Loading...
HomeMy WebLinkAboutPepperidge Drive Intersection Improvement Augusta Richmond GA DOCUMENT NAME: ~\0Cpf Of \\J~ \ntexSecnCXl \ru~Y()\JeM-eyTi DOCUMENTTYPE:~CAcS~ YEAR: BOX NUMBER: 0 ~ FILE NUMBER: \ '6 ddO NUMBER OF PAGES: \ l L\ I I I I I I: I I I I' I' I' I I I ;1 I I ,I '&7~ ~ 13;J;J~ CONTRACT DOCUMENTS FOR PEPP,ERIDGE DRIVE INTERSECTION IMPROVEMENTS PROJECT NO. 51-8691-094 GEORGIA DOT PROJECT NO.:TSAP-121(4-6)RICHMOND I I I I I I I I I I I I I I I I I I I LIST OF PROJECT DOCUME~ Pepperidge Drive Intersection Improvements Project Number: 51-8691-094 SECTION PAGES Instruction to Bidders IB-1 thru IB-3 Georgia Prompt Pay Act PPA-1 Minority and Economically Disadvantaged Business Support Special Conditions ME-1 SP-1 thru SP-2 A-1 thru A-4 1 thru 33 SC-1 thru SC-2 P-1 thru P-4 G-1 thru G-13 TC-1 thru TC-23 CC-1 thru CC-24 Agreement General Conditions Supplementary Conditions Proposal General Notes Traffic Control County Contract Specs. Plans 1 thru 6 I I I I I ,I I I I I I I I I I I I I I SECTION IB INSTRUCTION TO BIDDERS IB-01 GENERAL All proposals must be presented in a sealed envelope, addressed to the 'Owner. The proposal must be filed with the Owner on or before the time stated in the invitation for bids. Mailed proposals will be treated in every respect as though filed in person and will be subject to the same requirements. Proposals received subsequent to the time stated will be returned unopened. Prior to the time stated any proposal may be withdrawn at the discretion of the bidder, but no proposal may be withdrawn for a period of sixty (60) days after bids have been opened, pending the execution of contract with the successful bidder. IB-02 EXAMINATION OF WORK Each bidder shall, by careful examination, satisfy himself as to the nature and location of the work, the conformation of the ground, the character, quality and quantity of the facilities needed preliminary to and during the prosecution of the work, the general and local conditions, and all other matters which can in any way affect the work or the cost thereof under the contract. No oral agreement or conversation with any officer, agent, or employee of the Owner, either before or after the execution of the contract, shall affect or modify any of the terms or obligations therein. IB-03 ADDENDA AND INTERPRETATIONS No interpretation of the meaning of plans, 'specifications or other prebid docum~nts will be made to any bidder orally. . , Every request for such interpretation should be in writing addressed to the Director of Public Works, 1815 Marvin Griffin Road, Augusta, Georgia 30906, and to be given consideration must be received at least five days prior to the date fixed for the opening of bids. Any and all such interpretations and any supplemental instructions will be in the form of written addenda to the specifications which, if issued, will be sent by certified mail with return receipt requested to all prospective bidders (at the respective addresses furnished for such purposes), not later than three days prior to the date fixed for the opening of bids. Failure of any bidder to receive any such addendum or interpretation shall not relieve such bidder from any obligation under his bid as submitted. All addenda so issued shall become part of the Contract Documents. IB-1 I I I I I I I I I I I I I I I I I I I IB-04 PREPARATION OF BIDS Bids shall be submitted on the forms provided and must be signed by the bidder or his authorized representative. Any corrections to entries made on bid forms should be initialed by the person signing the bid. Bidders must quote on all items appearing on the bid forms, unless specific directions ,in the advertisement, on the bid form, or,in the special specifications allow for partial bids. Failure to quote on all items may disqualify the bid. When quotations on all items are not required, bidders shall insert the words "no bid" where appropriate. Alternative bids will not be considered unless specifically called for. Telegraphic bids will not be considered. Modifications to bids already submitted will be allowed if submitted by telegraph prior to the time fixed in the Invitation for Bids. Modifications shall be submitted as such, and shall not reveal the total amount of either the original or revised bids. Bids by wholly owned proprietorships or partnerships will be signed by all owners. Bids of corporations will be signed by an officer of the firm and his signature attested by the secretary thereof who will affix the corporate seal to the proposal. NOTE: A 10% Bid Bond is required in all cases. IB-05 BASIS OF AWARD The, bids will be compared on the basis of unit prices, as extended, which will include and cover the furnishing of al.l. material and, the performance of al.l. l.abor requisite or proper, and compl.eting of al.l. the work cal.l.ed for under the accompanying contract, and in" the manner set forth and described in the specifications. Where estimated quantities are included in certain items of the proposal, they are for the purpose of comparing bids. While they are believed to be close approximations, they are not guaranteed. It is the responsibility of the Contractor to check all items of construction. In case of error in extension of prices in a proposal, 'unit bid prices shall govern. IB-2 I I I I I I I I I I I I I I I I I I I IB-06 BIDDER'S OUALIFICATIONS No proposal will be received from any bidder unless he can present satisfactory evidence that he is skilled in work of a similar nature to that covered by the contract and has sufficient assets to meet all obligations to be incurred in carrying out the work. He shall submit with his proposal, sealed in a separate envelope, a FINANCIAL EXPERIENCE AND EQUIPMENT STATEMENT, giving r~liable information as to working capital available, plant equipment, and his experience and general qualifications. The Owner may make such investigations as are deemed necessary to determine the ability of the bidder to perform the work and the bidder shall furnish to him all such additional information and data for this purpose as may be requested. The Owner reserves the right to reject any bid if the evidence submitted by the bidder or investigation of him fails to satisfy the Owner that such bidder is properly qualified to carry out the obligations of the contract and to complete the work contemplated therein. Part of the evidence required above shall consist of a list of the names and addresses of not less than five (5) firms or corporations for which the bidder has done similar work. IB-07 PERFORMANCE BOND At the time of entering into the contract, the Contractor shall give bond to the Owner for the use of the Owner and all persons doing work or furnishing skill, tools, machinery or materials under or for the purpose of such contract, conditional for the payment as they become due, of all just claims for such work, tools, machinery, skill and terms, for saving the Owner harmless from all cost and charges that may accrue on account of the doing of the work specified, . and for compliance with the laws pertaining thereto. Said bond shall be for the amount of the contract satisfactory to the Owner and authorized by law to do business in the State of Georgia. Atto~neys-in-fact who sign bonds must file with each copy thereof a certified and effectively dated copy of the power of attorney. ' IB-08 REJECTION OF BIDS These proposals are asked for in good faith, and, awards will be made as soon as practicable, provided satisfactory bids are received. The right is reserved, however to waive any informalities in bidding, to reject any and all proposals, or to accept a bid other than the lowest submitted if such action is deemed to be in the best interest of the Owner. IB-3 I I I I I I I I I I I I I I I I I I I GEORGIA PROMPr PAY ACT This contract is intended by the parties to, and does, supersede any and all provisions of the Georgia Prompt Pay Act, O. C. G. A. section 13-11-1, et seg. . In the event any provision of this Contract is inconsistent with any provision of the Prompt Pay Act, the provision of this contract shall control. NOTICE All references in this document, which includes all papers, writings, drawings, plans or photographs to be used in connection with this document, to "Richmond County Board of Commissioners" shall be deemed to mean "Augusta-Richmond County Commission- Council and all references to "Chairman" shall be deemed to mean "Mayor". DISPOSALS Prior to any material from this project being wasted or otherwise disposed of outside the proj ect li1[11 ts the Contractor shall furnish the Engineer a copy of written permission, signed by the - property owner (or his authorized agent) describing the estimated amount and type of material to be placed on said property. If any portland' cement concrete, asphaltic concrete, wood or other such- materials are to be wasted on the property, a copy of the owner's inert landfill permit, issued by the Environmental Protection Division shall be furnished to the Engineer prior to any such waste being removed from the project. In all cases, regardless of the material being wasted, a grading permit issued by Augusta-Richmond County must be furnished to the Engineer. PPA-1 I I I I I I I I I I I I I I I I I I I XINORITY AND ECONOMICALLY DISADVANTAGED BUSINESS SUPPORT It is the intent of the Augusta-Richmond County- council to increase the involvement of qualified minority and economically disadvantaged businesses in the contracted work of County Government. In an effort to support this intention, this project is offered to all qualified firms. The bids will be evaluated based on qualifications, price and construction time. with all other items being considered equal, the contract, if awarded will be awarded to a minority and economically disadvantaged firm or a firm that has included such firms as subcontractors on this project. The bidders shall include with their bid a statement of qualification for themselves and/or any qualified subcontractors explaining why they should be considered a minority or economically disadvantaged firm. If the firm does not fall into this category, no information is necessary. ME-l I I I I I I I I I I I I I I I I I I I PEPPERIDGE DRIVE INTERSECTION IMPROVEMENTS project Number: 51-8691-094 SPECIAL CONDffiONS SCOPE: This project includes decel and accel lanes, reworking the pepperidge Drive entrance and traffic signal adjustments in accordance with the specifications and plans. The Contractor shall supply all materials, equipment, labor and supervision necessary to properly complete this project. TERMINI AND LENGTH: (See Plans) LUMP SUM CONSTRUCTION: Item Number 230-1000 Lump Sum Construction includes, but is not limited to, the following: Locating, maintaining and reclaiming disposal and/ or borrow areas, construction staking, removals and relocations not covered by a separate pay item, excavation, borrow, sawing pavement, traffic control, removing and resetting of other work obstructions, concrete right of way markers and any other work not covered by a specific pay item. TRAFFIC SIGNAL ADJUSTMENT: The Contractor shall bid on Item NUmber 639-5000 Prestressed Concrete Str~in Poles, Type IV, and said bid price shall include all required materials, labor and supervision necessary to accomplish all traffic signal modifications including two new Concrete strain Poles, Type IV, two Concrete Control Box Bases. It is the Contractor's responsibility to coordinate all phases of the Traffic Signal Modification with Augusta-Richmond County Traffic Engineering and Augusta-Richmond County's Construction Inspector. Priority Number 1: Contractor to set new concrete strain poles. Mike Amerson of Augusta-Richmond County Traffic Engineering must be notified 48 hours in advance of any signal work so they can install all conduit for the new control box SP-I I I I I I I I I I I I I I I I I I I I bases and to the junction boxes. Pour two new concrete bases for relocated control box and Pedestrian Signal Box. Mike Amerson may be contacted at 821-1842. Priority Number 2: Contractor to attach new signal cable and guy wires to new strain poles. At this time Augusta-Richmond County Traffic Engineering must relocate the existing control box and Pedestrian Signal Box to the new concrete bases and hook up all signal cables for this intersection. All this shall be coordinated by the Contractor. Priority Number 3. The Contractor shall remove and dispose of two existing strainpoles. Once roadway construction begins the Contractor shall notify Augusta-Richmond County Traffic Engineering so they can install the conduit and junction boxes for the new Pedestrian Head. Coordination of all signal work is the responsibility of the Contractor. Material and Enqineerinq: installation supplied by Traffic Control Box Pedestrian pole All guy wire All signal cable One ped head All loop cable One 5 piece signal head if needed All junction boxes All interconnect cable All lead-in cable All loop detectors as needed All loop sawing Materials and installation supplied by Contractor: 2 concrete traffic signal poles 2 concrete control box bases. Contact person for Augusta-Richmond County Traffic Engineering is Mike Amerson at (706)821-1842 (Pager Number 732-1942) No work involving Traffic Signal Adjustment started without a minimum of 48 hours notification to Mike Amerson. can be advance SP-2 I I I I ,I I I I I I I I I I I I I I ~, I \ SECTION A AGREEMENT THIS AGREEMENT, made on the ___ day of , 19___ by and between Auqusta-Richmond County Commission-Council party of the first part, hereinafter called the OWNER, and APAC-Georqia, Incorporated party of the second part, hereinafter called the CONTRACTOR. WITNESSETH, that the Contractor and the Owner, for the considerations hereinafter named, agree as follows: ARTICLE I - SCOPE OF THE WORK The Contractor hereby agrees to furnish all~of the materials and all of the equipment and labor necessary, and to perform all of the work shown on the plans and described in the specifications for the project entitled: Pepperidge Drive Intersection Improvements Project Number: 51-8691-094 and in accordance with the requirements and provisions of the Contract Documents as defined in the General and Special Conditions hereto attached, which are hereby made a part of this agreement. ARTICLE II - TIME OF COMPLETION - LIQUIDATED DAMAGES commenced notice by shall be extensions Cc:;mdi tions. The work to be performed under this Contract shall be within ~ calendar days after the date of written the Owner to the Contractor to proceed. All work completed within 100 calendar days with such of time as are provided for in the General It is hereby understood and mutually agreed, by and between the Contractor and the Owner, that the date of beginning, rate of progress and the time for completion of the work to be done hereunder are ESSENTIAL CONDITIONS of this contract. Contractor agrees that said work shall be prosecuted regularly, diligently, and uninterruptedly at such rate of progress as will insure full completion thereof within the time' specified. It is expressly understood and agreed by and between the Contractor and the Owner I that the time for completion of the work described herein is a reasonable time for ,completion of the same, taking into consideration the average climatic range and construction conditions prevailing in this locality. A-1 I I I I I I I I I I I I I I I I I I I IF THE CONTRACTOR SHALL NEGLECT, FAIL, OR REFUSE TO COMPLETE THE WORK WITHIN THE TIME HEREIN SPECIFIED, then the Contractor does hereby agree, as a part of the consideration for the awarding of this contract, to pay the Owner the sum of Five Hundred Dollars CS500l, not as a penalty, but as liquidated damages for such breach of contract as hereinafter set forth, for each and every calendar day that the Contractor shall be in default after the time stipulated in the Contract for completing the work. The said amount is fixed and agreed upon by and between the Contractor and the Owner because of the impracticability and extreme difficulty of fixing and ascertaining the actual damages the Owner would, in such event, sustain, and said amounts shall be retained from time to time by the Owner from current periodical estimates. It is further agreed that time is of the essence of each and every portion of this Contract and the specifications wherein a definite portion and certain length of time is fixed for the additional time is allowed for the completion of an work, the new time limit fixed by extension shall be the essence of this contract. ARTICLE III - PAYMENT (a) The Contract Sum The Owner shall pay to the Contractor for the performance of the Contract the amount as stated in the Proposal and Schedule of Items. No variations shall be made in the amount except as set forth in the specifications attached hereto. (b) Proaress Payment . On no later than the fifth day every month, the Contractor shall submit to the Owner's Engineer an estimate covering the percentage of the total amount of the Contract which has been completed from the start of the job up to and including the last working day of the proceeding month, together with such supporting evidence as may be required by the Owner and/ or the Engineer. This estimate shall include only the quantities in place and at the unit prices as set forth in the Bid Schedule. On the vendor run following approval of the invoice for payment, the Owner shall after deducting previous payments made, pay to the Contractor 90% of the amount of the estimate on units accepted in place. The 10% retained percentage may be held by the Owner until the final completion and acceptance of all work under the Contract. A-2 I I I I I I I I I I I I I I I I I I I ARTICLE IV - ACCEPTANCE AND FINAL PAYMENT (a) Upon receipt of written notice that the work is ready for final inspection acceptance, the Engineer shall within 10 days make such inspection, and when he finds the work acceptable under the Contract and the Contract fully performed, he will promptly issue a final certificate, over his own signature, stating that the work required by this Contract has been completed and is a,ccepted by him under the terms and conditions thereof, and the entire balance found to be due the Contractor, including the retained percentage, shall be paid to the Contractor by the owner within ,15 days after the date of said final certificate. (b) Before final payment is due, the Contractor shall submit evidence satiSfactory to the Engineer that all payrolls, material bills, and other indebtedness connected with work have been paid, except that in case' of disputed indebtedness of liens of evidence of payment of all such disputed amounts when adjudicated in cases where such payment has not already been guaranteed by surety bond. (c) The making and acceptance of the final payment shall constitute a waiver of all claims by the Owner, other than those arising from unsettled liens, from faulty work appearing within 12 months after final payment, from requirements of the specifications, or from manufacturer's guarantees. It shall also constitute a waiver of all claims by the Contractor except those previously made and still unsettled. (d) If after the work has been substantially completed, full completion thereof is materially delayed through no fault of the Contractor, and- the Engineer, so certifies, the Owner shall upon certification of the Engineer, and without terminating the Contract, make payment of the balance due for that portion of the work fully completed and accepted. Each payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. A-3 ..T ~ .i PERFORMANCE BOND LIBERTY fe BOND SERVICES. Bond Number: 1 4 0 0 0 02 5 0 :2 3 3 KNOW ALL MEN BY THESE PRESENTS, that we APAC-Georgia, Inc. , as Principal (the "Principal"), and Liberty Mutual Insurance Company, a mutual company duly organized under the laws of the Commonwealth of Massachusells, as Surety (the "Surety"), are held and firmly bound unto Augusta-Richmond County Commission-Council , as Obligee (the "Obligee"), in the penal sum of One Hundred Forty Seven Thousand One Hundred Seventy Three & 75/100--- Dollars ($ 1 47 , 1 73 . 75 ), for the payment of which sum well and truly to be made, the Principal and the Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. W_H_EJ~EAS,,!he Principal has by written agreement, dated (ihe '~Contract") with the Obligee for .. ."..,...;.~- , 19 ' , entered into a contrac' _~~Pepp~ridge Drive Intersection Improvements Project Number: 51-8691-094 which Contract is by reference made a part hereof. ,...''NOW;>IH'ERI;FORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the Principal shall promptly and faithfully ...,.,',. =perfor,"!",:_:t~'e:,.'Contract, then this obligation shall be null and void; otherwise it shall remain in full force and f :.,.' ~ffecr.- "..> -:::_. : - -.- ..... ......:::;. ". ~.::.- :---:.- ..--' , - PRO\/./DED3\:ND SUBJECT TO THE CONDITIONS PRECEDENT: .~ .- ~_: :: r:' :1'.-';: -Whe.ri~-~e'r 'the Principal shall be, and be declared by the Obligee to be in default under the Contract, the Obligee having " " ' .: .;- ~p~rtormed the Obligee's obligations thereun.der, the Surety may promptly remedy the default, or shall promptly: 1,1 Compete the Contrac,t in accordance with its terms and conditions, or 1,2 Obtain a bid or bids from alternative contractors to complete the Contract in accordance with its terms and condi'ions, and upon determination by the Surety of the lowest responsible bidder, or if the Obligee elects, upon determination by the Obligee and the Surety jointly of the lowest responsible bidder, arrange for a contract be'ween such bidder and the Obligee, and make available as work progresses (even though there should be a defaul! or a succession of defaults under the contract or contracts of completion arranged under this paragraph) sufficient funds to pay t1W cost of completion Jess the balance of the contract price; but not exceeding, including other costs and damages for which the Surety may be liable hereunder, the amount set forth in the first paragraph of this bond. The term "balance of the contract price," as used in this paragraph, shall mean the total amount payable by the Obligee to the Principal under the Contract and any amendments thereto, less the amount properly paid by the Obligee to the Principal. 2. Notwithstanding any other provision of this bond or the Contract, or otherwise, the Surety is not responsible for and shall not be held liable to the Obligee for any hazardous waste removal and the Surety shall not be held liable to, or ifi any other respect be responsible to, the Obligee by way of indemnity, claims or otherwise, or to any public authority or to any other person, firm or corporation, for or on account of any fines or claims by any public authority or for bodily injuries or property damage to any person or thing, including, but not limited to, injury or damage due to the release or threat of release of hazardous substances of any kind or damage to real estate or to the environment or clean-up costs or other damages of whatever kind or nature arising out of any act of commission or omission by the Principal, the Principal's agents, servants, employees, subcontractors or suppliers or any other person in connection with the performance of the Contract. This limitation applies regardless of when any such fine is assessed, claim is made, or injury, damage, release or threat of release occurs and without regard to any term or condition of the Contract. LBS-5100 8/94 Rev, , . 3, The Surety hereby waives notice of any alteration or extension of time made by the Obligee. 4, Any suit under this bond must be instituted before the expiration of two (2) years from the date on which the Principal' ceased to work on the Contract. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 5, No right of action shall accrue on this bond to or for the use of any person or corporation other than the Obligee named herein or the heirs, executors, administrators or successors of the Obligee. 6. Any claims must be presented in writing to Liberty Mutual Insurance Company, to the attention of Liberty Bond Services, Claim Department, 600 W. Germantown Pike, Plymouth Meeting, PA 19462. Signed and sealed this day of , 19 WITNESS OR ATTEST: APAC-Georqia. Inc. Principal '" -".-..,.. - ", (S~al) ~QJ8. C' (-~ By J t JJJl:? Name: . I?(~J Title: j)vV' r y LIBERTY MUTUA INSURANCE COMPANY / Surety - ~ . ......... (Seal) ...... . ,~ ~ . Jr. LBS-5100 8/94 Rev. ,; t PA YMENT ,_ BOND "*-"/" "-<t. ,,~......