cost
less market value of such items used but not consumed which remain the property of
CONTRACTOR.
11.4.5.3. Rentals of all construction equipment and machinery and the pans thereof
whether rented from CONTRACTOR or others in accordance with rental agreements
approved by OWNER with the advice of PROFESSIONAL, and the costs of transportation,
loading, unloading, installation, dismantling and removal thereof-all in accordance with
terms of said rental agreements. The rental of any such equipment, machinery or parts shall
cease when the use thereof is no longer necessary for the Work.
11.4.5.4. Sales, consumer, use or similar taxes related to the Work, and for which
CONTRACTOR is liable, imposed by Laws and Regulations.
11.4.5.5. Deposits lost for causes other than negligence of CONTRACTOR, any
Subcontractor or anyone directly or indirectly employed by any of them or for whose acts any
of them may be liable, and royalty payments and fees for permits and licenses.
11.4.5.6. Losses and damages (and related expenses), not compensated by
insurance or otherwise, to the Work or otherwise sustained by CONTRACTOR in connection
with the performance and furnishing of the Work (except losses and damages within the
deductible amounts of property insurance established by OWNER in accordance with
, paragraph 5.6). provided they have resulted from causes other than the negligence of
CONTRACTOR, any Subcontractor, or anyone directly or indirectly employed by any of them
GENERAL CONDITIONS
01001-35
GENERAL CONDITIONS
01001-36
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
or for whose acts any of them may be liable. Such losses shall include settlements made with
the written consent and approval of OWNER. No such losses, damages and expenses shall
be included in the Cost of the Work for the purpose of determining CONTRACTOR's Fee. If,
however, any such loss or damage requires reconstruction and CONTRACTOR is placed in
charge thereof, CONTRACTOR shall be paid for services a fee proportionate to that stated in
paragraph 11.6.2.
11.4.5.7. The cost of utilities, fuel and sanitary facilities at the site.
11.4.5.8. Minor expenses such as telegrams, long distance telephone calls,
telephone service at the site, expressage and similar petty cash items in connection the
Work.
11.4.5.9. Cost of premiums for additional Bonds and insurance required because of
changes in the Work and premiums of property insurance coverage within the limits of the
deductible amounts established by OWNER in accordance with paragraph 5.6.
11.5. The term Cost of the Work shall not include any of the following:
11.5.1. Payroll costs and other compensation of CONTRACTOR's officers,
executives, principals (of partnership and sole proprietorships), general managers, PROF-
ESSIONALs, architects, estimators, attorneys, auditors, accountants, purchasing and
contracting agents, expeditors, timekeepers, clerks and other personnel employed by
CONTRACTOR whether at the site or in CONTRACTOR's principal or a branch office for
general administration of the Work and not specifically included in the agreed upon schedule
of job classifications referred to in paragraph 11.4.1 or specifically covered by paragraph
11.4.4--all of which are to be considered administrative costs covered by CONTRACTOR's
Fee.
11.5.2. Expenses of CONTRACTOR's principal area branch offices other than
CONTRACTOR's office at the site.
11.5.3. Any part of CONTRACTOR's capital expenses, including interest on
CONTRACTOR'S capital used for the Change Order Work and charges against
CONTRACTOR for delinquent payments.
11.5.4. Cost of premiums for all Bonds and for all insurance whether or not
CONTRACTOR is required by the Contract Documents to purchase and maintain the same
(except for the cost of premiums covered by subparagraph 11.4.5.9 above).
11.5.5. Costs due to the negligence of CONTRACTOR, any Subcontractor, or anyone
directly or indirectly, employed by any of them or for whose acts any of them may be liable,
including but not limited to, the correction of defective Work, disposal of materials or
equipment wrongly supplied and making good any damage to property.
I
I
I
I '
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
11.5.6. Other overhead or general expense costs of any kind and the costs of any
item not specifically and expressly included in paragraph 11.4.
CONTRACTOR's Fee:
11.6. CONTRACTOR's Fee allowed to CONTRACTOR for overhead and profit shall
be determined as follows:
11.6.1. a mutually acceptable fixed fee; or if none can be agreed upon.
11.6.2. a fee based on the following percentages of the various portions or' the Cost
of the Work:
11.6.2.1. for costs incurred under paragraphs 11.4.1 and 11.4.2, CONTRACTOR's
Fee shall be fifteen percent:
11.6.2.2. for costs incurred under paragraph 11.4.3, CONTRACTOR's Fee shall five
percent; and if a subcontract is on the basis of Cost of the Work Plus a Fee, the maximum
allowable to CONTRACTOR on account of overhead and profit of all Subcontractors shall be
fifteen percent:
11.6.2.3. no fee shall be payable on the basis of costs itemized under paragraphs
11.4.4, 11.4.5 and 11.3:
11.6.2.4. the amount of credit to be allowed by CONTRACTOR to OWNER for
any such change which results in a net decrease in cost will be the amount of the actual net
decrease plus a deduction in CONTRACTOR's Fee by an amount equal to ten percent of the
net decrease: and
11.6.2.5. when both additions and credits are involved in anyone change, the
adjustment in CONTRACTOR's Fee shall be computed on the basis of the net change in
accordance with paragraphs 11.6.2.1 through 11.6.2.4, inclusive.
11.7. For all changes, CONTRACTOR shall submit an itemized cost breakdown,
together with supporting data in such detail and form as prescribed by the Project Manager.
When a credit is due, the amount of credit to be allowed by CONTRACTOR to OWNER for
any such change which results in a net decrease in cost will be the amount of the actual net
decrease in direct cost as determined by the Project Manager, plus the applicable reduction
in overhead and profit. When both additions and credits are involved in any change, the
combined overhead and profit shall be calculated on the basis of the next change, whether
an increase or decrease. In any event, the minimum detail shall be an itemization of all man-
hours required by discipline/trade with the unit cost per man-hour and total labor price, labor
burden, equipment hours and rate for each piece of equipment, material by units of measure
and price per unit, other costs specifically itemized, plus the overhead and profit markup.
GENERAL CONDITIONS
01001-37
GENERAL CONDITIONS
01001-38
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Cash Allowances:
11.8. It is understood that CONTRACTOR has included in the Contract Price all
allowances so named in the Contract Documents and shall cause the Work so covered to be
done by such Subcontractors or Suppliers and for such sums within the limit of the
allowances as may be acceptable to PROFESSIONAL, CONTRACTOR agrees that:
11.8.1. The allowances include the cost to CONTRACTOR (less any applicable trade
discounts) of materials and equipment required by the allowances to be delivered at the site,
and all applicable taxes; and
11.8.2. CONTRACTOR's costs for unloading and handling on the site, labor,
installation costs, overhead, profit and other expenses contemplated for the allowances have
been included in the Contract Price and not in the allowances. No demand for additional
payment on account of any thereof will be valid.
Prior to final payment, an appropriate Change Order will be issued as recommended by
PROFESSIONAL to reflect actual amounts due CONTRACTOR on account of Work covered
by allowances, and the Contract Price shall be correspondingly adjusted.
Unit Price Work:
11.9.1. Where the Contract Documents provide that all or part of the Work is to be
Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work
an amount equal to the sum of the established unit prices for each separately identified item
of Unit Price Work times the estimated quantity of each item as indicated in the Agreement.
The estimated quantities of items of Unit Price Work are not guaranteed and are solely for
the purpose of comparison of Bids and determining an initial Contract Price. Determinations
of the actual quantities and classifications of Unit Price Work performed by CONTRACTOR
will be m9de by PROFESSIONAL in accordance with Paragraph 9.10. .
11.9.2. Each unit price will be deemed to include an amount considered by
CONTRACTOR to be adequate to cover CONTRACTOR's overhead and profit for each sep-
arately identified item.
11.9.3. Where the quantity of any item of Unit Price Work performed by
CONTRACTOR differs materially and significantly from the estimated quantity of such item
indicated in the Agreement and there is no corresponding adjustment with respect to any
other item of Work and if CONTRACTOR believes that CONTRACTOR has incurred
additional expense as a result thereof, CONTRACTOR may make a claim for an increase in
the Contract Price in accordance with Article 11 if the parties are unable to agree as to the
amount of any such increase.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
ARTICLE 12--CHANGE OF CONTRACT TIME
12.1. The Contract Time may only be changed by a Change Order. Any request for
an extension in the Contract Time shall be made in writing and delivered to PROFESSIONAL
and Project Manager within seven (7) calendar days of the occurrence first happening and
resulting in the claim. Written supporting data will be submitted to PROFESSIONAL and
Project Manager within fifteen (15) calendar days after such occurrence unless the Project
Manager allows additional time. All claims submitted by CONTRACTOR for adjustments to
the Contract Time must set forth in detail the reasons for and causes of the delay and clearly
indicate why the subject delay was beyond CONTRACTOR's control or fault.
12.2. If CONTRACTOR is delayed at any time in the performance, progress,
commencement, or completion of the Work by any act or neglect of OWNER or
PROFESSIONAL, or by an employee of either, or by any separate CONTRACTOR employed
by OWNER, or by changes ordered in the Work, or by labor disputes, fire, unavoidable
casualties, utility conflicts which could not have been identified or foreseen by
CONTRACTOR using reasonable diligence, or any causes beyond CONTRACTOR's control
or fault, then the Contract Time shall be extended by Change Order for such reasonable
time as OWNER may determine. CONTRACTOR shall be entitled to an extension of time for
such causes only for the number of days of delay which OWNER may determine to be due
solely to such causes and only to the extent such occurrences actually delay the completion
of the Work and then only if CONTRACTOR shall have strictly complied with all the
requirements of the Contract Documents. Provided, however, notwithstanding anything in
the Contract Documents to the contrary, no interruption, interference, inefficiency,
suspension or delay in the performance, progress, commencement or completion of the
Work for any cause whatsoever, including those for which OWNER or PROFESSIONAL may
be responsible in whole or in part, shall relieve CONTRACTOR of its duty to perform or give
rise to any right to damages or additional compensation from OWNER. CONTRACTOR's
sole and exclusive remedy against OWNER for interruption, interference, inefficiency,
suspension or delay of any aspect of the Work shall be the right to seek an extension to the
Contract Time in accordance with the procedures set forth herein.
ARTICLE 13--WARRANTY AND GUARANTEE; TESTS AND INSPECTIONS:
CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK
Warranty and Guarantee:
13.1. CONTRACTOR warrants and guarantees to OWNER that all materials and
equipment will be new unless otherwise specified and that all work will be of good quality,
performed in a workmanlike manner, free from faults or defects, and in accordance with the
requirements of the Contract Documents and any inspections, tests, or approvals referred to
in this Article. All unsatisfactory Work, all faulty Work and all Work not conforming to the
requirements of the Contract Documents or such inspections, tests, approvals, or all
applicable building, construction and safety requirements shall be considered defective.
GENERAL CONDITIONS
01001-39
Notice of all defects shall be given to CONTRACTOR by PROFESSIONAL. All defective
work, whether or not in place, may be rejected, corrected, or accepted as provided in this
Article.
Access to Work:
13.2. For the duration of the Work, PROFESSIONAL and its representatives, other
designated representatives of OWNER, and authorized representatives of any regulatory
agency shall at all times be given access to the Work. CONTRACTOR shall provide proper
facilities for such access and observation of the Work and also for any inspection or testing
by others.
Tests and Inspections:
13.3. If the Contract Documents, laws, ordinances, rules, regulations or orders of any
public autho:-ity having jurisdiction require any Work to specifically be inspected, tested, or
approved by someone other than CONTRACTOR, CONTRACTOR shall give
PROFESSIONAL timely notice of readiness therefore.
13.4. The testing firm(s) (if assigned by OWNER to this Work) and all such
inspections, tests, or approvals provided for by OWNER shall be identified in writing by
PROFESSIONAL to CONTRACTOR. All other inspections, tests or approvals shall be at
CONTRACTOR's expense including additional expenses for inspection and tests required as
a result of delays by CONTRACTOR or hours worked in excess of 40 hours per week. For
all required inspections, tests, and approvals on any Work prepared, performed, or
assembled away from the site, CONTRACTOR will furnish PROFESSIONAL with the
required Certificates of Inspection, testing, or approval. All such tests will be in accordance
with the methods prescribed by the American Society for Testing and Materials or such other
applicable organizations as may be required by law or the Contract Documents. Materials or
Work in place that fail to pass acceptability tests shall be retested at the direction of
PROFE?SIONAL and at CONTRACTOR's expense.
13.5. All inspections, tests or approvals other than those required by-Laws or
Regulations of any public body having jurisdiction shall be performed by organizations
acceptable to OWNER and CONTRACTOR (or by PROFESSIONAL if so specified).
13.6. If any Work (including the work of others) that is to be inspected, tested or
approved is covered without written concurrence of PROFESSIONAL, it must, if requested by
PROFESSIONAL, be uncovered for observation. Such uncovering shall be at
CONTRACTOR's expense unless CONTRACTOR has given PROFESSIONAL timely notice
of CONTRACTOR's intention to cover the same and PROFESSIONAL has not acted with
reasonable promptness in response to such notice.
13.7. Neither observations by PROFESSIONAL or Project Manager nor inspections,
tests, or approvals by persons other than CONTRACTOR shall relieve CONTRACTOR of its
GENERAL CONDITIONS
01001-40
01
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
obligations to perform the Work in accordance with the requirements of the Contract
Documents.
Uncovering Work:
13.8. If any Work required to be inspected, tested or approved is covered prior
thereto without the prior written approval of PROFESSIONAL, or if any Work is covered
contrary to the request of PROFESSIONAL, the Work shall, if requested by
PROFESSIONAL, be uncovered for observation, inspection, testing or approval and replaced
at CONTRACTOR's expense.
13.9. If PROFESSIONAL considers it necessary or advisable that covered Work be
observed by PROFESSIONAL or inspected or tested by others. CONTRACTOR, at
PROFESSIONAL's request, shall uncover, expose or otherwise make available for
observation, inspection or testing as PROFESSIONAL may require, that portion of the Work
in question, furnishing all necessary labor, material and equipment. If it is found that such
Work is defective, CONTRACTOR shall bear all direct, and consequential costs of such
uncovering, exposure, observation, inspection and testing and of satisfactory reconstruction,
(including but not limited to fees and charges of PROFESSIONALs, architects, attorneys and
other PROFESSIONALs), and OWNER shall be entitled to an appropriate decrease in the
Contract Price, and, if the parties are unable to agree as to the amount thereof, may make a
claim therefor as provided in Article 11. If, however, such Work is not found to be defective,
CONTRACTOR shall be allowed an increase in the Contract Price, or an extension of the
Contract Time, or both, directly attributable to such uncovering, exposure, observation,
inspection, testing and reconstruction; and, if the parties are unable to agree as to the
amount or extent thereof, CONTRACTOR may make a claim therefor as provided in Articles
11 and 12.
Owner May Stop the Work:
13.10. When Work is defective or when CONTRACTOR fails to supply sufficient
skilled workmen or suitable materials or equipment, or make prompt payments to
Subcontractors for labor, materials, or equipment, or if CONTRACTOR violates any
provisions of these Contract Documents, OWNER may order CONTRACTOR to stop the
Work until the cause for such order has been eliminated. However, this right of OWNER to
stop the Work shall not give rise to any duty on the part of OWNER to exercise this right for
the benefit of CONTRACTOR or any other party. CONTRACTOR shall have no right to claim
an increase in the Contract Price or Contract Time or other damages for a stop work order
under this paragraph.
Correction or Removal of Defective Work:
13.11. When directed by PROFESSIONAL, CONTRACTOR shall promptly, without
cost to OWNER and as specified by PROFESSIONAL, either correct the defective Work
whether fabricated, installed, or completed, or remove it from the site and replace it with non
GENERAL CONDITIONS
01001-41
defective Work. If CONTRACTOR does not correct such defective Work or remove and
replace such defective Work within a reasonable time, all as specified in a written notice from
PROFESSIONAL, OWNER may have the deficiency corrected. All direct and indirect costs
of such correction shall be paid by CONTRACTOR or deducted from payment to
CONTRACTOR. CONTRACTOR will also bear the expense of correcting or removing and
replacing all Work of others destroyed or damaged by the correction, removal, or
replacement of the defective Work.
One Year Correction Period:
13.12. If, after approval of final payment and prior to the expiration of one year after
the date of substantial completion or such longer period of time as may be prescribed by law
or by the terms of any applicable special guarantee required by the Contract Documents, any
Work or materials are found to be defective, incomplete, or otherwise not in accordance with
the Contract Documents, CONTRACTOR shall promptly, without cost to OWNER and in
accordance with OWNER's written instructions, either correct such defective Work, or if it has
been rejected by OWNER, remove it from the Site and replace it with non-defective Work. If
CONTRACTOR does not promptly comply with the terms of such instructions, OWNER may
have the defective Work corrected, removed, or replaced. All direct, indirect and
consequential costs of such removal and replacement (including but not limited to fees and
charges of engineers, architects, attorneys and other PROFESSIONALs) will be paid by
CONTRACTOR.
Acceptance of Defective Work:
13.13. If, instead of requiring correction or removal and replacement of defective
Work, OWNER (and, prior to PROFESSIONAL's recommendation of final payment, also
PROFESSIONAL) prefers to accept it, OWNER may do so. CONTRACTOR shall bear all
direct, indirect and consequential costs attributable to OWNER's evaluation of and
determination to accept such defective Work (such costs to be approved by
PROFE~SIONAL as to reasonableness and to include but not be limited to fees and charges
of PROFESSIONALs, architects, attorneys and other PROFESSIONALs). If any such
acceptance occurs prior to PROFESSIONAL's recommendation of final payment, a Change
Order will be issued incorporating the necessary revisions in the Contract Documents with
respect to the Work and OWNER shall be entitled to an appropriate decrease in the Contract
Price, and, if the panics are unable to agree as to the amount thereof. OWNER may make a
claim therefor as provided in Article 11. If the acceptance occurs after such recommendation,
an appropriate amount will be paid by CONTRACTOR to OWNER.
OWN ER May Correct Defective Work:
13.14. If CONTRACTOR fails within a reasonable time after written notice of
PROFESSIONAL to proceed to correct and to correct defective Work or to remove and
replace rejected Work as required by PROFESSIONAL in accordance with paragraph 13.11,
GENERAL CONDITIONS
01001-42
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
or if CONTRACTOR fails to perform the Work in accordance with the Contract Documents, or
if CONTRACTOR falls to comply with any other provision of the Contract Documents,
OWNER may, after seven days' written notice to CONTRACTOR, correct and remedy any
such deficiency. In exercising the rights and remedies under this paragraph OWNER shall
proceed expeditiously, to the extent necessary to complete corrective and remedial action,
OWNER may exclude CONTRACTOR from all or part of the site, take possession of all or
part of the Work, and suspend CONTRACTOR's services related thereto, take possession of
CONTRACTOR's tools, appliances, construction equipment and machinery at the site and
incorporate in the Work all materials and equipment stored at the site or for which OWNER
has paid CONTRACTOR but which are stored elsewhere. CONTRACTOR shall allow
OWNER, OWNER's representatives, agents and employees such access to the site as may
be necessary to enable OWNER to exercise the rights and remedies under this paragraph.
All direct, indirect and consequential costs of OWNER in exercising such rights and remedies
will be charged against CONTRACTOR in an amount approved as to reasonableness by
PROFESSIONAL, and a Change Order will be issued incorporating the necessary revisions
in the Contract Documents with respect to the Work, and OWNER shall be entitled to an
appropriate decrease in the Contract Price, and, if the parties are unable to agree as to the
amount thereof, OWNER may make a claim therefor as provided in Article 11. Such direct,
indirect and consequential costs will include but not be limited to fees and charges of
PROFESSIONALs, architects, attorneys and other PROFESSIONALs, all court costs and all
costs of repair and replacement of work of others destroyed or damaged by correction,
removal or replacement of CONTRACTOR's defective Work. CONTRACTOR shall not be
allowed an extension of the Contract Time because of any delay in performance of the Work
attributable to the exercise by OWNER of OWNER's rights and remedies hereunder.
Neglected Work by CONTRACTOR
13.15. If CONTRACTOR neglects to execute the Work in accordance with the
Contract Documents, including any requirements of the progress schedule,
PROFESSIONAL may direct CONTRACTOR to submit a recovery plan and take specific
corrective actions including, but not limited to, employing additional workmen, and/or
equipmeAt, and working extended hours and additional days, all at no cost to OWNER in
order to put the Work back on schedule. If CONTRACTOR fails to correct the deficiency or
take appropriate corrective action, OWNER may terminate the contract or CONTRACTOR's
right to proceed with that portion of Work and have the Work done by others. The cost of
completion under such procedure shall be charged against CONTRACTOR. A Change
Order shall be issued incorporating the necessary revisions in the Contract Documents,
including an appropriate reduction in the Contract Price. If the payments due
CONTRACTOR are not sufficient to cover such amount, CONTRACTOR shall pay the
difference to OWNER.
13.16. Should CONTRACTOR work overtime, weekends or holidays to regain the
schedule, all costs to OWNER of associated inspection, construction management and
resident PROFES,SIONALs shall be identified to CONTRACTOR and the Contract Price
reduced by a like amount via Change Order.
GENERAL CONDITIONS
01001-43
ARTICLE 14-PA YMENTS TO CONTRACTOR AND COMPLETION
Schedule of Values:
14.1. The schedule of values established as provided in 2.9 will serve as the basis
for progress payments and will be incorporated into a form of application for Payment
acceptable to Project Manager. Progress payments on account of Unit Price Work will be
based on the number of units completed.
Application for Progress Payment:
14.2. At least twenty (20) calendar days before the date established for each
progress payment (but not more often than once a month), CONTRACTOR shall submit to
PROFESSIONAL for review an application for Payment filled out and signed by
CONTRACTOR covering the work completed as of the date of the application and
accompanied by such support:ng documentation as is required by the Contract Documents.
If payment is requested on the basis of materials and equipment not incorporated in the
Work but delivered and suitably stored at the site or at another location agreed to in writing,
the Application for Payment shall also be accompanied by a bill of sale, invoice or other
documentation warranting that OWNER has received the materials and equipment free and
clear of all liens and evidence that the materials and equipment are covered by appropriate
property insurance and other arrangements to protect OWNER's interest therein, all of which
will be satisfactory to OWNER. Payment is subject to a ten percent (10%) retainage that will
be held until the final payment or acceptance by OWNER. The amount of retainage with
respect to progress payments will be as stipulated in the Agreement.
CONTRACTOR's Warranty of Title:
14.3. CONTRACTOR warrants and guarantees that title to all Work, materials and
equipment covered by any Application for Payment, whether incorporated in the Project or
not, will pass to OWNER no later than the time of payment free and clear of all Liens.
Review of Applications for Progress Payment:
14.4. PROFESSIONAL will, within ten (10) calendar days after receipt of each
Application for Payment, either indicate in writing a recommendation of payment and present
the application to OWNER, or return the application to CONTRACTOR indicating in writing
PROFESSIONAL's reasons for refusing to recommend payment. In the latter case,
CONTRACTOR may make the necessary corrections and resubmit the application. OWNER
shall, within thirty-one calendar days of presentation to him of the application for payment
with PROFESSIONAL's recommendation of the amount for payment, pay CONTRACTOR
amount recommended.
14.5. PROFESSIONAL's recommendation of any payment requested in an
Application for Payment will constitute a representation by PROFESSIONAL to OWNER,
GENERAL CONDITIONS
01001-44
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
based on PROFESSIONAL's on-site observations of the Work in progress as an experienced
and qualified design PROFESSIONAL and on PROFESSIONAL's review of the Application
for Payment and the accompanying data and schedules that the Work has progressed to the
point indicated; that, to the best of PROFESSIONAL's knowledge, information and belief, the
quality' of the Work is in accordance with the Contract Documents subject to an evaluation of
the Work as a functioning whole prior to or upon Substantial Completion, to the results of any
subsequent tests called for -in the Contract Documents, to a final determination of quantities
and classifications for Unit Price Work under paragraph 9.10. and to any other qualifications
stated in the recommendation: and that CONTRACTOR is entitled to payment of the amount
recommended. However, by recommending any such payment PROFESSIONAL will not
thereby be deemed to have represented that exhaustive or continuous on-site inspections
have been made to check the quality or the quantity of the Work beyond the responsibilities
specifically assigned to PROFESSIONAL in the Contract Documents or that there may not
be other matters or issues between the parties that might entitle CONTRACTOR to be paid
additionally by OWNER or OWNER to withhold payment to CONTRACTOR.
14.6. PROFESSIONAL's recommendation of final payment will constitute an
additional representation by PROFESSIONAL to OWNER that the conditions precedent to
CONTRACTOR's being entitled to final payment as set forth in paragraph 14.13 have been
fulfilled.
14.7. PROFESSIONAL may refuse to recommend the whole or any part of any
payment if, in PROFESSIONAL's opinion, it would be incorrect to make such representations
to OWNER. PROFESSIONAL may also refuse to recommend any such payment, or,
because of subsequently discovered evidence or the results of subsequent inspections or
tests, nullify any such payment previously recommended, to such extent as may be
necessary in PROFESSIONAL's opinion to protect OWNER from loss because:
14.7.1. the Work is defective, or completed Work has been damaged requiring
correction or replacement.
14.7.2. the Contract Price has been reduced by Written Amendment or Change
Order.
14.7.3. OWNER has been required to correct defective Work or complete Work in
accordance with paragraph 13.14. or
14.7.4. of PROFESSIONAL's actual knowledge of the occurrence of any of the events
enumerated in paragraphs 15.2.1 through 15.2.9 inclusive.
OWNER may refuse to make payment of the full amount recommended by PROFESSIONAL
because claims have been made against OWNER on account of CONTRACTOR's per-
formance or furnishing of the Work or Liens have been filed in connection with the Work or
there are other items entitling OWNER to a set-off against the amount recommended, but
GENERAL CONDITIONS
01001-45
OWNER must give CONTRACTOR immediate written notice (with a copy to
PROFESSIONAL) stating the reasons for such action.
Substantial Completion:
I
14.8. When CONTRACTOR considers the entire Work ready for its intended use
CONTRACTOR shall notify OWNER and PROFESSIONAL in writing that the entire Work is
substantially complete (except for items specifically listed by CONTRACTOR as incomplete)
and request that PROFESSIONAL issue a certificate of Substantial Completion. Within a
reasonable time thereafter, OWNER, CON~RACTOR and PROFESSIONAL shall make an
inspection of the Work to determine the status of completion. If PROFESSIONAL does not
consider the Work substantially complete, PROFESSIONAL will notify CONTRACTOR in
writing giving the reasons therefor. If PROFESSIONAL considers the Work substantially
complete, PROFESSIONAL will prepare and deliver to OWNER a tentative certificate of
Substantial Completion which shall fix the date of Substantial Completion. There shall be
attached to the certificate a tentative list of items to be completed or corrected before final
payment. OWNER shall have seven days after receipt of the tentative certificate during which
to make written objection to PROFESSIONAL as to any provisions of the certificate or
attached list. If, after considering such objections. PROFESSIONAL concludes that the Work
is not substantially complete, PROFESSIONAL will within fourteen days after submission of
the tentative certificate to OWNER notify CONTRACTOR in writing. stating the reasons
therefor. If, after consideration of OWNER's objections, PROFESSIONAL considers the Work
substantially complete, PROFESSIONAL will within said fourteen days execute and deliver to
OWNER and CONTRACTOR a definitive certificate of Substantial Completion (with a revised
tentative list of items to be completed or corrected) reflecting such changes from the tentative
certificate as PROFESSIONAL believes justified after consideration of any objections from
OWNER. At the time of delivery of the tentative certificate of Substantial Completion PROF-
ESSIONAL will deliver to OWNER and CONTRACTOR a written recommendation as to
division of responsibilities pending final payment between OWNER and CONTRACTOR with
respect to security, operation, safety, maintenance, heat, utilities, insurance and,warranties.
Unless OWNER and CONTRACTOR agree otherwise in wilting and so inform
PROFESSIONAL prior to PROFESSIONAL's issuing the definitive certificate of Substantial
Completion, PROFESSIONAL's aforesaid recommendation will be binding on OWNER and
CONTRACTOR until final payment.
14.9. OWNER shall have the right to exclude CONTRACTOR from the Work after the
date of Substantial Completion, but OWN ER shall allow CONTRACTOR reasonable access
to complete or correct items on the tentative list.
Partial Utilization:
14.10. Use by OWNER at OWNER's option of any substantially completed part of the
Wprk which (i) has specifically been identified in the Contract Documents, or (ii) OWNER,
PROFESSIONAL, and CONTRACTOR agree constitutes a separately functioning and usable
part of the Work that can be used by OWNER for its intended purpose without significant
GENERAL CONDITIONS
01001-46
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
'I
I
I
I
I
I
I
I
I
I
interference with CONTRACTOR's performance of the remainder of the Work, may be
accomplished prior to Substantial Completion of all the Work subject to the following.
14.10.1. OWNER at any time may request CONTRACTOR in writing to permit
OWNER to use any such part of the Work which OWNER believes to be ready for its
intended use and substantially complete. If CONTRACTOR agrees, CONTRACTOR will
certify to OWNER and PROFESSIONAL that said part of the Work is substantially complete
and request PROFESSIONAL to issue a certificate of Substantial Completion for that part of
the Work. CONTRACTOR at any time may notify, OWNER and PROFESSIONAL in writing
that CONTRACTOR considers any such part of the Work ready for its intended use and
substantially complete and request PROFESSIONAL to issue a certificate of Substantial
Completion for that part of the Work. Within a reasonable time after either such request,
OWNER, CONTRACTOR and PROFESSIONAL shall make an inspection of that part of the
Work to determine its status of completion. If PROFESSIONAL does not consider that part of
the Work to be substantially complete, PROFESSIONAL will notify. OWNER and
CONTRACTOR in writing giving the masons therefor. If PROFESSIONAL considers that part
o(the Work to be substantially complete, the provisions of paragraphs 14.8 and 14.9 will
apply with respect to certification of Substantial Completion of that part of the Work and the
division of responsibility in respect thereof and access thereto.
14.10.2. OWNER may at any time request CONTRACTOR in writing to permit
OWNER to take over operation of any such part of the Work although it is not substantially
complete. A copy of such request will be sent to PROFESSIONAL and within a reasonable
time thereafter OWNER, CONTRACTOR and PROFESSIONAL shall make an inspection of
that part of the Work to determine its status of completion and will prepare a list of the items
remaining to be completed or corrected thereon before final payment. If CONTRACTOR
does not object in writing to OWNER and PROFESSIONAL that such part of the Work is not
ready for separate operation by OWNER, PROFESSIONAL will finalize the list of items to be
completed or corrected and will deliver such list to OWNER and CONTRACTOR together
with a written recommendation as to the division of responsibilities pending final payment
between OWNER and CONTRACTOR with respect to security, operation, safety,
maintenance, utilities, insurance, warranties and guarantees for that part of the Work which
will become binding upon OWNER and CONTRACTOR at the time when OWNER takes over
such operation (unless they shall have otherwise agreed in writing and so informed
PROFESSIONAL). During such operation and prior to Substantial Completion of such part of
the Work, OWNER shall allow CONTRACTOR reasonable access to complete or correct
items on said list and to complete other related Work.
14.10.3. No occupancy or separate operation of part of the Work will be accomplished
prior to compliance with the requirements of paragraph 5.15 in respect of property insurance.
14.10.4. OWNER, may at its discretion, reduce the amount of retainage subject to
Beneficial Occupancy.
GENERAL CONDITIONS
01001-47
Final Inspection:
14.11. Upon written notice from CONTRACTOR that the entire Work or an agreed
portion thereof is complete, PROFESSIONAL will make a final inspection with OWNER and
CONTRACTOR and will notify CONTRACTOR in writing of all particulars in which this
inspection reveals that the Work is incomplete or defective. CONTRACTOR shall
immediately take such measures as are necessary to remedy such deficiencies.
Final Application for Payment:
14.12. After CONTRACTOR has completed all such corrections to the satisfaction of
PROFESSIONAL and OWNER and delivered in accordance with the Contract Documents all
maintenance and operating instructions, schedules, guarantees, bonds, certificates or other
evidence of insurance required by 5.2, certificates of inspection, marked-up record
documents and other documents, CONTRACTOR may make application for final payment
following the procedure for progress payme:1ts. The final Application for Payment shall be
accompanied (except as previously delivered) by: (i) all documentation called for in the
Contract Documents, including but not limited to the evidence of insurance required, (ii)
consent of the surety, if any, to final payment, and (iii) complete and legally effective releases
or waivers (satisfactory to OWNER) of all liens arising out of or filed in connection with the
Work. In lieu of such releases or waivers of liens and as approved by County,
CONTRACTOR may furnish receipts or release in full and an affidavit of CONTRACTOR that
(i) the releases and receipts include all labor, services, material and equipment for which a
lien could be filed, and (ii) all payrolls, material and equipment bills and other indebtedness
connected with the Work for which OWNER or OWNER's property might in any way be
responsible have been paid or otherwise satisfied. If any Subcontractor or supplier fails to
furnish such a release or receipt in full, CONTRACTOR may furnish a bond or other collateral
satisfactory to OWNER to indemnify OWNER against any lien.
14.12.1. No application for final payment will be accepted by OWNER until approved
as-built qocuments by CONTRACTOR are accepted and approved by PROFESSIONAL.
14.12.2. Notwithstanding any other provision of these contract documents to the
contrary, OWNER and PROFESSIONAL are under no duty or obligation whatsoever to any
vendor, materials provider, Subcontractor, laborer or other party to ensure that payments due
and owing by CONTRACTOR to any of them are or will be made. Such parties shall rely
only on CONTRACTOR's surety bonds for remedy of nonpayment by him. CONTRACTOR
agrees to defend and resolve all claims made by Subcontractors, indemnifying OWNER and
PROFESSIONAL for all claims arising from or resulting from Subcontractor or supplier or
material men or laborer services in connection with this project.
14.12.3. General Indemnity: CONTRACTOR shall indemnify OWNER and
'PROFESSIONAL for any damages sustained including lost profits resulting from
CONTRACTOR's failure or refusal to perform the work required by these contract
documents.
GENERAL CONDITIONS
01001-48
'I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
.
.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Final Payment and Acceptance:
14.13. If, on the basis of PROFESSIONAL's observation of the Work during
construction and final inspection, and PROFESSIONAL's review of the final Application for
Payment and accompanying documentation as required by the Contract Documents,
PROFESSIONAL is satisfied that the Work has been completed and CONTRACTOR's other
obligations under the Contract Documents have been fulfilled, PROFESSIONAL will, within
ten (10) working days after receipt of the final Application for Payment, indicate in writing
PROFESSIONAL's recommendation of payment and present the Application to OWNER for
payment. At the same time PROFESSIONAL will also give written notice to OWNER and
CONTRACTOR that the Work is acceptable subject to the provisions of 14.6. Otherwise,
PROFESSIONAL will return the application to CONTRACTOR, indicating in writing the
reasons for refusing to recommend final payment, in which case CONTRACTOR shall make
the necessary corrections and resubmit the Application. After the presentation to OWNER of
the application and accompanying documentation, in appropriate form and substance and
with PROFESSIONAL's recommendation and notice of acceptability, the amount
recommended by PROFESSIONAL will become due and will be paid by OWNER to
CONTRACTOR.
14.14. If, through no fault of CONTRACTOR, final completion of the Work is
significantly delayed and if PROFESSIONAL so confirms, OWNER shall, upon receipt of
CONTRACTOR's final Application for Payment and recommendation of PROFESSIONAL,
and without terminating the Agreement, make payment of the balance due for that portion of .
the Work fully completed and accepted. If the remaining balance to be held by OWNER for
Work not fully completed or corrected is less than the retainage stipulated in the Contract,
and if bonds have been furnished as required in Article 5, the written consent of the surety to
the payment of the balance due for that portion of the Work fully completed and accepted
shall be submitted by CONTRACTOR to PROFESSIONAL with the application for such
payment. Such payment shall be made under the terms and conditions governing final
payment, except that it shall not constitute a waiver of claims.
CONTRACTOR's Continuing Obligation:
14.15. CONTRACTOR's obligation to perform and complete the Work in accordance
with the Contract Documents shall be absolute. Neither recommendation of any progress or
final payment by PROFESSIONAL, nor the issuance of a certificate of Substantial
Completion, nor any payment by OWNER to CONTRACTOR under the Contract Documents,
nor any use or occupancy of the Work or any part thereof by OWNER, nor any act of
acceptance by OWNER nor any failure to do so, nor any review and approval of a Shop
Drawing or sample submission, nor the issuance of a notice of acceptability by
PROFESSIONAL pursuant to paragraph 14.13. nor any correction of defective Work by
OWNER will constitute an acceptance of Work not in accordance with the Contract
Documents or a release of CONTRACTOR's obligation to perform the Work in accordance
with the Contract Documents (except as provided in paragraph 14.16).
GENERAL CONDITIONS
01001-49
Waiver of Claims:
14.16. The making and acceptance of final payment will constitute:
14.16.1. A waiver of all claims by OWNER against CONTRACTOR, except claims
arising from unsettled liens, from defective Work appearing after final inspection pursuant to
14.11 from failure to comply with the Contract Documents or the terms of any special
guarantees specified therein, or from CONTRACTOR's continuing obligations under the
Contract Documents; and
14.16.2. A waiver of all claims by CONTRACTOR against OWNER other than those
previously made in writing and still unsettled.
ARTICLE 15--SUSPENSION OF WORK AND TERMINATION
Owner May Suspend Work:
15.1. OWNER may, at any time and without cause, suspend the Work or any portion
thereof for a period of not more than ninety days by notice in wilting to CONTRACTOR and
PROFESSIONAL which will fix the date on which Work will be resumed. CONTRACTOR
shall resume the Work on the date so fixed. CONTRACTOR shall be allowed an adjustment
in the Contract Price or an extension of the Contract Time, or both, directly attributable to any
suspension if CONTRACTOR makes an approved claim therefor as provided in Articles 11
and 12.
Termination For Cause:
15.2. Upon the occurrence of anyone or more of the following events:
15.2. 1. if CONTRACTOR commences a voluntary case under any chapter of the
Bankruptcy Code (Title 11, United States Code), as now or hereafter in effect, or if
CONTRACTOR takes any equivalent or similar action by filing a petition or otherwise under
any other federal or state law in effect at such time relating to the bankruptcy,or insolvency;
15.2.2. if a petition is filed against CONTRACTOR under any chapter of the
Bankruptcy Code as now or hereafter in effect at the time of filing, or if a petition is filed
seeking any such equivalent or similar relief against CONTRACTOR under any other federal
or state law in effect at the time relating to bankruptcy or insolvency;
15.2.3. if CONTRACTOR makes a general assignment for the benefit of creditors;
15.2.4. if a trustee, receiver, custodian or agent of CONTRACTOR is appointed under
applicable law or under contract, whose appointment or authority to take charge of property
of CONTRACTOR is for the purpose of enforcing a Lien against such property or for the
GENERAL CONDITIONS
01001-50
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
purpose of general administration of such property for the benefit of CONTRACTOR's
creditors;
15.2.5. jf CONTRACTOR admits in writing an inability to pay its debts generally, as
they become due;
15.2.6. if CONTRACTOR fails to perform the Work in accordance with the Contract
Documents (including, but not limited to, failure to supply sufficient skilled workers or
suitable materials or equipment or failure to adhere to the progress schedule established
under paragraph 2.9 as revised from time to time);
15.2.7. if CONTRACTOR disregards Laws or Regulations of any public body having
jurisdiction;
15.2.8. if CONTRACTOR disregards the authority of PROFESSIONAL; or
15.2.9. if CONTRACTOR otherwise violates in any substantial way any provisions of
the Contract Documents,
OWNER may, after giving CONTRACTOR (and the surety, if there be one) seven days'
written notice and to the extent permitted by Laws and Regulations, terminate the services of
CONTRACTOR, exclude CONTRACTOR from the site and take possession of the Work and
of all CONTRACTOR's tools, appliances, construction equipment and machinery at the site
and use the same to the full extent they could be used by CONTRACTOR (without liability to
CONTRACTOR for trespass or conversion), incorporate in the Work all materials and
equipment stored at the site or for which OWNER has paid CONTRACTOR but which are
stored elsewhere, and finish the Work as OWNER may deem expedient. In such case
CONTRACTOR shall not be entitled to receive any further payment until the Work is finished.
If the unpaid balance of the Contract Price exceeds the direct, indirect and consequential
costs of completing the Work (including but not limited to fees and charges of
PROFESSIONALs, architects, attorneys and other PROFESSIONALs and court and
arbitration costs) such excess will be paid to CONTRACTOR. If such costs exceed such
unpaid balance, CONTRACTOR shall pay the difference to OWNER. Such costs incurred by
OWNER will be approved as to reasonableness by PROFESSIONAL and incorporated in a
Change Order, but when exercising any rights or remedies under this paragraph OWNER
shall not be required to obtain the lowest price for the Work performed.
15.3. In the event OWNER terminates the contract for cause and it is subsequently
judicially determined that there was no cause for termination, the termination for convenience
provision will be the means for disposition of the balance of the contract obligations.
GENERAL CONDITIONS
01001-51
Termination for Convenience
15.4. Upon seven working days' written notice to CONTRACTOR and
PROFESSIONAL, OWNER may, without cause and without prejudice to any other right or
remedy of OWNER, elect to terminate the Contract. In such case, CONTRACTOR shall be
paid (without duplication of any items):
15.4.1. For completed and acceptable Work executed in accordance with the
Contract Documents prior to the effective date of termination, including fair and reasonable
sums for overhead and profit on such Work;
15.4.2. For expenses sustained prior to the effective date of termination. in performing
services and furnishing labor, materials or equipment as required by the Contract Documents
in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit
on such expenses;
15.4.3. For all claims, costs, losses and damages incurred in settlement of terminated
contracts with Subcontractors, suppliers and others; and
15.4.4. For reasonable expenses directly attributable to termination.
CONTRACTOR shall not be paid on account of loss of anticipated profits or revenue or other
economic loss arising out of or resulting from such termination.
15.5. Where CONTRACTOR's services have been so terminated by OWNER, the
termination will not affect any rights or remedies of OWNER against CONTRACTOR then
existing or which may thereafter accrue. Any retention or payment of moneys due
CONTRACTOR by OWNER will not release CONTRACTOR from liability.
CONTRACTOR May Stop Work or Terminate:
15.6. If through no act or fault of CONTRACTOR, the Work is suspended for a
period of more than ninety calendar days by OWNER or under an order of courtor other
public authority, or PROFESSIONAL fails to act on any Application for Payment within thirty
days after it is submitted or OWNER fails for thirty-one days to pay CONTRACTOR any sum
finally determined to be due, then CONTRACTOR may upon seven working days' written
notice to OWNER and PROFESSIONAL and provided OWNER or PROFESSIONAL did not
remedy such suspension or failure within that time, terminate the Agreement and recover
from OWNER payment on the same terms as provided in 15.2. In lieu of terminating the
Agreement and without prejudice to any other right or remedy, if PROFESSIONAL has failed
to act on an Application for Payment within thirty days after it is submitted, or OWNER has
failed for thirty-one days after it is submitted, or OWNER has failed for thirty-one calendar
days to pay CONTRACTOR any sum finally determined to be due, CONTRACTOR may
upon seven day's written notice to OWNER and PROFESSIONAL stop the Work until
payment of all such amounts due CONTRACTOR, including interest thereon. The provisions
GENERAL CONDITIONS
01001-52
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
of this paragraph are not intended to preclude CONTRACTOR from making claim under
Articles 11 and 12 for an increase in Contract Price or Contract Times or otherwise for
expenses or damage directly attributable to CONTRACTOR's stopping Work as permitted by
this paragraph. The provisions of this paragraph shall not relieve CONTRACTOR of the
obligations under paragraph 6.30 to carry on the Work in accordance with the progress
schedule and without delay during disputes and disagreements with OWNER.
ARTICLE 16--D1SPUTE RESOLUTION
16.1. All disputes arising under this Contract or its interpretation whether involving
law or fact or both, or extra work, and all claims for alleged breach of contract shall within ten
(10) working days of the commencement of the dispute be presented by CONTRACTOR to
OWNER for decision. All papers pertaining to claims shall be filed in quadruplicate. Such
notice need not detail the amount of the claim but shall state the facts surrounding the claim
in sufficient detail to identify the claim, together with its character and scope. In the
meantime, CONTRACTOR shall proceed with the Work as directed. Any claim not
presented within the time limit specified in this paragraph shall be deemed to have been
waived, except that if the claim is of a continuing character and notice of the claim is not
given within ten (10) working days of its commencement, the claim will be considered only for
a period commencing ten (10) working days prior to the receipt by OWNER of notice thereof.
Each decision by OWNER will be in writing and will be mailed to CONTRACTOR by
registered or certified mail, return receipt requested, directed to his last known address.
16.2 All claims, disputes and other matters in question between OWNER and
CONTRACTOR arising out of, or relating to, the Contract Documents or the breach thereof
shall be decided under Georgia Law in the Superior Court of Richmond County, Georgia.
CONTRACTOR by execution of the Contract consents to jurisdiction and venue in the
Superior Court of Richmond County, Georgia, and waives any right to contest same.
ARTICLE 17-MISCELLANEOUS
Giving Notice:
17.1. Whenever any provision of the Contract Documents requires the giving of
written notice, it will be deemed to have been validly given if delivered in person to the indi-
vidual or to a member of the firm or to an officer of the corporation for whom it is intended, or
if delivered at or sent by registered or certified mail, postage prepaid, to the last business
address known to the giver of the notice.
Computation of Time:
17.2.1. When any period of time is referred to in the Contract Documents by days, it
will be computed to exclude the first and include the last day of such period. If the last day of
any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of
the applicable jurisdiction, such day will be omitted from the computation.
GENERAL CONDITIONS
01001-53
17.2.2. A calendar day of twenty-four hours measured from midnight to the next
midnight shall constitute a day.
General:
17.3. Should OWNER or CONTRACTOR suffer injury or damage to person or property
because of any error, omission or act of the other party or of any of the other party's
employees or agents or others for whose acts the other party is legally liable, claim should be
made in writing to the other party within a reasonable time of the first observance of such
injury or damage. The provisions of this paragraph 17.3 shall not be construed as a
substitute for or a waiver of the provisions of any applicable statute of limitations or repose.
17.4. The duties and obligations imposed by these General Conditions and the rights
and remedies available hereunder to the parties hereto, and, in particular but without
limitation, the warranties, guarantees and obligations imposed upon CONTRACTOR by
paragraphs 6.32,13.1,13.12,13.14,14.3 and 15.2 and all of the rights and remedies
available to OWNER and PROFESSIONAL thereunder, are in addition to, and are not to be
construed in any way as a limitation of, any rights and remedies available to any or all of
them which are otherwise imposed or available by Laws or Regulations, by special warranty
or guarantee or by other provisions of the Contract Documents, and the provisions of this
paragraph will be as effective as if repeated specifically in the Contract Documents in
connection with each particular duty, obligation, right and remedy to which they apply. All
representations, warranties and guarantees made in the Contract Documents will survive
final payment and termination or completion of the Agreement.
17.5. CONTRACTOR shall keep adequate records and supporting
documentation applicable to this Work and Contract. Said records and documentation shall
be retained by CONTRACTOR for a minimum of five (5) years from the date of final
completion or termination of this Contract. OWNER shall have the right to audit, inspect, and
copy all such records and documentation as often as OWNER deems necessary during the
period of the Contract and for a period of five (5) years thereafter provided, however, such
activity shall be conducted only during normal business hours. OWNER, during this period of
time, shall also have the right to obtain a copy of and otherwise inspect any audit made at
the direction of CONTRACTOR as concerns the aforesaid records and supporting
documentation.
17.6. The Contract Documents are intended by the Parties to, and do, supersede any
and all provisions of the Georgia Prompt Pay Act, O.C.G.A. Section 13-11-1, et seq. In the
event any provision of the Contract Documents are inconsistent with any provision of the
Prompt Pay Act, this provision of the Contract Documents shall control.
17.7. Notwithstanding any provision of the law to the contrary, the parties agree that
no interest shall be due Contractor on any sum held as retainage pursuant to the Contract
Documents and CONTRACTOR specifically waives any claim to same.
GENERAL CONDITIONS
01001-54
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 01002 - SPECIAL CONDITIONS
1.01 SCOPE OF THE WORK:
A. The work to be done consists of providing all plant, labor, fixtures, equipment,
materials and supplies and performing all operations in full compliance with the
Plans and Specifications and including the placing of the entire project into
satisfactory operation.
1.02 GENERAL CONDITIONS:
A. The General Conditions of the Construction Contract shall apply to all work in this
Contract except as otherwise specified in these Special Conditions. Requirements
of these Special Conditions supersede those of the General Conditions.
1.03 CONTRACTORS INSURANCE:
A. The Contractor shall maintain insurance In accordance with the
requirements of Article 5 of the General Conditions.
The limits of insurance are as follows:
Comprehensive General Liability - policy covering bodily injury and property
damage including premises, operations, products, and completed operations
$1,000,000 per occurrence $2,000,000 aggregate
Automobile Liability - policy covering injury and property damage.......$1,OOO,000
Umbrella Policy....... ........................ ............. ........... .... ................ ........ ..$1,000,000
Builders Risk........ ... .... .... ........ ......... ............. ... ...... ....... .........$Amount of Contract
B. Contractors Liability Insurance shall be effective for the duration of the work as
described in the contract documents, including authorized change orders, plus
any period of guarantee.
1.04 PROGRESS PAYMENTS:
To expedite the approval of requests for partial payment, the Contractor shall
submit with his request the following information:
A. A coPy of the Proqress Schedule marked to indicate the work actuallv
accomplished.
SPECIAL CONDITIONS
01002-1
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
B. An itemized list of materials stored for which payment is being claimed.
This list shall be accompanied by the suppliers' invoices indicating the
materials costs. Payment for materials stored shall be subject to the same
retainage provisions as for work completed.
7
C. An outline of time lost because of any event qivinq rise to a request for an
extension of contract time.
The Owner has a right to hold a payment to a contractor who has not included an
updated progress schedule with his pay request.
1.05 COORDINATION WITH OWNER's ON-SITE REPRESENTATIVE:
The Contractor shall provide a weekly printed schedule to the Owner's on-site
project representative and shall verbally updated the ~chedule with the representative on
a daily basis. In addition, the Contractor shall update the project representative's project
drawings with As-built data on a monthly basis.
1.06 WORKING HOURS:
Hours of Operation for plant administrative and maintenance personnel are 7:30AM
to 3:30PM, Monday through Friday. The Contractor should, in general adhere to this work
schedule. Work outside these hours may be used with prior approval. Excavation within
the fence line of the waste water plant may only occur during the normal plant operating
hours.
1.07 PROJECT STAGING:
Digesters will be made available to the Contractor one at a time for cleaning and
modificatiqn. The selected digester must be returned to service before subsequent units
will be-taken out of service. The Owner will continue to operate his land application of
digested sludge during the construction process and the Contractor is required to
cooperate with the Owner's Land Application Contractor during the construction of this
project. The Contractor will be required to submit a detailed staging plan incorporating
these requirements for approval prior to commencing work on the project.
1.08 PLANS:
Following are the Plans which form a part of this Contract:
Sheet No.
Title
C001 Cover Sheet
C101 Project Location Map - Schedule of Drawings
SPECIAL CONDITIONS
01002-2
I
I
I
I
I
I
I
I
I
I
-.
I
I
I
I
I
I
.
-
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Sheet No.
M701
M702
M703
M704 :
M705
M706
M707
M708
M709
M710
M711
M712
M713
M714
M715
M716
M717
M718
M719
M720
M721
M722
M723
M724
M725
P001
P701
P702
P703
P704
P705
P706
P707
P708 -
P709
E001
E002
E701
E702
E703
E704
E705
E706
E707
E708
E709
Title
Digester Area Plan
Digester No. 1 & No.2 - Demolition Plan
Digester No. 1 & No. 2 - Demolition Plan - Roof
Digester NO.4 & No.5 - Demolition Plan
Digester No.4 & No.5 - Demolition Plan - Roof
Digester No.3 & No. 6.- Demolition Plan
Digester No.3 & No.6 - Demolition Plan - Roof
Digester No. 1 Section - Demolition
Digester Nos. 2 thru 6 Section - Demolition
Digester No. 1 & NO.2 - Mechanical Plan EI133
Digester No. 1 & NO.2 - Mechanical Plan EI150
Digester No. 1 & No.2 - Mechanical Roof Plan
Digester No.4 & No.5 - Mechanical Plan EI133
Digester NO.4 & No.5 - Mechanical Plan EI 150
Digester No.4 & NO.5 - Mechanical Roof Plan
Digester NO.3 & No.6 - Mechanical Plan EI133
Digester No.3 & No.6 - Mechanical Plan EI150
Digester No.3 & No.6 - Mechanical Roof Plan
Digester No. 1 - Section
Digester 2, 4, 5 - Section
Digester Sections & Details
Digester Sections & Details
Digester Mixer Details
Miscellaneous Digester Details
Digester NO.1 Cover Details
Symbols & Abbreviations
Process & Instrumentation Diagram - Anaerobic Digester No. 1
Process & Instrumentation Diagram - Anaerobic Digester NO.2
Process & Instrumentation Diagram - Anaerobic Digester No.3
Process & Instrumentation Diagram - Sludge Heaters 1 & 2
Process & Instrumentation Diagram - Anaerobic Digester NO.4
Process & Instrumentation Diagram - Anaerobic Digester NO.5
Process & Instrumentation Diagram - Anaerobic Digester NO.6
Process & Instrumentation Diagram - Sludge Heaters 3 & 4
Process & Instrumentation Diagram - Boilers & Hot Water Pumps
Electrical Legend
Electrical Symbols
MCC One Line and Elevation
Electrical Plan - Digesters 1 & 2
Electrical Plan - Digesters 4 & 5
Electrical Plan - Digesters 3 & 6
Electrical Plan - Digester Control Buildings 1 & 2
Electrical Site Plan
Mixers, Valves & Temp Sensor Schematics
Level, Pressure and Flow Sensor Schematics
Conduit Cable Schedule
END OF SECTION 01002
SPECIAL CONDITIONS
01002-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 01605 - SHIPMENT. PROTECTION, AND STORAGE
1.01 GENERAL:
Equipment, products and materials shall be shipped, handled, stored, and installed in
ways_ which will prevent damage to the items. Damaged items will not be permitted as
part of the work except in cases of minor damage that have been satisfactorily repaired
and are acceptable to the Resident Project Representative.
2.01 PIPE:
Pipe and appurtenances shall be handled, stored, and installed as recommended by the
manufacturer. pipes with paint, tape coatings, linings or the like shall be stored to protect
the coating or lining from physical damage or other deterioration. Pipes shipped with
interior bracing shall have the bracing removed only when recommended by the pipe
manufacturer.
3.01 EQUIPMENT:
A. PACKAGE AND MARKING:
All equipment shall be protected against damage from moisture, dust, handling, or
other cause during transport from manufacturer's premises to site. Each item or
package shall be marked with the number unique to the specification reference
covering the item.
Stiffeners shall be used where necessary to maintain shapes and to give rigidity.
parts of equipment shall be delivered in assembled of subassembled units where
possible.
B. .IDENTIFICATION:
4~ ....~
Each item of equipment and valve shall have permanently affixed to it a label or tag
with its equipment or valve number designated in this contract. Marker shall be of
stainless steel. Location of label will be easily visible.
C. SHIPPING:
Bearing housings, vents and other types of openings shall be wrapped or otherwise
sealed to prevent contamination by grit and dirt.
Damage shall be corrected to conform to the requirements of the contract before the
assembly is incorporated into the work. The Contractor shall bear the costs arising
out of dismantling, inspection, repair, and reassembly.
SHIPMENT, PROTECTION AND STORAGE
01605-1
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
D. FACTORY APPLIED COATINGS:
Unless otherwise specified, each item of equipment shall be shipped to the site of the
work with the manufacturer's shop applied epoxy prime coating as specified in
Section 09800. The prime coating shall be applied over clean dry surfaces in
accordance with the coating manufacturer's recommendations. The prime coating will
serve as a base for field-applied finish coats.
E. STORAGE:
During the interval between the delivery of equipment to the site and installation, all
equipment, unless otherwise specified, shall be stored in an enclosed space affording
protection from weather, dust and mechanical damage and providing favorable
temperature, humidity and ventilation conditions to ensure against equipment
deterioration. Manufacturer's recommendations shall be adhered to in addition to
these requirements.
Equipment and materials to be located outdoors may be stored outdoors if protected
against moisture condensation. Equipment shall be stored at least 6 inches above
ground. Temporary power shall be provided to energize space heaters or other heat
sources for control of moisture condensation. Space heaters or other heat sources
shall be energized without disturbing the sealed enclosure.
F. PROTECTION OF EQUIPMENT AFTER INSTALLATION:
After installation, all equipment shall be protected from damage from, including but not
limited to, dust, abrasive particles, debris and dirt generated by the placement,
chipping, sandblasting, cutting, finishing and grinding of new or existing concrete,
terrazzo and metal; and from the fumes, particulate matter, and splatter from welding,
~rcE:ing and painting of new or existing piping and equipment. As a minimum,
vacuum cleaning, blowers with filters, protective shieldings, and other dust
suppression methods will be required at all times to adequately protect all equipment.
During concreting, including finishing, all equipment that may be affected by cement
dust must be completely covered. During painting operations, all grease fittings and
similar openings shall be covered to prevent the entry of paint. Electrical switchgear,
unit substation, and motor load centers shall not be installed until after all concrete
work and sandblasting in those areas have been completed and accepted and the
ventilation systems installed.
END OF SECTION 01605
SHIPMENT, PROTECTION AND STORAGE
01605-2
"I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 01660 -INSTALLATION. TESTING. AND COMMISSIONING
1.01 DESCRIPTION:
This section provides specifications for the installation and testing of all mechanical and
electrical systems. All commissioning work for the equipment installed under this contract,
including equipment furnished by the Owner, shall be performed by the Contractor.
1.02 QUALITY ASSURANCE:
A. INSTALLATION:
All mechanical, electrical, and instrumentation equipment shall be installed in
conformity with the details shown and specified and with the manufacturer's
requirements. Should a manufacturer's installation recommendations conflict with
specific requirements of this project manual, the Contractor shall bring the matter to
the attention of the Engineer. Any costs incurred by the Contractor through failure to
timely notify the Engineer of a difference between project manual and manufacturer's
installation requirements shall be borne by the Contractor.
B. TESTING:
1. GENERAL REQUIREMENTS: All materials, equipment, and work provided and/or
installed in this contract shall be tested and inspected to prove compliance with the
contract requirements. The work shall include the equipment supplied by others but
installed and/or connected by the Contractor. Unless otherwise specified, all costs of
testing, including temporary facilities and cormections, shall be borne by the
Contractor. For the purpose of this section, equipment shall mean any mechanical,
electrical, instrumentation, or other device with one or more moving parts or devices
requiring an electrical, pneumatic or hydraulic connection. Installed leakage tests and
.ot~r piping tests shall be as specified in Division 15. Installed tests for heating,
-ventilation, and air conditioning systems shall be as specified in Division'-15. Installed
tests for electrical and instrumentation devices and systems shall be in accordance
with Division 13 and 16.
No tests specified herein shall be applied until the item to be tested has been
inspected and approval given for the application of such test.
Test and inspection shall include:
a. The delivery acceptance test and inspections.
b. The installed tests and inspections of items as installed.
INSTALLATION, TESTING, AND COMMISSIONING
01660-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Test and inspections, unless otherwise specified or accepted, shall be in accordance
with the recognized standards of the industry.
The form of evidence of satisfactory fulfillment of delivery acceptance test and of
installed test and inspection requirements shall be, at the discretion of the Engineer,
either by tests and inspections carried out in his presence or by certificates or reports
of tests and inspections carried out by approved persons or organizations. The
Contractor shall provide and use forms which include all test information, including
specified operational parameters, and shall be acceptable in content to the Engineer.
2. DELIVERY ACCEPTANCE TESTS AND INSPECTIONS: The delivery
acceptance tests and inspections shall be at the Contractor's expense for any
materials or equipment specified herein and shall include the following:
a) Test of items at the plClce of manufacture during and/or on completion of
manufacture, comprising material tests, hydraulic pressure tests, electric and
instrumentation subsystem tests, performance and operating tests and inspections
in accordance with the relevant standards of the industry and more particularly as
detailed in individual clauses of these specifications to satisfy the Engineer that the
items tests and inspected comply with the requirements of this contract.
b) Inspection of all items delivered at the site or to any authorized place of storage
in order that the Engineer may be satisfied that such items are of the specified
quality and workmanship and are in good order and condition at the time of
delivery. To that end, the Contractor shall be prepared to remove all coverings,
containers or crates to permit the Engineer to conduct his inspection. Should the
Engineer find, in his opinion, indication of damage or deficient quality of
workmanship, the Contractor shall provide the necessary documentation or
conduct such tests deemed necessary by the Engineer to demonstrate
compliance.
-.- ..<,
....
3. INSTALLED TESTS AND INSPECTIONS:
a) General: All equipment including prepurchased equipment installed by the
Contractor shall be tested by the Contractor to the satisfaction of the Engineer
before and facility is put into operation. Tests shall be as specified herein and
shall be made to determine whether the equipment has been properly assembled,
aligned, adjusted and connected. Any changes, adjustments or replacements
required to make the equipment operate as specified shall be carried out by the
Contractor and part of the work.
b) Procedures
1) General: Prior to receipt of any progress payments in excess of 60
percent of the Contractor's lump sum bid for the work, the Contractor shall
INSTALLATION, TESTING, AND COMMISSIONING
01660-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
submit to the Engineer, in quintuplicate, details of the procedures he
proposed to adopt for testing and start-up of all equipment to be operated
singly and together, excepting when such procedures have been covered in
the specifications.
The procedures shall be divided into three distinct stages; preoperation
checkout, initial operation, and plant operational tests. Testing procedures
shall be designed to duplicate, as nearly as possible, all conditions of
operation and shall be carefully selected to ensure that the equipment is not
damaged. The Contractor is advised that failure to observe the testing
procedures may place the acceptability of the subject equipment in question.
Once the testing procedures have been reviewed by the Engineer, the
Contractor shall produce checkout, alignment, adjustment and calibration
sign-off forms for each item of equipment to be used in the field by the
Contractor and the Engineer jointly t09nsure that each item of electrical and
mechanical equipment has been properly installed and tested.
2) Preoperation Checkout: The procedures shall incorporate all
requirements of these specifications and shall proceed in a logical, step-wise
sequence to ensure that all equipment has been properly serviced, aligned,
connected, calibrated, and adjusted prior to operation. Preoperational
checkout procedures shall include, but not necessarily be limited to:
a. Electrical and instrumentation system testing as specified in Division
13 and 16.
b. Piping system pressure testing and cleaning as specified in Division
15.
~
c. Alignment of equipment.
d. Preoperation lubrication.
3) Initial Operation: Once all affected equipment have been subjected to the
required preoperational checkout procedures and the Engineer has
witnessed individual systems may be started and operated under the
simulated operating conditions to determine as nearly as possible whether
the equipment and systems meet the requirements of these specifications.
Potable water or chlorinated filter effluent, depending on availability, shall be
employed for testing. The Owner will provide the effluent and the Contractor
shall bear all expenses to pump or pipe it to the tested systems. Test media
for gaseous, oil or chemical systems shall either be the intended fluid or a
compatible substitute. The equipment shall be operated a sufficient period of
time to determine machine operating characteristics, including temperatures
INSTALLATION, TESTING, AND COMMISSIONING
01660-3
F&V Project No.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
and vibration; to observe performance characteristics; and to permit initial
adjustment of operating controls. When testing requires the availability of
auxiliary systems such as power, flushing or cooling water or control air which
have not yet been placed in service, the Contractor shall provide acceptable
substitute sources, capable of meeting the requirements of the machine,
device or system, at no additional cost to the Owner. Disposal methods for
test media shall be subject to review by the Engineer.
If under test, any portion of the work should fail to fulfill the contract
requirements and is adjusted, altered, renewed or replaced, tests on that
portion when so adjusted, altered, removed or replaced, together with all
other portions of the work as are affected thereby, shall, if so required by the
Engineer, be repeated within reasonable time and in accordance with the
specified conditions. The Contractor shall pay to the Owner all reasonable
expenses incurred by the Owner as a result of repeating such tests.
Once initial operation has been completed, all machines shall be
rechecked for proper alignment, realigned, if necessary, and doweled in
place. All equipment shall be checked for loose connections, unusual
movement or other indications of improper operating characteristics. Any
deficiencies shall be corrected to the satisfaction of the Engineer. All
machines or devices which exhibit unusual or unacceptable operating
characteristics shall be disassembled and inspected. They shall then be
repaired or removed from the site and replaced at no cost to the Owner.
...
Test results shall be within the tolerances set forth in the detailed
specification sections of this project manual. If no tolerances have been
specified, test results shall conform to tolerances established by recognized
industry practice. Where, in the case of an otherwise satisfactory installed
test, any doubt, dispute, or difference should arise between the Engineer and
the Contractor regarding the test results of the methods or equipment used in
the performance of such test, then the Engineer may order the test to be
repeated. If the repeat test, using such modified methods or equipment as
the Engineer may required, substantially confirms the previous test, then all
costs in connection with the repeat test will be paid by the Owner, otherwise
the costs shall be borne by the Contractor. Where the results of any installed
test fail to comply with the contract requirements for such test, then such
repeat tests as may be necessary to achieve the contract requirements shall
be made by the Contractor at his expense.
The Contractor shall provide at no expense to the Owner, all utilities,
supplies, labor and all other necessary items and work required to complete
all tests and inspection specified in this section. The Owner will allow the
Contractor use of plant power and water as long as it does not interfere with
plant operations. The Contractor shall provide at no expense to the Owner
INSTALLATION, TESTING, AND COMMISSIONING
01660-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
temporary heating, ventilating and air conditioning for any areas requiring it in
the case where permanent facilities are not complete and operable at the
time of installed tests. Temporary facilities shall be maintained until
permanent systems are in service.
4) Plant Operational Testinq: After completion of all installed testing and
certification by the Engineer that all equipment complies with the
requirements of the specifications, the Contractor shall fill all process systems
and units with the specified fluid.
Upon completion of the filling operations, the Contractor shall operate the
completed systems and processes for a period of not less than that specified
in paragraph 01660-3.01, during which all systems shall be operated as a
complete facility at various loading conditions, as directed by the Engineer.
Should the operational testing period be halted for any reason related to the
facilities constructed or the equipment furnished under this cO:1tract, or the
Contractor's temporary testing systems, the operational testing program shall
be repeated until the specified continuous period has been accomplished
without interruption. All process units and systems shall be brought to full
operating conditions, including temperature, pressure, and flow.
All costs for water, fuel, power, and chemicals required during this plant
operational test shall be borne by the Contractor. The Owner will make water
and power available as in paragraph 1.02 B.3.b.(3).
Process systems and units shall mean all materials and equipment
constructed or installed in this contract, including Owner-supplied equipment.
.-
5. Operational Instruction: During the testing of equipment, the Contractor
shall make available experienced factory-trained representatives of the
manufacturers of all the various pieces of equipment who shall instruct the
Owner's personnel in the operation and care thereof. Instructions'shall
include step-by-step troubleshooting procedures with all necessary test
equipment. Instruction shall be in sufficient detail to satisfy the Engineer the
above requirements have been met. The instruction shall take place within a
30-day period and shall be coordinated with the Engineer. The Engineer
shall be notified in writing 30 days in advance of the instruction period. All
manufacturer's instructions shall be provided in writing.
c. COMMISSIONING:
After completion of all installed and operational testing, the Contractor shall make
written application to the Engineer for permission to introduce appropriate fluid into
the facility and demonstrate compliance of the equipment, structures, and systems
furnished and installed under this contract with all requirements of this project
INSTALLATION, TESTING, AND COMMISSIONING
01660-5
F&V Project NO.9? 124 01
Oigester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
manual. Such application shall be furnished to the Engineer not less than 30 days
prior to the date fluids are to be released into completed portions of the facility.
Upon receipt of written permission from the Engineer, and on the agreed upon
date, the Contractor shall do all things necessary to effect the release of fluid into
the facility and to permit adequate operation of the facilities.
The Contractor shall allow for a commissioning period as set forth in Part 3 to
satisfy the Engineer that the contract requirements have been fulfilled. The
commissioning period may be broken into several segments comprising complete
systems at the discretion of the Engineer.
During the commissioning period, the Owner will provide a full-time (24 hours
daily) staff for operation and maintenance of the facility. The Contractor shall
provide full-time (8 hours per day for 5 days per week) coordinator service to
coordinate other Contractor personnel including equipment manufacturer service
representatives for troubleshooting, training of Owner personnel, or repair and
maintenance of equipment within the terms of the contract. Contractor provided
personnel for troubleshooting, repair or maintenance of equipment shall be
provided as soon as possible and in no case longer than 8 hours after notification
to the Contractor's coordinator. Such coordinators shall be familiar with the facility
equipment and operations and shall be acceptable to the Engineer. Coordinator
service shall mean attendance at the site for whatever period is required at
whatever time necessary in response to a request from the Engineer. In addition,
the Contractor shall provide the services of one laborer per 8-hour shift, 5 days per
week during the commissioning period to assist Owner personnel in general
cleanup and maintenance.
The Owner will pay for all electrical power, water, chemicals, and fuel necessary
for operation of the facility during commissioning.
...
PART 2 - MATERIALS AND METHODS
2.01 MATERIALS:
A. INSTALLATION:
Materials employed in the installation shall conform to the requirements of this project
manual and the recommendations of the equipment manufacturers. Where conflict
exists between project manual specifications and the manufacturer's
recommendations, the Contractor shall bring the matter to the attention of the
Engineer and request a resolution of the conflict. Any additional costs incurred by the
Contractor as a result of the Engineer's direction in the resolution of the conflict will be
reimbursed as extra work. Any costs incurred by the Contractor, through failure to
timely notify the Engineer of a conflict, shall be borne by the Contractor.
INSTALLATION, TESTING, AND COMMISSIONING
01660-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. TESTING:
1. GAGES. METERS. RECORDERS. AND MONITORS: Gages, meters, recorders
and monitors shall be provided by the Contractor as required by the Engineer to
supplement or augment the instrumentation system provided under this contract to
properly demonstrate that all equipment fully satisfies the requirements of this project
manual. All devices employed for the purpose of measuring the performance of the
facility's equipment and systems shall be specifically selected to provide a level of
uncertainty consistent with the variables to be monitored. All instruments shall be
recently calibrated, and the Contractor shall be prepared at all times to demonstrate,
through recalibration, the uncertainty of all instruments employed for testing purposes.