~'!. LIBERTY BOND SERVICES " Bond Number: 14- 0 0 0- 0 2 5- 0 2 3 3 KNOW ALL MEN BY THESE PRESENTS, that we APAC-Georgia, Inc. , as Principal (the "Principal"), and Liberty Mutual Insurance Company, a mutual company duly organized under the laws of the Commonwealth of Massachusetts, as Surety (the "Surety"), are held and firmly bound unto Augusta-Richmond County Commission-Council , as Obligee (the "Obligee"), in the penal sum of One Hundred Forty Seven Thousand One Hundred Seventy Three & 75/100-- Dollars ($ 1 47, 1 73. 75 ), for the Qayment of which sum well and truly to be made, the Principal and the Surety, bind ourselves, our heirs, ':ex~cuto'rS-, ad~inistrators, successors and assigns, jointly and severally, firmly by these presents. '-,,,...-. ~",.... - WHEREA-S, the-Principal has by written agreement dated , 19 '(the ~'Conlract") with the Obligee for ~epperidge Drive Intersection Improvements Project Number: 51-8691-094 , entered into a contract - whic~ .P2ntr.~ct.is by reference made a part hereof. - ~. -;.. -~". -, ...:: NOW, THgBEFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the Principal shall promptly make - - payn-i'ent to all Claimants, as hereinafter defined, for all labor and material used or reasonably required for use in the ,?perf&marce.;,of the Contract, then this obligation shall be null and void; otherwise it shall remain in full force and effect. ./ ;. - - ~~.~ - .. -~'...."~ . '.' :P,ROVIDED AND SUBJECT TO THE CONDITIONS PRECEDENT: 1. A "Claimant" is defined as one having a direct contract with the Principal or with a subcontractor of the Principal for labor, material, or both, used or reasonably required for use in the performance of the Contract, labor and material being construed to include that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental of equipment directly applicable to the Contract. 2, The Principal and the Surety hereby jointly and severally agree with the Obligee that every Claimant, who has not been paid in full before the expiration of a period of ninety (90) days after the date on which the last of such Claimant's work or labor was done or performed, or materials were furnished by such Claimant, may sue on this bond for the use of such Claimant, prosecute the suit to final judgment for such sum or sums as may be justly due Claimant, and have execution thereon. The Obligee shall not be liable for the payment of any costs or expenses of any such suit. 3. No suit or action shall be commenced hereunder by any Claimant: (a) Unless Claimant, other than one having a direct contract with the Principal, shall have given written notice to the Principal and the Surety within ninety (90) days after such Claimant did or performed the last of the work or labor, or furnished the last of the materials for which said claim is made, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were furnished, or for whom the work or labor was done or performed_ Such notice shall be served by mailing the same by registered mail or certified mail, postage prepaid, in an envelope addressed to the, Principal or the Obligee at any place where an office is regularly maintained for the transaction of business, or in any manner in which legal process may be served in the state in which the aforesaid project is located, save that such service need not be made by a public officer, and to the Surety to the attention of Liberty Bond Services, Claim Department, 600 W. Germantown Pike, Plymouth Meeting, PA 19462. (b) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state in which the project, or any part thereof, is situated, or in the United States District Court for the district in which the project, or any part thereof, is situated, and not elsewhere. '-B8'5200 810<1 R0.v, ) (c) After the expiration of one (1) year following the date on which Principal ceased work on the Contract. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. ' 4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith hereunder, inclusive of the payment by the Surety of mechanics' liens which may be filed of record against such improvement, whether or not claim for the amount of such lien be presented under and against this bond. Signed and sealed this day of ,19 WITNESS OR ATIEST: APAC-Georqia, Inc. Principal .'" ]?eal) , q'J1A-fA"'(Av( ti ,-.. C~oi1 By It' f!I; Namer p Vv r rl7.J, Title: By: AL INSURANCE COMPANY - (Seal) , Jr. LBS-5200 8/94 Rev. I I I I I I I I I I I I I I I I I I I IN WITNESS WHEREOF, the parties hereto have executed this Agreement in three (3) counterparts, each of which shall be deemed an original, in the year and day first mentioned above. SEAL Attest CX~8-~ Secretary 9'Jiuj..cJ 11. [~ witness AUGUSTA-RICHMOND COUNTY COMMISSION-COUNCIL (Owner) By: Cu.U Richmond County Commission-Council ~ lloInty ta ;J j? CONTRACTOR: PI1C-lDf:OIl6iA r ~~. .;jly'~ .~"~:~ .~ 7)w. ;;M'J~ By: Title: Address: P. o. 130 x. /f1...1 Av(,.v~TA. G~ o~C; I A 10903 -111.- <J j A-4 I I I I I I I I I I I I I I I I I I I GENERAL CONDITIONS I I I I I I I I I I I I I I I I I I I TABLE OF CONTENTS OF GENERAL CONDITIONS Article Number Tille DEFINITIONS..,.......... ., .,..... ,..... ,.......".,.........., '.. ~ PRELI~lIN AR Y MA. TIERS ........................................ 3 CONTRACT DOCUMENTS: INTENT. AMENDING AND REUSE............................... 4 A V AILABILITY OF LANDS: PHYSICAL CONDITIONS: REFERENCE POINTS. , . . .. .. . , . . , .. . ...... . .. . ...... . . . . . ... . .. . . . 5 BONDS AND INSURANCE ........................................ 6 CONTRACTOR'S RESPONSIBILITIES.,....".................... 7 OTHER WORK ",...."......."."..................,..."......,. 8 OWNER'S RESPONSiBILITIES...,..............................., 9 ENGINEER'S STATUS DURING CONSTRUCTION .'......'..:.. 10 CHANGES IN THE WORK......................................... II CHANGE OF CONTR.KT PRiCE,..............:.................. 11 CHANGE OF CONTRACT TIME........... .... ....... ' .. .......... 13 WARRANTY AND GUARANTEE: TESTS AND INSPECTIONS: CORRECTION. REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK. .. . . .. . ... .. . . . , . . . ... . . . . 14 PA YMENTS TO CONTRACTOR AND COMPLETION '........... 15 SUSPENSION OF WORK AND TERMINATION,...", "........ 16 ARBITRATION........,............................................ 17 MISCELL.-\:-.I EOUS ...". ......... ,.,...,...,.....,........,..,..... 3 Pafff! - f 8 9 10 II 14 18 19 19 ~I ~I 14 14 ~6 ~9 31 ,., )- I I INDEX TO GENERAL CONDITIONS I A.nici~ or Paragraph Numb~r Acceptance of lnsurance ............................. 5.13 Access to the Work ..................... . .. . . . .. . . ... 13.2 Addenda-definition of (see definition of Specifications} ..,..................................... 1 Agreement-definition of ................................ 1 All Risk Insurance.................:................... 5.6 Amendment. Written ............................. 1. 3.1.1 Application for Payment-definition of .................. I Application for Payment. Final ...................... 14.12 Application for Progress Payment .................... 14.2 Application for Progress Payment-review of .... 14.4-14.7 Arbitration ............................................. 16 Authorized Variation in Worle ......................... 9.5 Availability of Lands .................................. 4,1 A ward. Notice of-:iefined ,............................. I I I I I I Before Starting Construction .......,..'........... :.5-2. i Bid-:iefinition of ....................................... I Bonds and lnsurance-in general ........................ 5 Bonds-:ietinition of . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. I Bonds. Delivery of ............................. _. :.1. 5.1 Bonds. Performance and Other .................... 5.1-5.1 I I Cash Allowances ...,................................. 11.8 Change Order-:ietinition of ...,......................... I Change Orders-to be executed ...................... 10.4 Changes in the Work ...................,............... 10 Claims. Waiver of -on Final Payment ...........,... 14.16 Clarifications and Interpretations ...................... 9.4 Cleaning ......,..................,................... 6. 17 Completion . . . , . . . . . . . ' . . . . . . . . . . . . . . , . . . . . . . . . . . . . . , . .. 14 Compietlon. Substantial,..."........,........., 14.8-14.9 Conference. Pre::onstruction ,.....,,:.,..,...,........ :.8 Confljc~. Error. Dlscrepancy-Cunrractor to Report "",........,......."............... :.5. 3.3 Construction Machinery. Equipment. etc. ............. 6A Continuing Work. .................,...........,...... 6.19 Contract Documents-amending and supplementing .,................................. 3.4-3.5 Contract Document~efinition of ,..,....,...........,. 1 Contrac~ Documents-Intent ...................... 3.1-3..3 Contract Documents-Reuse of ....................... 3.6 Contrac~ Price. Change oj .............................. 11 Contract Price-iefinition ............................... 1 Contrac~ Time. Change oi ".......................,.... I: Contract Time. Commencement of .................... :..3 Contract Time-iefinition of "......................,... I Contractor-derinition oj ,....,.......................... 1 Contraclor May Stop Work or Terminate ,.,..,....... 15.5 Contractor's Continuing Obligation.................. 14.15 Contr:lctor's Duty to Report Discrepancy in Documents.................................. :.5. ),: Cuntr:lctor's Ft:t:-Cost Plus ... 11 A.5 .6. 11.5.1. 11.6-11.:- Contractor's Liability Insurance .......,.............,. 5.3 Contractor's Resoonsibilities--in general .,,'......,..... 6 I I I I I I I I I Contractor's WaJTaJ1ty ofTitJe ........................ 14.3 Contractors-other ...................................... 7 Contractual Liability Insurance ........................ 5.4 Coordinating Contractor.-:letinition of ................ 7.4 Coordination .......................................... 7.4 Copies of Documents .................................. Z.: COlTection or Removal ofDcfective Worle ........... 13.11 COlTection Period. One Year ..'..................... 13.12 COlTection. Removal or Acceptance of Defective Worle-in general ........................... 13.11-13.14 Cost-net decrease ....,............................ 11.6.1 Cost of W orle .................................... 11. 4-11.5 Costs. Supplemental .......................... . .. ... 11.4.5 Day-:iennition of ....................................... 1 Def~crive-<1ennition of ................................. I D~f~crive Work. Acceptance of ...................... 13.13 Def~crive Work. Correction or Removal of ,......... 13.11' D~fecrive Worle-in general ............... 13. 14.7. 14.11 Def~crive Worle. Rejecting..... ........................ 9.6 Definitions .............................................. 1 Delivery of Bonds' . . . . . . . . . . .. . . . . . . . . . . . . . . . . . . . . . .... 2.1 Determination for U nit Prices ........................ 9.10 Disputes. Decisions by Engineer .. .. .. . . . . .. .. ... 9.11-9.12 Documents. Copies of ................................. 2.2 Documents. Record '................................. 6.19 Documents. Reuse .................................... 3.6 Drawings--definition of ................................. I Easements ".......................................... 4.1 Effective date of Agreement-:iennition of ,... '. . . . . . . . . .. 1 Emergencies .............."............,..........., 6.12 Engineer.-:lefinition oj ,."......,...,..:...,..,.........1 Engineer's Decisions ............................ 9.10-9.12 Engineer's-Notice Work is Acceptable ............. 14.13 Engineer's Recommendation of Payment ...... 14,4. 14.13 Engineer's ResponsibIlities. Limitations on ................. 6.6,9.11,9.13-9.16,18.2 Engineer's Status During ConstrUction-in general ...... 9 Equipment. Labor. Materials and..... .. ...... ..... 6,3-0.6 Equivalent Materials and Equipment ................,. 6.7 Explorations oj physical conditions., ... ,.. ... ,....... 4,2 Fee. Contractor's-Costs Plus........................ 11.6 Field Order.-:lennition oj ..'......"........,.,......... I Field Order-issued by Engineer ......,........, 3.j.l. 9.5 Final Applic:llionforPayment .,....,...,............14.12 Final Inspection ..................................... 14; 1 ) Final Payment and Acceptance ...................... J 4.13 Final Payment. Recommendation of ,.,........ 14.13-14.14 General Provisions ".,.......................... 17.3-li.4 General Requirement~erinition of . . . . . . . , . . . . . . . . . .. .. I General Requirements-pnncipal references to ,..",.,.....,... :.6. 4.4, 6,4. 6.6-6.7. 6,23 ~ I I Giving Notice ...,.................................... 17.1 Guarantee of Work -by Contractor ................... 13.1 Indemnification . . . . . . . . . . . . . . . .. . . . . . . . . . . .. 6.30-6.32. 7.5 I 'Inspection. Final .................................... 14.11 Inspection. Tests and ...........:..................... 13.3 Insurance. Bonds and-..n general ....................... 5 Insurance. Certificates of ........................... 2.7.5 Insurance.-:ompleted operations...................... 5.3 Insurance. Conrractor'sLiability ...................... 5.3 Insurance. Conrractual Liability ....................... 5.4 Insurance. Owner's Liability .......................... 5.5 Insurance. Property .............................. 5.6-5.13 Insurance-Waiver of Rights ......................... 5.11 Inrent of Contract Documents ................... 3.3.9.14 Interpretations and Clarifications ...................... 9.4 Investigations of physical conditions. . . ,. . . .. . . .. . . . . .. 4,1 I I I I Labor. Materials and Equipment ......:........... 6.3-6.5 Laws and Regulations-dellnition of ..................... I Laws and Regulations-general ....................... 6.14 Liability Insurance-Contractor's ..................... 5.3 Liability Insurance-Owner's ...,..................... 5.5 Liens-dellnitions of ................................ 14.1 Limitations on Engineer's Responsibilities ..,.................. 6.6.9.11. 9.13-9.16 I I Materials and equipment-fumished by Contractor .... 6.3 Materials and equipment-not incorporated in Work .............................. 14.2 Materials or equipment~quivalent ....,.............. 6.7 Miscellaneous Provisions............................... 17 Multi.prime contractS ........ . . . . . . . . . . . . . . . . . . . . . . . . . .. 7 I I Notice. Giving of . .................................... 17.1 Notice of Acceptability of Project ................... 14.13 Notice of Award-definition of ,......................... I Notice to Proceeci-definition of ..,....................., 1 Notice to Proceed-giving of ,..,....................., 2.3 I I "Or-Equal" Items ,............."...,..",.....,...... 6.i Other contractors ................,.........,............ ~ Other work .... . . . . . . . . . . . . , . . . . . . . . . . . . . . . . . . . . . . . . . . . .. i Overtime Work-prohibition of . ........ ............... 6.3 Owner-definition of .................................... 1 Owner May Correct Defecrive Work....;............ 13.14 Owner May Stop Work. ............................. 13.10 Owner May Suspend Work. Terminate .......... 15.1-15A Owner's Duty to Execute Change Orders .........,... 11.S Owner's Liability Insurance........................... 5.5 Owner's Representative-Engineer to serve as ........ 9.1 Owner's Responsibilities-in general ,.,.........."..... 3 Owner's Separate Representative at site.,..,.,....,... 9,3 I I I I Partial Utilization .................................. 14.10 Partial Utilization-ierinition of ...,..................,., I Partial Utilization-Property Insurance ,.....,........ 5.15 Patent Fees and Royalties ,.,..".,.."........,..".. 6.12 Payments. Recommendation of ........... 14.4-1~.7, 14,13 Payments to C)Otractor-in general ....,..,............ 14 I I Payments to Contractor-when due ........... 14.4. 14.13 Payments to Contractor-withholding ................ 14.7 Perfonnance and other Bonds ..................... 5.1-5.2 Permits............................................... 6.13 Physical Conditions ................................... 4.2 Physical Conditions-Engineer's review ............. 4.2.4 Physical Conditions-existing strUctures ............. 4.2.2 Physical Conditions-explorations and repons ....... 4.2.1 Physical Conditions-possib1e document change ..... 4.2.~ Physical Conditions-price and time adjustments .... 4.2.5 Physical Conditions-report of differing ............. 4.2.3 Physical Conditions-Underground Facilities .......... 4.3 Preconstruction Conference ........................... 2.8 Preliminary Matters ..................................... 1 Premises. Use of ................................ 6.16-6.18 Price. Change of Contract .............................. 11 Price-C on tract-definition of ............................ 1 Progress Payment. Applications for. . . . . . . . . . . . . . . . . .. 14.2 Progress Payment-retainage ......................... 14.2 Progress schedule ............... 2.6. 2.9. 6.6. 6.29. 15.2.6 Project--definition of ..........,......................... I Project Representation-provision for ................. 9.3 Project Representative. Resident-definition of .......... I Project. Starting the ................................... 2.4 Property Insurance............................... 5.6-5.13 Property Insurance-Partial Utilization............... 5.15 Property Insurance-Receipt and Application of Proceeds ................................... 5.12-5.13 Protection. Safety and ........................... 6.20-6.2 I Punch list ........................................... 14.11 Recommendation of Payment.................. 14.4. 14.13 Record Documents ................................... 6.19 Reference Points ...................................... 4.4 Regulations. Laws and ............................... 6.14 Rejecting Defective Worle ............................. 9.6 Related Work at Site .............................. 7.1-7.3. Remedies Not Exclusive .............................. 17 A Removal or Correction of Defective Work ,.,.."..... 13.11 Resident Project Representative--definition of .,...."... 1 Resident Project Representative-provision for.,...... 9.3 ResponSibilities. Contractor's-in general ............... 6 Responsibilities. Engineer's-in general ................. 9 Responsibilities. Owner's-in general.................... 8 Retainage . .................. .......................... 14;2 Reuse of Documents .................................. 3.5 Rights of Way ....................,..........,......... 4.1 Royalties. Patent Fees and ........................... 6.11 Safety and Protection,...... 6.20-6.21, 18.1-18.2 Samples ...........,..............,............,. 6.13-6.18 Schedule of progress ........ 2.6.2.3.2.9.6,0.6.19. 15,1.6 Schedule of Shop Dr:awing submissions...................... 2.6.1.3-2.9.6.23. 14.1 Schedule of values ...................... 2.6.2.8-2.9. 14.1 Schedules. Finalizing...........,...................... 2.9 Shop Drawings and Samples, .. ,... .. .... , . . ...., 6.23-6.28 Shop Drawings--iefinition of , , . , . . . . . . . . . , , . . . . , . ',' . , . .. I Shop Drawings. use to approve substitutions ...................................... 6.7.3 5 I I Site. Visits t<>-by Engineer ........................... 9.2 Ispec~fiCatiOns--definitiOn of ............................. 1 StarUng ConstrUcuon. Before... . . . . . . . . . . . . .. . . . .. 2.5.2.8 Starting,the Project;. .'........... '...................... 2.4 Stopping Work-by ContraCtor....................... 15.5 IStOPPing Work-by Owner.......................... 13.10 SubcODtractor-definition of ..... . . . . . . . . . . . . . . . . . . . . . . .. I Subcontractors-in general ....................... 6.8-6.11 Subcontracts-requircd provisions ............5.11.1.6.11 I 11.4.3 Substantial Completion-<:enification of .............. 14.8 Substantial Completion-definition of .................... 1 Substitute or "Or-Equal" Items ....................... 6.7 I Subsurface Conditions........ ............ ...... .,. 4.2-4.3 Supplemental costs ................................. 11.4.5 SupplementarY Conditions--definition of ................ 1 I SupplementarY Conditions-principal references to .. 2.2.4.2.5.1.5.3. 5.f>.5.8. 6.3. 6.13. 6.23. 7.4.9.3 Supplementing Contract Documents ............... 3.4-3.5 I Supplier-defmition of . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. 1 Supplier-principal references to ... 3.6.6.5.6.7-6.9. 6.20. 6.24.9.13.9.16.11.8.13.4.14.12 Surety-consent to payment..... .. ........... 14.12. 14.14 I Surety-Engineer has no duty to ..................... 9.13 Surety-notice to .......................... 10.1. 10.5. 15.2 Surety-<!ualification of ,.......................... 5.1-5.2 I Suspending Work. by Owner ......................... 15.1 Suspension of Work and Termination--in general....... 15 Superintendent-Contractor's ......................... 6.2 Supervision and Superintendence ..................' 6.1-6.2 I Taxes--Payment by Contractor. . . . . . . . . . . .. . . . . . . . . .. 6.15 Termination-by Contractor.......................... 15.5 Termination-by Owner............... .......... 15.2-15.4 I Termination. Suspension of Work and-in general ...... 15 Tests and Inspections .,.,....................... 13.3-13.7 Time. Change of Contract ............................., 12 I I I I I I I Time. Computation of ................................ 17:2 Time. Contract-definition of ............................ I Uncovering Work............................... 13.8-13.9 Underground Facilities-definition of .................... 1 Underground Facilities-not shown or indicated..... 4.3.2 Underground Facilities-protection of ........... 4.3. 6.20 Underground Facilities-shown or indicated......... 4.3.1 Unit Price Work-definition of .......................... 1 Unit Price Work-general ................. 11.9. 14.1. 14.5 Unit Prices ......................................... 11.3.1 Unit Prices. Determinations for... .......... .......... 9.10 Use of Premises'.. . . .. .. . .. . . .. . . .. . .. .. .. .. .. . .. 6.16-6.18 Utility owners .......................... 6.13.6.20. 7.2-7.3 Values. Schedule of ......................... 2.6.2.9. 14.1 Variations in Work-Authorized............ 6.25.6.27.9.5 Visits to Site-by Engineer ............................ 9.2 Waiver of C1aims-on Final Payment.........,...... 14,16 Waiver of Rights by insured panies ,..........., 5.10.6.11 Warranty and Guarantee-by Contractor ............. 13.1 Warranty of Title. Contractor's ....................... 14.3 Work. Access to ..................................... 13.2 Work-by others ........................................ 7 Work Continuing During Disputes .................... 6.29 Work. Cost of ................................... 11.4-11.5 Work-definition of ..................................... 1 Work Directive Change-definition of ................... 1 Work Directive Change-principal , references to ............................3.4.3.10.1-10.2 Work. Neglected by Contractor ..................... 13.14 Work. Stopping by Contractor........................ 15.5 Work. Stopping by Owner,.,.................... IS. ).)5.4 Written Amendment-definition of ......,............... I Written Amendment-principal references to ..................... 3.4.1. 10.1. 11.2. 