Calibration procedures shall be in accordance with applicable standards of ASTM,
ISA and IEEE. The adequacy of all gages, meters, recorders and monitors shall be
subject to review of the Engineer.
2. RECORDS: The Contractor shall provide sign-off forms for all installed and
operational testing to be accomplished under this contract. The sign-off forms shall
be produced in quadruplicate on pressure sensitive paper. Sign-off forms shall be
provided for each item of mechanical, electrical and instrumentation equipment
provided or installed under this contract and shall contain provisions for recording
relevant performance data for original testing and not less than three retests.
Separate sections shall be provided to record values for the preoperation checkout,
initials of representatives of the equipment manufacturers, the Contractor and the
Engineer.
The Contractor shall maintain a master file of all equipment sign-off sheets, which
shall be available for inspection by the Engineer. Upon completion of testing, the
Contractor shall furnish the Engineer with the original and two copies of the sign-off
sheet for each equipment item.
.-
2.02 METHODS:
A. INSTALLATION:
All equipment shall be installed by specialists properly skilled in the trades and
professions required to assure first-class workmanship. Where required by detailed
specifications, the Contractor shall cause the installation of specific equipment items
to be accomplished under the supervision of factory-trained installation specialists
furnished by the equipment manufacturers. The Contract shall be prepared to
document skills and training of all workman engaged in the installation of all
equipment furnished either by the Contractor or the Owner.
Test procedures shall be included with equipment submittal.
INSTALLATION, TESTING, AND COMMISSIONING
01660-7
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia
The Contractor shall submit to the Engineer a complete testing procedure for each
item to be tested. The submittal shall include as a minimum the name and
description, required equipment, procedure standard (if standardized), step-by-step
procedure (if not standardized), acceptable tolerances, and expected results.
B. TESTING:
Testing shall proceed on a step-by-step basis in accordance with the Contractor's
written testing procedures. The Contractor's testing work shall be accomplished by a
skilled team of specialists under the direction of a coordinator whose sole
responsibility shall be the orderly, systematic testing of all equipment, systems,
structures and the complete facility as a unit. Each individual step in the procedures
shall be witnessed by a representative of the Engineer.
During the plant operational testin~ period, all equipment and systems shall be
operated, to the greatest extent practicable, at conditions which represent the full
range of operating parameters as defined by this project manual.
PART 3 - EXECUTION
3.01 PLANT OPERATIONAL TESTING AND COMMISSIONING:
The duration of the plant operational test shall be 14 days. Each day the complete facility - -.
shall be operated for 8 continuous hours. During the 14-day period I the Contractor shall
demonstrate the operation of all equipment and all systems installed under this contract.
The commissioning period for new facilities shall be 90 days and commence from the
date of substantial completion of each portion of the facility, system or subsystem.
END O~ S~CTION 01660
INSTALLATION, TESTING, AND COMMISSIONING
01660-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 01730 - OPERATING AND MAINTENANCE INFORMATION
PART 1 - GENERAL
1.01 SCOPE:
Where specified, operating and maintenance information shall be provided and shall
consist of the names and addresses of the manufacturer, the nearest representative of
the manufacturer, and the nearest supplier of the manufacturer's equipment and parts.
O&M instructions must be submitted and accepted before on-site training may start. In
addition, one or more of the following items of information shall be provided when
specified.
A. LUBRICATION INFORMATION:
This shall consist of the manufacturer's recommenrlations regarding the lubricants to
be used and the lubrication schedule to be followed.
B. CONTROL DIAGRAMS:
Diagrams shall show internal and connection wiring.
C. START-UP PROCEDURES:
These instructions consist of equipment manufacturer's recommendations for
installation, adjustment, calibration, and troubleshooting.
D. OPERATING PROCEDURES:
These instructions consist of the equipment manufacturer's recommended step-by-
_.ste'p procedures for starting, operating, and stopping the equipment under specified
modes of operation.
E. PREVENTATIVE MAINTENANCE PROCEDURES:
These instructions consist of the equipment manufacturer's recommended steps and
schedules for maintaining the equipment.
F. OVERHAUL INSTRUCTIONS:
These instructions consist of the manufacturer's directions for the disassembly, repair
and reassembly of the equipment and any safety precautions that must be observed
while performing the work.
OPERATION AND MAINTENANCE INFORMATION
01730-1
.. ...
F&V Project N0097 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
G. PARTS LIST:
This list consists of the generic title and identification number of each component part
of the equipment.
H. SPARE PARTS LIST:
This list consists of the manufacturer's recommendations of number of parts which
should be stored by the Owner and any special storage precautions which may be
required.
I. EXPLODED VIEW:
Exploded or cut views of equipment shall be provided if available as a standard item
of the manufacturer's information. When exploded or cut views are not available, plan
and section views shall be provided with detailed callouts.
J. SPECIFIC INFORMATION:
Where items of information not included in the above list are required, they will be
provided as described in the specification for the equipment.
2.01 TRANSMITTAL PROCEDURE:
Five copies of the specified operating and maintenance information shall be provided.
For ease of identification, each manufacturer's brochure and manual shall be
appropriately labeled with the equipment name and equipment number as it appears in
the project manual. The information shall be organized in the binders in numerical order
by the equipment numbers assigned in the project manual. The binders shall be
provided with a table of contents and tab sheets to permit easy location of desired
information. Binders shall be three-ring binders.
o. ...
If manufacturer's standard brochures and manuals are used to describe operating and
maintenance procedures, such brochures and manuals shall be modified to reflect only
the model or series of equipment used on this project. Extraneous material shall be
crossed out neatly or otherwise annotated or eliminated.
3.01 PAYMENT:
Acceptable operating and maintenance information shall be delivered to the Engineer
before the Contractor will be paid for more than 50 percent of the purchase value of the
equipment. Purchase value shall be the net price for the equipment as given on the
invoice. Acceptable operating and maintenance information for the projecrmust be
delivered to the Engineer prior to the project being 75 percent complete. Progress
OPERATION AND MAINTENANCE INFORMATION
01730-2
01
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
payments for work in excess of 75 percent completion will not be made until the specified
acceptable operating and maintenance information has been delivered to the Engineer.
4.01 FIELD CHANGES:
Following the acceptable installation and operation of an equipment item, the item's
instructions and procedures shall be modified and supplemented by the Contractor to
reflect any field changes or information requiring data.
END OF SECTION 01730
.;.
OPERATION AND MAINTENANCE INFORMATION
01730-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 01800 - SUBMITTALS
1.01 GENERAL:
Submittals covered by these requirements include manufacturers' information, shop
drawings, test procedures, test results, samples, requests for substitutions, and
miscellaneous work-related submittals. Submittals shall also include, but not be limited
to, all mechanical, electrical and electronic equipment and systems, materials, reinforcing
steel, fabricated items, and piping and conduit details. The Contractor shall furnish all
drawings, specifications, descriptive data, certificates, samples, tests, methods,
schedules, and manufacturer's installation and other instructions as specifically required
in the Project Manual to demonstrate fully that the materials and equipment to be
furnished and the methods of work comply with the provisions and intent of the contract
documents.
2.01 CONTRACTOR'S RESPONSIBILITIES:
The Contractor shall be responsible for the accuracy and completeness of the information
contained in each submittal and shall assure that the material, equipment or method of
work shall be as described in the submittal. The Contractor shall certify that all features
of all products conform to the specified requirements. Submittal documents shall be
clearly edited to indicate only those items, models, or series of equipment, which are
being submitted for review. All extraneous materials shall be crossed out or otherwise
obliterated. The Contractor shall ensure that there is no conflict in each case where his
submittal may affect the work of another contractor or the Owner. The Contractor shall
coordinate submittals among his subcontractors and suppliers.
The Contractor shall coordinate submittals with the work so that work will not be delayed.
He shall coordinate and schedule different categories of submittals, so that one will not
be delayed for lack of coordination with another. No extension of time will be allowed
because of failure to properly schedule submittals. The Contractor shall not proceed with
work related to a submittal unit the submittal process is complete. This requires that
submittals for review and comment shall be returned to the Contractor stamped
No Exceptions Taken or Make Corrections Noted.
The Contractor shall certify on each submittal document that he has reviewed the
submittal, verified field conditions, and complied with the contract documents.
The Contractor may authorize in writing a material or equipment supplier to deal directly
with the Engineer or with the Owner with regard to a submittal. These dealings shall be
limited to contract interpretations to clarify and expedite the work.
SUBMITTALS
01800-1
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
3.01 CATEGORIES OF SUBMITTALS:
A. GENERAL:
Submittals fall into two general categories, submittals for review and comment, and
submittals which are primarily for information only. Submittals which are for
information only are generally specified as PRODUCT DATA in Part 2 of applicable
specification sections.
B. SUBMITTALS FOR REVIEW AND COMMENT:
All submittals except where specified to be submitted as product data for information
only shall be submitted by the Contractor to the Engineer for review and comment.
C. SUBMITTALS (PRODUCT DATA) FOR INFORMATION ONLY:
Where specified, the Contractor shall furnish submittals (product data) to the Engineer
for information only. Submittal requirements for operation and maintenance manuals,
which are included in this category, are specified in Section 01730.
4.01 TRANSMITIAL PROCEDURE:
A. GENERAL:
Unless otherwise specified, submittals regarding material and equipment shall be
accompanied by Transmittal Form 01800-A following this section. Submittals for
operation and maintenance manuals, information and data shall be accompanied by
Transmittal Form 01800-8 following this section. A separate form shall be used for
each specific item, class of material, equipment, and items specified in separate,
discrete sections, for which the submittal is required. Submittal documents common
to more than one piece of equipment shall be identified with all the appropriate
equipment numbers. Submittals for various items shall be made with a single form
when the items taken together constitute a manufacturer's package or are so
functionally related that expediency indicates checking or review of the group or
package as a whole.
A unique number, sequentially assigned, shall be noted on the transmittal form
accompanying each item submitted. Original submittal numbers shall have the
following format: "XXX"; where "XXX" is the sequential number assigned by the
Contractor. Resubmittals shall have the following format: "XXX-Y"; where "XXX" is
the originally assigned submittal number and "y" is a sequential letter assigned for
resubmittals, i.e., A, G, or C being the first, second, and third resubmittals,
respectively. Submittal 25B, for example, is the second resubmittal of submittal 25.
SUBMITIALS
01800-2
'1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
B. DEVIATION FROM CONTRACT:
If the Contractor proposed to provide material, equipment, or method of work which
deviates from the project manual, he shall indicate so under "deviations" on the
transmittal form accompanying the submittal copies.
C. SUBMITTAL COMPLETENESS:
Submittals which do not have all the information required to be submitted. including
deviations, are not acceptable and will be returned without review.
5.01 REVIEW PROCEDURE:
A. GENERAL:
Submittals are specified for those features and characteristics of materials,
equipment, and methods of operation which can be selected based on the
Contractor's judgment of their conformance to the specified requirements. Other
features and characteristics are specified in a manner which enables the Contractor to
determine acceptable options without submittals. The review procedure is based on
the Contractor's guarantee that all features and characteristics not requiring
submittals conform as specified. Review shall not extend to means, methods,
techniques, sequences or procedures of construction, or to verifying quantities,
dimensions. weights or gages, or fabrication processes (except where specifically
indicated or required by the project manual) or to safety precautions or programs
incident thereto. Review of a separate item, as such, will not indicate approval of the
assembly in which the item functions.
When the contract documents require a submittal, the Contractor shall submit the
specified information as follows:
1. Six copies of all submitted information shall be transmitted with submittals for
review and comment.
2. Unless otherwise specified, five copies of all submitted information shall be
transmitted with submittals (product data) for information only.
B. SUBMITTALS FOR REVIEW AND COMMENT:
Unless otherwise specified, within thirty (30) calendar days after receipt of a submittal
for review and comment, the Engineer shall review the submittal and return two
copies to the Contractor. The returned submittal shall indicate one of the following
actions:
SUBMITTALS
01800-3
F&V Project No.9? 12401
Oigester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
1. If the review indicates that the material, equipment or work method complies with
the project manual, submittal copies will be marked No Exception Taken. In this
event, the Contractor may begin to implement the work method or incorporate the
material or equipment covered by the submittal.
2. If the review indicates limited corrections are required, copies will be marked Make
Corrections Noted. The Contractor may begin implementing the work method or
incorporating the material and equipment covered by the submittal in accordance with
the noted corrections. Where submittal information will be incorporated in O&M data,
a corrected copy shall be provided.
3. If the review reveals that the submittal is insufficient or contains incorrect data,
copies will be marked Revise and Resubmit. Except at his own risk, the Contractor
shall 'lot undertake work covered by this submittal until it has been revised,
resubmitted and returned marked either No Exception Taken or Make Corrections
Noted.
4. If the review indicates that the material, equipment, or work method does not
comply with the project manual, copies of the submittal will be marked Rejected.
Submittals with deviations which have not been identified clearly may be rejected.
Except at his own risk, the Contractor shall not undertake the work covered by such
submittals until a new submittal is made and returned marked either No Exception
Taken or Make Corrections Noted.
C. SUBMITTALS (PRODUCT DATA) FOR INFORMATION ONLY:
Such information is not subject to submittal review procedures and shall be provided
as part of the work under this contract and its acceptability determined under normal
inspection procedures.
...
6.01 EFFECT OF REVIEW OF CONTRACTOR'S SUBMITTALS:
Review of contract drawings, methods of work, or information regarding materials or
equipment the Contractor proposed to provide, shall not relieve the Contractor of his
responsibility for errors therein and shall not be regarded as an assumption of risks or
liability by the Engineer or the Owner, or by any officer or employee thereof, and the
Contractor shall have no claim under the contract on account of the failure, or partial
failure, of the method of work, material, or equipment so reviewed. A mark of No
Exception Taken or Make Corrections Noted shall mean that the Owner has no objection
to the Contractor, upon his own responsibility, using the plan or method of work
proposed, or providing the materials or equipment proposed.
END OF SECTION 01800
SUBMITTALS
018004
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
01800-A
SUBMITTAL TRANSMITTAL FORM
SUBMITTAL NO.:
CONTRACT NO.:
SPEC. SECTION:
FROM:
I
DATE:
TO:
I
I
ATTENTION:
THE FOllOWING MATERIAL IS TRANSMITTED FOR SUBMITTAL REVIEW
I
NO.
DATE
COPIES
DESCRIPTION/EQUIPMENT NO.
I
I
I
WE HAVE VERIFIED THAT THE MATERIAL TRANSMITTED HEREIN IS IN COMPLIANCE WITH THE
SPECIFICA TIONS
I
_ with no exceptions
_ except for the following deviations
NO.
DEVIA TION
I
I
I
I
CONTRACTOR'S SIGNATURE
NO EXCEPTION MAKE CORRECTIONS
TAKEN NOTED
REJECTED REVISE AND RESUBMIT
Checking is only for general conformance with the design
concept of the project and general compliance with the
information given in the contract documents. Any action
shown is subject to the requirements of the plans and
specifications. Contractor is responsible for: Dimensions
which shall be confirmed and correlated at the job site:
fabrication processes and techniques of construction:
coordination of his work with that of any other trades and the
satisfactory performance of his work.
I
I
I
I
FREEMAN & VAUGHN ENGINEERING, INC.
Date:
By:
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
01800-8
PRODUCT DATA TRANSMITTAL FORM
DATE:
TO:
PRODUCT DATA NO.:
CONTRACT NO.:
SPEC. SECTION:
FROM:
ATTENTION:
THE FOLLOWING MATERIAL IS TRANSMITTED AS PRODUCT DATA
NO. DATE COPIES DESCRIPTION/EQUIPMENT NO.
~
WE HAVE VERIFIED THAT THE MATERIAL TRANSMITTED HEREIN IS IN COMPLIANCE WITH THE SPECIFICATIONS
CONTRACTOR:
SIGNATURE
TITLE
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia .
SECTION 02050 - DEMOLITION
PART 1 - GENERAL:
1.01 RELATED DOCUMENTS:
A. Drawings and general provisions of Contract, including General and Supplementary
Conditions and Division-1 Specification sections, apply to work of this section.
1.02 DESCRIPTION OF WORK:
A. Extent of demolition work is indicated on drawings.
Demolition includes all operations necessary for demolition of the existing piping,
equipment, structures, and utilities as shown.
B. Cuttino non-structural concrete floors and masonry walls for underground piping and
ducts, and for above grade piping, ducts, and conduit is included with the work of the
respective mechanical and electrical Divisions 15 and 16 specification sections.
C. Cutting holes in existing prestressed concrete tanks for installation of digester mxing
equipment is specified in Division 11 sections.
D. Cleaning of existing digesters and disposal of digester contents is specified in Section
02190.
1.03 SUBMITIALS:
A. Schedule: Submit schedule indicating proposed methods and sequence of operations
for demolition work to Owner's Representative for review prior to commencement of
. work. Include coordination for shut-off, capping, and continuation of utility services as
iequired, together with details for dust and noise control protection. The procedures
shall provide for safe conduct of the work, careful removal and disposition of materials
specified to be salvaged, protection of property which is to remain undisturbed,
coordination with other work in progress, and timely disconnection of utility services.
The submittal shall include a detailed description of the methods and"equipment to be
used for each operation, and the sequence of operation.
Provide detailed sequence of demolition and removal work to ensure uninterrupted
progress of Owner's on-site operations.
Coordinate with Owner's continuing occupation of portions of existing structures.
DEMOLITION
2050-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1.04 JOB CONDITIONS:
A. Occupancy: Owner will be continuously occupying areas of the structures immediately
adjacent to areas of selective demolition. Conduct selective demolition work in manner
that will minimize need for disruption of Owner's normal operations. Provide minimum
Lif 72 hours advance notice to Owner of demolition activities which will severely impact
Owner's normal operations.
B. Condition of Structures: Owner assumes no responsibility for actual condition of items
or structures to be demolished.
Conditions existing at time of commencement of contract will be maintained by Owner
insofar as practicable. However, variations within structure may occur by Owner's
removal and salvage operations prior to start of selective demolition work.
C. Partial Demolition and Removal: Items indicated to be removed but of salvable value to
Contractor may be removed from structure as work progresses. Transport salvaged
items from site as they are removed.
Storage or sale of removed items on site will not be permitted.
D. Protections: Provide temporary barricades and other forms of protection as required to
protect Owner's personnel and general public from injury due to selective demolition
work.
Provide protective measures as required to provide free and safe passage of Owner's
personnel and general public to and from occupied portions of building.
Erect temporary covered passageways as required by authorities having jurisdiction.
-
~ro.vide interior and exterior shoring, bracing, or support to prevent movement,
settlement, or collapse of structure or element to be demolished, and adjacent facilities
or work to remain.
Protect from damage existing finish work that is to remain in place and becomes
exposed during demolition operations.
Protect floors with suitable coverings when necessary.
Construct temporary insulated solid dustproof partitions where required to separate
areas where noisy or extensive dirt or dust operations are performed. Equip partitions
with dustproof doors and security locks if required.
DEMOLITION
2050-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
.
-
=
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Provide temporary weather protection during interval between demolition and removal
of existing construction on exterior surfaces, and installation of new construction to
insure that no water leakage or damage occurs to structure or interior areas of existing
building.
~emove protections at completion of work.
E. Damaqes: Promptly repair damages caused to adjacent facilities by demolition work at
no cost to Owner.
F. Traffic: Conduct selective demolition operations and debris removal in a manner to
ensure minimum interference with plant roadways, walks, and other adjacent occupied
or used facilities.
Do not close, block or otherwise obstruct plant roadways, walks or other occupied or
used facilities without written permission from authorities having jurisdiction. Provide
alternate routes around closed or obstructed traffic ways if required by governing
regulations.
G. Explosives: Use of explosives will not be permitted.
H. Utility Services: Maintain existing utilities indicated to remain, keep in service, and
protect against damage during demolition operations.
Do not interrupt existing utilities serving occupied or used facilities, except when
authorized in writing by authorities having jurisdiction. Provide temporary services
during interruptions to existing utilities, as acceptable to governing authorities.
I. Environmental Controls: Use water sprinkling, temporary enclosures, and other suitable
methods to limit dust and dirt rising and scattering in air to lowest practical level.
. COR1ply with governing regulations pertaining to environmental protection.
Do not use water when it may create hazardous or objectionable conditions such as ice,
flooding, and pollution.
J. NESHAP Compliance: The Contractor is responsible for being aware of and complying
with the National Emission Standard for Hazardous Air Pollutants (NESHAP) Section
112 of the Federal Clean .Air Act regarding asbestos.
PART 2 - PRODUCTS:
(Not Applicable).
DEMOLITION
2050-3
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
PART 3 - EXECUTION
3.01 INSPECTION:
A. Prior to commencement of demolition work, inspect areas in which work will be
p-erformed. Photograph existing conditions to structure surfaces, equipment or to
surrounding properties which could be misconstrued as damage resulting from
selective demolition work; file with Owner's Representative prior to starting work.
3.02 PREPARATION:
A. Provide interior and exterior shorinq, bracing, or support to prevent movement,
settlement or collapse of structures to be demolished and adjacent facilities to remain.
Cease operations and notify the Owner's Representative immediately if safety of
structure appears to be endangered. Take precautions to support structure until
determination is made for continuing operations.
B. Cover and protect furniture, equipment and fixtures to remain from soiling or damage
when demolition work is performed in rooms or areas from which such item have not
been removed.
C. Erect and maintain dust-proof partitions and closures as required to prevent spread of
dust or fumes to occupied portions of the building.
Provide weatherproof closures for exterior openings resulting from demolition work.
D. Locate, identify. stub off and disconnect utility services that are not indicated to remain.
Provide by-pass connections as necessary to maintain continuity of service to occupied
-areas of building. Provide minimum of 72 hours advance notice to Owner ifshut-down
of service is necessary during change-over.
3.03 DEMOLITION:
A. Perform selective demolition work in a systematic manner. Use such methods as
required to complete work indicated on Drawings in accordance with demolition
schedule and governing regulations.
Demolish concrete and masonry in small sections. Cut concrete and masonry at
junctures with construction to remain using power-driven masonry saw or hand tools; do
not use power-driven impact tools.
DEMOLITION
2050-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Locate demolition equipment throughout structure and promptly remove debris to avoid
imposing excessive loads on supporting walls, floors or framing.
The use of burning at the project site for the disposal of refuse and debris will not be
permitted.
Demolish foundation walls to a depth of not less than 12" below existing ground surface
where indicated to be removed. Demolish and remove below-grade wood or metal
construction. Break up below-grade concrete slabs.
For interior slabs on grade, use removal methods that will not crack or structurally
disturb adjacent slabs or partitions. Use power saw where possible.
Completely fill below-grade areas and voids resulting from demolition work. Provide fill
consisting of approved earth, gravel or sand, free of trash and debris, stones over 6"
diameter, roots or other organic matter.
B. If anticipated mechanical, electrical or structural elements which conflict with intended
function or design are encountered, investigate and measure both nature and extent of
the conflict. Submit report to Owner's Representative in written, accurate detail.
Pending receipt of directive form Owner's Representative rearrange selective
demolition schedule as necessary to continue overall job progress without delay.
3.04 SALVAGE MATERIALS:
A. SalvaQe Items: Where indicated on Drawings as "Salvage-Deliver to Owner", carefully
remove indicated items, clean, store and turn over to Owner and obtain receipt. In
addition to specific items shown on the drawings, the following equipment is to be
salvaged and delivered to the Owner:
..sludge Recirculation Pumps P7220, P7320, P7420 & P7520
Historic artifacts, including cornerstones and their contents, commemorative plaques
and tables, antiques, and other articles of historic significance remain the property of
the Owner. Notify Owner's Representative if such items are encountered and obtain
acceptance regarding method of removal and salvage for Owner.
3.05 DISPOSAL OF DEMOLISHED MATERIALS:
Remove debris, rubbish and other materials resulting from demolition operations form
building site. Transport and legally dispose of materials off site.
DEMOLITION
2050-5
-.: ....., .. ~
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
If hazardous materials are encountered during demolition operations, comply with
applicable regulations, laws, and ordinances concerning removal, handling and protection
against exposure or environmental pollution.
Burning of removed materials is not permitted on project site.
3.06 CLEAN-UP AND REPAIR:
A. Upon completion of demolition work, remove tools, equipment and demolished
materials from site. Remove protections and leave interior areas broom clean.
B. Repair demolition performed in excess of that required. Return structures and surfaces
to remain to condition existing prior to commencement of selective demolition work.
Repair adjacent construction or surfaces soiled or damaged by selective demolition
work.
END OF SECTION 02050
,;
DEMOLITION
2050-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.97 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia. I
SECTION 02190 - DIGESTER CLEANING
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
Drawings and general provisions of Contract, including General and Supplementary
Conditions and Division-1 Specification sections, apply to work of this section.
1.02 DESCRIPTION OF WORK:
A. The work under this contract includes all labor, material, chemicals, supplies,
equipment, transportation and other incidentals required for the removal, dewatering,
transportation and disposal of all sludge, grit accumulations, rags, hair, grease, plastics
and other debris present in the six anaerobic digesters and high pressure water
cleaning of the interior walls, floor and piping in the digester. The Contractor shall
remove all digester contents encountered, regardless of composition. The Contractor
shall pay all tipping and/or disposal fees.
1.03 JOB CONDITIONS:
A. System Description:
The cylindrical portion of each tank is 100' in diameter with a wall height of 29'-0". The
bottom of the tank is conical, having a depth of 9'-6". The maximum sludge level will be
1 0'-0" above the conical portion of the tank or 8'-6" below the corbels supporting the
floating cover. Project staging requires that a single unit will be available for cleaning
and construction and additional units not available until all work is complete on the
previous digester and the digester placed into operation.
The cover for Digester No. 1 will be removed under this contract. All other digester
covers will remain in-place during the cleaning operations.
B. Protection of Existing Structures and Equipment:
Provide protections necessary to prevent damage to existing structures and equipment.
Protect improvements on adjoining properties and on Owner's property.
Restore damaged components to their original condition, as acceptable to parties
having jurisdiction.
DIGESTER CLEANING
02190-1
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
C. Documentation:
The Contractor shall submit to the Owner for approval the proposed location(s) for
diposal of digester contents. Daily records of the disposal location and quantity must be
provided to the Owner.
01.03 SAFETY REQUIREMENTS:
The Contractor shall comply with all applicable safety standards while conducting work on
this project. Submit a copy of Contractor's confined space entry policy and a statement
certifying that all Contractor employees entering the digester have been trained in confined
space entry.
The Contractor shall treat the digester as a confined, hazardous space at all times.
Maintain continuous atmospheric monitoring while personnel are inside digester for oxygen
levels, percent L.E.L., carbon monoxide, and hydrogen sulfide. Monitoring devices shall
include alarms to automatically warn workers of the onset of dangerous atmospheric
conditions. The digester shall be continuously ventilated. Confined space rescue
equipment shall be continuously in-place and Contractor personnel shall be certified in it's
use.
PART 2 - PRODUCTS
Not applicable to work of this section.
PART 3 - EXECUTION
3.01 DIGESTER CLEANING:
A. General:
--
Schedule digester cleaning services with the Owner. Where operation of the
wastewater treatment facility conflicts with the Contractor's work, the operation of the
plant will take precedence. The Contractor shall limit his work area such as to minimize
conflict with treatment facility operation. All equipment and piping shall be installed in
an approved manner and routed without interference to plant operation and traffic.
Maintain work areas in a clean and workmanlike manner. Provide Spill Prevention and
Control plans for on-site and off-site activities. Spills caused by the activities of the
Contractor shall be controlled and cleaned immediately. Contractor shall not allow any
sludge, free liquids or water from dewatering operations to enter storm drains,
roadways, waterways or public or private land.
Cooperate with other contractors on the site.
DIGESTER CLEANING
02190-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 1240100
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
B. Disposal:
All digester contents, except acceptable dewatering filtrate, shall be removed from the
plant site. The Contractor shall pay tipping fees and provide permits required for
disposal of digester contents. The Owner will designate a discharge point for
'{V9stewater generated by digester cleaning operations. The Contractor shall not return
any sludge, grit, sand, scum or other foreign material to the treatment plant flow or any
natural waterway. Wastewater generated by cleaning operations which are discharged
to the treatment process shall not contain more than 1,000 mgll of suspended solids.
Rates of discharge shall conform to the following additional requirements:
Maximum flow rate
Maximum Suspended Solids
Maximum Biochemical Oxygen Demand BOOs
300 GPM
150 Ib.lhr
100 Ib.lhr
The Contractor shall not use dilution water in an attempt to meet these requirements.
The Contractor shall provide reasonable measurement of flow discharged to plant liquid
stream. The method of flow measurement shall be accurate to within 2: 10 percent of
actual flow. The Owner will check the accuracy periodically.
C. Testinq:
The Owner reserves the right to monitor and test by any means necessary, and at any
time, to verify that the aforementioned limits are not exceeded. Should limits be
exceeded, the Owner may require the Contractor to cease operations and take
necessary steps to reduce loadings.
D. Use of Chemicals:
The Contractor is prohibited from using any chemical which poses a threat to plant
pers~nnel or interferes with plant processes. The Contractor shall furnish the Owner
with Material Safety Data Sheets (MSDS) for each chemical proposed for use on the
project. .
END OF SECTION 02190
DIGESTER CLEANING
02190-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 02200 - EARTHWORK
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
Drawings and general provisions of Contract, including General and Supplementary
Conditions and Division-1 Specification sections, apply to work of this section.
1.02 DESCRIPTION OF WORK:
A. Extent:
Extent of earthwork is indicated on drawings.
Preparation of subgrade for slabs, foundations, walks, and pavements is included as
part of this work.
Backfilling of utility trenches is included as part of this work.
B. Definition:
"Excavation" consists of removal of material encountered to subgrade elevations
indicated and subsequent disposal of materials removed.
1.03 QUALITY ASSURANCE:
A. Codes and Standards:
Perform excavation work in compliance with applicable requirements of governing
authorities having jurisdiction.
. , ...
B. Testinq and Inspection Service:
Owner will engage soil testing and inspection service for quality control testing during
earthwork operations.
1.04 JOB CONDITIONS:
A. Existing Utilities:
Locate existing underground utilities in areas of work. If utilities are to remain in place,
provide adequate means of support and protection during earthwork operations.
EARTHWORK
02200-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Should uncharted, or incorrectly charted, piping or other utilities be encountered during
excavation, consult utility owner immediately for directions. Cooperate with Owner and
utility companies in keeping respective services and facilities in operation. Repair
damaged utilities to satisfaction of utility owner.
Do not interrupt existing utilities serving facilities occupied and used by Owner or others,
during occupied hours, except when permitted in writing by Engineer and then only after
acceptable temporary utility services have been provided.
Provide minimum of 48-hour notice to Engineer, and receive written notice to proceed
before interrupting any utility.
Demolish and completely remove from the site existing underground utilities indicated to
be removed. Coordinate with utility companies for shut-off of services if lines are active.
B. Use of Explosives:
The use of explosives is not permitted.
c. Protection of Persons and Property:
Barricade open excavations occurring as part of this work and post with warning lights.
Operate warning lights as recommended by authorities having jurisdiction.
Protect structures, utilities, sidewalks, pavements, and other facilities from damage
caused by settlement, lateral movement, undermining, washout and other hazards
created by earthwork operations.
Perform excavation within drip-line of large trees to remain by hand, and protect the root
~ystem from damage or dryout to the greatest extent possible. Maintain moist condition
for root system and cover exposed roots with burlap. Paint root cuts of 1" diameter and
larger with emulsified asphalt tree paint.
PART 2 - PRODUCTS
2.01 SOIL MATERIALS:
A. Definitions:
Satisfactory soil materials are defined as those complying with ASTM D2487 soil
classification groups GW, GP, GM, SM, SW and SP.
EARTHWORK
02200-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Unsatisfactory Soil Materials:
Unsatisfactory soil materials are those classified as MH, CH, OH, OL, and Peat in
accordance with the Unified Soil Classification System. Excess water in material will not
be a basis for establishing unsuitable material regardless of gradation.
C. Backfill and Fill Materials:
Satisfactory soil materials free of clay, rock or gravel larger than 2" in any dimension,
debris, waste, frozen materials, vegetable and other deleterious matter.
D. Coarse Granular Beddinq:
Crushed stone or pea gravel, clean and graded, 95 to 100 percent of which shall pass a
3/4 inch sieve with 95 to 100 percent retained on a NO.4 sieve.
PART 3 - EXECUTION
3.01 EXCAVATION:
A. Excavation is Unclassified:
Excavation is Unclassified, and includes excavation to subgrade elevations indicated,
regardless of character of materials and obstructions encountered.
B. Stability of Excavations:
Slope sides of excavations to comply with local codes and ordinances having
jurisdiction. Shore and brace where sloping is not possible because of space restrictions
or stability of material excavated.
,..
-Maintain sides and slopes of excavations in safe condition until completion of backfilling.
C. Shorinq and Bracinq:
Provide materials for shoring and bracing, such as sheet piling, uprights, stringers and
cross-braces, in good serviceable condition. Protective systems for excavation shall
conform to Section 1926.652, 29 CFR Part 1926, Final Rule printed in October 31, 1989
issue of the Federal Register.
Establish requirements for trench shoring and bracing to comply with local codes and
authorities having jurisdiction.
Maintain shoring and bracing in excavations regardless of time period excavations will
be open. Carry down shoring and bracing as excavation progresses.
EARTHWORK
02200-3
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
D. Dewaterinq and Protection Aqainst Water:
Remove water from the site and shall lower the ground water level as necessary to
complete the excavations to the required depths and as required to maintain the
excavations sufficiently dry so that all required work can be accomplished. The
Contractor shall do such well construction, well pointing, sheeting, ditching, diking and
pumping and shall construct necessary drains, channels, sumps and cofferdams to
keep his excavations and new structures clear of ground water, storm water or sewage
and to keep his construction areas dry during the progress of the work and until the
finished work is accepted by the Owner, except as otherwise specified.
The Contractor shall be responsible for the effect of dewatering operations on adjacent
property and for the effect on water supplies located in the vicinity of the project.
Adequate measures and protection shall be provided by the Contractor to protect his
work from damage from uplift due to ground water, storm water, or flood water. Any
damages which may result shall be the Contractor's responsibility.
The Contractor shall accept all responsibility for damage to the work of this Contract
because of floods and water pressures and other water damages and shall accept all
risks of floods and other events which may occur.
All water discharged by pumping operations shall be discharged so as not to interfere
with work under this Contract or with existing structures and operations. Route of
dewatering pipe shall be subject to the Engineer's review. Discharge facilities and
water quality shall comply with applicable regulations of State and Federal agencies.
Dewatering operations shall be uninterrupted and continuous during the course of the
work so as not to endanger any construction in place or to present a hazard to workmen
.in C!nd around the site. The Contractor shall take all measures necessary ingluding, but
not limited to, standby equipment and constant attendance to insure that the dewatering
system remains operational and effective throughout the period of time that it is
req u ired.
E. Material Storaqe:
Stockpile satisfactory excavated materials where directed, until required for backfill or
fill. Place, grade and shape stockpiles for proper drainage.
Locate and retain soil materials away from edge of excavations. Do not store within drip
line of trees indicated to remain.
Dispose of excess soil material and waste materials as herein specified.
EARTHWORK
02200-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I'
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
F. Excavation for Structures:
Conform to elevations and dimensions shown within a tolerance of plus or minus 0.10',
and extending a sufficient distance from footings and foundations to permit placing and
removal of concrete formwork, installation of services, other construction, and for
inspection.
In excavating for footings and foundations, take care not to disturb bottom of
excavation. Excavate by hand to final grade just before concrete reinforcement is
placed. Trim bottoms to required lines and grades to leave solid base to receive other
work.
G. Cold Weather Protection:
Protect excavation bottoms against freezing when atmospheric temperature is less
than 35 deg. F (1 deg. C).
3.02 COMPACTION:
A. General:
Control soil compaction during construction providing minimum percentage of density
specified for each area classification indicated below.
B. Percentaqe of Maximum Density Requirements:
Compact soil to not less than the following percentages of maximum density for soils
which exhibit a well-defined moisture density relationship (cohesive soils) determined in
accordance with ASTM D 1557; and not less than the following percentages of relative
density, determined in accordance with ASTM D 2049, for soils which will not exhibit a
well-defined moisture-density relationship (cohesionless soils).
C. Structures. Buildinq Slabs and Steps. Pavements:
Compact top 12" of subgrade and each layer of backfill or fill material at 95% maximum
density.
D. Lawn or Unpaved Areas:
Compact top 6" of subgrade and each layer of backfill or fill material at 85% maximum
density for cohesive soils and 90% relative density for cghesionless soils.
EARTHWORK
02200-5
EARTHWORK
02200-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
E. Moisture Control:
Where subgrade or layer of soil material must be moisture conditioned before
compaction, uniformly apply water to surface of subgrade, or layer of soil material, to
prevent free water appearing on surface during or subsequent to compaction
operations.
Remove and replace, or scarify and air dry, soil material that is too wet to permit
compaction to specified density.
Soil material that has been removed because it is too wet to permit compaction may be
stockpiled or spread and allowed to dry. Assist drying by discing, harrowing or
pulverizing until moisture content is reduced to a satisfactory value.
3.03 BACKFILL AND FILL:
A. General:
Place acceptable soil material in layers to required subgrade elevations, for each area
classification listed below.
B. In excavations:
Use satisfactory excavated or borrow material.
C. Under qrassed areas:
Use satisfactory excavated or borrow material.
D. Under piping and conduit:
Use Coarse Granular Bedding; shape to fit bottom 90 deg. of cylinder.
H. Backfill excavations:
As promptly as work permits, but not until completion of the following:
Acceptance of construction below finish grade including, where applicable,
dampproofing, waterproofing, and perimeter insulation.
Inspection, testing, approval, and recording locations of underground utilities.
Removal of concrete formwork.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Removal of shoring and bracing, and backfilling of voids with satisfactory materials.
Cut off temporary sheet piling driven below bottom of structures and remove in
manner to prevent settlement of the structure or utilities, or leave in place if required.
Removal of trash and debris.
Permanent or temporary horizontal bracing is in place on horizontally supported
walls.
I. Ground Surface Preparation:
Remove vegetation, debris, unsatisfactory soil materials, obstructions, and deleterious
materials from ground surface prior to placement of fills. Plow strip, or break-up sloped
surfaces steeper than 1 vertical to 4 horizontal so that fill material will bond with existing
surface.
When existing ground surface has a density less than that specified under
"Compaction" for particular area classification, break up ground surface, pulverize,
moisture-condition to optimum moisture content, and compact to required depth and
percentage of maximum density.
J. Placement and Compaction:
Place backfill and fill materials in layers not more than 8" in loose depth for material
compacted by heavy compaction equipment, and not more than 4" in loose depth for
material compacted by hand-operated tampers.
Before compaction, moisten or aerate each layer as necessary to provide optimum
moisture content. Compact each layer to required percentage of maximum dry density
or relative dry density for each area classification. Do not place backfill or fill material on
surfaces that are muddy, frozen, or contain frost or ice.
Place backfill and fill materials evenly adjacent to structures, piping or conduit to
required elevations. Take care to prevent wedging action of backfill against structures
or displacement of piping or conduit by carrying material uniformly around structure,
piping or conduit to approximately same elevation in each lift.
3.04 GRADING:
A. General:
Uniformly grade areas within limits of grading under this section, including adjacent
transition areas. Smooth finished surface within specified tolerances, compact with
uniform levels or slopes between points where elevations are indicated, or between
such points and existing grades.
EARTHWORK
02200-7
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Gradinq Outside Buildinq Lines:
Grade areas adjacent to building lines to drain away from structures and to prevent
ponding.
Finish surfaces free from irregular surface changes, and as follows:
C. Lawn or Unpaved Areas:
Finish areas to receive topsoil to within not more than 0.10' above or below required
subgrade elevations.
D. Walks:
Shape surface of areas under walks to line, grade and cross-section, with finish surface
not more than 0.10' above or below required subgrade elevation.
E. Compaction:
After grading, compact subgrade surfaces to the depth and indicated percentage of
maximum or relative density for each area classification.
3.05 FIELD QUALITY CONTROL:
A. Quality Control Testinq Durinq Construction:
Allow testing service to inspect and approve subgrades and fill layers before further
construction work is performed.
B. Footinq Subqrade:
For each strata of soil on which footings will be placed, conduct at least one test to
verify required design bearing capacities. Subsequent verification and approval of each
footing subgrade may be based on a visual comparison of each subgrade with related
tested strata, when acceptable to Engineer.
C. Foundation Subgrade:
Make at least one field density test of subgrade for every 200 sq. feet of footing area or
building slab, but in no case less than 3 tests. In each compacted fill layer, make one
field density test for every 200 sq. ft. of overlaying foundations or paved area, but in no
case less than 3 tests.
EARTHWORK
02200-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
3.06 MAINTENANCE:
A. Protection of Graded Areas: Protect newly graded areas from traffic and erosion.
Keep free of trash and debris.
Repair and re-establish grades in settled, eroded, and rutted areas to specified
tolerances.
B. Reconditioninq Compacted Areas:
Where completed compacted areas are disturbed by subsequent construction
operations or adverse weather, scarify surface, re-shape, and compact to required
density prior to further construction.
C. Settling:
Where settling is measurable or observable at excavated areas during general project
warranty period, remove surface (pavement, lawn or other finish), add backfill material,
compact, and replace surface treatment. Restore appearance, quality, and condition of
surface or finish to match adjacent work, and eliminate evidence of restoration to
greatest extent possible.
3.09 DISPOSAL OF EXCESS AND WASTE MATERIALS:
A. Removal from Owner's Property:
Remove waste materials, including unacceptable excavated material, trash and debris,
and dispose of it off Owner's property.
END OF SECTION 02200
EARTHWORK
02200-9
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 02210 - EROSION CONTROL
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
Drawings and general provisions of the Contract, including General and Special Conditions,
and Division-1 Specification Sections apply to work of this section.
1.02 DESCRIPTION OF WORK:
Under this section shall be included ai'l measures both temporary and permanent to control
erosion and sedimentation, and protect all surface waters and property both on and off site.
This shall include all labor, materials and equipment necessary to meet the requirements
of this Section.
1.03 EROSION AND SEDIMENTATION ACT - DEFINED:
It is the intent of this Specification that the Project and the Contractor comply with all
applicable requirements of the Erosion and Sedimentation Act of 1975 and the Richmond
County Soil Erosion Ordinance.
The Manual for Erosion and Sediment Control in Georgia further defines practices and
requirements. The Contractor is responsible for maintaining all sediment and erosion
control measures on the project site during construction. The Contractor is responsible for
any damage caused due to failure to implement these requirements. A Soil Erosion and
Sedimentation Control Permit has been obtained by the Owner so that periodic inspections
may be made by the County. The Contractor is to cooperate with the person performing
these inspections.
...
1.04 COORDINATION WITH CONTRACT PLANS:
A Soil Erosion and Sedimentation Control Plan is included in the Contract Documents and
is to be implemented as a part of the procedures necessary to implement requirements of
the Act and Ordinance.
PART 2 - PRODUCTS
Not applicable to this specification section.
EROSION CONTROL
02210-1
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
PART 3 - EXECUTION
3.01 IMPLEMENTATION:
Implementation of the requirements of the Act is based on the following principles:
The disturbed area and the duration of exposure to erosion elements should be
minimized.
Stabilize disturbed areas immediately.
Retain or accumulate runoff.
Retain sediment.
Do not encroach upon watercourses.
3.02 SYMBOLS: -
The Soil Erosion and Sedimentation Control Plan contains standard symbols for the
different types of measures for implementing the Act. These symbols are defined for
conditions, design criteria and construction specifications in Sections II and III of the
Manual.
3.03 SPECIFIC REQUIREMENTS:
All disturbed areas shall be grassed by sodding or seeding, fertilizing, mulching and
watering to obtain a ground cover which prevents soil erosion.
A temporary construction egress pad shall be installed and maintained at any point where
constrCction vehicles enter a public right-of-way, street or parking area. The pad shall be
used to eliminate mud from the construction area onto public rights-of-way. The pad shall
be constructed as shown in the Manual for Erosion and Sediment Control.
All measures installed for sediment control shall be checked at the beginning and end of
eaeh day when construction is occurring to ascertain that the measures are in place and
functioning properly.
END OF SECTION 02210
EROSION CONTROL
02210-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 03310 - CONCRETE WORK
PART 1 - GENERAL
1.01 REI.A TED DOCUMENTS:
. ...,.... ll.. ,-:-
~ -
~.>
Drawings and general provisions of'Contract, including General and Supplementary
Conditions and Division-1 Specification sections, apply to work of this section.
1.02 SUMMARY:
Extent of concrete work is shown on drawings.
1.03 SUBMITTALS:
A. Product Data:
Submit data for proprietary materials and items, including reinforcement and forming
accessories, admixtures, patching compounds, waterstops, joint systems, curing
compounds, dry-shake finish materials, and others as requested by Engineer.
B. Shop Drawinqs: Reinforcement:
Submit original shop drawings for fabrication, bending, and placement of con~rete
reinforcement. Comply with ACI 315 "Manual of Standard Practice for Detailing
Reinforced Concrete Structures" showing bar schedules, stirrup spacing, diagrams of
bent bars, arrangement of concrete reinforcement. Include special reinforcement
required for openings through concrete structures.
C. Labo.ratorv Test Reports:
. ,..
-
Submit laboratory test reports for concrete materials and mix design test.
D. Materials Certificates:
Provide materials certificates in lieu of materials laboratory test reports when permitted
by Engineer. Materials certificates shall be signed by manufacturer and Contractor,
certifying that each material item complies with, or exceeds, specified requirements.
Provide certification from admixture manufacturers that chloride content complies with
specification requirements.
~ .:
CONCRETE WORK
03310-1
F&V Project No.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
1.04 QUALITY ASSURANCE:
A. Codes and Standards:
.,..:~ .~
~ -
~.:>
Comply with provisions of following codes, specifitations, and standards, except where
more stringent requirements are shown or specified:
ACI 301 "Specifications for Structural Concrete for Buildings".
ACI 305 "Hot Weather Concreting-ACI 305R (Rev. 1982)."
ACI 315 "Details and Detailing of Concrete Reinforcement."
ACI 318 "Building Code Requirements for Reinforced Concrete".
ACI 347 "Recommended Practice for Concrete Formwork (ACI 347-78)."
Concrete Reinforcing Steel Institute (CRSI), "Manual of Standard Practice".
B. Concrete Testing Service:
The Owner will engage a testing laboratory to perform material evaluation tests.
C. Materials and Installed Work:
Materials and installed work may require testing and retesting at anytime during
progress of work. Retesting of rejected materials for installed work, shall be done at
Contractor's expense. - .0
- --
..... -
1.05 PROJECT CONDITIONS:
A. Protection of Footinqs Aqainst Freezinq:
Cover completed work at footing level with sufficient temporary or permanent cover as
required to protect footings and adjacent subgrade against possibility of freezing;
maintain cover for time period as necessary.
B. Protection of Finish Materials:
Protect adjacent finish materials against spatter during concrete placement.
. -
. -
CONCRETE WORK
03310-2
I
.1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
PART 2 - PRODUCTS
2.01 FORM MATERIALS:
. -,~.~ :;r..
A. FOrms for Exposed Finish Concrete:
~ ~
Plywood, metal, metal-framed plywood faced, or other acceptable panel-type materials,
to provide continuous, straight, smooth, exposed surfaces. Furnish in largest
practicable sizes to minimize number of joints and to conform to joint system shown on
drawings.
B. Plywood:
Use plywood complying with U.S. Product Standard PS-1"B-B (Concrete Form)
Plywood", Class I, Exterior Grade or better, mill-oiled and edge-sealed, with each piece
bearing legible inspection trademark.
D. Forms for Unexposed Finish Concrete:
Plywood, lumber, metal, or other acceptable material. Provide lumber dressed on at
least 2 edges and one side for tight fit.
E. Form Coatings:
Provide commercial formulation form-coating compounds that will not bond with, stain,
nor adversely affect concrete surfaces, and will not impair subsequent treatments of
concrete surfaces.
F. EorrrLTies:
...
-
Factory-fabricated, adjustable-length, removable or snapoff metal form ties, designed to
prevent form deflection and to prevent spalling concrete upon removal. Provide units
which will leave no metal closer than 1-1/2" to surface.
Provide ties which, when removed, will leave holes not larger than 1" diameter in
concrete surface.
2.02 REINFORCING MATERIALS:
A. Reinforcinq Bars:
"-A-:STM A615, Grade 60, deformed.
CONCRETE WORK
03310-3
F&V Project No.9? 12401
Oigester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia.
B. Steel Wire:
ASTM A82, plain, cold-drawn steel.
.,....~ ;Ii-
C1' -
~>
C. Welded Wire Fabric:
ASTM A 185, welded steel wire fabric.
D. Supports for Reinforcement:
Bolsters, chairs, spacers, and other devices for spacing, supporting, and fastening
reinforcing bars and welded wire fabric in place. Use wire bar type supports complying
with CRSI specifications.
1. For slabs-on-Qrade, use supports with sand plates or horizontal runners where base
material will not support chair legs.
2. For exposed-to-view concrete surfaces, where legs of supports are in contact with
forms, provide supports with legs which are plastic protected (CRSI, Class 1) or
stainless steel protected (CRSI, Class 2).
2.03 CONCRETE MATERIALS:
A. Portland Cement:
ASTM C150, Type II.
Use one brand of cement throughout project, unless otherwise acceptab~ t<LEngineer.
~ ~
,..
B. FIV Ash:
ASTM C618, Type C or Type F.
C. Normal Weight AqqreQates:
ASTM C33, and as herein specified. Provide aggregates from a single source for
exposed concrete.
For exterior exposed surfaces, do not use fine or coarse aggregates containing
spalling-causing deleterious substances.
Aggregates size 467 (1-1/2 inches to No.4) shall be used for the heavier sections
where reinforcement is not closely spaced or close to forms, and aggregates sizes 57 (1
CONCRETE WORK
03310-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
inch to No.4) and 67 (3/4 inch to No.4) shall be used for thinner sections, heavily
reinforced work, and all parts where the coarser aggregate might cause honeycombing,
poor bond or exposed reinforcement.
. Q.: :~atiir
.. -
~ ,.
Potable and free of substances that may be deleterious to concrete or steel.
E. Air-Entraininq Admixture:
ASTM C260, certified by manufacturer to be compatible with other required admixtures.
1. Available Products: Subject to compliance with requirements, products which may
be incorporated in the work include, but are not limited to, the following:
"Air-Mix"; Euclid Chemical Co.
"Sika Aer"; Sika Corp.
"MB-VR or MB-AE"; Master Builders.
"Oarex AEA" or "Daravair"; W.R. Grace.
"Edoco 2001 or 2002"; Edoco Technical Products.
"Air- Tite"; Gifford-Hill/American Admixtures.
F. Water-Reducing Admixture:
ASTM C494, Type A, and containing not more than 0.1 percent chloride ions.
1. Available Products: Subject to compliance with requirements, products which may
be incorporated in the work include, but are not limited to, the following:
.'-' ~WRDA Hyco/"; W.R. Grace.
~ "PSI N"; Gifford-Hill/American Admixtures
"Eucon WR-75"; Euclid Chemical Co.
"Pozzolith Normal"; Master Builders.
"Plastocrete 160"; Sika Chemical Corp.
"Chemtard"; Chem-Masters Corp.
"Pro-Kete-N"; Protex Industries, Inc.
-'
G. Prohibited Admixtures:
Calcium chloride thyocyanates or admixtures containing more than 0.1 percent chloride
ions are not permitted.
':. ..:
CONCRETE WORK
03310-5
F&V Project NO.9? 124 01
Oigester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
H. Fibrous Reinforcement:
Collated, fibrillated, polypropylene fibers for secondary reinforcement of concrete slabs.
"~ .~ ~~ilable Products: Subject to compliance with requirements, ProdUC: ;hich may
be incorporated in the work include, but are not limited to, the following:
"Forta CR"; Forta Corp.
"Fibermesh"; Fibermesh, Inc.
2.04 RELATED MATERIALS:
A. Reqlets:
Where resilient or elastomeric sheet flashing or bituminous membranes are terminated
in reglets, provide reg lets of not less than 26 gage galvanized sheet steel. Fill reg let or
cover face opening to prevent intrusion of concrete or debris.
B. Waterstops:
Provide waterstops where shown. Also provide waterstops in all expansion joints and in
construction joints as required to make structures watertight.
Provide 6-inch high polyvinylchloride waterstops. Polyvinylchloride waterstop's of
expansion joints shall be centerbulb type equal to No. 7C by W.R. Grace and Company,
or No. 9380LB by Sonneborn-Contech, or equal and as specified. Polyvinylchloride
waterstops for construction joints shall be NO.3 by W.R. Grace and Company, or No.
4316 by Sonneborn-Contech, or equal, and as specified herein. Polyvinylchl<~ride
waterstops have the following properties: _
--, ~
~
Tensile Strength (ASTM D412) 2000 psi min.
Ultimate Elongation (ASTM 0412) 350 Percent min.
Low Temperature Brittleness (ASTM 0746) -35 Degrees F.
C. Granular Base:
Evenly graded mixture of fine and coarse aggregates to provide, when compacted, a
smooth and even surface below slabs on grade.
D. Vapor Retarder:
Provide vapor retarder' cover over prepared base material where indicated below slabs
on grade. Use only materials which are resistant to decay when tested in accordance
with ASTM E154, as follows:
CONCRETE WORK
03310-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
1. Polvethvlene Sheet not less than 6 mils thick.
2. Water Resistant Barrier Paper consisting of heavy Kraft papers laminated together
._,.. ~th .Q!.ass fiber reinforcement and over-coated with black polyethylene o~ach side.
~ -
E. Non-Shrink Grout:
CRD-C621, factory pre-mixed grout.
1. Available Products: Subject to compliance with requirements, products which may
be incorporated in the work include, but are not limited to, the following:
a. Metallic
"Vibrofoil"; A.C. Horn, Inc.
"Metallic Spec. Grout"; The Burke Co.
"Embeco 636"; Master Builders.
b. Non-metallic
"Set Grout"; Master Builders.
"Sonogrout"; Sonneborn-Rexnord.
"Euco-NS"; Euclid Chemical Co.
"Five Star Grout"; U.S. Grout Corp.
F. Absorptive Cover:
Burlap cloth made from jute ,or kenaf, weighing approximately 9 oz. per sq. yd.,
.c9f!)pJying with AASHTO M182, Class 2. _ ~
G. Moisture-Retaininq Cover:
One of the following I complying with ASTM C 171.
Waterproof paper.
Polyethylene film.
Polyethylene-coated burlap.
'":. -'
CONCRETE WORK
03310-7
CONCRETE WORK
03310-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
H. Liquid Membrane-Forminq Curinq Compound:
Liquid type membrane-forming curing compound complying with ASTM C309, Type I,
..~ ~asW'. Moisture loss not more than 0.055 gr./sq. cm. when applied at ~ ~q ft./gal.
1. Available Products: Subject to compliance with requirements, products which may
be incorporated in the work include, but are not limited to, the following:
"Masterseal"; Master Builders.
"A-H 3 Way Sealer"; Anti-Hydro Waterproofing Co.
"Ecocure"; Euclid Chemical Co.
I. Bonding Compound:
Polyvinyl acetate or acrylic base.
1. Available Products: Subject to compliance with requirements, products which may
be incorporated in the work include, but are not limited to, the following:
2. Polyvinyl Acetate (Interior Only):
"Euco Weld"; Euclid Chemical Co.
"Weldcrete"; Larsen Products Corp.
3. Acrylic or Styrene Butadiene:
"J-40 Bonding Agent"; Dayton Superior Corp.
"Everbond"; L & M Construction Chemicals.
- ~Hornweld"; A.C. Horn, Inc.
-
J. Epoxy Adhesive:
ASTM C881, two component material suitable for use on dry or damp surfaces.
Provide material "Type", "Grade", and "Class" to suit project requirements.
1. Available Products: Subject to compliance with requirements, products which may
be incorporated in the work include, but are not limited to, the following:
"Thiopoxy"; W.R. Grace.
"Epoxtite"; A.C. Horn, Inc.
'~Sikadur Hi-Mod"; Sika Chemical Corp.
"Euco Epoxy 452 or 620"; Euclid Chemical Co.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
2.05 PROPORTIONING AND DESIGN OF MIXES:
A. Desiqn Mixes:
Prepgre design mixes for each type and strength of concrete by either lab$ratory trial
",,~.~tCftor field experience methods as specified in ACI 301. Iftrial batch method used,
use an independent testing facility acceptable to Engineer for preparing and reporting
proposed mix designs. The testing facility shall not be the same as used for field quality
control testing.
Limit use of fly ash to not exceed 25 percent of cement content by weight.
B. Written Reports:
Submit written reports to Engineer of each proposed mix for each class of concr~te at
least 15 days prior to start of work. Do not begin concrete production until mixes have
been reviewed by Engineer
C. Design Mixes:
Design mixes to provide normal weight concrete with the following properties, as
indicated on drawings and schedules:
4000 psi 28-day compressive strength; W/C ratio, 0.44 maximum
(non-air-entrained), 0.35 maximum (air-entrained).
D. Adiustment to Concrete Mixes:
Mix design adjustments may be requested by Contractor when characteristics of
materials, job conditions, weather, test results, or other circumstances war,rant; at no
aadiuonal cost to Owner and as accepted by Engineer. Laboratory test data.for revised
mix design and strength results must be submitted to and accepted by Engineer before
using in work.
E. Admixtures:
1. Use water-reducinq admixture or high range water-reducing admixture (super
plasticizer) in concrete as required for placement and workability.
2. Use non-chloride accelerating admixture in concrete slabs placed at ambient
temperatures below 50 deg F (10 deg C).
3. Use air-entraininq admixture in exterior exposed concrete, unless otherwise
indicated. Add air-entraining admixture at manufacturer's prescribed rate to result in
CONCRETE WORK
03310-9
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
concrete at point of placement having total air content with a tolerance of plus-or-minus
1-112 percent within following limits:
Concrete structures and slpbs exposed to freezing and thawing, deice~chemicals, or
,~ ~bj3fted to hydraulic pressure: -. >
4.5 percent 1-1/2" max. aggregate.
5. Use admixtures for water-reducing and set-control in strict compliance with
manufacturer's directions.
G. Water-Cement Ratio:
Provide concrete with maximum water-cement (W/C) ratio of 0.45.
H. Slump Limits:
Proportion and design mixes to result in concrete slump not more than 4".
2.06 CONCRETE MIXING:
A. Readv-Mix Concrete:
Comply with requirements of ASTM C 94, and as herein specified.
During hot weather, or under conditions contributing to rapid setting of concrete, a
shorter mixing time than specified in ASTM C 94 may be required.
PART 3 - EXECUTION
- --
---.. .~
3.01 GENERAL:
Coordinate the installation of joint materials and vapor retarders with placement of forms
and reinforcing steel.
3.02 FORMS:
A. Maintenance:
Design, erect, support, brace, and maintain formwork to support vertical and lateral,
static, and dynamic loads that might be applied until such loads can be supported by
Gon_crete structure. Construct formwork so concrete members and structures are of
correct size, shape, alignment, elevation, and position. Maintain formwork construction
tolerances complying with ACI 347.
CONCRETE WORK
03310-10
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
B. Desiqn:
Design formwork to be readily removable without impact, shock, or damage to
c~st-il)-place concrete surfaces and adjacent materials. ~ ,.
.."......~ ~
- -
C. Construct:
Construct forms to sizes, shapes, lines, and dimensions shown, and to obtain accurate
alignment, location, grades, level and plumb work in finished structures. Provide for
openings, offsets, sinkages, keyways, recesses, moldings, rustications, reg lets,
chamfers, blocking, screeds, bulkheads, anchorages and inserts, and other features
required in work. Use selected materials to obtain required finishes. Solidly butt joints
and provide back-up at joints to prevent leakage of cement paste.
D. Temporary Openinqs:
Provide temporary openings where interior area of formwork is inaccessible for
c1eanout, for inspection before concrete placement, and for placement of concrete.
Securely brace temporary openings and set tightly to forms to prevent loss of concrete
mortar. Locate temporary openings on forms at inconspicuous locations.
E. Exposed Corners and Edges:
Chamfer exposed corners and edges as indicated, using wood, metal, PVC, or rubber
chamfer strips fabricated to produce uniform smooth lines and tight edge joints.
F. Provisions for Other Trades:
-
Provide openings in concrete formwork to accommodate work of other tr~s.
Determine size and location of openings, recesses, and chases from trades fMoviding
such items. Accurately place and securely support items built into forms.
G. Cleaninq and Tighteninq:
Thoroughly clean forms and adjacent surfaces to receive concrete. Remove chips,
wood, sawdust, dirt, or other debris just before concrete is placed. Retightening forms
and bracing after concrete placement is required to eliminate mortar leaks and maintain
proper alignment.
3.03 VAPOR RETARDER INSTALLATION:
A. Following leveling and tamping of granular base for slabs on grade, place vapor retarder
sheeting with longest dimension parallel with direction of pour.
CONCRETE WORK
03310-11
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
B. Lap joints 6" and seal with appropriate tape.
C. After placement of moisture barrier, cover with granular material and comJ?jlct to depth
~ -~ -.,~
.~ ~ stmwn on drawings.-
3.04 PLACING REINFORCEMENT:
A. Comply with Concrete Reinforcing Steel Institute's recommended practice for "Placing
Reinforcing Bars", for details and methods of reinforcement placement and supports,
and as herein specified.
Avoiding cutting or puncturing vapor retarder during reinforcement placement and
concreting operations.
B. Clean reinforcement of loose rust and mill scale, earth, ice, and other materials which
reduce or destroy bond with concrete.
C. Accurately position, support, and secure reinforcement against displacement by
formwork, construction, or concrete placement operations. Locate and support reinforc-
ing by metal chairs, runners, bolsters, spacers, and hangers, as required.
D. Place reinforcement to obtain at least minimum coverages for concrete protection.
Arrange, space, and securely tie bars and bar supports to hold reinforcement'in position
during concrete placement operations. Set wire ties so ends are directed into concrete,
not toward exposed concrete surfaces.
E. Install welded wire fabric in as long lengths as practicable. Lap adjoining pieces at least
one full mesh and lace splices with wire. Offset end laps in adjacent widths to prevent
c.9ntinuous laps in either direction. - -=
3.05 JOINTS:
A. Construction Joints:
Locate and install construction joints as indicated or, if not indicated, locate so as not to
impair strength and appearance of the structure, as acceptable to Engineer.
B. Kevways:
Provide keyways at least 1-1/2" deep in construction joints in walls, slabs, and between
walls and footings; accepted bulkheads designed for this purpose may be used for
slabs.
CONCRETE WORK
03310-12
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
C. Construction Joints:
Place constru~tion joints perpendicular to main reinforcement. Continue reinforcement
acros.~ construction joints, except as otherwise indicated. ~ ~
.,..:1;0. jlii;.-
~ -
D. Waterstops:
Provide waterstops in construction joints and expansion joints as indicated. All joints in
liquid holding concrete tanks, channels or troughs shall receive waterstop. Install
waterstops to form continuous diaphragm in each joint. Make provisions to support and
protect exposed waterstops during progress of work. Fabricate field joints in waterstops
in accordance with manufacturer's printed instructions.
E. Isolation Joints in Slabs-on-Ground:
Construct isolation joints in slabs-on-ground at points of contact between
slabs-on-ground and vertical surfaces, such as column pedestals, foundation walls,
grade beams, and elsewhere as indicated.
F. Joint Filler and Sealant:
Joint filler and sealant materials are specified in Division-7 sections of these
specifications.
G. Contraction (Control) Joints in Slabs-on-Ground:
Construct contraction joints in slabs-on-ground to form panels of patterns as shown.
Use saw cuts 1/8" x 1/4 slab depth or inserts 1/4" wide x 1/4 of slab depth, unless
otherwise indicated. '-
- -
-. -r-
H. Contraction Joints:
Form contraction joints by inserting premolded plastic, hardboard or fiberboard strip into
fresh concrete until top surface of strip is flush with slab surface. Tool slab edges round
on each side of insert. After concrete has cured, remove inserts and clean groove of
loose debris.
Contraction joints in unexposed floor slabs may be formed by saw cuts as soon as
possible after slab finishing as may be safely done without dislodging aggregate.
If joint pattern not shown, provide joints not exceeding 15' in either direction and located
to conform to bay spacing wherever possible (at column centerlines, half bays,
third-bays).
CONCRETE WORK
03310-13
F&V Project No.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
I. Joint Sealant Material:
.,.. -Jf>infSealant material is specified in Division-7 sections of these specifications.
3.06 INSTALLATION OF EMBEDDED ITEMS:
A. General:
Set and build into work anchorage devices and other embedded items required for other
work that is attached to, or supported by, cast-in-place concrete. Use setting drawings,
diagrams, instructions, and directions provided by suppliers of items to be attached
thereto.
3.07 PREPARATION OF FORM SURFACES:
Clean re-used forms of concrete matrix residue, repair and patch as required to return
forms to acceptable surface condition.
Coat contact surfaces of forms with a form-coating compound before reinforcement is
placed.
Thin form-coating compounds only with thinning agent of type, amount, and under
conditions of form-coating compound manufacturer's directions. Do not allow excess
form-coating material to accumulate in forms or to come into contact with in-place concrete
surfaces against which fresh concrete will be placed. Apply in compliance with
manufacturer's instructions.
Coaj steel forms with a non-staining, rust-preventative form oil or otherwise protect against
rusting. Rust-stained steel formwork is not acceptable. --
3.08 CONCRETE PLACEMENT:
A. Replacement Inspection:
Before placing concrete, inspect and complete formwork installation, reinforcing steel,
and items to be embedded or cast-in. Notify other crafts to permit installation of their
work; cooperate with other trades in setting such work. Moisten wood forms
immediately before placing concrete where form coatings are not used.
f:\pply temporary protective covering to lower 2' of finished walls adjacent to poured floor
slabs and similar conditions, and guard against spattering during placement.
CONCRETE WORK
03310-14
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
B. General:
Comply with ACI 304 "Recommended Practice for Measuring, Mixing, Transporting, and
Placing Concrete", and as herein specified.
~
. ,.. ~p~t concrete continuously or in layers of such thickness that no concret: will be
placed on concrete which has hardened sufficiently to cause the formation of seams or
planes of weakness. If a section cannot be placed continuously, provide construction
joints as herein specified. Deposit concrete as nearly as practicable to its final location
to avoid segregation.
C. Placing Concrete in Forms:
Deposit concrete in forms in horizontal layers not deeper than 24" and in a manner to
avoid inclined cons~ruction joints. Where placement consists of several layers, place
each layer while preceding layer is still plastic to avoid cold joints.
D. Placed Concrete:
Consolidate placed concrete by mechanical vibrating equipment supplemented by
hand-spading, rodding, or tamping. Use equipment and procedures for consolidation of
concrete in accordance with ACI 309.
E. Vibrators:
Do not use vibrators to transport concrete inside forms. Insert and withdraw vibrators
vertically at uniformly spaced locations not farther than visible effectiveness of machine.
Place vibrators to rapidly penetrate placed layer and at least 6" into preceding layer.
Do not insert vibrators into lower layers of concrete that have begun to set. At each
insertion limit duration of vibration to time necessary to consolidate concrEll,e ~nd
cemPfete embedment of reinforcement and other embedded items without causing
segregation of mix.
F. Placinq Concrete Slabs:
Deposit and consolidate concrete slabs in a continuous operation, within limits of
construction joints, until the placing of a panel or section is completed.
G. Concrete:
Consolidate concrete during placing operations so that concrete is thoroughly worked
around reinforcement and other embedded items and into corners.
CONCRETE WORK
03310-15
CONCRETE WORK
03310-16
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
H. Slab Surfaces:
Bring slab surfaces to correct level with straightedge and strikeoff. Use bull floats or
darbies to smooth surface, free of humps or hollows. Do not disturb slab ~rfaces prior
... t~b~inning finishing operations. -. ~
I. Reinforcinq:
Maintain reinforcing in proper position during concrete placement operations.
J. Cold Weather Placinq:
Protect concrete work from physical damage or reduced strength which could be
caused by frost, freezing actions, or low temperatures, in compliance with ACI 306 and
as herein specified.
1. When air temperature has fallen to or is expected to fall below 40 deg F (4 deg C),
uniformly heat water and aggregates before mixing to obtain a concrete mixture
temperature of not less than 50 deg F (10 deg C), and not more than 80 deg F (27 deg
C) at point of placement.
2. Do not use frozen materials or materials containing ice or snow. Do not place
concrete on frozen subgrade or on subgrade containing frozen materials.
3. Do not use calcium chloride, salt, and other materials containing antifreeze agents
or chemical accelerators, unless otherwise accepted in mix designs.
K. Hot Weather Placinq:
When hot weather conditions exist that would seriously impair quality andStr1mgth of
c~ncrete, place concrete in compliance with ACI 305 and as herein specified-:-
1. Cool ingredients before mixing to maintain concrete temperature at time of
placement below 90 deg F (32 deg C). Mixing water may be chilled, or chopped ice
may be used to control temperature provided water equivalent of ice is calculated to
total amount of mixing water. Use of liquid nitrogen to cool concrete is Contractor's
option.
2. Cover reinforcing steel with water-soaked burlap if it becomes too hot, so that steel
temperature will not exceed the ambient air temperature immediately before
embedment in concrete.
-
3. Fog spray forms, reinforcing steel, and subgrade just before concrete is placed.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
4. Use water-reducing retarding admixture (Type D) when required by high
temperatures, low humidity, or other adverse placing conditions.
3.09 FINISH OF FORMED SURFACES:
A~~~u3f1 Form Finish:
--t",
For formed concrete surfaces not exposed-to-view in the finish work or by other
construction, unless otherwise indicated. This is the concrete surface having texture
imparted by form facing material used, with tie holes and defective areas repaired and
patched and fins and other projections exceeding 1/4" in height rubbed down or chipped
off.
B. Smooth Form Finish:
For formed concrete surfaces exposed-to-view, or that are to be covered with a coating
material applied directly to concrete, or a covering material applied directly to concrete,
such as waterproofing, dampproofing, veneer plaster, painting, or other similar system.