12.1 6 I I GENERAL CONDITIONS rRTICLE I_DEFINITIONS Wherever used in these General Conditions or in the other Icontract Documents the following ,terms have the meanings indicated which are applicable to both the singular and plural thereof: IAddenda-Written or graphic instruments issued prior to the opening of 8 ids which clarify. correct or change the bidding documents or the Contract Documents. I A,l.'reemelll- The written agreement between OWN ER and CONTRACTOR covering the Work to be performed: other Contract Documents are auached to the Agreement and made a part thereof as provided therein. I Applicatioll .Ii)r Pa-"",elll- The form accepted by ENGI- NEER which is to be used by CONTRACTOR in requesting I progress or final payments and which is to include such sup- porting documentation as is required by the Contract Documents. I Bid-The offer or proposal of the bidder submitted on the prescribed form setting forth the prices for the Work to be performed, I Bonds-8id. performance and payment bonds and other instruments of securit y. I Change Order-A document recommended by ENGINEER. which is signed by CONTRACTOR and OWNER and autho- rizes an addition. deletion or revision in the Work. or an adjustment in the Contract Price or the Contract Time. issued I on or after the Effecti\'e Date of the Agreement. COlllmcT DO('/llIIeIIlS- The Agreement. Addenda (which per- tain to the Contract Documents). CONTRACTOR's 8id I (including documentation accompanying the Bid and any post- Bid documentation submitted prior to the Notice of Award) when attached as an exhibit to the Agreement. the Bonds. I these General Conditions. the Supplementary Conditions. the Specifications and the Drawings as the same are more spe- cifically identified in the Agreement. together with all amend- ments. modifications and supplements issued pursuant to paragraphs 3A and 3,~ lln or after the Effective Date of the Agreement, I I CVlltract Price-The moneys payable by OWNER to CON- TRACTOR under the Contract Documents as stated in the Agreement (subject to [he provisions of paragraph \1,1),\ in the case of Unit Price Work), I COlllracT Tillll'- The number of Jays (computed as provideJ in par:lgraph 17,2) or the date stated in the ,\greement for the compk[ion of the Work, I CONTRA.CTUR- The person. nrm or corpor.Hion with whelm OWNER has entered into the;: Agre;:eme;:nt. I defecril'e-An adjective which when modifying the word Work refers to Work that is unsatisfactory. faulty or deficient. or does not conform to the Contract Documents. or does not meet the requirements of any inspection. reference standard. test or approval referred to in the Contract Documents. or has been damaged prior to ENGINEER's recommendation of final payment (unless responsibility for the protection thereof has been assumed by OWNER at Substantial Completion in accordance with paragraph 14.8 or 14.10), Drml'ings- The drawings which show the character and scope of the Work to be performed and which have been prepared or approved by ENGINEER and are referred to in the Con- tract Documents. Effeclil'e Dare of rlre Agreemell1-The date indicated in the Agreement on which it becomes etTective. but if no such date is indicated it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. E.VGINEER- The person. firm or corporation named as such in the Agreement. Field Order-A written order issued by ENGINEER \vhich orders minor changes in the Work in accordance with para- graph 9.5 but which does not involve a change in the Contract Price or the Contract Time. General Requiremellls-Sections of Division 1 of the Speci- fications. Lall's and Regulations: Lall's or Regulations-Laws. rules. regulations. ordinances. codes and/or orders. Notice of ,{1I'ard-The written notice by OWNER to the apparent successful bidder stating that.upon compliance by the apparent successful bidder with the conditions precedent enumerated therein: within the time specified. OWNER will sign and deii\er the .\greement. ,Votice (0 Pwceed-A written notice given by OWNER to CONTRACTOR (with a copy to ENGINEERl fixing the ~ate on which the Contract Time will commence to run and on which CONTRACTOR shall start to ~erform CONTRAC- TOR'S obligations under the Contract Documents. OWNER-The public body or authority. corporation. asso- ciation. tirm ur person with whom CONTRACTOR has entered into the Agreement and for whom the Work is to be provided. Parlial Litili::ariol/-Placing a portion of the Wurk in service for the purpose for which it is intended (or a related purpose) before reaching Substantial Completion tor all the Work. PnJiecl- The total construction of which the Work to be provided under the Contracf Documents may be the whole. or a part as indicated elsewhere in the Contract Documents, Residel/t Pr"iect R('pre,H'l/llltil'e-The authorized re;:presen- t.Hive of E~GINEER who is assigned to the site or any part thereof. 7 I I Shop Drawings-All drawings, diagrams. illustrations, schedules and other data which are specifically prepared by I or for CONTRAcrOR to illustrate some portion of the Work and all illustrations, brochures. standard schedules. perfor- mance chans. instnlctions.-diagrams and other infonnation prepared by a Supplier and submitted by CONTRAcrOR to I illustrate material or equipment for some portion of the Work. Spuifications-Those ponions of the Contract Documents I consisting of written technical descriptions of materials. equipment. construction systems. standards and workman- ship as applied to the Work and cenain administrative details applicable thereto. I Subcontractor-An individual. finn or corporation having a direct contract with CONTRACTOR or with any other Sub- I contractor for the performance of a pan of the Work at the site. S ubsranrial Complerion- The Work (or a specified pan thereof) I has progressed to the point where. in the opinion of ENGI- NEER as evidenced by ENGINEER's definitive cenificate of Substantial Completion. it is sufficiently complete. in accordance with the Contract Documents. so that the Work I (or specified pan) can be utilized for the purposes for which it is intended: or if there be no such cenificate issued. when final payment is due in accordance with paragraph 14.13. The I terms "substantially complete" and "substantially com- pleted" as applied to any Work refer to Substantial Comple- tion thereof. I Supplemenrary Conditions-The pan of the Contract Docu- ments which amends or supplements these General Condi. tions. I Supplier-A manufacturer. fabricator. supplier. distributor. materialman or vendor. I Underground Faciliries-AJl pipelines. conduits. ducts. cables. wires. manholes. vaults. tanks. tunnels or other such facilities or attachments. and any encasements containing such facil- ities which have been installed underground to furnish any of I the following services or materials: electricity. gases. steam. liquid petroleum products. telephone or other communica- , tions. cable television. sewage and drainage removal. traffic or other control systems or water. I Unit Price Work-Work to be paid for on the basis of unit pnces. I Work-The entire completed construction or the various sep- arately identifiable pans thereof required to be furnished under the Contract Documents. Work is the result of per- I fonning services. furnishing labor and furnishing and incor- porating materials and equipment into the construction. all as required by the Contract Documents. I Work Direcrive Change-A written directive to CONTRAC- TOR. issued on or after the Effective Date of the Agreement and signed by OWNER and recommended by ENGINEER. I ordering an addition. deletion or revision in the Work. or responding to differing or unforeseen physical conditioDSunder which the Work is to be performed as provided in paragraph 4.2 or 4.3 or to emergencies under paragraph 6.22. A Work Directive Change may not change the Contract Price or the Contract Time. but is evidence that the parties expect that the change directed or documented by a Work Directive Change will be incorporated in a subsequently issued Change Order following negotiations by the panies as to its effect. if any, on the Contract Price or Contract Time as provided in paragraph 10.2. Wrirren Amendmenr-A written amendment of the Contract Doc:uments. signed by OWNER and CONTRACTOR on or after the Effective Date of the Agreement and normally deal- ing with the nonengineering or nontechnical rather than strict1y Work-related aspects of the Contract Documents. ARTICLE 2-PRELlMINARY MAITERS Deu"ery of Bonds: 2.1. When CONTRACTOR delivers the executed Agree- ments to OWNER. CONTRACTOR shall also deliver to OWNER such Bonds as CONTRACTOR may be required to furnish in accordance with paragraph 5 .1. Copies of DOCUnle1llS: 2.2. OWNER shall furnish to CONTRACTOR up to ten copies (unless otherwise specified in the SupplementarY Con- ditions) of the Contract Documents as are reasonably nee. essary for the execution of the Work. Additional copies will be furnished. upon request. at the cost of reproduction. Commencenuml of Cdnrrcu:t Time: /'v'ori&e to Proceed: :!.3. The Contract Time will commence to run on' the thinieth day after the Effective Date of the I\greement. Of. if a Notice to Proceed is given. on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within thiny days after the Effective Date of the Agree- ment. In no event will the Contract Time commence to run later than the seventy-fifth day after the day of Bid opening or the thinieth day after the Effective Date of the Agreement. whichever date is earlier. Suuring liIe Project: 2.4. CONTRACTOR shall stan to perform the Work on the date when the Contract Time commences to run. but no Work shall be done at the site prior to the date on which the Contract Time commences to run. Btfore Suuting Construction: 2.5. Before undenaking each pan of the Work. CON- TRACTOR shall carefully study and compare the Contract Documents and check and verify peninent figures shown 8 I I thereon and all applicable tield measurements. CONTRAC- _ TOR shall promptly report in writing to ENGINEER any conflict. error or discrepancy which CONTRACTOR may discover and shall obtain a written interpretation or clarifi- cation from ENGINEER before proceeding with any Work affected thereby: however. CONTRACTOR shall not be lia- ble to OWNER or ENGINEER for failure to report any conflict. error or discrepancy in the Contract Documents. unless CONTR.A.CTOR had actual knowledge thereof or should reasonably ha.ve known thereof. I I I 2.6. Within ten days after the Effective Date of the Agree- ment (unless otherwise specified in the General Require- ments), CONTRACTOR shall submit to ENGINEER for revIew: I I 2.6.1. an estimated progress schedule indicating the starting and completion dates of the various stages of the Work: I 2.6.2. a preliminary schedule of Shop Drawing sub- missions: and I 2.6,3, a preliminary schedule of values for all of the ,Work which will include quantities and prices of items aggregating the Contract Price and will subdivide the Work into component parts in sufficient detail to serve as the basis for progress payments during construction. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work which will be con- firmed in writing by CONTRACTOR at the time of sub- mission, I I 1.7, Before any Work at the site is started. CONTRAC- TOR shall deliver to OWNER. with a copy to ENGINEER, certificates land other evidence of insurance requested by OWNER) which CONTRACTOR is required to purchase and maintain'in :l..:cordance with paragraohs 5.3 and SA. and OWNER shall deliver to CONTRACTOR certificates land other evidence of insurance requested by CONTRACTOR) which OWNER is required to purchase and maintain in accordance with paragraphs 5,6 and 5.7, I I I Preconsrruction Conference: 2,8, Within twenlY days after the Effective Date of the Agreement. but before CONTRACTOR starts the Work at the site. a conlerence altended by CO~TRACTOR. ENGI- NEER and ~)(hers as appropriate will be held to discuss the schedules relerred to in paragraph 1.6, tu discuss procedures for handling Shop Drawings and other submittals and fur processing .-\pplications lor Payment. and to establish a working understanding among the parties as to the Work. I I I Finali:.illg Schedules: 2.9. .-\t least ten days before submission ulthe tirst .-\pr1i- cation for P:l\ment a ..:onference altended by CONTRAC- TOR. ENGI~EER and others as appropriate will be held to tinalile the o;.;;,edulcs submilted in :lc~ordance \\'ith p:lr:l- I I graph 2.6. The finalized progress schedule will be acceptable to ENGINEER as providing an orderly progression of the Work to completion within the Contract Time. but such acceptance will neither impose,on ENGINEER responsibility for the progress or scheduling of the Work nor relieve CON- TRACTOR from full responsibility therefor. The finalized schedule of Shop Drawing submissions will be acceptable to ENGINEER as providing a workable arrangement for pro- cessing the submissions. The finalized schedule of values will be acceptable to ENGINEER as to form and substance. ARTICLE 3-CONTRACT DOCUMENTS: INTENT, AMENDING. REUSE I nlenl: 3.1. The Contract Documents comprise the entire agree- ment between OWNER and CONT~ACTOR concerning the Work. The Contract Documents are complementary: what is called for by one is as binding as if called for by all. The Contract Documents will be construed in accordance WIth the law of the place of the Project. 3.2. It is the intent of the Contract Documents to describe a functionally complete Project (or part thereot) to be con- structed in accordance with the Contract Documents, Any Work. materials or equipment that may reasonably be inferred from the Contract Documents as being required to produce the intended result will be supplied whether or not specifically called for. When words which have a well-known technical or trade meaning are used to describe Work. materials or equipment such words shall be interpreted in accordance with that meaning. Reference to standard specifications. manuals or codes of any technical society. organization or association. or to the Laws or Regulation's of any governmental authority. whether such reference be specific or by implication. shall mean the latest standard specification.'manual. ..:ode or Laws or Regulations in etTect at the time of opening of Bids (or. on the Effective Date of the Agreement if there were no Bids l. except as may be otherwise specifically stated. 'However. no provision of any referenced standard specification. manual or code (whether or not specifically incorporated by reference in the Contract Documents) shall be effective to change the duties and responsibilities of OWNER. CONTRACTOR or ENGINEER. or any of their consuitants. agents or employ- ees from those set forth in the Contract Documents. nor shall it be effective to ;1.ssign to ENGINEER. or any of ENGI- NEER's consultants. agents or employees. any duty or authority to supervise or direct the furnishing or perlormance of the Work or any duty or authority to undertake responsi- bility contrary to the provisions of paragraph 9,15 or 9.16, Clarifications and interpretations of the Contract Documents ~hall be issued by ENGINEER as provided in paragraph 9,~, 3.3. If. during the pcrtormance of the Work. CONTRAC- TOR finds a confli~t. error or discrepancy in the Contract Documents. CONTRACTOR shall so report to ENGINEER in writing at once and before proceeding with the Work ;Itfected thereby shall obtain :J \\Tllten interpretation or c1aritication 9 I I from ENGINEER: however. CONTRACTOR shall not be I1ble to OWNER or ENGI)'olEER for failure to repon any nftict. error or discrepancy in the Contract Documents ess CONTRACTOR had actual knowledge thereof or should reasonably have'known thereof. lmending and SuppiemelllingConlTaCt DOCU11UIItS: 3.4. The Contract Documents may be amended to pro- Ide for additions. deletions and revisions in the Work or to odify the terms and conditions thereof in one or more of the following ways: I 3.4.1. a formal Written Amendment, 3.4.2. a Change Order (pursuant to paragraph 10.4), I or 3.4.3. a Work Directive Change (pursuant to para- graph 10.1). I s indicated in paragraphs 11.1 and 11.1. Contract Price and ~ontract Time may only be changed by a Change Order or a Written Amendment. I 3.5. In addition. the requirements of the Contract. Docu- ments may be supplemented. and minor variations and devia- f'ons in the Work may be authorized. in one or more of the ollowing ways: 3.5.1. a Field Order (pursuant to paragraph 9.5), I 3.5.1. ENGINEER's approval of a Shop Drawing or sample (pursuant to paragraphs 6.26 and 6.17). or I 3.5.3. ENGINEER's written interpretation or c1arifi. cation (pursuant to paragraph 9.41. IReuse of Documents: 3.6, Neither CONTRACTOR nor any Subcontractor or Supplier or other person or organization performing or fur. In~Shing any of the Work under a direct or indirect contract with OWNER shall have or acquire any title to or ownership rights in any of the Drawings. Specifications or other docu- ments t or copies of any thereoO prepared by or bearing the I seal of ENGINEER: and they shall not reuse any of them on extensions of the Project or any other project without written consent of OWNER and ENGINEER and specific written I 'erification 0' adapla,;on by ENGINEER. ARTICLE 4-A V AILABILITY OF tAN OS: PHYSICAL I CONDITIONS: REFERENCE POINTS AlIailabilily of Lands: I 4.1. OWNER shall furnish, as indicated in the Contract Documents. the lands upon which the Work is to be per- formed. rights-of-way and easements for access thereto, and I . . such other lands which are designated for the use of CON- TRACTOR. Easements for permanent structures or perma- nent changes in existing facilities will be obtained and paid for by OWNER. unless otherwise provided in the Contract Documents. If CONTRACTOR believes that any delay in OWNER's furnishing these lands. rights-of-way or case. ments entitles CONTRACTOR to an extension of the Con- tract Time. CONTRAc:rOR may make a claim therefor as provided in Anicle 12. CONTRACTOR shall.provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. Physical Conditions: 4.2.1. Explorations and Reports: Reference is made to the SupplementarY Conditions for identification of those repons of explorations and tests of subsurface conditions at the site that have been utilized by ENGINEER in prep. aration of the Contract Documents. CONTRACTOR may rely upon the accuracy of the technical data contained in such repons. but not upon nontechnical data. interpreta-' tions or opinions contained therein or for the completeness thereof for CONTRACTOR's purposes. Except as indi- cated in the immediately preceding sentence and in para- graph 4.2.6. CONTRACTOR shall have full responsibility with respect to subsurface conditions at the site. 4.2.2, Existing Structures: Reference is made to the SupplementarY Conditions for identification of those drawings of physical conditions in or relating to existing surface and subsurface structures (except Underground Facilities referred to in paragraph 4.3) which are at or contiguous to the site that have been utilized by ENGI. NEER in preparation of the Contract Docum~nts. CON- TRACTOR may rely upon the accuracy'of the technical data contained in such drawings. but not for the complete- ness thereof for CONTRACTOR's pUll'oses. Except as' indicated in the immediately preceding sentence and in paragraph 4.:.6. CONTRACTOR shall have full respon- sibility with respect-to physical conditions in or relating to such structures. 4.2.3. Report of Differing Conditions: If CONTRAC- TOR believes that: 4.2.3.1, any technical data on which CONTRAC- TOR is entitled to rely as provided in paragraphs 4.:.1 and 4.:.: is inaccurate. or 4,:.3.1. any physical condition uncovered or revealed at the site differs materially from that indi~ cated, reflected or referred to in the Contract Docu- ments. CONTRACTOR shall, promptly after becoming aware thereof and before performing any Work in connection therewith (except in an emergency as permitted by para- graph 6.2:!1. notify OWNER and ENGINEER in writing about the inaccuracy or difference, 10 I I 4.2.4. ENGINEER's Redell': E!'IGINEER will promptly review the pertinent conditions. determine the necessity of obtaining additional explorations or tests with respect thereto and advise OWNER in writingtwith a copy to CONTRACTOR) of ENGINEER's findings and con- clusions. I I 4.2.5, Possihle Document Chanl!e: If ENGINEER concludes that there is a material error in the Contract Documents or that because of newly discovered condi- tions a change in the Contract Documents is required. a Work Directive Change or a Change Order will be issued as provided in Article 10 to reflect and document the consequences of the inaccuracy or difference. I I 4.2.6. PO.fSihle Price alld Time' Adjustments: In each such case. an increase or decrease in the Contract Price or an extension or shortening of the Contract Time. or any combination thereof. will be allowable to the extent that they are attributable to any such inaccuracy or difference. If OWNER and CONTRACTOR are unable to agree as to the amount or length thereof. a claim may be made therefor as provided in Articles i I and 12. I I I Physical Condirions-Cllderground Facilities: 4.3.1. 5hol\'n or Indicated: The information and data shown or indicated in the Contract Documents with respect to existing Underground Facilities at or contiguous to the site is based on information and data furnished to OWNER or ENGINEER by the owners of such Underground Facil- ities or by others. Unless it is otherwise expressly pro- vided in the Supplementary Conditions: I I I ,4,3.1.1. OWNER and ENGINEER shall not be re~ponsible for the accuracy or completeness of any such information or data: and. I .U.I.:. CONTRACTOR shall have full responsi- bility for reviewing and checking all such information, and data. for locating all Underground Facilities shown or indicated in (he Contract Documents. for coordina- tion of the Work with the owners of such Underground Facilities during construction. for t.he safety and pro- tection thereof as provided in paragraph 6,.20 and repairing any damage thereto resulting from the Work. the cost of all of which will be considered as having been included in [he Contract Price. I I I ~.J.2. Not Sholl'n or II/dicllled, If an Underground Facility is uncovered or revealed at or contiguous to the site which was not shown or indicated in [he Contract Documents and which CONTRACTOR could not reason- ably have been expected to be aware of. CONTRACTOR shall. promptly after becoming aware thereof and before performing any Wllrk affected thereby (except in an emer- gency as permitted tw paragraph /),22). identify [he owner of such Underground Facility and give: wriuen notice thereof to that owner and tll OWNER and E!'IGINEER. ENGI- ~EER will rromptl\' review Ihe L!nderground Facililv 10 I I I determine the extent to which the Contract Documents should be modified to reflect and document the conse- " quences of the existence of the Underground Facility. and the Contract Documents will be amended or supplemented to the extent necessary. During such time. CONTRAC- TOR shall be responsible for the safety and protection of such Underground Facility as provided in paragraph 6,~0. CONTRACTOR shall be allowed an increase in the Con- tract Price or an extension of the Contract Time. or both. to the extent that they are auributable to the existence of any Underground Facility that was not shown or indicated in the Contract Documents and which CONTRACTOR could not reasonably have been expected to be aware of. If the parties are unable to agree as to the amount or length thereof. CONTRACTOR may make a claim therefor as provided in Articles II and 12. Reference Points: 4.4. OWNER shall provide engineering surveys to estab- lish reference points for construction which in ENGINEER's judgment are necessary to enable CONTRACTOR to proceed with the Work. CONTRACTOR shall be responsible for lay- ing out the Work (unless otherwise specified in the General Requirements). shall protect and preserve the established reference points and shall make no changes or relocations without the prior written approval of OWNER, CONTRAC- TOR shall report to ENGINEER whenever any reference point is lost or destroyed or requires relocation because of necessary changes in grades or locations. and shall be respon- sible for the accurate replacement or relocation of such ref- erence points by professionally qualified personnel. ARTICLE 5-BONDS AND INSURANCE Performance and Other Bonds: 5.1, CONTRACTOR shall furnish performance and pay- ment Bonds. each in an amount at least equal to (he Concract Price as security for the faithful pert'orinance and payment of all CONTRACTOR '5 obligations under the Contract Docu- ments. The,se Bonds shall remain in effect at least until one year after. the date when final payment becomes due. except as otherwise provided by Law or Regulation or by the Con- tract Documents. CONTRACTOR shall also furnish such other Bonds as are required by the Supplementary Condi- tions. All Bonds shall be in the forms prescribed by Law or Regulation or by the Coiltract Documents and be executed by such sureties as are named in the current list of "Com- panies Holding Certificates of Authority as Acceptable Sure. ties on Federal Bonds and as Acceptable Reinsuring Com- panies" as published in Circular 570 (amended) by the Audit .Staff Bureau of Accounts. U ,S. Treasury Department. All Bonds signed by an agent must be accompanied by a certiried .:opy of the authorit\' to act. 5.2. If the surety on any Bond furnished by CONTRAC- TOR is declared a bankrupt or becomes insolvent or its right tu do business is lerminated in any state where any part of II I I the Project is located or it ceases to meet the requirements f paragraph 5.1. CONTRACTOR shall within five days ereafter substitute another Bond and Surety, both of which ust be acceptable to OWNER. ' lontnzctors LiIUIiJilylnslU'tlllce: 5.3. CONTRACTOR shall purchase and maintain such comprehensive general liability and other insurance as is tproPriate for the Work being performed and furnished and will provide protection from claims set forth below which may arise out of or result from CONTRA'CTOR's perfor- fance and furnishing of the Work and CONTRACTOR's ther obligations under the ContraCt Documents. whether it s to be performed or furnished by