This is as-cast concrete surface obtained with selected form facing material, arranged
orderly and symmetrically with a minimum of seams. Repair and patch defective areas
with fins or other projections completely removed and smoothed.
C. Grout Cleaned Finish:
Provide grout cleaned finish to scheduled concrete surfaces which have received
smooth form finish treatment.
Combine one part portland cement to 1-1/2 parts fine sand by volume, and mix with
water to consistency of thick paint. Blend standard portland cement and white portland
cement, amounts determined by trial patches, so that final color of dry grout will match
__'. 'r- ~ -
ooJacent surfaces. __
Thoroughly wet concrete surfaces and apply grout to coat surfaces and fill small holes.
Remove excess grout by scraping and rubbing with clean burlap. Keep damp by fog
spray for at least 36 hours after rubbing.
D. Related Unformed Surfaces:
At tops of walls, horizontal offsets, and similar unformed surfaces occurring adjacent to
formed surfaces, strike-off smooth and finish with a texture matching adjacent formed
surfaces. Continue final surface treatment of formed surfaces uniformly across adjacent
unformed surfaces, unless otherwise indicated.
CONCRETE WORK
03310-17
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
3.10 MONOLITHIC SLAB FINISHES:
A. Float Finish:
- , ~~
..~ .A;>plffloat finish to monolithic slab surfaces to receive trowel finish and other finishes as
hereinafter specified, and slab surfaces which are to be covered with membrane or
elastic waterproofing, membrane or elastic roofing, or sand-bed terrazzo, and as other-
wise indicated.
After screeding, consolidating, and leveling concrete slabs, do not work surface until
ready for floating. Begin floating when surface water has disappeared or when concrete
has stiffened sufficiently to permit operation of power-driven floats, or both, Consolidate
surface with power-driven floats, or by hand-floating if area is small or inaccessible to
power units. Check and level surface plane to tolerances of F 18 - F 15. Cut down high
spots and fill low spots. Uniformly slope surfaces to drains. Immediately after leveling,
refloat surface to a uniform, smooth, granular texture.
B. Non-Slip Broom Finish:
Apply non-slip broom finish to exterior concrete platforms, steps, and ramps, and else-
where as indicated.
Immediately after float finishing, slightly roughen concrete surface by brooming with
fiber bristle broom perpendicular to main traffic route. Coordinate required final finish
with Engineer before application.
3.11 CONCRETE CURING AND PROTECTION:
A. General:
- -
..., ...-
P-rotect freshly placed concrete from premature drying and excessive cold orhot
temperatures.
Start initial curing as soon as free water has disappeared from concrete surface after
placing and finishing. Weather permitting, keep continuously moist for not less than 7
days.
Begin final curing procedures immediately following initial curing and before concrete
has dried. Continue final curing for at least 7 days in accordance with ACI 301
procedures. Avoid rapid drying at end of final curing period.
B. Curing Methods:
CONCRETE WORK
03310-18
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Perform curing of concrete by curing and sealing compound, by moist curing, by
moisture-retaining cover curing, and by combinations thereof, as herein specified.
3.12 REMOVAL OF FORMS:
--J, .
A~~ FlrrJ{tork not supportinq weiqht of concrete, such as sides of beams, wall~: 'columns,
and similar parts of the work, may be removed after cumulatively curing at not less than
50 deg F (10 deg C) for 24 hours after placing concrete, provided concrete is sufficiently
hard to not be damaged by form removal operations, and provided curing and pro-
tection operations are maintained.
B. Formwork supporting weight of concrete, such as beam soffits, joists, slabs, and other
structural elements, may not be removed in less than 14 days and until concrete has
attained design minimum compressive strength at 28 days. Determine potential
compressive strength of in-place concrete by testing field-cured specimens repre-
sentative of concrete location or members.
C. Form facinq material may be removed 4 days after placement, only if shores and other
vertical supports have been arranged to permit removal of form facing material without
loosening or disturbing shores and supports.
3.13 MISCELLANEOUS CONCRETE ITEMS:
A. Fillinq-In:
Fill-in holes and openings left in concrete structures for passage of work by other
trades, unless otherwise shown or directed, after work of other trades is in place. Mix,
place, and cure concrete as herein specified, to blend with in-place construction.
Provide other miscellaneous concrete filling shown or required to complete work.
B. CUrbS:
Provide monolithic finish to interior curbs by stripping forms while concrete is still green
and steel-troweling surfaces to a hard, dense finish with corners, intersections, and
terminations slightly rounded.
C. Equipment Bases and Foundations:
Provide machine and equipment bases and foundations, as shown on drawings. Set
anchor bolts for machines and equipment to template at correct elevations, complying
with certified diagrams or templates of manufacturer furnishing machines and
equipment.
CONCRETE WORK
03310-19
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
1. Grout base plates and foundations as indicated, using specified non-shrink grout.
Use non-metallic grout for exposed conditions, unless otherwise indicated.
3.14 CONCRETE SURFACE REPAIRS:
~ .'
...~.io. ~
. -
A. Patchinq Defective Areas:
Repair and patch defective areas with cement mortar immediately after removal of
forms, when acceptable to Engineer.
Cut out honeycomb, rock pockets, voids over 1/4" in any dimension, and holes left by tie
rods and bolts, down to solid concrete but, in no case to a depth of less than 1". Make
edges of cuts perpendicular to the concrete surface. Thoroughly clean, dampen with
water, and brush-coat the area to be patched with specified bonding agent. Place
patching mortar after bonding compound has dried.
1. For exposed-to-view surfaces, blend white portland cement ana standard
portland cement so that, when dry, patching mortar will match color surrounding.
Provide test areas at inconspicuous location to verify mixture and color match before
proceeding with patching. Compact mortar in place and strike-off slightly higher than
surrounding surface.
B. Repair of Formed Surfaces:
Remove and replace concrete having defective surfaces if defects cannot be repaired to
satisfaction of Engineer. Surface defects, as such, include color and texture
irregularities, cracks, spalls, air bubbles, honeycomb, rock pockets; fins and other
projections on surface; and stains and other discolorations that cannot be removed by
cleaning. Flush out form tie holes, fill with dry pack mortar, or precast cement cone
p-Iugs secured in place with bonding agent.
1. Repair concealed formed surfaces, where possible, that contain defects that
affect the durability of concrete. If defects cannot be repaired, remove and replace
concrete.
C. Repair of Unformed Surfaces:
Test unformed surfaces, such as monolithic slabs, for smoothness and verify surface
plane to tolerances specified for each surface and finish. Correct low and high areas as
herein specified. Test unformed surfaces sloped to drain for trueness of slope, in
addition to smoothness using a template having required slope.
1. Repair finished unformed surfaces that contain defects which affect durability of
concrete. Surface defects, as such, include crazing, cracks in excess of 0.01" wide or
CONCRETE WORK
03310-20
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
which penetrate to reinforcement or completely through non-reinforced sections
regardless of width, spalling, pop-outs, honeycomb, rock pockets, and other
objectionable conditions.
2. Correct high areas in unformed surfaces by grinding, after concrete haS cured at
.,~ 'l~asn4 days.
3. Correct low areas in unformed surfaces during or immediately after completion of
surface finishing operations by cutting out low areas and replacing with fresh concrete.
Finish repaired areas to blend into adjacent concrete. Proprietary patching compounds
may be used when acceptable to Engineer.
4. Repair defective areas, except random cracks and single holes not exceeding 1"
diameter, by cutting out and replacing with fresh concrete. Remove defective areas to
sound concrete with clean, square cuts and expose reinforcing steel with at least 3/4"
clearance all around. Dampen concrete surfaces in contact with patching concrete and
apply bonding compound. Mix patching concrete of same materials to provide concrete
of same type or class as original concrete. Place, compact, and finish to blend with
adjacent finished concrete. Cure in same manner as adjacent concrete.
3.17 QUALITY CONTROL TESTING DURING CONSTRUCTION:
A. Testinq:
The Owner will employ a testing laboratory to perform tests and to submit test reports.
Sampling and testing for quality control during placement of concrete may include the
following, as directed by Engineer.
B. ~alTlpling Fresh Concrete:
ASTM C 172, except modified for slump to comply with ASTM C 94.
C. Slump:
ASTM C 143; one test at point of discharge for each day's pour of each type of
concrete; additional tests when concrete consistency seems to have changed.
D. Air Content:
ASTM C 173, volumetric method for lightweight or normal weight concrete; ASTM C 231
pressure method for normal weight concrete; one for each day's pour of each type of
air-entrained concrete.
CONCRETE WORK
03310-21
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
E. Concrete Temperature:
Test hourly when air temperature is 40 deg F (4 deg C) and below, and when 80 deg F
(27 deg C) and above; and each time a set of compression test specime1J3 made.
~-. ......~
.......- .... jiF-- .
... -
F. Compressive Strenqth Tests:
Standard 6-inch diameter compression test cylinders shall be made in the field and
tested in the laboratory in accordance with ASTM C31, C39 and C 172. Test cylinders
shall be made in forms provided by the testing laboratory.
1. Advance tests of the concrete shall be made. Six standard 6-inch compression
cylinders, 3 to be tested in 7 days and 3 at 28 days, shall be made with the propor-
tioning and materials proposed to be used for each of the principal mixes required for
the work. The slump shall not be less than the greatest slump expected to be used in
the structure for each of the mixes. The tests made on the aggregates, as required
above, may be made a part of these tests, if suitably referenced on the reports, which
shall be issued for 7 and 28 day tests. These tests shall be repeated, if necessary,
because of changes in material or unsatisfactory results. The advance testing may be
waived at the request of the Contractor and with the Engineer's approval if the concrete
is being produced by an established ready-mix plant with suitable records of mixes and
testing and if the plant certifies that it will continue to use the same materials involved in
the recorded testing.
2. During the progress of the work, and for each different mix of concrete, a set of three
standard 6-inch concrete cylinders shall be made and tested for each and every day's
operation (or 8-hour shift) where more than 5 cubic yards of concrete are placed. Make
an additional set of three cylinders for each additional 50 cubic yards of concrete where
more than 50 cubic yards are placed in one day (or 8-hour shift). The Contractor shall
be responsible for seeing that these cylinders are made; cast the cylinders iftesting
~boratory personnel are not available. The cylinders of each set shall be molded from
the same sample of concrete and tested, one at 7 days and one at 28 days. If
high-early strength cement is used, then the tests shall be made at 3 and 7 days
instead of at 7 and 28 days.
3. If any test cylinder shows a strength of less than that required at 28 days, then the
concrete represented by such cylinder shall be further tested in accordance with Article
17.3 of ACI 301, except that Paragraph 17.3.2.3 shall not apply. If such further tests
show a compressive strength less than required, then the concrete shall be rejected
and shall be replaced with new work at the specified strength by the Contractor at his
own expense.
4. Test results will be reported in writing to Engineer, Structural Engineer and
Contractor within 24 hours after tests. Reports of compressive strength tests shall con-
CONCRETE WORK
03310-22
I
I
I
I
'I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
tain the project identification name and number, date of concrete placement, name of
concrete testing service, concrete type and class, location of concrete batch in
structure, design compressive strength at 28 days, concrete mix proportions and
materials; compressive breaking strength and type of break for both 7 -day tests and
2~-day tests. ~ __
.-....V'" - ~ }iE-
G. Nondestructive Testinq:
Impact hammer, sonoscope, or other nondestructive device may be permitted but shall
not be used as the sole basis for acceptance or rejection.
H. Additional Tests:
The testing service will make additional tests of in-place concrete when test results
indicate specified concrete strengths and other charact::lristics have not been attained in
the structure, as directed by Engineer. Testing service may conduct tests to determine
adequacy of concrete by cored cylinders complying with ASTM C 42, or by other
methods as directed. Contractor shall pay for such tests when unacceptable concrete is
verified.
END OF SECTION 03310
~. .-
CONCRETE WORK
03310-23
I.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Oigester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 04200 - UNIT MASONRY
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
~-.,.
'..~~ ~.1ii ~
. -
Drawings and general provisions of Contract, including General and Supplementary
Conditions and Division-1 Specification sections, apply to work of this section.
1.02 DESCRIPTION OF WORK:
A. Extent of each type of masonry work is indicated on drawings and schedule.
B. Types of masonry work required include:
1. Brick masonry.
1.03 SUBMITTALS:
A. Product Data:
Submit manufacturer's product data for each type of masonry unit, accessory, and other
manufactured products, including certifications that each type complies with specified
requirements.
1.04 DELIVERY, STORAGE. AND HANDLING:
A. Deliver masonry materials to project in undamaged condition.
B. Store and handle masonry units to prevent their deterioration or damage due. to
~oisture, temperature changes, contaminants, corrosion or other causes:- =-
C. Store cementitious materials off the ground, under cover and in dry location.
D. Store aggregates where grading and other required characteristics can be maintained.
E. Store masonry accessories including metal items to prevent deterioration by corrosion
and accumulation of dirt.
1.06 PROJECT CONDITIONS:
A. Protection of Work: During erection, cover top of walls with waterproof sheeting at end
of each day's work. Cover partially completed structures when work is not in progress.
MASONRY
04200-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Extend cover a minimum of 24 inches down both sides and hold cover securely in
place.
C. Staininq: Prevent grout or mortar or soil from staining the face of masonry to be left
exposed or painted. Remove immediately grout or mortar in contact wit~~ch masonry.
. .~..,.... ~ .-. 1"-
. -
D. Protect base of walls from rain-splashed mud and mortar splatter by means of coverings
spread on ground and over wall surface.
E. Protect sills, ledges and projections from droppings of mortar.
F. Cold Weather Protection:
1. Do not lav masonry units which are wet or frozen.
2. Remove any ice or snow formed on masonry bed by carefully applying heat until top
surface is dry to the touch.
3. Remove masonry damaged by freezing conditions.
4. For clav masonry units with initial rates of absorption (suction) which require them to
be wetted before laying, comply with the following requirements.
a. For units with surface temperatures above 32 deg. F (0 deg. C), wet with water
heated to above 70 deg. F (21 deg. C).
b. For units with surface temperatures below 32 deg. F (0 deg. C), wet with water
heated to above 130 deg. F (54 deg. C).
q. Perform the following construction procedures while masonry work is progressing.
ferAperature ranges indicated below apply to air temperatures existing at tiffie of
installation except for grout. For grout, temperature ranges apply to anticipated
minimum night temp"eratures. In heating mortar and grout materials, maintain mixing
temperature selected within 10 deg. F (6 deg. C).
a. 40 deq. F (4 deg. C) to 32 deq. F (0 deq. C):
1. Mortar: Heat mixing water to produce mortar temperature between 40 deg.
F (4 deg. C) and 120 deg. F (49 deg. C).
b. 32 deq. F (0 deq. C) to 25 deg. F (-4 deq. C):
MASONRY 04200-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1. Mortar: Heat mixing water and sand to produce mortar temperatures
between 40 deg. F (4 deg. C) and 120 deg. F (49 deg. C); maintain
temperature of mortar on boards above freezing.
c. 25 deQ. F (-4 deg. C) to 20 deq. F (-7 deQ. C):
.."...... ~ $it. ~~
~ -
~ .-
1. Mortar: Heat mixing water and sand to produce mortar temperatures
between 40 deg. F (4 deg. C) and 120 deg. F (49 deg. C); maintain
temperature of mortar on boards above freezing.
2. Use windbreaks or enclosures when wind is in excess of 15 mph.
6. Masonry Units: Heat masonry units so that they are above 20 deg. F (-7 deg. C) at
time of laying.
7. Provide enclosure and auxiliary heat to maintain an air temperature of at least 40
deg. F (4 deg. C) for 24 hours after laying units.
8. Do not heat water for mortar and grout to above 160 deg. F (71 deg. C).
9. Protect completed masonry and masonry not being worked on in the following
manner. Temperature ranges indicated apply to mean daily air temperatures except for
grouted masonry. For grouted masonry, temperature ranges apply to anticipated
minimum night temperatures.
a. 40 deq. F (4 deg. C) to 32 deq. F (0 deQ. C): Protect masonry from rain or snow
for at least 24 hours by covering with weather-resistive membrane.
b. 32 deq. F (0 deg. C) to 25 deq. F (-4 deQ. C): Completely cover masonry with
weather-resistive membrane for at least 24 hours.
...
c. 25 deq. F (-4 deQ. C) to 20 deg. F (-7 deq. C): Completely cover masonry with
weather-resistive insulating blankets or similar protection for at least 24 hours, 48
hours for grouted masonry.
d. 20 deq. F (-7 deQ. C) and below: Except as otherwise indicated, maintain
masonry temperature above 32 deg. F (0 deg. C) for 24 hours using enclosures and
supplementary heat, electric heating blankets, infrared lamps or other methods
proven to be satisfactory. For grouted masonry maintain heated enclosure to 40
deg. F (4 deg. C) for 48 hours.
MASONRY
04200-3
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
PART 2 - PRODUCTS
2.01 BRICK MADE FROM CLAY OR SHALE:
~ -~
.." . Iii IF--
A. General:
Brick shall match adjacent surfaces in type, grade and dimension.
2.02 MORTAR MATERIALS:
A. Portland Cement:
ASTM C 150, Type I, except Type III may be used for cold weather construction.
Provide natural cJlor or white cement as required to produce required mortar color.
B. Masonry Cement
ASTM C 91.
C. Water: Clean and potable.
2.03 JOINT REINFORCEMENT. TIES AND ANCHORING DEVICES:
A. Materials:
Comply with requirements indicated below for basic materials and with requirements
indicated under each form of joint reinforcement, tie and anchor for size and.other
characteristics: _.
....
1. Austenitic Stainless Steel Wire: ASTM A 580, AISI Type 304 (UNS S30400) alloy.
a. Application: Use for masonry exposed to exterior and in contact with earth.
2. Zinc-Coated (Galvanized) Steel Sheet: Carbon steel with zinc coating complying
with ASTM A 525, Coating Designation G90.
a. Application: Use for dovetail slots and where indicated.
3. Flexible Anchors: Where flexible anchors are indicated for connecting masonry to
structural framework, provide 2-piece anchors as described below which permit vertical
or horizontal differential movement between wall and framework parallel to, but resist
tension and compression forces perpendicular to, plane of wall.
MASONRY
04200-4
'I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I.
I
I
I
I
I
I
I
I
I
,
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia
a. For anchoraQe to concrete framework, provide manufacturer's standard
anchors with dovetail anchor section formed from 0.1046" (12 gage) thick sheet
metal and triangular-shaped wire tie section sized to extend within 1" of masonry
face.
"...rr. ~~ ~
. -
~~
b. For anchoraqe to steel framework provide manufacturer's standard anchors
with crimped 1/4" diameter wire anchor section for welding to steel and
triangular-shaped wire tie section sized to extend within 1" of masonry face.
1. Wire Size: 0.1875" diameter.
4. Masonry Veneer Anchors: Two-piece assemblies which permit vertical or horizontal
differential movement between wall and framework parallel to, but resist tension and
compression forces perpendicular to, plane of wall; consisting of wire tie section and
metal anchor section for attachment over sheathing to metal studs and complying with
the following requirements:
a. Wire Size: 0.1875" diameter.
b. Wire Tie Shape: Triangular.
c. Wire Tie Length: As required to extend within 1" of masonry veneer face.
5. Dovetail Slots: Furnish dovetail slots, with filler strips, of slot size indicated,
fabricated from 0.0336" (22 gage) sheet metal.
6. Anchor Bolts: Provide steel bolts with hex nuts and flat washers complying with
ASTM A 307, Grade A, hot-dip galvanized to comply with ASTM C 153, Class C, in
sizes and configurations indicated.
2.04 CONCEALED FLASHING MATERIALS:
". ,..-'
-
A. Sheet Metal Flashinq:
Fabricate from the following metal complying with requirements specified in Division-7
section "Flashing and Sheet Metal" and below:
1. Stainless Steel: 0.015" thick.
2.05 MISCELLANEOUS MASONRY ACCESSORIES:
A. ReinforcinQ Bars:
Deformed steel, ASTM A 615, Grade 60 for bars NO.3 to No. 18.
MASONRY
04200-5
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Non-Metallic Expansion Joint Strips:
Premolded, flexible cellular neoprene rubber filler strips complying with ASTM D 1056,
....... .~a~ RE41 E 1, capable of compression up to 35%, of width and thickneS'S. indicated.
. -
c. Premolded Control Joint Strips:
Material as indicated below, designed to fit standard sash block and to maintain lateral
stability in masonry wall; size and configuration as indicated.
1. Styrene-butadiene rubber compound complying with ASTM D 2000, Designation
2M-805.
D. Bond Breaker Strips:
Asphalt-saturated organic roofing felt complying with ASTM D 226, Type I (No. 15
asphalt felt).
E. Weep holes:
Provide the following for weepholes:
1. Plastic Tubinq: Medium density polyethylene, outside diameter and length as
indicated below:
a. 1/4" x 4".
2.06 MORTAR AND GROUT MIXES:
-=- ~.-
A. GelWral:
Do not add admixtures including coloring pigments, air-entraining agents, accelerators,
retarders, water repellent agents, anti-freeze compounds or other admixtures, unless
otherwise indicated.
Do not use calcium chloride in mortar or grout.
B. Mixinq:
Combine and thoroughly mix cementitious, water and aggregates in a mechanical batch
mixe\; comply with referenced ASTM standards for mixing time and water content.
MASONRY
04200-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
C. Mortar for Unit Masonry:
Comply with ASTM C 270, Proportion Specification, for types of mortar required, unless
otherwise indicated.
.. __ .1i;, lJrnit cementitious materials in mortar to portland cement-lime. ~ .-
..
2. Use Type M mortar for masonry below grade and in contact with earth, and where
indicated.
3. Use Type S mortar for reinforced masonry and where indicated.
4. Use Type N mortar for exterior, above-grade loadbearing and non-load bearing walls;
for interior load bearing walls; and for other applications where another type is not
indicated.
PART 3 - EXECUTION
3.01 INSTALLATION, GENERAL:
A. Wettinq Clay Brick:
Wet brick made from clay or shale which have ASTM C 67.initial rates of absorption
(suction) of more than 30 grams per 30 sq. in. per minute. Use wetting methods which
ensure each clay masonry unit being nearly saturated but surface dry when laid.
B. Cleaning Reinforcing:
Before placing, remove loose rust, ice and other coatings from reinforcing.
C. Openinqs:
Leave openings for equipment to be installed before completion of masonry work. After
installation of equipment, complete masonry work to match work immediately adjacent
to the opening.
D. Cut Masonry Units:
Cut masonry units using motor-driven saws to provide clean, sharp, unchipped edges.
1. Cut units as required to provide continuous pattern and to fit adjoining work. Use
full-size units without cutting where possible.
MASONRY
04200-7
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
E. Matchinq Existing Masonry Work:
Match coursing, bonding, color and texture of new masonry work with existing work.
3.02 CONSTRUCTION TOLERANCES:
!'fIw""" ~. ZP'<-
... -
~ .-
A. Variation from Plumb:
For vertical lines and surfaces of columns, walls and arises do not exceed 1/4" in 10', or
3/8" in a story height not to exceed 20', nor 1/2" in 40' or more. For external corners,
expansion joints, control joints and other conspicuous lines, do not exceed 1/4" in any
story or 20' maximum, nor 1/2" in 40' or more. For vertical alignment of head joints do
not exceed plus or minus 1/4" in 10', 1/2" maximum.
B. Variation from Level:
For bed joints and lines of exposed lintels, sills, parapets, horizontal grooves and other
conspicuous lines, do not exceed 1/4" in any bay or 20' maximum, nor 1/2" in 40' or
more. For top surface of bearing walls do not exceed 1/8" between adjacent floor
elements in 10' or 1/16" within width of a single unit.
C. Variation of Linear Building Line:
For position shown in plan and related portion of columns, walls and partitions, do not
exceed 1/2" in any bay or 20' maximum, nor 3/4" in 40' or more. .
D. Variation in Mortar Joint Thickness:
Do not exceed bed joint thickness indicated by more than plus or minus 1/8"~ with a
~axjmum thickness limited to 1/2". Do not exceed head joint thickness in.Qic.ated by
more than plus or minus 1/8".
3.03 LAYING MASONRY WALLS:
A. General:
Layout walls in advance for accurate spacing of surface bond patterns with uniform joint
widths and to accurately locate openings, movement-type joints, returns and offsets.
Avoid the use of less-than-half-size units at corners, jambs and wherever possible at
other locations.
Lay-up walls to comply with specified construction tolerances, with courses accurately
spaced and coordinated with other work.
MASONRY
04200-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Pattern Bond:
Lay exposed masonry in the bond pattern shown or, if not shown, lay in running bond
with vertical joint in each course centered on units in courses above and below. Lay
concealed masonry with all units in a wythe in running bond or bonded by lapping not
'..... .I~s~an 2". Bond and interlock each course of each wythe at corners. Db-not use
units with less that nominal 4" horizontal face dimensions at corners or jambs.
C. Stoppinq and Resuminq Work:
Rack back 1/2-unit length in each course; do not tooth. Clean exposed surfaces of set
masonry, wet units lightly (if required) and remove loose masonry units and mortar prior
to laying fresh masonry.
D. Built-in Work:
As the work progresses, build-in items specified under this and other sections of these
specifications. Fill in solidly with masonry around built-in items.
3.04 MORTAR BEDDING AND JOINTING:
A. Lav solid brick size masonry units with completely filled bed and head joint; butter ends
with sufficient mortar to fill head joints and shove into place. Do not slush head joints.
B. Maintain ioint widths shown, except for minor variations required to maintain bond
alignment. If not shown, lay walls with 3/8" joints.
C Cut joints flush for masonry walls which are to be concealed or to be covered by other
materials, unless otherwise indicated.
D. Torn-exposed ioints slightly concave using a jointer larger than joint thickness, unless
otherwise indicated.
E. Remove masonry units disturbed after laying; clean and reset in fresh mortar. Do not
pound corners or jambs to shift adjacent stretcher units which have been set in
position. If adjustments are required, remove units, clean off mortar and reset in fresh
mortar.
3.05 CAVITY WALLS:
A. Keep cavity clean of mortar droppings and other materials during construction. Strike
joints facing cavity flush.
MASONRY
04200-9
MASONRY
04200-10
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Tie exterior wythe to back-up with individual metal ties spaced not more than 18" o.c.
vertically and 24" o.c. horizontally. Stagger alternate courses.
C. Provide weep holes in exterior wythe of cavity wall located immediately above ledges
and..f1ashing, spaced 2'-0" o.c., unless otherwise indicated. ~ .-
~'oc-.<"' ~ ~
3.06 ANCHORING MASONRY WORK:
A. General: Provide anchor devices of type indicated.
B. Anchor masonry to structural members where masonry abuts or face~ structural
members to comply with the following:
1. Provide an open space not less than 1" in width between masonry and structural
member, unless otherwise indicated. Keep open space free of mortar or other rigid
materials.
2. Anchor masonry to structural members with flexible anchors embedded in masonry
joints and attached to structure.
C. Space anchors as indicated, but not more than 24" o.c. vertically and 36" o.c.
horizontally.
3.07 LINTELS:
A. Install steel lintels where indicated.
B. Provide minimum bearinq of 8" at each jamb, unless otherwise indicated.
3.08 FIELD QUALITY CONTROL:
-. -
A. Owner will employ separate testing laboratory to perform field quality control testing.
3.09 REPAIR, POINTING AND CLEANING:
A. Remove and replace masonry units which are loose, chipped, broken, stained or
otherwise damaged, or if units do not match adjoining units as intended. Provide new
units to match adjoining units and install in fresh mortar or grout, pointed to eliminate
evidence of replacement.
B. Pointinq: During the tooling of joints, enlarge any voids or holes, except weep holes,
and completely fill with mortar. Point-up all joints including corners, openings and
adjacent work to provide a neat, uniform appearance, prepared for application of
sealants.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I.
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
C. Final Cleaning: After mortar is thoroughly set and cured, clean masonry as follows:
1. Remove larqe mortar particles by hand with wooden paddles and non-metallic
scrape hoes or chisels.
~ -
,.. ~
.. -
2. Test cleaninq methods on sample wall panel; leave 1/2 panel uncleaned for
comparison purposes. Obtain Architect's approval of sample cleaning before
proceeding with cleaning of masonry.
3. Protect adjacent stone and non-masonry surfaces from contact with cleaner by
covering them with liquid strippable masking agent, polyethylene film or waterproof
masking tape.
4. Saturate wall surfaces with water prior to application of cleaners; remove cleaners
promptly by rinsing ~horoughly with clear water.
5. Use bucket and brush hand cleaninq method described in BrA "Technical Note No.
20 Revised" to clean brick masonry made from clay or shale, except use masonry
cleaner indicated below.
a. Detergent.
b. Acidic cleaner; apply in compliance with directions of cleaner manufacturer.
6. Clean concrete unit masonry to comply with masonry manufacturer's directions.
D. Protection: Provide final protection and maintain conditions in a manner acceptable to
Installer, which ensures unit masonry work being without damage and deterieration at
time-of substantial completion.
END OF SECTION 04200
MASONRY
04200-11
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 05430 - FIXED ALUMINUM DOME TANK COVER
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
- '.
A. D?a~gs and general provisions of Contract, including General and Supplementary
Conditions and Division-1 Specification sections apply to work of this section.
1.02 SUMMARY:
A. This specification includes the design, fabrication, and erection of an aluminum dome
roof structure(s) for circular wastewater anaerobic digesters with appurtenances as
shown on the contract drawings and specified herein. The dome fabricator/erector
shall furnish all labor, materials and equipment required to design, fabricate, deliver, and
erect the aluminum dome roof(s). The dome manufacturer shall provide a support ring
in the center of the roof for a roof mounted mixer furnished under Section 11800.
Coordinate with the mixer manufacturer for support and sealing requirements
1.03 SUBMITTALS:
A. DESIGN CALCULATIONS AND SUBMITTALS:
1. Before executing any of the work in this section, calculations and prints or
drawings shall be submitted to the engineer showing dimensions, sizes"thickness,
gauges, materials, finishes, joint attachments and erection procedures. Submittals
shall be in accordance with Section 01800. These calculations & prints or
drawings shall be reviewed and sealed by a Professional Engineer registered and
licensed in the state in which the installation is to be made.
2. _Certification that the specified material alloys, sizes and quantities -'lave been
furnished shall be submitted by the manufacturer upon completion of the project.
3. The manufacturer shall submit, as part of its submittal package, documentation
from a qualified, independent third party testing laboratory that certifies that the
manufacture has prototyped and tested the proposed pressure dome cover and
the performance met the following conditions:
a. The unit was pressurized to a minimum of twice the proposed operating
pressure or a minimum of 26 inches water column (wc) pressure and it held leak
free for a minimum of twelve (12) hours.
b. The unit was pressurized to a minimum of 12 inches of wc pressure and it held
- -leak free for twenty four (24) hours.
FIXED ALUMINUM DOME TANK COVER
05430-1
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
During the test all seams shall be tested with a soapy water solution of sufficient
strength to cause bubbling at an air seep of as little as one (1) cubic foot per hour.
A minimum of four leak tests shall be made during the testing period.
1.04 DESIGN:
.... ,."..
- -
A. The- roof shall be a dome structure(s) conforming to the specified dimensions of the
tank. The structural frame of the dome shall consist of a fully triangulated, aluminum,
space truss that shall be clear-span and self supporting from the periphery structure;
primary horizontal thrust shall be contained by an integral tension ring. Provisions shall
be made to allow for thermal expansion of the dome and it's parts over a temperature
range of -40oF to +140oF.
B. The dome surface paneling shall consist of non-corrugated aluminum closure panels
that shall be desi!=lned as a gas-tight system under all design load and temperature
conditions. All raw edges of the aluminum panels shall be covered, sealed, and firmly
clamped with batten bars in an interlocking manner to prevent slipping or
disengagement under design load and temperature changes.
C. The dead weight of the dome structure shall not exceed 3.5 pounds per square foot of
surface area.
D. The roof framing system shall be designed as a three dimensional truss with moment-.
resisting joints. The design must consider the increased minor axis bending and
compression induced in the framing members due to tension in the roof panels.
E. The structural analysis shall be performed using stiffness analysis models. The
structural computer models shall include the effect of geometry irregularities such as
perimeter support members.
F. j;onnection forces shall be transferred through gusset plates connected to ibe top and
bottom flanges of the beam-struts. The connections shall be designed as moment
connections; a minimum of four Huck lock-bolts shall be used to connect the gusset
plate to each strut flange.
G. All aluminum dome fasteners shall be designed with a safety factor of 2.34 on ultimate
strength and 1.65 on yield strength. All stainless steel fasteners shall be designed with
a safety factor of 3.0 on ultimate strength.
H. The design of welded components shall be done in accordance with the Aluminum
Structural Welding Code ANSI/AWS D1.2.
I. The vertical load~ transferred from the roof to the tank shall be in line with the tank
st:Ipport wall. The transfer of horizontal loads to the tank shall be minimized by means
FIXED ALUMINUM DOME TANK COVER
05430-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
of low friction slide supports. Radial forces applied to the tank shall not exceed 10% of
the vertical reactions.
J. Dissimilar materials which are not compatible shall be isolated by an insulator to prevent
galvanic corrosion.
~ -.
~ --
PART 2 - PRDDUCTS
2.01 MANUFACTURERS:
A. The dome fabricator/erector must have installed at least one clear span aluminum
dome with a diameter equal to or larger than the unit(s) specified that has been
operating satisfactorily for a minimum period of four (4) years under design pressures
of not less than 12" W.C. Evidence of such experience shall be submitted with his bid
proposal and/or pre-bid submittal.
The experience requirement will be waived if the manufacturer provides a five-year
Performance Bond in lieu of evidence of experience and operation. Proof of the ability
to provide said bond shall be submitted with his bid proposal and/or pre-bid submittal.
The bond shall guarantee satisfactory leak free operation as defined by the technical
specifications, and it shall state that the manufacturer will, in case of unsatisfactory
service, remedy any problem(s) within thirty (30) days after written notification, or, at
the Owner's option, replace the domes or forfeit the bond. The bonding period shall
commence upon written acceptance by the Owner of the installed equipment and all
appurtenances and final acceptance of the General Contract
B. Available Manufacturers: Subject to compliance with requirements, manufacturers
offering products which may be incorporated in the work include, but are not limited to,
the following:
1.. Aluminum Dome Tank Covers:
T emcor.
Conservatek.
B. MATERIALS:
1. Triangulated dome frame struts: 6061-T6 aluminum.
2. Structural frame gussets: 6061-T6 aluminum, 0.375" nominal thickness.
3. Triangular closure panels: 0.050" nominal thickness 3003-H16 aluminum Sheet.
-4:- Perimeter tension/compression ring: 6061-T6 aluminum.
FIXED ALUMINUM DOME TANK COVER
05430-3
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
5. Fasteners: 7075-T73 anodized aluminum or Austenitic series 300 stainless steel
as required by the manufacturers design.
6. Sealant: Silicone conforming to Federal Specification TT-S-00230 as
manufactured by Pecora, or equal. ~ '.
... p..
- -
7. Gaskets: Silicone conforming to Federal Specification ZZ-R-765, Class 2, Grade
50 as manufactured by General Electric, SE-44/88, Neoprene per ASTM C509, or
equal.
8. Anchor Bolts: Austenitic Series 300 stainless steel.
9. Hatches and nozzles: 6061-T6, 5086-H34 or 5052-H36 aluminum, 0.090" nominal
thickness.
C. ALLOWABLE STRESSES:
Aluminum structural members and their connections shall be designed in accordance
with the Aluminum Association's Specifications for Aluminum Structures and the
following additions and clarifications.
1. Aluminum Structural Members
For members subjected to axial forces and bending moments due to load
eccentricity or lateral loads, the combined member stresses shall be determined by
adding the stress component due to axial load to the stress components due to
bending in both the major and minor axis.
2. Snap-Through Buckling
- _General shell buckling shall be determined In accordance with tile following
formula:
w=
2258x 106 JI:A
(SF) R2 L
1
Where:
w = Allowable load [pressure pst].
Ix = Moment of inertia of strut about the strong axis [in4].
A = Cross sectional area of strut [in2].
R = Spherical radius of dome [in].
L = Average member length [in].
SF = Safety factor (1.65).
FIXED ALUMINUM DOME TANK COVER
05430-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
The allowable buckling pressure shall be compared to the maximum intensities of
symmetrical and non-symmetrical load conditions.
D. DESIGN LOADS:
~. ~ome Design Loads
The dome frame and skin shall be designed in accordance with the most recent
edition of "Specifications for Aluminum Structures" as published by the Aluminum
Association and designed for full dead load plus live or snow load in accordance with
applicable local codes.
a. Basic Wind Load [mph]: 80
b. Ground Snow Load [pst]: 5
c. Internal Pressure [wc]: 15 inches
d. Center Mounted Mixer Load:
10,OOOlbs
2. Panel Design Loads (not acting simultaneously with the above loads)
The aluminum panels shall be secured to the dome frame to withstand the following
vertical loads:
a. Two concentrated loads of 250 pounds each, applied simultaneously on two
separate one square foot areas of the panel or 60 psf distributed over the total
panel area.
b. A distributed load equal to the ground snow load (item 1.b) or 60 pounds per
square foot over the total panel, whichever is greater.
3. Wind Loads:
The minimum wind load shall be the load resulting from a minimum wind velocity of
80 mph unless otherwise specified by the purchaser. Wind pressures may be
based on certified wind tunnel tests.
4. Seismic Loads:
The roof shall be designed for the seismic loading as specified in local building
codes.
FIXED ALUMINUM DOME TANK COVER
05430-5
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia,
PART 3 - EXECUTION
3.01 PREPARATION:
~,--
... -
- -
A. Field Measurements: Take field measurements prior to preparation of shop drawings
and fabrication, where possible. Do not delay job progress; allow for trimming and fitting
were taking field measurements before fabrication might delay work.
B. Coordinate and furnish anchoraqes, setting drawings, diagrams, templates, instructions
and directions for installation of anchorages, such as concrete inserts, sleeves, anchor
bolts and miscellaneous items having integral anchors, which are to be embedded in
concrete or masonry construction. Coordinate delivery of such items to project site.
C. Fabrication And Erection:
1. The contractor shall perform the work described herein with mechanics skilled and
experienced in the fabrication and erection of aluminum dome roof structures. All field
work shall be directed by a qualified supervisor who will remain on the job site until the
dome construction is completed.
2. Field re-fabrication of structural components or panels will not be accepted.
Forcing of the structure to achieve fit-up during construction is expressly forbidden and
not acceptable. Any indication of improper fit-up of parts shall be immediately reported
to the dome fabricator.
3. All sealant joints shall be tooled slightly concave after sealant is installed. Care
shall be taken to keep sealant confined to joint area, and any outside of the joint shall
be removed so that the panels will be free from misplaced sealant.-AII gasket
_maferials shall be continuous; splices will not be allowed. ~
D. GUARANTEE:
The dome(s) shall be guaranteed for a period of one (1) year against defective
materials and workmanship.
END OF SECTION 05430
FIXED ALUMINUM DOME TANK COVER
05430-6
'I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 05500 - METAL FABRICATIONS
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
~ --
Drawings and general provisions of Contract, including General and Supplementary
Conditions and Division-1 Specification sections, apply to work of this section.
1.02 DESCRIPTION OF WORK:
A. Definition: Metal fabrications include items made from iron and steel shapes, plates,
bars, strips, tubes, pipes and castings which are not a part of structural steel or other
metal systems specified elsewhere.
B. Extent of metal fabrications is indicated on drawings and schedules.
C. Types of work in this section include metal fabrications for:
1. Rough hardware.
2. Ladders.
3. Ladder and safety cages.
4. Loose bearing and leveling plates.
5. Loose steel lintels.
6. Miscellaneous framing and supports.
~~
T. Floor plate.
D. Handrails and Railinqs are specified in another section in Division 5.
E. Painting is specified in Section 09800.
1.03 QUALITY ASSURANCE:
A. Shop Assembly:
1. Preassemble items in shop to greatest extent possible to minimize field splicing and
assembly.
METAL FABRICATION
05500-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2. Disassemble units only as necessary for shipping and handling limitations. Clearly
mark units for reassembly and coordinated installation.
1.04 SUBMITTALS:
A. f!roffuct Data: Submit manufacturer's specifications, anchor details and installation
instructions for products used in miscellaneous metal fabrications, including paint
products and grout.
B. Shop Drawinqs:
1. Submit shop drawings for fabrication and erection of miscellaneous metal
fabrications. Include plans, elevations and details of sections and connections. Show
anchorage and accessory items. Provide templates for anchor and bolt installation by
others.
2. Where materials or fabrications are indicated to comply with certain requirements for
design loadings, include structural computations, material properties and other
information needed for structural analysis.
PART 2 - PRODUCTS
2.01 MATERIALS:
A. Ferrous Metals:
1. Metal Surfaces, General: For fabrication of miscellaneous metal work which will be
exposed to view, use only materials which are smooth and free of surface blemishes
including pitting, seam marks, roller marks, rolled trade names and roughness.
2. Steel Plates, Shapes and Bars: ASTM A 36.
...
3. Steel Tubinq: Cold-formed, ASTM A 500; or hot-rolled, ASTM A 501.
4. Structural Steel Sheet: Hot-rolled, ASTM A 570; or cold-rolled ASTM A 611, Class 1;
of grade required for design loading.
5. Galvanized Structural Steel Sheet: ASTM A 446, of grade required for design
loading. Coating designation as indicated, or if not indicated, G90.
6. Steel Pipe: ASTM A 53; Type and grade (if applicable) as selected by fabricator and
as required for design loading; black finish unless galvanizing is indicated; standard
weight (schedule 40), unless otherwise indicated.
METAL FABRICATION
05500-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
7. Brackets, Flanges and Anchors: Cast or formed metal of the same type material and
finish as supported rails, unless otherwise indicated.
8. Concrete Inserts: Threaded or wedge type; galvanized ferrous castings, either
malleable iron, ASTM A 47, or cast steel, ASTM A 27. Provide bolts, washers and
s!'in:l..s as required, hot-dip galvanized, ASTM A 153. ~ -
B. Aluminum Metals:
1. Aluminum Bar Gratinqs: ASTM B 221, alloy 6061-T6 or 6063-T6 for bearing bars,
alloy 6061-T1 for cross bars.
2. Fasteners for Aluminum Gratinqs: Use fasteners made of same basic metal as
fastened metal except use galvanized fasteners complying with ASTM A 153 for
exterior aluminum units, unless otherwise indicated. Do not use metals which are
corrosive or incompatible with metals joined.
C. Grout:
1. Metallic Non-Shrink Grout: Pre-mixed, factory-packaged, ferrous aggregate grout
complying with CE CRD-C588, Type M.
2. Non-Shrink Non-Metallic Grout: Pre-mixed, factory-packaged, non-staining,
non-corrosive, non-gaseous grout complying with CE CRO-C621. Provide grout
specifically recommended by manufacturer for interior and exterior applicatior's of type
specified in this section.
2.02 FABRICATION. GENERAL:
A. Workmanship:
l. ....General: Use materials of size and thickness indicated, or if not indicated, as
required to produce strength and durability in finished product for use intended. Work to
dimensions indicated or accepted on shop drawings, using proven details of fabrication
and support. Use type of materials indicated or specified for various components of
work.
2. Form exposed work true to line and level with accurate angles and surfaces and
straight sharp edges. Ease exposed edges to a radius of approximately 1/32" unless
otherwise indicated. Form bent-metal corners to smallest radius possible without
causing grain separation or otherwise impairing work.
3. Weld corners and seams continuously, complying with AWS recommendations. At
exposed connections, grind exposed welds smooth and flush to match and blend with
adjoining surfaces.
METAL FABRICATION
05500-3
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
4. Form exposed connections with hairline joints, flush and smooth, using concealed
fasteners wherever possible. Use exposed fasteners of type indicated or, if not
indicated, Phillips flat-head (countersunk) screws or bolts.
5;. F'rovide for anchorage of type indicated, coordinated with supporting structure.
Fabricate and space anchoring devices to provide adequate support for intended use.
6. Cut, reinforce, drill and tap miscellaneous metal work as indicated to receive finish
hardware and similar items.
B. Galvanizing: Provide a zinc coating for those items indicated or specified to be
galvanized, as follows:
1. ASTM A 153 for galvanizing iron and steel hardware.
2. ASTM A 123 for galvanized rolled, pressed and forged steel shapes, plates, bars
and strip 1/8" thick and heavier.
3. ASTM A 386 for galvanizing assembled steel products.
4. Fabricate joints which will be exposed to weather in a manner to exclude water or
provide weep holes where water may accumulate.
2.03 ROUGH HARDWARE:
A. Furnish bent or otherwise custom fabricated bolts, plates, anchors, hangers, dowels
and other miscellaneous steel and iron shapes as required for framing and supporting
woodwork, and for anchoring or securing woodwork to concrete or other structures.
Straight bolts and other stock rough hardware items as specified in Divisi~n-6 sections.
B. Fa6ricate items to sizes, shapes and dimensions required. Furnish malleab~-iron
washers for heads and nuts which bear on wood structural connections; elsewhere,
furnish steel washers.
2.04 LADDERS:
A. Fabricate ladders for the locations shown, with dimensions, spacings, details and
anchorages as indicated. Comply with requirements of ANSI A 14.3, unless otherwise
indicated.
B. Unless otherwise indicated, provide 1/2" x 2-1/2" continuous structural steel flat bar side
rails with eased edges, spaced 18" apart.
C. Provide 3/4" diameter solid structural steel bar rungs, spaced 12" o.c.
METAL FABRICATION
05500-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
D. Fit runqs in centerline of side rails, plug weld and grind smooth on outer rail faces. .
E. Support each ladder at top and bottom and at intermediate points spaced not more than
5'-0" o.c. Use welded or bolted steel brackets, designed for adequate support and
anchorage, and to hold ladder clear of the wall surface with a minimum of..4'''.c1earance
frbrrr wall to centerline of rungs. Extend rails 42" above top rung, and return rails to wall
or structure unless other secure handholds are provided. If the adjacent structure does
not extend above the top rung, goose-neck the extended rails back to the structure to
provide secure ladder access.
F. Provide non-slip surface on top of each rung, either by coating the rung with aluminum
oxide granules set in epoxy resin adhesive, or by using a type of manufactured rung
which is filled with aluminum oxide grout.
2.05 LADDER SAFETY CAGES:
A. Fabricate ladder safety caqes from structural steel flat bars, assembled by welding or
riveting. Unless otherwise indicated, provide 5/16" x 4" top and bottom hoops and
intermediate hoops spaced not more than 20'-0" o.C.; 5/15" X 2" hoops at 4'-0" o.c.
between the 4" wide hoops; and 5/16" x 2" vertical bars, secured to each hoop. Space
vertical bars approximately 9" o.c. Fasten assembled safety cage to ladder rails and
adjacent construction as indicated.
2.06 LOOSE BEARING AND LEVELING PLATES:
Provide loose bearinQ and levelinq plates for steel items bearing on masonry or concrete
construction, made flat, free from warps or twists, and of required thickness and bearing
area. Drill plates to receive anchor bolts and for grouting as required. Galvanize after
fabrication.
2.07 LOGS~-STEEL LINTELS:
A. Provide loose structural steel lintels for openings and recesses in masonry walls and
partitions as shown. Weld adjoining members together to form a single unit where
indicated. Provide not less than 8" bearing at each side of openings, unless otherwise
indicated.
2.08 MISCELLANEOUS FRAMING AND SUPPORTS:
A. Provide miscellaneous steel framing and supports which are not a part of structural
steel framework, as required to complete work.
B. Fabricate miscellaneous units to sizes, shapes and profiles indicated or, if not indicated,
of required dimensions to receive adjacent other work to be retained by framing. Except
METAL FABRICATION
05500-5
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
as otherwise indicated, fabricated from structural steel shapes, plates and steel bars of
welded construction using mitered joints for field connection. Cut, drill and tap units to
receive hardware and similar items.
C. ~ units with integrally welded anchors for casting into concrete or buil.Qjn-9 into
mas5nry. Furnish inserts if units must be installed after concrete is placed.
D. Except as otherwise indicated, space anchors 24" o.c. and provide minimum anchor
units of 1-1/4" x 1/4" x 8" steel straps.
2.09 FLOOR PLATE:
A. Raised Pattern Floor Plates: Provide aluminum alloy 3003 diamond tread aluminum
floor plate from manufacturer's standard pattern, unless otherwise indicated:
B. Include aluminum anqle stiffeners and fixed and removable sections as indicated from
alloy 6061.
C. Provide 2 floor liftinq handles, one at each end of each removable section.
PART 3 - EXECUTION
3.01 PREPARATION:
A. Field Measurements: Take field measurements prior to preparation of shop drawings
and fabrication, where possible. Do not delay job progress; allow for trimming and fitting
where taking field measurements before fabrication might delay work.
B. Coordinate and furnish anchorages, setting drawings, diagrams, templates, instructions,
andllirections for installation of anchorages, such as concrete inserts, sleeves, anchor
bolts and miscellaneous items having integral anchors, which are to be emb;dded in
concrete or masonry construction. Coordinate delivery of such items to project site.
3.02 INSTALLATION:
A. General:
1. Fasteninq to In-Place Construction: Provide anchorage devices and fasteners where
necessary for securing miscellaneous metal fabrications to in-place construction;
including, threaded fasteners for concrete and masonry inserts, toggle bolts,
through-bolts, lag bolts, wood screws and other connectors as required.
2. Cuttinq, Fitting and Placement: Perform cutting, drilling and fitting required for
installation of miscellaneous metal fabrications. Set work accurately in location,
METAL FABRICATION
05500-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
alignment and elevation, plus, level, true and free of rack, measured from established
lines and levels. Provide temporary bracing or anchors in formwork for items which are
to be built into concrete masonry or similar construction.
3. Fit exposed connections accurately together to form tight hairline joints. Weld
cgn'lections which are not to be left as exposed joints, but cannot be shop'welded
because of shipping size limitations. Grind exposed joints smooth and touch-up shop
paint coat. Do not weld, cut or abrade the surfaces of exterior units which have been
hot-dip galvanized after fabrication, and are intended for bolted or screwed field
connections.
4. Field Welding: Comply with AWS Code for procedures of manual shielded metal-arc
welding, appearance and quality of welds made, and methods used in correcting
welding work.
5. Settinq Loose Plates: Clean concrete and masonry bearing surfaces of any
bond-reducing materials, and roughen to improve bond to surfaces. Clean bottom
surface of bearing plates.
6. Set Loose leveling and bearing plates on wedges, or other adjustable devices. After
the bearing members have been positioned and plumbed, tighten the anchor bolts. Do
not remove wedges or shims, but if protruding, cut-off flush with the edge of the bearing
plate before packing with grout. Use metallic non-shrink grout in concealed locations
where not exposed to moisture; use non-metallic non-shrink grout in exposed locations,
unless otherwise indicated.
Pack grout solidly between bearing surfaces and plates to ensure that no voids remain.
3.03 ADJUST AND CLEAN:
A. Touch-Up Paintinq:
~
1. Cleaning and touch-up painting of field welds, bolted connections and abraded .
areas of the shop paint on miscellaneous metal is specified in Division 9 of these
specifications.
B. For galvanize surfaces: Clean field welds, bolted connections and abraded areas and
apply galvanizing repair paint to comply with ASTM A 780.
END OF SECTION 05500
METAL FABRICATION
05500-7
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 05532 - FIBERGLASS FLOOR GRATING
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
DraWings and general provisions of Contract, including General and Supplementary
Conditions and Division-1 Specification sections, apply to work of this section.
1.02 DESCRIPTION OF WORK:
Extent of fiberglass floor grating is indicated on the drawings.
1.03 SYSTEM PERFORMANCE:
Treads and Platforms of Stairs: Capable of withstanding a uniform load of 100 Ibf per sq. ft.
or a concentrated load of 300 Ibf so located as to produce maximum stress conditions.
1.04 QUALITY ASSURANCE:
A. All materials shall comply with the pertinent provisions of the following reference
standards:
1. ASTM E-84 - Surface Burning.
2. ASTM D-790 - Flexural.
3. ASTM D-2583 - Barcol Hardness.
4. ASTM D-2584 - Glass Content.
1.05 SUBMITTALS:
A. Product Data: Submit manufacturer's specifications, load tables, anchor details and
installation instructions for products used in fiberglass floor gratings.
B. Shop Drawings:
1. Submit shop drawings for fabrication and erection of fiberglass floor grating. Include
plans, elevations and details of sections and connections. Show anchorage and
accessory items.
2. Where materials or fabrications are indicated to comply with certain requirements for
design loadings, include structural computations, material properties and other
information needed for structural analysis.
FIBERGLASS FLOOR GRATING
05532-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
PART 2 - PRODUCTS
2.01 FIBERGLASS GRATING:
A. Materials: Fiberglass roving reinforced composite molded in a single piece mold with
smooth mold surfaces. Resin shall be opaque, fire retardant, premium grade
thermosetting resin, producing a Class 1 flame spread below 25 and a fuel contribution
of zero (ASTM E-84). Color of grating shall be green, yellow or gray, selected by the
Owner from the manufacturer's standard colors.
B. Desiqn: Grating shall have a non-porous, angular silica anti-slip surface. Grid pattern
shall be 1-1/2" high, 6" by 1-1/2" unless noted otherwise on the drawings. Bearing bars
shall be 3/8" wide at 1-1/2" centers. Cross bars shall be 5/8" wide (minimum) on 6"
centers. Grating shall have weight of not less than 3.4 pounds per square foot and an
open area of not less than 67%.
C. Manufacturer: Subject to compliance with requirements, provide fiberglass floor grating
of one of the following:
1. Chemgrate Corporation, Woodinville, WA.
2. Fibergrate Corporation, Dallas, TX.
3. Seasafe, Inc., Lafayette, LA.
PART 3 - EXECUTION
3.01 PREPARATION:
A. Field Measurements: Take field measurements prior to preparation of shop drawings
and fabrication, where possible. Do not delay job progress; allow for trimming and fitting
wh~re taking field measurements before fabrication might delay work. ~
B. Coordinate and furnish anchorages, setting drawings, diagrams, templates, instructions,
and directions for installation of anchorages, such as concrete inserts. Coordinate
delivery of such items to project site.
3.02 INSTALLATION:
A. Gratinqs:
1. Complv with manufacturer's recommendations for installation of gratings, including
installation clearances and standard anchoring details.
FIBERGLASS FLOOR GRATING
05532-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
2. Secure removable units to supporting members with type and size clips and
fasteners indicated, or if not indicated as recommended by grating manufacturer for
type of installation conditions shown.
3. Resin Coat field-cut or sanded surfaces with resin furnished by the manufacturer,
aRplj~d in accordance with the manufacturer's instructions.
4. Protect installed grating from damage due to construction activities until acceptance
of the project by the Owner.
END OF SECTION 05532
.- ~-
FIBERGLASS FLOOR GRATING
05532-3
I
I
I
I'
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 05720 - HANDRAILS AND RAILINGS
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
DraWIngs and general provisions of Contract, including General and Supplementary
Conditions and Division-1 Specification sections, apply to work of this section.
1.02 DESCRIPTION OF WORK:
A. Extent of handrails and railings is indicated on the drawings.
B. Types of work in this section include:
1. Aluminum pipe I ailings
1.03 SYSTEM PERFORMANCES:
A. Handrails and Toprails: Capable of withstanding the following loads applied as indicated
when tested per ASTM E 935.
1. Concentrated loads of 200 Ibf applied at any point in any direction.
2. Uniform load of 50 Ibf per linear ft. applied simultaneously in both vertical and
horizontal directions.
3.. Concentrated and uniform loads above need not be assumed to act concurrently.
B. Guards:
- ~
1. Intermediate rails, balusters and panel fillers capable of withstanding aut:liform load
of 25 Ibf per sq. ft. of gross area of guard, including any open areas, of which they are
a part.
2. Above load need not be assumed to be acting concurrently with uniform horizontal
loads on toprails of railing assembly in determining stress on guard supporting
members.
1.04 SUBMITTALS:
A. Product Data: Submit manufacturer's specifications, anchor details and installation
instructions for products used in handrails and railings.
HANDRAILS AND RAILINGS
05720-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Shop Drawinqs:
1. Submit shop drawings for fabrication and erection of handrails and railings. Include
plans, elevations and details of sections and connections. Show anchorage and
accessory items.
2. Where materials or fabrications are indicated to comply with certain requirements for
design loadings, include structural computations, material properties and other
information needed for structural analysis.
PART 2 - PRODUCTS
2.01 MATERIALS:
A. Grout:
1. Metallic Non-Shrink Grout: Pre-mixed, factory-packaged, ferrous aggregate grout
complying with CE CRD-C588, Type M.
2. Non-Shrink Non-Metallic Grout: Pre-mixed, factory-packaged, non-staining,
non-corrosive, non-gaseous grout complying with CE CRD-C621. Provide grout
specifically recommended by manufacturer for interior and exterior applications of type
specified in this section.
B. Fasteners:
1. General: Provide stainless steel fasteners for exterior use or where built into exterior
walls. Select fasteners for the type, grade and class required.
2. Masonry Anchoraqe Devices: Expansion shields, FS FF-S-325.
3. Toqgle Bolts: Tumble-wing type, FS FF-B-588, type, class and style as required.
2.02 ALUMINUM PIPE RAILINGS AND HANDRAILS:
A. Fabricate aluminum pipe railinqs and handrails to design, dimensions, and details
indicated. Provide railings and handrails members formed of pipe of sizes and wall
thickness indicated, but not less than that required to support design loading.
B. Interconnect railing and handrail members by butt-welding or welding with internal
connectors, at fabricator's option, unless otherwise indicated.
C. At tee and cross intersections provide coped joints.
D. At elbow bends provide mitered joints.
HANDRAILS AND RAILINGS
05720-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
E. Form simple and compound curves by bending pipe in jigs to produce uniform curvature
for each repetitive configuration required; maintain cylindrical cross-section of pipe
throughout entire bend without buckling, twisting or otherwise deforming exposed
surfaces of pipe.
F. ProVide wall returns at ends of wall-mounted handrails, except where otherwise
indicated.
G. Close exposed ends of pipe by welding 3/16" thick aluminum plate in place or by use of
prefabricated fittings.
H. Kickplates: Provide kickplates at railings around openings and at the edge of
open-sided floors and platforms. Fabricate to dimensions and details indicated, or if not
indicated, use a 4" high x 1/8" plate welded to, and centered between, each railing post.
I. Brackets, FlanQes, FittinQs and Anchors: Provide wall brackets, end closures, flanges,
miscellaneous fittings and anchors for interconnections of pipe and attachment of
railings and handrails to other work. Furnish inserts and other anchorage devices for
connecting railings and handrails to concrete or masonry work.
J. For railinq posts set in concrete provide sleeves of aluminum or stainless steel pipe not
less than 6" long and with an inside diameter not less than 1/2" greater than the outside
diameter of pipe. Provide plate closure welded to bottom of sleeve and of width and
length not less than 1" greater than outside diameter of sleeve.
PART 3 - EXECUTION
3.01 PREPARATION:
A. Field Measurements: Take field measurements prior to preparation of shop drawings
and fabrication, where possible. Do not delay job progress; allow for trimmir.lg and fitting
where taking field measurements before fabrication might delay work.
B. Coordinate and furnish anchorages, setting drawings, diagrams, templates, instructions,
and directions for installation of anchorages, such as concrete inserts, sleeves, anchor
bolts and miscellaneous items having integral anchors, which are to be embedded in
concrete or masonry construction. Coordinate delivery of such items to project site.
3.02 INSTALLATION:
A. Aluminum Pipe RailinQs and Handrails:
1. Adiust railinq prior to anchoring to ensure matching alignment at abutting joints.
Space posts at spacing indicated, or if not indicated, as required by design loadings.
HANDRAILS AND RAILINGS
05720-3
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Plumb posts in each direction. Secure posts and railing ends to building construction as
follows:
2. Anchor posts in concrete by core drilling holes not less than 5" deep and 3/4"
greater than outside diameter of post. Clean holes of all loose material, insert posts and
fUl annular space between post and concrete with non-shrink, non-metallic grout, mixed
and placed to comply with grout manufacturer's directions.
3. Leave anchorage joint exposed, wipe off excess grout and leave 1/8" build-up,
sloped away from post. For installation exposed on exterior or to flow of water, seal
grout to comply with grout manufacturer's directions.
4. Anchor rail ends into concrete and masonry with aluminum or stainless steel round
flanges welded to rail ends and anchored into wall construction with stainless steel
expansion anchors.
5. Provide removable railinq sections as indicated. Furnish slip-fit metal socket or
sleeve for casting into concrete. Accurately locate sleeves to match post spacing.
6. Secure handrails to wall with wall brackets and end fittings. Provide bracket with not
less than 1-1/2" clearance from inside face of handrail and finished wall surface. Locate
brackets as indicated, or if not indicated, at spacing required for design loading. Secure
wall brackets and wall return fittings to building construction as follows:
a. Use type of bracket with flange tapped for concealed anchorage to threaded
hanger bolt.
b. For concrete and solid masonry anchorage, use drilled-in expansion shield and
either concealed hanger bolt or exposed lag bolt, as applicable.
"C-. For hollow masonry anchoraqe, use toggle bolts having square heajs.
END OF SECTION 05720
HANDRAILS AND RAILINGS
05720-4
"1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
'I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 07900 - JOINT SEALERS
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
Drawings and general provisions of Contract, including General and Supplementary
Conditions and Division 1 Specification Sections, apply to this Section.
1.02 SUMMARY:
A. Extent of each form and type of joint sealer is indicated on drawings and schedules.
1.03 SYSTEM PERFORMANCES:
Provide joint sealers that have been produced and installed to establish and maintain
watertight and airtight continuous seals.
1.04 SUBMITTALS:
Product Data from manufacturers for each joint sealer product required, including
instructions for joint preparation and joint sealer application.
1.05 DELIVERY, STORAGE, AND HANDLING:
A. Delivery:
Deliver materials to Project site in original unopened containers or bundles with labels
informing about manufacturer, product name and designation, color, expiration period
for lJse, pot life, curing time, and mixing instructions for multicomponent materials.
- - ,..-
B. Storaqe and Handlinq:
Store and handle materials in compliance with manufacturers' recommendations to
prevent their deterioration or damage due to moisture, high or low temperatures,
contaminants, or other causes.
1.06 PROJECT CONDITIONS:
A. Environmental Conditions:
Do not proceed with installation of joint sealers under the following conditions:
JOINT SEALERS
07900-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1. When ambient and substrate temperature conditions are outside the limits permitted
by joint sealer manufacturers.
2. When joint substrates are wet due to rain, frost, condensation, or other causes.
B. Joint Width Conditions:
Do not proceed with installation of joint sealers where joint widths are less than allowed
by joint sealer manufacturer for application indicated.
PART 2 - PRODUCTS
2.01 ACCEPTABLE MANUFACTURERS:
Providing caulking and sealant from the following manufacturers: Dow Corning and G.E.
for Silicone; Pecora Corp. and SJnneborn for polysylfide. Equivalent materials from other
manufacturers may be provided, if approved prior to bid by the AlE. Materials shall be from
one source for each type specified.
2.02 CAULKING AND SEALANT MATERIAL:
A. Exterior Sealant System:
Dow Corning 790 Building Sealant or G.E. Silicone "Silpruf'.
B. Interior Caulkinq System:
Two component polysulfide sealant, selected from one of the following: "Synthacalk
GC-S" or "Sonolastic Sealant".
C. Primer:
...
As recommended by the caulking or sealant manufacture.
D. Backup Materials, Where Required:
"Ethafoam" as manufactured by Dow Chemical Company or approved equivalent
material. Size of backup material shall be such that minimum of 25% compression and
a maximum of 50% is obtained in all joints. Braided rods are not acceptable.
E. Bondbreaker:
Polyethylene bond breaker tape recommended by sealant manufacturer.
JOINT SEALERS
07900-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
F. Solvents and Cleaninq Agents:
Solvents and cleaning agents as recommended by the manufacturer for use with the
particular caulking of sealant being applied.
G. Color:
As selected by Engineer.
PART 3 - EXECUTION
3.01 EXAMINATION:
A. Examine ioints indicated to receive ioint sealers, with Installer present, for compliance
with requirements for compliance with requirements for joint configuration, installation
tolerances and other conditions affecting joint sealer performance. Do not proceed with
installation of joint sealers until unsatisfactory conditions have been corrected.
3.02 AREAS OF APPLICATION
A. The required typical applications of sealants and caulking include, but are not
necessarily limited to the following general locations:
1. Exterior wall joints, including exterior and interior perimeter of metal doors and
windows frames and louvers.
2. Other interior and exterior joints noted on Drawings.
3. Joints at penetrations of walls, decks and floors by piping and other services and
equipment.
4. "'Other exterior and interior joints between different building materials where voids are
created by construction joints and where indicated on Drawings.
3.03 PREPARATION:
A. Surface Cleaninq of Joints:
Clean out joints immediately before installing joint sealers to comply with
recommendations of joint sealer manufacturers and the following requirements:
1. Remove all foreign material from joint substrates which could interfere with adhesion
of joint sealer, including dust; paints, except for permanent,":pro.tective coatings tested
and approved for sealant adhesion and compatibility by sealant manufacturer; old joint
sealers; oil; grease; waterproofing; water repellents; water; surface dirt; and frost.
JOINT SEALERS
07900-3
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2. Clean concrete, masonry, unglazed surfaces of ceramic tile and similar porous joint
substrate surfaces, by brushing, grinding, blast cleaning, mechanical abrading, or a
combination of these methods to produce a clean, sound substrate capable of
developing optimum bond with joint sealers. Remove loose particles remaining from
above cleaning operations by vacuuming or blowing out joints with oil-free compressed
aIr.
3. Remove laitance and form release agents from concrete.
4. Clean metal, glass, porcelain enamel, glazed surfaces of ceramic tile; and other
nonporous surfaces by chemical cleaners or other means which are not harmful to
substrates or leave residues capable of interfering with adhesion of joint sealers.
B. Joint Priming:
Prime joint substrates where indicated or where recommended by joint sealer
manufacturer based on preconstruction joint sealer-substrate tests or prior experience.
Apply primer to comply with joint sealer manufacturer's recommendations. Confine
primers to areas of joint sealer bond, do not allow spillage or migration onto adjoining
surfaces.
C. Maskinq Tape:
Use masking tape where required to prevent contact of sealant with adjoining surfaces
which otherwise would be permanently stained or damaged by such contact or by
cleaning methods required to remove sealant smears. Remove tape immediately after
tooling without disturbing joint seal.
3.03 INSTALLATION OF JOINT SEALERS:
...
A. General:
Comply with joint sealer manufacturers' printed installation instructions applicable to
products and applications indicated, except where more stringent requirements apply.
B. Installation of Fire-Stopping Sealant:
Install sealant, including forming, packing, and other accessory materials to fill openings
around mechanical and electrical services penetrating floors and walls to provide
fire-stops with fire resistance ratings indicated for floor or wall assembly in which
penetration occurs. Comply with installation requirements established by testing and
inspecting agency.
JOINT SEALERS
07900-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
3.04 CLEANING:
Clean off excess sealants or sealant smears adjacent to joints as work progresses by
methods and with cleaning materials approved by manufacturers of joint sealers and of
products in which joints occur.
3.05 PROTECTION:
Protect ioint sealers during and after curing period from contact with contaminating
substances or from damage resulting from construction operations or other causes so that
they are without deterioration or damage at time of Substantial Completion. If, despite such
protection, damage or deterioration occurs, cut out and remove damaged or deteriorated
joint sealers immediately and reseal joints with new materials to produce joint sealer
installations with repaired areas indistinguishable from original work.
END OF SECTION 07900
.;;.
JOINT SEALERS
07900-5
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 09800 - SPECIAL COATINGS
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
--
" -...
DralJ:iings and general provisions of Contract, including General and Supplementary
Conditions and Division 1 Specification sections, apply to this section.
1.02 SUMMARY:
A. This Section includes application of special coating systems to items and surfaces
scheduled, including surface preparation, prime coats and topcoats.
B. Types of special coatinq systems required for the project include:
1. Special Coatings for Exterior Use:
a. Heat-resistant coating.
b. 2-component pigmented aliphatic polyurethane coating
c. 2-component pigmented polyester/polyurethane coating
2. Special Coatings for Interior Use:
a. 2-component high performance polyamide epoxy coating.
b. Pigmented aliphatic polyurethane coating.
1.03 SUBMITTALS:
A. Product Data:
SUbmit manufacturer's technical information including basic materials analysis and
application instructions for each coating material specified.
B List and Identify:
List each material and cross-reference the specific coating and finish system and
application. Identify each material by the manufacturer's catalog number and general
classification.
SPECIAL COATINGS
09800-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1.04 QUALITY ASSURANCE:
A. Single Source Responsibility:
--. -
~ro~ide primers and undercoat material produced by the same manufac~ur~r as the
finish coats. Use only thinners recommended by the manufacturer, and only within
recommended limits.
B. Coordination of Work:
1. Review sections in which other coatings are provided to ensure compatibility of the
total systems for various substrates. Upon request, furnish information on
characteristics of specified finish materials, to ensure that compatible prime coats are
used.
2. Notify the Engineer of problems anticipated using the coatings systems specified.
C. Material Qualitv:
Provide the best quality grade of the various coatings as regularly manufactured by
acceptable coating manufacturers. Materials not displaying manufacturer's identification
as a best-grade product will not be acceptable.
D. Proprietary Names:
Shall be used to designate colors or materials are not intended to imply that products of
named manufacturers are required to the exclusion of equivalent products of other
manufacturers.
1.05 DELIVERY. STORAGE AND HANDLING:
~ ~
A. Deliver materials to the job site in the manufacturer's original, new, unopened packages
and containers bearing manufacturer's name and label and the following information:
1. Name or title of material.
2. Federal Specification number, if applicable.
3. Manufacturer's name, stock number and date of manufacture.
4. Contents by volume, for major pigment and vehicle constituents.
5. Thinning instructions.
6. Application instructions.
7. Color name and number.
8. H~ndling instructions and precautions.
SPECIAL COATINGS
09800-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
.1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Store materials not in actual use in tightly covered containers at a minimum ambient
temperature of 45 deg. F (7 deg. C) in a well ventilated area.
1. Maintain containers used in storage of coatings in a clean condition, free of foreign
materials and residue.
~ -6-
2:" Protect from freezing. Keep storage area neat and orderly. Remove ojlyrags and
waste daily. Take necessary precautionary measures to ensure that workmen and work
areas are adequately protected from fire hazards and health hazards resulting from
handling, mixing and application of coatings.
-- -
1.06 PROJECT CONDITIONS:
A. Apply coatinqs only when the temperature of surfaces to be coated and surrounding air
temperatures are above 45 deg. F (7 deg. C), and below 100 deg. F (38 deg. C) unless
otherwise permitted by manufacturer's printed instructions.
B. Do not apply coatings in snow, rain, fog or mist, or when the relative humidity exceeds
85 percent, or at temperatures less than 5 deg. F (3 deg. C) above the dew point, or to
damp or wet surfaces unless otherwise permitted by manufacturer's printed
instructions. Allow wet surfaces to dry thoroughly and attain the temperature and
conditions specified before proceeding with or continuing the coating operation. Do not
apply urethane coatings in evening when dew is expected overnight. Do not apply when
surface temperature is less than 5 deg F above dew point. Do not apply Acrylic
Coatings if temperatures are expected to drop below 50 deg F within 24 hours of
application.
PART 2 - PRODUCTS
2.01 MANUFACTURERS:
A. Ava1'/able Manufacturers:
Subject to compliance with requirements, manufacturers offering products which may
be incorporated in the work include, but are not limited to, the following:
1. The Glidden Company. (Glidden).
2. Benjamin Moore and Co. (Moore).
3. Carboline Company (Carboline).
4. Sherwin-Williams Company (S-W).
5. Tnemec Company, Inc. (Tnemec).
6. Valspar Corporation (Valspar).
SPECIAL COATINGS
09800-3
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2.02 EXTERIOR COATING MATERIALS:
A. Exterior Primers:
Provide factory formulated prime coat material compatible with the subst~E:. and finish
&~ indicated.
1. Primer for ferrous metal under a heat resisting black enamel coating for surfaces
exposed to temperatures up to 400 deg. F (204 deg. C):
a. Glidden: Y-5546 Glid-Guard Silicone Alkyd Primer - Tan.
b. Moore: (No Primer Required).
c. Carboline: 1248 #0900 Black - 2 coats @ 1.5 mils each.
d. S-W: (No Primer Required).
e. Tnemec: (No Primer Required).
2. Primer for ferrous metal under a 2-component aliphatic or polyester polyurethane
coating:
a. Glidden: Glid-Guard 5475/5476 Metallite Epoxy.
b. Tnemec: Series N66 Hi-build Epoxoline.
c. Valspar: 78 Series High Build Epoxy Primer.
d. S-W: Recoatable Epoxy Primer.
e. Carboline: 890 Gloss Epoxy.
B. Finish Coats:
Provide factory formulated, finish coat material compatible with the substrate and prime,
base or intermediate coat material indicated.
1. 2-Component Aliphatic Polyurethane Coatinq over ferrous metal:
.c, .,...
a. Glidden: 10407/10168 Glid-Guard High Solids Urethane.
b. S-W: Hi-solids Polyurethane, B65-300 Series.
c. Tnemec: 74 Series Endura-Shield Aliphatic Polyurethane Enamel.
d. Valspar: V-Thane Hi-Solids Urethane Enamel, 54 Series.
e. Carboline: 134 Hi Soilds.
2. 2-Component Polyester/Polyurethane Coatinq over ferrous metal:
a. Tnemec: 71 Series Endura-Shield Polyester/Polyurethane Enamel.
b. Carboline: Sanitile 800 VOC Finish.
2. Heat-Resistant Coating: Aluminum pigmented, silicone based heat-resistant coating
over ferrous metal subject to temperatures to 1000 deg. F (538 deg. C).
SPECIAL COATINGS
09800-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
a.
b.
c.
d.
Devoe: 647-S-9100 Silicone Alkyd HT-10 High-Heat Aluminum.
Glidden: Y-5542 Glid-Guard Silicone Hi-Temp Aluminum.
Carboline: 4631.
S-W: Hi-Heat Silicone Alkyd Aluminum, B59S8.
Tnemec: Series 39-1261 Silicone Aluminum.
........ -
"'.Ai(.
2.03 INTERIOR COATING MATERIALS:
A. Interior Primers:
Provide factory formulated prime coat material compatible with the substrate and finish
coats indicated.
1. Primer over ferrous metal:
a. Glidden: Y-5461/5242 Glid-Guard Double Build Epoxy.
b. Moore: Ironclad Epoxy Rust Inhibitive Primer Base 181/177.
c. Carboline: 893 Epoxy Primer.
d. S-W: Tile-Clad II Hi-Build Primer B62N71/B60V60.
e. Tnemec: Series N66 Hi-build Epoxoline.
B. Finish Coats:
Provide factory formulated, finish coats compatible with the substrate and prime, base
or intermediate coat indicated.
1. Hiqh Performance Polvamide Epoxv Coatinq (HIPAC): High gloss coating over
concrete, concrete masonry units, wood and ferrous metal.
_a. Glidden: Y-5240 Chemical-Resistant Epoxy.
e; "'~ ,.:.
~ b. Moore: Ironclad Chemical and Water Resistant Epoxy Enamel 182.
c. Carboline: 890 Gloss Epoxy.
d. S-W: Tile-Clad II Epoxy Enamel B62 Series/B60VlO.
e. Tnemec: Series 83 Ceramalo II.
PART 3 - EXECUTION
3.01 EXAMINATION:
Examine substrates and conditions under which coating will be performed for compliance
with requirements for application of coatings. do not proceed with application until
unsatisfactory conditions have been corrected.
SPECIAL COATINGS
09800-5
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Start of coating work will be construed as the Applicator's acceptance of surfaces within
particular area.
3.02 PREPARATION:
~.
A. 'l5eneral:
--
1. Remove hardware, hardware accessories, plates, machined surfaces, light fixtures,
and similar items which are not to be coated, or provide surface-applied protection prior
to surface preparation and coating. Remove these items if necessary for complete
coating of the items and adjacent surfaces. Following completion of coating operations
in each space or area, reinstall items removed, using workmen skilled in the trades
involved.
2. Clean surfaces before applying coatings or surface treatments. Schedule cleaning
and coating application so dust and other contaminates will not fall on wet, newly coated
surfaces.
B. Surface Preparation:
1. General:
a. Perform surface preparation and cleaning in compliance with the
manufacturer's instructions for the particular substrate conditions, and as specified.
b. Notify the Engineer in writing of anticipated problems using coatings specified
with substrates primed or furnished by others.
2. Ferrous Metal Surfaces:
-;;? Clean non-galvanized, ferrous metal surfaces, that have not been shop-coated;
remove oil, grease, dirt, loose mill scale and other foreign substances. Use solvent
or mechanical cleaning methods that comply with the recommendations of the Steel
Structures Painting Council.
b. Blast clean steel surfaces as recommended by the coating system
manufacturer and in accordance with the requirements of SSPC specification
SSPC-SP 10.
c. Touch-up shop applied prime coats which have been damaged, and bare
areas. Wire-brush, solvent clean, and touch-up with the same primer as the shop
coat.
SPECIAL COATINGS
09800-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F& V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
3. Non-Ferrous Metal Surfaces: Clean non-ferrous and galvanized surfaces in
accordance with the manufacturer's instructions for the type of service, metal substrate
and application required.
C. Material Preparation:
-c- ~.,..
- -
--- -
1~ Carefully mix and prepare materials in compliance with the coating manufacturer's
directions. Two component materials shall be mixed by power agitation only.
2. Stir materials before application to produce a mixture of uniform density, and as
required during application. Do not stir film, which may form on surfaces, into the
material. Remove film and, if necessary, strain the &&
3.03 APPLICATION:
A. General:
1. Apply special coatings by brush, roller, spray, squeegee, or other applicators in
accordance with manufacturer's directions. Use brushes best suited for the material
being applied. Use rollers of carpet, velvet back, or high-pile sheep's wool as
recommended by the manufacturer for the material and texture required.
2. Coating colors, surfaces treatments and finishes are indicated in the "Schedules" of
the contract documents.
3. Provide finish coats compatible with the primers used.
4. The number of coats and film thickness required is the same regardless of the
application method. Do not apply succeeding coats until the previous coat has cured as
recommended by the manufacturer. Sand between applications where sanding is
c~q~ired to produce an even smooth surface in accordance with the manufacturer's
directions.
5. The term "exposed surfaces" includes areas visible when permanent or built-in
fixtures, convector covers, covers for finned tube radiation, grilles, and similar
components are in place in areas to be coated. Extend coatings in these areas as
required to maintain the system integrity and provide desired protection.
6. Coat surfaces behind movable equipment and furniture the same as similar exposed
surfaces.
7. Coat the back sides of access panels, removable or hinged covers, and similar
hinged items, to match exposed surfaces.
SPECIAL COATINGS
09800-7
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Minimum Coatinq Thickness:
Apply each material at not thinner than the manufacturer's recommended spreading
rate. Provide total dry film thickness of the entire system as recommended by the
manufacturer. Applicators must maintain a wet film thickness gauge on t~ project
~rif1g coating operations. _ .
C. Prime Coats:
1. Before application of finish coats, apply a prime coat, as recommended by the
manufacturer, to material required to be coated or finished, and which has not been
prime coated by others.
2. Recoat primed and sealed substrates where there is evidence of suction spots or
unsealed areas in the first coat, to assure a finish coat with no burn-through or other
defects due to insufficient sealing.
D. Brush Application:
1. Brush-out and work brush coats into surfaces in an even film. Eliminate cloudiness,
spotting, holidays, laps, brush marks, runs, sags, ropiness, or other surface
imperfections. Neatly draw glass lines and color breaks.
2. Apply primers and first coats by brush unless the manufacturer's instructions permit
use of mechanical applicators.
E. Mechanical Applications:
1. Use mechanical methods for coating application when permitted by the
manufacturer's recommendations, governing ordinances, and trade union.regulations.
~ ~
2. Wherever spray application is used, apply each coat to provide the equivalent hiding
of brush-applied coats. Do not double-back with spray equipment building-up.film .
thickness of 2 coats in one pass, unless recommended by the manufacturer.
F. Completed Work:
Match approved samples for color, texture and coverage. Remove, refinish or recoat
work not in compliance with specified requirements.
3.04 FIELD QUALITY CONTROL:
A. The Owner reserves the right to invoke the following test procedure at any time, and as
often as the Owner deems necessary, during the period when coating operations are
being conducted.
SPECIAL COATINGS
09800-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. The Owner will engage the services of an independent testing laboratory to sample the
coating being used. Samples of material delivered to project site will be taken, identified
and sealed, and certified in the presence of the Contractor.
C. Jh~testing laboratory will perform appropriate tests for the following characteristics as
req-uired by the Owner:
1. Quantitative materials analysis including solids by volume.
2. Absorption.
3. Accelerated weathering.
4. Accelerated yellowness.
5. Color retention.
6. Alkali and mildew resistance.
7. Abrasion resistance.
8. Apparent refloctivity.
9. Washability.
10. Dry Opacity.
11. Recoating.
12. Skinning.
D. If results show materials being used do not comply with requirements, the Contractor
may be directed to stop work, and remove non-complying materials, pay for testing,
recoat surfaces coated with rejected materials, or remove rejected materials from
previously coated surfaces if, upon recoating with specified materials, the two coatings
are not compatible.
3.05 CLEANING:
A. At the end of each work day, remove rubbish, empty cans, rags and other discarded
.,m'!ierials from the site.
B. Upon completion of work, clean glass and spattered surfaces. Remove spattered
coatings by washing, scraping or other proper methods, using care not to scratch or
damage adjacent finished surfaces.
C. Remove and dispose of all containers and paint residue in accordance with State, Local
and Federal regulations.
3.06 PROTECTION:
A. Protect work of other trades, whether to be coated or not, against damage from
coating. Correct damage by cleaning, repairing, replacing, and recoating as acceptable
to the Engineer. Leave in an undamaged condition.
SPECIAL COATINGS
09800-9
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Provide "Wet Paint" signs to protect newly-coated finishes. Remove temporary
protective wrappings provided by others for protection of their work, after completion of
coating operations.
C. At completion of construction activities of other trades, touch-up and restore_damaged
... .~
(jf defaced coated surfaces.
3.07 EXTERIOR SPECIAL COATING SCHEDULE:
A. General:
1. Provide the following coating systems for substrates indicated.
2. Apply additional coats when undercoats or other conditions show through the final
coat, until the cured film is of uniform coating finish, color and appearance.
B. Ferrous Metal:
1. (Process equipment and pipinq above fluid level and not subiect to splash):
a. 2-Component Aliphatic Polvurethane Coatinq: SSPC-SP10 minimum surface
preparation. Provide a spray applied high solids single coat system with a total dry
film thickness not less than 7.0 mils.
1. Primer: Primer for ferrous metal under a 2-component aliphatic
polyurethane coating (5 mils min. DFT).
2. Finish Coat: 2-component aliphatic polyurethane coating (2 mils min. DFT).
2. (Process equipment and pipinq below fluid level or subiect to splash):
-.
c:; ,...
a. 2-Component Polvamide-Epoxv Coal-Tar: Provide two coats with total dry film
thickness not less than 15 mils.
1. First Coat: Coal-tar Epoxy (SSPC Paint 16).
2. Second Coat: Coal-tar Epoxy (SSPC Paint 16).
C. (Miscellaneous Ferrous Metal - Heat Resistant):
1. Heat-Resistant Coatinq: For surface temperatures up to 1000 deg. F (538 deg.C).
Provide 2 coats.
a. First Coat: Aluminum Pigmented, Silicone-Based Heat-Resistant Coating (FS
TT-P-28).
SPECIAL COATINGS
09800-10
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
b. Second Coat: Aluminum Pigmented, Silicone-Based Heat-Resistant Coating
(FS TT-P-28).
D. (Diqester Covers and accessories):
~ ..
... -
--. -
r 2-Component Polyester Polyurethane Coating: SSPC-SP10 minimum.surface
preparation. Provide a spray applied high solids single coat system with a total dry film
thickness not less than 10.0 mils.
a. Prime: Primer for ferrous metal under a 2-component aliphatic or polyester
polyurethane coating (5 mils min. DFT).
b. Finish Coat: 2-component polyester/polyurethane coating (2.5 mils min. DFT).
3.08 INTERIOR SPECIAL COATING SCHEDULE:
A. General:
1. Provide the following coating systems for substrates indicated:
2. Apply additional coats when undercoats or other conditions show through final coat,
until the cured film is of uniform coating finish, color and appearance.
B. Ferrous Metals:
1. (Process equipment and pipinQ above fluid level and not subject to splash):
a. High Performance Polyamide Epoxy Coating: Provide 1 Prime and 2 finish
coats with total dry film thickness not less than 1 0.0 mils.
4;- r"""
1. Metal Primer: Manufacturer's recommended metal primer.
2. First Coat: High Performance Polyamide Epoxy Coating (FS TT-C-535,
Type II).
3. Second Coat: High Performance Polyamide Epoxy Coating (FS TT-C-535,
Type II).
2. (Process equipment and pipinQ below fluid level or subiect to splash):
a. 2-Component Polyamide-Epoxy Coal-Tar: Provide two coats with total dry film
thickness not less than 15 mils.
1. First Coat: Coal-tar Epoxy (SSPC Paint 16).
SPECIAL COATINGS
09800-11
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2. Second Coat: Coal-tar Epoxy (SSPC Paint 16).
C. (Miscellaneous):
1. f1iqh Performance Polvamide Epoxv Coatinq System: Provide 2 finist"! coats of
2-component polyamide epoxy coating, gloss finish (FS TT-C-535, Type II) over metal
pnmer.
a. Metal Primer: Manufacturer's recommended metal primer.
b. First Coat: High Performance Polyamide Epoxy Coating (FS TT-C-535, Type
II) .
c. Second Coat: High Performance Polyamide Epoxy Coating FS TT-C-535, Type
II) .
D. (Dioester Covers and accessories):
1. Hiqh Performance Polvamide Epoxv Coatinq: SSPC-SP10 minimum surface
preparation. Provide 2 finish coats with total dry film thickness not less than 10.0 mils.
a. Metal Primer: Manufacturer's recommended metal primer.
b. First Coat: High Performance Polyamide Epoxy Coating (FS TT-C-535, Type
II).
c. Second Coat: High Performance Polyamide Epoxy Coating (FS TT-C-535,
Type II).
~
~ ~
END OF SECTION 09800
SPECIAL COATINGS
09800-12
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 11000 - GENERAL REQUIREMENTS FOR EQUIPMENT
PART 1 - GENERAL
1.01 DESCRIPTION:
Q ...
A. SCOPE:
This section specifies general requirements which are applicable to all mechanical
equipment in these specifications. The Contractor is responsible for ensuring that all
mechanical equipment meets the requirements of this section in addition to the
specific requirements of the individual equipment specification section.
B. EQUIPMENT LISTS:
Equipment lists, presented in these ~pecifications and as specified on the drawings,
are included for the convenience of the Engineer and Contractor and are not
complete listings of all equipment, devices and material to be provided under this
contract. The Contractor agrees to prepare his own material and equipment takeoff
lists as necessary to meet the requirements of this project manual.
1.02 QUALITY ASSURANCE:
A. ARRANGEMENT:
The arrangement of equipment shown on the drawings is based upon information
available to the Owner at the time of design and is not intended to show exact
dimensions peculiar to a specific manufacturer. The drawings, are in part,
diagrammatic, and some features of the illustrated equipment installation may require
revision to meet actual equipment installation requirements. Structural supports,
foundations, connected piping, valves, and electrical conduit specified may have to be
a1tered to accommodate the equipment provided. No additional payment will be made
for such revisions and alterati08s.
B. REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall
prevail.
GENERAL REQUIREMENTS FOR EQUIPMENT
11 000-1
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Reference
Title
AFBMA Std. 9-78
Load Ratings and Fatigue Life for Ball Bearings
-:Ar:"'BMA Std. 11-78
Load and Fatigue Life for Roller Beari!1gs
ANSI B1.1-82
Unified Screw Threads
ANSI B1.20.1-83
Pipe Threads, General Purpose (Inch)
ANSI B16.1-75
Cast Iron Pipe Flanges and Flanged Fittings, Class
125
ANSI B18.2.1-81
Square and Hex Bolts and Screws, Including Askew
Head Bolts, Hex Cap Screws, and Log Screws
ANSI B18.2.2-87
Square and Hex Nuts
C. UNIT RESPONSIBILITY:
Equipment systems made up of two or more components shall be provided as a unit
by the responsible manufacturer.. Unless otherwise specified, the Contractor shall
obtain each system from the supplier of the driven equipment, which supplier shall
provide all components of the system to enhance compatibility, ease of construction
and efficient maintenance. Contractor is responsible to the Owner for performance of
all systems as provided in Division 1.
PART 2 - PRODUCTS
2.01 FLANGES AND PIPE THREADS:
...
Flanges on equipment and appurtenances provided under this section shall conform in
dimensions and drilling to ANSI B16.1, Class 125. Pipe threads shall conform in
dimension and limits of size to ANSI B1.1, coarse thread series, Class 2 fit.
Threaded flanges shall have a standard taper pipe thread conforming to ANSI B1.20.1.
Unless otherwise specified, flanges shall be flat faced.
Flat assembly bolts shall be heavy pattern, hexagonal head, carbon steel machine bolts
with heavy pattern, hot pressed, hexagonal nuts conforming to ANSI B18.2.1 and
B 18.2.2. Threads shall be Unified Screw Threads, Standard Coarse Thread Series,
Class 2A and 2B, ANSI B 1.1.
GENERAL REQUIREMENTS FOR EQUIPMENT
11000-2
I
I
I
I
I
I
I
I
I
I
I
I
I'
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2.02 BEARINGS:
Unless otherwise specified, equipment bearings shall be oil or grease lubricated, ball or
roller type, designed to withstand the stresses of the service specified. Each bearing
shall be rated in accordance with the latest revisions of AFBMA Methods of Evaluating
Load Ratings of Ball and Roller Bearings. Unless otherwise specified, equj,pment
.... -
bear'ings shall have a minimum L-10 rating life of 50,000 hours. The rating.life shall be
determined using the maximum equipment operating speed.
Grease lubricated bearings, except those specified to be factory sealed and lubricated,
shall be fitted with easily accessible grease supply, flush, drain and relief fittings.
Extension tubes shall be used when necessary. Grease supply fittings shall be standard
hydraulic alemite type.
Oil lubricated bearings shall be equipped with either a pressure lubricating system or a
separate oil reservoir type system. Each oil lubrication system shall be of sufficient size
to safely absorb the heat energy normally generated in the bearing under a maximum
ambient temperature of 60 degrees C. and shall be equipped with a filler pipe and an
external level indicator gauge.
2.03 V-BELT ASSEMBLIES:
Unless otherwise specified, V-belt assemblies shall be Dodge Dyna-V belts with matching
Dyna-V sheaves and Dodge Taper-lock bushings, Wood's Ultra V-belts with matching
Ultra-V sheaves and Wood's Sure-Grip bushing, or equal.
Sheaves and bushings shall be statically balanced. Additionally, sheaves and bushings
which operate at a peripheral speed of more than 5,500 feet per minute shall be
dynamically balanced. Sheaves shall be separately mounted on their bushings by means
of three pull-up grub or cap tightening screws. Bushings shall be key seated to the drive
sha~. ~
Selts shall be selected for not less than 150 percent of rated driver horsepower and, .
where two sheaves sized are specified, shall be capable of operating with either set of
sheaves. Belts shall be of the anti-static type where explosion-roof equipment is
specified.
2.04 SEALS:
A. MECHANICAL:
Unless otherwise specified, rotating shafts shall be provided with mechanical seals
and stuffing boxes tapped (or flushing seal faces. Seals shall be factory installed.
Seals shall be internal, single or double as specified, and unbalanced except
balanced seals shall be provided when shaft speed is greater than 3,600 rpm for
GENERAL REQUIREMENTS FOR EQUIPMENT
11000-3
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
variable speed pumps, or when pressures are greater than shown in the following.
Mechanical seals for variable speed pump applications shall be specifically designed
to accommodate shaft deflection incurred under specified operating conditions.
Seal inside Sea I illil
... ~ diameter, inches Shaft speed, rpm
- pressure, pSlq
1/2 to 2 Up to 1,800 100
1,801 to 3,600 50
Over 2 to 4 Up to 1,800 50
1,801 to 3,600 25
Single unbalanced seals shall be Crane 8-1, Durametallic RO, or equal. Single
balanced seals shall be Chesteron 880, Crane 8B-1 , or equal. Double seals shall be
Chesteron 241, Durametallic RO/RD, or equal.
To maintain the necessary minimum or maximum pressure across the seal faces,
spring pressure shall be uniformly distributed to the sealing faces by a coil spring or
multiple springs. The rotating seal element shall be clamped to the shaft and
provided with an O-ring seal. The stationary seal element shall be sealed with O-ring
or gasket material.
Seal faces shall be either tungsten carbide, carbon, silicon carbide or ceramic.
Elastomeric materials shall be Viton. Metal parts shall be type 316 stainless steel.
B. SHAFT PACKING:
Where shaft packing is specified, stuffing boxes shall be tapped to permit introduction
Of seal liquid and shall hold a minimum of five rows of packing. Unless otherwise
specified, latern rings shall be bronze, packing shall be die-molded packin~ rings of
non-asbestos material suitable for the intended service and as recommended by the
manufacturer, and glands shall be bronze, two piece split construction. Lantern rings
shall be of two-piece construction and shall be provided with tapped holes to facilitate
removal. Lantern rings shall be drilled and tapped 1/4 NC-20. Threaded lantern ring
removal tools shall be provided with spare parts for each pump.
2.05 COUPLINGS:
Unless otherwise specified in the particular equipment sections, equipment with a driver
greater than 1/2 HP, and where the input shaft of a driven unit is directly connected to the
output shaft of the driver, shall have its two shafts connected by a flexible coupling which
can accommodate angular misalignment, parallel misalignment and end float, and which
GENERAL REQUIREMENTS FOR EQUIPMENT
11000-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
cushions shock loads and dampens torsinal vibrations. The flexible member shall consist
of a tire with synthetic tension members bonded together in rubber. The flexible member
shall be attached to flanges by means of clamping rings and cap screws, and the flanges
shall be attached to the stub shaft by means of taperlock bushings which shall give the
equivalent of a shrunk-on fit. There shall be no metal-to-metal contact between the driver
ani th~ driven unit. Each coupling shall be sized and provided as recomrrrended by the
coupling manufacturer for the specific application, considering horsepower, speed or
rotation, and type of service.
Where torque or horsepower capacities of couplings of the foregoing type is exceeded,
Thomas-Rex, Falk Steel Flex, or equal, couplings will be acceptable provided they are
sized in accordance with the equipment manufacturer's recommendations and sizing
data are submitted. They shall be installed in conformance to the coupling
manufacturer's instructions.
2.06 GUARDS:
Exposed moving parts shall be provided with guards which meet the requirements of
OSHA. Guards shall be fabricated of 14-gauge stainless steel, 1/2-13-15 expanded
metal screen or rigid fiberglass with screen to provide visual inspection of moving parts
without removal of the guard. Guards shall be galvanized after fabrication and shall be
designed to be readily removable to facilitate maintenance of moving parts. Reinforced
holes shall be provided. Provisions shall be made to extend lube fittings through guards.
2.07 CAUTION SIGNS:
Equipment with guarded moving parts which operates automatically or by remote control
shall be identified by signs reading "CAUTION-AUTOMATIC EQUIPMENT MAY START
AT ANY TIME." This includes supply and exhaust fans. Signs shall be constructed of
fiberglass material, minimum 0.1 inch thick, rigid, 10 inches by 14 inches, suitable for
mOl,JntLng per paragraph 10441-3.02. Letters shall be black on a yellow background.
These signs shall be in addition to signs specified in Division 10.
2.08 GAUGE TAPS. TEST PLUGS, AND GAUGES:
Gauge taps shall be provided on the suction and discharge sides of pumps, blowers and
compressors. Pressure and vacuum gauges shall be provided where specified. Gauge
taps, test plugs, and gauges shall be as specified in Divisions 13 and 15.
2.09 NAMEPLATES:
Nameplates shall be provided on each item of equipment and shall contain the specified
equipment name or abbreviation and equipment number as designated on the Process
and Instrumentation Drawings. Equipment nameplates shall be engraved or stamped
GENERAL REQUIREMENTS FOR EQUIPMENT
11000-5
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
stainless steel and fastened to the equipment in an accessible location with stainless
steel screws or drive pins.
2.10 LUBRICANTS:
Th~d'litractor shall provide for each item of mechanical equipment a supply of the
lubricant required for the commissioning period. Lubricants shall be of the type
recommended by the equipment manufacturer and shall be products of the Owner's
current lubricant supplier. The Contractor shall limit the various types of lubricants by
consolidating them, with the equipment manufacture's approval, into the least number of
different types. Not less than 90 days before the date shown in his construction schedule
for starting, testing and adjusting equipment, the Contractor shall provide the Owner with
five copies of a list showing the required lubricants by name and type, after consolidation,
for each item of mechanical equipment. The list shall show estimated quantity of
lubricant needed for a full year's operation, assuming the equipment will be operating
continuously.
2.11 ANCHOR BOLTS:
Anchor bolts shall be designed for lateral forces for both pullout and shear. Unless
otherwise stated in the detailed specification, anchor bolt materials shall be 316L
stainless steel.
2.12 SPARE PARTS:
Spare parts, wherever required by detailed specification sections, shall be stored in
accordance with the provisions of this paragraph. Spare parts shall be tagged by project
equipment number and identified as to part number, equipment manufacturer, and
subassembly component (if appropriate). Spare parts subject to deterioration such as
ferrous metal items and electrical components shall be properly protected by lubricants or
desicc,?nts and encapsulated in hermetically sealed plastic wrapping. Spare parts with
individual weights less than 50 pounds and dimensions less than 2 feet wide, or 18
inches high, or 3 feet in length shall be stored in a wooden box with a hinged wooden
cover and locking hasp. The box shall be painted and identified with stenciled lettering
stating the name of the equipment, equipment numbers, and the words "spare parts." A
neatly typed inventory of spare parts shall be taped to the underside of the cover.
PART 3 - EXECUTION
Installation of equipment accessories included in this section shall be as recommended
by the equipment manufacturer unless otherwise specified in the individual equipment
specification section.
END OF SECTION 11000
GENERAL REQUIREMENTS FOR EQUIPMENT
11000-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 11002 -EQUIPMENT MOUNTING
PART 1 - GENERAL
::,:;V
1.01 DESCRIPTION:
.... -
This-se-ction specifies mounts, supports, and anchorage for equipment, tanks, piping and
accessones.
1.02 QUALITY ASSURANCE:
Support, anchorage, and mounting of all tanks, piping and equipment shall be provided
by the Contractor according to the manufacturer's recommendations, Standard Building
Code, and industry standards requirements, unless otherwise specified and/or shown.
All elements required to resist the calculated forces described herein or required by the
equipment manufacturer shall be provided by the Contractor.
PART 2 - PRODUCTS
2.01 GENERAL:
Equipment mountings shall be as shown. All equipment located on floor slabs shall be
mounted on concrete pads. Where a steel or cast base is shown or specified between
the equipment and the concrete pedestal, it shall be hot-dip galvanized after fabrication
unless otherwise specified.
2.02 CAST IRON BASES:
Cast iron bases located within a building do not require galvanizing but must be sealed in
accordance with the requirements specified in Section 09800 prior to grouting. All
fasteners requiring connections to the base shall be terminated by nuts welded to the
bottOm side of the base and plugged with cork, plastic lugs or grease, or acorn nuts. In
no case shall the fastener terminate only into the metal base.
2.03 CONCRETE PEDESTALS:
Concrete pedestals shall be at least 2 inches larger than the steel or cast base. All
conduits, piping connections, and drains shall be enclosed by the concrete base. Unless
otherwise shown or specified, no conduits, piping connections, or drains will be accepted
which rise directly from the floor.
EQUIPMENT MOUNTING
11002-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
PART 3 - EXECUTION
3.01 INSTALLATION:
A. EQUIPMENT:
... -
Each piece of equipment shall be anchored to resist a minimum lateral force required
by the code or manufacturer of the equipment. This force shall be considered acting
at the center of gravity of the piece under consideration. No equipment shall be
anchored to vertical structural elements without written approval of the Engineer. The
installation shall be certified on Form 11 OOO-A attached.
Equipment which is not vibration isolated shall be anchored directly to the supporting
floor system. In addition to the anchorage, all such equipment shall be internally
designed so that all static and moving parts are anchored to the supporting framework
to resist any imposed seismic force. All forces must be transmitted to the base in
order to be anchored as required. Vibration isolated equipment shall be specially
designed to meet these same requirements.
Equipment, tanks, piping supports, and anchorage located outside any building or
structure shall be designed to comply with the latest SBC.
B. PIPING:
All piping, raceways, accessories, and appurtenances furnished with equipment shall
be anchored to resist the lateral force generated by the internal thrust of the system.
This force shall be considered acting at the center of gravity of the piece under
consideration.
Piping with flexible connections and/or expansion joints shall be anchored such that
tbe ~intended used of these joints are maintained in the piping system.
C. DUCTWORK:
All ductwork for both heating, ventilating, and air conditioning and for mechanical
equipment shall be anchored to the floor system(s) or to the roof as shown on the
drawings.
END OF SECTION 11002
EQUIPMENT MOUNTING
11002-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I.
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia .
11002-A. MANUFACTURER'S INSTAllATION CERTIFICATION FORM:
Contract No.:
Specification Section:
Equipment Name:
. -
Contractor: -
Manufacturer of Equipment Item:
The undersigned manufacturer of the equipment item described above hereby certifies that he
has checked the installation of the equipment and that the equipment, as specified in the
Project Manual, has been provided in accordance with the manufacturer's recommendations
and that the trial operation of the equipment item as been satisfactory.
Comments:
Date
Manufacturer
Signature of Authorized Representative
~
Date
Contractor
Signature of Authorized Representative
EQUIPMENT MOUNTING
11002-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 11020 - VIBRATION AND CRITICAL SPEED LIMITATIONS
PART 1 - GENERAL
1.01 DESCRIPTION:
... "-
This-section specifies vibration and critical speed limitations for rotating mechanical
equipment. Field testing and vibration measurements shall be taken when specified.
1.02 VIBRATION LIMITATIONS:
A. GENERAL:
Vibration frequencies shall span the range from 5.0 to 5,000 Hz. Where specified,
measurements shall be obtained while the installed equipment is operating within the
specified speed range.
B. CENTRIFUGAL:
1. MACHINES WITH SLEEVE BEARINGS: Unless otherwise specified, centrifugal
machines with sleeve bearing shafts shall not exhibit unfiltered RMS readings for
vibration displacement in excess of the following:
Shaft speed ranqe, rpm
Displacement. peak to peak. mils
Up to 900
901 to 1,800
1,801 to 3,000
3,001 to 4,500
Above 4,500
3.5
3.0
2.5
2.0
1.6
...
Elisplacement measurements shall be taken radially on the shaft at two points at each
bearing. Measuring points shall be 90 degrees apart.
2. MACHINES WITH ANTI-FRICTION BEARINGS: Unless otherwise specified,
centrifugal machines with anti-friction bearing shafts shall not exhibit unfiltered RMS
readings for vibration velocity in excess of 0.12 inch per second. Velocity
measurements shall be taken on one point of each bearing housing.
C. POSITIVE DISPLACEMENT MACHINES:
Unless otherwise specified, positive displacement machines of the rotary,
reciprocating and controlled volume types shall operate without any lateral or torsional
vibration characteristics that may accelerate wear of the equipment. The Contractor
shall provide manufacturer's certification that the manufacturer has inspected the
VIBRATION AND CRITICAL SPEED LIMITATIONS
11020-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
machine under operating conditions and found it to comply with the requirements of
this paragraph.
1.03 CRITICAL SPEED REQUIREMENTS:
Unl~s"'otherwise specified, rotating mechanical equipment shall not exhibit critical
speeds within the specified range of operating speeds. Critical speeds for equipment
with rigid rotor systems shall be at least 20 percent greater than maximum operating
speed. Critical speeds for equipment with flexible shaft-rotor systems shall be at least 15
percent below minimum operating speed and 20 percent above maximum operating
speed.
1.04 SUBMITTALS:
The following information shall be provided in accordance with Section 01800:
A. Manufacturer's certified data showing location of critical speeds in relation to
operating speeds.
B. A copy of this specification section and all referenced sections with each paragraph
check marked to show specification compliance or marked to show deviations.
END OF SECTION 11020
VIBRATION AND CRITICAL SPEED LIMITATIONS
11020-2
I
I
I
I
I
I
I
I
I
I
I
I.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 11800 - DIGESTER SLUDGE MIXERS
PART 1 - GENERAL
1.01 RELATED DOCUMENTS:
A. erawings and general provisions of Contract, including General and Suppl~mentary
Conditions and Division-1 Specification sections apply to work of this section.
1.02 SUMMARY:
A. The Contractor shall furnish, install, adjust, and test four (4) digester sludge mixers
for each digester and as shown on the plan drawings. The equipment to be
provided with each of the mixers shall include the reversible drive assembly, drive
assembly housing, lubrication systems, draft tubes, lower anchoring base, drive
guard, controls, and accessories.
B. The equipment covered by these specifications is intended to be standard
equipment of proven performance as manufactured by reputable concerns.
Equipment shall be designed, constructed, and installed in accordance with the best
practices of the trade, and shall operate satisfactorily when installed as shown on the
Contract Drawings.
C. Available Manufacturers: Subject to compliance with requirements, manufacturers
offering products which may be incorporated in the work include, but are not limited
to, the following:
1. EIMCO Process Equipment Co.
2. WesTech Engineering, Inc.
3. Approved Equal
D. EQUIPMENT LIST:
Item
Equipment Number
Primary Anaerobic DiQester NO.1
Digester Mixer NO.1 MX7201
Digester Mixer NO.2 MX7202
Digester Mixer NO.3 MX7203
Digester Mixer NO.4 MX7204
Primary Anaerobic Digester NO.2
Digester Mixer No. 1 MX7301
Digester Mixer NO.2 MX7302
Digester Mixer No.3 MX7303
Digester Mixer NO.4 MX7304
DIGESTER SLUDGE MIXERS
11800-1
F&V Project No.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Primary Anaerobic Diqester NO.4
Digester Mixer NO.1 MX7401
Digester Mixer NO.2 MX7402
Digester Mixer NO.3 MX7403
Digester Mixer No.4 MX7404
- -
... -
Primary Anaerobic Diqester NO.5
Digester Mixer NO.1 MX7501
Digester Mixer No.2 MX7502
Digester Mixer NO.3 MX7503
Digester Mixer NO.4 MX7504
1.03 RELATED WORK
A. Division 3 - Concrete
B. Division 5 - Metals
C. Division 9 - Finishes
D. Division 13 - Instrumentation
E. Division 16 - Electrical
1.04 REFERENCES
A. ASTM A-36 - Standard Specifications for Steel Bridges and Buildings
B. AWS - American Welding Society
1.04 SUBMITTALS
A. The Contractor shall submit to the Engineer for review, design data, support details,
and detailed shop drawings of the mixers in accordance with the requirements of
Section 01800.
B.- The submittal shall include a list of not less than six (6) mixer installations using a 36"
diameter ragless propeller and meeting the requirements of these specifications, and
which have been in operation for at least one (1) year.
1.05 OPERATION AND MAINTENANCE MANUAL
A. The contractor shall submit operation and maintenance manuals in accordance with
the procedures and requirements wet forth in Section 01730. Two copies of a
preliminary or reference O&M manual shall be included in the shop drawing
submittal. Final manuals shall include information regarding the shop testing of each
mixer.
DIGESTER SLUDGE MIXERS
11800-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
1.06 SERVICES OF MANUFACTURER'S REPRESENTATIVE
A. The Contractor shall provide the services of a qualified manufacturer's technical
representative who shall adequately inspect the installation and testing of all
... e<1uipment furnished under this Contract and instruct the Contractor's personnel and
-the Owner's operating personnel in its maintenance and operation of the equipment.
The services of the manufacturer's representative shall be provided for a period of
not less than four (4) days as follows:
B. One trip of two (2) days for installation inspection and start-up services.
C. One trip of two (2) days to instruct Owner's operating personnel.
D. The Contractor shall be responsible for successful installation and operation of the
I equipment.
PART 2 - PRODUCTS
2.01 DRAFT TUBE MIXERS - GENERAL
A. Each mixer assembly shall consist of a drive unit, drive shaft, drive shaft housing,
upper and lower drive shaft bearings, motor and structural motor mount, seals, drive
mounting flange, propeller, belt guards, and controls. The mixer assembly shall be
removable as a unit without disturbing the Sludge Mixer draft tube, without varying
the normal water level or gas pressure within the digesters, and without removing the
motor drive assembly.
B. Each mixer shall have a nominal recirculation capacity of 20,000 GPM, with the flow
directed in either the upward or the downward direction.
2.02 SWDGE MIXER DRIVE DESIGN
A. The drive assembly shall consist of a 15 horsepower explosion-proof, reversible
single-speed motor driving a vertical propeller shaft through guarded static-
conducting V-belts and sheaves. The V-belts must be easily replaceable. The belt
drive shall be protected with an FRP belt guard meeting OSHA requirements and
incorporate the use of stainless steel quick-release latches.
B. The drive shaft shall be of cold-rolled steel enclosed within a steel shaft housing.
The upper drive shaft bearing shall consist of an anti-friction, grease lubricated roller
bearing. The upper bearing shall be mounted near the top of the drive shaft and
shall be replaceable without removing the mixer assembly from the draft tube. The
upper bearing shall be designed to withstand all applied axial and radial loads. The
upper bearing shall include type URn seals at both ends. The lower bearing shall be
DIGESTER SLUDGE MIXERS
11800-3
F&V Project No.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
contained within a separate lower shaft housing mounted near the propeller
(approximately 4" from the propeller) and designed to withstand all applied radial
loads. This bearing shall be protected by a mechanical seal cartridge including a
tungsten carbide rotary seal face and a tungsten carbide stationary seal seat
designed to prevent entry of any foreign material. A positive head of oil shall be
jTIaTntained upon the lower bearing at all times. An oil level dip stick accessible from
above the drive mounting flange shall be provided to allow for inspection of the lower
bearing oil level.
C. A center stabilizing assembly which is permanently mounted to the mixer drive shaft
housing shall be .provided to assist in dampening site specific hydraulic frequencies.
This assembly shall be adjustable from above the drive mounting flange. This
device shall act as a partial flow deflector when pumping in the upward direction.
D. For each mixer there shall be provided a 36" diameter, 3-bladed propeller mounted
at the end of the vertical drive shaft. The mixer design shall allow for periodic
reversing of drive shaft rotation without a reduction in mixing effectiveness in the
reversed condition. The propeller shall be constructed of cast iron, ASTM 48A Class
40, with a Brinell hardness of at least 215, and shall be of a "rag less" design,
capable of pumping either upward or downward without loss of efficiency. A
"ragless" design shall be designed as one in which the angle of the leading edge of
the propeller is such that any stringy or fibrous material striking the propeller blades
will be directed outward, away from the hub of the propeller. This rag less condition
must occur when pumping in both the upward and downward directions. Pumping
efficiency shall be certified by an independent engineer. Certification shall include
pumping rates in both directions.
E. The drive mounting flange shall be fabricated of 1/2" steel plate. It shall be provided
with suitable gas-tight connections for mounting the drive assembly to the draft tube.
2.03 COVER MOUNTED DRAFT TUBE DESIGN
A. The draft tube for the cover mounted mixers shall be fabricated of 1/4" steel and
shall be 39" diameter and shall be supported from the digester cover. It shall be
designed with a flange at the top to mate with the mixer mounting port flange as part
of the digester cover design. The upper portion of the draft tube shall be a steel
cylinder designed to permit removal of the mixer drive assembly without loss of
digester gas through the mixer mounting port. The draft tube shall be connected to
this cylinder with anti-vortex support members and shall extend sufficient length to
enclose the propeller. The draft tube shall be supported from the digester cover and
shall extend sufficient length to enclose the propeller and to overlap the lower
extension tube by a minimum of 12 inches.
B. The lower extension tube shall be arranged as shown on the plans and shall have
a minimum diamtere of 40 inches. The extension tube shall be of sufficient length
DIGESTER SLUDGE MIXERS
11800-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
to overlap the cover supported draft tube and to extend within 5 feet of the tank
floor. It shall be supported by structural legs which shall be anchored to the
digester tank floor. Anchor bolts shall be epoxy set and 316 stainless steel.
2.04 EXTERNAL DRAFT TUBE DESIGN
-
A. 'lhe mixers to be located external to the digester tanks shall be design~d. with a 39"
diameter vertical dfaft tube fabricated from 1/4" steel plate. The draft tube shall be
designed with suitable flanges for gas-tight connection to the mixer drive assembly
and mounting flange.
B. The design of the external draft tube shall include an upper and a lower section for
attachment of the mixef inlet/discharge nozzles and an integral mounting base
designed to support the entire weight of the mixer.
C. Inlet/dischafge nozzles for the unit shall be 36" in diameter. The nozzles shall
penetrate the concrete tank wall along a radial line emanating from the digester
center in accordance with the details shown. Inlet/discharge nozzles shall terminate
outside the digester in a welded connection to the vertical draft tube sections and
inside the digester in a 450 elbow which can be oriented to provide maximum mixing
and scum breaking capability. A 3/16", minimum thickness, square escutheon plate
shall be provided for each nozzle to cover the wall opening.
2.05 HEAT EXCHANGE JACKETS
A. There shall be furnished as part of each external sludge mixer draft tube a hot water
heat exchanger jacket. The heat exchanger jacket shall serve to heat the digester
sludge as it is recirculated through the enclosed draft tube.
B. The heat exchanger shall be capable of transferring 150,000_BTU per hour from the
hot water to the sludge when the avefage sludge temperature is 950F, and the
-sludge flow fate is 20,000 GPM, and the hot watef flow fate is 100 GPM and is
entering the exchanger at 160 OF.
C. The heat exchanger jacket shall be water-tight, constructed of 1/4" steel plate and
provided with internal baffles for directing the flow of water. The portion of the draft
tube surrounded by the heat exchanger shall be constructed of 3/16" type 304
stainless steel plate. It shall enclose, and be supported by, the vertical d.raft tube.
The heat exchanger jacket shall be provided with suitable inlet piping and outlet
piping to handle the flow of water required. The heat exchangef shall be designed
for operation at least 15 psi. The heat exchanger shall be provided with a pressure
reducing valve to protect against over-pressurization. The contractor shall insure
that when testing the water supply lines that the heat exchange jacket are protected
from over-pressurization.
DIGESTER SLUDGE MIXERS
11800-5
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
D. Adequate insulation shall be provided as part of the heat exchanger jacket.
Insulation shall be provided as specified in other sections and installed by the
Contractor.
2.06 MIXER MAINTENANCE PLATFORM
oiii. ...
- -
A. Each externally mounted mixer shall be provided with an 10' by 10' -maintenance
platform as shown on the plans. The mixer manufacturer shall provide the structural
framing members and support members for the platform and the contractor shall
supply the accessory handrail and grating conforming to the platform design and to
the sections of these specifications describing handrail and grating requirements.
B. The framing and structural members shall be of ASTM A36 steel fabrication.
Framing shall be coated as specified in Section 09800. The grating shall be
fiberglass reinforced plastic and the handrail shall be aluminum and as specified
elsewhere and supplied and installed by the Contractor.
2.07 MIXER MOTOR DESIGN
A. The motor for each mixer shall be designed, manufactured, and tested in
accordance with the latest edition of NEMA MG 1. The motor shall conform to the
following:
B. Type: Single-speed, reversible, explosion-proof, (Class I, Division 1, Group D).
C. Horsepower: 15 hp.
D. Motor speed: 1200 RPM.
E. Electrical: 230/460 volts, 3 phase, 60 hertz.
F. Minimum motor efficiency at high speed: 89%.
G. NEC rating: T2A.
2.08 DIGESTER SLUDGE MIXER CONTROLS
A. An explosion-proof selector switch station for mounting adjacent ,to each sludge
mixer shall be provided. The local station shall include selector switches suitable for
forward/reverse and hand/off/auto operation. A remote control panel for the
digesters shall be furnished under Section 13615. Reversing motor starters,
disconnects, transformers, etc. shall be provided in the MCC under Divivision 16 of
these specifications.
PART 3 - EXECUTION
3.01 INSTALLATION
A. The mixers shall be installed and lubricated in accordance with the manufacturer's
recommendations. The wall penetration for the upper and lower discharge and
DIGESTER SLUDGE MIXERS
11800-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.97 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
suction tubes shall be constrcuted by the prestressed tank vendor, Cram
Corporation, to maintain the structural integrity of the Anaerobic Digester structures.
3.02 ANCHOR/ASSEMBLY BOLTS
A. -.Adhesive anchor bolts constructed of 316 stainless steel with necessary hex nuts
~an~ washers shall be provided for all parts of the mixers which are to be secured to
the concrete external support pad.
B. All assembly bolts or bolts used for flanged connections shall be ASTM A449, Grade
5, HDG galvanized or zinc coated steel unless specific high strength bolts are
required as part of the mixer design.
3.03 FINISHES
A. All fabricated surfaces reC'luiring painting shall be shop cleaned by near white blast
and painted with one prime coat of Tnemec 66-1211, or equal. Final field painting
and touch up of the mixers shall be as directed Section 09800.
3.04 TESTING
A. The Contractor shall inspect the mixers after installation in accordance with the
manufacturers "Field Service Check List".
B. The manufacturer shall include the following tests at the factory:
1. Dynamic balance of each rag less propeller to not more than 3 mils vibration.
2. Each shaft shall be certified in the shop to not more than 0.006" TIR runout from
top to bottom.
3. Run each mixer drive unit with the propeller in dry or wet conditions in the shop
for at least 4 hours. The shop test shall show temperature at the shaft housing of
not more than 1500 F, and specifically at the lower bearing location of the shaft
housing the temperature shall not exceed 1500 F.
4. Check each shaft housing for pinhole leaks.
5. Complete check of all control panels to ensure proper operation.
6. Make all final adjustments as required prior to shipment.
C. The Contractor, assisted by the manufacturer, shall field verify the following items as
a minimum:
1. Motor installed and appropriately mounted for operation.
2. Mixer rotation direction and speed.
3. Motor reverses properly.
4. Amperage measurements not exceeding nameplate rating.
5. Proper lubrication.
6. Proper centering device adjustment.
DIGESTER SLUDGE MIXERS
11800-7
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
7. Assembly bolts tightened properly.
8. Drive belts aligned and tensioned properly.
9. Belt guards installed properly.
C. The Contractor shall correct any functional deficiencies. The Contractor shall
~p(evide all water and other materials necessary to complete the fiela verification.
Completed inspection reports shall be submitted to the Engineer.
END OF SECTION 11800
DIGESTER SLUDGE MIXERS
11800-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 11815 - DIGESTER GAS HANDLING EQUIPMENT
PART 1 - GENERAL
1.01 DESCRIPTION:
.... IIIIior
This seCtion specifies digester gas handling and safety equipment for anaerobic
digesters. The equipment covered by these specifications is intended to be standard
equipment of proven performance as manufactured by reputable concerns. Equipment
shall be designed, constructed, and installed in accordance with the best practices of the
trade, and shall operate satisfactorily when installed as shown on the Contract Drawings.
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ANSI B1.20.1-83
Pipe Threads, General Purpose (Inch)
ANSI B16.5-88
Pipe Flanges and Flanged Fittings
1.03 SUBMITTALS:
...
The following information shall be provided in accordance with Section 01800:
A. Manufacturer's Product data Sheets for each item.
1.04 RELATED WORK
A. Cover Position Indicators are specified in Section 13615.
B. Finish painting of ferrous metals and shop primed components is specified in Section
09800.
DIGESTER GAS HANDLING EQUIPMENT
1181 5- 1
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
PART 2 - PRODUCTS
2.01 RELIEF VALVE AND FLAME ARRESTER UNIT:
Pressure and vacuum relief valve with flame arrester shall have 6 inch size 125 lb. flat
faced flanged connections. Pressure relief shall be set at 8 inches WC. Capacity shall be
not less than 60,000 SCFH digester gas 8 inches WC. Vacuum relief shall be set at 2
inches WC. Capacity shall be not less than 30,000 SCFH at 4 inches WC under-
pressure. Pressure and vacuum ports shall be oversized to minimize over-pressure.
Pallets and seat rings shall be replaceable. Pallets shall be dead weight loaded, center
and side guided and shall include replaceable Teflon seat inserts. Pressure pallet shall
include removable loading weights to provide adjustment from 4" to 15".WC in 1" WC
increments. HDPE protective screens shall be provided at the pressure and vacuum
ports, located external of the pallets. The valve body, cover, flame arrester housing and
covers shall be fabricated from 356-T6 low copper cast aluminum alloy. Flame arrester
bank assembly shall include low copper aluminum frame and bank sheets. Spun hood,
seat rings and pallet assemblies shall be low copper aluminum. Guide posts shall be 304
stainless steel. The relief valve and flame arrester combination shall be the all-weather
type and shall be Whessoe Varec 5811 Series or equal.
2.02 FLAME TRAP ASSEMBLY:
Flame arrester shall have 4 inch size 125 lb. flat faced flanged connections. Capacity
shall be not less than 8,000 SCFH digester gas at 2 inches WC pressure drop. Assembly
shall include thermal shut-off valve and flame arrester. The unit shall be suitable for
installation vertically or horizontally.
The thermal valve shall include a fusible element designed to close the valve within 15
seconds of reaching a temperature of 2600 F. The thermal valve body and cover shall be
fabr~caJed from 356-T6 low copper cast aluminum alloy. Inner valve shall include a low
copper aluminum pallet with 304 stainless steel compression spring. Thermal shut-off
valve shall be Whessoe Varec 430 Series or equal.
Net free area through the bank assembly shall be not less than 3 times the
corresponding size standard pipe. The entire bank assembly shall be easily removed
from the housing to facilitate inspection and cleaning. Bank frame shall be extendible
and shall be filled with corrugated rectangular bank sheets. Sheets shall be arranged for
individual removal. Flame arresters for vertical installation shall be self draining. Flame
arresters for horizontal installation shall include an offset housing with a manual drip trap
at the low point. The flame arrester housing and covers shall be fabricated from 356-T6
low copper cast aluminum alloy. Flame arrester bank assembly shall include low copper
aluminum frame and bank sheets. Flame arrester shall be leak-proof to 10 PSIG. The
vertical flame arrester shall be Whessoe Varec 5000 Series or equal. The horizontal
DIGESTER GAS HANDLING EQUIPMENT
11815-2
01
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
flame arrester shall be Whessoe Varec 5010 Series or equal with a Whessoe Varec 246
low pressure manual drip trap.
The thermal shut-off valve and flame arrester shall be factory assembled as one flame
trap assembly. The flame trap assembly shall be Whessoe Varec 450 Series or equal.
... -
2.03 CONDENSATE AND SEDIMENT TRAP:
Condensate and Sediment Trap shall have 4 inch size 125 lb. flat faced flanged
connections. Flow Capacity shall be not less than 7,400 SCFH digester gas at 0.5 inches
WC pressure drop. Trap shall store a minimum of 6 gallons of sediment and 6 gallons of
condensate. The sediment trap shall include a 2 inch NPT blowout connection and a 1"
NPT drain connection. The sediment trap shall include a sight glass with isolation valves.
The top cover shall be gasketed and removable with an integral 3/4" NPT inspection pipe
for sediment level measurement. Construction shall be heavy welded steel. The trap
shall be shop primed and filed painted in accordance with the requir~mE::nts of Section
09800. Maximum working pressure shall be 25 PSIG. The Condensate and Sediment
Trap shall be Whessoe Varec 233 Series or equal with a Whessoe Varec 246 low
pressure manual drip trap and Whessoe Varec 218 Series sight glass.
2.04 LOW PRESSURE MANUAL DRIP TRAP:
Drip traps shall have a capacity of 2.5 quarts and 1 inch NPT inlets and outlets. Trap
shall be the rotating disc type and shall preclude the escape of gas from the trap
regardless of the disc position. An air inlet port shall be provided to permit free flow of
condensate from the storage reservoir. The drip trap body, cover plate, disc and handle
shall be fabricated from 356-T6 low copper cast aluminum alloy. Internal working parts
and fasteners shall be stainless steel. Maximum working pressure shall be 5 PSIG. The
drip trap shall be Whessoe Varec 246 or equal.
2.05 PRESSURE (EXPLOSION) RELIEF VALVE:
Pressure relief valve shall have a 6 inch 125 lb. flat faced flange connection. Capacity
shall be not less than 102,000 SCFH digester gas at 10 inches WC over-pressure.
Pallets shall be dead weight loaded and shall include replaceable synthetic rubber seat
inserts. Pressure pallet shall include removable loading weights to provide adjustment
from 4" to 15" WC in 1" WC increments. Valve shall have an extended neck between
flange and seat ring. Valve body and seat ring shall be fabricated from 356-T6 low copper
cast aluminum alloy. Pallet assembly, hood and guide post shall be low copper
aluminum. Seat insert shall be neoprene. The pressure relief valve shall be Whessoe
Varec 700 Series or equal.
DIGESTER GAS HANDLING EQUIPMENT
11815-3
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2.06 WASTE GAS BURNER AND IGNITION SYSTEM:
Waste gas Burner shall have a 4 inch 125 lb. flat faced flange connection. Burning
capacity shall be not less than 19,800 SCFH digester gas at 0.5 inches WC pressure
drop. Burner shall be designed for burning waste gas composed primarily of methane of
500:t3TU/SCF heat content. The burner shall be self-supporting and shall be constructed
of 304 stainless steel shroud and upper 24 inches of stack and pilot piping. Remainder
of burner shall be mild steel. Pilot nozzles, thermocouple and thermowell shall be 316
stainless steel. No component of the ignition system shall be mounted to the burner
stack or shroud.
The continuous flame nozzle shall be mounted integral to the burner and shall be
designed to provide a long profile flame. Pilot shall be inclined 30 degrees off vertical.
Pilot flame shall extend through the waste gas flow profile to ensure ignition of waste gas
regardless of flow rate. Unprotected pilot shall withstand 110 mph winds and shall burn
at elevated temperatures to assist in conversion of hydrogen sulfide. Pilot shall be
capable of operating on natural or LPG gas supplied to the blower at 8 inches WC.
The burner shall be supplied with an automatic ignition system which shall include the
following:
Continuous pilot nozzle.
Flame retention nozzle which will flow gas upon demand during the ignition cycle.
Type K thermocouple in a heavy wall thermowell.
2" NPT inspirating venturi for delivery of combustible air/gas mixture, including
combustion chamber, spark plug and backflash preventer.
_ Blower, valve and regulator package for controlling the pilot fuel. Package shall
..
include isolation valves, pressure regulators, pressure gauges, explosion proof
solenoid valve, air/gas mixing chamber, combustion chamber with spark plug,
spark generator and high tension lead. Blower shall be general purpose type and
shall include a motor starter switch. All components shall be installed in a
ventilated, weatherproof enclosure. Gas inlet connection shall be 1" NPT. Gas
outlet connection shall be 2" NPT to the continuous flame line and 1/2" NPT to the
flame retention line.
Solid state automatic ignition controller mounted in a NEMA 4 enclosure.
Components shall be UL, FM or CSA approved.
The Controller shall include the following features:
Pilot flame monitoring.
DIGESTER GAS HANDLING EQUIPMENT
11815-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Status lights for solenoid valve position, Ignition on, Pilot on and flame failure.
Adjustable thermocouple setpoint.
.... t\.1anual ignite button.
SPDT contacts for remote indication of pilot on-off and system alarm functions.
Capability for repeated ignition cycle.
Provision for remote start.
Waste gas burner and ignition system shall be Whessoe Varec 244W Series or equal.
2.07 BACK PRESSURE REGULATOR:
Back pressure regulator shall be single port with 4 inch flat faced 125 lb. flanged
connections. Regulator shall be used for upstream control and shall maintain 8.5" WC
back pressure. Flow capacity shall be not less than 5,000 SCFH at a pressure drop not
to exceed 2" WC. Regulator shall be controlled by a large spring loaded diaphragm and
shall provide tight shut-off. The spring barrel shall include a glass enclosed pointer and
scale to indicate setting. Setting range shall be adjustable from 2" we to 12" we. The
valve body and diaphragm and spring housing shall be fabricated from 356-T6 low
copper cast aluminum alloy. Inner valve shall include a low copper aluminum pallet with
304 stainless steel stems and bushings. Diaphragm shall be nylon reinforced Buna-N
rubber. Setting spring shall be zinc plated steel. The pressure regulator shall be
Whessoe Varec 386 Series or equal.
2.08 PRESSURE REGULATOR:
...
Pressure regulator shall be double port with 4 inch flat faced 125 lb. flanged connections.
Regulator shall be used for downstream control and shall maintain 6" we downstream
pressure. Flow capacity shall be not less than 5,000 SCFH at a pressure drop not to
exceed 2" WC. Regulator shall be controlled by a 20.5" diameter diaphragm and shall
provide a sensitivity of 5% of the setting pressure. Setting range shall be adjustable from
2" WC to 1 A" WC. The valve body and diaphragm housing shall be fabricated from 356-
T6 low copper cast aluminum alloy. Inner valve seats, stem and ball bearings shall be
304 stainless steel. Diaphragm shall be nylon reinforced Buna-N rubber. Setting spring
shall be zinc plated steel and balance weights shall be cast iron. The pressure regulator
shall be Whessoe Varec 187 Series or equal.
DIGESTER GAS HANDLING EQUIPMENT
11815-5
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
PART 3 - EXECUTION
Digester gas handling equipment shall be installed in accordance with the manufacturer's
recommendations. Components shall be installed such that the indicators and adjusting
elements are visible and accessible to the operator.
-. ~
END OF SECTION 11815
DIGESTER GAS HANDLING EQUIPMENT
11815-6
-.L~
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I -L .,~_.,
'~:~~.-:'.,,:,. ~
I
I
I
I
. . ., ~..,~
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F& V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 11820 - SUPERNATANT REMOVAL DEVICE & ACCESSORIES
PART 1 - GENERAL
1.01 DESCRIPTION:
.... ;.r
A. SCOPE:
This section specifies supernatant removal devices and accessories for anaerobic
digesters. The equipment covered by these specifications is intended to be standard
equipment of proven performance as manufactured by reputable concerns.
Equipment shall be designed, constructed, and installed in accordance with the best
practices of the trade, and shall operate satisfactorily when installed as shown on the
Contract Drawings.
B. EQUIPMENT LIST:
Item
Equipment Number
Supernatant Device NO.3
Supernatant Device NO.6
SRD7800
SRD7600
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of
this section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ANSI B 1.20.1-83
Pipe Threads, General Purpose (Inch)
ANSI B16.5-88
Pipe Flanges and Flanged Fittings
1.03 SUBMITTALS:
The following information shall be provided in accordance with Section 01800:
A. Manufacturer's Product data Sheets for each item.
SUPERNATANT REMOVAL DEVICE AND ACCESSORIES
11820-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1.04 RELATED WORK
A. Cover Position Indicators are specified in Section 13615.
B. Finish painting of ferrous metals and shop primed components is specified in Section
09800.
PART 2 - PRODUCTS
2.01 SUPERNATANT REMOVER:
A General:
The mechanism shall consist of a draw-off pipe assembly, positioning assembly
with indicator, bearing housing, and swivel joint. The Supernatant Remover shall
be constructed to allow withdrawal of liquid from any predetermined 10' level
range within the tank. A draw-off pipe, free to rotate within the tank, shall be
mounted on and pass through an arc of 1800 to withdraw supernatant at any point
in its range.
B. Drawoff Pipe
The draw-off pipe shall be of 6" diameter 316L stainless steel and shall extend 5'
from the bearing housing centerline to the pipe inlet end centerline and shall be
capable of withdrawing supernatant through a 10' vertical band as the pipe is
rotated through an arc of 1800. The draw-off pipe shall be bolted securely to a
flange fastened to the end of the rotating sleeve inserted through the bearing
housing after the gearing housing has been firmly secured in the concrete tank
wall. The rotating sleeve shall terminate outside the wall in a standard 6"
diameter AS.A 125 lb. flange to which a worm gear sector and a 6" diameter
swivel joint shall be securely bolted.
C. Positioninq Assemblv
_ p... cast iron gear housing shall be bolted to the bearing housing. The gear housing
shall be machined to receive the steel worm and worm shaft bushings equipped
with grease fittings. A hand crank operator shall be attached to the worm shaft.
The cast iron worm gear sector shall be enclosed in a cast iron housing, The
worm gear sector shall be so machined that the draw-off pipe can be rotated
through a 1800 arc.
D. Bearing Housing
The steel bearing housing shall be arranged for securing in the opening provided
ion the prestressed composite tank side wall. It shall be machined to receive
sleeve bearing, packing and rotating sleeve, and shall provide the attachment for
the gear housing.
SUPERNATANT REMOVAL DEVICE AND ACCESSORIES
11820-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
The bearing between the rotating sleeve and the bearing housing shall be bronze.
The packing gland and packing shall be furnished with a watertight seal for the
rotating sleeve. The annular space between rotating sleeve and the bearing
housing shall be filled with grease from an accessible grease fitting.
.... T"ype 304 stainless steel expansion anchors shall be provided for attaching the
bearing to the concrete wall.
E. Drawoff Scale
A circular scale calibrated to indicate feet of vertical depth shall be provided to
indicate position of the draw-off pipe. A steel pointer shall be attached to the
worm gear sector to indicate the position of the draw-off pipe.
F. Painting
All fabricated surfaces and castings requiring painting shall be cleaned by
commercial sandblast blast and painted with one (1) coat of T nemec 37-77
Chemprime. Finish painting shall be as specified in Section 09800.
G. Available Manufacturers: Subject to compliance with requirements, manufacturers
offering supernatant removal devices which may be incorporated in the work include,
but are not limited to, the following:
1. EIMCO Process Equipment Co.
2. WesTech Engineering, Inc.
3. Approved Equal
2.02 SUPERNATANT SIGHT GLASS:
A General
- The assembly shall consist of a 6" 125 lb. flanged transition body casting, viewing
sections, cleaning rod, wiper, packing gland and packing, solvent hand pump, and
spotlight with mounting bracket.
The body casting shall be of close grained, gray cast iron free from flaws and
blowholes, with standard 125 lb. Connecting flanges. It shall form a transition
section from circular end openings of standard pipe size to a central body casting.
The cleaning rod and wiper assembly shall include a section of brass pipe with
operating handle and cast brass wiper with neoprene wipers and brass wiper
retainers. The wiper holder shall have passages connected to the cleaning rod to
permit discharge of a cleaning solvent under pressure against the glass surface to
loosen and dissolve deposits. A stuffing box and threaded packing gland with
graphite packing shall be provided in the body casting to seal the cleaning rod
SUPERNATANT REMOVAL DEVICE AND ACCESSORIES
11820-3
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia
against leakage. The cleaning rod shall have sufficient stroke to permit wiping of
the entire viewing section. The shape of the transition section shall allow the wiper
of the entire viewing section. The shape of the transition section shall allow the
wiper to be withdrawn from the viewing area and the path of flow. A solvent pump
shall be included with a feed hose, valve, and mounting bracket.
... -
The body casting and fabricated steel components shall be given (1) shop coat of
Tnemec 77 Primer, or equal, before assembly. Finish painting shall be in
accordance with Section 09800.
B. Available Manufacturers: Subject to compliance with requirements, manufacturers
offering supernatant sight glasses which may be incorporated in the work include,
but are not limited to, the following:
1. EIMCO Process Equipment Co.
L. WesTech Engineering, Inc.
3. Approved Equal
PART 3 - EXECUTION
Supernatant removal device and accessories shall be installed in accordance with the
manufacturer's recommendations. Components shall be installed such that the
operatinh handles, indicators and adjusting elements are visible and accessible to the
operator.
END OF SECTION 11820
SUPERNATANT REMOVAL DEVICE AND ACCESSORIES
11820-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 13600 - PROCESS INSTRUMENTATION AND CONTROLS-GENERAL
PROVISIONS
PART 1 - GENERAL
1.01 SCOPE OF WORK:
Furnish and install all instrumentation and controls hereinafter specified to perform the
intended function, including all work necessary during the warranty period, as specified
herein, under other instrumentation sections of this specification and shown.
All equipment, materials, and services, hereinafter termed the system, shall be supplied by
the Contractor who, shall coordinate, and have responsibility for interconnecting with
equipment existing or being installed under this Contract as shown.
Auxiliary and accessory devices necessary for system operation or performance, such as
transducers or relays to interface with existing equipment or equipment provided under
other Sections of this Specification, shall be included whether specified or not.
Attention is directed to the fact that the Instrumentation and Control System shall be
furnished by a single SYSTEM SUPPLIER (Supplier), who shall provide all of the services,
equipment and appurtenances required to achieve a fully integrated and operational
system. Products shall be the same major instrumentation Manufacturer, with panel
mounted devices of the same type and model as far as possible.
Substitutions on functions or equipment specified will not be acceptable. In order to ensure
the interchangeability of parts, the ease of interfacing between the various subsystems, and
the establishment of minimums with regard to ranges and accuracy, strict compliance with
the above requirements shall be maintained. In order to ensure compatibility between all
equipment, it shall be the responsibility of the Supplier hereunder to coordinate all interface
requirements with existing equipment and with mechanical and electrical system suppliers
and furnish any signal isolation devices that may be required.
Equipment shall be fabricated, assembled, installed, and placed in proper operating
condition in full conformity with detail drawings, specifications, engineering data,
instructions and recommendations of the equipment manufacturer as approved by the
Engineer.
Equipment removed in the course of this work shall become the property of the Owner.
All equipment and installations shall satisfy applicable national, state and local mechanical
and electrical codes.
PROCESS INSTRUMENTATION AND CONTROLS GENERAL PROVISIONS
13600-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1.02 RELATED WORK:
A. Division 11 - Equipment.
B. Division 15 - Mechanical.
C. Division 16 - Electrical.
1.03 QUALIFICATIONS:
A. The SYSTEM SUPPLIER shall be required to demonstrate a minimum of five years
recent, past experience in the design, manufacture and commissioning of
instrumentation and control systems of comparable size, type, and complexity to the
proposed project. The SYSTEM SUPPLIER shall be required to have his own in-house
capability to handle complete system engineering, fabrication, and testing.
B. The SYSTEM SUPPLIER shall have in his employ capable personnel for detailed
engineering, coordination, drafting, procurement and expediting, scheduling,
construction, testing, inspection, installation, start-up service for calibration and
commissioning, and warranty compliance for the period specified.
1.04 SUBMITTALS - PROCESS INSTRUMENTATION AND CONTROLS:
Submittals shall be complete giving at least equipment specifications, details of
connections, wiring, range and dimensions. Submittals consisting of only general sales
literature will not be acceptable.
Submit detailed information for each instrument or control device, including manufacturer's
descriptive literature and a specific data sheet for each device and its configuration which
shaU include as a minimum:
--
1. Tag number per the Loop Diagrams.
2. Product (item) name used herein and on the Contract Drawings.
3. Manufacturer's complete model number.
4. Location of the device.
5. Input/output characteristics.
6. Range, size, and graduations.
7. Physical size with dimensions, enclosure NEMA classification and mounting
details.
8. Materials of construction of all components.
9. Instrument or control device sizing calculations where applicable.
10. Certified calibration data on all flow metering devices.
11. Accuracy, resolution, hysteresis, and frequency response.
PROCESS INSTRUMENTATION AND CONTROLS GENERAL PROVISIONS
13600-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Submit a detailed loop diagram on a single 8-1/2 inch x 11-inch sheet for each monitoring
or control loop. The format shall be the Instrument Society of America, Standard for
Instrument Loop Diagrams, ISA-S5.4. Each wire or pipe shall be shown with all
terminations as part of the loop diagram. Terminations furnished under other sections of
this specification shall be shown and completely identified on the as-built drawings in the
submittal. The loop diagrams shall use the same number as used herein.
- '""
Submit detailed ladder diagrams of the relay and switch logic. The ladder diagram format
shall be the same for all processes, systems, subsystems and equipment. Diagram
formats differing based on difference manufacturers will not be accepted. Rungs of the
ladders shall be cross-referenced. All functions shall be annotated and cross-referenced to
loop drawings.
The data sheets shall be provided with an index and proper identification and
cross-referencing. There shall be separate volumes for field/panel and in-line equipment.