CONTRACTOR. by any Subcontractor. by anyone directly or indirectly employed by ry of them to perform or furnish any of the Work. or by ryone for whose acts any of them may be liable: I 5.3.1. Claims under workers' or workmen' s compen- sation. disability benefits and other similar employee ben. efit acts; I 5.3.2. Claims for damages because of bodily injury, occupational sickness or disease. or death of CONTRAC- TOR's employees; I 5.3.3. Claims for damages because of bodily injury, sickness or disease. or death of any person other than CONTRACTOR's employees: I 5,3.4. Claims for damages insured by personal injury liability coverage which are sustained lal by any person as a result of an offense directly or indirectly related to the employment of such person by CONTRACTOR. or (b) by any other person for any other reason: I I 5.3.5, Claims for damages. other than to the Work itself. because of injury to or destruction of tangible prop- erty wherever located. including loss of use resulting therefrom; I 5.3.6. Claims arising out of operation of Laws or Reg- ulations for damages because of bodily injury or death of any person or for damage to property: and I 5.3.7. Claims for damages because of bodily injury or death of any person or property damage arising out of the ownership. maintenance or use of any motor vehicle. I The insurance required by this paragraph 5.3 shall include the specific coverages and be written for not less than the limits of liability and coverages provided in the Supplemen. I tary Conditions. or required by law. whichever is greater. The comprehensive general liability insurance shall include completed operations insurance. All of the policies of insur- ance so required to be purchased and maintained lor the I certificates or other evidence thereoO shall contain a provi- sion or endorsement that the coverage afforded will not be cancelled. materially changed or renewal refused until at least I thirty days' prior written notice has been given to OWNER and ENGINEER by certified mail. All such insurance shall remain in effect until final payment and at all times thereafter when CONTRACTOR may be correcting, removing or replacing detecrive Work in accordance with paragraph 13.12. In addition. CONTRACTOR shall maintain such completed operations insurance for at least two years after final payment and furnish OWNER with evidence of continuation of such insurance at final payment and one year thereafter. ConlnU:tlUJl LiIUIiJiIy I nslU'tlllCe: 5.4. The comprehensive general liability insurance required by paragraph 5.3 will include conuactualliability insurance applicable to CONTRACTOR's obligations under paragraphs 6.30 and 6.31. OWl'U!rs LiIUIiJily /nslU'tlllCe: 5.5. OWNER shall be responsible for purchasing and maintaining OWNER's own liability insurance and. at OWNER's option. may purchase and maintain such insur- ance as will protect OWNER against claims which may arise from operations under the Contract Documents. Pro~rry Insurance: 5.6. Unless otherwise provided in the Supplementary Conditions. OWNER shall purChase and maintain property insurance upon the Work at the site to the full insurable value ,thereof (subject to such deductible amounts as may be pro- vided in the Supplementary Conditions or required by Laws and Regulations I. This insurance shall include the interests of OWNER. CONTRACTOR. Subcontractors. ENGINEER and ENGINEER's consultants in the Work. all of whom shall be listed as insureds or additional insured parties. shall insure against the ,perils of fire and extended coverage and shall include "all risK" insurance for physical loss and damage including theft. vandalism and malicious mischief. collapse and water damage. and such other perils as may be provided in the Supplementary Conditions. and shall include damages. losses and expenses arising out of or resulting from any insured loss or incurred in the repair or replacement of any insured property (including but not limited to fees and charges of engineers. architects. attorneys and other professionals I. If not covered under the "all risk" insurance or otherwise pro- vided in the Supplementary Conditions. CONTRACTOR shall purchase and maintain similar property insurance on portions of the Work stored on and ofT the site or in transit when such portions of the Work are to be included in an Application for Payment. 5.7, OWNER shall purchase and maintain such boiler and machinery insurance or additional property insurance as may be required by the Supplementary Conditions or Laws and Regulations which will include the interests of OWNER. CONTRACTOR. Subcontractors, ENGINEER AND ENGINEER's consultants in the Work. all of whom shall be listed as insured or additional insured parties. 12 I I 5.8. All the policies of insurance (or the certificates or other evidence thereot) required, to be purchased and main- tained by OWNER in accordance with paragraphs 5,6 and 5.7 will contain a' pn,lVision or endorsement that the coverage afforded will not be cancelled or materially changed or renewal refused until at least thirty days . prior written notice has been given to CONTRACTOR by certified mail and will contain waiver provisions in accordance with paragraph 5.11.2. I I I 5.9, OWNER shall not be responsible for purchasing and maintaining any property insurance to protect the interests of CONTRACTOR. Subcontractors or others in the Work to the extent of any deductible amounts that are provided in the Supplementary Conditions, The risk of loss within the deductible amount. will be borne by CONTRACTOR. Sub- contractor or others suffering any such loss and if any of them wishes property insurance coverage within the limits of such amounts. each may purchase and maintain it at the purchas- er's own expense. I I I 5,10. If CO NTRACTO R requests in writing that other special insurance be included in the property insurance pol- icy. OWNER shall. if possible. include such insurance. and the cost thereof will be charged to CONTRACTOR by appro- priate Change Order or Written Amendment. Prior to com- mencement of the Work at the site. OWNER shall in writing advise CONTRACTOR whether or not such other insurance has been procured by OWNER. I I Waiver of Rights: .5 .11.1. OWNER and CONTRACTOR waive all rights against each other for all losses and damages caused by any of the perils covered by the policies of insurance provided in response to paragraphs 5.6 and 5,7 and any other property insurance applicable to the Work. and also waive all such rights against the Subcontractors. ENGI- :--IEER. ENGIi'lEER's consultants and all other parties named as insureds in such policies for losses and damages so caused. As required by paragraph 6.11. each subcon- tract between CONTRACTOR and a Subcontractor will contain similar waiver provisions by the Subcontractor in favor of OWNER. CONTRACTOR. ENGINEER. ENGI- N EER' s consultants and all other parties named as insureds. None of the above waivers shall extend to the rights that any of the insured parties may have to the proceeds of insurance held by OWNER as trustee or otherwise pay- able under any policy so issued. I I I I I I 5.11.2. OWNER and CONTRACTOR intend that any policies ,provided in response to paragraphs 5.6 and 5.7 shall protel:t all of the parties insured and provide primary coverage for all losses and damages I:aused by the perils co\'ered thereby. A':l:ordingly. all such policies shall con- tain provisil.lns to [he dfect that in {he event of payment of any loss or damage the insurer will have no rights L)f reco\'ery against an\' of the parties named as insureds Llr additional insureds. and if the insurers require separ;lle waiver forms to b~ signed by ENGINEER or ENGI- ~ E ER' s cLlnsultant UW~ E R willllbtain th~ same. and if I I I such waiver forms are required of any Subcontractor. CONTRACTOR will obtain the same. Receipt and Applicalion of Proceeds: 5,12. Any insured loss under the policies of insurance required by paragraphs 5,6 and 5.7 will be adjusted with OWNER and made payable to OWNER as trustee for the insureds. as their interests may appear. subject to the require- ments of any applicable mortgage clause and of paragraph 5.13. OWNER shall deposit in a separate account any money so received. and shall distribute it in accordance with such agreement as the parties in interest may reach. If no other special agreement is reached the damaged Work shall be repaired or replaced. the moneys so received applied on account thereof and the Work and the cost thereof covered by an appropriate Change Order or Written Amendment. 5.13. OWNER as trustee shall have power to adjust and settle any loss with the insurers unless one of the parties in interest shall object in writing within fifteen days after the occurrence of loss to OWNER's exercise of this power, If such objection be made. OWNER as trustee shall make set- tlement with the insurers in accordance with such agreement as the parties in interest may reach. If required in writing by any party in interest. OWNER as trustee shall. upon the occurrence of an insured loss. give bond for the proper per- formance of such duties. Acceptance of Insurance: 5.14. If OWNER has any objection to the coverage afforded by or other provisions of the insurance req\:ired to be pur- chased and maintained by CONTRACTOR in accordance with paragraphs .5 ,3 and 5.4 on the basis. of its not complying with the Contract Documents, OWNER shall notify CON- TRACTOR in writing thereof within ten days of the date of delivery of such certificates to OWNER in accordance with paragraph 2.7. If CONTRACTOR has any objection to the coverage atTorded by or other provisions of the policies of insurance required to be purchased and maintained by OW1'I!ER in accordance with paragraphs 5.6 and 5.7 on the basis of their no~ complying with the Contract Documents. CON- TRACTOR shall notify OWNER in writing thereof within ten days of the date of delivery of such certificates to CON- TRACTOR in accordance with paragraph 2.7. OWNER and CONTRACTOR shall each provide to the other such addi- tional information in respect of insurance provided by each as the other may reasonably request. Failure by OWNER or CONTRACTOR to give any such notice of objection within the time provided shall constitute acceptance of such insur- ance purchased by the other as cumplying with the Contract Documents. Partwl L'tili:.ation-Property Insurance: ),15. If OWNER linds it necessarv to OI:CUPY or use a portion or ponions of the Work prior to Substantial Comple- [ion of all the Work. such use or occupancy may be accom- plished in accordanl:': with paragraph 14.10: provided that no 13 I I such use or occupancy shall commence before the insurers providing the property insurance have acknowledged notice thereof and in writing effected the changes in coverage neces- sitated thereby. The insurers providing the property insur- ance shall consent by endorsement on the l'Olicy or policies. but,the property insurance shall, not be cancelled or lapse on account of any such partial use or occupancy. I I I ARTICLE 6-CONTRACTOR'S RESPONSIBILITIES I Sup~rvision and SuperillU1Uienc~: 6.1. CONTRACTOR shall supervise and direct the Work competently and efficiently. devoting such attention thereto and applying such skills and expenise as may be necessary to perform the Work in accordance with the Contract Doc- uments. CONTRACTOR shall be solely responsible for the' means. methods. techniques. sequences and procedures of construction. but CONTRACTOR shall not be responsible for the negligence of others in the design or selection of a specific means. method. technique. sequence or procedure of construction which is indicated in and required by the Contract Documents. CONTRACTOR shall be responsible to see that the finished Work complies accurately with the Contract Documents. I I I I 6.1. CONTRACTOR shall keep on the Work at all times during its progress a competent resident superintendent. who shall not be replaced without written notice to OWNER and ENGINEER except under extraordinary circumstances. The superintendent will be CONTRACTOR's representative at the site and shall have authority to act on behalf of CON- TRACTOR. All communications given to the superintendent shall be as binding ,as if given to CONTRACTOR. I I I iAJlor. MarerUUs and Equipment: 6.3. CONTRACTOR shall provide competent. suitably qualified personnel to survey and layout the Work and per- form construction as required by the Contract Documents. CONTRACTOR shall at all times maintain good discipline and order at the site. Except in connection with the safety or protection of persons or the Work or property at the site or adjacent thereto. and except as otherwise indicated in the Contract Documents. all Work at the site shall be performed during regular working hours. and CONTRACTOR will not permit overtime work or the performance of Work on Sat- urday. Sunday or any legal holiday without OWNER's writ- len consent given after prior written notice to ENGINEER. I I I I 6.4, Unless otherwise specified in the General Require- mems. CONTRACTOR shall furnish and assume full respon- sibility for all materials. equipment. labor. transportation. construction equipment and machinery, lools. appliances, fuel. power. light. heat. telephone. water. sanatary facilities. temporary facilities and all other facilities and incidentals necessary for the furnishing. performance. testing. stan-up and completion of the Work. I I 6.5. AU materials and equipment shall be of good quality and new. except as otherwise provided in the Comract Doc- uments. If required by ENGINEER. CONTRACTOR shall furnish satisfactory evidence (including reports of required tests) as to the kind and quality of materials and equipment. All materials and equipment shall be applied. installed. con- nected. erected. used. cleaned and conditioned in accordance with the instrUctions of the applicable Supplier except as otherwise provided in the Contract Documents: but no pro- vision of any such instructions will be effective to assign to ENGINEER. or any of ENGINEER's consultants. agents or employees. any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or author- ity to undenake responsibility contrary to the provisions of paragraph 9.15 or 9.16. Adjusting Progress Schedule: 6.6. CONTRACTOR shall submit to ENGINEER for acceptance Ito the extent indicated in paragraph 1.91 adjust- ments in the progress schedule to reflect the impact thereon of new developments: these win conform generally to the progress schedule then in effect and additionally will comply with any provisions of the General Requirements applicable thereto. SubstUllleJ or "Or-EqUlJi" It~ms: 6.7.1. Whenever materials or equipment are specified or described in the Contract Documents by using the name of a proprietary item or the name of a panicular Supplier the naming of the item is intended to establish the type. function and quality required. Unless the name is followed by words indicating that no substitution is permitted. materials or equipment of other Suppliers may be accepted by ENGINEER if sufficient information is submitted by CONTRACTOR to allow ENGINEER to determine t~at the material or equipment proposed is equivalent or equal, to that named. The procedure for review by ENGINEER will include the following as supplemented in the General, Requirements. Requests for review of substitute items of material and equipment will not be accepted by ENGI- NEER from anyone other than CONTRACTOR. If CON. TRACTOR wishes to furnish or use a substitute item of material or equipment. CONTRACTOR shall make writ- ten application to ENGINEER for acceptance thereof. certifying that the proposed substitute will perform ade- quately the functions and achieve the results called for by the general design. be similar and of equal substance to that specified and be suited to the same use as that spec- ified. The application will state that the evaluation and acceptance of the proposed substitute will not prejudice CONTRACTOR's achievement of Substantial Comple- tion on time. whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with OWNER for work on the Project) to adapt the design to the proposed substitute and whether or not incorporation or use of the substitute in connection with the Work is subject to payment or" any license iee or 14 I I royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance. repair and replacement service will be indi- cated. The application will also contain an itemized esti- mate of all costs that will result directly or indirectly from acceptance of such substitute. including costs of redesign and claims of other contractors affected by the resulting change. all of which shall be considered by ENGINEER in evaluating the'proposed substitute. ENGINEER may require CONTRACTOR to furnish at CONTRACTOR's expense additional data about the proposed substitute, I I I 6.7.2. If a specific means. method. technique. sequence or procedure of construction is indicated in or required by the Contract Documents. CONTRACTOR may furnish or utilize a substitute means. method. sequence. technique or procedure of construction acceptable to ENGINEER. if CONTRACTOR submits sufficient information to allow ENGINEER to determine that the substitute proposed is equivalent to that indicated or required by the Contract Documents, The procedure for review by ENGINEER will be similar to that orovided in paragraph 6.7.1 as applied by ENGINEER and as may be supplemented in the Gen- eral Requirements, I I I I 6.7.), ENGINEER will be allowed a reasonable time within which to evaluate each proposed substitute. ENGI- NEER will be the sole judge of acceptability. and no substitute will be ordered. installed or utilized without ENGINEER's prior written acceptance which will be evi- denced by either a Change Order or an approved Shop Drawing. OWNER may require CONTRACTOR to fur- nish atCONTRACTOR's expense a special performance guarantee or other surety with respect to any substitute. ENGINEER will record time required by ENGINEER and ENGINEER's consultants in eva:uating substitutions proposed by CONTRACTOR dnd in making changes in the Contract Documents occasioned thereby, Whether or not ENGIN EER accepts a proposed substitute. CON- TRACTOR shall reimburse OWNER for the charges of ENGINEER and ENGINEER's consultants for evaluat- ing each proposed substitute. I I I I I Conceming Subcontractors, Suppliers and Others: 6.8.1, CONTRACTOR shall not employ any Subcon- tractor. Supplier or other person or organization I including those acceptable to OWNER and ENGINEER as indi- cated in paragraph 6.8.2). whether initially or as a substi- tute. against whom OWNER or ENGINEER may ha\'e reasonable objection. CONTRACTOR shall not be required to employ any Subcontractor. Supplier or other person llr organization to furnish or perform any of the Work against whom CONTRACTOR has reasonable objectil1O, _ 6.~,2. If the Supplementary Conditions require the identity of .:ertain Subcontractors, Suppliers or other per- sons or \lrganizatillns I incluuing those who are 10 furnish the principal items of materials and equipment I (0 be sur-- mined to OWNER in advunce of the specified date prillr to (he EI'f.:ctive Dat.: of the ,\greement for acc.:nrance r-\ I I I I I OWNER and ENGINEER and if CONTRACTOR has submitted a list thereof in accordance with the Supple- mentary Conditions. OWNER's or ENGINEER's accept- ance (either in writing or by failing to make written objec- tion thereto by the date indicated for acceptance or objec- tion in the bidding documents or the Contract Documents) of any such Subcontractor. ~upplier or other person or organization so identified may be revoked on the basis of reasonable objection after due investigation. in which case CONTRACTOR shall submit an acceptable substitute. the Contract Price will be increased by the difference in the cost occasioned by such substitution and an appropriate Change Order will be issued or Written Amendment signed. No acceptance by OWNER or ENGINEER of any such Subcontractor. Supplier or other person or organization shall constitute a waiver of any right of OWNER or ENGI- NEER to reject defecril'e Work. 6.9. CONTRACTOR shall be fully responsible to OWNER and ENGINEER for all acts and omissions of the Subcon- tractors. Suppliers and other persons and organizations per- forming or furnishing any of the Work under a direct or indirect contract with CONTRACTOR just as CONTRAC- TOR is responsible for CONTRACTOR's own acts and omis- sions. Nothing in the Contract Documents shall create any contractual relationship between OWNER or ENGINEER and any such Subcontractor. Supplier or other person or organization. nor shall it create any obligation on the part of OWNER or ENGINEER to payor to see to the payment of any moneys due any such Subcontractor. Supplier or other person or organization except as may otherwise be required by Laws and Regulations, 6.10. The divisions and sections of the Specifications and the identifications of any Drawings shall not control CON- TRACTOR in dividing the Work among Subcontractors or Suppliers or delineating the Work to be perfonned by any specific trade. 6, II. .-\11 Work performed for CONTRACTOR by a Sub- contracter will be pursuant to an appropriate agreement between CONTRACTOR and the Subcontractor which spe- cifically binds the Subcontractor to the applicable terms and conditions of the Contract Documents for the benefit of OWNER and ENGINEER and contains waiver provisions as required by paragraph 5.11. CONTRACTOR shall pay each Subcontractor a just share of any insurance moneys received by CONTRACTOR on account of losses under pol- icies issued pursuant to paragraphs 5.6 and 5.7, Patent Fees and Royalties: 6,12. CONTRACTOR shall pay all license fees and roy- alties and assume all costs incident to the use in the perfor- mance of the Work or the incorporation in the Wurk of any invention. uesign. process. product or uevice which is (he subject of patent rights llr copyrights ht:lu h~' lHhers, If a particular invention. design. process. product or device is specified in (he Contract Documents for use in the perfor- mance of the Work and if III the actual knowledge ufOWNER 15 I I or ENGINEER its use is subject to patent rights or copyrights camog for the payment of any license fee or royalty to others. I the existence of such rights shall be disclosed by OWNER in the Contraet Documents. CONTRACTOR shall indemnify and hold harmless OWNER and .ENGINEER and anyone directly or indirectly employed by either of them from and I against all claims. damages. losses and expenses (including attorneys' fees and coun and arbirration costs) arising out of any infringement of patent rights or copyrights incident to I the use in the perfonnance of the Work or resulting from the incorporation in the Work of any invention. design. process. product or device not specified in the Contract Documents. and shall defend all such claims in connection with any alleged I infringement of such rights. Permia: I 6.13. Unless otherwise provided in the Supplementary Conditions..CONTRACTOR shall obtain and pay for all con. struction pennits and licenses. OWNER shall assist CON- I TRACTOR. when necessary. in obtaining such pennits and licenses. CONTRACTOR shall pay all governmental charges and inspection fees necessary for the prosecution of the Work. I which are applicable at the time of opening of Bids. or if there are no Bids on the Effective Date of the Agreement. CON. TRACTOR shall pay all charges of utility owners for con- nections to the Work. and OWNER shall pay all charges of I such utility owners for capital costs related thereto such as plant investment fees. I Laws and ReguiJllio1U: 6.14.1. CONTRACTOR shall give all notices and comply with all Laws and Regulations applicable to fur- nishing and performance of the Work. Except where oth- erwise expressly required by applicable Laws and Regu- lations. neither OWNER nor ENGINEER shall be respon- sible for monitoring CONTRACTOR's compliance with any Laws or Regulations. I I 6.14.2. If CONTRACTOR observes that the Specifi. cations or Drawings are at variance with any Laws or Regulations. CONTRACTOR shall give ENGINEER prompt written notice thereof. and any necessary changes will be authorized by one of the methods indicated in paragraph 3.4. If CONTRACTOR performs any Work knowing or having reason to know that it is contrary to such Laws or Regulations. and without such notice to ENGINEER. CONTRACTOR shall bear all costs arising therefrom: however. it shall not be CONTRACTOR's pri- mary responsibility to make cenain that the Specifications and Drawings are in accordance with such Laws and Regulations. I I I I Tazes: I 6.15. CONTRACTOR shall pay all sales. consumer. use and other similar taxes required to be paid by CONTRAC- TOR in accordance with the Laws and RegulaLions of the I place of the Project which arc applicable during the pertor. mance of the Work. Vn of Pn"we:s: 6.16. CONTRACTOR shall confine construction equip- ment. the storage of materials and equipment and theoper- ations of workers to the Project site and land and areas iden- tified in and permitted by the Conrract Documents and other land and areas pennitted by Laws and Regulations. rights- of-way. penn its and easements. and shall not unreasonably encumber the premises with construction equipment or other materials or equipment. CONTRACTOR shall assume full responsibility for any damage to any such land or area. or to the owner or occupant thereof or of any land or areas contig- uous thereto. resulting from the performance of the Work. Should any claim be made against OWNER or ENGINEER by any such owner or occupant because of the performance of the Work. CONTRACTOR shall promptly anempt to settle with such other party by agreement or otherwise resolve the claim by arbirration or at law. CONTRACTOR shall. to the fullest extent pennined by Laws and Regulations. indemnify and hold OWNER and ENGINEER hannJess from and against all claims. damages. losses and expenses (including. but not limited to. fees of engineers. architects. anorneys and other professionals and court and arbitration costs) arising directly. indirectly or consequentially out of any action. legal or equi- table. brought by any such other party against OWNER or ENGINEER to the extent based on a claim arising out of CONTRACTOR's perfonnance of the Work. 6.17. During the progress of the Work. CONTRACTOR shall keep the premises free from accumulations of waste materials. rubbish and other debris resulting from the Work. At the completion of the Work CONTRACTOR shall remove all waste materials. rubbish and debris from and about the premises as well as all tools. appliances. construction equip" ment and machinery. and surplus materials. and shall leave the site clean and ready for occupancy by OWNER. CON- TRACTOR shall restoJ:e to original condition all propeny not designated for alteration by the Contract Documents. 