The in-line equipment shall be coordinated with the piping work. The detailed luop
diagrams shall accompany the field/panel instrument submittal. Each volume shall be
submitted in its entirety. Partial submittals will be rejected. Re-submittals packages shall
also be bound.
Submit detailed drawings concerning control panels and/or enclosures including:
1. Cabinet assembly and layout drawings to scale.
2. Fabrication and painting specifications.
3. Color selection samples for selection by the Engineer.
4. Point to point wiring diagrams depicting wiring within the panel as well as
connections to external devices.
5. Where graphic display panels are required or to be modified, submit detailed layout
to scale, including symbols and line widths, as well as color selection samples and
details of fabrication. Half-scale layout will be acceptable.
Exceptions to the Specifications or Drawings shall be clearly defined by the SYSTEM
SUPPLIER. Data shall contain sufficient details so a proper evaluation may be made by
the Engineer.
1.05 FINAL DOCUMENTATION - PROCESS INSTRUMENTATION AND CONTROLS:
A. Prior to final acceptance of the system, six (6) sets of operating and maintenance
manuals covering instruction and maintenance on each type of equipment shall be
furnished as noted herein.
B. The instructions shall be bound in three-ring binders with Drawings reduced or folded
for inclusion and shall provide at least the following as a minimum:
1. A comprehensive index.
PROCESS INSTRUMENTATION AND CONTROLS GENERAL PROVISIONS
13600-3
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2. A complete "As Constructed" set of approved shop drawings.
3. A complete list of the equipment supplied, including serial numbers, ranges, and
pertinent data.
4. Full specifications on each item.
5. System schematic drawings "As Constructed", illustrating all compone~ts, piping,
... and electrical connections of the systems supplied under this Section.
6. Detailed service, maintenance, and operation instructions for each item supplied.
7. Special maintenance requirements particular to this system shall be clearly defined,
along with special calibration and test procedures.
8. The operating instructions shall also incorporate a functional description of the entire
system with references to the systems' schematic drawings and instructions.
9. Complete parts lists with stock numbers and name, address, andtelephone number
of the local supplier.
1.06 SOURCE QUALITY CONTROL:
Manufacturers of the equipment and fabricators of panels and/or cabinets supplied under
this Section shall allow the Engineer and/or Owner to inspect and witness the testing of the
equipment at the site of fabrication. Equipment shall include the cabinets, special control
systems, and other pertinent systems and/or devices. A minimum of ten (10) working days
notification shall be provided to the Engineer prior to testing. No shipments shall be made
without the Engineer's approval.
1.07 PRODUCT HANDLING:
A. Shippinq Precautions:
After completion of shop assembly, factory test, and approval, all equipment, cabinets,
panels, and consoles shall be packed in protective crates and enclosed in heavy duty
polyethylene envelopes or secured sheeting to provide complete protection from
damage, dust and .moisture. Dehumidifiers shall be placed inside the polyethelyne
...
coverings. The equipment shall then be skid-mounted for final transport. Lifting rings
shall be provided for moving without removing protective covering. Boxed Weights shall
be shown on shipping tag together with instructions for unloading, transporting, storing
and handling at job site.
Special instructions for proper field handling, storage and installation required by
Manufacturer for proper protection shall be securely attached to each piece of
equipment prior to packaging and shipment.
B. Identification:
Each component shall be tagged to identify its location, tag number, and function in the
system. Identification shall be prominently displayed on the outside of the package.
PROCESS INSTRUMENTATION AND CONTROLS GENERAL PROVISIONS
13600-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly'Wastewater Treatment Plant
Augusta-Richmond County, Georgia .
A permanent stainless steel or other non-corrosive material tag firmly attached and
permanently and indelibly marked with the instrument tag number, as given in the
tabulation, shall be provided on each piece of equipment supplied under this Section.
C. StoraQe:
Equipment shall not be stored out-of-doors. Equipment shall be stored in dry
permanent shelters, and shall be adequately protected against mechanical and
corrosive damage. If any apparatus has been damaged, such damage shall be
repaired by the contractor at his own cost and expense. If any apparatus has been
subject to possible injury by water, it shall be thoroughly dried out and put through such
tests as directed by the Engineer. This shall be at the cost and expense of the
Contractor, or the apparatus shall be replaced by the Contractor at his own expense.
PART 2 - PRODUCTS
2.01 PROCESS INSTRUMENTATION AND CONTROLS - GENERAL:
A. Type:
All instrumentation supplied shall be of the Manufacturer's latest design and shall
produce or be activated by signals which are established standards for the water and
wastewater industries.
All electronic instrumentation shall be of the solid-state type and shall utilize
transmission, signals which conform to all FCC and local requirements.
Outputs of equipment that are not of the standard signals as outlined, shall have the
output immediately converted to compatible standard signals for remote transmission.
All i9struments shall be provided with mounting hardware and floor stands, wall
brackets, or instrument racks as shown on the Drawings or as required.
Equipment installed in a hazardous area shall meet Class, Group, and Division as
shown on the Contract Electrical Drawings, to comply with the National Electrical Code.
All pneumatic field instrument signal and air supply lines shall be 1/4-inch O.D.
polyflo tubing unless otherwise noted. All tubing shall be supported in suitable sized
and braced cable trays or unistrut for individual runs and shall not interfere with
present or future instrument access. All tube fittings shall be designed for polyflo, as
manufactured by Imperial Eastman, or approved equal.
All indicators and recorder readouts shall be linear in process units.
PROCESS INSTRUMENTATION AND CONTROLS GENERAL PROVISIONS
13600-5
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
All transmitters shall be provided with either integral indicators or conduit mounted
indicators in process units, accurate to two percent.
Electronic equipment shall be of the Manufacturer's latest design, utilizing printed
circuitry and suitably coated to prevent contamination by dust, moisture and fungus.
Solid state components shall be conservatively rated for their purpose, to. assure
optimum long-term performance and dependability over ambient atmospheric
fluctuations, and 0 to 100 percent relative humidity. The field mounted equipment
and system components shall be designed for installation in dusty, humid, and
slightly corrosive service conditions.
All equipment, cabinets and devices furnished hereunder shall be heavy-duty type,
designed for continuous industrial service. The system shall contain products of a
single. Manufacturer, insofar as possible, and shall consist of equipment models
which are currently in production. All equipment provided shall be of modular
construction and shall be capable of field expansion.
All electronic equipment shall be provided with radio frequency interference
protection.
2.02 ELECTRICAL:
All equipment shall be designed to operate on a 60-Hertz alternating current power source
at a nominal 100-volts, plus or minus 10 percent, except where specifically noted. All
regulators and power supplies required for compliance with the above shall be provided
between power supply and interconnected instrument loop. Where equipment requires
voltage regulation, constant voltage transformers shall be supplied.
All analog transmitter and controller outputs shall be 4 - 20 milliamps into a minimum load
range of 0 - 750 ohms, unless specifically noted otherwise.
...
All switches shall have double-pole, double-throw contacts rated at a minimum of
600 VA, unless specifically noted otherwise.
Materials and equipment used shall be U.L. approved wherever such approved
equipment and materials are available.
All equipment shall be designed and constructed so that in the event of a power
interruption, the equipment specified hereunder shall resume normal operation without
manual resetting when power is restored.
PROCESS INSTRUMENTATION AND CONTROLS GENERAL PROVISIONS
13600-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2.03 LIGHTING/SURGE PROTECTION:
A. General:
Lighting/Surge protection shall be provided to protect the electronic instrumentation
syst~m from induced surges propagating along the analog and discrete _signal and
poWer supply lines. The protection systems shall be such that the protective level shall
not interfere with normal operation, but shall be lower than the instrument surge
withstand level, and be maintenance-free and self-restoring. Instruments shall be
housed in a suitable metallic case, properly grounded. Ground wires for all surge
protectors shall be connected to a good earth ground and where practical each
ground wire run individually and insulated from each other. These protectors shall
be mounted within the instrument enclosure or a separate NEMA 4X stainless
steel or fiberglass junction box coupled to the enclosure.
B. Power Supplv:
Protection of all alternating current (AC) instrument power supply lines shall be
provided. Cabinet(s)/panel(s) and groups of field instruments, as approved by the
Engineer, shall be protected by isolation transformers and surge suppressors.
Individual field instruments shall be protected by individual gas tube surge
suppressors.
C. Signal Line:
Protection of all field analog, discrete, digital and telemetered signal lines shall be
provided. Protection devices shall be installed at both ends and as close to the
instrument being protected as possible. Where signal lines enter control rooms through
an interface cabinet, the protection devices shall be mounted in the interface cabinet.
Protection shall be with the combined use of gas tube surge arrester and Zener diode
protectors.
...
PART 3 - EXECUTION
3.01 GENERAL INSTALLATION:
Instrumentation and accessory equipment shall be installed in accordance with the
Manufacturer's instructions. The locations of equipment, transmitters, alarms and similar
devices shown on the Drawings are approximate only. Exact locations shall be as
approved by the Engineer during construction. Obtain in the field all information relevant
to the placing of process control work and in case of any interference with other work,
proceed as directed by the Engineer and furnish all labor and materials necessary to
complete the work in an approved manner.
PROCESS INSTRUMENTATION AND CONTROLS GENERAL PROVISIONS
13600-7
F&V Project NO.9? 124 01
Digester Modifications.. Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
The instrumentation loop diagrams indicate the intent of the interconnections between the
individual instruments. Any exceptions should be noted.
The installation details on the Drawings indicate the designed installation for the
equipment specified. Where specific installation details are not specified or s~own on the
DraWings, the American Petroleum Institute (API) Recommended Practice 550 shall be
followed as applicable.
All work shall be executed in full accordance with codes and local rulings. Should nay
work be performed contrary to said rulings, ordinances, and regulations, the Contractor
shall bear full responsibility for such violations and assume all costs arising therefrom.
All equipment used in areas designated as hazardous shall be designed.. for the Class,
Group, and Division as required on the Electrical Drawings for the locations. All
installation shall be in strict accordance with codes.
Unless specifically shown in the Contract Documents, direct reading or electrical
transmitting instrumentation shall not be mounted on process piping. Instrumentation shall
be mounted on instrument racks or stands as detailed on the installation detail
drawings. All instrumentation connections shall be provided with shutoff and drain
valves. For differential pressure transmitters, three-way stainless steel valve manifolds
shall also be provided. For slurries, chemical or corrosive fluids, diaphragm seals
with flushing connections shall be provided.
All piping to and from field instrumentation shall be provided with necessary Unions,
test tees, couplings, adaptors, and shut-off valves.
Field instruments requiring power supplies shall be provided with local electrical
shut-offs and fuses as required.
BrackeJs and hangers required for equipment mounting shall be prov,ided. They shall
be installed in a workmanlike manner and not interfere with any other equipment.
The SYSTEM SUPPLIER shall investigate each space in the building through which
equipment must pass. to reach its final location. If necessary, the SYSTEM SUPPLIER
shall be required to ship his material in sections sized to permit passing through
restricted areas in the building. The SYSTEM SUPPLIER shall also investigate, and
make any field modifications to the allocated space for each cabinet, enclosure, and
panel to assure proper space and access (front, rear, side).
The shield on each process instrumentation cable shall be continuous from source to
destination and be grounded as directed by the Manufacturer of the instrumentation
equipment but in no case shall more than one grounded point be employed for each
shield.
PROCESS INSTRUMENTATION AND CONTROLS GENERAL PROVISIONS
13600-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Lifting rings from cabinets/assemblies shall be removed. Hole plugs shall be provided for
the holes of the same color as the cabinet.
The SYSTEM SUPPLIER shall coordinate the installation, the placing and location of
system components, their connections to the process equipment panels, cabinets and
devices, subject to the Engineer's approval. He shall be responsible to insure that all field
wiring for power and signal circuits are correctly done in accordance with best industry
practice and provide for all necessary system grounding to insure a satisfactory
functioning installation.
3.02 FIELD TESTS:
The Contractor shall furnish the services of the SYSTEM SUPPLIER's servicemen, all
special tools, calibration equipment and labor to perform the tests. Certified copies of
the tests shall be furnished in duplicate to the Engineer. The Owner shall be given a
48-huur notice prior to calibration and start-up.
Following connection, check-out, and final adjustment of all panels, instruments, meters,
monitoring, and control devices, a performance check shall be made on each. Analog
instruments and system inputs shall be tested at 0 percent, 25 percent, 50 percent, 75
percent, 100 and 101 percent of scale, as required. All status and alarm switches as
well as all monitoring and control functions shall also be checked. Testing shall be done
from the signal source (transmitter) to the final receiving device including all field wiring.
All piping and tubing shall be air-tested, with the instrument and control connections
open, to the maximum pressure that does not exceed maximum working pressure of the
instruments or controls. Each joint shall be soap tested and leaks shall be eliminated.
If, during running of the tests, one or more points appear to be out by more than the
specified amount, the system supplier's servicemen shall make such adjustments or
alterations as are necessary to bring equipment up to specification performance.
...
Following such adjustments, the tests shall be repeated for all specified points to insure
compliance.
3.03 INSTRUCTION - INSTRUMENTATION:
The Contractor shall furnish a SYSTEM SUPPLIER's representative for a field training
program to be run at the Owner's Plant site and consist of the one (1) day instruction for
the Owner's personnel. The program shall cover instrumentation debugging,
trouble-shooting, calibration and maintenance procedures, and system operation. This
training program will be held at a time chosen by the Owner and will be exclusive of
any instruction given at the time of system start-up.
END OF SECTION 13600
PROCESS INSTRUMENTATION AND CONTROLS GENERAL PROVISIONS
13600-9
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 13615 - PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
PART 1 - GENERAL
1.01 RELATED WORK:
Section -13600 - Process Instrumentation and Controls General Provisions.
Division 11 - Equipment.
Division 15 - Mechanical
Division 16 - Electrical.
1.02 TOOLS AND TEST EQUIPMENT:
Test equipment shall be provided, together with items such as instruction manuals,
carrying/storage cases, unit battery charger where applicable, special tools, calibration
fixtures, cord extenders, patch cords, and test leads, which are not specified but are
necessary for checking field operation of equipment supplied under this Section.
1.03 SPARE PARTS:
A. Recorder Supplies:
One year supply of charts for each recorder furnished.
One year supply of ink, of each color for each recorder furnished.
B. Miscellaneous Spare Parts:
One years supply of the manufactures recommended spare parts for the equipment
furnished.
C. General:
The spares listed above shall be packed in a manner suitable for long-term storage and
shall be adequately protected against corrosion, humidity and temperature.
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-1
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-2
I
I
I
I
I
I
I
I
I
I
I
I
I
'1
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
PART 2 - PRODUCTS
2.01 FIELD MOUNTED INSTRUMENT:
A. Lellel~Element - Pressure Indicatinq Transmitter:
[PIT7211, 7311, 7411,7511,7611,7811]
1. Type:
a. Close -coupled extended diaphragm.
b. Electronic Output, digital, field configurable.
c. NEMA 4X stainless steel enclosure rated for Class I, Division I, Groups B, C
and D hazardous environments.
2. Operation:
a. Purpose - To sense variations in pressure and produce a standard current
output signal linear with the pressure.
b. Sensing Element - differential-capacitance cell, bonded strain gauge, or
differential pressure cell.
c. Indicator - integral, digital.
3. Functional:
a. Range: 0 - 400 inches WC.
b. Power Supply - DC (from receiver over signal leads).
c. Output - 4-20 mA DC.
d. Process Connections - 1/2" NPT low side, 4" flange high side.
4. Phvsical:
a. Body Material - 316 stainless steel.
b. Wetted Parts - 316 stainless steel.
c. Electronics Housing - NEMA 4X stainless steel enclosure.
5. Performance:
a. Accuracy - plus or minus 0.25 percent of span.
b. Indicator Accuracy - plus or minus 2.0 percent of span.
6. Manufacturers:
a. Foxboro ModeIIDP10-DF10C1F-SN1RN.
b. Approved Equal.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Flow Element - Thermal Mass:
[FE7101, 7102, 7103, 7201, 7301, 7401, 7501, 7601, 7801]
1. Type:
jnsertion type primary element - differential temperature producing.
2. Operation:
Function - Produces a flow signal proportional to the temperature differential of two
mass balance elements with precision RTD's.
3. Physical:
a. Probe - 5" insertion length(7201-7601), 6" insertion length (7101-7103), 3~6L
s~ainless steel.
b. Mounting - 1" NPT Fitting - 316L stainless steel.
4. Manufacturers:
a. STI/Magnetrol Model TET-0050-00X with 011-4719-002 NPT Ferrules.
b. Approved Equal.
C. Flow Indicatinq Transmitter - Thermal' Mass:
[FIT7101, 7102, 7103, 7201, 7301, 7401,7501,7601,7801]
1. Type:
a. Low level input.
b. Compatible with thermal differential flow element.
..c. Electronic, microprocessor based.
2. Operation:
a. Purpose - To convert a low level signal from a thermal mass sensor to
prQduce a standard 4-20 mA output linearly proportional to flow.
b. Operation - The transmitter uses built in formula to convert the signal from the
sensor to a flow reading.
3. Functional:
a. Accuracy - plus or minus 1 percent of reading + 0.5% of full scale.
b. Range - 0-7500 ACFH @ 8 inches WC.(7201-7206)
0-10,000 ACFH @ 8 inches we (7101-7103)
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-3
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
4. Physical:
a. Enclosure: NEMA 4X suitable for Class I, Division 2, Groups A, B, C and D
hazardous environments.
5'. Manufacturers:
a. STI/Magnetrol Model TAI-2200-110 with Model 037-3305-050 connect cable.
b. Approved Equal.
D. Temperature Indicatinq Transmitter:
[TIT7211, 7311, 7411, 7511]
1. IYlliL
a. Resistance Temperature Detector (RTD).
b. Spring Loaded with thermowell mount.
c. Insertion length 12"
2. Operation:
a. Purpose - To produce a low level voltage output signal proportional to
temperature.
3. Functional:
a, Power Requirement - 24VDC.
b. Electrical Class - NEMA 4X enclosure
c. Output 4-20 mA DC.
4. Physical:
a. RTD- 100 ohm platinum (ASTM - B).
b. Thermowell- 316L stainless steel, welded and tapered.
c. Enclosure - NEMA 4X for explosion proof service.
d. Indicator - 3 line LCD.
5. Performance:
a. Range: 0-120 OF.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
6. Manufacturers:
a. Foxboro RTI20-D1 L TQFD-L3.
b. Approved Equal.
, I
E Pressure Gauqe:
1. Type:
Bourdon Tube.
2. Operation:
To measure pressure of the process fluid and indicate locally in psi.
3. Process:
a. Fluid - Wastewater Sludge
b. Maximum Pressure - 100 psig.
c. Maximum Temperature - 120 degrees F.
4. Physical:
a. Dial - 3.5-inch, stainless steel with zero stop - white with black engraving.
b. Lens - 1/8-inch laminated glass.
c. Movement - Stainless steel.
d. Process Connection - 1/4-inch NPT.
e. Case:
1. Material - 316 satin finish stainless steel.
2. Bottom connected for pipe mounted gauges and back connected for flush
mounted.
3. Liquid fill, glycerin.
f. Tube, socket, tip material- 316 stainless steel.
5. Performance:
a. Range - Reference contract drawings.
b. Accuracy - 1 percent of span.
6.' Manufacturer:
Ashcroft 35-1 009-SW-021-XXX-1 00 or approved equal.
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-5
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
F. Pressure Gauqe Isolation Rinq:
1. Type:
: a: Wafer Style.
2. Operation:
a. Purpose - To isolation instrumentation from abrasive or corrosive process fluid..
b. Operating Principle - Flexible cylinder, fluid filled with built-in 1/4" needle valve..
3. Physical:
a. Inner Flexible Wall - Viton.
b. Assembly Flanges - 316 stainless steel.
c. Process Connection - 1/4-inch NPT.
4. Manufacturer:
Ashcroft 80XX-YS-02T-CG or approved equal.
G. Thermometer.
1. Type:
Bi-metal.
2. Operation:
To measure temperature of the process fluid and indicate locally in degrees F.
3. Process:
a. Fluid - wastewater sludge and hot water supply & return.
b. Maximum Pressure - 30 psig.
c. Maximum Temperature - 120 degrees F.
4. Physical:
a. Dial - 3-inch, stainless steel with zero stop - white with black engraving.
b. Lens - heavy duty glass.
c. Movement - Stainless steel and Teflon.
d. Process Connection - 1/4-inch NPT.
e. Case:
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1. Material - 316 satin finish stainless steel.
2. Back connected for mounting in thermowell.
f. Thermowell- 316 stainless steel.
5. = Performance:
a. Range - 0 - 1500 F.
b. Accuracy - 1 percent of span.
6. Manufacturer:
Ashcroft 30-EI-60-R-060-XXX-0/1500F or approved equal.
H. Cover Positio.1Indicator:
[L17311, L17411, L17511, L17611, L17811]
Gauge-head type cover position indicator shall be suitable for measuring the position of
vertically guided floating digester covers. Local readout shall be in feet, inches and
sixteenth inches. Counter movement shall be simultaneous with cover travel and shall read
"Oil when the cover rests on the corbels. Counter shall be protected by a glass window and
isolated from the main gauge-head housing. Mechanism shall be powered by a spring
motor actuated by a tape/cable assembly attached directly to the cover. Limit switches for
remote high and low cover position shall be provided ZS7311~-B, . ZS7411A-B, ZS7511A-
8, ZS7611A-B and ZS7811A-B. Switches shall have explosion-proof housings suitable for
Class 1, Group C & D areas. Gauge-head and sheave elbows shall be cast aluminum.
Gauge-head internal components shall be stainless steel and aluminum with Teflon
bearings. Tape/cable assembly shall be 316 stainless steel. Gauge-head Type cover
position indicator shall be Whessoe Varec 2592V Series with 2557 Series limit switches.
2.02 CONTROL PANELS:
DIGESTER CONTROL PANEL (DCP):
A. General:
Panel shall be all non-ferrous construction with heavy duty anodized aluminum extrusion
framing and a solid back plane. All doors hinged, gasketed and removable. All cutouts
are to be made with rounded corners.
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-7
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
The digester control panel shall include the following control features:
1. Monitor the level in six (6) anaerobic digesters by accepting level input from the digester
level transmitters PIT7211, 7311, 7411, 7511, 7611, 7811. The level shall be displayed
for each digester on the panel mounted graphic recorder. Low level alarms and high
level alarms shall be displayed. High level alarm in a digester shall close the
inlet/transfer valve to the appropriate digester. Low level alarm shall close the sludge
outlet valve for the appropriate digester.
2. Control operation of the digester inlet/transfer valves for each digester CV7201,
CV7203,CV7301,CV7303,CV7401,CV7403,CV7501,CV7503,CV7601 and
CV7801. Valve status shall be displayed on the graphic recorder. Valves shall be
controlled by an open-close selector switch.
3. Control operation of the digester sludge outlet valves for each digester CV /202,
CV7302, CV7 402, CV7502, CV7602 and CV7802. Valve status shall be displayed on
the graphic recorder. Valves shall be controlled by an open-close selector switch.
4. Control sludge transfer from digester to digester by controlling sludge pumps P781 0
and P7820, sludge transfer valves and sludge drawoff valves. Pumps shall be
controlled by on-off selector switches. Pump status shall be displayed on the Panel
Status Indicator.
5. Control operation of digester mixers MX7201, MX7202, MX7203 and MX7204,
MX7301, MX7302, MX7303 and MX7304, MX7401, MX7402, MX7403 and MX7404,
MX7501, MX7502, MX7503 and MX7504. Controls shall include on-off-reverse selector
switches for each unit (forward/reverse). Controls shall shutdown the mixers on
digester low-level. Controls shall interface with hand-off-remote controls furnished with
the mixers under Section 11800. Mixer status (on-off-reverse shall be displayed on the
Panel Status Indicator. Reversing starters for the mixers will be mounted in the MCC as
specified in Division 16.
6. Monitor digester temperature in four (4) anaerobic digesters by accepting input from the
digester temperature transmitters TIT7211, 7311,7411,7511. Temperature shall be
displayed on the graphic recorder. Cover Position (hi-low) shall be displayed on the
Panel Status Indicator.
7. Monitor digester cover position in five (5) anaerobic digesters by accepting input from
the digester high and low level switches ZS7311A-B, . ZS7411A-B, ZS7511A-B,
ZS7611A-B and ZS7811A-B. Low and high alarms shall be displayed on the graphic
recorder.
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
8. Monitor digester gas flow rate in six (6)) anaerobic digesters and three (3) waste gas
flow rates by accepting input from the digester gas flow transmitters FIT71 01, 7102,
7103,7201,7301,7401,7501,7601,7801 . Gas flow rate shall be displayed on the
graphic recorder. The gas flow rate shall be totalized in the graphic recorder.
9. Control sludge transfer from digester to truck loading area by controlling sludge pumps
P7840 and P7850. Pumps shall be controlled by on-off-remote selector switches to
allow for remote operation of the pumps from the truck loading stations. Pump status
shall be displayed on the Panel Status Indicator.
10. Provide a common alarm for routing to the central control system.
2.03 PANEL MOUNTED INSTRUMENTS:
A. Graphic Recorder:
1. Type:
a. Electronic: VGA, TFT, color, 320 x 240 pixel, liquid crystal display.
b. Touch sensitive screen.
c. Front panel mounting.
d. nema 4.
2. Operation:
Fully configurable using touch screen for group displays, vertical trends and bar-
graphs, horizontal trends and bar-graphs, and alarm summary page.
3. Functional:
a. Input - 4-20 maDe, RTD or contact closure as required.
b. Power -120 VAC, 60 Hz.
c. Low, high and alarm internal adjustable setpoints with Form C relay outputs.
d. Custom scale and captions per required variable display.
4. Manufacturer:
a. Foxboro Model 763GNA.
b. Approved equal.
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-9
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. Panel Status Indicator:
Provide a modular panel mounted status indicator for the discrete inputs specified
above to be displayed. Each window of the modular panel shall be individually
-: engraved to indicate status of a minimum of 72 inputs. Terminal strips shall be
included to allow for interface wiring from remote devices. Panel shall be Ronan
Model 12.6X11SNLR-3000 with push-button module, 72 auxiliary contact modules
and 375 watt power supply or equal.
2.04 MISCELLANEOUS PANEL COMPONENTS:
All components shall be mounted in a manner that shall permit servicing, adjustment,
testing and removal without disconnecting, moving or removing any other component.
Components mounted on the inside of panels shall be mounted on removal plates and not
directly to the enclosure. Mounting shall be rigid and stable unless ShOl;k mounting is
required otherwise by the manufacturer to protect equipment from vibration. Components
mounting shall be oriented in accordance with the component manufacturer's and
industries' standard practices. All internal components shall be identified with suitable
plastic or metal engraved tags attached with drive pins adjacent to (not on) each
component identifying the component in accordance with the drawing, specifications, and
supplier's data.
1. Push buttons, switches, indicating lights: The pushbuttons shall be heavy-duty, oil
tight, with momentary contacts. Switches shall be supplied with the number of poles
required for the application, an escutcheon plate, and contacts rated for 10 amperes
at 120 volts AC.
2. Relays: Relays shall be double pole, double throw, octal plug in type with a
transparent dust cover. The relay shall be equipped with an indicating light to
indicate when its coil is energized. The relays shall have 5-amperes 120-volt AC
contacts. The mechanical life of the relay shall be 10,000,000 operations minimum.
3. Time Delay Relay: The time delay relays shall be of the pneumatic type with time
delay and instantaneous contacts. The time delay relays shall be set for sixty
seconds but be adjustable from 0 to 90 seconds.
4. Illuminated Push Buttons: The illuminated push buttons mounted on the Main
Control Panel shall be heavy-duty, watertight Type KX as manufactured by the
Square D Company.
5. Loop Power Supplies: 115V AC/24VDC power supply modules shakll be provided in
quantity sufficient to power all 2 wire 24VDC transmitters. The maximum number of
loops powered by each power supply module shall be limited to the loops associated
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-1 0
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
with each digester. A minimum of six loop power supply modules shall be provided.
Power supply modules shall be AGM Model AUX 4552-1 or DIN 4552-1.
PART 3 - EXECUTION:
3.01 GENERAL INSTALLATION:
Refer to Section 13600
END OF SECTION 13615
PROCESS INSTRUMENTATION AND CONTROLS-PRODUCTS
13615-11
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 15010- GENERAL PROVISIONS
PART 1 GENERAL
1.01 GENERAL REQUIREMENTS
A. - General conditions, supplementary, and Special Conditions of the Contract
govern work under this Section.
B. Contractors performing work shall be totally responsible for work and shall
coordinate, connect and conform to all sections or divisions of the
Specifications and all drawings as required to provide complete systems.
C. Applicable provisions of this section apply to and are hereby made part of
the other sections of this Division.
D. The Drawings and Specifications shall be understood to cover, according to
their intent and meaning, complete operating systems as shown on the
drawings and specified under appropriate sections of the specifications.
The Drawings and Specifications are to be taken together. Work specified
and not shown or work shown and not specified shall be performed of
furnished as though mentioned in both specifications and drawings.
E. Minor items and accessories or devices reasonably inferable as necessary
to the complete and proper operation of any system shall be provided for
such system.
F. Verification of Existing Conditions: No allowance shall be made for failure to
investigate site before building.
G...; Coordinate all utility construction and service installation with respective
utility.
H. The Contractor shall remove and/or relocate existing equipment and'devices
as required to provide clearance for new construction and to render system
operational in existing spaces.
1.02 CODES, STANDARDS AND FEES
A. Standard Building Code, Latest Edition with Revisions.
B. Standard Plumbing Code, Latest Edition with Revisions.
C. Standard Mechanical Code, Latest Edition with Revisions.
D. National Electric Code - 1993 Edition.
E. NFPA 72E - 1990 Automatic Fire Detectors.
F. NFPA 90A - 1993 Installation of Air Conditioning and Ventilating Systems.
GENERAL PROVISIONS
15010 - 1
GENERAL PROVISIONS
15010 - 2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
G. NFPA 101 - 1991 Life Safety Code.
1.03 SPECIAL REQUIREMENTS
A. LAYOUT OF WORK: Drawings are Diagrammatic. Correlate final equipment
locations with governihg Architectural and Structural drawings and existing
conditions. Layout work before installation so that all trades may install
equipment in spaces available. Provide coordination as required for
installation in a neat and workmanlike manner. Verify working clearances
and install per code.
B. COORDINATION: Provide all required coordination and supervision where
work connects to or is effected by work of the sections of the Specification
and comply with all requirements effecting the Division. Work required
under other Divisions, Specifications, or Drawings to be performed by this
Division shall be coordinated with the Divisio.l.
C. SUPERVISION OF WORK: Provide a field superintendent who has had
previous successful experience on projects of comparable size and
complexity. Superintendent shall be present at all times that work in being
installed.
D. Inspections: All work must pass routine and final inspections by Augusta-
Richmond County.
E. Suitably protect all materials and equipment and item furnished under this
Contract during construction. Restore all damaged surfaces and items to
"like new" condition before a request for final acceptance.
F.
CLEANLINESS CONTROL AND CLEAN-UP: Provide dust partitions,
vacuum systems or exhaust fan to control dust and debris during
construction operations. Procedures shall prevent dust and debris from
entering finished areas. The Contractor shall also be responsible for
removal of trash on a daily basis and shall maintain the construction area
free of stored materials. If the Contractor is negligent in this regard, the area
will be cleared in accordance with the terms of the General Conditions.
G. CUTTING AND PATCHING: Locate all openings required for work work
required under this Section. Cut openings with minimum over-cut, place
sleeves or other closure system as required and patch all areas about the
cut zone to match existing finishes. Openings in concrete shall be blocked
out before placement of concrete. Core boring or saw cutting only with
approval of Engineer.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
1.04 SUBSTITUTIONS: Comply with pertinent provisions of the Instructions to Bidders.
PART 2 GUARANTEE
2.01 Furnish one year written guarantee to Owner from date of substantial completion
on material and workmanship.
2.02 Furnish extended guarantee certificate on all items where greater that one year
guarantee is specified.
~~.;,.
END OF SECTION 15010
,;;.
GENERAL PROVISIONS
15010 - 3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 15050 - PIPING SYSTEMS
PART 1 - GENERAL
1.01 DESCRIPTION:
A. SZ:O"PE:
This section specifies systems of process piping and general requirements for piping
systems. Detailed specifications for the components listed on the Piping System
Specification Sheets are found in other sections of Division 15. This section shall be
used in conjunction with those sections.
B. DEFINITIONS:
Pressure terms used in Section 15050 and elsewhere ir. Division 15 are defined as
follows:
1. Maximum: The greatest continuous pressure at which the piping system operates.
2. Test: The hydrostatic pressure used to determine system acceptance.
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall
prevail.
Reference Title
AASHTO M36/M36M-87 Metallic (Zinc or Aluminum) Coated eorrugated Steel
Culverts and Underdrains
ANSI A 13.1-81 Scheme for Identification of Piping Systems
ANSI B1.20.1-83 Pipe Threads, General Purpose (Inch)
ANSI B16.1-89 Cast Iron Pipe Flanges and Flanged Fittings Class 25,
125,250, and 800
ANSI B 16.3-85 Malleable Iron Threaded Fittings Class 150 and 300
PIPING SYSTEMS 15050-1
F& V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
ANSI B16.5-88
Pipe Flanges and Flanged Fittings
ANSI B16.9-86
Factory-Made Wrought Steel Buttwelding Fittings
ANSI B16.11-80
Forged Steel Fittings, Socket Welding and Threaded
....: ~..
ANSI B16.12-83
Cast Iron Threaded Drainage Fittings
ANSI B 16.22-89
Wrought Copper and Copper Alloy Solder Joint Pressure
Fittings
ANSI B16.26-88
Cast Copper Alloy Fittings for Flared Copper Tubes
ANSI B31.1-89
Power Piping
ANSI B31.3-87
Chemical Plant and Petroleum Refillery Piping
ASME SECTION IX-89
Boiler and Pressure Vessel Code; Welding and Brazing
Qualifications
ASTM A4 7 -84
Malleable Iron Casting
ASTM A53-89
Pipe, Steel, Black and Hot Dipped, Zinc-Coated Welded
and Seamless
ASTM A74-87
Cast Iron Soil Pipe and Fittings
ASTM A105/A1005M-87a Forgings, Carbon Steel, for Piping Components
ASTM A 106-89
Seamless Carbon Steel Pipe for High-Temperature
Service
ASTM A197-87 Cupola Malleable Iron
ASTM A234/A234M-89 Pipe Fittings of Wrought Carbon Steel and Alloy Steel for
Moderate and Elevated Temperatures
ASTM A312/A312M-89 Seamless and Welded Austenitic Stainless Steel Pipe
ASTM A403/A403M-89 Wrought Austenitic Stainless Steel Piping Fittings
ASTM A536-84 Ductile Iron Castings
-
ASTM A570/A570M-88' Hot-Rolled Carbon Steel Sheet and Strip, Structural
Quality
PIPING SYSTEMS 15050-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
ASTM B88-89
Seamless Copper Water Tube
ASTM C76-89
Reinforced Concrete Culvert, Storm Drain, and Sewer
Pipe
ASTM-C296-88
Asbestos-Cement Pressure Pipe
ASTM C564-88
Rubber Gaskets for Cast Iron Soil Pipe and Fittings
ASTM D1248-84
Polyethylene Plastics Molding and Extrusion Materials
ASTM 01784-81
Rigid Poly (Vinyl Chloride) (PVC) Compounds and
Chlorinated (CPVC) Compounds
ASTM 01785-89
Poly (Vinyl Chloride) (PVC) Plastic Pipe, Schedules 40,
80 and 120
ASTM D2241-89
Poly (Vinyl Chloride) (PVC) Plastic Pipe (SDR-PR)
ASTM D2513-88b
Thermoplastic Gas Pressure Pipe, Tubing, and Fittings
ASTM D2665-89a
Poly (Vinyl Chloride) (PVC) Plastic Drain, Waste, and
Vent Pipe Fittings
ASTM D2996-88
Filament-Wound Reinforced Thermosetting Resin Pipe
ASTM D3261-88a
Butt Fusion Polyethylene (PE) Plastic Fittings for
Polyethylene (PE) Plastic Pipe and Tubing
ASTM D4174-82
Cleaning, Flushing, and Purification of Petroleum Fluid
Hydraulic Systems
,;
ASTM 04101-82
Propylene Plastic Injection and Extrusion Materials
ASTM F441-89
"
Chlorinated Poly (Vinyl Chloride) (CPVC) Plastic Pipe,
Schedules 40 and 80
AVWVA C105-88
Polyethylene Encasement for Ductile-Iron Piping for
Water and Other Liquids
AVWVA C110-87
Ductile-Iron and Gray-Iron Fittings, 3 Inch through 48
Inch, for Water and Other Liquids
AVWVA C111-85
R.ubber-Gasket Joints for Ductile-Iron and Gray-Iron
Pressure Pipe and Fittings
PIPING SYSTEMS
15050-3
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
AWWA C115-88
Flanged Ductile-Iron and Gray-Iron Pipe with Threaded
Flanges
AWWA C151-86
Ductile-Iron Pipe, Centrifugally Cast in Metal Molds or
Sand-Lined Molds, for Water or Other Liquids
AWWA C200-86
Steel Water Pipe 6 Inches and Larger
AWWA C203-86
Coal-Tar Protective Coatings and Linings for Steel Water
Pipelines--Enamel and Tape--Hot-Applied
AWWA C205-89
Cement-Mortar Protective Lining and Coating for Steel
Water Pipe--4 Inches and Larger--Shop Applied
AWWA C206-88
Field Welding of Steel Water Pipe
AWWA C207-86
Steel Pipe Flanges for Waterworks Services--Sizes 4
Inches through 144 Inches
AWWA C208-83
Dimensions for Fabricated Steel Water Pipe Fittings
AWWA C209-84
Cold-Applied Tape Coating for Special Sections,
Connections, and Fittings for Steel Water Pipelines
AWWA C210-84
Coal-Tar Epoxy Coating System for the Interior and
Exterior of Steel Water Pipe
AWWA C214-83
Tape Coating Systems for the Exterior of Steel Water
Pipelines
Av0NA C301-84
Prestressed Concrete Pressure Pipe, Steel Cylinder
Type, for Water and Other Liquids
AWWA C303-87
Reinforced Concrete Pressure Pipe--Steel Cylinder Type,
Pretensioned, for Water and Other Liquids
AWWA C600-87
Installation of Ductile-Iron Water Mains and Their
Appurtenances
AWWA C651-86
Disinfecting Water Mains
AWWA C900-89
Polyvinyl Chloride (PVC) Pressure Pipe, 4 Inches through
12 Inches, for Water
PIPING SYSTEMS
15050-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
A\MNA M11-85
Steel Pipe--A Guide for Design and Installation
CISP1301-75
Specification Data for Hubless Cast Iron Sanitary System
with No-Hub Pipe and Fittings
FEDSPEC L-C-530B(1)-7 Coating, Pipe, Thermoplastic Resin or Thermosetting
... ,;;..
Epoxy
MIL-H-13528B-87
Hydrochloric Acid, Inhibited, Rust Removing
MIL-STD-810C(1975)
Environmental Test Methods
SAE J1227-86
Assessing Cleanliness of Hydraulic
Fluid Power Components and Systems
SPC (1990)
Standard Plumbing Code
B. FITTINGS AND COUPLING COMPATIBILITY:
To assure uniformity and compatibility of piping components, fittings and couplings for
grooved end piping systems shall be furnished by the same manufacturers.
PART 2 - PRODUCTS
2.01 PIPING MATERIALS:
Unless otherwise specified, piping materials, including pipe, gaskets, fittings, connection
and joint assemblies, linings and coatings, shall be selected from those listed on the
piping $ystem specification sheets. Piping materials shall conform to detailed
speGifications for each type of pipe and piping appurtenance specified in other sections of
Division 15.
2.02 PIPING IDENTIFICATION:
A. PLASTIC CODING MARKERS:
Plastic markers for coding pipe shall conform to ANSI A 13.1 and shall be as
manufactured by W.H. Brady Company, Seton Name Plate Corporation, Marking
Services, Inc., or equal. Markers shall be the mechanically attached type that are
easily removable; they shall not be the adhesive applied type. Markers shall consist
of pressure sensitive legends applied to plastic backing which is strapped or
otherwise mechanically attached to the pipe. Legend and backing shall be resistant
to petroleum based oils and grease and shall meet criteria for humidity, solar
PIPING SYSTEMS
15050-5
F&V Project No.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
radiation, rain, salt, fog and leakage fungus, as specified by MIL-STO-810C. Markers
shall withstand a continuous operating temperature range of -40 to 180 degrees F.
Plastic coding markers shall not be the individual letter type but shall be manufactured
and applied in one continuous length of plastic.
Markers bearing the legends on the backgr9und colors specified in the Piping
Services Tables shall be provided in the following letter heights: .
Outside Pipe Oiameter,* Inches
Letter Heiqht, Inches
Less than 1-1/2
1-1/2 through 3
Greater than 3
1/2
1-1/8
2-1/4
*Outside pipe diameter shall include insulation and jacketing.
2.03 VALVES:
Valves of the same size and service shall be provided by a single valve manufacturer.
packing shall be non-asbestos material. Actual length of valves shall be within 1/16 inch
(plus or minus) of the manufacturer's specified length. Flanges shall meet the
requirement of ANSI 816.5. Push-on and mechanical joints shall meet the requirements
of A WNA C 111. Valve operators are specified in Section 15185.
2.04 ROOF CONES:
A. A bare pipe rising through roof sleeves shall be provided with roof cones made of 11
gage sheets of material which is compatible to the pipe material. These cones are to
be continuously welded to the pipe circumference and shall have a base diameter of 6
inches larger than the roof sleeve extension. Roof sleeves are detailed on Building
pr~wings.
2.05 PRODUCT DATA:
Product data on piping materials shall be provided in accordance with Section 01800
where specified.
Piping layout drawings shall be transmitted to the Engineer a minimum of 2 weeks prior
to construction. Orawings shall be original layouts by the Contractor; photocopies of
contract drawings are not acceptable.
PIPING SYSTEMS
15050-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
PART 3 - EXECUTION
3.01 INSTALLATION:
A. LOCATION:
... ~
Piping shall be provided as specified except for adjustments to avoid architectural and
structural features and shall be coordinated with electrical construction.
B. PIPING SIZES:
Where the size of piping is not specified, the Contractor shall provide piping of the
sizes required by the Uniform Plumbing Code. Unless specified otherwise, small
piping (less than 1 inch in diameter) required for services not described by UPC shall
be 1/2 inch.
C. PIPE SUPPORT, ANCHORAGE. AND SEISMIC BRACING:
Piping shall be supported by anchor brackets, guides, saddles or hangers.
Acceptable types of supports, guides, saddles, hangers and structure attachments for
general pipe support, expansion/contraction and for seismic bracing, as well as
anchorage details, are shown on the drawings. Minimum spacing shall be as
specified for supports and for seis.mic bracing. Where a specific type of support or
anchorage is indicated on the layout drawings, then only that type shall be used there.
Piping shall be vertically supported by anchor brackets, guides, saddles or hangers
and shall be seismically braced where indicated to resist lateral load. Supports shall
be provided on each run at each change of direction. Pipe supports shall be hot-dip
or mechanically galvanized. Unless otherwise specified, existing pipes and supports
shall not be used to support new piping.
D. ANCHORAGE FOR BURIED PIPING:
All plugs, caps, tees and bends in buried pressure piping systems shall be' anchored
by means of reaction backing or restrained joints as specified.
E. BEDDING IDENTIFICATION:
Bedding and backfill for buried piping shall be as specified.
PIPING SYSTEMS
15050-7
F&V Project No.~7 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
3.02 PIPING IDENTIFICATION:
A. PIPE CODING:
After application of the specified coating and insulation systems, exposed piping,
interior and exterior, and piping in ceiling spaces, pipe trenches, pipe chases and
valve boxes shall be identified with plastic markers as specified in Paragraph 15050-
2.02 A. Legend markers and directional arrows shall be located at each side of walls,
floors and ceilings, at one side of each piece of equipment, at piping intersections,
and at approximately 50-foot centers.
B. DETECTION TAPE:
Detection tape/marking tape shall consist of a minimum 4.0 mil thickness inert
polyethylene plastic that is resistant to alkalis, acids and other destructive elements
found in the soil. The tape shall have a minimum 3" width and a minimum tensile
strength of 2,800 psi. A continuous warning message repeated every 16" to 36" shall
be imprinted on the tape surface. The tape shall contain an opaque color concentrate
designating the color code as defined in the Piping Services Table. The message
shall read: "Caution - (Service Type) Line Below" imprinted in black. The service type
shall be the particular service such as "Chlorine," "Water," etc.
3.03 VALVE IDENTIFICATION:
Stainless steel tags bearing the specified valve number stamped in 1/4-inch high letters
shall be installed on valve flanges in a position visible from floor level. Flangeless valves
8 inches in diameter and larger shall have tags attached to the valve body by self-tapping
corrosion resistant metal screws. Flangeless valves 6 inches in diameter and smaller
shall have tags attached to the valve stem by stainless steel wire, 0.063 inch minimum.
...
3.04 TESTING:
A. GENERAL:
Upon completion of piping, but prior to application of insulation on exposed piping, the
Contractor shall test the piping systems. Pressures, media and test durations shall be
as specified in Section 3.06 - Piping System Materials. Equipment which may be
damaged by the specified test conditions shall be isolated. Testing shall be
performed using calibrated test gages and calibrated volumetric measuring equipment
to determine leakage rates. Each test gage shall be selected so that the specified
test pressure falls within the upper half of the gage's range. Unless otherwise
specified, the Contractor shall notify the Engineer 24 hours prior to each test.
PIPING SYSTEMS
15050-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
'1
I
I
I
I
I
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia.
Unless otherwise specified, testing, as specified herein, shall include existing piping
systems which connect with new pipe systems. Any piping which fails the test shall
be repaired. Repair of existing piping will be considered and paid for as extra work.
Where testing existing chlorine and sulfur dioxide systems to the nearest isolation
v?lv~, Contractor shall provide a tee in the line adjacent to the valve. The branch
outlet on the tee shall be valved and used for cleaning, pressure testing, draining, and
drying the line. Unless otherwise indicated, the existing chlorine or sulfur dioxide
system shall not be shut down during the testing or connecting the tee and valve.
Prior to placing the line in service, the valve on the branch outlet shall be plugged or
sealed with a blind flange or threaded plug. Contractor shall be responsible for all
damage to the existing system as a result of this work.
B. GAS. AIR, AND VAPOR SYSTEMS:
The Contractor shall test steam lines hydrostatically in accordance with the ASME
procedure for testing pressure piping.
Unless otherwise specified, the testing medium for other gas, air and vapor systems
shall be as follows:
Pipeline Size Specified Test Pressure Testing Medium
2 inch and smaller 75 psi or less Air or Water
2 inch and smaller Greater than 75 psi Water
Greater than 2 inch 3 psi or less Air or Water
Greater than 2 inch Greater than 3 psi Water
.. ~ '. ..4
.. .
"fhe allowable leakage rate for hazardous gas systems, insulated systems, and
systems tested with water shall be zero at the specified test pressure throughout the
specified test period. Hazardous gas systems shall include propane, sludge gas and
natural gas systems.
The allowable leakage rate for other systems tested with air shall be based on a
maximum pressure drop of 5 percent of the specified test pressure for the duration of
the period. Prior to starting a test interval using air, the air shall be at ambient
temperature and specified test pressure.
C. LIQUID SYSTEMS:
Leakage shall be zero at the specified test pressure throughout the specified duration
for the following systems: exposed piping, buried insulated piping, and buried or
PIPING SYSTEMS
15050-9
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
exposed piping carrying liquid chemicals. Testing procedures for hydraulic and lube
oil systems are specified in Paragraph 15050-3.04 E. Unless otherwise specified,
leakage from other buried liquid piping systems shall be less than 0.02 gallon per hour
per inch diameter per 100 feet of buried piping.
D. HYDRAULIC AND LUBE OIL SYSTEMS:
Upon completion of cleaning, all field connections shall be completed and the system
tested at the specified pressure. Pressure loss shall be zero for the specified test
period. For fluid power systems, the manufacturer shall supervise the installation and
testing of all systems components including all field piping.
E. DRAINS:
Drain systems, other than pumped drain systems, shall be tested in accordance with
LJPC.
3.05 CLEANING AND FLUSHING:
A. GENERAL:
Piping systems shall be cleaned following completion of testing and prior to
connection to operating, control, regulating or instrumentation equipment. The
Contractor may, at his option, clean and test sections of buried or exposed piping
systems. Use of this procedure, however, will not waive the requirement for a full
pressure test of the completed system. Unless specified otherwise, piping 24 inches
in diameter and smaller shall first be cleaned by pulling a tightly fitting cleaning ball or
swab through they system. Piping larger than 24 inches in diameter may be cleaned
manually or with a cleaning ball or swab.
B. TEMPORARY SCREENS:
~
Upon completion of the cleaning, the Contractor shall connect the piping systems to
related process equipment. Temporary screens, provided with locator tabs which
remain visible from the outside when the screens are in place, shall be inserted in
pipelines at the suction of pumps and compressors in accordance with the following
table:
Equipment suction or pipinq size,
inches
Maximum screen opening,
inches
o to 1
1/16
1-1/4 to 3
1/4
PIPING SYSTEMS
15050-10
I
I
I
I
I
I
I
'I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
3-1/2 to 6
1/2
Over 6
1
The Contractor shall maintain the screens during testing, initial start-up, and initial
operating phases of the commissioning process. In special cases. screens may be
removed as required for performance tests. The Contractor shall remove .the
temporary screens and make the final piping connections after the screens have
remained clean for at least 24 consecutive hours of operation. Systems handling
solids are exempted.
C. GAS AND AIR SYSTEMS:
Unless otherwise specified, gas and air system piping 6 inches in diameter and
smaller shall be blown out, using air or the testing medium specified. Piping larger
than 6 inches shall be cleaned by having a swab or "rig" drawn through the separate
reaches of pipe. After connection to the equipment, it shall then be blown out using
the equipment. Upon completion of cleaning, the piping shall be drained and dried
with an air stream. Sludge gas, natural gas and propane systems shall be purged
with nitrogen and a nitrogen pad maintained at 10 psi until put in service.
D. LIQUID SYSTEMS:
After completion of cleaning, liquid systems, unless otherwise specified, shall be
flushed with clean water. With temporary screens in place, the liquid shall be
circulated through the piping system using connected equipment for a minimum
period of 15 minutes and until no debris is collected on the screens.
E. HOT WATER SYSTEMS:
;,
'k,
if.
Before the hot water system is put into service, cleaning shall be performed to remove
such contaminants as mill scale, weld scale, corrosion products, oil, grease, dust and
dirt. Cleaning shall include a water flush performed at a velocity not less than 2 feet
per second and an alkaline flush boilout of the boiler. .
After flushing as indicated above, the boiler shall be treated with a caustic compound
such as sodium triphosphate, soda ash, sodium tripolyphosphate, or caustic soda.
The cleaning process shall be in accordance with steam system cleaning scheme
developed by Dowell, the Mogul Division of Dexter Corp., Bentz Entec, or equal.
After cleaning and flushing, and prior to continuous operation of the hot water system,
adequate corrosion protection shall be provided by maintaining the system full of
potable water. If continuous operation does not occur within 60 days after cleaning
and flushing, the potable water shall be treated with an acceptable corrosion inhibiting
chemical to assure adequate corrosion protection of the steam system.
PIPING SYSTEMS
15050-11
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
F. POTABLE WATER SYSTEMS:
Potable water piping systems shall be flushed and disinfected in accordance with
AWVVA C651.
3.06 PIPING SYSTEM MATERIALS:
Piping and valves for groupings of similar plant processes or types of service lines are
specified as the following systems. Piping services are grouped according to the
chemical and physical properties of the fluid conveyed and/or by the temperature or
pressure requirements. Each grouping of services (System No.) is identified by a piping
system number. Piping services are alphabetically arranged by designated service
symbols as shown in Table A. Table A also indicates the system number, fluid category,
and pipe coating color of each service.
Symbol
Service
System
Fluid Cateqorv
D Orain 24 OrainNent
DS Digested Sludge 14 Sludge'
FLG Flue Gas 31 Gas
HWR Hot Water Return 9 Water
HWS Hot Water Supply 9 Water
IA Instrument Air 2 Air
LSG Low Pressure Sludge 7 Gas
Gas
NG Natural Gas 5 Gas
OF Overflow 14 Wastewater
PS Primary Sludge 14 Sludge/Scum
SN Supernatant 14 Sludge
...
THS Thickened Sludge 14 Sludge
TRS Sludge Transfer 14 Sludge
V Vent 24 DrainNent
WAS Waste Activated Sludge 14 Sludge
1W Potable Water (City 8 Water
Water)
2W Non Potable City Water 11 Water
PIPING SYSTEMS
Pipe Coatinq
Color
Green
Brown
Green
Green
Orange
Yellow
Yellow
Green
Brown
Green
Brown
. Brown.
Yellow
Brown
Blue
Green
15050-12
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
3.06 PIPING SPECIFICATION:
System - 2 Piping Symbol/ Service: I'A - Instrument Air
SA - Service Air
Test Requirements: Medium: Ref. Spec Paragraph 15050 - 3.04B.
: Pressure: 200psig
~ -
Duration: 120 minutes
Gasket requirements: Flange: Compressed gasketing consisting of organic fibers (Kevlar)
and neoprene binder
Push-on/Mech Cpl: N/A
Exposed Pipe and Valves: (See drawings for pipe size and valve type)
(1/2" and smaller)
Tubing: Stainless Steel tube: ASTM A296-TP316, 0.035 in. will 316 stainless steel.
Connections: 316 stainless steel compression type.
Fittings: 316 stainless steel, Swagelok, Gyrolok, or equal.
(3/4" thru 2")
Pipe: Steel Pipe: Sch 40, ERW, threaded and coupled spec 15061.
Connections: Threaded.
Fittings: class 150 screwed banded, malleable iron ANSI B16.3.
(2" and Smaller)
Valves: Ball: Worcester 44-6-6-T-SE, Nibco T-590, or equal ,
lift Check: Lunkenheimer 1616, Crane 366E. or equal.
(2-1/2" thru 6")
Pipe: Steel: ASTM A53, ERW, Grade B, black, no lining. Ref. Spec section
15061,
Connections: Butt weld, flanged for valves.
Fittings: Steel, ASTM A234, ANSI B16.9; ends to match pipe.
Valves: Ball: Worcester 51-2-6- T-150, Nibco F-510-CS-R-66/FS, or equal.
Check: Pennsylvania Airchek, Hoerbiger. or equal.
Buried and Encased Pipe and Valves: (See drawings for pipe size and valve type. Omit
coatings on encased pipe.)
(2" and Smaller)
Pipe: Copper tube: ASTM B88, Type K, annealed or drawn.
Connections: Solder type.
Fittings: Wrought copper or bronze, ANSI B 16.22.
Valves: Ball: Same as exposed with extension stem and valve box.
(2-1/2" thru 6")
Pipe: Steel: Same as exposed with polyethylene tape coating. Field
application of coating to all couplings. Ref. spec Section 15061.
Connections: Same as exposed with coating.
Fittings: Same as exposed with coating.
Valves: Ball: Same as exposed with extension stem and valve box. Coating per
spec. Section 09800.
PIPING SYSTEMS
15050-13
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
System - 5 Piping Symbol/Service: I NG - Natural Gas
Test Requirements: Medium: Ref. Spec Paragraph 15050 - 3.04 B.
Pressure: 150 psig
Duration: 120 minutes
Gasket re~uirements: Flange: Neoprene, C.1. (NG)
<' Push-on/Mech Cpl: N/A
Exposed Pipe and Valves: (See drawings for pipe size and valve type.)
(2" and smaller)
Pipe: Steel: ASTM A106, seamless, Grade B, black, no lining. Ref. spec.
section 15061.
Connections: Taper threaded, ANSI B 1.20.1.
Fittings: Malleable iron, ASTM A197, ANSI B16.3, Class 150; ends to
match pipe.
Valves: Ball: Jamesbury 11-2136TT, Apollo Series 73-140, Lunkenheimer 711 ST, or
equal.
Globe: Crane 254XR, Lunkenheimer 1021-PS, or equal.
Lift Check: Jenkins 54, Lunkenheimer 1616, or equal
(2-1/2" thru 8")
Pipe: Steel: ASTM A53, seamless, Grade B, black, no lining. Ref. Spec
Section 15061.
Connections: Butt weld, flanged for valves.
Fittings: Steel, ASTM A234, ANSI B16.9; ends and wall thickness to
match pipe.
Valves: Lubricated Plug: Cast iron, flanged, Teflon coated plug, Rockwell Fig. 143,
Walworth Fig. 1797F, or equal, thru 5-inch; worm gear operator
Rockwell Fig. 149, Walworth Fig. 1727.F, or equal, 6- to 8-inch.
Butterfly: Ref. spec. Section 15103.
Check: Pennsylvania Airchek, Hoerbiger, or equal.
Buried and Encased Pipe and Valves: (See drawings for pipe size and valve type. Omit
coating on encased pipe.)
(2" and smaller)
Pipe: Steel: Same as exposed with polyethylene coating. Field application of
coating to all couplings. Ref. spec. Section 15061. Provide
- plastic tracer tape.
Connections: Same as exposed with coating. ..
Fittings: Same as exposed with coating.
Valves: Ball: Same as exposed with extension stem and valve bax. Coating per spec.
Section 09800.
(2-1/2" thru 8")
Pipe: Steel: Same as exposed with coating specified above. Provide plastic
tracer tape.
Connections: Same as exposed with coating.
Fittings: Same as exposed with coating.
Valves: Lubricated Plug: Same as exposed with extension stem and valve box. Coating
per spec. Section 09800.
Butterfly: Same ans exposed with extension stem and valve box. Coating
per spec. Section 09800.
Valves: Ball: Same as exposed with extension stem and valve box. Coating per
spec Section 09800.
PIPING SYSTEMS
15050-14
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
System - 7 Piping Symbol/ Service: I LSG - Low Pressure Sludge Gas
Test Requirements: Medium: Ref.. Spec Paragraph 15050 - 3.04B.
Pressure: 150 psig
Duration: 120 minutes
Gasket regujrements: Flange: Neoprene, C.!. (NG)
Exposed Pipe and Valves: (See drawings for pipe size and valve type)
(1/2" thru 12")
Pipe: Stainless Steel: ASTM A312-TP316L stainless steel Schedule 20S seamless,
Bevel end. ANSI B36.19.
Joints: Butt weld. Flanged where required to match valves or equipment
connections.
Fittings: ASTM A403-WP316LS butt weld ends to ANSI B16.9 with wall thickness
to match pipe.
Unions: (1/2" thru 1-1/2") ASTM A1403, Class 3000 316L stainless steel,
socket weld type with integral seat per ANSI B16.9.
Flanges: (1/2" thru 1-1/2") ASTM A182-1:316L, Class 150, 316L stainless steel,
slip-on, raised face. Faced and drilled per ANSI B16.5.
(2" thru 12") ASTM A536, Class 150 ductile iron back-up flange,
drilled per ANSI B16.5.
Valves: Ball: (1/2" thru 2") Class 150, 316 stainless steel, three piece body, threaded
ends, lever oper, Worcester 44-6-6-T-SE, NfBCO T-590-S6-R-66 or equal.
Butterfly (4" thru 8") Ref. Spec Section 15103
Check: Pennsylvania Air Check, Hoerbiger, or equal
Buried and Encased Pipe and Valves: (See drawings for pipe size and valve type. Omit
coating on encased pipe.)
(2-1/2" thru 8")
Pipe: Steel: ASTM A53, seamless, Grade B, black, no lining. Polyethylene
Coating. Ref. Spec Section 15061. Provide plastic tracer tape.
Connections: Butt weld, flanged for valves. Polyehtylene Coating
Fittings: Steel, ASTM A234, ANSI B16.9; ends and wall thickness to
match pipe. Polyethylene Coating.
Valves: Lubricated Plug: per Spec Section 15110.
- Extension Stem and Valve Box. Coating per 09800.
PIPING SYSTEMS
15050-15
I
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant I
Augusta-Richmond County, Georgia.
BRANCH TABLE I
HEADER BRANCH SIZE
SIZE I
1/2 3/4 1 1/2 2 21/2 3 4 6 8 10 12 14 16 18 20 24
1/2 T
3/4 RT T
1 RT RT T .1
1 1/2 RT RT RT T
2 RT RT RT RT T
2 1/2 SOL SOL SOL SOL W T I
3 SOL SOL SOL SOL W N T
4 SOL SOL SOL SOL W N N T I
6 SOL SOL SOL SOL W N N N T
8 SOL SOL SOL SOL W N N N N T
10 SOL SOL SOL SOL W N N N N N T I
12 SOL SOL SOL SOL W N N N N N N T
14 SOL SOL SOL SOL W N N N N N N N T
16 SOL SOL SOL SOL W N N N N N N N N T I
18 SOL SOL SOL SOL W N N N N N N N N N T
20 SOL SOL SOL SOL W N N N N N N N N N N T
24 SOL SOL SOL SOL W N N N N N N N N N N N T I
T = Straight Tee I
RT = Reducing Tee
C = Half Coupling, Socket Weld, Class 3000
SOL = Sockolet I
TOL = Thredolet
W = Weldolet
N = Nozzle Weld per B31.3 Code I
I
I
I
I
I
PIPING SYSTEMS 15050-16 I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
System - 8 Piping Symbol! Service: I 1W - Potable Water
Test Requirements: Medium: Water, Ref. Spec Paragraph 15050 - 3.04C.
Pressure: 150 psig
Duration: 60 minutes
Gasket requirements: Flange: Compressed gasketing consisting of organic fibers (Kevlar)
- and neoprene binder
~ Push-on/Mech Cpl: EPDM
Exposed Pipe and Valves: (See drawings for pipe size and valve. See remarks for insulation
requirements. )
(3" and smaller)
Pipe: Copper tube: ASTM B88, Type L, drawn. Ref. Spec Section 15066.
Connections: Solder type with threaded or flanged adapters for valves.
Fittings: Wrought copper or bronze, ANSI B16.22.
(2" and smaller)
Valves: Ball: Worcester 44-6-6-T-SE, Nibco T-590, or equal
Swing Check: Crane 127, Lunkenheimer 230, or equal.
(4" and larger)
Pipe: Ductile Iron: AWl/VA C151 with cement mortar lining. Ref. spec. 15062.
Steel: ASTM A53, seamless, Grade B, black, With cement mortar
lining. Ref. Spec section 15061.
Connections: Grooved mechanical pipe coupling or flanged.
Fittings: Malleable iron, ductile iron, or steel per spec Section 15061; ends
and lining to match pipe.
(2-1/2" and larger)
Valves: Butterfly: Ref. spec Section 15103. Substitute Type B on 2-1/2-inch lines. "
Swing Check: Sprin"g loaded per spec Section 15118.
Buried and Encased Pipe and Valves: (See drawings for pipe size and valve type. Omit
coating on encased pipe.)
(3" and Smaller)
Pipe: Copper tube: ASTM B88, Type K, annealed or drawn.
Connections: Solder type, with threaded or flanged adapters for valves.
Fittings: Wrought copper or bronze, ANSI 816.22.
Valves: - Gate: Ref. spec. Section 15101, with extension stem and valve box. Coating
per spec. Section 09800.
(4" and Larger)
Pipe: Ductile Iron: AWl/VA C151 with cement mortar lining. Ref. spec. Section
15062.
Connections: Grooved end or restrained push-on rubber gasket joint. Flanged
adapters for valves.
Fittings: Ductile iron per spec. section 15062; coating, lining, and ends to
match pipe.
Valves: Butterfly: Same as exposed with extension stem and valve box. Coating per
spec. Section 09800.
PIPING SYSTEMS
15050-17
F&V Project NO.97 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
System - 11 I Piping Symbol/Service: I HWR - Hot Water Return
HWS - Hot Water Supply
Test Requirements: Medium: Water, Ref.. Spec Paragraph 15050 - 3.04C.
Pressure: 150 psig
Duration: 60 minutes
. Gasket requirements: Flange: Compressed gasketing consisting of organic fibers (Kevlar)
and neoprene binder
Push-on/Mech Cpl: Nitrile or Neoprene.
Exposed Pipe and Valves: (See drawings for pipe size and valve type)
(3" and smaller)
Pipe: Steel: ASTM A53, ERW, grade B. no lining, Ref Spec 15061.
Connections: Taper threaded, ANSI B1.20.1.
Fittings: Malleable iron, ASTM A197, ANSI B16.3, Class 150.
Valves: Ball: Worcester 44-6-6-T-SE, Nibco T-590, or equal
Globe: Crane 7TF or 17TF, Lunkenheimer 123 or 214, or equal.
Swing Check: Crane 137, Lunkenheimer 230, or equal.
(4" thru 8")
Pipe: Steel: ASTM A53, ERW, Grade B, black, no lining. Ref. Spec section
15061.
Connections: Butt weld, grooved mech pipe coupling or flanged.
Fittings: Malleable iron, ductile iron, or steel per spec. Section 15061; ends
to match pipe.
Valves: Butterfly: Ref. spec. Section 15103. Substitute Type Bon 2-1/2 inch lines.
Swing Check: Spring loaded per spec. Section 15118.
(10" and larger)
Pipe: Steel: Same as 8-inch or AWWA C200, 1/4-inch thick, with lining. Ref.
spec. Section 15061.
Connections: Butt weld, mech. pipe coupling, or flanged.
Fittings: Steel, ASTM A234, or fabricated steel, AWWA C208; lining and
ends to match pipe.
Buried and Encased Pipe and Valves: (See drawings for pipe size and valve type. Omit
coating on encased pipe.)
-
(3" and larger)
Pipe: Steel: Same as exposed with polyethylene tape coating. Field
application of coating to all couplings. Ref. spec. Section 15061.
Connections: Taper threaded, ANSI B1.20.1 with coating. Flanged adapters
for 2-1/2 inch, 3-inch valves.
Fittings: Malleable Iron, ASTM A197, ANSI B16.3, Class 150, galvanized
with coating.
Valves:
Butterfly: Same as exposed with extension stem and valve box. Coating
per spec. Section 09800.
Remarks:
1. Manual air vents shall be provided at the high points and drains provided at the low
points of each reach of pipeline as specified in Paragraph 15095-3.03.
PIPING SYSTEMS
15050-18
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
System - 14 Piping Symbol/Service: os - Digested Sludge
TRS - Sludge Transfer
WAS - Waste Activated Sludge
SN - Supernatant
PS - Primary Sludge
Test Requirements: Medium: Water; ref. Spec Paragraph 15050 - 3.04 C.
Pressure: 125 psig
Duration: 120 minutes
Gasket requirements: Flange: Compressed gasketing consisting of organic fibers (Kevlar)
and neoprene binder.
Push-on/Mech Cpl: Nitrile or Neoprene.
Exposed Pipe and Valves: (See drawings for pipe size and valve type.)
(4" thru 24")
Pipe: Stainless Steel: ASTM A240, 316L, ref. spec. Section 15067.
Connections: Butt weld, mech. pipe coupling or flanged.
Fittings: Stainless Steel, ASTM A774.
Valves: Eccentric Plug: Per Spec 15110 Install with seat upstream.
Check: Per Spec 15116.
Buried and Encased Pipe and Valves: (See drawings for pipe size and valve type. Omit
coating on encased pipe.)
Valves: Eccentric Plug: Same as exposed with extension stem and valve box. Coating
per spec. Section 09800.
(4" and larger")
Pipe: Ductile Iron: AWWA 151. Ref. spec. Section 15062
Connections: Restrained push-on rubber gasket joint.
Fittings: Ductile Iron per spec. 15062; coating, lining and end to
match pipe.
Valves: Eccentric Plug: Same as exposed with extension stem and valve box. Coating
per spec. Section 09800.
Remarks:
1. Mar}ual air vents shall be provided at the high points and drains provided at the low
points of each reach of pipeline as specified in Paragraph 15095-3.03.
2. Gravity flow piping shall be tested at a pressure of 15 psig.
PIPING SYSTEMS
15050-19
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
System - 24 Piping o - Drain
Symbol/Service: V - Vent
Test Requirements: Medium: In accordance with Standard Plumbing Code.
Pressure: In accordance with Standard Plumbing Code.
Duration: In accordance with Standard Plumbing Code.
Gasket requirements: Flange: Compressed gasketing consisting of organic fibers (Kevlar) and
neoprene binder.
Push-on/Mech Cpl: Nitrile/neoprene.
Exposed Pipe and Valves: (See drawings for pipe size.)
(3" and smaller)
Pipe: Steel: ASTM A53, galvanized. Ref. spec. 15061.
Connections: Taper threaded, ANSI B1.20.1.
Fittings: Cast iron, threaded drainage fittings, ASTM A 125, ANSI B 16.12,
galvanized.
Valves: None.
(4" thru 6")
Pipe: Cast Iron Soil Pipe (CISP): ASTM A74.
Connections: Service hub and spigot compression type or hubless cast iron
sanitary system per CISPI 301.
Fittings: CISP, ASTM A74, joint options to match pipe.
Valves: None.
Buried and Encased Pipe and Valves Under and Five Feet Outside Building: (See drawings
for pipe size.)
(6" and smaller)
Pipe: Cast Iron Soil Pipe (CISP): Same as exposed.
Valves: None.
(8" and larger)
Pipe: Ductile Iron: Same as exposed.
Valves: None:
Buried and Encased Pipe and Valves Under and Five Feet Outside Building: (See drawings
for pipe size.) Buried and Encased Pipe and Valves Under and Five Feet Outside Building:
(See drawings for pipe size.)
(8" and smaller)
Pipe: PVC: ASTM 01784, Class 12454-B, ASTM 02665, Sch. 40. Ref. spec
15064. Provide magnetic tracer tape.
Connections: Plain end, solvent weld.
Fittings: PVC, socket type, DWV, ASTM 02665.
Valves: None.
System 24 (eontinued)
(10" and 12")
Pipe: PVC: ASTM 03034, SDR 35. Provide magnetic tracer tape.
Connections: Push-on with nitrile gasket.
Fittings: PVC or IPS cast iron; ends to match pipe.
Valves: None.
PIPING SYSTEMS
15050-20
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
System - 31 Piping FLG - Flue Gas
Symbol/Service:
Test Requirements: None.
Gasket re,quirements: Flange: Spiral wound with type 347 SS V-shaped strips, separated by
~ graphoil filler.
Push-on/Mech Cpl: N/A.
Exposed Pipe and Valves: (See drawings for pipe size and valve type.)
All Pipe: Steel: ASTM A358 Class I Type 321 or 316L seamless, Schedule 10S
per Section 15067 with 100 percent X-ray certification.
Connections: Butt weld, flanged for equipment connections.
Fittings: Same as pipe.
Dampers: See specification section 15863.
Remarks:
Pipe and fittings shall be insulated as specified in Section 15250.
END OF SECTION 15050
PIPING SYSTEMS
15050-21
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 96 000 00
Project Name
Client & Client Project No.
SECTION 15061 - STEEL PIPE
PART 1 - GENERAL
1.01 DESCRIPTION:
This section specifies steel pipe and fittings.
1.02 REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall prevail.
Reference
Title
ANSI B16.3-85
Malleable Iron Threaded Fittings, Class 150 and 300
ANSI B16.9-86
Factory-Made Wrought Steel Suttwelding Fittings
ANSI B16.11-80
Forged Steel Fittings, Socket-Welding and Threaded
ASTM A36/A36M-87
Structural Steel
ASTM A47 -84
Ferritic Malleable Iron Castings
ASTM A53-87
Pipe, Steel, Slack and Hot-Dipped, Zinc-Coated Welded
and Seamless
ASTM A 1 05/A 1 05M-87
Forgings, Carbon Steel, for Piping Components
.;
ASTM A 106-87
Seamless earbon Steel Pipe for High-Temperature
Service
ASTM A 120-84
Pipe, Steel, Black and Hot-Dipped Zinc-Coated
(Galvanized) Welded and Seamless, for Ordinary Uses
ASTM A 197 -87
Cupola Malleable Iron
ASTM A234/A234M-87
Pipe Fittings of Wrought Carbon Steel and Alloy Steel for
Moderate and Elevated Temperatures
Low and Intermediate Tensile Strength Carbon Steel
Plates, Shapes and Bars
ASTM A283/A283M-87
STEEL PIPE
15061-1
STEEL PIPE
15061-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 96 000 00
Project Name
Client & Client Project No.
ASTM A536-84
Ductile Iron Castings
ASTM A570/A570M-88
Hot-Rolled Carbon Steel Sheet and Strip, Structural
Quality
AS-rM A572/A572M-85
High Strength Low Alloy Columbium-Vanadium Steels of
Structural Quality
AVWVA C200-86
Steel Water Pipe 6 Inches and Large
AVWVA C2003-86
Coal-Tar Protective Coatings and Linings for Steel Water
Pipelines--Enamel and Tape--Hot-Applied
AVWVA C205-85
Cement-Mortar Protective Lining and Coating for Steel
Water Pipe--4 Inches and Larger-Shop Applied
AVWVA C206-82
Field Welding of Steel Water Pipe
AVWVA e207-86
Steel Pipe Flanges for Waterworks Services-Sixes 4
Inches through 144 Inches
AVWVA C208-83
Dimensions for Fabricated Steel Water Pipe Fittings
AVWVA C209-84
Cold-Applied Tape Coating for Special Sections,
Connections, and Fittings for Steel Water Pipelines
AVWVA C210-84
Coal-Tar Epoxy Coating System for the Interior and
Exterior of Steel Water Pipe
AVWVA C214-83
Tape Coating Systems for the Exterior of Steel Water
Pipelines
AVWVA C600-82
Installation of Ductile-Iron Water Mains and Their
Appurtenances
AVWVA M11-85
Steel Pipe--A Guide for Design and Installation
SSPC-82
Steel Structures Painting Council Specifications
B. TESTING:
Factory testing shall conform to the requirements of ASTM A53, ASTM A 106, ASTM
A 120, or AVWVA C200 as applicable.
I
I
I
I,
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 9600000
Project Name
Client & Client Project No.
1.03 SUBMITTALS:
The following information shall be provided in accordance with Section 01800:
1. Affidavits of Compliance with AWVVA C200 or ASTM A53, ASTM A 106 or ASTM
~ A120, as applicable.
2. Contractor's layout drawings as specified in Paragraph 15050-2.04.
PART 2 - PRODUCTS
2.01 PIPE MATERIALS:
Steel pipe and fittings shall be provided in accordance with ASTM A53, ASTM A 106,
ASTM 120, or AWVVA C200 as specified in Section 15050, Piping Systems.
Steel for pipe fabricated to meet requirements of AWVVA C200 shall conform to the
requirements of ASTM A36, ASTM A572, Grade 42, ASTM A570, Grades 33 and 36, or
ASTM A283, Grade D. Steel for ASTM A53 and ASTM A106 pipe shall be Grade B.
2.02 PIPE MANUFACTURE:
Unless otherwise specified, ASTM A53 pipe shall be Type E, electric resistance welded
or Type S, seamless pipe as specified in Section 15050. The minimum wall thickness for
ASTM A53, ASTM A106, or ASTM A120 pipe shall be Schedule 40 for pipe 10 inch
diameter and less and 3/8 inch for pipe 12 inch through 24 inch diameter. Increased
shell thickness shall be provided where specified.
AVWVA C200 pipe shall be straight or spiral seam. The minimum wall thickness shall be
7 gage for pipe 6 inch through 24 inch diameter and 1/4 inch for pipe 26 inch diameter
and ~ar.ger. Increased shell thickness shall be provided where specified.
2.03 CONNECTIONS:
Connections shall be as specified in Section 15050 and shall conform to Section 15085.
Coating for buried connections shall be as specified in Paragraph 15085-2.06.
2.04 FITTINGS AND APPURTENANCES:
Malleable iron threaded fittings and appurtenances shall conform to the requirements of
ASTM A47 or ASTM A197, ANSI B16.3.
STEEL PIPE
15061-3
F&V Project No. 96 000 00
Project Name
Client & Client Project No.
Unless otherwise specified, steel fittings and appurtenances shall conform to the
requirements of ASTM A234, ASTM A 105, or ANSI B16.11; and fabricated steel fittings
and appurtenances shall conform to AV'MIA C208.
Fittings for grooved end piping systems shall be full flow cast fittings, steel fittings, or
segmentally welded fittings with grooves or shoulders designed to accept grooved end
couplings. Cast Fittings shall be cast of ductile iron conforming to ASTM A-536 or
malleable iron conforming to ASTM A47. Standard steel fittings, including large size
elbows, shall be forged steel conforming to ASTM A-1 06. Standard segmentally welded
fittings shall be fabricated of schedule 40 carbon steel pipe.
Unless otherwise specified, all fittings shall be rated for pressure and loadings equal to
the pipe.
2.05 PIPE LINING:
A. CEMENT MORTAR:
Where specified, pipe and fittings shall be lined with cement mortar as specified in
AWVVA C205. Fittings and specials larger than 24 inches, not fabricated from
centrifugally lined straight sections, shall require 2-inch by 4-inch by 13-gage self-
furring wire mesh reinforcement for hand-applied lining.
B. EPOXY:
Where specified, steel pipe and fittings shall be epoxy lined with not less than 10 mils
of epoxy suitable for temperatures of 225 degrees F. Epoxy lining shall be 3M
Scotchkote 306, Porter MCR 65 High Solids Epoxy, or equal. Surfaces shall be
prepared in accordance with SSPC-SP 10 Near White Blast Cleaning, and the lining
applied as recommended by the manufacturer.
2.06 PIPE COATING:
A. COAL TAR EPOXY:
Unless otherwise specified, pipe and fittings for buried installation shall be coated with
coal tar epoxy, shop applied in accordance with AV'MIA C210 to a minimum thickness
of 20 mils in not less than two coats.
B. POLYETHYLENE TAPE:
Where specified, pipe and fittings shall be coated and wrapped with prefabricated
multilayer cold applied polyethylene tape coating in accordance with AWVVA C214.
Th~ coating application shall be a continuous step operation in conformance with
STEEL PI PE
15061-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
'1
I
I
I
I
I
I
F&V Project No. 9600000
Project Name
Client & Client Project No.
AVWVA C214, Section 3. The total coating thickness shall be not less than 50 mils for
pipe 26 inches and larger.
2.07 JOINT GASKETS:
J9int gaskets shall be as specified in Section 15075.
PART 3 - EXECUTION
3.01 INSTALLATION:
A. GENERAL:
Pipe shall be installed in accordance with AVWVA M11, Chapter 16. Welded joints shall
be in accordance with AVWVA C206 and Section 15085.
Sleeve-type mechanical pipe couplings shall be provided in accordance with AVWVA
M11 and Paragraph 15085-2.02 A.
Pipe lining and coatings at field joints shall be applied as specified in Paragraphs
15061-2.05 and 2.06.
Unless otherwise specified, buried mechanical couplings and valves shall be field
coated as specified in Paragraph 15085-2.06.
B. ANCHORAGE:
Anchorage shall be provided as specified. Calculations and drawings for proposed
alternative anchorage shall be submitted in accordance with Section 01800.
3.02 TEST(~G:
Hydrostatic testing shall be in accordance with Section 4 of AVWVA C600 except thattest
pressures and allowable leakage shall be as listed in Section 15050.
END OF SECTION 15061
STEEL PIPE
15061-5
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 9600000
Project Name
Client & Client Project No.
SECTION 15062 - DUCTILE IRON PIPE
PART 1 - GENERAL
1.01 DESCRIPTION:
-
A. SCOPE:
This section specifies ductile iron pipe, ductile fittings and gaskets.
B. DEFINITION:
Where cast iron pipe is specified, the term and symbol shall mean ductile iron pipe.
1.02 REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall prevail.
Reference
Title
ANSI A21.14-84
Ductile-Iron Fittings 3 Inches through 24 Inches, for Gas
ANSI A21.52-81
Ductile-Iron Pipe, Centrifugally Cast, in Metal Molds or
Sand Lined Molds for Gas
ANSI B16.1-75
Cast Iron pipe Flanges and Flanged Fittings, Class 25,
125, 250, and 800
ANSI 816.5-81
Pipe Flanges and Flanged Fittings
ASTM A 716-82
Ductile-Iron Culvert Pipe
ASTM C 150-86
P.ortland Cement
A\MNA C104-85
(ANSI A21.4)
Cement-Mortar Lining for Ductile-Iron and Gray-Iron
Pipe and Fittings for Water
A\MNA C110-82
(ANSI A 21.10)
Ductile-Iron and Gray-Iron Fittings, 3 Inches through 48
Inches, for Water and Other Liquids
A\MNA C111-85
(ANSI A21.11)
Rubber Gasket Joints for Ductile-Iron and Gray-Iron
Pressure Pipe and Fittings
DUCTILE IRON PIPE
15062-1
F&V Project No. 9600000
Project Name
Client & Client Project No.
A\f'MJA C115-83
(ANSI A21.15)
A\f'MJA C150-81
(ANSI A21.50)
A\f'MJA C151-81
(ANSI A21.51)
A\f'MJA C153-84
(ANSI A21.53)
A\f'MJA C600-82
A\f'MJA C606-81
PART 2 - PRODueTS
2.01 GENERAL:
Flanged Ductile-Iron and Gray-Iron Pipe With Threaded
Flanges
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Thickness Design of Ductile-Iron Pipe
Ductile-Iron Pipe, Centrifugally Cast, in Metal Molds or
Sand-Lines molds, for Water or Other Liquids
Ductile-Iron Compact Fittings, 3 Inches through 12
Inches for Water and Other Liquids
Installation of Ductile-Iron Water Mains and Their
Appurtenances
Grooved and Shouldered Type Joints
Pipe design, materials and manufacturer shall comply with the following references:
Item
Thickness design
Manufacturing requirements
Water or other liquid
Gas
Gr..avity service pipe
Joints
Rubber gasket
Threaded flange
Fittings
Water or other liquid
Gas
Cement mortar lining
2.02 PIPE:
Reference
A\f'MJA C150
A\f'MJA C151
ANSI A21.52
ASTM A716
A\f'MJA C111
A\f'MJA C115
A\f'MJA C110/A\f'MJA C153
ANSI A21.14
A\f'MJA C11 O/A\f'MJA C153
Unless otherwise specified, ductile iron pipe shall be Class 50 and have nominal laying
lengths of 18 or 20 feet. For grooved-end pipe, sizes through 16-inch diameter shall be
DUCTILE IRON PIPE
15062-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 96 000 00
Project Name
Client & Client Project No.
Class 53; 18-inch, 20-inch, and 24-inch diameter pipe shall be Class 54, 55, and 56,
respectively.
2.03 GASKETS:
Unle?s otherwise specified, gasket stock shall be a synthetic rubber compound in which
the elastomer is nitrile or neoprene. The compound shall contain not less than 50
percent by volume nitrile or neoprene and shall be free from factice, reclaimed rubber
and other deletefio-us substances. Gaskets shall, In addition, comply with AVWl/A C111
for push-on and mechanical joints and with AVWl/A C606 for grooved end joints.
2.04 FITTINGS:
Unless otherwise specified, fittings shall conform to AVWl/A C110. Ends shall be flanged,
restrained mechanical joint, restrained push-on, or grooved to suite the conditions
specified. The AVWl/A C153 compact ductile iron fittings in sizes 3 through 12 inches are
an acceptable substitute for standard fittings unless otherwise specified. Long-radius
elbows shall be provided where specified. Grooved end fittings shall comply with
paragraph 15050-1.02 B.
2.05 JOINTS:
A. UNRESTRAINED JOINTS:
1. PUSH-ON JOINTS: Unless otherwise specified, unrestrained joints shall be the
rubber ring compression, push-on type joint suitable for buried service. Unrestrained
joints shall be the Fastite Joint as manufactured by American Cast Iron Pipe
company, the Tyton Joint as manufactured by U.S. Pipe, or equal. This joint is not
permitted on fittings or specials, unless otherwise specified. Unless otherwise
specified, joints shall have an allowable deflection up to 5 degrees at specified
p_ressures. Joint assembly and field cut joints shall be made in strict conformance
with AVWl/A C600 and manufacturer's recommendations.
2. MECHANICAL JOINTS: Where specified, mechanical joints for above or below
ground service shall meet the requirements of ANSI/AVWVA A21.1 0/C11 0 and
ANSI/AVWl/A A21.11/C111. Gaskets and bolts and nuts shall comply with paragraphs
15062-2.03 and 2.05 0, respectively.
B. RESTRAINED JOINTS:
1. GENERAL: Unless otherwise specified, restrained joints are required for exposed
piping and all buried fittings and specials. Restrained joints for buried pipe sections
shall be provided where specified. Unless otherwise specified, restrained joints shall
DUCTILE IRON PIPE
15062 -3
F&V Project No. 9600000
Project Name
Client & Client Project No.
be flanged or grooved end for exposed service and push-on or grooved end for buried
service.
2. PUSH-ON JOINTS: Restrained push-on joints shall be as specified in paragraph
15062-2.05 A.1., modified for restraint. Joints shall be the Flex-Ring or Lok-Ring Joint
as manufactured by American Cast Iron Pipe Company, TR Flex Joint as.
manufactured by US Pipe, or equal. Restrained joints shall be capable of being
deflected after full assembly. Joint assembly shall be in strict conformance with
AWWA C600 and manufacturer's recommendations. No field cuts of restrained pipe
are permitted without prior approval of the Engineer.
3. FLANGED ASSEMBLIES: Unless otherwise specified, flanges shall be ductile
iron and shall be threaded-on flanges conforming to ANSI/AWWA A21.15C115 or
cast-on flanges conforming to ANSIIAWWA A21.10/C11 O. Flanges shall be adequate
for 250 psi working pressure. 80lt circle and bolt holes shall match those of ANSI
B 16.1, Class 125 flanges and ANSI B 16.5, Class 150 flanges. Where specified,
flanges shall be threaded-on cast-on flanges conforming to ANSI B16.1, Class 250.
Unless otherwise specified, bolts and nuts for flange assemblies shall conform with
paragraph 15085-2.01 C. Gaskets shall be as specified in paragraph 15085-2.01 B.
4. GROOVED END JOINTS: Grooved end couplings shall conform to AWWA C606
and shall be Gustin-Bacon 500 Series, Victaulic Style 31, or equal with flush seal type
gasket designed for ductile iron pipe. Unless otherwise specified, grooved end
couplings shall be rigid joint for exposed service and flexible joint for buried service.
Unless otherwise specified, bolts and nuts shall comply with paragraph 15062-2.05 D.
5. MECHANICAL JOINTS: Where specified, restrained mechanical joints shall be
the positive restraint type. Mechanical joints with retainer glands are not acceptable.
locked mechanical hydrant tees, bends and adapters are an acceptable substitute for
anchoring fire hydrants and valves to the pipe main.
c. BOLTS AND NUTS:
Corrosion-resistant bolts and nuts for use with ductile iron joints shall be high-
strength, low alloy steel as specified in ANSI/AWWA C111/A21.11.
2.06 PIPE COATING:
A. ASPHALTIC COATING:
Unless otherwise specified, pipe and fittings shall be coated with asphaltic material as
specified in AWWA C151.
DUCTILE IRON PIPE
15062 -4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No. 9600000
Project Name
Client & Client Project No.
2.07 PIPE LINING:
A. ASPHALTIC LINING:
Unless otherwise specified, pipe and fittings shall be lined with asphaltic material as
specified in AWWA C151.
B. CEMENT MORTAR LINING:
Where specified, interior surfaces of pipe and fittings shall be cement mortar lined in
accordance with AWWA C104. Cement shall be ASTM C150, Type II orV, low alkali,
containing less than 0.60 percent alkalies.
2.08 PRODUCT DATA:
The following information shall be provided in accordance with Section 01800.
A. Shop drawings.
B. Alignment drawings.
C. Certifications specified in the following references:
ANSI A21.14, paragraph 14-4.2
ANSI A21.52, paragraph 52-4.2
ASTM A716, paragraph 4.2
AWWA C110, paragraph 10-5.3
AWWA C111, paragraph 11-6.1
AWWA C115, paragraph 15-4.2
AWWA C151, paragraph 51-5.2
;. AWWA e153, paragraph 53-5.3
PART 3 - EXECUTION
3.01 INSTALLATION:
A. GENERAL:
Piping runs specified on the drawings shall be followed as closely as possible.
Proposed deviations shall be submitted in accordance with Section 01800.
Pipe shall be installed in accordance with AWWA C600.
DUCTILE IRON PIPE
15062-5
F&V Project No. 96 000 00
Project Name
Client & Client Project No.
Connections to existing structures and manholes shall be made so that the finished
work will conform as nearly as practicable to the requirements specified for the new
manholes, including necessary concrete work, cutting and shaping. Concrete mortar
shaping within any structure and manhole shall be as specified.
B. INSULATING SECTIONS:
Where a metallic non-ferrous pipe or appurtenance is connected to ferrous pipe or
appurtenance, and insulating section shall be provided as specified in paragraph
15085-3.01 E.
C. ANCHORAGE:
Anchorage shall be provided as specified. Calculations and drawings for proposed
alternative anchorage shall be submitted in accordance with Section 01800.
3.02 ACCEPTANCE TESTING:
Hydrostatic pressure tests shall be conducted in accordance with Section 4 of AWWA
C600 except that test pressures and allowable leakage shall be as listed in Section
15050.
The Contractor shall conduct the tests in the presence of the Owner's representative.
END OF SECTION 15062
DUCTILE IRON PIPE
15062-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15066 - COPPER PIPING
PART 1 - GENERAL
1.01 DESCRIPTION:
This 'section specifies copper piping, tubing, couplings and fittings.
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of
this section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ANSI B16.22-80
Wrought Copper and Copper Alloy Solder Joint
Pressure Fittings
ANSI B16.26-83
Cast Copper Alloy Fittings for Flared Copper Tubes
ASTM 832-87
Solder Metal
ASTM 888-88
Seamless Copper Water Tube
1.03 SUBMITTALS:
Contractor's layout drawings and catalog data demonstrating compliance with this
specification and giving full description of the copper piping shall be provided in
accordance with Section 01800.
PART 2 - PRODUCTS
2.01 COPPER TUBING:
Copper tubing shall be seamless copper, conforming to ASTM B88. Unless otherwise
specified, copper tubing shall be Type L, drawn, where used in exposed service and
Type K, annealed or drawn for buried service.
COPPER PIPING
15066-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2.02 COUPLINGS AND FITTINGS FOR COPPER TUBING:
Unless otherwise specified, couplings and fittings for copper tubing 1/2-inch and smaller
nominal diameter shall be compression type, brass or bronze, capable of holding the full
bursting strength of the tubing; shall meet the requirements of ANSI B16.26; and shall be
Swagelok, Gyrolok, or equal.
Couplings and fittings for copper tubing larger than 1/2-inch nominal diameter shall be
wrought copper or bronze, solder joint pressure fittings and shall conform to ANSI
B 16.22.
2.03 SOLDER:
Solder to be used in copper piping shall be ASTM B32, Alloy Grade Sn95.
PART 3 - EXECUTION
3.01 FABRICATION:
A. SOLDER JOINTS:
All pipe and fittings to be jointed with solder shall be free from all burrs and wire
brushed or steel wool cleaned. After cleaning, a paste flux shall be evenly and
sparingly applied to the surfaces to be joined. Solder shall then be applied and flame
passed toward the center of the fitting until the solder disappears. All excess solder
shall be removed while it is still disappears. All excess solder shall be removed while
it is still plastic. Absolutely no acid flux or acid wipe shall be used in making solder
joints.
B. TAKEDOWN COUPLINGS:
..
Takedown couplings shall be screw union type and shall be provided in accordance
with paragraph 15085-3.01 C.
C. DIELECTRIC PROTECTION:
Copper tubing or fittings shall not be permitted to come in contact with steel piping,
reinforcing steel, or other steel at any location. Electrical checks shall be made to
assure no contact is made between copper tubing and steel elements. Wherever
electrical contact is demonstrated by such tests, the Contractor shall provide dielectric
protection as specified in paragraph 15085-3.01 E.
COPPER PIPING
15066-2
'1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
3.02 INSTALLATION, CLEANING, DISINFECTION, AND TESTING:
The installation, cleaning, disinfection, and testing of copper piping shall be as
specified in SectiQn 15050.
END OF SECTION 15066
COPPER PIPING
15066-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15067 - STAINLESS STEEL PIPING
PART 1 - GENERAL
1.01 DESCRIPTION:
A. SCOPE:
This section specifies stainless steel pipe and fittings.
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following documents. They are a part of this
saction as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ANSI 816.1-75
Cast Iron Pipe Flanges and Flanged Fittings Classes
25, 125,250, and 800
ANSI B16.11-80
Forged Steel Fittings, Socket Welding and Threaded
ANSI 831.1-86
Power Piping
ANSI B36.19M-85
Stainless Steel Pipe
AS~E Section IX (1986)
Boiler and Pressure Vessel eode; Welding and Brazing
Qualifications
ASTM A 182/A 182M-88
Forged or Rolled Alloy-Steel Pipe Flanges, Forged
Fittings, and Valves and Parts for High-Temperature
Service
ASTM A 193/A 193M-88
Alloy Steel and Stainless Steel Bolting Materials for
High-Temperature Service
ASTM A 194/A 194M-88
Carbon and alloy Steel Nuts for Bolts for High-pressure
and High-Temperature Service
STAINLESS STEEL PIPING
15067 -1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
ASTM A240-88
ASTM A276-87
ASTM A312/A312M-88
ASTM A320/A320M-88
ASTM A403/A403M-88
ASTM A409/A409M-88
ASTM A480/A480M-88
ASTM A774/A77M-88
ASTM A778-82
B. QUALIFICATIONS:
Heat-Resisting Chromium and Chromium Nickel
Stainless Steel Plate, Sheet, and Strip for Pressure
Vessels
Stainless and Heat-Resisting Steel Bars and Shapes
Seamless and Welded Austenitic Stainless Steel Pipes
Alloy Steel Bolting Materials for Low-Temperature
Service
Wrought Iron Austenitic Stainless Steel Piping Fittings
Welded Large Diameter Austenitic Steel Pipe for
Corrosive or High-Temperature Service
General Requirements for Flat-Rolled Stainless and
Heat-Resisting Steel Plate, Sheet, and Strip
As-Welded Wrought Austenitic Stainless Steel Fittings
for General Corrosive Service at Low and Moderate
Temperatures
Welded, Unannealed, Austenitic Stainless Steel Tubular
Products
All shop-fabricated stainless steel pipe and fittings shall be furnished by a single
manufacturer who is experienced and qualified in the manufacture and fabrication of
the items to be furnished. The pipe and fittings shall be shop-fabricated and field-
installed in accordance with common industry-wide practices and methods, and shall
comply with these specifications.
...
Only weld procedures which have been qualified under ASME Section IX and only
welders who have successfully completed performance qualification tests per ASME
Section IX on these qualified procedures shall be utilized.
C. TESTING:
Factory testing shall conform to the requirements of ASTM A312, ASTM A409 HO-O,
or ASTM A778, depending on the size and type of stainless steel pipe provided.
1.03 SUBMITTALS:
The following information shall be provided in accordance with Section 01800:
STAINLESS STEEL PIPING
15067-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1. Shop fabrication drawings showing details of materials, piping, fittings, couplings,
dielectric connections, joint locations and details, types and locations of supports.
2. Other data necessary to show conformance of the complete piping system to
these specifications.
PART 2 - PRODUCTS
2.01 PIPE:
Stainless steel pipe 2-1/2 inches and smaller shall be Type 316L, seamless, threaded
joints conforming to ASTM A312. The minimum wall thickness shall be Schedule 20S.
Unless otherwise specified, stainless steel piping 3 inches and larger shall be
manufactured from ASTM A240 annealed and pickled sheets and plates, Type 316L, in
accordance with ASTM A778 or ASTM A409 HT-O. Only extra-low carbon (ELC)
materials with .03 percent maximum carbon shall be used. Pipe shall be manufactured to
nominal pipe sizes as listed in ANSI B36.19, Table 2, and shall have the following
nominal wall thickness:
Nominal pipe
size, inches
Schedule
qauqe/plate
Wall thickness,
inches
3-8
1 0-12
14-18
20
24-36
42-48
54-60
Schedule 10S
12-gauge sheet
11-gauge sheet
10-gauge sheet
3/16-inch plate
1/4-inch plate
5/16-inch plate
0.105
0.120
0.135
0.188
0.250
0.312
...
2.02 FITTINGS:
Stainless steel fittings 2-1/2 inches and smaller shall be ASTM A403, of the same
material and pressure rating as the pipe, threaded long radius with dimensions
conforming to ANSI B16.11.
Unless otherwise specified, stainless steel fittings 3 inches and larger shall be butt-weld
type manufactured in accordance with ASTM A774 of the same material and in the same
thickness as the pipe. Long radius elbows up to 24 inches in diameter shall be smooth
flow. All short radius, special radius, and reducing elbows and long radius elbows greater
than 24 inches in diameter shall be of mitered construction. Reducers shall be straight
tapered, cone type. Tees, crosses, laterals, and wyes shall be shop-fabricated from pipe.
STAINLESS STEEL PIPING
15067 -3
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2.03 JOINTS:
Stainless steel pipe fabricated into spool pieces shall have shop-welded circumferential
butt-weld joints or flanges. Unless otherwise specified, flanged joints shall be
Van Stone joints madefup of stainless steel slip-on type, rolled-angle face rings and
ductile iron back-up flanges drilled to ANSI 16.1, Class 125 standard. The angle face
ring thickness shall be equal to or greater than the wall of the pipe for fitting to which it is
welded, and it shall be continuously welded on both sides to the pipe or fitting. the angle
leg shall not interfere with the flange bolt holes. For submerged joints, back-up flanges
shall be stainless steel plate flanges. The back-up flanges shall be supplied with the
following nominal thicknesses.
Nominal pipe,
size, inches
Flanged thickness,
inches
3
4
6-10
12-16
1/2
9/16
5/S
3/4
2.04 COUPLINGS:
A. GENERAL:
Fabricated stainless steel piping shall be shop-prepared for pipe couplings where
specified. Unless otherwise specified, couplings shall be arched-band or grooved
type.
B. SLEEVE TYPE:
Sle~ve type couplings, where specified, shall be of standard steel construction as
specified in Paragraph 15085-2.02 A. Pipe shall be plain-end with external weld
beads ground smooth to ensure proper gasket seating. For pressure pipe lines,
sleeve coupling joints shall be restrained by the use of harness rods connecting
l;lcross the joint to flange lugs on adjacent flange joints. Where no adjacent flange
"joints exist, stainless steel harness lugs shall be welded to the pipe to receive the
harness rods.
C. ARCHED-BAND TYPE:
Arched-band type couplings shall be stainless steel of the same material and wall
thickness as the pipe and shall be Depend-O-Look type as manufactured by Brioche,
or equal. Couplings shall be fixed--FxF, Expansion--ExE, or Fixed by Expansion--FxE
as specified or as required. The pipe shall be plain-end with external weld beads
STAINLESS STEEL PIPING
15067 -4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
ground smooth and with SS restraining rings shop-welded to the piping for fixed type
couplings.
D. GROOVED-END TYPE:
Grooved-end or split type couplings shall be malleable iron or ductile iron as specified
in Paragraph 15085-2.02 C., except that submerged couplings shall be the same
material as the pipe. The pipe ends shall be roll-grooved to the coupling
manufacturer's specifications. Where roll grooving is impractical, the pipe shall have
heavy-wall machine-grooved pipe nipples or machines ring collars fully welded to the
pipe or fitting. Nipples shall be taper-bored to the 1.0. of the adjoining pipe to allow
full-weld penetration. Collars shall be welded on both sides to the piping. Nipples
and collars shall be of the same alloy as the piping.
E. EXPANSION TYPE:
Unless otherwise specified, expansion couplings shall be the flanged rubber arch type
as specified in Section 15090. Pipe flanges shall be provided for these couplings.
2.05 THREADED CONNECTIONS:
Threaded pipe, gauge, or instrument connections shall be made using stainless steel,
150-pound, threaded half-couplings conforming to ASTM A 182 or ASTM A276, shop-
welded to the pipe at the location specified.
2.06 GASKETS:
Unless otherwise specified, gaskets shall be as specified in the PIPE SPECS and in
Paragraph 15085-2.03. For air lines, gaskets shall be neoprene or EPDM, suitable for
temperatures to 240 degrees F.
...
2.07 SOL TS:
Bolts, nuts, and washers for stainless steel flange assemblies and stainless steel
couplings shall be the same material, conforming to ASTM A320 for low-temperature
service and ASTM A 193 and ASTM A 194 for high-temperature service. Bolts, nuts, and
washers for other couplings shall be as specified in referenced paragraphs for the
couplings.
2.08 PIPE SUPPORT SYSTEMS:
Unless otherwise specified, all hangers, rods, structural attachments, and other
components of supports systems for stainless steel pipe shall be of the same materials
as the pipe and conform to Section 15096.
STAINLESS STEEL PIPING
15067 -5
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia
2.09 FINISH:
After all shop operations have been completed, pipe and fittings shall be pickled and
passivated in manufacturer's plant, and scrubbed and washed until discoloration an
possible iron picked up from the manufacturing process are removed. The standard
finish for 16-gauge through 8-gauge material shall be NO.1 or 2B per ASTM ~480; 3/16-
inch and heavier plate material shall be NO.1 mill finish or better per ASTM A480.
2.10 PRODUCT DATA:
The following information and data shall be provided:
1. Certifications specified in the following documents:
ASTM A403, paragraph 14.1
ASTM A774, paragraph 14.1
ASTM A778, paragraph 14.1
ASTM A409, paragraph 17.1
2. Test results specified in paragraph 15067-1.02 e.
3. Names and qualification records of proposed welders.
PART 3 - EXECUTION
3.01 PIPE CUTTING, THREADING, AND JOINTING:
Pipe cutting, threading, and jointing shall conform to the requirements of ANSI B31.1. All
pipe threads shall be lubricated with Teflon tape.
3.02 WELDING:
A. GENERAL:
Piping with wall thickness up to 11-gauge (0.120-inch) shall be welded with the TIG
(GTAW) process. Unless otherwise specified, heavier walls shall be properly beveled
and have a root pass with the TIG (GTAW) process followed by subsequent passes
with the TIG (GTAW) , MIG (GMAW), or Metallic Arc (SMAW) process. Filler wire of
ELC grades only shall be added to all welds to provide a cross section at the weld
equal to or greater than the parent metal. Weld deposit shall be smooth and evenly
distributed and have a crown of no more than 1/16-inch on the I.D. and 3/32-inch on
the 0.0. of the piping. Concavity, undercut, cracks, or crevices shall not be allowed.
Butt-welds shall have full penetration to the interior surface, and inert gas shielding
shall be provided to the interior and exterior of the joint. Excessive weld deposits,
STAINLESS STEEL PIPING
15067 -6
"1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
slag, spatter, and projections shall be removed by grinding. Welds on gasket
surfaces shall be ground smooth.
B. FIELD WELDING:
Field welding shall be minimized to the greatest extend possible by use of couplings
and prefabrication of pipe systems at the factory. Pipe butt-welds may be. performed
at the job site providing the butt-welds are performed only with an inert gas shielded
process and that other applicable specified welding requirements are rigidly adhered
to.
All residue, oxide, and heat stain is to be removed from any type of field weld and the
affected areas adjacent by the use of stainless steel wire brushes, followed by
cleaning with an agent such as Eutectic Company's "Eucleen," or equal, followed by
complete removal of the agent.
C. PREPARATION OF SURFACES TO BE WELDED:
Surfaces of joints to be welded shall be free from mill scale, slag, grease, oil, paint,
rust, and other foreign material. Joints to be welded shall be wire-brushed with
stainless steel wire brushes and precisely fitted before welding.
D. WEATHER CONDITIONS:
Welding shall be done only when the surfaces are completely free of any moisture.
Welding of the pipe shall not be done during periods of high winds or rain unless the
areas being welded are properly shielded.
E. TACK WELDS. CLIPS. AND OTHER ATTACHMENTS:
Nicks, gouges, notches, and depressions in the base metal in the area of the joint
...
shall be repaired before the joint weld is made. Tack welds, clips, and other
attachments shall be removed and defects repaired, except where the tack welds
occur within the weld area and these tack welds do not exceed the size of the
completed weld. Cracked tack welds shall be removed. Areas to be repaired shall be
ground to clean metal and then repaired by building up with weld metal. The repaired
areas shall be ground smooth to form a plane surface with the base metal.
F. DEFECTS AND REPAIRS:
Welds with cracks, slag inclusions, porosity, undercutting, incomplete penetration, or
which are otherwise deficient in quality or made contrary to any provisions of these
specifications shall be removed by chipping or grinding throughout their depth to clean
base metal. Caulking or peening of welds to correct defects shall not be done. Welds
found deficient in dimension but not in quality shall be enlarged by additional welding
STAINLESS STEEL PIPING
15067-7
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
after thoroughly cleaning the surface of previously deposited metal and the adjoining
plate. Weld deposits, slag, weld spatter, and projections into the interior of the pipe
shall be removed by grinding.
3.03 MARKING, SHIPPING, AND STORAGE:
All pipe, fittings, and fabrications shall be properly marked with type, gauge, and heat
number. All fabricated piping shall have openings plugged and flanges secured for
storage and/or transport after fabrication. all fabricated piping shall be piece-marked with
identifying numbers or codes which correspond to the contractor's layout and installation
drawings. The marks will be located on the spools at opposite ends and 180 degrees
apart. Pipe spools shall be loaded, blocked, and logged as necessary to ensure
protection from damage during shipping. Stainless steel pipe and fittings shall be stored
per manufacturer's recommendation. Dents, gouges, and scratches in stainless steel
pipe and fittings are not acceptable and are reason for rejecting pipe and fittings.
3.04 FABRICATION/INSTALLATION REQUIREMENTS:
The piping supplier during manufacturing, fabricating, and handling stages; and the
contractor during handling and installation stages shall use extreme care to avoid the
contact of any ferrous materials with the stainless steel piping. All saws, drills, files, wire
brushes, etc. shall be used for stainless steel piping only. Pipe storage and fabrication
racks shall be non-ferrous or stainless steel or rubber-lined. Nylon slings or straps shall
be used for handling stainless steel piping. Contact with ferrous items may cause rusting
of iron particles embedded in the piping walls. After installation, the contractor shall wash
and rinse all foreign matter from the piping surface. All welded joints shall be treated with
a pickling solution, brushed with stainless steel wire brushes and rinsed clean. If rusting
of embedded iron occurs, the contractor shall pickle the affected surface with Oakite
Deoxidizer SS, or equal, scrub with stainless steel brushes, and rinse clean.
3.05 COATINGS:
After installation, the contractor shall paint all steel or iron flanges, couplings, and
appurtenances in accordance with Section 09800. Painting of the stainless steel pipe is
not required; however, the contractor shall be responsible for supplying and installing the
stainless steel piping with a consistently clean surface. Identifying spool piece marks
shall be removed with paint thinner or solvents and the entire stainless steel surface shall
be washed with detergent and hot water and rinsed cleaned.
END OF SECTION 15067
STAINLESS STEEL PIPING
15067 -8
'1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 15075 - JOINT GASKETS
PART 1 - GENERAL
1.01 DESCRIPTION:
This section specifies rubber gaskets for push-on compression type joints used with
fabricated steel pipe, steel pipe, reinforced concrete pipe, concrete cylinder pipe, and
cement mortar lined and coated steel pipe.
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ASTM D395-85
Rubber Property--Compression Set, Test for
ASTM D412-87
Rubber Properties in Tension, Test for
ASTM D471-79
Rubber Property--Effect of Liquids, Test for
ASTM D573-81
Rubber--Deterioration in an Air Oven, Test for
ASTM 01149-86
Rubber Oeterioration--Surface Ozone Cracking in a
ehamber (Flat Specimens), Test for
~
ASTM D2240-86
Rubber Property--Durometer Hardness, Test for
B. TESTING:
Certified copies of test reports indicating that the gasket material has been tested and
that the results of the tests comply with the requirements specified in paragraph
15075-2.02 shall be provided as a submittal.
1.03 SUBMITTALS:
Provide test reports described above and manufacturer's catalog cut sheets per Section
01800.
JOINT GASKETS
15075-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
PART 2 - PRODUCTS
2.01 MATERIALS:
Gasket stock shall be.a synthetic rubber compound in which the elastomer is neoprene.
The compound shall contain no less than 50 percent by volume neoprene and shall be
free from factice, reclaimed rubber and other deleterious substances.
2.02 PHYSICAL REQUIREMENTS:
The compound shall meet the following physical requirements when tested in accordance
with the specified A TM standards.
A. TENSILE (ASTM D4121:
The tensile strength shall be 1500 psi minimum and the ultimate elongation shall be
350 percent minimum.
B. HARDNESS (ASTM D2240, TYPE A DUROMETER):
The compound shall have a hardness in the range of 35 to 50 for concrete spigots
and 50 to 65 for steel spigots.
C. COMPRESSION SET (ASTM D395):
The compression test shall not exceed 20 percent when compressed for 22 hours at
70 degrees c.
The te.st specimens shall be circular discs cut from the gaskets. Test specimens shall
be .0.500 (i: 0.005 - 0.025) inches in height. The diameter of the test specimen shall
be that of the gasket but not to exceed 1.129 i: 0.010 inches in diameter.
D. AGING (ASTM 0573):
The test specimen deterioration shall be less than 20 percent reduction in tensile
strength, 40 percent reduction ultimate elongation, and 15 points increase in
hardness.
E. EFFECT OF LIQUIDS (ASTM 0471):
The maximum volume change in oil and in water shall be as follows:
1. Oil: 100 percent in ASTM oil NO.3.
JOINT GASKETS
15075-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
2. Water: 15 percent.
The test specimens shall have a thickness of 0.080 :!= 0.005 inches and shall be
circular discs cut from the gasket.
F. OZONE CRACKING (ASTM D1149):
The test specimen shall be gasket loop mounted to give at lest 20 percent elongation.
There shall be no cracking visible at two times magnification of the gasket after 100
hours exposure to 1 mg/l ozone at 40 degrees C.
PART 3 - EXECUTION
The gaskets shall be installed in accordance with the manufacturer's recommendations. .
END OF SECTION 15075
~
JOINT GASKETS
15075-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 15085 - PIPING CONNECTIONS
PART 1 - GENERAL
1.01 DESCRIPTION:
This section specifies the following methods of connecting metallic piping: flanges,
threading, mechanical couplings, dielectric unions, and welding.
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section a/'ld those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ANSI 81.1-82
Unified Inch Screw Threads (UN and URN Thread
Form)
ANSI 81-20.1-83
Pipe Threads, General Purpose (Inch)
ANSI 816.1-75
Cast Iron Pipe Flanges and Flanged fittings Class 25,
125,250, and 800
ANSI 816.5-81
Pipe Flanges and Flanged Fittings
ANSI 818.2.1-81
Square and Hex 80lts and Screws Inch Series Including
Hex eap Screws and Lag Screws
ANSI B18.2.2-87
Square and Hex Nuts
ANSI B31.1-86
Power Piping
ANSI B31.3-84
Chemical Plant and Petroleum Refinery Piping
ASME Section IX (1986)
Boiler and Pressure Vessel Code; Welding and Brazing
Qualifications
PIPING CONNECTIONS
15085-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
ASTM A536-84
Ductile Iron Castings
A\!IMJA C111-85
Rubber-Gasket Joints for Ductile-Iron and Gray-Iron
Pressure Pipe and Fittings
A\!IMJA C206-82
Field Welding of Steel Water Pipe
A\!IMJA C207-86
Steel Pipe Flanges for Waterworks Service - Size 4 In.
through 144 In.
A\!IMJA C606-81
Grooved and Shouldered Type Joints
A\!IMJA M11-85
Steel Pipe--A Guide for Design and Installation
1.03 SUBMITTALS:
Provide manufacturer's catalog cut sheets per Section 01800.
PART 2 - PRODUCTS
2.01 FLANGED ASSEMBLIES:
A. FLANGES:
Cast iron flanges shall be faced in accordance with ANSI 816.1. Where companion
flanges are used, the flanges on pipe shall be refaced to be flush with the companion
flange face. Class 150 and Class 300 forged steel flanges shall be raised face
conforming to ANSI B16.5. Light weight slip-on flanges shall be plain face conforming
to A\!IMJA C207, Class B and ANSI 816.5. Unless otherwise specified, steel flanges
shall be ANSI B16.5, Class 150 or A\!IMJA C207, Class D. Plain faced flanges shall
not be bolted to raised face flanges.
B. GASKETS:
Gasket material shall be as specified in paragraph 15085-2.03.
Gaskets for plain faced flanges shall be the full face type. Thickness shall be 1/16-
inch for pipe 10 inches and less in diameter and 1/8-inch for pipe 12 inches and larger
in diameter. Unless otherwise specified, gaskets for raised face flanges shall match
the raised face and shall be 1 /16-inch thick for pipe 3-1/2 inches and less in diameter
and 1/8-inch thick for pipe 4 inches and larger.
PIPING CONNECTIONS
15085-2
I
I
I
I
I
I
I
I
I
I
I
I
I
,
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
C. BOLTS:
Flanged assembly bolts shall be ANSI B 18.2.1 standard square or hexagon head
carbon steel machine bolts with ANSI B 18.2.2 standard hot pressed hexagon nuts.
IhrE?9ds shall be ANSI B 1.1, standard coarse thread series; bolts shall be Class 2A,
nuts shall be class 2B. Bolt length shall conform to ANSI B16.5. Flange assembly
bolts and nuts for submerged or buried service shall be made of non-corrosive alloy
metal as specified in AVWVA C111, regardless of any other protective coating.
2.02 MECHANICAL COUPLINGS:
A. SLEEVE-TYPE COUPLINGS:
Unless otherwise specified, sleeve-type mechanical pipe couplings shall be Rockwell
Type 411, Dresser Style 38. or equal, with the stop removed fron I the middle ring.
Reducing couplings shall be Rockwell Type 415, Dresser Style 62, or equal. Sleeve-
type flanged coupling adapters shall be Rockwell Type 913. Dresser Style 128, or
equal. Insulating couplings shall be Rockwell Type 416, Dresser Style 39, or equal.
Bolts and nuts shall be made of non-corrosive alloy metal as specified in AVWVA
C111.
Gaskets shall be as specified in paragraph 15085-2.03 and AVWVA C111.
B. PLAIN END COUPLINGS:
Plain end pipe couplings for pipe sizes 6 inches and smaller shall be Gustin-Bacon
200, Victaulic Style 99, or equal for Schedule 80 pipe and Gustin-Bacon 205, Victaulic
Style 90, or equal for lighter weight pipe. Plain end couplings for pipe sizes 8 inches
and larger shall be Gustin-Bacon 200, Victaulic Style 99, or equal. Unless otherwise
specified, bolts and nuts shall comply with AWWA e606.
Gaskets shall be as specified in paragraph 15085-2.03 and AWVVA C606..
C. GROOVED END COUPLINGS:
Grooved end flexible-type couplings shall be Gustin-Bacon 100, Victaulic Style 77, or
equal. Grooved end rigid-type couplings shall be Gustin-Bacon 120 Rigi-Grip,
Victaulic Style 07 Zero-Flex, or equal. Flexible-type couplings shall be used for all
piping greater than 12 inches in diameter and for pipe 12 inches in diameter and less
in rack-mounted tunnel piping applications. All other applications for piping 12 inches
in diameter and less shall utilize rigid-type couplings. Grooved end flanged coupling
adapters shall be either Gustin-Bacon 154, Victaulic Style 741, or equal. Snap-joint
grooved end couplings shall be Gustin-Bacon 115, Victaulic Style 78, or equal. Cut
PIPING CONNECTIONS
15085-3
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
grooves are not permitted on fabricated or literal pipe. Unless otherwise specified,
bolts and nuts shall comply with A\JINIJA C606.
Gaskets shall be as specified in paragraph 15085-2.03 and A\JINIJA C606/
2.03 GASKETS:
Gaskets designated in Section 15050 shall be as follows:
1. EPDM: ethylene-propylene-diene-terpolymer.
2. Neoprene: neoprene.
3. Nitrile: nitrile (Buna N).
4. Neoprene, C.!.: neoprene with cloth insert.
5. Neoprene, oil resistant; neoprene with oil-resting characteristics.
6. TFE: non-creeping tetrafluorethylene (TFE) with insert filler.
7. Compressed gasketing consisting of organic fibers (Kevlar), fillers and styrene
butadiene rubber (S8R) binder.
8. TFE bonded EPDM: TFE bonded to EPDM in full-face gasket having concentric-
convex molded rings.
2.04 THREAD:
Pipe thread dimensions and size limits shall conform to ANSI 81.20.1.
. -
--
2.05 DIELECTRIC UNIONS:
Dielectric unions shall be EPCO, Capital, or equal.
2.06 ADAPTER FLANGES:
A. Adapter flanges for ductile iron or steel pipe shall be manufactured of high strength
ductile iron, ASTM A536, Grade 65-45-12. Flange dimensions and drilling shall be in
accordance with ANSI B 16.1, 125 pound patterns for cast iron, and/or ANSI B 16.5,
150 pound pattern for steel. Gaskets shall be BUNA-S (SBR) in accordance with
A\JINIJA C111and shall be included with the flange.
PIPING CONNECTIONS
15085-4
I
I
I
I
I
I
I
I'
I
I
I
I
I
I
I
I
I
I
.
.
-
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
B. Adapter flanges shall be UL Listed and FM Approved and shall be Megaflange Series
2100, as manufactured by EBAA Iron Sales, Inc., or approved equivalent.
2.07 COATINGS:
Unle.s_s qtherwjse specified, flange assemblies and mechanical sleeve type couplings for
buried installation shall be field coated as specified in Section 09800.
2.08 PRODUCT DATA:
The Contractor shall provide for each welder, a welder qualification certificate indicating
the welder is certified for pipe welding in accordance with ASME Boiler and Pressure
Vessel, Section IX. Each welder's certificate shall be provided to the Resident Project
Representative prior to that welder working on the job.
PART 3 - EXECUTION
3.01 INSTALLATION:
A. PIPE CUTTING. THREADING AND JOINTING:
Pipe cutting, threading and jointing shall conform to the requirements of ANSI 831.1.
B. PIPE WELDING:
Pipe shall be welded by ASME-certified welders using shielded metal arc, gas
shielded arc or submerged arc welding methods. Welds shall be made in accordance
with the requirements of ANSI 831.1 for Piping Systems 8, 26, and 28 specified in
Section 15050. Welds shall be made in accordance with the requirements of ANSI
831.2 for piping System 20 specified in Section 15050.
Welds for piping systems not specified above e shall be made in accordance with
AVWVA C206.
C. TAKEDOWN COUPLINGS:
Takedown couplings shall be screw unions, flanged or grooved end mechanical
coupling type joints and shall be provided as specified. Flanged or grooved end joints
shall be employed on pipelines 2-1/2 inches in diameter and larger. Where piping
passes through walls, takedown couplings shall be provided within 3 feet of the wall,
unless specified otherwise.
A union or flanged connection shall be provided within 2 feet of each threaded end
v'alve.
PIPING CONNECTIONS
15085-5
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
D. FLEXIBILITY:
Unless otherwise specified, piping 2 inches in diameter and larger passing from
concrete to earth shall be provided with pipe couplings or flexible joints as specified
With'2 feet of the structure. Steel and ductile iron pipe shall be provided with one such
coupling or joint; other pipe shall be provided with two such couplings or joints. .
Where required for resistance to pressure, mechanical couplings shall be restrained in
accordance with AVWVA M11, paragraph 13.10, Tables 13-6 and 13-7, and Figure 13-
17.
E. DIELECTRIC CONNECTIONS:
Where a copper pipe is connected to steel or cast iron pipe, and insulating section of
rubber or plastic pipe shall be provided. The insulating section !'>hall have a minimum
length of 12 pipe diameters. Dielectric unions as specified in paragraph 15085-2.05
may be used instead of the specified insulating sections. Where copper pipe is
supported from hangers, it shall be insulated from the hangers, or copper-plated
hangers shall be used.
END OF SECTION 15085
. .
...
PIPING CONNECTIONS
15085-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15090 - EXPANSION JOINTS AND FLEXIBLE METAL HOSE
PART 1 - GENERAL
1.01 DESCRIPTION:
This section specifies piping expansion joints and flexible metal hose.
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following document. It is a part of this section
as specified and modified. In case of conflict between the requirements of this section
and those of the listed document, the requirements of this section shall prevail.
Reference
Title
ASTM A276-84
Stainless and Heat-Resisting Steel Bars and Shapes
B. PERFORMANCE AND SERVICE CONDITIONS:
Expansion joints shall be suitable for pressure, temperature and service as specified
in Section 15050, without crimping of corrugations.
C. DESIGN REQUIREMENTS:
1. FLEXIBLE METAL HOSE: Live lengths for flexible metal hose shall be based
upon the service conditions listed under paragraphs 15090-1.02 A and B and a
design life of 1,000,000 full displacement cycles.
,;.
2: EXPANSION JOINTS: Corrugated type expansion joints shall be suitable for a
minimum of 10,000 pressure, temperature and deflection cycles.
1.03 SUBMITTALS:
The following information shall be provided in accordance with Section 01800:
1. Design and construction details of formed metal bellows type expansion joints.
2. Pressure thrust force and spring rate data for formed metal bellows expansion
joints.
EXPANSION JOINTS AND FLEXIBLE METAL HOSE
15090-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
3. Details for installation of all expansion joints.
PART 2 - PRODUCTS
2.01 EXPANSION JOINTS:
A. METAL CONSTRUCTION:
1. STEEL EXPANSION COMPENSATOR TYPE: Steel expansion compensator type
expansion joints shall be Flexonics Model H Expansion Compensator, Hyspan Series
8500, Keflex 70, or equal. Compensators shall have 2-ply stainless steel bellows and
carbon steel shroud and end fittings. Compensators shall be rated for 175 psi
maximum working pressure and 750 degrees F.
,
2. BRONZE EXPANSION COMPENSATOR TYPE: Bronze expansion compensator
type expansion joints shall be Flexonics Model HB Expansion Compensator, Hyspan
Series 8500, Keflex 70, or equal. Compensators shall have 2-ply phosphor bronze or
stainless steel bellows and copper tube end fittings. eompensators shall be rated for
150 psi maximum working pressure and 400 degrees F.
B. ELASTOMER AND FABRIC CONSTRUCTION:
1. GENERAL: Elastomer and fabric expansion joints shall be the standard spool
arch type or the precision molded spherical design type as indicated or specified.
Expansion joint connectors shall have control units (restraints) to prevent
excessive axial elongation and to accept the static pressure thrust in the piping
system. Number and sizes of control rods or restraints shall be as determined by
the manufacturer. Unless otherwise specified, single arch and sphere type
expansion joints shall have 6-inch face-to-face dimension for pipe up to 8 inches
. .:.and 8-inch face-to-face dimension for pipe 10 and 12 inches.
The cover elastomer shall be chlorobutyl, neoprene or EPDM. For temperatures
between 180 and 240 degrees F, the type elastomer shall be chlorobutyl or EPD.
Neoprene or Buna N liners are acceptable for temperatures to 180 degrees F.
2. SPOOL TYPE: spool type expansion joints shall be of the resilient arch type and
shall be standard or tapered as specified. Unless otherwise specified, all tapered
connectors shall be eccentric.
Spool type expansion joints shall be constructed of multiple plies of woven fabric
impregnated with elastomer and reinforced with steel rings or wire embedded in
.the body. Standard arch type expansion joints suitable for the specified
temperature and pressure shall be provided with retaining rings or backup rings.
EXPANSION JOINTS AND FLEXIBLE METAL HOSE
15090-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
'1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Retaining rings shall be 3/8-inch thick steel, split, either galvanized or zinc shield
coated. Expansion joints, single, multiple, or filled arch, shall be Mason Style
EJBN, Garlock Style 204, Mercer Style 500, Goodall Style E-1462, General Style
1025, or equal. Filled arch type shall be used on all piping systems carrying fluids
containing solids. High pressure couplings suitable for 240 degree F operation
_ !~mperatures shall be Mason Style EJBN-HD, Mercer Style 510, Garlock Style
. 204-HP, Goodall Style E-1489, General Style 1075, or equal.
3. SPHERICAL MOLDED TYPE: Spherical molded type expansion joints shall be
precision molded of multiple plys of nylon tire cord fabric and elastomer suitable for
specified temperature and pressure. Spherical molded type expansion joints shall
have steel of ductile iron floating flanges, and no metal parts shall come in contact
with the fluid. Single Sphere molded connectors shall be Mason Type MFNC,
Mercer Type 5500, Goodall Type E-611, General Type 1010, Garlock Style 8100,
or equal. Double sphere or triple sphere connectors shall be provided where
required to provide for the specified movement.
2.02 FLEXIBLE METAL HOSE:
A. GENERAL:
Flexible metal hose shall be corrugated type 321 stainless steel with stainless steel
fittings and shall be provided with stainless steel single braid, unless otherwise
specified. End connections shall be attached by the heliarc welding process using
stainless steel welding rod. Bronze flexible metal hose shall be provided for copper
and brass systems.
B. BRAIDED TYPE:
1. TYPE A: Type A braided flexible metal hose shall be Flexonics Series
401M/402M, Flexweld USFWSS-31/32, or equal.
, .
2. TYPE B: Type B braided flexible metal hose shall be Flexonics Series 301,
Flexweld USFWB-31, or equal.
PART 3 - EXECUTION
3.01 INSTALLATION:
Expansion joints and anchors shall be located as specified. Location and number of
guides shall be determined from standards of the Expansion Joint Manufacturer's
Association.
EXPANSION .JOINTS AND FLEXIBLE METAL HOSE
15090-3
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Expansion joints shall not be installed during times of temperature extreme or in a fully
compressed or fully expanded condition.
3.02 ALIGNMENT:
Pipirrg systems shall be aligned prior to installation of expansion joints. Expansion joints
shall not be used to correct piping misalignment during installations. Expansion joints
normally preset at the factory for rated axial compression and expansion shall be
installed in this preset condition.
3.03 EXPANSION JOINT AND CONNECTOR SCHEDULE:
Expansion joints and/or flexible metal hose connectors provided for specific equipment
items or piping systems are specified on the following schedule.
Type of expansion
joint/connector Type of service/use
Bronze expansion compensator eopper piping.
(2.01 A.3)
Elastometer spool arch Pump/blower connectors and
(2.01 B.2) expansion joints for piping 14-inch
diameter and larger.
Elastomer spherical molded Pump/blower connectors and
(2.01 B.3) expansion joints for piping 12-inch
diameter and less.*
. ... Bronze braded hose Air compressor discharge and pump
(2.02 B.2) connectors for copper lines.
*Excludes steam and chemical services.
END OF SECTION 15090
EXPANSION JOINTS AND FLEXIBLE METAL HOSE
15090-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15095 - PIPING APPURTENANCES
PART 1 - GENERAL
1.01 DESCRIPTION:
This'seClion specifies pipeline thermometers, flow and level gages, pressure gages,
strainers, steam traps, vents and drains.
1.02 SUBMITTALS:
Manufacturer's catalog cut sheets shall be provided in accordance with Section 01800.
PART 2 - PRODUCTS
2.01 PIPELINE THERMOMETERS:
A. GENERAL:
The operating temperature range for pipeline thermometers shall be suitable for the
temperature range specified in Section 15050. Pipeline thermometers shall indicate
fluid temperatures within the pipeline to an accuracy of plus or minus 2 percent of
thermometer full scale.
Pipeline thermometers shall be provided with threaded thermowell mountings,
designed to permit removal of the thermometer without depressurization or loss of
process fluid. For insulated pipes a thermowell with a lagging extension shall be
provided.
B. BIMETALLIC THERMOMETERS:
Bimetallic type thermometers shall be of the adjustable angle type mounted for
convenient viewing. Bimetallic thermometers shall have type 304 stainless steel.
case. Thermometer dials shall be a minimum of 5 inches in diameter and shall be
equipped with an external adjustment mechanism for zero reset. Bimetallic
thermometers shall be Ashcroft, Type EH, Marsh Mastertherm, or equal.
A. FILLED THERMOMETERS:
Filled type thermometers shall have minimum scale length of 9 inches and shall be of
the adjustable angle type mounted for convenient viewing. Filled thermometers shall
consist of a type 304 stainless steel frame and a mercury-filled pyrex tube. The
thermometer tube shall be recessed into the frame. Filled thermometers shall be
Princo, Ametek, or equal.
PIPING APPURTENANCES
15095-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia
2.02 FLOW AND LEVEL GAGES:
A. ROTAMETERS:
Unless otherwise specified, rotameters for purges and other low capacity services
shaH-be Brooks Sho-Rate "50," Wallace & Tiernan 3-inch purge meter, Schutte-
Koerting, or equal, with integral needle valve and flow controller. Meter tubes shall be
glass, floats shall be stainless steel, and cases shall be aluminum or stainless steel.
Units shall have a 3-inch minimum scale.
Rotameters for high capacity service shall be glass tube-type with a 5-inch scale and
stainless steel frame. Flow range shall be as specified and scales shall indicate the
units of flow. Rotameters shall be as manufactured by Brooks, Wallace & Tiernan,
Schutte & Koerting, or equal.
B. SIGHT GAGES:
Sight gages shall be 3/4-inch Penberthy 205 Series, Lunkenheimer Fig. 589, or equal,
automatic water gage complete with pyrex gage glass and gage glass protector.
Overall length of gages, type of mounting, and orientation of set shall be as specified.
C. FLOW INDICATORS:
Flow indicators shall be provided where specified. Each indicator shall consist of a
bronze body with threaded ends and a sight glass with rotary wheel. pressure ratings
for flow indicators shall match pipe pressure ratings. Indicators shall be as
manufactured by Jacoby-Tarbox, Schutte & Koerting, Eugene Ernst Products, or
equal.
2.03 PRESSURE DEVICES:
A. . GAGE COCKS:
Gage cocks shall be Robershaw 1303, Ashcroft 1095, or equal. The exposed threads
of each gage cock shall be protected by a brass plug.
B. PRESSURE SENSORS:
Pressure sensors (tubular chemical seals) are specified in Division 13.
PIPING APPURTENANCES
15095-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
.1
'1
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
2.04 STRAINERS:
A. AIR AND GAS STRAINERS:
Air and gas line strainers shall be V-pattern, cast iron body, with 40 mesh Monel
sCreens packed with Everdur wool. Air line strainers shall be fitted with a brass
blowoff cock. Strainers shall be Leslie, or equal.
B. STEAM AND WATER STRAINERS:
Steam and water strainers shall be of V-pattern, unless otherwise specified. Steam
strainers shall have carbon steel body; water strainers shall have cast iron body.
Strainers shall have 304 stainless steel screens and tapped and plugged blowoff
connections. Screen perforations shall be 0.020 inch for steam service and 0.045
inch for water service. Strainers shall be Leslie Cu., Charles M. Bailey Co., or equal.
PART 3 - EXECUTION
3.01 APPLICATION:
A. PIPELINE THERMOMETERS:
Bimetallic thermometers shall be provided at the inlet and outlet of each process
stream at each heat exchanger and boiler.
Thermometers for sludge service shall be provided at elbows with the process sensor
oriented in the direction of sludge flow.
Filled thermometers shall be provided at process inlet and outlet connections for engines
and chillers where required within 20 feet of any pump and adjacent to process tapes
fortemperature sensing instrumentation.
B. GAGE TAPS:
Gage taps shall be provided on the suction and discharge of pumps, fans,
compressors, vacuum pumps and blowers. Gage taps shall consist of a 1/4-inch
gage cock attached by a threaded nipple to the pipeline, duct or equipment.
C. VENTS AND DRAINS:
Manual air vents shall be provided at the high points of each reach of pipeline where
specified. Air vents shall consist of bronze cock and copper tubing return. Air vents
shall be taken to the nearest floor with cock mounted 4 feet above the floor. Vents in
PIPING APPURTENANCES
15095-3
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
piping systems for fluids containing solids shall be 1-inch non-lubricated eccentric
plug valves fitted with quick couplers.
Drains shall be piped to a sump, gutter, floor drain or other collection point with a
valve mounted 4 feet above the floor. Drain valves shall be threaded end gate valves
of the size specified. When drains cannot be run to collection points, they shall be
routed to a point of easy access and shall have hose gate valves of the size specified.
END OF SECTION 15095
PIPING APPURTENANCES
15095-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 15096 - PIPE HANGERS AND SUPPORTS
PART 1 - GENERAL
1.01 DESCRIPTION:
A. SCOPE:
This section specifies hangers and supports for all piping systems specified in Section
15050.
B. OPERATING CONDITIONS:
The hangers and supports specified in this section are provided to resist pipe loads
occurring primarily in the downward (gravity) direction. For the purpose of pipe
, hanger and support selection, this section establishes pipe support classifications
based on the operating temperatures of the piping contents. Pipe support
classifications are as follows:
1. Hot Systems:
A - 1. 120 to 450 degrees F
A - 2. 451 to 750 degrees F
A - 3. Over 750 degrees F
2. Ambient Systems:
B. 60 to 119 degrees F
3. Cold Systems:
..:;
e - 1 . 33 to 59 deg rees F
C - 2. -20 to 32 degrees F
C. HANGER SUPPORT SELECTION:
The Contractor shall select pipe hangers and supports as specified in the project
manual. Selections shall be based upon the pipe support classifications specified in
this section, the piping insulation thickness specified in Section 15250, and any
special requirements which may be specified in the project manual.
The Contractor shall review the piping layout in relation to the surrounding structure
and adjacent piping and equipment before selecting the type of support to be used at
each hanger point.
PIPE HANGERS AND SUPPORTS
15096-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Hangers and supports shall withstand all static and specified dynamic conditions of
loading to which the piping and associated equipment may be subjected. As a
minimum, consideration should be given to the following conditions:
1: Weights of pipe, valves, fittings, insulating materials, suspended hanger
components, and normal fluid contents.
2. Weight of hydrostatic test fluid or cleaning fluid if normal operating fluid contents
are lighter.
3. Reaction forces due to the operation of safety or relief valves.
4. Wind, snow or ice loadings on outdoor piping.
Hangers and supports shall be sized to fit the outside diameter of pipe, tubing, or,
where specified, the outside diameter of insulation.
Where negligible movement occurs at hanger locations, rod hangers should be used
for suspended lines, wherever practical. For piping supported from below, bases,
brackets or structural cross members should be used.
Hangers for the suspension of size 2-1/2 inches and larger pipe and tubing shall be
capable of vertical hanger component adjustment under load.
The supporting systems shall provide for and control the free or intended movement
of the piping including its movement in relation to that of connected equipment.
Where there is horizontal movement at a suspended type hanger location, hanger
components shall be selected to allow for swing. The vertical angle of the hanger rod
snelll not, at any time, exceed 4 degrees.
There shall be no contact between a pipe and hanger or support component of
dissimilar metals. Prevent contact between dissimilar metals when supporting copper
tubing by use of copper-plated, rubber, plastic or vinyl coated, or stainless steel
hanger and support components.
Unless otherwise specified, existing pipes and supports shall not be used to support
new piping.
Unless otherwise specified, pipe support components shall not be attached to
pressure vessels.
Stock hanger and support components shall be used wherever practical.
PIPE HANGERS AND SUPPORTS
15096-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
1.02 REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
sec.tLon_~md those of the listed documents, the requirements of this section shall prevail.
Reference
Title
AISC M011-80
Manual of Steel Construction Sth Edition
MSS SP-58
Pipe hangers and Supports Materials, Design and
Manufacture
MSS SP-69
Pipe Hangers and Supports Selection and Application
FEDSPEC
VVW-H-171e-78
Hangers and Supports, Pipe
MFMA-1-84
Metal Framing Standards Publication
1.03 SUBMITTALS:
Hanger and support locations and components shall be indicated on the piping layout
drawings required by paragraph 15050-2.04.
PART 2 - PRODUCTS
2.01 ACCEPTABLE PRODUCTS:
Stand~rd pipe supports and component shall be manufactured by B-Line, earpenter &
Patterson, Kin-Line, ITT Grinnell, Michigan, Pipe Shields Incorporated, Superstrut,
Unistrut, or equal. Pipe support components shall conform to the requirements of MSS
SP-69 and FEDSPEC WW-H-171e. Pipe support mat~r.ials shall conform to the
requirements of MSS SP-5S.
2.02 MATERIALS:
A. GENERAL:
Unless otherwise specified, hangers and supports shall be hot-dip or mechanically
galvanized after fabrication. Nuts, bolts and washers may be zinc-plated except for
those subject to moisture or corrosive atmosphere, as specified in paragraph 16000-
1.05 B, which shall be type 304 stainless steel.
PIPE HANGERS AND SUPPORTS
15096-3
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
B. PIPE HANGERS AND SUPPORTS:
1. TYPE 1 CLEVIS PIPE HANGER: Clevis hangers shall be carbon steel with
configuration and components equivalent to MSS and FEDSPEC Type 1.
a. Steel pipe (insulated) shall be B-Line B3100, Grinnell Fig. 260, or equal, with
insulation shield.
b. Steel pipe (uninsulated) shall be 8-Line B3100, Grinnell Fig. 260, or equal.
c. Cast and ductile iron pipe shall be B-line B3102, Grinnell Fig. 590, or equal.
d. Copper pipe (uninsulated) shall be B-Line 83104 CT, Grinnell fig. CT-65, or
equal.
e. Copper pipe (insulated) shall be B-line B3100, Grinnell Fig. 260, or equal,
with insulation shield.
2. TYPE 2__"J" PIPE HANGER: Hangers shall be carbon steel with configuration and
components equivalent to MSS type 5. This hanger shall be used only on
uninsulated pipe.
a. Steel pipe shall be B-Line 83690, Michigan model 418, or equal.
b. Copper and plastic pipe shall be Michigan model 419, Unistrut J 1205N
series, or equal.
3. TYPE 3--DOUBLE BOLT PIPE CLAMP: Pipe clamp shall be carbon steel, with
configuration and components equivalent to MSS and FEDSPEC Type. 3.
a. Steel pipe (insulated) shall be 8-Line B3144, Grinnell Fig. 295, or equal, with
insulation shield. Insulation shield is optional for hot and ambienfsystems.
b. Steel pipe (uninsulated) shall be B-Line B3144, Grinnell Fig. 295, or equal.
c. Copper pipe (insulated only) shall be B-Line B3144, Grinnell Fig. 295, or equal,
with insulation shield.
4. TYPE 4--ADJUSTABLE ROLLER HANGER: Rollers shall be cast iron, yoke and
cross bolt shall be carbon steel. Configuration and components shall be
equivalent to MSS Type 43 and FEDSPEC Type 44.
PIPE HANGERS AND SUPPORTS
15096-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
a. Steel pipe (insulated) shall be B-Line B3110, Grinnell Fig. 181, or equal, with
insulation shield.
b. Steel pipe (uninsulated) shall be B-Line B311 0, Grinnell Fig. 181, or equal.
G,_ Cgpper pipe (insulated only) shall be B-;Line B31110, Grinnell Fig. 181, or equal,
with insulation shield.
5. TYPE 5--SINGLE PIPE ROLL: Rollers and sockets shall be cast iron, cross rod
shall be steel. Configuration and components shall be equivalent to MSS Type 41
and FEDSPEC Type 42.
a. Steel pipe (insulated) shall be B-Line B3114, Grinnell Fig. 171, or equal, with
insulation shield.
b. Steel pipe (uninsulated) shall be'B-Line B3114, Grinnell Fig. 171, or equal.
6. TYPE 6--FRAMING CHANNEL PIPE CLAMP: Pipe clamps shall be steel with
galvanized finish and material thickness as listed below:
a. Steel pipe (uninsulated) pipe size 3/8-inch and 1/2-inch shall be 16 gage; 3/4-inch
through 1-1/4 inches shall be 14 gage; 1-1/2 inches through 3 inches shall be
12 gage; 3-1/2 inches through 5 inches shall be 11 gage; 6 and 8 inches shall
be 10 gage; Michigan model 431, Unistrut P 1109 series, or equal.
b. Steel pipe (insulated pipe clamp shall be as described in paragraph 15096-2.02
A.6.a with insulation shield.
c. Copper pipe (uninsulated) and plastic pipe size 318-inch and 1 inch shall be 16
gage; 1-1/4 inches and 1-1/2 inches shall be 14 gage; 2 inches through 3
;. inches shall be 12 gage; 4 inches shall be 11 gage; clamp shall be copper-
plated, plastic coated or lined with dielectric material; Michigan model 432,
Unistrut P 2024C and P202PC series, or equal.
d. Copper pipe (insulated) pipe clamp shall be as described in paragraph 16096-2.02
A.6.a with insulation shield.