6.18. CONTRACTOR shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure. nor shall CONTRACTOR subject any part of the Work or adjacent property to stresses or pressures that will endanger it. Record Documents: 6.19. CONTRACTOR shall maintain in a safe place at the site one record copy of all Drawings. Specifications. Aduenda. Written Amendments. Change Orders. Work. Directive Changes. Field Orders and written interpretations and clarifications (issued pursuant to paragraph 9.4) in good order and annotated to show all changes made during con- struction. These record documents together with all approved samples and a counterpan of all approved Shop Drawings will be available to ENGINEER for reference. Upon com- 16 I I pletion of the Work. these record documents. samples and Shop Drawings will be delivered to ENGINEER for OWNER. I Safety and Protection: 6.20. CONTRACTOR shall be responsible for initiating. maintaining and supervising all safety precautions and pro- grams in connection with the Work. CONTRACTOR shall take all necessary precautions for the safetY of. and shall provide the necessary protection to prevent damage. injury or loss to: I I I 6.20,1. all employees on the Work and other persons and organizations who may be atTected thereby: I 6.20,2. all the Work and materials and equipment to be incorporated therein. whether in storage on or off the site: and I 6.20.3, other property at the site or adjacent thereto. including trees. shrubs. lawns. walks. pavements. road- ways. structures. utilities and Underground Facilities not designated for removal. relocation or replacement in the course of construction. I CONTRACTOR shall comply with all applicable Laws and Regulations of any public body having jurisdiction for the safety of persons or property or to protect them from damage. injury or loss: and shall erect and maintain all necessary safeguards for such safety and protection. CONTRACTOR shall notify owners of adjacent property and of Underground Facilities and utility owners when prosecution of the Work may affect them. and shall cooperate with them in the pro- tection. removal. relocation and replacement of their prop- erty. .-\11" damage. injury or loss to any property referred to in paragraph 6,20.2 or 6,20,3 caused. directly or indirectly, in whole or in part. by CONTRACTOR. any Subcontractor. Supplier or any other person or organization directly or indi- rectly employed by any of them to perform or furnish any: 01 the Work or anyone for whose acts any of them may be liable.' shall be remedied by CONTRACTOR (except damage or loss attributable to the fault of Drawings or Specifications or to the acts or omissions of OWNER or ENGINEER or anyone employed by either of them or anyone for whose acts either of them may be liable. and not attributable. directly or indi- rectly, in whole or in part. to the fault ur negligence uf CO:-';. TR.-\CTORl. CONTRACTOR's duties and respllOsibilities for the safety and protection uf the Wurk shall cuntinue until such time as all the Work is completed and ENGI~EER has issued a notice to OWN ER and CONTRACTOR in accord- ance Illth paragraph 14,13 that the Work is acceptable lexcept as otherwise expressly provided in connection wjth Substan- rial Completiun). I I I I I I I I 6,21, CONTRACTOR shall designate a respl1nsible rep- resent;lli\"<: ;\1 the ,ile whuse dUll' ,hall b<: the rr<:lemilln 11r" accillents. This persun shall be CONTR,-\CTOR' s superin- tendent unless utherwise designated in writin~ by CO;-..;- TR.-\CTOR tll OWN ER, I I Emergencies: 6.22. In emergencies affecting the safety or protection of persons or the Work or property at the site or adjacent thereto. CONTRACTOR. without special instruction or authorization from ENGINEER or OWNER. is obligated to act to prevent threatened damage. injury or loss. CONTRACTOR shall give ENGINEER prompt written notice if CONTRACTOR believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby, If ENGI- 'NEER determines that a change in the Contract Documents is required because of the action taken in response to an emergency. a Work Directive Change or Change Order will be issued to document the consequences of the changes or variations. Shop Drawings and Samples: 6.23. After checking and verifying all field measurements and after complying with applicable procedures specified in the General Requirements. CONTRACTOR shall submit to ENGINEER for review and approval in accordance with the accepted schedule of Shop Drawing submissions t see para-' graph 2.9), or for other appropriate action if so indicated in the Supplementary Conditions. five copies (unless otherwise specified in the General Requirements) of all Shop Drawings. which will bear a stamp or specific written indication that CONTRACTOR has satisfied CONTRACTOR's responsi-, bilities under the Contract Documents with respect to the review of the submission. All submissions will be identified as ENGINEER may require. The data shown on the Shop Drawings will be complete with respect to quantities, dimen- sions. specified performance and design criteria. materials and similar data to enable ENGINEER to review the infor- mation as required. 6.24, CONTRACTOR shall also submit to ENGI~EER for review and approval with such prompmess as to cause no delay in Work. all samples required by l~e Contract Doc- uments. All samples will have been checked bv and accom- panied by a specific written indication that CONTRACTOR has satisfied CONTRACTOR's responsibilities under the COntract Documents with respect to the review of the sub- mission and will be identified clearly as to material. S4Pplier. pertinent data such as catalog numbers and the use for which intended. 6.25.1, Before submission of each Shop Drawing or sample CONTR.-\CTOR shall have determined and veri- fied all quantities. dimensions, specified performance cri- teria. installation requirements. materials. catalog num- bers and similar data Ililh respect thereto and reviewed or coordinated each Shop Drawing or sample with other Shop Drawings and samples and with the requirements of [he Work and the Contract Documents. 6.25.2, At the lime Ilf each submission. CONTRAC- TOR shall give E~G I ~ E ER ~pe(iric wrillen nOlicl: of each variatiun that the Shop Drawings or samples may have from the requirements Ill' the Cl.lOtract Documents. and. in additilln, shall \:ause ;\ ~l'lecitic nOlatiun 10 he maue nn 17 I I each Shop Drawing submitted to ENGINEER for review and approval of each such variation. I 6.26. ENGINEER will review and approve with reason- able promptness Shop Drawings and samples. but ENGI- NEER's review and approval will be only for conformance with the design concept of the Project and for compliance with the information given in the Contract Documents and shall not extend to means. methods. techniques. sequences or procedures of constnlction (except where a specific means. method. technique. sequence or procedure of constnlction is indicated in or required by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. CON- TRACTOR shall make corrections required by ENGINEER. and shall return the required number of corrected copies of Shop Drawings and submit as required new samples for review and approval. CONTRACTOR shall direct specific attention in writing to revisions other than the corrections called for by ENGINEER on previous submittals. I I I I I 6.27. ENGINEER's review and approval of Shop Draw- ings or samples shall not relieve CONTRACTOR from responsibility for any variation from the requirements of the Contract Documents unless CONTRACTOR has in writing called ENGINEER's attention to each such variation at the time of submission as required by paragraph 6.15.1 and ENGINEER has given written approval of each such varia- tion by a specific written notation thereof incorporated in or accompanying the Shop Drawing or sample approval: nor will any approval by ENGINEER relieve CONTRACTOR from responsibility for errors or omissions in the Shop Draw- ings or from responsibility for having complied with the pro- visions of paragraph 6.15.1. I I I I 6.28. Where a Shop Drawing or sample is required by the Specifications. any related Work pen"ormed prior to ENGI- NEER's review and approval of the pertinent submission will be the sole expense and responsibility at' CONTRACTOR. I I Continuing the Work: 6.29. CONTRACTOR shall carry on the Work and adhere to the progress schedule during all disputes or disagreements with OWNER. No Work shall be delayed or postponed pend- ing resolution of any disputes or disagreements. except as permitted by paragraph 15.5 or as CONTRACTOR and OWNER may otherwise'agree in writing. I I J ruUmniftatiDn: 6.30. To the fullest extent permitted by Laws and Regu- lations CONTRACTOR shall indemnify and hold harmless OWNER and ENGINEER and their consultants. agents and employees from and against all claims. damages, losses and expenses. direct. indirect or consequential (including but not limited to fees and charges of engineers. architects. attorneys and other professionals and court and arbitration costs) aris- ing out 01 or reSUlting Irom the periormance of the Work. I I I provided that any such claim. damage. loss or expense (al is attributable to bodily injury. sickness. disease or death. or to injury to or destnlction of tangible property (other than the Work itselO including the loss of use resulting therefrom and (b) is caused in whole or in part by any negligent' act or omission of CONTRACTOR. any Subcontractor. any person or organization directly or indirectly employed by any of them to perform or furnish any of the Worle or anyone for whose acts any of them may be liable. regardless of whether or not it is caused in part by a party indemnified hereunder or arises by or is imposed by Law and Regulations regardless of the negligence of any such party. 6.31. In any and all claims against OWNER or ENGI. NEER or any of their consultants. agents or employees, by any employee of CONTRACTOR. any Subcontractor. any person or organization directly or indirectly employed by any of them to perform or furnish any of the Work or anyone for whose acts any of them may be liable. the indemnification obligation under paragraph 6.30 shall not be limited in any way by any limitation on the amount or type of damages. compensation or benefits payable by or for CONTRACTOR or any such Subcontractor or other person or organization under workers' or worlemen's compensation acts. disability benefit acts or other employee benefit acts. 6.32. The obligations of CONTRACTOR under para- graph 6.30 shall not extend to the liability of ENGINEER. ENGINEER's consultants. agents or employees arising out of the preparation or approval of maps. drawings, opinions. reports. surveys. Change Orders. designs or specifications. ARTICLE 7-0THER WORK Reltued Work al Sile: 7.1. OWNER may perfonn other work related to the Proj. ect at the site by OWNER's own forces. have other work perfonned by utility owners or let other direct contracts therefor, which shall contain General Conditions similar to these. If the fact that such other work is to be performed was not noted in the Contract Documents. written notice thereof will be given to CONTRACTOR prior to starting any such other work: and. if CONTRACTOR believes that such perfor- mance will involve additional expense to CONTRACTOR or requires additional time and the parties are unable to agree as to the extent thereof. CONTRACTOR may make a claim therefor as provided in Articles 11 and 12. 7;1., CONTRACTOR shall afford each utility owner and other contractor who is a party to such a direct contract (or OWNER. if OWNER is performing the additional worle with , OWNER's employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work. and shall properly connect and coordinate the Work with theirs. CONTRACTOR shall do all cutting. fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. CON. 18 I I TRACTOR shall not endanger any work of others by cutting. excavating or otherwise altering their work and will only cut or alter their work with the written consent of ENGINEER and the others whose work will be affected. The duties and responsibilities 'of CONTRACTOR under this paragraph are for the benefit of such utility owners and other contractors to the extent that there are comparable provisions for the benefit of CONTRACTOR in said direct contracts between OWN ER and such utility owners and other contractors. I .1 I 7.3. If any part of CONTRACTOR's Work depends for proper execution or results upon the work of any such other contractor or utility owner (or OWNER1.'CONTRACTOR shall inspect and promptly report to ENGINEER in writing any delays. defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. CONTRACTOR's failure so to report will constitute an acceptance of the other work as fit and proper for integra- tion with CONTRACTOR's Work except for latent or non- apparent defects and deficiencies in the other work. I I I Coordination: 1 7.4. If OWNER contracts with others for the perfor- mance of other work on the Project at the site. the person or organization who will have authority and responsibility for coordination of the activities among the various prime con- tractors will be identified in the Supplementary Conditions. and the specific matters to be covered by such authority and responsibility will be itemized. and the extent of such author- ity and responsibilities will be provided. in the Supplementary Conditions. Unless otherwise provided in the Supplementary Conditions. neither OWNER nor ENGINEER shall have any authority or responsibility in respect of such coordination. 1 1 I ARTICLE 8-0WNER'S RESPONSIBILITIES I 8. I. OWN ER shall issue all communications 10 CON- TRACTOR through ENGINEER. I 8,:!. In case of termination of the employment of ENGI- NEER. OWNER shall appoint an engineer against whom CONTRACTOR makes no reasonable objection. whose sta- tus under the Contract Documents shall be that of the former ENGINEER. Any dispute in connection with such appoint- ment shall be subject to arbitration, I I 8.3, OWNER shall furnish the data required of OWNER under the Contract Documents promptly and shall make pay- ments to CONTRACTOR promptly after they are due as provided in paragraphs 14,4 and 14.13. I SA. OWNER's duties in respect 9f providing lands and easements and providing engineering surveys to establish reference points are set forth in paragraphs ~,I and 4,4, Para- graph 4.:; refers to OWNER's identifying and making avail- able to CONTRACTOR copies of reportS of explorations and tests of 'iUhSlIl1'ace I.:onditions at the site and in e:'(Isting strtll.:- I I tures which have been utilized by ENGINEER in preparing the Drawings and Specifications. 8.5. OWNER's responsibilities in respect of purchasing and maintaining liability and property insurance are set forth in paragraphs 5.5 through 5.8. 8.6. OWNER is obligated to execute Change Orders as indicated in paragraph 10.4. 8.7. OWNER's responsibility in respect of certain inspections. tests and approvals is set forth in paragraph 13.4. 8,8. In connection with OWNER's right to stop Work or suspend Work. see paragraphs 13.10 and Ij.l. Paragraph 15.2 deals with OWNER's right to terminate services of CON- TRACTOR under certain circumstances. ARTICLE 9-ENGINEER'S STATUS DURING CONSTRUCTION Owner's Representative: 9.1. ENGINEER will be OWNER's representative dur- ing the construction period. The duties and responsibilities and the limitations of authority of ENG INEER as OWNER's representative during construction are set forth in the Con- tract Documents and shall riot be extended without \\.:ritten consent of OWNER and ENGINEER. Visits to Site: 9.2. ENGINEER will make visits to the site at intervals appropriate to the various stages of construction to observe the progress and quality of the executed Work and to deter- mine. in general. if the Work is proceeding in accordance with the Contract Documents. E~GINEER will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. ENGINEER's .:ffons will be directed toward providing for OWNER a greater,degree of confidence that the completed Work will conform to the Contract Documents. On the basis of such visits and on-site observations as an experienced and qualified design, profes- sional. ENGINEER will keep OWNER'informed of the prog- ress of the Work and will endeavor to guard OWNER against defects and deficiencies in the Work. Project Representation: 9.3. If OWNER and ENGINEER agree. ENGINEER will furnish a Resident Project Representative to assist ENGINEER in observing the performance of the Work, The duties. responsibilities and limitations of authority lJf any such Resident Project Representative and assistants will be as provided in the Supplementary Conditions. If OWNER designates another agent to represen[ OWNER at [he site who is not ENGINEER's agent or employee. [he duties. responsibilities and limitations of authority of such other L'erson will he as provided in the Supplementarv Conditions, 19 I I C/izrijiazJions llIUi 1~llIIiDns: 9.4. ENGINEER wiU issue with reasonable promptness such wrinen clarifications or interpretations of the require- ments of the Contract Documents (in the form of Drawings or otherwise) as ENGINEER may detcnnine necessary, which shall be consistent with or reasonably inferable from the overall intent of the Contract Documents. If CONTRACTOR believes that a wrinen clarification or interpretation justifies an increase in the Contract Price or an extension of the Contract Time and the parties are unable to agree to the amount or extent thereof. CONTRACTOR may malee a claim therefor as provided in Anicle 11 or Article 12. I I I I AUlhoriud VariluiDns ill Wor*: 9.5. ENGINEER may authorize minor variations in the Worle from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the , Contract Time and are consistent with the overall intent of the Contract Documents. These may be accomplished by a Field Order and wiU be binding on OWNER. and also on CONTRACTOR who shall perform the Worle involved promptly. If CONTRACTOR believes that a Field Order justifies an increase in the Contract Price or an extension of the Contract Time and the parties are unable to agree as to the amount or extent thereof. CONTRACTOR may malee a claim therefor as provided in Anicle 11 or 12. I I I I Rljleling Dlflen"l Wor*: 9.6. ENGINEER will have authority to disapprove or reject Work which ENGINEER believes to be defective, and will also ha ve authority to require special inspection or testing of the Work as provided in paragraph 13.9. whether or not the Work is fabricated, installed or completed. I I Shop Drawings, Change Ordus and Payments: 9.7. In connection with ENGINEER's responsibility for Shop Drawings and samples. see paragraphs 6.13 through 6.29 inclusive. I I 9.8. In connection with ENGINEER's responsibilities as to Change Orders. see Articles 10, 11 and 11. I 9.9. In connection with ENGINEER's responsibilities in respect of Applications for Payment. etc.. see Article 14. I DlllrmilUllions for Unit pricis: 9.10. ENGINEER will determine the actual quantities and classifications of Unit Price Work periormed by CON- TRACTOR. ENGINEER wiU review with CONTRACTOR ENGINEER's preliminary determinaLions on such matters before rendering a written decision thereon (by recommen. dation of an Application for Payment or otherwise). ENGI- NEER's written decisions thereon will be final and binding upon OWNER and CONTRACTOR. unless. within ten days after the date of any such decision. either OWNER or CON- TRACTOR delivers to the other party to the Agreement and I I I to ENGINEER wrineD notice of intention to appeal from such a decision. DlcisiDns on Dispuus: 9.11. ENGINEER will be the initial interpreter of the requirements of the ContraCt Documents and judge of the acceptability of the Worle thereunder. Claims. disputes and other matters relating to the acceptability of the Work or the interpretation of the requirements of the Contract Documents pertaining to the performance and furnishing of the Work and claims under Articles 11 and 12 in respect of changes in the ContraCt Price or Contract Time will be referred initially to ENGINEER in writing with a request for a formal decision in accordance with this paragraph. which ENGINEER will render in writing within a reasonable time. Written notice of each such claim. dispute and other maneI' will be delivered by the claimant to ENGINEER and the other party to the Agreement promptly (but in no event tater than thirty days) after the occurrence of the event giving rise thereto. and written supporting data will be submitted to ENGINEER and the other party within sixty days after such occurrence unless ENGINEER allows an additional period of time to ascertain more accurate data in support of the claim. 9.12. ,When functioning as interpreter and judge under paragraphs 9.10 and 9.11. ENGINEER will not show par- tiality to OWNER or CONTRACTOR and will nOI be liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by ENGINEER pursuant to paragraphs 9.10 and 9.11 with respect to any such claim. dispute or other matter (except any which have been waived by the making or acceptance of final pay. ment as provided in paragraph 14.16) will be a condition precedent to any exercise by OWNER or CONTRACTOR of such rights or remedies as either may otherwise have under lhe Contract Documents or by Laws or Regulations in respect of any such claim. dispute or other matter. Limiuuions on ENGINEER's Responsibilities:' ,9.13. Neither ENGINEER's authority to act under this Article 9 or elsewhere in the Contract Documents nor any decision made by ENGINEER in good faith either to exercise or nOI exercise such authority shall give rise to any duty or responsibility of ENGINEER to CONTRACTOR. any Sub- contractor. any Supplier. or any other person or organization performing any of the Work. or to any surety for any of them. 9.14. Whenever in the Contract Documents the terms "as ordered", .. as directed". .. as required", .. as allowed", .. as approved" or terms of like effect or import are used. or ,the adjectives "reasonable", "suitable". "acceptable". "proper" or "satisfactory" or adjectives of like effect or import are used to describe a requirement. direction. review or judgment of ENGINEER as to the Work. it is intended that such requirement. direction. review or judgment will be solely to evaluate the Work for compliance with lhe Contract Docu- ments (unless there is a specific statement indicating other- wise). The use of any such term or adjective shall not be 20 I I effective to assign to ENGINEER any duty or authority to supervise or direct the furnishing or perfonnance of the Work or any duty or authority to undertake responsibility contrary to the provisions of paragraph 9.15 or 9.16. I I 9,.15. ENGINEER will not be responsible for CON- TRACTOR's means. methods. techniques. sequences or pro- cedures of construction. or the safety precautions and pro- grams incident thereto. and ENGINEER will not be respon- sible for CONTRACTOR's failure to perfonn or furnish the Work in accordance with the Contract Documents, I 9,16. ENGINEER will not be responsible for the acts or omissions of CONTRACTOR or of any Subcontractor. any Supplier. or of any other person or organization perfonning or furnishing any of the Work. I I ARTICLE H)--CHANGES IN THE WORK I I 10.1. Without invalidating the Agreement and without notice to any surety. OWNER may. at any time or from time to time. order additions. deletions or revisions in the Work: these will be authorized by a Written Amendment. a Change Order. or a Work Directive Change. Upon receipt of any such document. CONTRACTOR shall promptly proceed with the Work involved which will be perfonned under the applicable conditions of the Contract Documents (except as otherwise specifically provided). . I I 10,2, If OWNER and CONTRACTOR are unable to agree as to the extent. if any. of an increase or decrease in the Contract Price or an extension or shortening of the Contract Time that should be allowed as a result of a Work Directive Change. a claim may be made therefor as provided in Article 11 or Anicfe 12. I I 10,3, CONTRACTOR shall not be entitled to an increase in the Contract Price or an extension of the Contract Time with respect to any Work perfonned that is not required by the Contract Documents as amended. modified and supple. mented as provided in paragraphs 3.4 and 3.5. except in the case of an emergency as provided in paragraph 6.22 and except in the case of uncovering Work as provided in para- graph 1],9, I I 10.... OWNER and CONTRACTOR shall execute appro- priate Change Orders (or Written Amendments) covering: I lOA. I. changes in the Work which are ordered by OWNER pursuant to paragraph 10.1. are required because of acceptance of Jeji!cril'e Work under paragraph 13,1.; ur correcting ddi!ctil'e Work under paragraph 13,1~, ur are: ;.\greed to b\' the panies: I I 10A.2. changes in the Cuntract Price or Contract Time: which are agreed to lw the parties: and I 10.4.3. changes in the Contract Price or Contract Time which embody the substance of any written decision ren- dered by ENGINEER pursuant to paragraph 9.11: provided that. in lieu of executing any such Change Order. an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations., but during any such appeal. CON- TRACTOR shall carry on the Work and adhere to the prog- ress schedule as provided in paragraph 6.29. 10.5" If notice of any change affecting rhe general scope of the Work or the provisions of the Contract Documents (including. but not limited to. Contract Price or Contract Timel is required by the provisions of any Bond to be given to a surety. the giving of any such notice will be CONTRAC- TOR's responsibility. and the amount of each applicable Bond will be adjusted accordingly. ARTICLE II-CHANGE OF CONTRACT PRICE 11.1. The Contract Price constitutes the total compen- sation (subject to authorized adjustments) payable to CON- TRACTOR for perfonning the Work. All duties. responsibil- ities and obligations assigned to or undertaken by CON- TRACTOR shall be at his expense without change in the Contract Price. 11.2. The Contract Price may only be changed by a Change Order or by a Written Amendment. Any claim for an increase or decrease in the Contract Price shall be based on written notice delivered by the party making the claim to the other party and to ENGINEER promptly (but in no event later than thirtv davs) after the occurren~e of the, event giving rise to the ~Iai~ and statim! the 2eneral nature of the claim. Notice of the amount of the claim with sUPPo,rting data shall be delivered within sixty days after such occurrence (unless ENGINEER allows an additional period of time to ascenain more accurate data in suppon of the claim) and shall be accompanied by claimant's written statement that the amount claimed covers all known amounts (direct. indirect and con- sequentiaJ) to which the claimant is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Price shall be determined by ENGINEER in accor. dance with paragraph 9.11 if OWNER and CONTRACTOR cannot otherwise agree on the amount involved. No claim for an adjustment i; the Contract Price will be valid if not submitted in accordance with this paragraph 11.2. 11.3, The value of any Work covered by a Change Order or of any claim for an increase or decrease in the Contract Price shall be determined in one of the following ways: 11,3.1, Where the Work involved is covered by unit prices contained in the Cuntract Documents. by applica- tion of unit prices to the quantities of the items involved (subject to the provisions of paragraphs 11. 9. I. through 11,9,3, inclusive!. ~I I I 11.3.2. By mutual acceptance of a lump sum (which may include an allowance for overhead and profit not necessarily in accordance with paragraph 11.6.2.1). I I 11.3.3. On the basis of the Cost of the Work (deter. mined as provided in paragraphs 11.4 and 11.5) plus a CONTRACTOR's Fee for overhead and profit (deter- mined as provided in paragraphs 11.6 and 11.7). I COlto/the Work: 11.4. The term Cost of the Work means the sum of all I costs necessarily incurred and paid by CONTRACTOR in the proper performance of the Work. Except as otherwise may be agreed to in writing by OWNER. such costs shall be in amounts no higher than those prevailing in the locality of I the Project. shall include only the following items and shall not include any of the costs itemized in paragraph I U: I 11.4.1. Payroll costs for employees in the direct employ of CONTRACTOR in the performance of the Work under schedules of job classifications agreed upon by OWNER and CONTRACTOR. Payroll costs for employees not employed full time on the Work shall be apponioned on the basis of their time spent on the Work. Payroll costs shall include, but not be limited to, salaries and wages plus the cost of fringe benefits which shall include social security contributions. unemployment. excise and payroll taxes, workers' or worJcmen's compensation, health and retirement benefits, bonuses. sick leave. vacation and hol- iday pay applicable thereto. Such employees shall include superintendents and foremen at the site. The expenses of performing Work after regular working hours. on Satur- day. Sunday or legal holidays. shall be included in the above to the extent authorized by OWNER. I I I I I 1.4.2. Cost of all materials and equipment furnished and incorporated in the Work. including costs of trans- ponation and storage thereof. and Suppliers' field services required in connection therewith. All cash discounts shall accrue to CONTRACTOR unless OWNER deposits funds with CONTRACTOR with which to make payments. in which case the cash discounts shall accrue to OWNER. All trade discounts. rebates and refunds and all returns from sale of surplus materials and equipment shall accrue to OWNER. and CONTRACTOR shall make provisions so that they may be obtained. I I I I 11.4,3. Payments made by CONTRACTOR to the Subcontractors for Work performed by Subcontractors. If required by OWNER. CONTRACTOR shall obtain competitive bids from Subcontractors acceptllble to CON- TRACTOR and shall deliver such bids to OWNER who will then determine. with the advice of ENGINEER. which bids will be accepted. If a subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work Plus a Fee. the Subcontractor's Cost of the Work shall be determined in the same manner as CONTRAC- TOR's Cost oi the Work. All subcontracts shall be subject I I I to the other provisions of the Contract Documents insofar as applicable. 11.4.4. Costs of special consultants (including but not limited to'engineers. architects. testing laboratories. sur- veyors, attorneys and accountants) employed for services specifically related to the Work. 11.4.5. Supplemental costs including the following: 11.4.5.1. The proponion of necessary transpona. tion, travel and subsistence expenses of CONTRAC- TOR's employees incurred in discharge of duties con- nected with the Work. 11.4.5.2. Cost. including transponation and main- tenance. of all materials. supplies. equipment. machin- ery, appliances. office and temporary facilities at the site and hand tools not owned by the workers. which are consumed in the performance of the Work. and cost less market value of such items used but not consumed which remain the propeny of CONTRACTOR. 11.4.5.3. Rentals of all construction equipment and machinery and the pans thereof whether rented from CONTRACTOR or others in accordance with rental agreements approved by OWNER with the advice of ENGINEER, and the costS of uansponation. loading, unloading, installation, dismantling and removal thercof-all in accordance with terms of said rental agreements. The rental of any such equipment, machin- ery or pans shall cease when the use thereof is no longer necessary for the Work. 11.4.5.4. Sales. consumer, use or similar taxes related to the Work. and for which CbNTRACTOR is liable. imposed by Laws and ~egulations, 11.4.5.5. Deposits lost for causes other than negli- gence of CONTRACTOR. any Subcontractor or any- one directly or indirectly employed by any of them or . for whose acts any of them may be liable. and royalty payments and fees for permits and licenses. 11.4.5.6. Losses and damages (and related expenses). not compensated by insurance or otherwise. to the Work or otherwise sustained by CONTRACTOR in connection with the performance and furnishing of the Work (e){cept losses and damages within the deductible amounts of propeny insurance established by OWNER in accordance with paragraph 5.9l. pro- vided they have resulted from causes other than the negligence of CONTRACTOR. any Subcontractor. or anyone directly or indirecti}' employed by any of them or for whose acts any of them may be liable. Such losses shall include settlements made with the written consent and approval of OWNER. No such losses. damages and expenses shall be included in the Cost of the Work for the purpose of determining CONTRAC. TOR's Fee. If. however, any such loss or damage 22 I I requires reconstruction and CONTRACTOR is placed in charge thereof. CONTRACTOR shall be paid for services a fee proportionate to that stated in paragraph 11.6.2. I I 11.4.5.7, The cost of utilities. fuel and sanitary facilities at the site. I 11.4.5.8. Minor expenses such as telegrams. long distance telephone calls. telephone service at the site. expressage and similarpellY cash items in connection , with the Work. I 11.4,5.9. Cost of premiums for additional Bonds and insurance required because of changes in the Work and premiums for property insurance coverage within [he limits of the deductible amounts established by OWNER in accordance with paragraph 5.9. 11.5. The term Cost of the Work shall not include an~' of the following: I I 11,5.1, Payroll costs and other compensation of CON- TRACTOR's officers. executives. principals (of panner- ship and sole proprietorships). general managers. engi. neers. architects. estimators. allomeys. auditors. accoun- tants. purchasing and contracting agents. expeditors. timekeepers. clerks and other personnel employed by CONTRACTOR whether at the site or in CONTRAC- TOR's principal or a branch office for general administra- tion of the Work and not specifically included in the agreed upon schedule of job classifications referred to in para- graph 11,4.1 or specifically covered by paragraph 11.4.4- all of which are to be considered administrative costs covered by the CONTRACTOR's Fee. I I I I 11.5,2. Expenses pf CONTRACTOR's principal and brancrr offices other than CONTRACTOR's office at the site. I 11,5.3, ,-\ny part oiCONTRACTOR's capital expenses. including interest on CONTRACTOR'S capital employed' for the Work and charges against CONTRACTOR for delinquent payments. I 11.5.4. Cost of premiums for all Bonds and for all insurance whether or not CONTRACTOR is required by the Contract Documents to purchase and maintain the same t except for the cost of premiums covered by sub- paragraph 11.4.5,9 above). I I 11.5,5. Costs due to the negligence of CONTRAC. TOR. any Subcontr:lctor. or anyone directly llr indirectly employed by any of i~.:m or for who~e acts any of them may bc liahle, ir..:I'idin!; but not limited to. the correction of clt'f{.( ..:" '.. 'urk. Jisposal llf matcrials or equipment wrongly Sll, ,,! ,', ,: ......ak:r.g good any dam;lge to prop- ert\', I I 11.5.6. Other o\'erhead or general expense costs of any kind and the costs of any item not specifically and e,\pressl\' includc:d in paragraph II A, I CONTRACTOR's Fee: 11.6. The CONTRACTOR's Fee allowed to CONTRAC- TOR for overhead and profit shall be determined as follows: 11.6.1., a mutually acceptable fixed fee: or if none can be agreed upon. 11.6.2. a fee based on the following percentages of the various portions of the Cost of the Work: 11.6.1.1, for costs incurred under paragraphs 11.4.1 and 11.4.1. the CONTRACTOR's Fee shall be fifteen percent: 11.6.1.2. for costs incurred under paragraph 11.4.3. the CONTRACTOR's Fee shall be f.ve percent: and if a subcontract is on the basis of Cost of the Work Plus a Fee. the maximum allowable to CONTRACTOR on account of overhead and profit of all Subcontractors shall be fifteen percent: 11.6.1.3. no fee shall be payable on the basis of costs itemized under paragraphs 11.4.4, II..U and 11.5: 11.6.2.4. the amount of credit to be allowed by CONTRACTOR to OWNER for any such change which results in a net decrease in cost will be the amount of the actual net decrease plus a deduction in,CONTRAC- TOR's Fee by ao amount equal to ten percent of the net decrease: and 11.6.2.5. when both additions and credits are involved in anyone change. the adjustment in CON. TRACTO R' s Fee shall be computed on the basis of the net change in accordance with paragraphs 11.6.1..1 throLlgh 11.6.2.4. inclusive, 11.7. Whenever the cost of any Work is to be determined pursuant to paragraph 11.4 or 11,5, CONTRACTOR will submit in form acceptable to ENGINEER an itemized cost breakdown together with supporting data. Cash Allowances: 11.8. It is understood that CONTRACTOR has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be done by such Subcontractors or Suppliers and for such sums within the limit of the allowances as may be acceptable to ENGI- NEER. CONTRACTOR agrees that: 11.8.1. The allowances include the cost to CON- TRACTOR /less any applicable trade discounts) of mate- rials and equipment required by the allowances to be deliv ered at the site. and all applicable taxes: and 11.8.2, CONTRACTOR' s wsts for unloading and handling on the site. laoor. installation costs. overhead. profit and other expenses contemplated for the allowances have heen included in (he Contract Price and not in the 23 I I allowances. No demand for additional payment on account of any thereof will be valid.' I Prior to final payment. an appropriate Change Order will be issued as recommended by ENGINEER to reflect actual amounts due CONTRACTOR on account of Work covered by allowances. and the Contract Price shall be correspond- ingly adjusted. I I Unit Priu Work.' 11.9. I. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work. initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the established unit prices for each separately identified item of Unit Price Work times the estimated quantity of each item as indi. cated in the Agreement. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quan- tities and classifications of Unit Price Work performed by CONTRAcrOR will be made by ENGINEER in accor- dance with Paragraph 9.10. I I I I 11.9.2. Each unit price will be deemed to include an amount considered by CONTRAcrOR to be adequate to cover CONTRAcrOR' s overhead and profit for each sep. arately identified item. I I 11.9.3. Where the quantity of any item of Unit Price Work performed by CONTRAcrOR differs materially and significantly from the estimated quantity of such item indicated in the Agreement and there is no corresponding adjustment with respect to any other item of Work and if CONTRACTOR believes that CONTRACTOR has incurred additional expense as .a result thereof. CON- TRACTOR may make a claim for an increase in the Con- tract Price in accordance with AniCle J I if the panies are unable to agree-as to the amount of any such increase. I I I ARTICLE 12-CHANGE OF CONTRACT TIME I 12.1. The Contract Time may only be changed by a Change Order or a Written Amendment. Any claim for an extension or shortening of the Contract Time shall be based on written notice delivered by the party making the claim to the other party and to ENGINEER promptly (but in no event later than thirty days) after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be deliv- ered within sixty days after such occurrence (unless ENGI- NEER allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accom- panied by the claimant's written statement that the adjust- ment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Time I I I I shall be determined by ENGINEER in accordance with para- graph 9.11 if OWNER and CONTRAcrOR cannot otherwise agree. No claim for an adjustment in'the Contract Time will be valid if not submitted in accordance with the requirements of this paragraph 12.1. 12.2. The Contract Time will be extended in an amount equal to time lost due to delays beyond the control of CON. T-RAcrOR if a claim is made 'therefor as provided in para- graph 12.1. Such delays shall include. but not be limited to. acts or neglect by OWNER or others performing additional wort as contemplated by Article 7. or to fires. floOds. labor disputes. epidemics. abnormal weather conditions or acts of God. 12.3. All time limits stated in the Contract Documents are of the essence of the Agreement. The provisions of this Anicle 12 shall not exclude recovery for damages (including but not limited to fees and charges of engineers. architects. attorneys and other professionals and court and arbitration costs) for delay by either party. ARTICLE 13-W ARRANTY AND GUARANTEE; TESTS AND INSPEcrIONS: CORREcrION. REMOVAL OR ACCEPTANCE OF DEFEcrIVE WORK. WCImIIIlY and GlUJI1UIUe: 13.1. CONTRACTOR warrants and guarantees to OWNER and ENGINEER that all Work will be in accor- dance with the Contract Documents and will not be defective. Prompt notice of all defects shall be, given to CONTRAC- TOR. All defective Work. whether or not in place. may be rejected. corrected or accepted as provided in this Article 13. AcctS's to W 0'*: 13.2. ENGINEER and ENGINEER's representatives. other representatives of OWNER. testing agencies and gov- ernmental agencies with jurisdictional interests will have access to the Work at reasonable times for their observation. inspecting and testing. CONTRACTOR shall provide proper and safe conditions for such access. rests and Inspections: 13.3. CONTRACTOR shall give ENGINEER timely notice of readiness of the Work for all required inspections. tests or approvals. 13.4. If Laws or Regulations of any public body having jurisdiction require any Work lor part thereat) to specifically be inspected. tested or approved. CONTRACTOR shall assume full responsibility therefor. pay all costs in connection therewith and furnish ENGINEER the required certificates oi inspection. testing or approval. CONTRACTOR shall also 24 I I be responsible for and shall pay all costs in connection with any inspection or testing required in connection with OWN. ER's or ENGINEER~s acceptance of a Supplier of materials or equipment proposed to be incorporated in the Work. or of materials or equipment submit'ted for approval prior to CON- TRACTOR's purchase thereoffor incorporation in the Work. The cost of all inspections. tests and approvals in addition to the above which are required by the Contract Documents shall be paid by OWNER (unless otherwise specifiedl. I I I 13.5. All inspections. tests or approvals other than those required by Laws or Regulations of any public 'body having jurisdiction shall be performed by organizations acceptable to OWNER and CONTRACTOR (or by ENGI~EER if so specified). I I 13.6, If any Work (including the work of othersl that is to be inspected. tested or approved is covered without written concurrence of ENGINEER. it must. if requested by ENGI- NEER. be uncovered for observation. Such uncovering shall be at CONTRACTOR's expense unless CONTRACTOR has given ENGINEER timely notice of CONTRACTOR's inten- tion to cover the same and ENGINEER has not acted with reasonable promptness in response to such notice. I I 13.7. Neither observations by ENGINEER nor inspec- tions. tests or approvals by others shall relieve CONTRAC- TOR from CONTRACTOR's obligations to perform the Work in accordance with the Contract Documents. I I Uncovering Work: 13.8. Ifany Work is covered contrary to the written request of ENGINEER. it must. if requested by ENGI~EER. be uncovered for ENGINEER's observation and replaced at CONTRACTOR's expense. I I 1]',9, If ENGINEER considers it necessary or advisable that covered Work be observed by ENGINEER or inspected or tested by others. CONTRACTOR. at ENGINEER's request. shall uncover. expose or otherwise make available for observation. inspection ~r testing as ENGI~EER may require. that portion of the Work in question. furnishing all necessary labor. material and equipment. If it is found that such Work is d~ti!ctil'l'. CONTRACTOR shall bear all direct. indirect ami ~onsequential costs of such uncovering, expo- sure. observation. inspection and testing and of ~atisfactor\' reconstruction. (including but not limited to fees and charges of engineers. architects. attorneys and olher professionals I. and OWN ER shall be entitled to an appropriate Je~rease in the Conlract Price. and. if the parties are unable w agree as to the amount thereof. may make a ('Iaim thc:refor as provided in Article II, If. ho\\ e\ er. such Wurk is not f,'und to be dett'crjl'(', CO:\TRACTOR ~hall be allowell an increase in the C.lnlract Pn.,_ .:' ..i ,,"\;~n~ion of the Contract Time. .'r borh, Jin:t:ll~ attmlulabk Lv such uncovering, exposure, observation. inspection. testing and ret:onstructi,'n: and. if the parties are unable III agree as 10 the amount .'r extent I I I I I I thereof, CONTRACTOR may make a claim therefor as pro- vided in Articles II and 12. Ow"er May Stop the Work: 13.10, If the Work is defectil'e, or CONTRACTOR fails to supply sufficient skilled workers or suitable materials or equipment. or fails to furnish or perform the Work in such a way that the completed Work will conform to the Contract Documents. OWNER may order CONTRACTOR to stop lhe Work. or any portion thereof. until the cause for such order has been eliminated: however. this right of OWNER to stop the Work shall not give rise to any duty on the part of OWNER to exercise this right for the benefit of CONTRACTOR or any other party. Cornelio" or Removal of Defective Work: 13,11. If required by ENGINEER. CONTRACTOR shall promptly, as directed. either correct all defectil'e Work. whether or not fabricated. installed or completed. or. if the Work has been rejected by ENGINEER. remove it from the site and replace it with nondefectil'e Work. CONTRACTOR shall bear all direct. indirect and consequential costs of such correction or removal (including but not limited to fees and charges of engineers. architects. attorneys and other profe's- sionalsl made necessary thereby, ' One Year Correction Period: 13.12. If within one year after the date of Substantial Completion or such longer period of time as may be pre- scribed by Laws or Regulations or by the terms of any appli- cable special guarantee required by the Contract Documents or by any specific provision of the Contract Documents. anv Work is found to be defectil'e, CONTR..1"CTOR shall p~omPtIY. without cost to OWNER and in accordance with OWNER's written instructions. either correct such ddectil'e Work, or. if it has been rejecteg by OWNER. remove il from the site and replace' it with nonde/ectil'e Wo~k. If CONTRACTOR does not promptly comply with the terms of such instructions. or in an emergency where delay would cause serious risk of loss or damage. OWNER may have the defecti\'e Work cor- rected or the rejected Work removed and replaced. and all direct. indirect and consequential costs of such removal and replacement (including but not limited to fees and charges of engineers. architects. attorneys and other professionals) will be paid by CONTRACTOR. In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work. the