7. TYPE 7--U-BOLT: U-bolts shall be carbon steel with configuration equivalent to
MSS and FEDSPEC Type 24.
a. Steel pipe (uninsulated) shall be Grinnell Fig. 137, B-Line B3188, or equal.
b. Steel pipe (insulated) shall be Grinnell Fig. 137, B-Line B3188, or equal, with
insulation shield.
PIPE HANGERS AND SUPPORTS
15096-5
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
c. Cast ductile iron pipe shall be Grinnell Fig. 137, B-Line B3188, or equal.
d. Copper pipe (uninsulated) shall be Carpenter & Patterson Fig. 222 CT, B-
Line B3501 CT, or equal.
e. Copper pipe (insulated) shall be Grinnell Fig. 137, B-Line B3188, or equal,
with insulation shield.
8. TYPE 8--ADJUSTABLE PIPE ROLL SUPPORT: Rollers and sockets shall be cast
iron, cross rod and support rods shall be carbon steel. Configuration and
components shall be equivalent to MSS Type 46 and FEDSPEC Type 47.
a. Steel pipe (insulated) shall be B-Line B3122, Grinnell Fig. 177, or equal, with
insulation shield.
b. Steel pipe (uninsulated) shall be B-Line B3122, Grinnell Fig. 177, or equal.
c. eopper pipe (insulated only) shall be B-Line B3122, Grinnell Fig. 177, or
equal, with insulation shield.
9. TYPE 9 --WELDED PIPE STANCHION: Minimum material thickness shall be
standard schedule carbon steel pipe, cut to match contour of the pipe elbow. Use
of this support shall be limited to ambient systems only.
10.TYPE 10--PIPE STANCHION SADDLE: Saddles and yokes shall be carbon steel
and comply with MSS Type 37 and FEDSPEC Type 38.
a. Steel pipe (insulated) shall be Carpenter & Patterson Fig. 125, B-Line B3090, or
equal, with insulation shield.
b. Steel pipe (uninsulated) shall be Carpenter & Patterson Fig. 125, B-Line B3090, or
equal.
c. Cast and ductile iron pipe shall be Carpenter & Patterson Fig. 125, B-Line B3090
NS, or equal.
d. Copper pipe (uninsulated) shall be Carpenter & Patterson Fig. 125, B-Line B3090,
or equal, with insulation shield or lined with dielectric material.
e. Copper pipe (insulated) shall be Carpenter & Patterson Fig. 125, B-Line B3090, or
equal, with insulation shield.
PIPE HANGERS AND SUPPORTS
15096-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia.
11. TYPE 11--0FFSET PIPE CLAMP: Pipe clamp shall be carbon steel with
configuration and components as specified and shall be of standard design
manufactured by a pipe hanger component manufacturer.
a. Steel pipe (insulated) shall be B-Line B3148, Grinnell Fig. 103, or equal, with
insulation shield.
b. Steel pipe (uninsulated) shall be B-Line B3148, Grinnell Fig. 103, or equal.
c. Cast and ductile iron pipe shall be B-Line B3148 NS, Grinnell Fig. 103, or equal.
d. Copper pipe (uninsulated) shall be B-Line B3148, Grinnell Fig. 103, or equal, with
insulation shield.
e. Copper pipe (insulated) shall be B-Line B3148, Grinnell Fig. 103, or equal, lined
with dielectric material.
Vertical pipe support applications shall be as specified above except that insulation
shields shall not be used for insulated pipe.
12.TYPE 12-RISER CLAMP: Riser clamp shall be carbon steel with configuration and
components as specified equivalent to MSS and FEDSPEC Type 8.
a. Steel pipe (insulated) shall be B-Line 83373, Grinnell Fig. 261 t or equal.
b. Steel pipe (uninsulated) shall be B-Line 83373, Grinnell Fig. 261, or equal.
c. Cast and ductile iron pipe shall be 8-Line 83373, Grinnell Fig. 261, or equal.
d. Copper pipe (insulated) shall be 8-Line 83373 CT, Michigan model 511, or equal.
e. Copper pipe (uninsulated) shall be 8-Line B3373, Michigan model 511, or equal.
13. TYPE 13--FRAMING CHANNEL PIPE STRAP: Pipe strap shall be carbon steel, with
configuration equivalent to MSS Type 26.
a. Steel pipe (uninsulated) shall be Superstrut No. C-708-U, Kin-Line No. 477, or
equal.
b. Steel pipe (insulated) shall be Superstrut No. C-708-U, Kin-Line No. 477, or equal,
with insulation shield.
c. Copper pipe (uninsulated) shall be Superstrut No. C-708-U, Kin-Line No. 477, or
equal, with insulation shield or lined with dielectric material.
PIPE HANGERS AND SUPPORTS
15096-7
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
d. Copper pipe (insulated) shall be Superstrut No. C-708-U, Kin-Line No. 477, or
equal, with insulation shield.
C. RACK AND TRAPEZE SUPPORTS:
1. GENERAL: Unless otherwise specified, trapeze and pipe rack components shall
have a minimum steel thickness of 12 gate, with a maximum deflection 1/240 of
the span.
2. TYPE 20--TRAPEZE PIPE SUPPORT: Trapeze pipe support cross members
shall be 1-5/8 inch square carbon steel framing channel. Single 'channel cross
members shall be Unistrut P1 000, Superstrut A-1200, or equal. Double channel
cross members shall be Unistrut P1 001, Superstrut A-1202, or equal. Flat plate
fittings shall bE' 1-58 inch square carbon steel of standard design manufactured by
framing channel manufacturer, Unistrut p2471, Superstrut AB-241, or equal.
D. TYPE A MALLEABLE IRON CONCRETE INSERT:
1. TYPE A MALLEABLE IRON CONCRETE INSERT: Concrete inserts shall be
malleable iron and comply with MSS and FEDSPEC Type 18. Grinnell Fig. 282,
earpenter & Patterson Fig. 108, or equal.
2. TYPE B SIDE BEAM BRACKET: Bracket shall be malleable iron and comply with
MSS type 34 FEDSPEC Type 35. Grinnell Fig. 202, B-Line B3062, or equal.
3. TYPE C MALLEABLE BEAM CLAMP WITH EXTENSION PIECE: Clamp and
extension piece shall be malleable iron, tie rod shall be steel. Beam clamp shall
comply with MSS and FEDSPEC Type 30. Grinnell Fig. 229, B-Line B3054, or
equal.
p .
...
4. TYPE D STEEL BEAM CLAMP WITH EYE NUT: Beam clamp and eye nut shall
be forged steel. Configuration and components shall comply with MSS and
FEDSPEC Type 28. Grinnell Fig. 292, Carpenter & Patterson Fig. 297, or equal.
5. TYPE E FRAMING CHANNEL POST BASE: Post bases shall be carbon steel, of
standard design manufactured by framing channel manufacturer. Unistrut P 1887,
Kin-Line No. 237, or equal.
6. TYPE F WELDED BEAM ATTACHMENT: Beam attachment shall be carbon steel
and comply with MSS and FEDSPEC Type 22. B-Line B3083, Grinnell Fig. 66, or
equal.
PIPE HANGERS AND SUPPORTS
15096-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
7. TYPE G WELDED STEEL BRACKET: Bracket shall be carbon steel and comply
with MSS Type 32 and FEDSPEC Type 33 for medium welded bracket. Heavy
welded bracket shall comply with MSS Type 33 and FEDSPEC Type 34.
S. TYPE H CAST IRON BRACKET: Bracket shall be cast iron, Grinnell Fig. 213,
'_ C?rpenter & Patterson Fig. 340, or equal.
9. TYPE J ADJUSTABLE BEAM ATTACHMENT: Beam attachment shall be carbon
steel, Carpenter & Patterson Fig. 151, B-Line B30S2, or equal.
10. TYPE K DOUBLE CHANNEL BRACKET: Wall channel shall be carbon steel 1-5/8
inch square framing channel, Unistrut P1000, Superstrut A-1200, or equal.
Cantilever bracket shall be a carbon steel double framing channel assembly,
Unistrut P2542 through P2546, Superstrut S-251, or equal.
11.TYPE L SINGLE CHANNEL BRACKET: Wall channel shall be ca,'bon steeI1-5/S
inch square framing channel, Unistrut P1000, Superstrut A-1200, or equal.
Cantilever bracket shall be a carbon steel single framing channel assembly,
Superstrut S-250, Kin-Line No. 322, or equal.
12.TYPE M WALL MOUNTED CHANNEL: Wall channel shall be carbon steel 1-5/8
inch square framing channel, Unistrut p1 000, Superstrut A-1200, or equal.
13. TYPE N PIPE STANCHION FLOOR ATTACHMENT: Baseplate shall be carbon
steel with 1/2-inch minimum thickness. Anchor bolt holes shall be 1/16-inch larger
than the anchor bolt diameter. The space between the baseplate and the floor
shall be filled with non-shrink grout.
E. ACCESSORIES:
1. .j.-iANGER RODS: Rods shall be carbon steel, threaded on both ends of
-
continuous threaded and sized as specified.
2. WELDLESS EYE NUT: Eye nut shall be forged steel and shall comply with MSS
and FEDSPEC Type 17. Eye nut shall be Grinnell Fig. 290, B-Line B3200, or
equal.
3. WELDED EYE ROD: Eye rod shall be carbon steel with eye welded closed.
Inside diameter or eye shall accommodate a bolt diameter 1/S-inch larger than the
rod diameter. Eye rod shall be Grinnell Fig. 27S, B-Line B3211, or equal.
4. TURNBUCKLE: Turnbuckle shall be forged steel and shall comply with MSS and
FEDSPEC Type 15. Turnbuckle shall be Grinnell fig. 230, B-Line B3202, or equal.
PIPE HANGERS AND SUPPORTS
15096-9
PIPE HANGERS AND SUPPORTS
15096-10
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
5. FRAMING CHANNEL: Framing channel shall conform to the Metal Framing
Manufacturers Association Standard MFMA-1. Framing channel shall be 1-5/8
inches square, roll formed, 12-gage carbon steel. Channel shall have a
continuous slot along one side with inturned clamping ridges. Framing channel
shall be Unistrut P-1000 series, Superstrut A-1200 series, or equal.
2.03 THERMAL PIPE HANGER SHIELD:
Thermal shields shall be provided at hanger, support and guide locations on pipe
requiring insulation. The shield shall consist of an insulation layer encircling the entire
circumference of the pipe and a steel jacket encircling the insulation layer. The thermal
shield shall be the same thickness as the piping system insulation specified in Section
15250. The standard shield shall be used for hot systems and the vapor barrier shield
shall be used for cold systems. Stainless steel band clamps shall be used where
specified to ensure against slippage between the pipe wall and the thermal shield.
A. STANDARD SHIELD:
1. INSULATION:
a. Hydrous calcium silicate, high density, waterproof.
b. Compressive strength: 100 psi average.
c. Flexural strength: 75 psi average.
d. K factor: 0.38 at 100 degrees F mean.
e. Temperature range: 20 to 500 degrees F.
2. STEEL JACKET: Galvanized steel. Gage shall be the manufacturer's standard
supplied for the given pipe size.
3. Shield shall have butt connection to pipe insulation. Steel jacket and insulation
. ..shall be flush with end.
B. VAPOR BARRIER SHIELD:
1. INSULATION:
a. Hydrous calcium silicate, high density, waterproof.
b. Compressive strength: 100 psi average.
c. Flexural strength: 75 psi average.
d. K factor: 0.38 at 100 degrees F mean.
e. Temperature range: 20 to 500 degrees F.
2. STEEL JACKET: Galvanized steel. Gage shall be the manufacturer's standard
supplied for the given pipe size.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
3. Shield shall have butt connection to pipe insulation. Insulation shall extend 1 inch
each side of steel jacket for vaportight connection to pipe insulation vapor barrier.
PART 3 - EXECUTION
3.01 HANGER AND SUPPORT LOCATIONS:
The Contractor shall locate hangers and supports as near as possible to concentrated
loads such as valves, flanges, etc. Locate hangers, supports and accessories within the
maximum span lengths specified in the project manual to support continuous pipeline
runs unaffected by concentrated loads.
At least one hanger or support shall be located within 2 feet from a pipe change in
direction.
The Contractor shall locate hangers and supports to ensure that connections to
equipment, tanks, etc., are substantially free from loads transmitted by the piping.
Where piping is connected to equipment, a valve, piping assembly, etc., that will require
removal for maintenance, the piping shall be supported in such a manner that temporary
supports shall not be necessary for this procedure.
Pipe shall not have pockets formed in the span due to sagging of the pipe between
supports caused by the weight of the pipe, medium in the pipe, insulation, valves and
fittings.
3.02 TESTING:
Welded and bolted attachments to the building structural steel shall be in accordance
with t~ requirements of AISe M011. Unless otherwise specified, there shall be no
drilling or burning of holes in the building structural steel.
Hanger components shall not be used for purposed other than for which they were
designed. They shall not be used for rigging and erection purposes.
The Contractor shall install items to be embedded before concrete is poured. Fasten
embedded items securely to prevent movement when concrete is poured.
Embedded anchor bolts shall be used instead of concrete inserts for support installations
in areas below water surface or normally subject to submerging.
The Contractor shall install thermal pipe hanger shields on insulated piping at required
locations during hanger and support installation. Butt joint connections to pipe insulation
PIPE HANGERS AND SUPPORTS
15096-11
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
shall be made at the time of insulation installation in accordance with the manufacturer's
recommendations.
Hanger and support components in contact with plastic pipe shall be free of burrs and
sharp edges.
Rollers shall roll freely without binding.
Finished floor beneath Type N structural attachments and framing channel post bases
shall be roughed prior to grouting. Grout between base plate and floor shall be free of
voids and foreign material.
Baseplates shall be cut and drilled to specified dimensions prior to welding stanchions or
other attachments and prior to setting anchor bolts.
Plastic or rubber end caps shall be provided at the exposed ends of all framing channels
that are located up to 7 feet above the floor.
3.03 ADJUSTMENTS:
The Contractor shall adjust hangers and supports to obtain required pipe slope and
elevation. Shims made of material that is compatible with the piping material may be
used. Stanchions shall be adjusted prior to grouting their baseplates.
END OF SECTION 15096
PIPE HANGERS AND SUPPORTS
15096-12
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15101 - GATE VALVES
PART 1 - GENERAL
1.01 DESCRIPTION:
This section specifies bronze and iron-body, solid-wedge gate valves. Iron body valves
shall be bronze mounted.
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ANSI 816.1-75
Cast Iron Pipe Flanges and Flanged Fittings Class 25,
125, 250 and 800
ASTM A 126-84
Gray Iron Castings for Valves, Flanges, and Pipe
Fittings
AWNA C500-86
Gate Valves for Water and Sewerage Systems
AWNA C509-87
Resilient Seated Gate Valves for Water and Sewerage
Service
..;
B. DESIGN CRITERIA:
Gate valves 3 inches through 48 inches in size shall comply with AVWVA C500,
including applicable hydrostatic testing. Gate valves smaller than 3 inches shall be
subject to hydrostatic tests at the test pressure.
1.03 SUBMITTALS:
The following information shall be provided in accordance with Section 01800:
1. Affidavits of compliance, as required by AVVWA C500.
2. -Hydrostatic test results.
GATE VALVES
15101-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
3. Manufacturer's catalog cut sheets.
PART 2 - PRODUCTS
2.01 CONSTRUCTION:
A. Gate Valves (2-1/2 Inches and Smaller) designed for a working pressure of not less
than 125 psi. Bronze, rising stem, double disc, parallel seat, screwed bonnet type.
1. Available Manufacturers: Subject to compliance with requirements, manufacturers
offering gate valves which may be incorporated in the work include, but are not limited
to, the following:
a. Carne No. 440
b. Nibco No. T-111-2
c. Approved equal
B. Gate Valves (3 Inches and Larger) shall be double disc, parallel seat type with non-
rising stem, conforming to AWVVA C500.
Unless otherwise indicated or specified. Gate valves shall be designed for a working
pressure of not less than 150 pounds.
Valves shall take full test pressure on either face. Valves shall be from not more than
two manufacturers and similar sizes shall be identical and parts interchangeable.
They shall be constructed with bolted bonnets provided with stuffing boxes having
bolted followers. The stuffing boxes shall be easily accessible and shall be packed
ready for use.
Rubbing surfaces and surfaces in contact during the seating operations, including
wedge, wedge seats, thrust ring seats, top and bottom stem guide bearing surfaces,
packing gland surfaces and contact seats provided for packing under pressure, shall
be all bronze bushed or bronze faced.
Stems shall be cast forged or rolled bronze conforming to AWVVA C500. Cast stems
shall be Grade IV Bronze. Bronze for forged and rolled stems shall be Grade III.
Valves 6 inches and larger, when installed on sewage or sludge lines, shall be
provided with suitable c1eanouts or approved type in near the base of the body for
removal of sediment.
C. Resilient-Seated Gate Valves (3 Inches throuqh 12 Inches) shall conform to AWVVA
C509 with non-rising stem.
GATE VALVES
15101-2
I
I
I
I
I
I
I
I
I
I
I
I
I
,
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I'
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Unless otherwise indicated or specified, gate valves shall be designed for a working
pressure of not less than 150 psig.
Valves shall take full pressure on either face. Valves shall be from one manufacturer
aQd sjmilar sizes shall be identical and parts interchangeable. They shall be
constructed with bolted bonnets provided with two O-ring stem seals which can be
replaced with the valve under pressure in the full-open position.
All internal and external surfaces shall be coated with epoxy to a minimum thickness
of 8 mils.
Valve seats shall be coated with a rubber material conforming to AVWVA C509 so that
there shall be no rubber to metal contact when the valve is in the fully closed position.
1. Available Manufacturers: Subject to compliance with requirements, manufacturers
offering resilient seated gate valves which may be incorporated in the work include,
but are not limited to, the following:
a. American
b. Waterous
c. Approved Equal
2.02 MISCELLANEOUS:
A. END CONNECTIONS:
Gate valve end connections shall be flanged or threaded as specified. Threaded
ends shall not be provided on gate valves with end connections larger than 4 inches.
End flanges shall be integral with the gate valve body and be faced and drilled in
accordance with ANSI 816.1 for 125-pound flanges.
B. MANUAL OPERATORS:
Unless specified otherwise, valves less than 12 inch size shall be provided with
handwheels, and valves 12 inches and larger shall be provided with geared operators.
END OF SECTION 15101
GATE VALVES
151 01-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15103 - BUTTERFLY VALVES
PART 1 - GENERAL
1.01 DESCRIPTION:
A. StOPE:
This section specifies butterfly valves for air, gas and water service.
B. TYPES:
1. TYPE A: Valves used in the following piping systems for sizes 3 inches and larger
shall be designed Type A. Where 2-1/2 inch valves are specified, substitute Type B.
Pipinq Systems
8, 11
2. TYPE B: Valves used in the following piping systems shall be designated Type B:
Piping System
9,7
3. TYPE C: (Not used.)
4. TYPE D: (Not Used)
1.02 QUALITY ASSURANCE:
..;.
A. REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ANSI 816.1-75
Cast Iron Pipe flanges and Flanged Fittings Class 25,
125, 250 and SOO
ANSI B16.5-81
Pipe Flanges and Flanged Fittings ASTM A4S-83 Gray
BUTTERFLY VALVES
15103-1
F& V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Iron Castings
ASTM A 1 OS-S1
Steel Bars, Carbon, Cold-Finished, Standard Quality
ASTM A 126-S4
Gray Iron Castings for Valves, Flanges, and Pipe
Fittings
ASTM A216/A216M-84
Steel Castings, Carbon, Suitable for Fusion Welding, for
High Temperature Service
ASTM A276-84
Stainless and Heat-Resisting Steel Bars and Shapes
ASTM A436-S4
Austenitic Gray Iron Castings
ASTM A536-S4
Ductile Iron Castings
AWWA C504-S0
Rubber-Seated Butterfly Valves
1.03 SUBMITTALS:
The following information shall be provided per Section 01S00:
1. Manufacturer's catalog cut sheets.
2. Affidavits of compliance with AWWA C504 for Type A valves.
PART 2 - PRODUCTS
2.01 MATERIALS:
A. TYI?E A:
Type A valves are specified according to size as follows.
1. TYPE A, SIZE 3 THROUGH 24 INCHES: Type A valves from 3 through 24 inches
in size shall be constructed of the following materials:
Component
Material
Shaft
Stainless steel, ASTM A276, type 304 or 316
Carbon steel, ASTM A 1 OS, with stainless steel
journals
BUTTERFLY VALVES
15103-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Disc
Cast iron, ASTM A436, type 1 (Ni-Resist), or
Gate
Cast iron, ASTM 48, Class 40 with Ni-Chrome or
stainless steel edge
Seat sealing surface
Neoprene or Buna
Body
Cast iron, ASTM A126, Class B or ASTM A48, Class
40
B. TYPE B:
Type B valves shall be constructed of the following materials:
Component
Material
Shaft
Stainless steel, ASTM A582, type 416
Disc
Cast iron, ASTM A126, Class B
Seat sealing surface
Neoprene or Buna N--air and gas services
. Nordel--(high temp water)
Body
Cast iron, ASTM A126, Class B
Disc Edge
Nickel
C. TYPE C:
;.
(Not used.)
D. TYPE D:
(Not Used)
2.02 MANUFACTURE:
A. GENERAL:
Valves shall be the stub or through shaft design. Wafer type valves are not
acceptable for buried service. Unless otherwise specified, valve flange drilling shall
be per ANSI B16.1, Class 125.
BUTTERFLY VALVES
15103-3
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. TYPE A:
Type A valves shall be designed in accordance with AVVWA C504. Shafts shall be
turned, ground and polished. Shaft dimensions and operator torque shall be chosen
for tne pressure specified in Section 15050 and Class B as specified in AVWVA C504.
When carbon steel shafts and stainless steel journals are used, static seals shall be
provided to isolate the interior of the disc and the shaft from the process fluid.
Type A valves, size 3 through 72 inches, shall have seats that are vulcanized,
bonded, mechanically secured, or clamped to the body or disc.
C. TYPE B:
Valves shall be rated at 175 psig and provide driptight shutoff up to the full valve
rating on dead-end or isolation service. Seat shall be mechanically held in place and
shall be field replaceable. Valve ends shall be as specified in Section 15050.
Type B valves, size 2 through 20 inches, shall have seats that are bonded to a rigid
reinforcing ring.
D. TYPE C (SIZE 2 THROUGH 20 INCHES:
(Not used.)
E. TYPE D:
(Not Used)
2.03 MANUAL OPERATORS:
A. GENERAL:
Manual operators shall be designed in accordance with AVWVA C504 and shall have
a disc position indicator designating the opened and closed position of the valve.
B. TYPE A:
Manual operators for Type A valves shall be of the traveling nut, rack and pinion, or
worm gear type. Operators shall be equipped with adjustable mechanical stop-
limiting devices to prevent overtravel of the disc in the open and closed positions and
shall be self-locking and designed to hold the valve in any intermediate position
BUTTERFLY VALVES
15103-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
between full open and full closed. Valve operator component shall withstand an input
torque of ft-Ibs at the extreme operator positions without damage.
Operator for buried service shall include an AWWA operating nut and shall be
gasketed and grease packed for submerged operation at water pressure to 10 psig.
Qper?tors for exposed service shall include a handwheel and be gasketed for
weatherproof service.
C. TYPE B, C AND D:
Operators for Type B, Type C, and Type D valves 6 inches in diameter and smaller
shall be latch lock levers. Valves shall be capable of being locked in at least five
intermediate positions between fully open and fully closed.
Operators for Type B and Type C valves 8 inches in diameter and larger shall be the
traveling nut or worm gear type. Operators for exr:osed service shall be gasketed for
weatherproof service. A handwheel or chain wheel shall be provided for each
operator as required in Section 15185.
PART 3 - EXECUTION
Valves shall be installed in accordance with the manufacturer's recommendations.
END OF SECTION 15103
.:.
BUTIERFL Y VALVES
15103-5
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15110 - ECCENTRIC PLUG VALVES
PART 1 - DESCRIPTION
This section specifies eccentric plug valves.
1.02 REF"E~RENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall prevail.
Reference
Title
ANSI .B 16.1-89
Cast Iron Pipe Flanges and Flanged Fittings Class 25,
125,250 and 800
ASTM A 126-84
Gray Iron Castings for Valves, Flanges, and Pipe
Fittings
ASTM A536-84
Ductile Iron Castings
AWWA C504-87
Rubber-Seated Butterfly Valves
1.03 SUBMITTALS:
The following information shall be provided in accordance with Section 01800:
1. Manufacturer's product data.
PART 2 - PRODueTS
2.01 MATERIALS:
Materials of construction shall be as follows:
Component
Material
Body
Cast iron, ASTM A126, Class B
Plug
Cast iron, ASTM A126, class B, or cast iron ASTM
A436 (Ni-resist), or ductile iron, ASTM A536
Plug facing
Neoprene or Buna-N
ECCENTRIC PLUG VALVES
1511 0-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Body seats
Less than 3 inches
3 inches and larger
Cast iron, ASTM A126, Class B
Stainless steel, ASTM A276, Type 304 or nickel
PaCking
Buna V-flex or TFE
2.02 MANUFACTURE:
A. GENERAL:
Valves shall be straight-flow non-lubricated resilient plug type suitable for driptight, bi-
directional shutoff at the specified valve design pressure. Port areas for the valve
shall be at least 80 percent of the adjacent full pipe area nd shall be capable of
passing solids 55 percent of pipe size. Valve hody seats consisting of nickel for
valves 3 inches and larger shall be constructed of a welded-in overlay of not less than
90 percent pure nickel. Upper and lower journal hearings shall be replaceable,
sleeve-type, corrosion resistant, and permanently lubricated. Packing shall be self-
adjusting chevron type replaceable without disassembling the valve.
Unless otherwise specified, valves shall, as a minimum, conform to the following
pressure ratings:
Size. inches
Design pressure. psig
12 and smaller
175
B. END CONNECTIONS:
Valves 3 inches and smaller shall have threaded ends. Valve flange drilling for valves
larger than 3 inches shall be per ANSI B 16.1, Class 125. Grooved-end valves may be
provided with grooved-end piping systems.
C. MANUAL OPERATORS:
Unless otherwise specified, valves 4 inches and smaller shall be provided with a leer
type manual operator. Valves larger than 4 inches shall be provided with totally
enclosed worm gear operators. Where specified, manual operators shall have an
adjustable stop. All operator components shall be sized for the valve design pressure
in accordance with AVWVA C504, Section 3.8. Operators shall comply with applicable
portions of Section 15184.
ECCENTRIC PLUG VALVES
15110-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
D. Available Manufacturers: Subject to compliance with requirements, manufacturers
offering products which may be incorporated in the work include, but are not limited to,
the following:
1. Dezurik, Sartell, MN.
2. Approved Equal
PART 3 - EXECUTION
Unless otherwise specified, valves shall be provided with the seat downstream away from
flow. Valves at tank connections shall be installed with seat away from tank. Valves on
pump discharge lines shall be installed with seat adjacent to the pump.
END OF SECTION 15110
ECCENTRIC PLUG VALVES
1511 0-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15116 - SYNTHETIC SWING DISC CHECK VALVES
PART 1 - GENERAL
1.01 DESCRIPTION:
'. -
This section specifies synthetic swing disc check valves.
.., .1.02 SUBMITTALS:
Manufacturer's catalog information including dimensions, cross-sectional views, details of
construction and materials list shall be provided in accordance with Section 01800.
PART 2 - PRODUCTS
2.01 ACCEPTABLE PRODUCTS:
Check valves shall be Valmatic Swing Flex Series 500 or equal.
2.02 MATERIALS:
Materials of construction shall be as follows:
Component
Material
Body, cover
ASTM A 126, Class B Cast Iron
Disc
ASTM D2000-BG, Buna N (NBR)
~
2.03 MANUFAeTURE:
Valve design shall be full flow opening equal to the nominal pipe diameter at any point
through the valve. The seating surface shall be on a 45 degree angle. The top access
port shall allow removal of the disc without removing the valve body from the pipeline.
The disc shall be precision molded with an integral O-ring type sealing surface and
contain steel and nylon reinforcements. The disc shall be designed for non-slam closing.
The interior of the valve shall be coated with an epoxy coating.
The flanged end connections shall be ANS1 816.1, Class 125.
SYNTHETIC SWING DISC CHECK VALVES
15116-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Unless otherwise specified, valves shall be, as a minimum, conform to the following
pressure ratings:
Size, inches
Workinq Pressure psiq
2 through 12
14 through 24
200
150
PART 3 - EXECUTION
Check valves shall be installed in accordance with the manufacturer's recommendations.
END OF SECTION 15116
SYNTHETIC SWING DISC CHECK VALVES
15116-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 15118 - SPRING-LOADED SWING CHECK VALVES
PART 1 - GENERAL
1.01 DESCRIPTION:
-- '-
This section specifies spring-loaded swing check valves.
1.02 REFERENCES:
A. REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ASTM A 126-84
Gray Iron Castings for Valves, Flanges, and Pipe
Fittings
ASTM A276-84
Stainless and Heat-Resisting Steel Bars and Shapes
ASTM C508-82
Swing-Check Valves for Waterworks Service, 2 In.
through 24 In. NPS
1.03 SUBMITTALS:
Manufacturer's catalog information including dimensions, cross-sectional views, details of
construction and materials list shall be provided in accordance with Section 01800.
-- --
PART 2 - PRODUCTS
2.01 ACCEPTABLE PRODUCTS:
Check valves shall be Golden Anderson Fig. 230-0 with outside lever and spring, APCO
Series 6000 CLS, or equal.
2.02 MATERIALS:
Materials of construction shall be as follows:
-. -
SPRING-LOADED SWING CHECK VALVES
1 511 8-1
SPRING-LOADED SWING CHECK VALVES
15118-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Component
Material
Body, cover
Cast iron, ASTM A 126, Class B
--DiSc
Cast iron, ASTM A 126, Class B
Seat rings
Bronze, AVWVA C508
Hinge shafts and
hinge pins
Stainless steel, ASTM A276, Type 304
Shaft bushings
Bronze, AVWVA C508
2.03 MANUFACTURE:
Disc, disc arm, shaft, keyways, lever and spring shall be capable of closing within .05
seconds of pump stoppage and fluid moving at velocity of 8 feet per second. Spring
tension shall be adjustable. The valve design shall permit mounting levers and springs
on either slide of the valve body.
Valves shall be provided with a clear opening equal to or greater than the connecting
piping, with no raised seating surface. Seats shall be threaded onto the body or fitted
with an O-ring seal and locked in place with stainless steel screws or pins an shall be
replaceable. Shafts shall be provided with stuffing box and packing or O-ring seals at
each end which are externally replaceable.
Unless otherwise specified, valves shall be, as a minimum, conform to the following
pressure ratings:
Size, inches
Workinq Pressure
~
Hydrostatic test
pressure, psiq
_ -to-
..
2 through 12
14 through 30
175
150
350
300
PART 3 - EXECUTION
Spring loaded swing check valves shall be installed in accordance with the
manufacturer's recommendations.
END OF SECTION 15118
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
I
I
I
.. ---
I
I
I
I
I
I
I
I
I
~
- --
I
I
I
I
I
SPRING-LOADED SWING CHECK VALVES
15118-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatf\lent Plant
Augusta-Richmond County, Georgia
SECTION 15150 - SPECIALTY VALVES
PART 1 - GENERAL
1.01 DESCRIPTION:
- <-
This section specifies specialty valves which are auxiliary to process piping systems.
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following document. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed document, the requirements of this section shall
prevail.
Reference
Title
ASTM A 126-84
Gray Iron Castings for Valves, Flanges, and Pipe
Fittings
1.03 SUBMITTALS:
Provide manufacturer's catalog cut sheets per Section 01800.
PART 2 - PRODUCTS
2.01 RELIEF VALVES:
Pr~Uf~ and vacuum relief valves shall be of the weight loaded type. The pressure limit
shall be as specified. Valves shall be anodized aluminum body and trim with Buna-N or
neoprene seats. Valves shall be Varec 2010-51 series, Oceco V130 Series, or equal.
2.02 SAFETY VALVES:
Safety valves for air shall be ASME certified, Lunkenheimer Figure 1226 or 1227, Crane
2550 or 2551, or equal. Size and pressure settings shall be as specified or as required
for the service intended. Safety and pressure relief valves for cold and hot water shall be
Crane 2606, McDonnell and Miller 230, or equal.
2.03 AIR RELEASE VALVES:
SPECIALTY VALVES
15150-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Air release valves shall be float operated, simple lever type. Valves shall be suitable for
pressures up to 150 psi. Body and cover shall be cast iron, float shall be type 316
stainless steel, seat shall be synthetic rubber, and other internal parts shall be type 316
stainless steel. Valves shall be APCO Model 200A, Crispin P10, or equal.
2.04 FL~Hll\JG COCKS:
Flushing cocks shall consist or a DeZurik 159/118-S, Homestead 1112, or equal,
neoprene-faced eccentric plug valve with a hose nipple adapter if required. Unless
specified otherwise, flushing cocks shall be 1-inch in diameter.
2.05 QUICK DISCONNECTS:
Quick disconnects shall not be disconnectable under pressure. Quick disconnects for air
service shall be Swagelok, Milton Quick-Change, or equal, and shall be 1/2-inch, unless
otherwise specified. Quick disconnects for water service shall be EverTite Part B, Gate
Part B, or equal, and shall be 1-inch, unless specified otherwise.
PART 3 - EXEeUTION
Specialty valves shall be installed in accordance with the manufacturer's
recommendations.
END OF SECTION 15150
~-~
SPECIALTY VALVES
15150-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15153 - PRESSURE REGULATING VALVES
PART 1 - GENERAL
1.01 DESCRIPTION:
.. ~
This section specifies direct acting and pilot controlled pressure regulating valves for air,
water and gas service.
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following document. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed document, the requirements of thi::i section shall
prevail.
Reference
Title
ANSI 816.5-88
Pipe Flanges and Flanged Fittings
B. PERFORMANCE:
Direct acting type pressure regulating valves shall control the discharge pressure
within i. 5 percent of set pressure. Pilot controlled type pressure regulating valves
shall maintain the set discharge pressure regardless of fluctuations in inlet pressure.
C. TESTING:
JjYct9static tests shall be conducted by the manufacture for one valve of each type
supplied for a particular service. Steel-bodied valves shall be hydrostatically tested in
accordance with the requirements of ANSI B 16.5. aluminum-, bronze-, and brass:"
bodied valves shall be hydrostatically tested at double the MAX pressure specified.
Leakage, sweating or visible deformation at any point on the valve shall be cause for
rejection of valves of that type and manufacture.
1.03 SUBMITTALS:
The following information shall be provided in accordance with Section 01800:
1. Manufacturer's product data.
2. Hydrostatic test results.
~ -
PRESSURE REGULATING VALVES
15153-1
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1.04 RELATED WORK
A. Pressure regulators for digester gas are specified in Section 11815.
PART 2 - PRODUCTS
.. .,-"
2.01 ACCEPTABLE PRODUCTS:
A. GENERAL:
Pressure regulating valves shall be flanged or threaded connections as specified.
Moving parts requiring lubrication shall have means provided for lubrication and shall
be lubricated prior to delivery. All pressure regulating valves shall be equipped with
pressure gauges on the regulated side of the valve.
B. WATER SERVICE:
Valves less than 1-1/4 inches shall be direct acting, spring-operated type. Valves less
than 1-1/4 inches shall be Bailey 30A, eash-Acme E-41 Series 3, Watts 223, or equal,
with separate Y-pattern strainer.
Valves 1-1/4 inches and larger shall be pilot-controlled type, unless otherwise
specified. Valves 1-1/4 inches and larger shall be Cia-Val Co. Clayton 90-01 Series,
Bailey 400, Watts/Muesco 115, or equal.
C. AIR SERVICE:
Valves for air service shall be Bailey 30A, Cash-Acme E-41 Series, Watts 152A, or
equal, with separate Y -pattern strainer.
D:-(sA~ SERVICE:
Valves for gas service shall conform to all AGA regulations and criteria. Valves shall
be sized as recommended by the manufacturer for the intended use. Pressure
regulating valves for gas shall be Fisher, Kieley and Mueller, or equal.
PART 3 - EXECUTION
Pressure regulating valves shall be installed in accordance with the manufacturer's
recommendations. Regulators shall be installed such that the pressure gauge is visible
by the operator.
~ -
END OF SECTION 15153
PRESSURE REGULATING VALVES
15153-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia.
SECTION 15180 - CONTROL VALVE SCHEDULE
PART 1 - GENERAL
. 1.01 DESCRIPTION:
... '"--
This section is a schedule of the control valves for this work.
1.02 VALVE SIZING:
Where specific valve is smaller than the connected pipe, the Contractor shall provide
reducers.
1.03 SCHEDULE:
Operator Type Service Type Definition
EMTT Throttling Electric motor multi-turn
EOTT Throttling Electric motor quarter-turn
EMTI Isolating Electric Motor multi-turn
EOTI Isolating Electric motor quarter-turn
pel Isolating Pneumatic cylinder
POI Isolating Pneumatic diaphragm
CONTROL VALVE SCHEDULE
Control Valve Open/Close
valve size, Operator Failure NEMA time,
number Services inches type position* enclosure seconds
e-vlW1 TRS 6 pel Fe 7 30-60
CV7202 OS 10 PCI FC 7 30-60
CV7203 TWAS 6 PCI FC 7 30-60
CV7301 TRS 6 PCI FC 7 30-60
CV7302 DS 10 PCI FC 7 30-60
CV7303 TWAS 6 PCI FC 7 30-60
CV7401 TRS 6 PCI FC 7 30-60
CV7402 DS 10 PCI FC 7 30-60
CV7403 TWAS 6 PCI FC 7 30-60
... -
CV7501 TRS 6 PCI FC 7 30-60
CONTROL VALVE SCHEDULE
15180-1
F& V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Control Valve Open/Close
valve size, Operator Failure NEMA time,
number Services inches type position* enclosure seconds
CV7502 OS 10 PCI FC 7 30-60
C'\1.7 5"0 3 TWAS 6 PCI FC .- 7 30-60
CV7601 TRS 6 PCI FC 7 30-60
CV7602 OS 10 PCI FC 7 30-60
CV7801 TRS 6 PCI FC 7 30-60
CV7802 OS 10 PCI FC 7 30-60
CV7803 OS 10 PCI FC 7 30-60
*FLP = fail last position
FC = fail closed
FO = fail open
NC = normally closed
NO = normally open
END OF SECTION 15180
.- --
~
CONTROL VALVE SCHEDULE
15180-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15184 - MANUAL VALVE & GATE OPERATORS & OPERATOR APPURTENANCE
PART 1 - GENERAL
1.01 DESCRIPTION:
- -" ,
This section specifies manual operators for valves and gates, and operator
appurtenances.
1.02 REFERENCES:
This section contains references to the following document. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed document, the requirements of this section shall prevail.
Reference
Title
AWWA C500-86
Gate Valves 3 through 48 inch NPS, for Water
and Sewage Systems
1.03 SUBMITTALS:
The following information shall be provided in accordance with Section 01800:
1. Manufacturer's catalog information and other data confirming conformance to
design and material requirements.
PART 2 - PRODUCTS
2.01 ACCEPTABLE PRODUCTS:
~
Excepfas specified in valve and gate specification sections, manual operators shall be
as specified herein. Operators shall be mounted on the valve or gate and provided as a
unit. Each valve body or operator shall have cast thereon the word "OPEN," an arrow
indicating the direction to open, and flow direction arrows.
2.02 OPERATORS:
A. GENERAL:
Manual operators shall have operating torques less than 800 foot-pounds. Unless
specified otherwise, each manual operator shall be provided with an operating wheel.
Unless specified otherwise, the direction of rotation of the operator shall be
cCll.mterclockwise for opening.
MANUAL VALVE & GATE OPERATORS & OPERATOR APPURTENANCES
15184-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. WRENCH NUTS:
Wrench nuts shall comply with Section 3.16 of AWWA C500. A minimum of two
Ot:>ernting keys, but no less than one key per every ten valves, shall be provided for
operation of the wrench nut operated valves.
C. CHAIN WHEELS:
Chain wheels shall be ductile iron. Operating chains shall be galvanized.
2.03 OPERATOR APPURTENANCES:
A. VALVE BOXES:
Valve boxes shall be cast iron and shall have suitable base castings to fit properly
over the bonnets of their respective valves and heavy top sections with stay-put
covers. Covers shall be not-dip galvanized.
B. FLOOR BOXES:
Floor boxes shall be hot-dip galvanized. Where the operating nut is in the concrete
slab, the floor box shall be bronze bushed. Where the operating nut is below slab, the
opening in the bottom of the box shall be sufficient for passage of the operating key.
C. ADJUSTABLE SHAFT VALVE BOXES:
Adjustable shaft valve boxes shall be concrete or cast iron Brooks No. 3RT, Christie
G5, Empire 7-1/2 valve extension box, or equal. Box covers on water lines shall be
~pressed with the letter "W.n Gas line covers shall be impressed with the letter "G."
PART 3 - EXECUTION
3.01 GENERAL:
Installation shall be as specified herein. Valve operators shall be located so that they are
readily accessible for operation and maintenance. Valve operators shall be mounted for
unobstructed access, but mounting shall not obstruct walkways. Valve operators shall
not be mounted where shock or vibration will impair their operation. Support systems
shall not be attached to handrails, process piping, or mechanical equipment.
-.. -
MANUAL VALVE & GATE OPERATORS & OPERATOR APPURTENANCES
15184-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
3.02 OPERATORS:
A. GENERAL:
Valves and gates shall be provided with manual operators, unless specified
Qth~rwise. Where possible, manual operators shall be located between 48 inches
and 60 inches above the floor or a permanent work platform. .
B. WRENCH NUTS:
Wrench nuts shall be provided on buried valves, on valves which are to be operated
through floor boxes, and where specified. Extended wrench nuts shall be provided if
necessary so that the nut will be within 6 inches of the valve box cover.
C. CHAIN WHEELS: Unless otherwise specified, valves with centerlines more than 7
feet, 6 inches above the ~pecified operating level shall be provided with chain wheels
and operating chains. Chain wheel operated valves shall be provided with a chain
guide. Operating chains shall be looped to extend within 4 feet of the specified
operating level below the valve. For plug-type valves 8 inches and larger, the
operator shall be provided with a hammer blow wheel. Hooks shall be provided for
chain storage where the chain may hang in a walkway.
3.03 OPERATOR APPURTENANCES:
A. VALVE BOXES:
Valve boxes extending to finished surfaces shall be provided for buried valves.
B. FLOOR BOXES:
~Io~ boxes shall be provided for wrench operation of valves located below concrete
slabs. Each floor box and cover shall be of the depth required for installation in the
slab.
END OF SECTION 15184
~ -
MANUAL VALVE & GATE OPERATORS & OPERATOR APPURTENANCES
15184-3
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 15186 - PNEUMATIC VALVE & GATE OPERATORS & OPERATOR
APPURTENANCE
PART 1 - GENERAL
1.01 DESCRIPTION:
-- '-
A. SCOPE:
This section specifies pneumatic operators for valves and gates, and operator
appurtenances.
1.02 REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall prevail.
Reference
Title
ASTM A519-89
Seamless Carbon and Alloy Steel Mechanical
Tubing
Copper Alloy Sand Castings for General
Applications
Pneumatic Standards for Industrial Equipment
and General Purpose Machine Tools
Industrial Control Devices, Controllers and
Assemblies
ASTM 8584-89
JIC P-1-1975
NEMA ICS-2-88
1.03 SUBMITTALS:
Th8'rollO'wing information shall be provided in accordance with Section 01800:
1. Control wiring diagrams for operators marked to show specific changes necessary
. for the supplied equipment. If no changes are required, the drawing shall be
marked "no changes required."
2. A copy of this specification section with addenda updates, and all referenced
sections with addenda updates, with each paragraph check marked to show
specification compliance or marked to show deviations.
3. Manufacturer's catalog information and other data confirming conformance to
design and material requirements.
PNEUMATIC VALVE & GATE OPERATORS & OPERATOR APPURTENANCE
15186-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
PART 2 - PRODUCTS
2.01 GENERAL:
Operators shall be factory-mounted on the valve or gate and provided as a unit. Each
valveb0ay or operator shall have cast thereon the word "0PEN,n an arrow indicating the
direction to open, and flow direction arrows.
2.02 PNEUMATIC OPERATORS:
A. GENERAL:
Operators shall be sized to produce an operating torque equal to twice the maximum
required valve operating torque under the specified flow conditions.
B. PNEUMATIC CYLINDER OPERATORS:
1. GENERAL: Unless otherwise specified, pneumatic cylinder operators shall be
provided in accordance with the operator specification sheets and the following
requirements.
2. MECHANISM: Operators shall be spring-return unless otherwise specified in
Section 15180. Unless otherwise specified, operators shall be double-piston, rack-
and-pinion type and shall provide a 90-degree rotation of the output shaft. Operators
shall be totally enclosed, with no external moving parts, except for the output shaft
which shall be accessible for manual operation of the valve. Searing surfaces,
including the inside cylinderwall and guides, shall be coated with a permanent, dry-
film lubricant and corrosion inhibitor. Cylinder and end caps shall be made of
precision extruded, hard-anodized aluminum. Pistons shall be made of hand-anodized
aluminum alloy and the output shaft and pinion shall be hardened. and tempered alloy
-s1eE!t Operators shall be suitable for operating in temperatures ranging from -20 to
+160 degrees F. Piston seals shall be O-ring type. Operators shall be suitable for
use with non-lubricated dry instrument quality air at up to 120 psig. Operators shall
have internal porting with no external piping.
Heavy-duty, totally enclosed scotch-yoke type mechanisms, where specified, shall
comply with applicable portions of the specification for double-piston type actuators
and shall be suitable for use with non-lubricated dry instrument quality air. Cylinder
shall be steel, ASTM A519, Grade 1018; piston shall be gray iron; bearings shall be
bronze, ASTM B584, Grade 88-10-2; and seals shall be lip- or cup-type of duro-nitrile
elastomer. Steel cylinder rod shall be electroplated with nickel.
-Scotch-yoke type mechanism may also be provided when the double-piston type is
unable to comply with the requirements of paragraph 15185-2.02 A.
PNEUMATIC VALVE & GATE OPERATORS & OPERATOR APPURTENANCE
15186-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No,9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
3. MOUNTING: The operator output shaft shall attach directly to the valve stem with
no intermediate linkages. Operators shall be suitable for operation in any valve
mounting attitude and either parallel or perpendicular to the pipe line.
2.03 OPEJilAIOR APPURTENANCES:
A. TUBING:
Unless otherwise specified, tubing furnished with powered operators shall ASTM
A296-TP316, 0.035 in. wall, 316 stainless steel.
B. TUBE FITTINGS:
Unless otherwise specified, tube fittings furnished with powered operators shall be
316 stainless steel compression fittings, Swagelok, Parker or equal.
C. AIR PRESSURE FILTER REGULATORS:
A supply air filter regulator with a gage shall be provided with each pilot solenoid
valve. Filter regulators shall have aluminum bodies and a second tapped output gage
connection. Filter regulators shall be provided with an output pressure gage and
range spring appropriate for the intended application. The output pressure gage shall
be a minimum of 2 inches in diameter and shall have an accuracy of plus or minus 2
percent of scale, or better. The filter element shall be 40 micron, replaceable and
shall be made of resin-impregnated cellulose. The filter dripwell shall be equipped
with a drain cock. Filter regulators shall be adjustable over the spring range by
means of a wrench-adjustable set screw. The set screw shall be equipped with a lock
nut. Filter regulators shall be equipped with an internal relief valve to maintain the
output pressure at set point during periods of no flow. Filter regulators shall be Fisher
~p~67FR, or equal.
D. PILOT SOLENOID VALVES:
Operators shall be provided with a factory-mounted and piped pilot solenoid valve.
Unless otherwise specified, supply air tubing shall be 3/8-inch. Pilot solenoid valves
shall be direct-acting, three-way with 1/4-inch NPTF ports. Unless otherwise
specified, solenoid valves shall be designed to seal the pressurized (supply port and
exhaust the operator when deenergized. Valves shall have combination NEMA 7C,
7D, and 4 enclosures. Coils shall be fully encapsulated, shall have Class H
insulation, and shall be rated for continuous duty at 120 volts ac. Pilot solenoid valves
shall be CSA certified and UL listed.
PNEUMATIC VALVE & GATE OPERATORS & OPERATOR APPURTENANCE
15186-3
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Solenoid valves shall be Automatic Switch Company, Series 8320, or equal, modified
as necessary to provide the specified features.
E. POSITION SWITHCES:
OPerators shall be provided with position switches. The position switches shall have
Form C (SPDP) contacts rated not less than 10 amperes at 120 volts ac and 0.8
power factor at 24 volts dc. Unless specified otherwise, one set of limit switches shall
be set to actuate when the valve is less than 3 percent open, and the second set shall
be set to actuate when the valve is more than 97 percent open. Limit switches shall
be enclosed in a NEMA 7 explosion-proof case and shall be rotary type, positively
coupled to the actuator. Limit switches shall be fisher Type 304,. or equal.
F. POSITION INDICATOR:
Operators shall be provided with position indicator mounted directly to the acuator
body. The position indicator shall provide a readily visible indication of open-close
position.
PART 3 - EXECUTION
3.01 INSTALLATION:
A. GENERAL:
Installation shall be as specified herein. Valve operators shall be located so that they
are readily accessible for operation and maintenance. Valve operators shall be
mounted for unobstructed access, but mounting shall not obstruct walkways. Valve
operators shall not be mounted where shock or vibration will impair their operation.
Support systems shall not be attached to handrails, process piping, or mechanical
-equiPment.
B. PNEUMATIC OPERATORS:
1. GENERAL: Pneumatic operators shall have their manual operating accessory,
where possible, located between 48 inches and 60 inches above the floor or a
permanent work platform. Each operator shall be provided with a 16-gage stainless
steel identification tag. Identification tags shall bear the complete equipment number
of the operator, as specified. Characters shall be 1/4-inch, die-stamped.
Identification tags shall be securely attached to the operator in a readily visible
location using stainless steel screws or wire.
~, EtECTRICAL POWER WIRING: Electrical power wiring and equipment shall be
in compliance with Division 16.
PNEUMATIC VALVE & GATE OPERATORS & OPERATOR APPURTENANCE
15186-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
'I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
3. SIGNAL WIRING: Electrical signal wiring and equipment shall be in compliance
with Division 16.
3.02 TESTING:
A. G1=NERAL REQUIREMENTS:
Testing shall be performed in accordance with Section 01660, and this section. No
required test shall be applied without prior notice to the Construction Manager, who
has the right to witness any test. At least 14 days before the commencement of any
testing activity, a detailed step-by-step test procedure, complete with forms for the
recording of test results shall be provided. All equipment necessary to perform the
required tests shall be provided.
B. PIPING TESTING:
1. PNEUMATIC PIPING TESTING: Pneumatic piping systems shall be tested for
leaks in compliance with Section 15050.
2. LIQUID PIPING SYSTEMS: Liquid piping systems shall be tested for leaks in
compliance with Section 15050.
3.03 TRAINING:
Operation and maintenance training for the equipment provided under this section shall
be provided for the Owner's personnel.
END OF SECTION 15186
~- '=-
PNEUMATIC VALVE & GATE OPERATORS & OPERATOR APPURTENANCE
15186-5
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15250 -INSULATION FOR EXPOSED PIPING AND EQUIPMENT
PART 1 - GENERAL
1.01 DESCRIPTION:
A. SCOPE:
This section specifies insulation for exposed piping and related equipment and
appurtenantsurfaces.-
B. TEMPERATURE CLASSES:
Insulation for exposed piping and equipment is classified for the following temperature
ranges: low, medium and high.
Low temperature class (not in this contract).
Medium temperature class insulation shall be suitable for an operating temperature
range of 200 to 650 degrees F.
High temperature class (Not in this contract).
1.02 REFERENCES:
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall prevail.
Reference
Title
~
AsiMt3209-86
Aluminum and Aluminum-Alloy Sheet and Plate
ASTM C533-85
Calcium Silicate Block and Pipe Thermal Insulation
ASTM C534-82
Performed Flexible Elastomeric Cellular Thermal
Insulation in Sheet and Tubular Form
ASTM C552-86
Cellular Glass Thermal Insulation
ASTM E96-80
Water Vapor Transmission of Materials
FEDSPEC L-P-535-79
Plastic Sheet (Sheeting) "Plastic Strip" Poly (Vinyl
chloride) and Poly (Vinyl Chloride-Vinyl Acetate), Rigid
INSULATION FOR EXPOSED PIPING AND EQUIPMENT
15250-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
FED SPEC
Insulation, Blocks, Boards, Blankets, Felts
HH-I-558B(3)-76
Sleeving (Pipe and Tube Covering), and Pipe Fitting
Covering, Thermal (Mineral Fiber, Industrial Type)
- -
1.03 SUBMITTALS:
The following information shall be provided in accordance with Section 01800:
1. Manufacturer and manufacturer's type designation.
2. Samples, for each insulation material type, of typical jacket and closures for
fittings, valves and appurtenances.
3. Descriptive literature and catalog data for materials to be used showing methods
of installation.
4. Certification of ratings for water vapor transmission and puncture and stiffness as
specified in paragraph 15250-2.03 A.
PART 2 - PRODUCTS
2.01 GENERAL:
Insulation for pipe, valves, fittings, expansion joints, flanges and other connections shall
be segmented sections, molded, or blanket type coverings of the specified type and
thickness of pipe insulation. Equipment insulation shall be blanket or rigid board type cut
to fit the surface.
2.02 IN~LATION:
A. GENERAL:
Low temperature class insulation shall be of the unicellular elastomeric thermal,
cellular glass, or fiberglass type.
Medium temperature class insulation shall be of the cellular glass or fiberglass type.
High temperature class insulation shall be of the calcium silicate type.
B. -GE.blULAR GLASS TYPE:
INSULATION FOR EXPOSED PIPING AND EQUIPMENT
15250-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
DigesterModifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia .
Cellular glass type insulation shall conform to the requirements of ASTM C552, Type
II.
C. FIBERGLASS TYPE:
fjbefglass type insulation shall conform to the requirements of.FEDSPE~ HH-I-558B.
D. CALCIUM SILICATE TYPE:
Calcium silicate type insulation shall conform to the requirements of ASTM C533,
Type II. Class C.
2.03 INSULATION JACKETS:
A. LAMINATED JACKETS:
Laminated jackets shall consist of aluminum and white Kraft paper. Jackets shall
have a perm rating for water vapor transmission of not more than 0.02 in accordance
with procedure A of ASTM E96.
2.04 INSULATION COVERS:
A. STAINLESS STEEL COVERS:
Insulation covers shall be constructed of corrugated finish stainless steel sheet.
Covers shall be 0.010 inch thick. Sheet metal screws shall be stainless steel.
Jackets shall be secured with 0.020 by 3/4 inch type 316 stainless steel expansion
bands.
2.05 SHIELDS:
~
-.a~ ~
Unless otherwise specified, thermal pipe hanger shields shall be provided at pipe
supports. Thermal hanger shields shall be as specified in paragraph 15096-2.03.
PART 3 -~EXECUTION
3.01 INSTALLATION:
A. GENERAL:
Insulation shall be applied over clean, dry surfaces. Double layer insulation, where
specified, shall be provided with staggered section joints. Piping and equipment shall
~e ~ted with stainless steel jackets.
INSULATION FOR EXPOSED PIPING AND EQUIPMENT
15250-3
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. PIPE SUPPORTS AND SHIELDS:
Unless otherwise specified, thermal pipe hanger shields shall be provided by the
Contractor and installed during pipe support installation. Where thermal pipe hanger
. Shierds are used, apply the following to all butt joints.
1. On hot pipe systems, the Contractor shall apply 3-inch wide vapor barrier tape or
band over the butt joints.
C. PROTECTION:
Insulation and jackets shall be protected from crushing, denting, and similar damage
during construction. Vapor barriers shall not be penetrated or otherwise damaged.
Insulation, jacket, and vapor barriers damaged during construction shall be removed
and new material shall be installed.
D. PIPING INSULATION:
1. GENERAL:
a. PIPE: Piping shall be continuously insulated along its entire length including all
in-line devices such as valves, fittings, flanges, couplings, strainers and other
piping appurtenances. Piping insulation shall be provided with laminated jackets
and stainless steel covers. Insulation shall be buttted firmly together and jacket
laps and joint strips provided with lap adhesive. Jackets shall be provided with
their seams located on the underside of the pipe.
~
b. FITTINGS. CONNECTIONS FLANGE AND VALVES: Fitting, connection,
~ange and valve insulation shall be provided with rigid covers specified in
paragraph 15250-2.04. Insulation shall be secured in place with.20-gage wire and
a coat of insulating cement. Covers shall overlap the adjoining 'pipe insulation and
jackets. Covers shall be provided with their seams located on the underside of
fittings and valves.
3. MEDIUM- AND HIGH-TEMPERATURE CLASS:
a. PIPE: Insulation shall have ends sealed with end joint strips and held in place
by waterproof adhesive.
b. FITTINGS. CONNECTIONS, FLANGES AND VALVES: Insulation shall be
-provided with rigid stainless steel covers specified in paragraph 15250-2.04 B.
INSULATION FOR EXPOSED PIPING AND EQUIPMENT
15250-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Covers shall be mechanically secured by corrosion.:.resistant tacks pushed into the
overlapping throat joint.
4. OUTDOOR PIPING:
_ a- PIPE: Insulation shall be provided with stainless steel jackets specified in
paragraph 15250-2.03 B on all piping exposed to weather.
b.FITTINGS. CONNECTIONS. FLANGES AND VALVES: Insulation shall be
provided with rigid stainless steel covers specified in paragraph 15250-2.05 B.
E. MECHANICAL EQUIPMENT INSULATION:
1. GENERAL: Insulation shall fit the contours of equipment and shall be provided
with a stainless steel jacket scecured by screws and 3/4 by 0.020 inch stainless
steel bands spaced a maimum of 18 inchess on center. Weld pins or stick clips
with washers shall be used for securing insulation to walss and roof of stroage
tank and spaced a maximum 9 inches apart. Joints shall be staggered and voids
filled with insulating cement. Insulation shall be provided with laminated jackets
specified in paragraph 15250-2.03 A. Insulation shall be provided with joints at
equipment disassembly points and access points so that insulation can be
removed without cutting.
2. MEDIUM- AND HIGH-TEMPERATURE CLASS: Joints shall be covered and
cemented in place with 4-inch wide strips of the same material as the laminated
jackets specified in paragraph 15250-2.03 A.
F. FLASHING:
Flashing shall be provided at jacket penetrations and terminations. Clearance for
Jl?s!ling shall be provided between insulation system and piping supports.
A heavy tack coat of sealant shall be troweled over the insulation, extending over the
. jacket edge 1-inch and over the pipe or protrusion 2 inches. Reinforcement shall be
stretched over the tack coat after clipping to fit over pipe and jacket. Clipped
reinforcing shall be strapped with a continuous band of reinforcing to prevent curling.
Sealant shall then be troweled over the reinforcement to a minimum thickness of 1/8-
inch.
Stainless steel caps shall be formed to fit over the adjacent jacketing and to
completely cover coated insulation. Cap shall be held in place with a jacket strap.
INSULATION FOR EXPOSED PIPING AND EQUIPMENT
15250-5
INSULATION FOR EXPOSED PIPING AND EQUIPMENT
15250-6
I
I
I
I
I
I
I
I
I
I
I
I
I
.1
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
3.02 INSULATION THICKNESS SCHEDULE:
The insulation dimensional tolerances shall comply with the specified standards. The
minimum insulation thicknesses, exclusive of jacket, shall be as follows:
-Y '-
Piping and Valves:
Piping Service
Insulation Class
Thickness
HWR & HWS
Medium Temperature
1-1 /2"
OS & TRS
Medium Temperature
1-1/2n
Heat Exchanqers:
1-1/2n mineral wool or fiberglass board, with stick pins and washers @ gn o.C.,
stainless steel corrugated jacket, secured with stainless bands @ 18n O.C.
END OF SECTION 15250
~e:...
~
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15620 - PACKAGED HOT WATER HEATING SYSTEM
PART 1 - GENERAL
1.01 DESCRIPTION:
A. SC~E:
This section specifies packaged hot water heating systems including dual gas-fired
hot water boilers and hot water pumped recirculation systems. The equipment
covered by these specifications is intended to be standard equipment of proven
performance a~ manufactured by reputable concerns. Equipment shall be designed,
constructed, and installed in accordance with the best practices of the trade, and shall
operate satisfactorily when installed as shown on the Contract Drawings.
B. EQUIPMENT LIST:
Item
Equipment Number
Hot Water Boiler No. 1
Hot Water Boiler NO.2
Hot Water Pump No. 1
Hot Water Pump NO.2
Hot Water Pump NO.3
Hot Water Pump NO.3
B7111
B7121
P7121
P7122
P7221
P7222
Temperature Control Valve - B7111
Temperature Control Valve -87121
TCV7111
TCV7121
Temperature Control Valve - MX7202
Temperature Control Valve - MX7203
. Temperature Control Valve - MX7204
Temperature Control Valve - MX7302
Temperature Control Valve - MX7303
-4=en1perature Control Valve - MX7304
Temperature Control Valve - MX7402
Temperature Control Valve - MX7403
Temperature Control Valve - MX7404
Temperature Control Valve - MX7502
Temperature Control Valve - MX7503
Temperature Control Valve - MX7504
TCV7202
TCV7203
TCV7204
TCV7302
TCV7303
TCV7304
lCV7 402
TCV7403
TCV7404
TCV7502
TCV7503
TCV7504
1.02 QUALITY ASSURANCE:
A. REFERENCES:
This section contains references to the following documents. They are a part of this
-se<*ion as specified and modified. In case of conflict between the requirements of
PACKAGED HOT WATER HEATING SYSTEM
15620-1
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
this section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
~ ~
ANSI B 1.20.1-83
Pipe Threads, General Purpose (Inch)
ANSI B16.5-88
Pipe Flanges and Flanged Fittings
1.03 SUBMITTALS:
A. AFFIDAVIT OF COMPLIANCE:
Submit manufacturer's affidavit that all materials delivered comply with this spec-
ification and the cited standard specifications.
B. SHOP DRAWINGS:
Submit six (6) sets of shop drawings for hot water boilers. Include details of piping
connections and anchors.
C. MAINTENANCE DATA:
Submit six (6) copies of maintenance data and parts list for hot water boilers.
PART 2 - PRODUCTS
2.01 HOT WATER BOILER:
-diI"' b.
A. GENERAL:
The Hot Water Boiler shall be designed for 30 psig hot water. The maximum water
temperature will be 180 degree F, and the maximum system temperature drop will
be 10 degree F. The boiler shall have a maximum output of 1,000,000 BTUH when
fired with natural gas (1,000 BTU/SCF) or digester gas (500 BTU/SCF). Electrical
power available will be 120 Volt, 1 Phase, 60 Cycle.
B. GENERAL BOILER DESIGN:
The boiler shall be a four pass horizontal firetube updraft. boiler with 470 cm 2 of
heating surface per rated boiler kilowatts. It shall be mounted on a heavy steel frame
with integral forced draft burneLand burner controls. The complete package boiler
..1'hall be approved as a unit by Underwriters Laboratories and shall bear the UUULC
label.
PACKAGED HOT WATER HEATING SYSTEM
15620-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
The boiler shall be completely pre-assembled and fire tested at the factory. The unit
shall be ready for immediate mounting on floor or simple foundation and ready for
attachment of water, steam, fuel, electrical, vent and blowdown connections.
The boiler shall be built to comply with the following insurance and codes Factory
Mutual, ASME CSD-1.
~ ~
1. Boiler Shell.
The boiler shell must be constructed in accordance with ASME Boiler Code and
must receive authorized boiler inspection prior to shipment. A copy of the
inspection report shall be furnished to the purchaser.
The hot water return and outlet connections shall be located on the top center
line of the boiler. The boiler shall be designated to rapidly mix the return water
with the boiler water. Forced internal circulation shall be used. A dip tube shall
be included as an integral part of the water outlet.
Two lifting eyes shall be located on top of the boiler.
Front and rear doors on the boiler shall be hinged or davited. Doors are to be
sealed with fiberglass tadpole gaskets and fastened tightly using heavy cap-
screws that thread into replaceable brass nuts.
Rear refractory and insulation shall be contained in the formed door, which must
swing open for inspection of brick work.
The boiler tubes shall not include turbulators, swirlers or other add-on
appurtenances.
Front and rear tube sheets 'and all flues must be fully accessible for inspection
and cleaning when the doors are swung open. The shell must be furnished with
-- 'adequate hand-holds to facilitate boiler inspection and cleaning.
A manhole shall be provided.
The exhaust gas vent shall be located near the front of the boiler on the top
center line and shall be capable of supporting 907.2 Kg and shall contain a stack
thermometer. A multi-wall stack and, rain hood shall be furnished and extended
through the roof of the Digester Control Building. Existing stack openings may
be used for the new stack, Flashing shall be provided between the roof and the
stack and the penetration shall be weather-tight.
Observation ports for the inspection of flame conditions shall be provided at each
-end of the boiler.
PACKAGED HOT WATER HEATING SYSTEM
15620-3
F&V Project NO.97 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
The boiler insulation shall consist of a 5 cm blanket under a sectional pre-formed
sheet metal lagging. This insulation must be readily removable and capable of
being reinstalled, if required.
The entire boiler based frame and other components shall be factory painted
_ before shipment using a hard finish enamel coating.
C. BOILER TRIM:
. 1. Low Water Cutoff. A low water cutoff control (manual reset) shall be
mounted on the top centerline of the boiler wired into the burner control
circuit to prevent burner operation if boiler water falls below a safe level.
2. Pressure and Temperature Gauqes. Pressure and temperature gauges shall
be mounted on the boiler with temperature sensing element located adjacent
to the hot water outlet.
?
3. Relief Valves. Water relief valves of a type and size to comply with ASME
Code requirements shall be mounted on the unit.
4. Temperature Controls. Temperature controls to regulate burner operation
shall be mounted on the unit with temperature sensing elements located
adjacent to the hot water outlet. Controls shall be high limit (manual reset),
operating limit (auto reset), and firing rate control.
D. BURNER AND CONTROLS:
1. Mode of Operation. Burner operation shall be full modulation principle. The
burner shall always return to low fire position for ignition.
2. Blower. Air for combustion shall be supplied by a forced draft blower
mounted in the front boiler door, above the burner, to eliminate vibration and
reduce noise level. The impeller shall be cast aluminum, radial blade,
carefully balanced, and directly connected to the blower motor shaft.
~ -
3. Combustion Air Control. Combustion air damper and cam operated fuel
metering valves shall be operated by a single damper control motor that
regulates the fire according to load demand. Potentiometer type position
controls shall be provided to regulate operation of the damper control motor.
4. Fuel Specification and Piping.
a. Burner Tvpe - The burner shall be integral with the front head of the boiler
and of high radiant multi-port type for gas. The burner shall be approved for
operation on natural gas fuel. Burners shall be suitable for use on natural
gas or digester gas.
PACKAGED HOT WATER HEATING SYSTEM
15620-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia .
b. Gas Pilot - The gas pilot shall be a premix type with automatic electric
ignition. An electronic detector shall monitor the pilot so that the primary gas
valve cannot open until pilot flame has been established. The pilot train shall
include two manual shut-off valves, solenoid valve, pressure regulator and
pressure gauge.
~ --
c. Gas Burner Piping - Gas burner piping on all units shall include primary
gas shutoff valve, motor operated with proof of closure switch and plugged
leakage test connection. The main gas valve(s) shall be wired to close
automatically in the event of power failure, flame failure, low water or any
safety shutdown condition. A lubricating plug cock or butterfly shutoff valve
shall be provided as a means for a tightness check of the primary shut off
valve. An additional plug cOck on butterfly valve shall be furnished at
entrance to gas train. High and low gas pressure switches shall be provided.
d. Burner Turndown - Turndown range of burner shall be 4:1 when firing
natural gas.
5.
Boiler Flame Safeguard Controller and Control Panel.
Controller shall be computerized solid state having sequence and flame-on
lights and digital "first out" fault code indications of flame safeguard trip
functions. It shall include dynamic self-check logic. The controller shall have
a fixed operating sequence incapable of being manually altered. The
sequence shall include start, pre-purge, pilot and main fuel ignition run and
post-purge cycles.
~- .~
Controller shall be the non-recycle type for maximum safety that shall
shutdown the burner and indicate as a minimum the following trip functions:
pilot and main flame failure, high and low fire proving switch faults, running
interlocks open, false flame signal and fuel valve open. The controller shall
have a run/test switch. It shall allow interruptions to sequence just after pre-
purge, during pilot ignition trial and run cycles for adjustments to firing rate
motor, damper linkages and pilot flame for minimum turndown tests.
The control panel shall be mounted on the front door of the boiler in a
location convenient to the operator. The hinged metal cabinet will have
NEMA 1A rating that includes a neoprene dust seal and a Yale cabinet key
type lock. The panel shall contain the boiler flame safeguard controller,
blower motor starter, indicating lights and selector switches. The panel shall
have a removable sub-basefor mounting the flame safeguard controller,
blower motor starter, and terminal blocks. For combination fired boilers the
panel will contain the fuel selector switch. The panel shall contain the
following lights and switches:
PACKAGED HOT WATER HEATING SYSTEM
15620-5
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Lig hts .
White -load demanded.
White - .fuel valve open.
Red - low water.
Red - flame failure.
~
Control Switches
Burner On-Off.
Manual-Automatic.
Manual Firing Rate Control.
Oil, heat and moisture resistant wire shall be used and identified with circuit
numbers corresponding to the electrical wiring diagram. All electrical
equipment and wiring shall be in conformance with Underwriters
Laboratories requirements. Boiler to be supplied with a control circuit
transformer and fuse protection for the control circuit.
Each boiler shall be factory equipped with a Boiler Management Control
System. The system shall consist of a computer based boiler controller and
solid state sensors totally integrated to provide automatic burner
sequencing, flame supervision, and indications of system status, faults, and
self-diagnostics.
The boiler controller shall consist of chassis, program module, keyboard
display, and flame signal amplifier. It shall be the non-recycle type and have
a fixed operating sequence incapable of being manually altered. The
sequence shall include standby, pre-purge, pilot, main fuel ignition; and run,
and post-purge periods. The system shall incorporate full modulating control
of fuel and combustion air as well as firing rate control based on system
demand.