correction period for that item may slart to run from an earlier date if so provided in the Specirications or by Written Amendmenl. A,ueptance of Defective Work: 13.13, If. inslead of requiring correction or removal and replacement of deii!crjn' Work. OWN ER land. prior to ENGINEER's recommendation of final payment. also ENGIN EERl prefers to accept it. OWNER may do so, CON- TRACTOR ~hall bear all direct. Indirect and consequential ~5 1 I costs attributable to OWNER's evaluation of and determi- nation to accept such defective Work (such costs to be approved I by ENGINEER as to reasonableness and to include but not be limited to fees and charges of engineers. architects. attor- neys and other professionaJs). if any such acceptance occurs prior to ENGINEER's recon:unendation of final ~yment. a I Change Order will be issued incorporating the necessary revi- sions in the Contract Documents with respect to the Work: and OWNER shall be entitled to an appropriate decrease in I the Contract Price. and. if the panies are unable to agree as to the amount thereof. OWNER may make a claim therefor as provided in Article 11. If the acceptance occurs after such recommendation. an appropriate amount will be paid by CONTRACTOR to OWNER. I I OWNER Ma, Comct Defee1iw Work: 13.14. If CONTRACTOR fails within a reasonable time after written notice of ENGINEER to proceed to correct and I to correct defective Work or to remove and replace rejected Work as required by ENGINEER in accordance with para- graph 13.11, or if CONTRACTOR fails to perform the Work in accordance with the Contract Documents. or if CON. I TRACTOR fails to comply with any other provision of the Contract Documents, OWNER may, after seven days' writ- ten notice to CONTRACTOR. correct and remedy any such I' deficiency. In exercising the rights and remedies under this paragraph OWNER shall proceed expeditiously. To the extent necessary to complete colTective and remedial action. OWNER may exclude CONTRACTOR from all or pan of the site, take I possession of all or pan of the Work, and suspend CON. TRACTOR's services related thereto, take possession of CONTRACTOR's tools. appliances, construction equipment and machinery at the site and incorporate in the Work all materials and equipment stored at the site or for which OWNER has paid CONTRACTOR but which are stored elsewhere. CONTRACTOR shall allow OWNER. OWNER's represen- I talives. agents and employees such access to the site as may be necessary to enable OWNER to exercise the rights and remedies under this paragraph. All direct, indirect and con. sequential costs of OWNER in exercising such rights and I remedies will be Charged apinst CONTRACTOR in an amount approved as to reasonableness by ENGINEER. and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work: and I OWNER shall be entitled to an appropriate decrease in the Contract Price" and. if the' panies are unable to agree as to the amount thereof. OWNER may make a claim therefor as provided in Article 11, Such direct. indirect and consequen. tial costs will include but not be limited to fees and charges of engineers. architects. attorneys and other professionals, all court and arbitration costs and all costs of repair and I replacement of work of others destroyed or damaged by correction. removal or replacement of CONTRACTOR's defective Work. CONTRACTOR shall not be allowed an I extension of the Contract Time because of any delay in per- formance of the Work attributable to the exercise by OWNER of OWNER's rights and remedies hereunder. I I I ARTICLE I4-PA YMENTS TO CONTRACTOR AND COMPLETION ScMdIlU of VaWu: 14.1. The schedule of values established as provided in paragraph 2.9 will serve as the basis for progress payments and will be incorporated into a form of Application for Pay. ment acceptable to ENGINEER. Progress payments on account of Unit Price Work will be based on the number of units completed. Appli.cJzlion for Prognss Ptzymeru: 14.2. At least twenty days before each progress payment is scheduled (but not more often than once a month). CON. TRACTOR shall submit to ENGINEER for review an Appli- cation for Payment filled out and signed by CONTRACTOR covering the Work completed as of the date ofthe Application and accompanied by such supponing documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored ill the site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale. invoice or other documentation wammting that OWNER has received . the materials and equipment free and clear of all liens. charges. security interests and encumbrances (which are hereinafter in these General Conditions referred to as "Liens") and evidence that the materials and equipment are covered by appropriate propcny insurance and other arrangements to protect OWNER's interest therein. all of which will be sat- isfactory to OWNER. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. CONTRACTOR's Wamurry of Tille: 14.3. CONTRACTOR warrants and guarantees that title to all Work, materials and equipment covered by any Appli- ' cation for Payment. whether incorporated in the Project .or , not. will pass to OWNER no later than the time of payment free and clear of all Liens. Retluw of AppliCluiotU for Prognss Paymeru: 14,4. ENGINEER will. within ten days after receipt of each Application for Payment. either indicate in writing a recommendation of payment and present the Application to OWNER. or return the Application to CONTRACTOR indi- cating in writing ENGINEER's reasons for refusing to rec- ommend payment. In the latter casc. CONTRACTOR may make the necessary corrections and resubmit thc Applica- tion. Ten days after presentation of the Application for Pay. mel'll with ENGINEER's recommendation. the amount rec- ommended will (subject to the provisions of the last sentenCe of paragraph 14.7) become due and when due will be paid by OWNER to CONTRACTOR. 14.5. ENGINEER's recommendation of any payment requested in an Application for Payment will constitute a 26 I I represenlalion by ENGINEER to OWNER. based on ENGI- NEER's on-site observations of the Work in progress as an . experienced and qualified design professional and on ENGI- N EER' s review of ihe Application for Payment and the accompanying data and schedules that the Work has pro- gr:essed 10 the point indicated: thaI. to the best of ENGI- NEER's knowledge. information and belief. the quality of the Work is in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion. to the results of any ,subsequent te'sts called for in the Contract Documents. to a final determination of quantities and classifications for Unit Price Work under paragraph 9,10. and to any other qualifi- cations stated in the recommendationl: and that CONTRAC- TOR is entitled to payment of the amount recommended, However. by recommending any such payment ENGINEER will not thereby be deemed to have represented that exhaus- tive or continuous on-site inspections have been made to check the quality or the quantity of the Work beyond the responsibilities specifically assigned to ENGINEER in the Contract Documents or that there may not be other matters or issues between the panies that might entitle CONTRAC- TOR to be paid additionally by OWNER or OWNER to withhold payment to CONTRACTOR. I I I ,I I 1 I 14,6. ENGINE~R's recommendation of final payment will constitute an additional representation by ENGINEER to OWNER that the conditions precedent to CONTRAC- TOR's being entitled to final payment as set fonh in paragraph 14.13 have been fulfilled. 1 I 14.7, ENGINEER may refuse to recommend the whole or any pan of any payment if. in ENGINEER's opinion. it would be incorrect to make such representations to OWNER. ENGIN EER may also' refuse to recommend any such pay- ment. or. because of subsequently discovered evidence or the results of subsequent inspections or tests. nullify any such paymenl previously recommended, to such extent as may be necessary in ENGINEER's opinion to protect OWNER from loss because: I I 14.7,1. the Work is defecti\'e, or completed Work has been damage? requiring correction or replacement. I 14,7.:. the Contract Price has been reduced by Writ- ten Amendment or Change Order. I 14,7.3. OWNER has been required to correct defl'c- ri\'e Work or complete Work in accordance with paragraph 13.14. or I 14, iA, ut' ENGINEER's actual knowkdge of [he occurrence of any of the events enumerated in paragraphs 15,:!,1 through 15.:!.9 inclusive. I OWNER may refuse to make payment of the full amount recommended bv ENGINEER because claims have been made againsl O\VNER un account ut'CONTRACTOR's per- formance or furnishing of the Work or Liens have been filed in connection with the Work ur [here are other items enlitling I I OWNER to a set-off against the amount recommended. but OWNER must give CONTRACfOR immediate written notice (with a copy to ENGINEER) stating the reasons for such action. Substantial Completion: 14.8. When CONTRACTOR considers the entire Work ready for its intended use CONTRACfOR shall notify OWNER and ENGINEER in writing that the entire Work is substantially complete (except for items specifically listed by CONTRACTOR as incomplete) and request that ENGI- NEER issue a cenificate of Substantial Completion. Within a reasonable time thereafter. OWNER. CONTRACTOR and ENGINEER shall make an inspection of the Work to deter- mine the status of completion. If ENGIN EER 'does not con- , sider the Work substantially complete. ENGINEER will notify CONTRACTOR in writing giving the reasons therefor. If ENGINEER considers the Work substantially complete, ENGINEER will prepare and deliver to OWNER a tentative cenificate of Substantial Completion which shall fix the date of Substantial Completion. There shall be allached to the cenificate a tentative list of items to be completed or cor- rected before final payment. OWNER shall have seven days after receipt of the tentative cenificate during which to make written objection to ENGINEER as to any provisions of the cenificate or attached list. If. after considering such objec- tions. ENGINEER concludes that the Work is not substan- tially complete. ENGINEER will within founeen days after submission of the tentative cenificate to OWNER notify CONTRACTOR in writing. stating the reasons therefor. If. after consideration of OWNER's objections. ENGINEER considers the Work substantially complete. ENGINEER will within said founeen days execute and deliver to OWNER and CONTRACTOR a definitive cenificate of Substantial Completion (with a revised tentative list of items to be com- pleted or corrected) reflecting such changes from the tentative cenificate as ENGINEER believes justified after consider- ation of any objections from OWNER. Atthe time of delivery of the tentative certificate of Substantial Completion ENGI- NEER.will deliver to OWNER and CONTRACTOR liwrillen recommendation as to division of responsibilities pending final payment between OWNER and CONTRACTOR with respect to security, operation. safety. maintenance. heat. utilities. insurance and warranties. Unless OWNER and CONTRACTOR agree otherwise in writing and so inform ENGIN EER prior to ENGINEER's issuing the definitive cenificate of Substantial Completion. ENGINEER's afore- said recommendation will be binding on OWNER and CON- TRACTOR until final payment. 1~.9. OWNER shall have the ngnl to exclude CON- TRACTOR from the Work after the date of Substantial,Com- pletion. but OWNER shall allow CONTRACTOR reasona~le access to complete ur correct items on the tentative lisl. Parti41 L'ti/i:.ation: 14.10. Use by OWNER ofany finished part of the Work. which has specifically ol:l:n identified in the Contract Do.:u- 27 I I ments. or which OWNER. ENGINEER and CONTRAC- TOR agree constitutes a separately functioning and use able I part of the Work that can be used by OWNER without sig. nmeant interference with CONTRACTOR's performance of the remainder of the Work. may be accomplished prior to Substantial Completion of all the Work subject to the follow- ling: I 14.10.1. OWNER at any time may request CON- TRACTOR in writing to permit OWNER to use any such part of the Work which OWNER believes to be ready for its intended use and substantially complete. If CON- TRACTORagrees. CONTRACTOR will certify to OWNER and ENGINEER that said part of the Work is substantially complete and request ENGINEER to issue a certificate of Substantial Completion for that pan of the Work. CON- TRACTOR at any time may notify OWNER and ENGI. NEER in writing that CONTRACTOR considers any such part of the Work ready for its intended use and substan- tially complete and request ENGINEER to issue a certif- icate of Substantial Completion for that part of the Work. Within a reasonable time after either such request. OWNER. CONTRACTOR and ENGINEER shall make an inspec. tion of that pan of the Work to determine its s,atus of completion. If ENGINEER does not consider that part of the Work to be substantially complete. ENGINEER will notify OWNER and CONTRACTOR in writing giving the reasons therefor. If ENGINEER considers that pan of the Work to be substantially complete. the provisions of para- graphs 14.8 and 14.9 will apply with respectto certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. I I I I I I 14.10.1. OWNER may at any time request CON- TRACTOR in writing to permit OWNER to take over operation of any such part of the Work although it is not substantially complete. A copy of ,such request will be sent to ENGINEER and within a reasonable time there- after OWNER. CONTRACTOR and ENGINEER shall make an inspection of that pan of the Work to determine its status of completion and will prepare a list of the items remaining to be completed or corrected thereon before final payment. If CONTRACTOR does not object in writ- ing to OWNER and ENGINEER that such pan of the Work is not ready for separate operation by OWNER. ENGINEER will finalize the list of items to be completed or corrected and will deliver such list to OWNER and CONTRACTOR together with a written recommendation as to the division of responsibilities pending final payment between OWNER and CONTRACTOR with respect to security, operation. safety, maintenance. utilities. insur- ance. warranties and guarantees for that pan of the Work which will become binding upon OWNER and CON- TRACTOR at the time when OWNER takes over such operation (unless they shall have otherwise' agreed in writ- ing and so informed ENGINEERl. During such operation and prior to Substantial Completion of such pan of the Work. OWNER shall allow CONTRACTOR reasonable access to complete or correct items on said list and to complete other related Work. I I I I I I I I 14.10.3. No occupancy or separate operation of pan of the Work will be accomplished prior to compliance with the requirements of paragraph 5. IS in respect of property insurance. FiMllnspcction: 14.11. Upon written notice from CONTRACTOR-that the entire Work or an agreed portion thereof is complete. ENGI. NEER will make a final inspection with OWNER and CON. TRACTOR and will notify CONTRACTOR in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. CONTRACTOR shall immediately take such measures as are necessary to remedy such defi- ciencies. F iMl AppliuJion for Payme1ll: 14.12. After CONTRACTOR has completed all such cor- rections to the satisfaction of ENGINEER and delivered all maintenance and operating instrUctions. schedules. guanm- tees. Bonds. certificates of inspection. marked-up record documents (as provided in paragraph 6.19) and other docu- ments-aJ1 as required by the Contract Documents. and after ENGINEER has indicated that the Work is acceptable (sub- ject to the provisions of paragraph 14.16). CONTRACTOR may make application for final payment following the pro- cedure for progress payments. The final Application for Pay. ment shall be accompanied by all documentation called for in the Contract Documents. together with complete and legally effective releases or waivers (satisfactory to OWNER) of all Liens arising out of or filed in connection with the Work. In lieu thereof and as approved by OWNER. CONTRACTOR may furnish receipts or releases in full: an affidavit of CON- TRACTOR that the releases and receipts include all labor. services. material and equipment for which a Lien could be filed. and that all payrollS. material and equipment bills. and other indebtedness connected With the' Work for which OWNERorOWNER's propeny might in any way be respon- sible. have been paid or otherwise satisfied: and consent of the surety. if any. to final payment. If any Subcontractor or Supplier fails to furnish a release or receipt in full. CON; TRACTOR may furnish a Bond or other collateral satisfac- tory to OWNER to indemnify OWNER against any Lien. Firud Payment and AccepUJllce: 14.13. If. on the basis of ENGINEER's observation of the Work during constrUction and final inspection. and ENGINEER's review of the final Application for Payment and accompanying documentation-all as required by the Contract Documents. ENGINEER is satisfied that the Work has been completed and CONTRACTOR's other obligations under the Contract Documents have been fulfilled. ENGI- NEER will. within ten days after receipt of the final Appli- cation for Payment. indicate in writing ENGINEER's rec- ommendation of payment and present the Application to OWNER for payment. Thereupon ENGINEER will give written notice to OWNER and CONTRACTOR that the Work is acceptable subject to the provisions of paragraph 14.16. 28 I I Otherwise. ENGINEER will return the Application to CON- TRACTOR. indicating in writing the reasons for refusing to recommend final payment., in which case CONTRACTOR shall make the necessary corrections and resubmit the Appli- cation. Thiity days after presentation to OWNER of the Application and accompanying documentation. in appropri- ate form and substance. and with ENGlNEER's recommen- dation and notice of acceptability. the amount recommended by ENGIN EER will become due and will be paid by OWNER to CONTRACTOR. I' I I 14.14. If. through no fault of CONTRACTOR. final com- pletion of the Work is significantly delayed and if ENGI- NEER so confirms. OWNER shall. upon receipt of CON- TRACTOR's final Application for Payment and recommen- dation of ENGINEER. and without terminating the Agree- ment. make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by OWNER for Work not fully completed or corrected is less than the retainage stipulated in the Agree- ment. and if Bonds have been furnished as required in para- graph 5.1. the written consent of the surety to the payment of the balance due for that portion of the Work fully com- pleted and accepted shall be submitted by CONTRACTOR to ENGINEER with the Application for such payment. Such payment shall be made under the terms and conditions gov- erning final payment. except that it shall not constitute a waiver of claims, I I I I I Contractor's Continuing Obligation: 14.15. CONTRACTOR's obligation to perform and com- plete the Work in accordance with the Contract Documents shall be absolute. Neither recommendation of any progress or final payment by ENGINEER. nor the issuance of a cer- tificilte of Substantial Completion. nor any payment by OWNER to CONTRACTOR under the Contract Documents. nor any use or occupancy of the Work or any part thereof by' OWNER. nor any act of acceptance b~' OWNER nor any failure 10 do so. nor any review and approval of a Shop Drawing or sample submission. nor the issuance of a notice of acceptability by ENGINEER pursuant to paragraph 14.13. nor any correction of defective Work by OWNER will con- stitute an acceptance of Work not in accordance with the Contract Documents or a release of CONTRACTOR's obli- gation !O pe::rform the:: Work in accordance with the Contract Documents lexcept as provided in paragraph 14,161, I I I I I Wah,t'r of Claims: I~, \6, The making and acceptance or' tinal pa\'ment will .:onS(J[Ule: I I l~, 16,', a waiver of all claims by OWNER against CO:--lTR.-\CTOR. except claims arising from unse:llled Liens. from det<'Clil'e Work appearing after tinal inspe::c- [illn pursuant to paragraph I~, II or from failure: tll .:ompl\ \\ ith the Cllnlract Dllcume::nls or the: tams of any spe.:ial guaranlce::s spccifie::d therein: howeve:r. it will Oll( consti- IlIte a \\'aiver t1\' OWNER of an\ nghts in r~sp.:ct llr' I I CONTRACTOR's continuing obligations under the Con- tract Documents: and 14.16.2. a waiver of all claims by CONTRACTOR against OWNER other than those previously made in writ- ing and still unsettled. ARTICLE 15-SUSPENSION OF WORK AND TERMINATION Owner May Suspend Work: 15.1. OWNER may. at any time and without cause. sus- pend the Work or any portion ,thereof for a period of not more than ninety days by notice in writing to CONTRACTOR and ENGINEER which will fix the date on which Work will be resumed. CONTRACTOR shall resume the Work on the date so fixed. CONTRACTOR shall be allowed an increase in the Contract Price or an extension of the Contract Time. or both. directly attributable to any suspension if CONTRACTOR makes an approved claim therefor as provided in Articles II and 12. Owner May TerminDle: 15.2. Upon the occurrence of anyone or more of the following events: 15.2.1. if CONTRACTOR commences a voluntary case under any chapter of the Bankruptcy Code (Title II. United States Code). as now or hereafter in effect. or if CON- TRACTOR takes any equivalent or similar action by filing a petition or otherwise under any other federal or state law in effect at such time relating to the bankruptcy o~ insolvency: 15,2,2. if a petition is filed against CONTRACTOR under any chapter of the Bankruptcy Code as now or hereafter in effect at the time of filing. ur if a petition is filed seeking any such equivalent or similar relief against CONTRACTOR under any other federal or state law in effect at the time relating to bankruptcy or insolvency.: 15,2.3, if CONTRACTOR makes a general assignment for the benefit of creditors: 15,2.4, if a trustee. receiver. custodian or agent of CONTRACTOR is appointed under applicable law or under contract. whose appointment or authority to take charge of property of CONTRACTOR is for the purpose of enforcing a Lien against such property or ior the purpose of general administration of such property for the benefit of CONTRACTOR's creditors: 15,2.5, if CONTRACTOR admits in writing an inabil- ity to pay its debts gene::rally as (hey becl1me due: 15.2.6. if CONTRACTOR persistently fails to perform the Work in a\:l:ordam:e with [he Contract Documents 29 I I (including. but not limited to. failure to supply sufficient skilled workers or suitable materials or equipment or failure to adhere to the progress schedule established under paragraph 2.9 as revised from time to time): I I 15.2.7. if CONTRACTOR disregards Laws or Regu. lations ofany public body having jurisdiction: I 15.2.8. if CONTRACTOR disregards the authority of ENGINEER: or 15.2.9. if CONTRACTOR otherwise violates in any substantial way any provisions of the Contract Docu. I ments: OWNER may. after giving CONTRACTOR (and the surety. if there be one) seven days' written notice and to the extent I permitted by Laws and Regulations. terminate the services of CONTRACTOR. exclude CONTRACTOR from the site and take possession of the Work and of all CONTRACTOR's I tools. appliances. construction equipment and machinery at the site and use the same to the full extent they could be used by CONTRACTOR (without liability to CONTRACTOR for trespass or conversion). incorporate in the Worle all materials I and ,equipment stored at the site or for which OWNER has paid CONTRACTOR but which are stored elsewhere. and finish the Work as OWNER may deem expedient. In such case CONTRACTOR shall not be entitled to receive any I further payment until the Work is finished. If the unpaid balance of the Contract Price exceeds the direct. indirect and consequential costs of completing the Work (including but I not limited to fees and charges of engineers. architects. attor. neys and other professionals and court and arbitration costs) such excess will be paid to CONTRACTOR. If such costs exceed such unpaid balance. CONTRACTOR shall pay the I difference to OWNER. Such costs incurred by OWNER will be approved as to reasonableness by ENGINEER and incor- porated in a Change Order. but when exercising any rights or remedies under this paragraph OWNER shall not be required Ito obtain the lowest price for the Work performed, I I I 15.3. Where CONTRACTOR's services have been so terminated by OWNER. the termination will not affect any rights or remedies of OWNER against CONTRACTOR then existing or which may thereafter accrue. Any retention or payment of ,moneys due CONTRACTOR by OWNER will not release CONTRACTOR from liability. 