-:i- ~
The boiler controller shall have a non-volatile memory that retains history
files and sequence status after interruptions. An 80 character, 2 line liquid
crystal (LCD) display and keyboard shall be provided to adjust control
settings and display 73 fault messages, 12 diagnostic messages, 38
historical messages as well as system status messages and operating
pressures and temperatures. Boiler firing rate shall also be displayed in
addition to the last 6 lockouts and boiler operating information when the
lockout occurred. Provisions for a security access code shall be provided.
Separate status indicators will show:
Ready: system operational.
Demand: call for heat.
Main Valve: fuel valve open.
PACKAGED HOT WATER HEATING SYSTEM
15620-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
Low Water: low water condition.
Alarm: safety shutdowns.
---'!
The boiler controller shall incorporate a five function run/test switch. The
system shall be characterized for the boiler. The system shall also
incorporate a tailored pre-purge cycle that minimizes pre-purge energy
losses, while maintaining the maximum required air changes. It shall permit
the user to select a specific rate control program for precise load tracking
that reduces on-off cycling due to load swings. The system shall also provide
an integrated thermal stress protection program to prolong boiler life. An
assured low fire cutoff feature shall also be provided.
The system shall monitor inputs from solid state sensor for gas pressure, oil
pressure, and temperature. A single solid state sensor shall be used for both
on-off and proportioning control of the burner. The highllow limits and
operating set points of all sensors will be programmable from t~.e keyboard
display. The system shall be capable of detecting a jumpered or defective
sensor. A dynamic check of the gas pressure sensor shall be made prior to
the main flame establishing period to ensure it is fully operational. Options
such as Lead/Lag, Boiler Efficiency, and Heating Boiler packages can be
interfaced to this module without any change to the existing system
structure. The communications module shall be able to interface with an IBM
PC or compatible system.
2.02 HOT WATER CIRCULATION SYSTEM:
A. GENERAL:
The Hot Water Heating system shall include a skid-mounted packaged pumping
system for circulating hot water through the heat exchangers. The pumps shall
be of the horizontal and suction, centrifugal type. The pumps shall be controlled by
variable frequency drives which receive a speed control signal from a pressure
-- transmitter on the discharge piping loop which maintains system pressure at 40
PSIG (operator adjustable); The pumps shall conform to the detailed specifications
as set forth below:
1. Casino: Volute type, Dolted to adapter, with recessed lock fit to insure
alignment. Separate suction cover bolted to casing through machined lock
joint. No stud or bolt holes are tapped through casing to liquid ways. Tapping
openings provided for priming, venting, draining and suction and discharge
gauge connections. Piping connection to be as shown on plans and as per
pump data sheets, NPT threaded nozzles integral with casing or 125 lb. ANSI
flat face standard drilled flanged.
""'"""' ~ Impeller: Enclosed, single suction type, cast in one piece. All impellers are to
be statically balanced to insure smooth operation, also hydraulically balanced
PACKAGED HOT WATER HEATING SYSTEM
15620-7
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
~
~ ~
except in some small sizes whefe end thrust is but a minor factor. Impeller
mounted directly on the extended motor shaft, keyed to shaft and held in
lateral position between shaft sleeve and impeller washer. A self-locking cap
nut will hold a compression seal washer securely against hub and prevent
leakage of liquid between shaft sleeve and shaft.
3.
Wearing Rinqs:Renewable type; maintain propef funning clearance with
impeller hubs to minimize leakage between suction and discharge.
4.
Shaft Sleeves: To be shouldered on shaft near impeller and covefS full
length of shaft from impeller hub to motor end bracket. Seals by compression
between shaft sleeve and impeller hub, also between sleeve and shouldef on
shaft, protecting shaft from contact with liquid. Shaft sleeve is free to expand
or contract with temperature changes.
5.
Stuffinq Box: The stuffing box shall be cast integral with the pump casing
and will be complete with tapped openings fOf sealed liquid or a flushing
connection. The stuffing box hardware shall be non-corrosive. The stuffing
box shall contain a face type mechanical seal. The seal shall have a carbon
rotating head against a Ni-Resist stationary face and be complete with a
Buna-N boot with stainless steel spring and spring retainer.
6.
Adapter: Maintains rigid assembly between motor and casing. Machined lock
between adapter and motor end bracket keeps adapter and casing in
permanent alignment with motor and extended motor shaft. Sides of adapter
are fully open for ready access to stuffing box and gland.
7.
Motor: Motor shall be wound for 230/460V, 3 phase 60 hertz selVice and
shall be assembled as an integral part of the complete units. End bracket
machined to match. recessed lock fit on adapter to insure permanent
alignment. Shaft carries impeller and sleeve. Motor bearings ball bearing type,
designed to carry all radial and thrust loads, and installed in sealed housing
which retain lubricant and exclude dirt and moisture. Motors shall be TEFC
type and suitable for operation with a variable frequency drive.
B. CIRCULATING WATER CONTROL VALVE:
Each hot water heating system unit shall be provided with a three-way, pneumatic
actuated, thermostatic pilot controlled valve placed in the hot water circulating line
to maintain a boiler water temperature of 1800 ::!::3.00F. The control valve shall also
limit the digester heat exchanger jacket water from exceeding a temperature of 1620
::!::3.00F. Extend air supply from the existing plant air header in the Digester Control
Room.
PACKAGED HOT WATER HEATING SYSTEM
15620-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia .
C. DIGESTER TEMPERATURE CONTROL:
The system for controlling the temperature of the digester contents within the.
desired limits shall be furnished by the Hot Water Heating System Supplier,' and
shall be complete with temperature indicating controller, three-way self-operating
temperature control valve, rigid sensing bulb and armored capillary tube. The
~nttoller shall maintain the digester contents at 950 F. The controller shall have a
80 -1500F range. Valve shall be Trerice Model4n JVA/91 000 or equal.
D. HOT WATER SYSTEM CONTROL PANEL:
Each Hot Water Heating System shall include a control panel with breakers, starters,
variable frequency drives and other necessary control and status elements for each
hot water circulating pump. Control power transformers shall be provided for
providing 120 VAC power to the boiler and controls. The controls shall operate the
hot water system as a constant-pressure system with control input provided by a
pressure indicating transmitter furnished by the hot water heating system vendor.
The controls shall be housed in a NEMA 4 panel suitable for floor mounting in the
existing Digester Control Room
PART 3 - EXECUTION
3.01 INSTALLATION:
The Hot Water Heating System shall be installed in accordance with the
manufacturers instructions. Skid mounted units shall be provided with 4n concrete
housekeeping pads and secured with 316 stainless steel anchor bolts as directed by
the manufacturer. Controls shall be wired to the appropiate components. The
system shall be completely piped and wired such that the only connections required
will be:
--- ~
Three phase power supply
Natural gas supply
Digester Gas Supply
Hot Water Supply Header
Hot WaterReturn Header
Make-up Water Supply
3.02 WARRANTY:
All equipment is to be guaranteed against defects in materials and/or workmanship
for a period of 12 months from date of start-up.
PACKAGED HOT WATER HEATING SYSTEM
15620-9
PACKAGED HOT WATER HEATING SYSTEM
15620-10
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
3.03 TESTING:
The packaged hot water heating system must receive factory tests to check the
construction, controls, and operation of the unit. All tests may be witnessed by the
Qwner, if desired. The system shall be field tested for a minimum of 24 continuous
hours before the system is placed on-line with sludge. Equipment failing during the
test period shall be replaced and the testing repeated until the entire system
successfully passes the 24 hour test.
3.04 START-UP SERVICE:
After Hot Water Heating System installation is completed, the manufacturer shall
provide th~ services of a field representative for starting the unit and training the
operator at no additional costs. A factory approved and authorized start-up report
shall be submitted to the Engineer at the time of start-up.
END OF SECTION 15620
- ~
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
SECTION 15625 - PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
PART 1 - GENERAL
1.01 DESCRIPTION:
A. SCOPE:
This section specifies packaged hot water heating systems including ,dual gas-fired
hot oil boilers, oil/water heat exchangers and hot water pumped recirculation
systems. The equipment covered by these specifications is intended to be standard
equipment of proven performance as manufactured by reputable concerns.
Equipment shall be designed, constructed, and installed in accordance with the best
practices of the trade, and shall operate satisfactorily when installed as shown on the
Contract Drawings.
B. EQUIPMENT LIST:
Item
Equipment Number
Hot Oil Boiler No. 1
Oil/Water Heater Exchanger No. 1
Hot Oil Boiler NO.2
Oi//Water Heater Exchanger NO.2
B7111
HX7111
B7121
HX7121
Hot Water Pump No. 1
Hot Water Pump NO.2
Hot Water Pump No. 3
Hot Water Pump NO.3
P7121
P7122
P7221
P7222
Temperature Control Valve - 87111
Temperature Control Valve - B7121
TCV7111
TCV7121
Temperature Control Valve - MX7202
Temperature Control Valve - MX7203
Temperature Control Valve - MX7204
Temperature Control Valve - MX7302
Temperature Control Valve - MX7303
Temperature Control Valve - MX7304
Temperature Control Valve - MX7402
Temperature Control Valve - MX7403
Temperature Control Valve - MX7404
Temperature Control Valve - MX7502
Temperature Control Valve - MX7503
Temperature Control Valve - MX7504
TCV7202
TCV7203
TCV7204
TCV7302
TCV7303
TCV7304
TCV7 402
TCV7403
TCV7 404
TCV7502
TCV7503
TCV7504
PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
15625-1
PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
15625-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1.02 QUALITY ASSURANCE:
A. REFERENCES:
1=hi~section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of
this section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ANSI B1.20.1-83
Pipe Threads, General Purpose (Inch)
ANSI B16.5-88
Pipe Flanges and Flanged Fittings
1.03 SUBMITTALS:
A. AFFIDAVIT OF COMPLIANCE:
Submit manufacturer's affidavit that all materials delivered comply with this spec-
ification and the cited standard specifications.
B. SHOP DRAWINGS:
Submit six (6) sets of shop drawings for hot water boilers. Include details of piping
connections and anchors.
C. ~AINTENANCE DATA:
Submit six (6) copies of maintenance data and parts list for hot water boilers.
PART 2 - PRODUCTS
2.01 HOT OIL BOILER:
A. GENERAL:
The Hot Water Heating System shall be designed to produce 30 psig hot water. The
maximum water temperature will be 180 degree F, and the maximum system
temperature drop will be 10 degree F. The boiler shall have a maximum output of
1,000&00 BTUH when fired with natural gas (1,000 BTU/SCF) or digester gas (500
BTU/SCF). Electrical power available will be 120 Volt, 1 Phase, 60 Cycle.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
B. HEATER:
The heater shall be a helical coil type, with two coils manufactured from ASTM A 106
seamless schedule 40 pipe. Heater shall be of a forced circulation design. The coil
shall be designed and stamped according to the specifications of the ASME Section VIII
- Pressure Vessel Code for 7500F at 250 psig. The coils shall be hydro-tested at 375
psi~ The nominal heater operating pressure shall be 80 to 120 psig. Aminrmum of
100% of the inner coil welds and 10% of the outer coil welds shall be x-ray inspected.
The heater inlet and outlet connections shall be ASNI 300# flanged and shall be fitted
with thermowells for sensors to monitor the heater inlet and outlet temperatures.
The combustion chamber shall be sized to prevent flame impingement, insuring that the
. flame has no direct contact with the coils and that the flame burns out completely prior
to entering the second pass of the heater. The coil surface area shall be sized to
guarantee that the "average heat flux densityn is minimized, therefore maximizing the
life of the thermal fluid. The coil surface area and average heat flux density must be
stated in the proposal.
The heater shell shall be manufactured from a minimum of ASTM A36 carbon steel
plate. The shell is to be externally insulated with a minimum of four inches of mineral
wool insulation, quilted on expanded metal and covered with an embossed aluminum
outer cover to prevent heat loss radiation, accidental injuries and overheating of the
working environment. The heater lid shall be removable for inspection and cleaning if
necessary. The heater lid is to have a high temperature ceramic fiber bla'nket lining.
Refractory use shall be minimal, preventing excess heat radiation after shut-down (ie.
power failure) therefore minimizing the degradation of the thermal fluid.
Heater efficiency shall be guaranteed to exceed 85% (LHV) without combustion air
preheat. If combustion air-preheat zones are used, the efficiency must be stated with
and without air-preheat zone.
C. BU~NER:
The burner shall be a standard, packaged type, forced draft burner as manufactured by
Gordon-Piatt, Eclipse, Industrial Combustion, North American or approved equal having
adequate parts and service readily available through local service contractors. Burners
shall be suitable for use on natural gas or digester gas. Burner, fan, motor and fuel train
to be furnished to comply with applicable Nationally Recognized Testing Laboratories
(N.F.P.A.; Industrial Risk Insurers, Factory Mutual and/or U.L. regulations).
A full-modulation control system shall be 'provided to meet the required temperature and
heater output characteristics. Proposal shall state turndown capability of burner.
The1lcrme safety system shall utilize a Self Checking - UV flame detector.
PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
15625-3
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
D. BURNER CONTROL PANEL:
A prewired NEMA 4, control panel shall be provided as an integral part of the system.
The control panel shall be designed with Honeywell UDC series components to
continuously monitor and/or control thermal fluid supply & return temperature, thermal
fluiQ. flQW rate, and flue gas temperature. The controller shall modulate the air and gas
flow for maximum fuel efficiency. The control logic must hold the firing rate 'of the
burner at low fire during start up and while at low thermal fluid temperature until the
minimum velocity (determined based on the fluid) through the heater has been
achieved.
The flame safeguard shall be a Honeywell RM 7800 series, or approved equal,
providing automatic burner sequencing, flame supervision, system status indication,
system or self-diagnostics and troubleshooting with alpha-numeric characterized read-
out that displays the six most recent combustion faults.
Motor starters and overloads for the burner blower and the primary loop circulation
pump(s) shall be mounted in the control panel.
The control panel shall contain a minimum of the following independently labeled fault
lights:
1. High Thermal Fluid Temperature
2. High Flue Gas Temperature
3. Low Thermal Fluid Level in Expansion Tank
4. Low Thermal Fluid Flow
5. Burner or Flame Failure
The control panel shall carry a Nationally Recognized Testing Laboratory (NRTL) listing
such as Underwriters Laboratories (UL), ETL Testing Laboratories (ETL) or equivalent.
='" .....
E. CONTROL DEVICES:
A differential pressure (DP) switch with indication, shall continuously monitor flow
based on DP across an orifice plate mounted at the thermal fluid heater outlet and
shall shut off the burner if the flow drops below 95% of the design value.
The thermal fluid system shall also contain a minimum of the following control devices:
1. High Thermal Fluid Temperature Switch (Each Coil Monitored Independently)
2. High Flue Gas Temperature Switch
3. Temperature Sensors (RTD Type for Thermal Fluid Supply & Return)
4. One Pressure Relief Valve (ASME Section VIII)
5. One Low Fluid Level Switch (See UK. Expansion Tank")
PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
15625-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
F. THERMAL FLUID PUMP:
Each Burner shall be equipped with a primary and standby thermal fluid pump.
Pumps shall be low-pressure centrifugal pumps as manufactured by KSB, Dean,
Goulds, Cesterton or approved equal. Designed for organic thermal fluids, suitable for
thermal fluid temperatures up to 650oF. Pump to be supplied with mechanical seals
deSigned for thermal fluid use to assure maintenance-free operation. Pumps shall be
mounted on a common base plate complete with coupling, coupling guard and TEFC
motor.
The Thermal Fluid Pump shall also contain a minimum of the following control
devices:
1. Pressure Gauge (0 to 160 psi) (Pump Discharge)
2. Combination Pressure I Vacuum Gauge (-30 in. Hg to 60 psi) (Pump Suction)
3. Two Gauge Valves with Air Bleed
G. BOILER VALVES:
Valves must be welded end valves, with the exception of control valves which are to
be flanged, designed for use in thermal fluid systems and to be maintenance free. All
process valving shall be the preferred "Bellows Sealn type, as manufactured by ARI,
Ph6nix, Eagle or approved equal, to virtually eliminate nuisance leakage.
A minimum of the following shall be provided in order to provide for independent
isolation of either the heater or the thermal fluid pumps for maintenance purposes:
1. Three Shut-Off Valves - Thermal Fluid Duty up to 6500F with "Maintenance
Free" Stainless Steel Bellows Seal and Safety Packing (Independent Isolation of
Heater or Pump).
2. One Regulating Valve - Thermal Fluid Duty up to 6500F with "Maintenance
Fr~n-Stainless Steel Bellows Seal and Safety Packing for System By-Pass (Sized for
50% of Flow Through Primary Loopr
3. Two Gate Valves (Drain & Heat-up Line)- Socket weld, rated for operati"ng
temperature of 6500F at 250 psi, spindle and seat made of stainless steel, packing
suitable for conventional heat transfer oils.
H. STRAINER:
A pump strainer must be provided"for each pump, designed for use in thermal fluid
system up to 6500F with Stainless Steel Basket.
PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
15625-5
,
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
I. SKID MOUNTING:
The previously mentioned components shall be skid mounted. The skid(s) will provide
all necessary piping between components. The control panel will be prewired to
equipment such as the burner, devices and pump(s) when supplied on the same skid.
Some...prewired accessories may be removed for shipment, but must be appropriately
tagged and labeled to facilitate field installation. . .
All systems shall be supplied as "Pump in Returnn (pumping into the heater) to
maximize pump seal life. Systems supplied as "Pump in Returnn require and must
include an ASME Section VIII pressure relief valve set at a nominal 150 psi.
A pressure/leakage test of all piping shall be performed prior to installation of any pipe
insulation.
J. THERMAL BUFFER:
The thermal buffer is used to accommodate the change in thermal fluid volume, during
normal operation, without exposing hot thermal fluid to oxygen in the expansion tank.
Increasing the thermal fluid service life by reducing oxidation and degradation of the
heat transfer fluid considerably. The thermal buffer is dimensioned and designed
according to heat capacity and volume of thermal fluid in the installation.
K. EXPANSION TANK:
Expansion Tank shall be designed to hold up to 200% of system "thermal fluid
expansion volume", complete with the necessary connections and over-flow.
Fabricated to a 50 psi @ 6500F design minimum.
1. Low Fluid Level Switch (as manufactured by Magnetrol) mounted in the..Expansion
~ Tenk
L. DRAIN TANK:
Drain tank shall be designed to hold up to 100% of the total system volume or the
largest volume between any two isolation valves utilized for periodic maintenance.
Tank shall be complete with the necessary connections. Fabricated to a 50 psi @
6500F design minimum.
M. EXHAUST STACK:
An exhaust stack shall be supplied. The stack diameter shall be designed to maintain
al!u~gas velocity between 20 ft/s and 35 ft/s. The height shall be at a minimum so as
to facilitate a natural draft in the event of a power failure, thus preventing a back flow
of high temperature combustion gasses through the burner. Supplied as.follows:
PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
15625-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
1. Freestanding Design (No guy wires)
2. 100 MPH Wind Load Rating
3. Carbon Steel Construction
4. Transition Up to 5' In Length From Heater to Stack (No Bullhead Tee's, use
multiple 450)
5.~ -One Piece Design
6. False Bottom w/ Drain
N. OPERATION & MAINTENANCE MANUALS:
Operation and Maintenance Manuals shall be provided in accordance with Section
01730. A minimum of the following shall be provided:
1. Operation & Maintenance'lnstructions
2. Process & Instrumentation Diagrams
3. Dimension Sheets
4. Electrical/Instrumentation Control Schematics - Wiring Diagrams
5. Documentation on Accessories Such As Burner, Pumps, Valves, Controls, and
Devices
6. Spare Parts List
2.02 HOT WATER CIRCULATION SYSTEM:
A. GENERAL:
The Hot Water Heating system shall include a skid-mounted packaged pumping
system for circulating hot water through the heat exchangers. The pumps shall
be of the horizontal and suction, centrifugal type capable of 300 GPM at 40 PSIG.
The pumps shall be controlled by variable frequency drives which receive a speed
control signal from a pr~ssure transmitter on the discharge piping loop which
maintains system pressure at 40 PSIG (operator adjustable). The pumps shall
- conform to the detailed specifications as set forth below:
1. Casino: Volute type, bolted to adapter, with recessed lock fit to insure
alignment. Separate suction cover bolted to casing through machined lock
joint. No stud orbolt holes are tapped through casing to liquid ways. Tapping
openings provided for priming, venting, draining and suction and discharge
. gauge connections. Piping connection to be as shown on plans and as per
pump data sheets, NPT threaded nozzles integral with casing or 125 lb. ANSI
flat face standard drilled flanged.
2. Impeller: Enclosed, single suction type, cast in one piece. All impellers are to
be statically balanced to insure smooth operation, also hydraulically balanced
except in some small sizes wtlere end thrust is but a minor factor. Impeller
mounted directly on the extended motor shaft, keyed to shaft and held in
PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
15625-7
F&V Project No.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
lateral position between shaft sleeve and impeller washer. A self-locking cap
nut will hold a compression seal washer securely against hub and prevent
leakage of liquid between shaft sleeve and shaft.
3.
Wearinq Rings: Renewable type; maintain proper running clearance with
impeller hubs to minimize leakage between suction and discharge.
4.
Shaft Sleeves: To be shouldered on shaft near impeller and covers full
length of shaft from impeller hub to motor end bracket. Seals by compression
between shaft sleeve and impeller hub, also between sleeve and shoulder on
shaft, protecting shaft from contact with liquid. Shaft sleeve is free to expand
or contract with temperature changes.
5.
Stuffinq Box: The stuffing box shall be cast integral with the pump casing
and will be complete with tapped openings for sealed liquid or a flushing
connection. The stuffing box hardware shall be non-corrosive. The stuffing
box shall contain a face type mechanical seal. The seal shall have a carbon
rotating head against a Ni-Resist stationary face and be complete with a
Buna-N boot with stainless steel spring and spring retainer.
6.
Adapter: Maintains rigid assembly between motor and casing. Machined lock
between adapter and motor end bracket keeps adapter and casing in
permanent alignment with motor and extended motor shaft. Sides of adapter
are fully open for ready access to stuffing box and gland.
7.
Motor: Motor shall be wound for 230/460V, 3 phase 60 hertz service and
shall be assembled as an integral part of the complete units. End bracket
machined to match recessed lock fit on adapter to insure permanent
alignment. Shaft carries impeller and sleeve. Motor bearings ball bearing type,
designed to carry all radial and thrust loads, and installed in sealed. housing
which retain lubricant and exclude dirt and moisture. Motors shall be TEFC
type and suitable for operation with a variable frequency drive.
B. CIRCULATING WATER CONTROL VALVE:
Each hot water heating system unit shall be provided with a three-way, pneumatic
actuated, thermostatic pilot controlled valve placed in the hot water circulating line
to maintain a boiler water temperature of 1800 ::!:3.00F. The control valve shall also
limit the digester heat exchanger jacket water from exceeding a temperature of 1620
::!:3.00F. Extend air supply from the existing plant air header in the Digester Control
Room.
PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
15625-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
.1
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
C. DIGESTER TEMPERATURE CONTROL:
The system for controlling the temperature of the digester contents within the
desired limits shall be furnished by the Hot Water Heating System Supplier, and
shall be complete with temperature indicating controller, three-way self-operating
temperature control valve, rigid sensing bulb and armored capillary tube: The
controller shall maintain the digester contents at 950 F. The controller shall have a
80 -1500F range. Valve shall be Trerice Model 4" JVA/91 000 or equal.
D. HOT WATER SYSTEM CONTROL PANEL:
Each Hot Water Heating System shall include a control panel with breakers, starters,
variable frequency drives and other necessary control and status elements for each
hot water circulating pump. Control power transformers shall be provided for
providing 120 VAC power to the boiler and controls. The controls shall operate the
hot water system as a constant-pressure system with control input provided by a
pressure indicating transmitter furnished by the hot water heating system vendor.
The controls shall be housed in a NEMA 4 panel suitable for floor mounting in the
existing Digester Control Room
PART 3 - EXECUTION
. 3.01 INSTALLATION:
The Hot Water Heating System shall be installed in accordance with the
manufacturers instructions. Skid mounted units shall be provided with 4n concrete
housekeeping pads and secured with 316 stainless steel anchor bolts as directed by
the manufacturer. Controls shall be wired to the appropriate components. The
system shall be completely piped and wired such that the only connections required
will be:
Three phase power supply
Natural gas supply
Digester Gas Supply
Hot Water Supply Header
Hot Water Return Header
Make-up Water Supply
3.02 WARRANTY:
All equipment is to be guaranteed against defects in materials and/or workmanship
for a period of 12 months from date.of start-up.
PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
15625-9
PACKAGED HOT WATER HEATING SYSTEM (Alternate No.1)
15625-1 0
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia
3.03 TESTING:
The packaged hot water heating system must receive factory tests to check the
construction, controls, and operation of the unit. All tests may be witnessed by the
Owner, if desired. The system shall be field tested for a minimum of 24 continuous
AolKS before the system is placed on-line with sludge. Equipment failing during the
test period shall be replaced and the testing repeated until the entire system
successfully passes the 24 hour test.
3.04 START-UP SERVICE:
After Hot Water Heating System installation is completed, the manufacturer shall
provide the services of a field representative for starting the unit and training the
operator at no additional costs. A factory approved and authorized start-up report
shall be submitted to the Engineer at the time of start-up.
END OF SECTION 15625
I
I
I
I
I
I
I
I
'1
I
I
I
I
I
I
I
I
I
I
F& V Project No.9? 124 01 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 16000 - ELECTRICAL - GENERAL PROVISIONS
PART 1 - GENERAL
1.01 DESCRIPTION
This section specifies electrical work including electrical material, equipment, instc;lllation
and testing requirements. The electrical drawings included in this project manual are
functional in nature and do not specify exact locations of equipment or equipment
terminations.
1.02 QUALITY ASSURANCE
REFERENCES:
This section contains references to the following documents. They are a part of this
sedion as specified and modified. In case of conflict between the requirements of this
section and those of the listed documents, the requirements of this section shall prevail.
Reference
ANSI A58.1-82
Title
Minimum Design Loads for
Buildings and Other Structures
IEEE 81-83
Measuring Earth Resistivity,
Ground Impedance, and Earth
Surface Potentials of a Ground
System
IEEE C57.12.01-89 General Requirements for Dry-
Type Distribution and Power
Transformers
~ ~ ..
NEMA 250-85 Enclosures for Electrical
Equipment (1000 volt Maximum)
NEMA ICS 1-88 General Standards for Industrial Controls and Systems
NEMA ICS 2-88 Industrial Control Devices,
Controllers, and Assemblies
NEMA ICS 6-88 Enclosures for Industrial Controls and Systems
NEMA ST20-86 Dry-Type Transformers for
General Application
ELECTRICAL - GENERAL PROVISIONS
16000-1
ELECTRICAL - GENERAL PROVISIONS
16000-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
NEMA WD 1-83
General Requirements for Wiring Devices
NEC 1996
National Electric Code (NEC)
SBC 1991
Standard Building Code
UL 67-88
Panelboards
UL 489-86
Molded-Case Circuit Breakers
and Circuit Breaker Enclosures
UL 506-79
Specialty Transformers
IDENTIFICATION OF LISTED PRODUCTS
Electrical equipment and Inaterials shall be listed by an independent testing laboratory for
the purpose for which they are to be used. Three such organizations are Underwriters
Laboratories, Inc. (UL), Canadian Standards Association (CSA), and Electrical Testing
Laboratories (ETL). The independent testing laboratory shall be acceptable to the
inspection authority having jurisdiction.
1.03 SUBMITTALS
The following information shall be provided for all electrical equipment and materials:
Verification of fault withstand and interrupting ratings of all applicable power equipment
and devices.
Interconnection diagrams-The Contractor shall prepare interconnection diagrams
depicting all cable requirements together with their actual terminations as specified below.
Interconnection diagrams shall be drawn similar to the typical interconnection diagram
specified on the drawings. The interconnection diagram shall indicate wiring between
panels, terminal boxes, remotely mour~ted devices, and motor starters. The diagrams
shall interface with the manufacturer's internal connection diagrams for panels. The
diagrams shall indicate the terminations to terminal blocks of field devices at each end of
the cable, the number of conductors in the cable, the size of wire, and the number of
spare conductors. For each termination, the diagrams shall indicate the terminal number,
wire color, and wire number as it appears on the wire marker. All terminal blocks,
including spares, shall be indicated on the diagrams. Interconnection diagrams shall be
provided prior to installation of equipment.
Catalog-cuts including technical specifications, application information, ratings, and other
information required to verify the equipment and/or material meets the requirements of this
specification.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
A copy of this specification section with addenda updates, and ,all referenced sections with
addenda updates, with each paragraph check marked to shoW specification compliance or
marked to show deviations.
Completed test Forms 16000-A and 16000-B.
1.04 PROJECT/SITE CONDITIONS
GENERAL
Unless otherwise specified, equipment and material shall be sized and rated for an
ambient temperature of 40 degrees C at an elevation ranging from sea level to 3000 feet
without exceeding the manufacturer's stated ratings.
PART 2 - PRODUCTS
2.01 GENERAL
Equipment and materials shall be new and free from defects. All equipment of the same
or similar type shall be of the same manufacturer throughout the work. Standard
production materials shall be used wherever possible.
2.02 RACEWAY. FITTINGS. AND SUPPORT
GENERAL:
Conduits shall be provided for power, control, instrumentation, grounding, lighting,
receptacles, and signaling systems.
RACEWAY:
Exposed conduit shall be threaded, galvanized, rigid steel conduit. Minimum size shall be
% inch~- -BUShings shall be galvanized, malleable iron with a feed through compression
lug. Unions shall be galvanized, ferrous alloy type. Threadless fittings are not acceptable. .
Running threads shall not be used in lieu of conduit nipples. . Thread hubs shall be used to
terminate conduits entering boxes.
Liquidtight, flexible steel conduit shall be formed from spirally wound, galvanized steel strip
with successive convolutions securely interlocked and jacketed with liquidtight plastic
cover. Minimum size shall be % inch. Fittings for liquidtight conduifshall have cadmium-
plated, malleable iron body and gland nut with cast-in lug, brass grounding ferrule
threaded to engage conduit spiral and O-ring seals around the conduit and box connection
and insulated throat. Forty five and 90 deg'ree fittings shall be used where applicable.
Embeddec}-or encased conduit shall be schedule 40, high impact, polyvinyl chloride
(PVC). Minimum size shall be 1 inch.
ELECTRICAL - GENERAL PROVISIONS
16000-3
ELECTRICAL - GENERAL PROVISIONS
16000-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Fittings for PVC conduit shall be solvent welded type.
BOXES:
Boxes for tb.e use outdoors and in process areas shall be hot-drip, galvanized cast ferrous
alloy type FD with integrally cast threaded hubs for conduit entry. Boxes larger th'an FD
boxes shall be welded steel and hot-dip galvanized after fabrication.
Boxes installed in areas where electrical metallic tubing is specified shall be standard UL
approved electro-galvanized sheet steel, 4 inch square or octagon minimum trade size.
Conduit bodies shall be ferrous alloy type with screw taps for fastening covers. Gaskets
shall be made of neoprene.
RACEWAY SU?PORT:
Hot-dip galvanized framing channel shall be used to support groups of conduit. Individual
conduit supports shall be one-hole galvanized malleable iron pipe straps with galvanized
iron clamp backs and nesting backs where required. Ceiling hangers shall be adjustable,
galvanized carbon steel rod hangers. Straps or plumbers tape is not acceptable. Hanger
rods shall be % inch all thread rod.
2.03 CONDUCTORS. WIRE. AND CABLE
GENERAL:
Conductors, wires, and cables shall be provided for power, control, lighting, receptacles,
instrumentation, grounding and signal circuits. The quantity and size of conductors shall
be as sp_eclfied.
POWER AND CONTROL CONDUCTORS:
Power and control conductors shall be single conductor stranded, annealed cooper with
600 Volt THWN-2/THHN polyvinyl chloride (PVC) insulation, Okonite, Okoseal-N,
CABLEC; or equal.
LIGHTING AND RECEPTACLE CIRCUIT CONDUCTORS:
Conductors for lighting and receptacle circuits shall be single conductor, annealed copper
with 600 Volt THWN-2 PVC insulation. Conductor sizes NO.1 0 AWG and larger shall be
stranded. Minimum conductor size shall be No. 12 AWG. Conductors shall be Okonite,
Okoseaf:N; CABLEC; or equal.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 1240100
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
GROUNDING CONDUCTORS:
Grounding conductors shall be as specified in this section.
INSTRUMENTATION AND SIGNAL CABLE:
. Cable for illStrumentation and signal circuit shall be twisted shielded pair of triad as
specified, No. 16 AWG 7 -strand copper with 600 Volt PVC insulation, 100 percent
aluminum-Mylar tape shield, NO.18 AWG tinned copper drain wire and overall PVC jacket,
Okonite, Okoseal-N type P-OS, or equal.
SPLICING AND TERMINATING MATERIALS:
CONNECTORS:
Cornectors for stranded conductors shall be tool applied, tin-plated copper, compression
type of the correct size and UL approved for the application.
Connectors for wire sizes No.10 AWG and smaller shall be nylon self-insulated, ring
tongue or locking-space terminals. Connectors for wire sizes NO.8 AWG and larger shall
be one-hole lugs up to size no.3/0 AWG and two-hole or four hole for size 4/0 AWG and
larger. Mechanical clamp, dimple, or screw type connectors are not acceptable.
480 Volt motor terminations shall be made using bolt connected lugged connectors and
factory engineered kits consisting of heat shrinkable, polymeric insulating material with
high dielectric strength mastic sealant.
Termination of solenoid valves, 120 Volt motors and other devices furnished with pigtail
leads shall be made using self-insulating, tubular compression connectors.
TERMINAL BLOCKS:
T erniina~ blocks shall be provided for external control and power wires size NO.10 A WG
and smaller. Terminal blocks shall be 600 Volts, heavy-duty, rated 20 amperes for control
and 30 amperes for power.
WIRE MARKERS:
Wire markers shall be yellow or white shrink tubing, Thermofit Marker System (TMS) by
Raychem Co. I or equal for conductors NO.1 0 AWG and smaller and locking tab cable
markers, W.H. Brady Co., or equal, for conductors NO.8 and larger. Letters and numbers
identifying each conductor shall be machine printed in permanent black ink.
ELECTRICAL - GENERAL PROVISIONS
16000-5
ELECTRICAL - GENERAL PROVISIONS
16000-6
I
I
I
I
I
I
I
,
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 1240100
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
2.04 WIRING DEVICES
GENERAL:
Receptacles, plugs, switches, and appurtenances shall be provided as specified on the
drawings.. Wiring devices shall be UL approved for the current and voltage specified and
shall comply with NEMA WD-1. Receptacles and switches shall be premium, spedfication
grade.
RECEPTACLES:
Receptacles shall be grounding type. Receptacles for use outdoors and in process areas
shall be corrosion resistant, marine duty with polycarbonate weatherproof lift covers,
Hubbell 53CM62/53CM21, General Electric, or equal.
2.05 INDIVIDUAL MOTOR STARTERS:
GENERAL:
Unless otherwise specified, individual motor starters shall be combination type with
molded case motor circuit protector, 3-pole, 600 Volt AC contactor, and three overload
relays, NEMA size 1 minimum. Each motor starter shall be individually enclosed.
ENCLOSURES:
The door of the motor starter enclosure shall be interlocked with an externally operated
disconnect handle, lockable in the open position. Enclosures shall be NAME 12 for dry
indoor areas and NEMA 4X for outdoor and process areas.
MOTOR~ BRANCH PROTECTION:
Molded case motor circuit protectors shall be magnetic only with trip setting$ adjustable
over a range of 700 to 1300 percent of the full load current of the motor served. The
motor circuit protector, in conjunction with the starter, shall be rated to interrupt 22,000
amperes (symmetrical) unless otherwise specified.
OVERLOAD RELAY:
Overload relays shall be bimetallic type with separate heaters for each of the three poles.
Reset shall be accomplished with a reset pushbutton located on the unit door exterior.
Trip setting shall be adjustable from 85 to 115 percent of the motor full load rating.
.". ...:- oJ'
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
CONTROL CIRCUITS:
Control power transformers, fuses, and control devices shall be provided as specified.
Two control transformer primary fuses rated to interrupt 200,000 amperes at 600 Volts,
shall be provided on all motor starters. Each motor starter shall be provided with one
control cTrctJit secondary fuse rated to interrupt 10,000 amperes at 250 Volts and.sized at
125 percent of the control circuit full load current. Control circuit shall be 120 V with
grounded leg.
WIRING:
Conductors shall be switchboard type and rated 90 degrees C above ambient
temperature. Conductor shall be identified with tag numbers as specified.
MANUAL STARTERS:
Manual starters shall be provided as indicated on the drawings. Manual starters shall
consist of a horsepower rated quick-make, quick-break toggle mechanism together with
one or two overloads as specified.
2.06 MOTOR CONTROL CENTER:
See section 16100 for Motor Control Center specification.
2.07 ELECTRICAL CONTROL DEVICES
CONTROL DEVICES
PUSH BUTTONS:
Pushbuttons shall be flush head, heavy-duty, 600 Volts, 10 amperes, continuous with
NEMA rating to match enclosure types. Pushbuttons operators shall be red for stop
functions and black for all other functions. Escutcheon plates shall be as specified on the
drawings.
SELECTOR SWITCHES:
Selector switches shall be heavy-duty, with NEMA rating to match enclosure type, rated
600 Volt, 10-ampere, continuous. Switches shall be provided with contact blocks and
number of positions as required to perform the specified operations. The escutcheon
legend shall be as specified on the drawings.
ELECTRICAL - GENERAL PROVISIONS
16000-7
F&V Project No9? 1240100
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County. Georgia.
INDICATING LIGHTS:
Indicating lights shall be heavy-duty, push-to-test, transformer type with 6.3-Volt lamps.
Indicating lights shall be NEMA rated to match enclosure type.
CONTROL STATIONS:
Unless otherwise specified, control stations shall be NEMA 12 for dry, indoor locations and
NEMA 4X for process areas and outdoor locations, Allen Bradley Bulletin 800H, Crouse-
Hinds NCS series, or equal.
CONTROL RELAYS
LOAD-SWITCHING CONTROL RELAYS:
Control relays used for switching loads (solenoids, actuators, contactors, motor starter
coils, etc.) shall be heavy-duty, machine tool type. Relays that have contacts used for
remote interlocking or for which the switching load is not shown shall also be heavy-duty
machine tool type.
Contacts shall, as a minimum, be 4-pole and be field interchangeable to either normally
open or normally closed. Relay shall be capable of accepting a 4-pole adder.
AC relays shall have NEMA A600 contact rating and electrical clearances for up to 600
Volts. DC relays shall have NEMA P300 contact ratings and electrical clearances of up to
250 Volts.
Relays shall be Allen Bradley Bulletin-700, Square D Class 8501, or equal.
LOGIC LEVEL SWITCHING CONTROL RELAYS:
Control relays used for switching solid-state logic and signal circuits shall be Potter
Blumfield series KUP, Schrack Series RA, or equal. Relays shall have a minimum of three
SPOT, gold-flashed, fine silver contacts rated 3 amps resistive at 120 Volts AC or 28 Volts
DC. Relay shall be plug-in type with heavy-duty, barrier-protected screw terminal sockets
and clear polycarbonate dust cover with clip fastener. AC models shall have neon lamp
indicator wired in parallel with coil.
TIMING RELAYS:
Solid state timing relays shall be pulse-count type using a high frequency RC oscillator
and integrated circuit counter for timing. Electrolytic capacitors shall not be used in the
timing circuits. Time delays from 0.1 seconds to 48 hours shall be available with each
timer model adjustable over a 20:1 range. On-delay, off-delay, and single-shot timing
models shall be available. Timer shall reset in 0.3 seconds or less. Timer accuracy shall
ELECTRICAL - GENERAL PROVISIONS
16000-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
be plus or minus 2.0 percent undernormal conditions. The timing relay shall have two
NEMA Form-C timed contacts. Solid state timing relays shall be Agastat, STA series or
equal.
2.08 GROUNDING MATERIAL:
CABLE: - -
Grounding cable shall be concentric stranded, annealed bare copper. Cable size shall be
as specified.
GROUND RODS:
Ground rods shall be copper-covered steel, % inch diameter, and 10 feet long. Rods shall
have threaded type, removable caps so that extension rods of the same diameter and
length may be added where necessary.
COMPRESSION CONNECTORS:
Compression connectors shall be cast copper as manufacturer by Thomas and Betts, or
equal.
BOLTED CONNECTORS:
Bolted connectors shall be Burndy, O.Z. Gedney, or equal.
2.09 LIGHTING FIXURES
GENERAL
Fixtures shall be aligned and directed to illuminate an area as specified. Fixtures shall be
directly and rigidly mounted on their supporting structures. Unless otherwise specified,
conduit system shall not be used to support fixtures. Where brackets or supports for
lighting fixtures are welded to steel members, the welded area shall be treated with rust-
resistant primer and finish paint.
BALLASTS:
FLUORESCENT MAGNETIC:
Ballasts for fluorescent lamps shall be non-leaking, thermosetting, compound filled, rated
for 120 Volt service unless otherwise specified. Ballasts shall be Class P, protected type,
high power factor and shall carry the Certified Ballast Manufacturer's (CBM) and UL
labels. Ballasts for fixtures located in covered, unheated areas and open areas shall be
low temperature type.
ELECTRICAL - GENERAL PROVISIONS
16000-9
ELECTRICAL - GENERAL PROVISIONS
16000-10
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
2. HIGH PRESSURE SODIUM:
Ballasts for high pressure sodium lamps shall be autotransformer, high power factor type.
Starting current shall not exceed normal running current.
LAMPS:
ACCEPTABLE PRODUCTS:
Lamps shall be General Electric, North American Philips (Norelco), Sylvania, Venture
Lighting International, or equal.
GENERAL:
Unless otherwise specified, fluorescent lamp~ shall be warm white.
Unless otherwise specified high-pressure sodium lamp envelopes shall be clear.
Incandescent lamps shall be rated 130 Volts AC. Unless otherwise specified, lamp shape
shall be standard A or PS and envelope shall be frosted inside.
PHOTOELECTRIC CELL UNITS:
Photoelectric cell units shall consist of a cadmium sulfide cell housed in a plug receptacle
assembly. The plug receptacle assembly shall be three-prong polarized locking type.
Assembly shall be suitable for outdoor mounting and shall be rated for 1800 VA at 120
Volts maximum capacity.
2.10 DISTRIBUTION EQUIPMENT
PANELBOARDS:
Panelboards shall be circuit breakers, dead front type with bus bar construction.
Panelboards shall be composed of individually mounted circuit breakers designed to be
removed without disturbing other breakers.
Bus shall be tin-plated copper and shall have a current rating as shown on the panel
schedules sized in accordance with UL 67. Panel fault withstand rating shall be equal to
the interrupting rating of the smallest circuit breaker in the panel.
Panelboards shall be provided with a separate ground bus and a full capacity neutral bus.
Neutral bus shall be mounted on insulated standoffs with removable link connector to
ground bus. Panelboards shall be Square 0, Cutler Hammer/Westinghouse, Siemens, or
approved equal.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
CIRCUIT BREAKERS
Circuit breakers shall be molded-case type provided for the current ratings and pole
configurations specified on the panelboard schedule. Circuit breaker rated 120/208 Volts
and 120/240 Volts AC shall have a minimum interrupting current rating as indicated on the
drawings: .
Circuit breakers shall be bolt-on type.
Circuit breakers shall be listed in accordance with UL-489 for the service specified.
Load terminals of circuit breakers shall be solderless connectors.
Circuit breakers and panelboards shall be products of the same manufacturer.
DRY-TYPE TRANSFORMERS:
Transformers shall conform to IEEE-C57.12.01 and UL 506. The voltage, frequency,
number of phases, and KVA rating shall be as specified.
Transformers 15 KVA and above shall have a class 220 insulation system in accordance
with NEMA 5T20. Transformers 25 KVA and greater shall be designed not to exceed 80
degrees C temperature rise.
Transformer coils shall be copper or aluminum. Transformer coils 15 KVA and above shall
be impregnated with varnish. Transformer coils 10 KVA and below shall be encapsulated.
Transformers shall have electrically isolated primary and secondary windings. Primary
and secondary winding configurations shall be as specified. Provisions shall be made to
permit separate grounding of the neutral conductor and the enclosure. Single phase
transformers shall be the four winding type.
Transformers 15 KV A and above shall be provided with two 2 % percent full capacity taps
above normal voltage and four 2 % percent full capacity taps below rated voltage on the
primary winding.
Terminal compartments shall be sized to permit termination of cables specified. Terminal
connections shall be made in the bottom third of the enclosure. The terminals shall be
copper and sized for the cable specified.
Transformers rated 15KVA and smaller shall be provided with weatherproof, non-
ventilated enclosures.
ELECTRICAL - GENERAL PROVISIONS
16000-11
ELECTRICAL - GENERAL PROVISIONS
16000-12
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No9? 1240100
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia,
Indoor transformers rated 'greater than 15 KVA shall be provided with drip-proof, ventilated
enclosures. Outdoor transformers shall have weatherproof enclosures.
2.11 NAMEPLATES
Nameplates shall be made from laminated'phenolic plastic. The nominal size of the
nameplates shall be % inch high by 2 inches long. Nameplates shall have black'
backgrounds with 3/1 inch white letters. If abbreviations are required because of space
limitations, abbreviations shall be submitted to the Construction Manager prior to
manufacture. Nameplates shall be fastened using self-tapping stainless steel screws.
The use of adhesives will not be permitted on the outside of enclosures.
2.12 PRODUCT DATA
The following information shall be provided:
Applicable operating and maintenance instructions.
Lighting fixture information as follows:
Polar plots on 8 ~ x 11 inch paper providing candlepower versus angle and foot-Iamberts
(brightness) versus angle for longitudinal and transverse axis.
Table of utilization factors for calculation of illumination levels by the zonal cavity method.
Catalog information describing fixture make, materials, and dimensions.
PART 3 - EXECUTION
3.01 GENERAL
Unless otherwise detailed or dimensioned, electrical layout drawings are diagrammatic.
The Contractor shall coordinate the location of electrical material and equipment with the
work.
Electrical equipment shall be protected from dust, water, and damage.
3.02 RACEWAY. FITTINGS. AND SUPPORTS
GENERAL:
The Contractor shallljmit the number of directional changes of conduit to a total of not
more than 270 degrees in any run between pull boxes. Conduit runs shall be limited to
400 feet, less 100 feet for each 90 degree change in direction.
Signal conduit shall be separated from AC power and control conduits. The minimum
separation shall be 12 inches for rigid steel and 24 inches for PVC conduits.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
EXPOSED CONDUITS:
Metallic conduit shall be assembled to provide a continuous ground path. Joints shall be
made with standard couplings or threaded unions. Bends and offsets shall be made with
a hicky or conduit bending machine or shall be factory pre-formed bends.
Exposed'conduit shall be run on supports spaced not more than 10 feet apart and shall be
constructed with runs parallel and perpendicular to walls, structural members, or
intersections of vertical planes and ceiling. No conduit shall approach closer than 6 inches
to any object operating above 30 degrees C.
Conduit supports shall be secured to concrete walls and ceilings by means of cast-in-
place anchors, die cast, rustproof alloy expansion shields, or cast-flush anchors. Wooden
plugs, plastic inserts, or gunpowder driven inserts are not acceptable as a base for
securing conduit supports.
Liquidtight, flexible steel conduit shall be used for the final connection to equipment,
devices, and instruments where flexibility is required.
The length of liquidtight flexible steel conduit shall not exceed the lesser of 15 times the
trade diameter of the conduit or 36 inches.
EMBEDDED OR ENCASED CONDUIT:
Conduits constructed in concrete which is in contact with earth shall be separated from
earth by at least 3 inches of concrete. Clearances equal to the nominal conduit diameter
but not less than 2 inches, shall be maintained between encased or embedded conduits
except where conduits cross or terminate.
ELECTRICAL METALLIC TUBING
Electrical metallic tubing shall be used only within stud walls and above suspended
ceilings.
3.03 CONDUCTORS. WIRE AND CABLE
GENERAL:
Raceway construction shall be complete, cleaned, and protected from the weather prior to
wire and cable being installed. Pulling wire and cable into conduit shall.be completed
without damaging or putting undue stress on the cable insulation. Soapstone, talc, or UL
listed pulling compounds are acceptable lubricants for pulling wire and cable. Grease is
not acceptable. Nylon pull rope shall be pulled through the conduit immediately after
concrete pour.
ELECTRICAL - GENERAL PROVISIONS
16000-13
ELECTRICAL - GENERAL PROVISIONS
16000-14
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Each power, control, signal, and instrumentation conductor shall be identified at each
terminal to which it is connected utilizing the wire markers specified in paragraph 16000-
2.3 G.
600 VOLT CONDUCTOR AND CABLE
Slack shall be provided in junction and pull boxes. Slack shall be sufficient to allow cable
or conductors to be routed along the walls of the box.
Conductors crossing hinges shall be bundled in groups not exceeding 12 and shall be so
arranged that they will be protected from chaffing when the hinged member is moved.
Raceway fill limitations shall be as defined by NEC and the following:
Lighting and receptacle circuits may be together in the same conduit in accordance with
derating requirements of the NEC. However, lighting and receptacle circuits shall not be
in conduit with other circuits.
Solid wire shall not be lugged nor shall electrical spring connectors be used on any except
for solid wires in lighting and receptacle circuits. Lugs and connectors shall be installed
with a compression tool.
SIGNAL AND INSTRUMENTATION CABLES:
Signal and instrumentation circuits shall be run as individual shield twisted pairs or triads.
Triads shall be used where ever three wire circuits are required. Terminal blocks shall be
provided at cable junction for running signal leads and shield drain wires. Each conductor
shall be identified at such junctions.
Shields shall not be used as a ground path.
3.04 WIRING DEVICES
Switches and receptacles for use outdoors and in process areas shall be mounted in "FD"
type boxes. Unless otherwise specified, switches shall be mounted 48 inches above the
floor. Receptacles shall be mounted 18 inches above the floor in finished areas and 48
inches above the floor in process areas and outdoors unless otherwise specified.
3.05 INDIVIDUAL MOTOR STARTERS:
Individual motor starters shall be mounted with the operating mechanism 48 inches above
the finished floor unless otherwise specified. The Contractor shall size the overload
heater elements to the nameplate full load amperes of the motor served. Motor circuit
protectors shall be adjusted to the lowest setting not causing false tripping.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 124 01 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
3.06 MOTOR CONTROL CENTER:
See section 16100 for Motor Control Center specification.
3.07 MISCELLANEOUS CONTROL DEVICES:
Control stations shall be mounted 48 inches above the floor unless otherwise specified.
3.08 GROUNDING
Electrical equipment and enclosures, metal surfaces of equipment, and metal structural
members shall be grounded. Grounding system shall be provided in compliance with the
NEC and as specified on the drawings.
Embedded and buried cable connections shall be made by cast copper compression
connectors utilizing diamond or hexagon dies and a halld compression tool for wire sizes
2 AWG and smaller and a hydraulic pump and compression laead for wire size 2/0 AWG
and larger. Embedded ground cables and fittings shall be securely attached to concrete
reinforcing steel with tie wires.
Grounding conductors which extend beyond concrete surfaces for equipment connection
shall be extended .a sufficient length to reach the final connection point without splicing.
Grounding conductors which project from a concrete surface shall be located as close as
possible to a corner of the equipment pad, protected by conduit or tenninated in a flush
grounding plate.
Exposed ground connections shall be made by bolted connectors. Exposed grounding
conductors shall be supported by non-corrosive metallic hardware at 4-foot intervals or
less.
Grounding conductors entering enclosures shall be bonded together to the enclosure if it
is meta:iji~:and to metallic racewaywithin terminating at the enclosure. Metal surfaces
shall be cleaned prior to making grounding connections and bonds.
3.09 LIGHTING FIXTURES:
GENERAL:
. ,
The location and type of fixtures and receptacles are shown on the drawings. Raceways
and wire shall be provided from the fixtures, switches, and receptacles to the lighting panel
in accordance with the NEC.
Fixtures labeled to require conductors with a temperature rating exceeding 75 defJrees C
shall be spliced to circuit conductors in a separately mounted junction box. Fixture shall
ELECTRICAL - GENERAL PROVISIONS
16000-15
F&V Project No.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
be connected to junction box using flexible conduit with a temperature rating equal or
greater than that of the fixture.
Photoelectric cells shall be oriented toward the north.
Labels an~ marks, except the UL label, shall be removed from exposed parts of the
fixtures." Fixtures shall be cleaned when the project is ready for acceptance.
3.10 PANELBOARDS:
The Contractor shall type in the circuit descriptions on the circuit directory as shown on the
final drawings or panel schedule.
3.11 TESTING:
GENERAL:
Prior to energizing the electrical circuits, the tests shall be performed as specified. Unless
otherwise specified, a 10QQ-Volt megohmmeter shall be used for resistance
measurements.
The measurements of the tests shall be recorded on the specified forms and provided in
accordance with paragraph 16000-1.03.
INSULATION RESISTANCE MEASUREMENTS:
GENERAL:
General insulation resistance measurements shall be made on conductors and energized
parts of electrical equipment. Minimum acceptable values of insulation resistance shall be
in accordance with the applicable ICEA, NEMA, 'or ANSI standards for the equipment or
materia*-.baitlg tested, unless otherwise specified. The ambient temperature at which
insulation resistance is measured shall be recorded on the test form.
CONDUCTOR AND CABLE TESTS:
The phase-to-ground insulation resistance shall be measured for all circuits 120 Volts and
above except lighting circuits. Measurements may be made with motors and other
equipment connected.
Insulation resistance shall be recorded in a format similar to Form 16000-A, contained in
Section 01999. Insulation with resistance of less than 10 megohms is not accep~aqle.
ELECTRICAL - GENERAL PROVISIONS
16000-16
I
I
I
I
I
I
I
I
I
I
... ~..
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
MOTOR TESTS:
The installed Motor Test Form, 16000-B, shall be completed for each motor after
installation. All motors shall have their insulation resistance measured before they are
connected. Motors 50 HP and larger shall have their insulation resistance measured at
the time of delivery as well as when they are connected. Insulation resistance values less
than 10 megohms are not acceptable.
FUNCTIONALCHECKOU~
Prior to energization of equipment, the Contractor shall perform a functional checkout of
the control circuit. Prior to functional testing, all protective devices shall be adjusted and
made operative. Checkout shall consist of energizing each control circuit and operating
each control, alarm or malfunction device and each interlock in turn to verify that the
specified action occurs. Contractor shall submit a description of his proposed functional
test procedures prior to the performance of functional checkout.
The Contractor shall verify that motors are connected to rotate in the correct direction.
Verification may be accomplished by momentarily energizing the motor, provided the
Contractor confirms that neither the motor not the driven equipment will be damaged by
reverse operation.
GROUNDING SYSTEM TESTS:
The Contractor shall test each grounding connection to determine the ground resistance.
The grounding test shall be IEEE Standard 81. A plot of ground resistance readings for
each isolated ground rod or ground mat shall be provided to the Construction Manager on
81/2 X 11 inch size graph paper. The current reference rod shall be driven at least 100
feet from the ground rod or grid under test. The measurements shall be made at 10-foot
intervals beginning 25 feet from the test electrode and ending 75 feet from it, in direct line
between the ground rod or center of grid and the current reference electrode.
A grounding system that shows greater than 2 ohm resistance for the flat portion of the
plotted data shall be considered inadequately grounded. The Contractor shall add
additional parallel connected ground rods and/or deeper driven rods until the ground
resistance measurements meet the 2 ohm requirement. Ground rods required over that
specified will be paid for as extra work. Use of salts, water, or compounds to attain the
specified ground resistance is not acceptable.
ELECTRICAL - GENERAL PROVISIONS
16000-17
1-
ELECTRICAL - GENERAL PROVISIONS
16000-18
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 124 01 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
3.12 RECORD DRAWINGS:
Record drawings refer to those documents maintained and annotated by the Contractor
during construction include record drawings, and the following additional schedules, lists,
and drawings:
Interconnection Diagrams (16000, part 1)
Original Submittal Drawings (16000, part 1)
END OF SECTION 16000
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 1240100
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
FORM 16000-A
WIRE AND CABLE RESISTANCE TEST DATA FORM
Wire or Cable No.:
Location of Test
1.
2.
3.
4.
5.
6.
7.
8.
9.
10.
11.
12.
Certified
Contractor's Rep
Witnessed
Owner's Rep
ELECTRICAL - GENERAL PROVISIONS
Temperature, F
Insulation Resistance
Megohms
Date:
Date:
16000-19
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
FORM 16000-B
INSTALLED MOTOR TEST FORM
Motor Equipment Number
Date of Test
Equipment Driven
MCC Location
Ambient Temperature
Resistance:
Insulation resistance phase-to-ground megohms:
Phase A
Phase B
Current at Full Load:
Phase A
Phase B .
Thermal Overload Device: Manufacturer/catalog number
Amperes
Circuit Breaker (MCP) setting:
Motor Nameplate Markings:
Mfr
Mfr type
Frame
Volts
Phase RPM
Service Factor
Amps_ Freq_ Ambient temp. rating
Time rating
(NEMA 1-10.35)
Design letter
(NEMA MG-1.16)
Code Letter
Insulation class
Certified
Date:
Contractor's Rep
Witnessed
Date:
Owner's Rep
ELECTRICAL - GENERAL PROVISIONS
Phase C
Phase C
HP
16000-20
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
SECTION 16100 - 600 VOLT MOTOR CONTROL CENTERS
PART 1 - GENERAL
1.01 DESCRIPTION:
A.' SCOPE:
This section specifies freestanding, factory assembled 600 volt motor control centers
(MCC).
8. EQUIPMENT LIST:
MCCs specified herein shall be furnished by a single manufacturer. Refer to the
drawings for additional motor control center requirements.
1.02 REFERENCES
This section contains references to the following documents. They are a part of this
section as specified and modified. In case of conflict between the requirements of
this section and those of the listed documents, the requirements of this section shall
prevail.
Reference
Title
ANSI/NEMA ICS 1-88
General Standards for Industrial Controls and Systems
ANSI/NEMA ICS 2-88
Industrial Control Devices, Controllers and Assemblies
JIC EMP 1-67
Electrical Standards for Mass Production Equipment
UL 845-88
Motor Control Centers
1.03 SUBMITTALS
The following information shall be provided:
1. Elementary connection and interconnection diagrams as required in
paragraph 16100-2.07, in accordance. with JIC EMP 1 and/or NEMA
ICS standards.
2. Time current curves for all protection devices.
3. List of starters and feeder tap compartments indicating the size and
type of circuit protection.
600 VOLT MOTOR CONTROL CENTER
16100-1
600 VOLT MOTOR CONTROL CENTER
16100-2
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
4. Interrupting, withstand and continuous current rating of:
a. Bus bars
b. Feeder tap units
c. Starter units
d. Main incoming units
5. A copy of this specification section with addenda updates and all
referenced sections with addenda updates, with each paragraph
check marked to show specification compliance or marked to show
deviation.
6. Manufacturer's certification and calculations that the equipment
complies with the seismic requirements of section 16000.
7. Manufacturer's certification that the following items are capable of
interrupting and/or withstanding the specified short circuit condition:
a. Bus bar bracing
b. Feeder tap units
c. Starter units
8. Dimensions and weights.
9. Installation instructions.
10. Manufacturer's product data.
PART 2 - PRODUCTS
2.01 ACCEPTABLE PRODUCTS
Motor control centers shall comply with ANSI/NEMA ICS 2-322, AC General-
Purpose Motor Control Centers, and UL 845 and shall be Square 0, or equal.
2.02 SERVICE
Motor control centers shall be rated 600 volts, 60 hertz, 3 phase, 3- or 4-wire as
specified and shall be suitable for operation at the specified voltages and short circuit
capacities.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
2.03 STRUCTURE AND CONSTRUCTION
A. STRUCTURE:
Motor control centers shall be made of No. 14 gage steel minimum and each
section shall be 90 inches high by 20 inches wide by 20 inches deep. The
individual unit compartments shall be a minimum of 12 inches high. There
shall be 72 inches available for stacking starter units. Compartments shall
.have pan-type doors with a minimum of two quarter-turn hold-down latches;
and neoprene gaskets.
A full height vertical wireway, 20 square inch minimum, shall be provided for
each vertical motor control center section. The wireway shall contain full
height removable doors. Horizontal wireways shall be provided top and
bottom, extending the length of motor control centers.
Bottom channel sills shall be mounted front and rear of the vertical sections
extending the full length of the motor control center lineup. A removable
lifting angle shall be mounted on top and shall extend the width of the motor
control center lineup.
B. CONSTRUCTION:
Motor control centers located indoors shall have NEMA 1, gasketed enclosures;
motor control centers located outdoors shall be in a NEMA-3R weatherproof
non-walk-in enclosure; motor control centers located aUhe process area shall
be in a NEMA 12 enclosure.
Starter units, size 4 and smaller, and feeder tap units less than 225 amperes
shall be drawout plug-in construction with hardened, plated copper free-floating
stabs, steel spring backups. The door shall have interference tabs which
prevent door closure if.unit i~ improperly installed. Units shall be latched in the
position to assure proper bus contact. The unit disconnect device shall be
interlocked to prevent removal or reinsertion of a unit when the disconnect is in
the "ON" or "TRIPPED" positions..
Circuit breaker disconnect operators shall be capable of accommodating three
padlocks for locking in the "OPEN" position.
Hardware for mounting future starter and feeder tap units shall be provided at
compartments specified as "FUTURE."
2.04 (NOT USED)
600 VOLT MOTOR CONTROL CENTER
16100-3
600 VOLT MOTOR CONTROL CENTER
16100-4
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F& V Project NO.9? 124 01 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
2.05 FINISH AND COLOR
The finish and color shall be in accordance with paragraph 16000-2.01.
2.06 BUS
A. GENERAL:
Bus shall be tin-plated copper with bolted connections between vertical and
horizontal bus bars. Access for tightening these connections shall be from the
front, without the need for tools on the rear of the connection. Insulated
horizontal and vertical bus barriers shall be provided. Barriers shall be
fabricated from high-strength, glass-filled polyester resin. Unless otherwise
specified, the bus shall be braced to withstand a fault current of
25,000 amperes, RMS, symmetrical.
B. HORIZONTAL BUS:
Unless otherwise specified, the main horizontal bus shall be rated a minimum
800 amperes continuous.
C. VERTICAL BUS:
Unless otherwise specified, the vertical bus shall be rated a minimum
300 amperes continuous.
D. NEUTRAL BUS:
Where specified, a neutral bus shall be provided. The neutral bus shall have
the same rating as the main horizontal bus.
E "GROUND BUS:
A 1/4-inch by 2-inch ground bus shall be provided the full length of the motor
control center. Ground bus shall be located at the bottom of the motor control
center. Provide a lug to terminate a bare 4/0 AWG copper ground conductor at
each end of the ground bus.
2.07 WIRING
A. GENERAL:
Motor control centers shall be provided with NEMA Class II, Type B wiring. All
starter units shall have terminal blocks for control wiring. Terminal blocks shall
be provided for power wiring for starters size 2 and smaller. Motor control
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
centers shall be provided with all necessary interconnecting wiring and inter-
locking. Provide elementary and connection diagrams for each starter unit and
an interconnection diagram 'for the entire motor control center. Additional
terminal blocks shall be provided as shown on control diagrams.
B. POWER WIRE:
Power wire shall be copper 90 degrees C "MTW' insulated, sized to suit load;
minimum power wire size shall be No. 12 AWG copper stranded.
C. CONTROL WIRE:
Control wire shall be No. 16 AWG stranded copper wire, rated 90 degrees C
and UL listed for panel wiring.
D. TERMINATIONS AND CABLE CONNECTIONS:
1. TERMINALS: Control wiring, and power wiring for sizes NO.1 0 AWG and
smaller shall be lugged with ring-tongue or locking spade crimp type
terminals made from electrolytic copper, tin-plated.
2. CABLE CONNECTORS: Cable connectors for use with stranded copper
wire, sizes NO.8 AWG to 1000 MCM, shall be UL listed. Dished conical
washers shall be used for each bolted connection. Connectors shall be
reusable and shall be rated for use with copper conductors. Incoming line
and outgoing feeder compartments shall be provided with crimp type lugs,
3M, Burndy, or equal.
E. CONDUCTOR MARKERS:
Markers used for identification shall meet the requirements of section 16000.
2.08 FEEDER BRANCH CIRCUIT PROTECTION
A. GENERAL: .
Feeder tap unit shall consist of circuit breakers, as specified for feeder branch
circuit protection.
B. (NOT USED)
C. CIRCUIT BREAKERS (THERMAL MAGNETIC):
Thermal-magnetic circuit breakers shall be molded case equipped with toggle
type handle, quick-make, quick-break over center switching mechanism that is
600 VOLT MOTOR CONTROL CENTER
16100-5
600 VOLT MOTOR CONTROL CENTER
16100-6
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project No.9? 1240100
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
trip-free so that breaker cannot be held closed against short circuits and
abnormal currents. The tripped position shall be clearly indicated by breaker
handle maintaining a position between "ON" and "OFF." All poles shall open,
close, and trip simultaneously. Minimum short circuit capacity shall be
42,000 amps symmetrical.
2.09 MOTOR STARTER UNITS
A. GENERAL:
Motor startefunits shall be combination type with contactor and motor circuit
protector as specified on the drawings. The starter units shall have a minimum
combination UL listing of 22,000 amps RMS, symmetrical or as specified in the
schedule.
B. (NOT USED)
C. MOTOR CIRCUIT PROTECTORS:
The molded case motor circuit protector shall operate on the magnetic principle
with a current sensing coil in each of the three poles to provide an
instantaneous trip for short circuit protection. The trip setting shall be adjustable
from 700 to 1300 percent of the motor full load amperes from the front of the
breaker. The motor circuit protector shall be set at its lowest position at the
factory .
D. CONTROL TRANSFORMERS:
Each control transformer shall be rated 480/240-120V, single phase, 2 wire,
60 Hz. Unless otherwise specified, the transformer shall be sized for the load it
_ feeds but shall not be less than the minimum ratings as follows:
NEMA starter size
Minimum transformer
volt-ampere rating
1
2
3
4
100
150
200
300
Each control transformer shall be provided with time-delay, slow-blow secondary
fuse rated to interrupt 10,000 amperes short circuit at 250 volts AC. Two
primary fuses rated to interrupt 200,000 amperes at 600 volts shall be provided
on all starters.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 1240100
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
Fuse holder for secondary fuse shall be drawout indicating type and mounted on
the door of the compartment. Fuse holders for primary fuses shall be fuse clips
with full barriers between fuses.
E. CONTACTORS:
Unless atherwise specified, contactors shall be full valtage, 3-pole, 600 volt AC,
NEMA size 1 minimum. Contacts shall be double break, silver-cadmium axide,
and weld resistant. Contacts shall be isolated to prevent arcing. Coils and
magnets shall be capable of being removed ar replaced without special tools.
F. TRANSIENT SURGE SUPPRESSOR:
A transient surge suppressor shall be provided in each starter. Suppressor shall
be encapsulated in a small module suitable for mounting directly to the starter
coil. AdditioLal panel space for suppressor shall not be required. Suppressors
shall be rated 120V AC.
G. AUXILIARY CONTACTS:
Contactars shall be equipped with auxiliary contacts, rated 10 amperes at
120 volts AC. Unless atherwise specified on the drawings, each contactar shall
be equipped with two. narmally open and two. normally closed electrically
isalated auxiliary cantacts. Auxiliary contacts shall be wired aut to. terminal
blocks. Refer to drawings far actual quantities required.
H. OVERLOAD RELAY:
The averlaad relay with three heater elements shall protect the power wiring and
mator from excessive avercurrents. The relay shall be ambient compensated
and have adjustment from 90 to 110 percent of the normal heater rating. The
--. sensing element shall be bimetal type and conform to ANSI/NEMA ICS
2-222.06, Class 20 tripping time.
I. TERMINAL BLOCKS:
Terminal blocks shall be screw type rated 600 volts; 20 amperes for control
wiring and 30 amperes power wiring (starters size 3 and larger shall terminate
the power leads directly to the contactor). The number of terminal blocks shall
be specified an the drawings. Terminal blocks shall be provided with integral
marking strips and shall be permanently marked with the conductor number as
specified on the drawings. Internal wiring shall be connected o.n one side of the
terminal block; outgoing conductors shall be connected to the other side.
600 VOLT MOTOR CONTROL CENTER
16100-7
600 VOLT MOTOR CONTROL CENTER
16100-8
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
2.10 MISCELLANEOUS
A. GENERAL:
Control devices such as pushbuttons, selector switches, indicating lights and
overload reset pushbuttons shall be mounted on the unit compartment ~oor.
B. NAMEPLATES:
Nameplates shall be provided in accordance with the requirements of section
16000. Nameplates shall be provided for all cubicles and compartments. A
Nameplate shall be provided identifying the motor control center.
2.11-2.13(NOTUSED
2.14 METERING COMPARTMENT
Metering compartment shall include the following:
3 - current transformer
1 - AC ammeter, indicating type
1 - Ammeter transfer switch
1 - AC voltmeter, indicating type
1 - voltmeter transfer switch
1 - set of fuses
Meters shall be provided as per specification Section 16440.
2.15 SPARE PARTS
One set consisting of the following spare parts shall be provided:
1 - set each fuse size and type
10 - indicating light bulbs
PART 3 - EXECUTION
3.01 GENERAL
The motor control centers shall be erected in accordance with the recommendations
of the manufacturer and with the details specified herein.
Field wiring shall meet the requirements of section 16000. Cables larger than NO.6
AWG which hang from their vertical connections shall be supported within 2 feet of
the connection.
I
I
I
I
I
I
I'
I
I
I
I
I
I
I
I
I
I
I
I
F&V Project NO.9? 12401 00
Digester Modifications - Messerly Wastewater Treatment Plant
Augusta-Richmond County, Georgia.
The overload relay heater elements shall be provided by the Contractor and
sized based on the actual full load amperes of the motor connected to the starter.
The motor circuit protectors shall be adjusted by the Contractor to the lowest
setting not causing false tripping.
600 VOLT MOTOR CONTROL CENTER
16100-9