15.4. Upon seven days' written notice to CONTRAC- TOR and ENGINEER. OWNER may. without cause and without prejudice to any other right or remedy. elect to aban- don the Work and terminate the Agreement. In such case. ' CONTRACTOR shall be paid for all Work executed and any expense sustained plus reasonable termination expenses. which will include. but not be limited to. direct. indirect and con. sequential costs (including. but not limited to. fees and charges of engineers. architects. attorneys and other professionals and court and arbitration costs). Conll'rll:tDr May Stop Work or TermintlU: 15.5. If. through no act or fault of CONTRACTOR. the Work is 'Suspended for a period of more than ninety days by OWNER or under an order of court or other public authority. or ENGINEER fails to act on any Application for Payment within thirty days after it is submitted. or OWNER fails for thirty days to pay CONTRACTOR any sum finally deter- mined to be due. then CONTRACTOR may. upon seven days' written notice to OWNER and ENGINEER. terminate the Agreement and recover from OWNER payment for all Work executed and any expense sustained plus reasonable termination expenses. In addition and in lieu of terminating the Agreement. if ENGINEER has failed to act on an Appli- , cation for Payment or OWNER has failed to make any pay- ment as aforesaid. CONTRACTOR may upon seven days' written notic~ to OWNER and ENGINEER stop the Work until payment of all amounts then due. The provisions of this paragraph shall not relieve CONTRACTOR of the obligations under: paragraph 6.29 to carry on the' Work in accordance with the progress schedule and without delay during disputes and disagreements with OWNER. ,[The remainder of this page was left blank intentionally,] I I I 30 I I I I I I I I I I I I I I I I I I I ARTICLE 16--ARBITRATION 16.1 All claims, disputes and other matters in question between OWNER and CONTRACTOR arising out of, or relating to, the Contract Docu- ments or the breach, thereof shall be decided under Georgia Law in the Superior Court of Richmond County, Georgia. (The remainder of this page was left blank intentionally.) 31 I I I I ,I I I I I I I I I I I I I I I (This page was left blank lntentlona.lly.) 32 I I ARTICLE l7-MISCELLANEOUS I . Givi1lg NotU:e: 17.1. Whenever any provIsIon of the Contract Docu- ments requires the giving of written notice. it will be deemed tQ have been validly given if delivered in person to the indi- vidual or to a member of ' the firm or to an officer of the corporation for whom it is intended. or if delivered at or sent by registered or cenified mail. postage prepaid. to the last business address known to the giver of the notice. Compllllllion ofTim8: 17.2.1. When any period of time is referred to in the Contract Documents by days. it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction. such day will be omitted from the computa- tion. I I I I I 17.2.2. A calendar day of twenty-four hours measured from midnight to the next midnight shall constitute a day. I General: 17.3. Should OWNER or CONTRACTOR suffer injury or damage to person or property because of any error. omis- I I I I I I I I I I sion or act of the other party or of any of the other party's employees or agents or others for whose acts the other party is legally liable. claim will be made in writing to the other party within a reasonable time of the first observance of such injury or damage. The provisions of this paragraph 17.3 shall ,nol, be constrUed, as a substitute for or a waiver of the pro. visions of any applicable statute of limitations or repose. 17.4. The duties and obligations imposed by these Gen- eral Conditions and the rights and remedies available here- under to the parties hereto. and. in particular but without limitation. the warranties. guarantees and obligations imposed upon CONTRACTOR by paragraphs 6.30. 13. I. 13.12. 13.14. 14.3 and 15.2 and all of the rights and remedies available to OWNER and ENGINEER thereunder. are in addition to. and are not to be construed in any way as a limitation of. any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations. by special warranty or guarantee or by other provisions of the Contract Documents. and the provisions of this paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty. obliga- tion. right and remedy to which they apply. All representa. tions. warranties and guarantees made in the Contract Doc- uments will survive final payment and termination or com- pletion of the Agreement. 33 I I I I I I I I I I I I I I I I I I I SUPPLEMENTARY CONDITIONS 1.1 OWNER'S LIABILITY & PROPERTY INSURANCE: section 5.5, 5.6, 5.7, 5.8, 5.9, 5.10 of the General Conditions shall be amended as follows: No additional liability or property insurance will be purchased by Augusta-Richmond County for this project. CUrrent insurance coverages will remain in effect for the life of this Contract. 1.2 CONTRACTOR'S LIABILITY: As indicated under Section 5.3 of the General Conditions, the Contractor's Liability Insurance shall be in an amount not less than $200,000 for injuries, including accidental death, to anyone person, and subject to the same limit for each person, in an amount not less than $500,000 on account of one accident, and Contractor's Property Damage Insurance in an amount not less than $100,000 for all property damage sustained by anyone person in anyone accident; and a limit of liability of not less than $200,000 for any such damage sustained by two or more persons in anyone accident. The Contractor shall either (1) require, each of his subcontractors to procure and to maintain during the life of his subcontract, Subcontractor's Liability and Property Damage Insurance of the type and in the same amounts as specified in the preceding paragraph, or (2) insure the activities of his subcontractors in his own policy. 1.3 SPECIAL HAZARDS: The Contractor's and his Subcontractor's Liability and property Damage Insurance shall provide adequate protection against the following special hazards: . (a) Work within the right-of-ways of the Augusta-Richmond County Road System. (b) Work within easements granted by property owners in connection with the construction of the project. (c) Work in close proximity to existing water lines, power lines, telephone lines, gas lines, other utilities and private structures contiguous to the job site. SC-1 'I I I' I I I I I I I I I I I I I I I I 1.4 TESTING LABORATORY: All testing and laboratory work in connection therewith shall be performed by an independent firm and paid for by the Contractor. Copies of all test reports shall be forwarded to Augusta-Richmond County Public Works. There will be no separate payment for this work. 1.5 SURVEYS: The Contractor will provide surveying for construction staking, horizontal control and vertical control as necessary. 1.6 PROGRESS PAYMENT: section 14.2 of the General Conditions shall be amended as follows: The contractor may submit monthly estimate for work completed and materials properly stored as approved by the Engineer. When 'an estimate includes materials stored, a bill of sale, invoice or other documentation warranting that the Owner is receiving the material free and clear of all liens, charges, security interest and other encumbrances shall be attached to the payment request. 1. 7 ENGINEER: All references to "Engineer" shall be interpreted to mean the Augusta-Richmond County Engineer, or his official designee. 1. 8 UNDERGROUND UTILITIES: (References 4.3, 1.4', 3.2) The Contractor shall coordinate with all utility companies through the "one call" method or other appropriate steps to locate and avoid damage to all utilities that-may affect or be affected by the Contractor's work. 1.9 SAFETY: (Reference 6.20) The Contractor shall use certified flacjmen, barricades and signs as necessary to notify the public, in particular those persons driving in the vicinity of the project, of the construction and its affect on traffic. SC-2 i I'I'~~- ...." II J' I. II II' II I. ,. -. - .. :I. "l. - 1. r_ - ,~. !". -- =- -:-. . . . :1 SECTIONP PROPOSAL Date: J L4 I II I z. )~q 7 Gentlemen: In compliance with your invitation for bids dated , 19___, the undersigned hereby proposes to furnish all labor, equipment, and materials, and to perform all work for the installation of streets, and appurtenances referred to herein as: Pepperidge Drive Intersection Improvements Project Number: 51-8691-094 in strict accordance with the Contract Documents and in consideration of the amounts shown on the Bid Schedule attached hereto and totaling: ,t:)/Y'~ IlurlJrfOrI hrfr Sf'Yf'tI /~o(,/sa",d CJr/~ IhlYdred SeyeHIv I 75/ " ,7X/ee l" //tJt'.7 OOI:iLARS($ /1-1) /73, 7-' ) The undersigned hereby agrees that, upon written acceptance of this bid, he will within 10 days of receipt of such notice execute a formal contract agreement with the OWNER, and that he will provide the bond or guarantees required by the Contract Documents. The undersigned hereby agrees that, if awarded the contract, he will. commence the work within 10 ' calendar days after the date of written notice to proceed" and .that he will complete the work within 100 calendar days. The undersigned acknowledges receipt of the following addenda: #1 RespectfullY Submitted ,AlAe - Geor9'Q ) INC. (Name of Firm) p. o.,!k~ I. z 9 (Business By: Title: (' - Y!/1/' , P-1 I I I I I I I I I I I I I I I I I I I To remain progressive in this computer oriented age Augusta- Richmond County is making the blank spreadsheet of bid items and quantities available via diskette. It is necessary to have a Lotus based spreadsheet program with the WYSIWYG application to access this tool. In order to obtain a copy, proof of purchase of the bid package must be provided and either a 3.5 inch or 5.25 inch diskette supplied. The spreadsheet will then be copied onto YOUR diskette at no. additional charge by Cheryl Nelson in the Finance Department, Room 211 of the Municipal Building. A hard copy of all bid document pages must be turned in for bid as before along with proper bonding. The diskette is NOT a substitute for the bid quote and is ~ to be turned in for the bid quote. P-2 ITEM'.;. . .'. .", . . . ..:..;.....;:~~...,'::-.;: ; ; .. ":;":':'::;:.::.::'.,.;'/.~ >:;'<)JJNIT';: .. :.. '::<:........:.;"..:. . , ':'{ , :., ';.... ~" " ~:,.). ... .... '. .....:.... ."- . . ,. ......~ .. .:..... ,-....: . 'i . " . DEScRIPTION' .'" ... '~.'.' '.~-. ';;.~.',:. :O~ .... ..:.: ;.'.PRICE" .' ,AMOUNT NUMBER. . . .--..........-........ : ".':'.' UNIT '.... TY'. .... ;. ," :'..::'-.-.' :::'-:-~'<',:: 150-1000 TRAFFIC CONlROL LS 1 /3300,00 I 3 300 . OC) 163-2051 CONSTR, MAINT AND REMOVE BALED STRA W EROISION CHECK LF 50 G. ZO ~/O,OO 171-0010 TEMPORARY SILT FENCE. TYPE A LF 100 -')-, ?S ,"'fb 6. 00 230-1000 LUMP SUM CONSTRUCTION * LS 1 .:J:'i 750.00 3575"0,00 310-5060 GR AGGR BASE CRS. 6 INCH. INCL MATL SY 475 3'f , 00 /6/50.00 318-3000 AGGR SURF CRS TN 50 / C . ?is 8'1 z. . So 402-0011 RECYCLED ASPH CONC B, GP 1 OR 2, INCL BITUM MATL TN 175 I. X . 00 //900,00 402-0013 IRECYCLED ASPH CONC E, GP 1 OR 2, INCL . BITUMMATL TN 135 ~ 3. 't() 'g559,oo 413 -1 000 BITUM TACK COAT GL 145 j,QO If 8 . 50 441-4010 CONC V ALLEY GUTIER 4 IN SY 100 ?7,tS Z 7b5, 00 441-6022 CONC CURB & GUTIER 6 IN X 30 IN. TP 2 LF 1 100 /2.30 / -35-30 00 550-1180 STORM DRAIN PIPE 18IN HI-I0 LF 12 /0 7 . 00 } z 84 . 00 610-0011 REM CONC DRlVEW A Y PAVING LS 1 ,755.6n 7S.5,()O u' , 1'\ /"1"'/"1/"1 REM CH LK FENCE. ALL SIZES & TYPES LF 140 Z,ZO 3 () 8 . on ._....., 'JI___ 1610-0220 REM WOOD FENCE LF 25 2,2D 55 , ()O 1610-2586 REM ASPH PVMT INCL BASE SY 805 (,80 Z c5"4 .00 ~ REM CONC GUTIER W/CURB ("g() /I 7 Z (, ,00 610-2785 LF 695 610-6675 REM PORTION OF CATCH BASIN EA 1 ~-lO .00 5z 0 . 00 . i61 0-9001 REM SIGN EA 1 4/,S, 00 4- b 6-, () 0 !611-3100 RECONSTR JUNCTION BOX EA 1 /.1aO,oO /300,00 . 1611-5029 RESET CHAIN LINK FENCE, ALL SIZES & TYPES LF 95 8,'lS 783 ,7S 1611-5551 RESET SIGN EA 1 .~ l8j,oo 3 c.. ~ 5, 00 1':11-8050 ADJUST MANHOLE TO GRADE EA 2 too.oO I Z'OO .O() II II 'I 'I II II II II II II II II !!II -. - -- - - - -- . PEPPERIDGE DRIVE INTERSECTION IMPROVEMENTS PROJECT NUMBER: 51-8691-094 DETAILED ESTIMATE ] 0/] 6/96 P-3 I I I I I I I I I I I il I I I I I I I PEPPERIDGE DRIVE INTERSECTION IMPROVEMENTS PROJECT NUMBER: 51-8691-094 DETAILED ESTIMATE l'fEM ..,'"", .. .. ..~,."":"..."':.;i;.,>"..,:<:')i<!'(:::.,.:c:..>. :,' ........;'::.:..;,.,:.;,,;.~.....,.:,,:'. " ..:.;.......),:,..:.....: "'" ""'. .:,). ',,' ...... . UNIT .. NUMBER . . .... ,::';":-:'U;:::)I):ESC1liBTio.r~f:i':':Y.}/i2HV:.,:i\:h:'i::.: iUNIT;,;'offl ;:::,,::U:::PRICE .'.... . . 639-5000 !PRESTRESSED CONC STRAIN POLE TP IV ** EA 2 7 "i/O, 00 653-0120 THERMOPLASTIC PVMT MARKING, ARROW, TP2 653-0210 THERMOPLASTICPVMTMARKING, WORD, TP 1 653-1501 THERMOPLASTIC SOLID TRAF STRIPE,S IN, WHITE 653-1502 THERMOPLASTIC SOLID TRAF STRIPE,S IN, YELLOW 653-1704 THERMOPLASTIC SOLID TRAF STRIPE, 24 IN, WHITE THERMOPLASTIC TRAF STRIPING WHITE THERMOPLASTIC TRAF STRIPING. YELLOW CA TCH BASIN. GP 1 668-2100 IDROP INLET GP 1 670-9710 RELOCATE EXIST FIRE HYDRANT 700-0200 GRASSING 10/16/96 653-6004 653-6006 668-1100 TOTAL CONTI;lACT: EA EA LF 750 LF 110 LF SY SY EA 12 250 20 EA EA LSAC /~7 /73, 7S 2 I:J.~ 00 2 /'10, 00 I, 75 1,76 1 /1, 00 'l,XD ~,go /~OO. 00 /~'75, 00 Z3Z0.00 1 I (JO 00 1 1 1 * LUMP SUM CONSTRUCTION includes, but is not limited to, Concrete R/W markers; Construction Layout; all removals, resetting and. disposals; or any other . work or materials without a specific pay item. * * All costs incurred by the contractor regarding modifications of the existing traffic signal shall be included in the price bid for Item Number 639-5000 Prestressed Concrete Strain Pole, T e IV, P-4 4NC -72Z: CONTRA~O . //1. ~ D, v. ?res. -LNe. ) :':':;',".: "'c.:.:."'.:',.,.- AMOUNT IS020,00 Z 70 00 38().00 /3/2,So 19 Z , So 132,()0 2.2.00,06 / 7 (, 00 / too, OQ /b7S,00 2 3 ~o 00 1100.00 I I I I I I I I I I I I I I I I I I I PEPPERXDGE DRXVE XNTERSECTXON XMPROVEMENTS ADJUSTING MINOR STRUCTURES TO GRADE: This item consists of raising or lowering the upper portion of existing manholes, water valve boxes, gas valve boxes or any other miscellaneous structures within the area of construction. There will be no separate payment for this work unless shown as a separate pay item. AGGREGATE SURFACE COURSE: The item aggregate surface course is for' use in inclement weather to facilitate the movement of local traffic along roadway construction and to permit ingress and egress at drives. When used for this purpose, section 318, Georgia Standard Specifications, is modified to permit truck dumping on unprepared and muddy subgrade. section 318 is further modified to permit the use of crusher run stone as described in Subsection 806.02. The Contractor will have the choice of the following materials. Graded Aggregate Coarse Aggregate Size 467 Stabilizer Aggregate Type 1 or 2 Crushed Stone Subsection 815.01 Subsection 800.01 Section 803 Subsection 806.02 All materials to be used as directed by the Engineer. AS-BUILT PLANS: The Contractor shall furnish a legible set of "as-built" plans, in good condition, to the Project Inspector no later than the date of the Final Inspection. Such plans shall have all significant changes marked in red.. The Project Inspector shall review the marked plans for accuracy, legibility and completeness. As-built plans, approved by the Project Inspector, must have the Inspector's signature on the cover sheet. No "as-built" plans will be accepted without the approval of the Project Inspector. COMPACTION: All compaction shall be as defined in the current edition of Georgia Department of Transportation Specifications.' Special attention shall be given to the backfill, or minor structures (pipe, box culverts, manholes, catch basins, drop inlets, etc.). Compaction shall be achieved using approved tamps and soil layers of approximately 6 inches (loose measure) and in accordance with Georgia Department of Transportation Standards 1030-0 and 1401. Backfilling operations of this nature shall G-1 I 1 I' I I 1 1 1 I I I I I I I I I I 1 not begin until the Contractor has on hand all equipment in good working condition, and competent operators. The backfilling of pipe and other minor structures shall be in accordance with Georgia Department of Transportation Standard Specifications, CUrrent Edition. Backfilling with sand using jetting and/or flooding will not be allowed in any case without the written permission of the Engineer. CONCRETE: The Contractor shall have a slump cone on, the project at all times when concrete is being placed. He shall, in the Engineer's presence, perform slump tests as directed by the Engineer. Tests shall be performed by qualified personnel with a properly cleaned slump cone. Allowable slumps are 2" minimum and 4" maximum. Class "A" concrete shall have a minimum of 611 lbs. cement per cubic yard. Class "B" concrete shall have a minimum of 470 lbs. cement per cubic yard. Concrete not meeting these requirements will be rejected by the Engineer. CONSTRUCTION: Transition ties of proposed curb and gutter to existing curbs (valley gutter, granite curb, header curb, etc.) shall be paid for in the unit price bid for curb and gutter. At locations where new pavement is to be placed adjacent to existing pavement without an overlay or where curbing is to be placed across paved parking lots, a joint shall be sawed on a line to ensure pavement removal to be neat. Only those joints sawed in concrete pavement will be paid for under the pay item-Sawed Joints...Per Linear Foot. Where curb and gutter is used and the shoulder elevations are higher than adjacent ground, the actual direction of drainage runoff shall be determined by the Contractor.' He shall make such provisions as necessary to ensure that no ponding is caused by the new construction. He may place additional fill to provide drain inlets.' compensation will be under the price bid for the appropriate pay item. Driveway profiles may also be altered allowing the concrete pa~ to slope down outside the back of the curb line not to exce~d an algebraic difference of 0.07. This should be used primarily on the high side of superelevated curves. The Contractor should use caution with standard variance and place special emphasis on hydraulic considerations. Where curb and gutter is to be built on the high side of superelevated curves the gutter slope shall match the roadway slope or superelevation rate. The Contractor shall provide borrow and/or waste pits for this project. All pits acquired for use on this project shall be reclaimed in accordance with Subsection 107.23 and Section 160 of the Standard Specifications. G-2 I I I I I I I I I I I I I I I I I I I All storm drain pipe, side drain pipe, pipe culvert wingwalls, steps, retaining walls, curbs and gutters, headwalls, all types of pavement, wooden structures, except those specifically shown as a removal pay item will be removed as Clearing and Grubbing, Grading Complete, Grading Per Mile or Lump Sum Construction. cut and fill slopes outside of clear zones may be adjusted on construction where necessary to remain within the right of way. Curb cuts ramps in accordance with Standard 9031-W are to be used at all street intersections on this project. CONSTRUCTION LAYOUT: Construction layout work shall be performed by the Contractor. See section 149 of the Standard Specifications. The survey for this project was made by W. R. Toole Enqineers (706)722 -4114). DESIGN ALTERATIONS: The Commission-Council recognizes that various changes in design may be made as the project progresses. Any requests for additional payment will be processed based on actual work in place and the unit prices submitted as a part of this bid. Items not covered in this bid shall be priced separately and no work shall be, done on these items until approved, in writing, by the Engineer. DRIVEWAYS: The item aggregate surface course is for use as surface for unpaved drives and for use in inclement weather to facilitate the movement of local traffic along roadway construction and to permit ingress and egress at drives~ When used for this purpose, section 318, Georgia Standard Specifications is modified to permit truck dumping on unprepared and muddy subgrade. 'section 318 is further modified to permit the use 'of crusher run stone as described in Subsection 806.02. The Contractor will have the choice of the following materials: Graded Aggregate Coarse Aggregate Size 467 Stabilizer Aggregate Type 1 or 2 Crushed Stone Subsection 815.01 Subsection 800.01 section 803 Subsection 806.02 All materials to be used as directed by the Engineer. All driveways that are to be reconstructed shall be replaced in kind i.e., asphalt for asphalt, concrete for concrete, and aggregate surface courses for earth. The driveway locations indicated on the plans are from the best available data. The Contractor shall obtain the approval of the Engineer prior to making any revisions such as to location, width, and/or number of drives to be constructed where required. G-3 I I I I I I I I I I I I I I I I I I I Ingress and egress shall be maintained at all times to adjacent properties, unless otherwise noted in the plans. All valley gutter drives shall conform to Standard 6050 or 9031-J. EROSION AND SEDIMENT CONTROL: The Contractor shall be responsible for all soil erosion and sediment control practices. All on-site erosion control shall comply with local Augusta-Richmond County erosion and sediment control ordinances. The cost of this work shall be included in the cost of the project unless shown as a separate pay item. EXCESS MATERIAL: All excess material is to be disposed of as directed by the Engineer or as noted in Subsection 107.23 of the Specifications. FENCE: All new fence called for on the plans and/or contract documents shall meet the requirements of section 643 of the Georgia Department of Transportation Standard Specifications, current edition. New fence not meeting these Specs will be rejected. In contracts where remove and reset fence items are involved (either as pay items or as Lump Sum Construction) all replacement fence shall be equal to or better than the existing fence as approved by the Engineer. This means equal to or better than the original fence at the time of it's installation. In accordance with Subsection 643. 03D the Contractor must furnish positive locking devices, padlocks and keys with a~l gate assemblies. FINISHING AND DRESSING: All unpaved and natural areas which are disturbed by the construction of this project are to be returned to the pre- existing shape and slope and then finished and dressed. No separate payment will be made for grassing, fertilizing and mulching of disturbed areas, unless specifically shown as a pay item. FLAGGING: Flaggers shall be provided as required to handle traffic, as specified in the Plans or Special provisions, and as required by the Engineer. . All flaggers shall meet the requirement of part 6F of the MUTCD and must have received training and a certificate upon completion of the training from a Department approved training G-4 I I I I I I I I I I I I I I I I I I I program. Failure to provide certified flaggers as required above shall be reason for the Engineer suspending work involving the flagger(s) until the Contractor provides the certified flagger(s). Flaggers shall wear a fluorescent orange cap or hat, and a fluorescent orange vest, shirt, or jacket, and shall use a stop/Slow paddle meeting the requirements of section 6F-2 of the MUTCD for controlling traffic. The Stop/Slow paddle shall have a shaft length of six (6) feet minimum. In addition to the flag as an additional device to attract attention. For night work, the vest shall have reflectorized stripes on front and back. Signs for flagger traffic control shall be placed in advance of the flagging operation in accordance with the MUTCD. In addition to the signs required by the MUTCD, signs at regular intervals, warning of the presence of the flagger shall be placed beyond the point where traffic can reasonably be expected to stop under the most severe conditions for that day's work. ' FOUNDATION BACKFILL MATERIAL, TYPE I: Foundation Backfill Material Type I shall ,conform to Georgia Standard 1030-0 and section 207 of the Standard Specifications. No separate payment will be made for this material or its placement. FOUNDATION BACKFILL MATERIAL, TYPE II: Foundation Backfill Material, Type II shall conform to Georgia Standard 1030-0 and section 207 of the Standard Specifications and shall be used in wet/unstable conditions as directed by the Engineer. It shall also be used beneath all concrete box culverts. Quantities shall be measured for payment in accordance with Georgia Standard 1030-C or as directed by the Engineer. Payment shall be per cubic yard unless otherwise specified in the contract. . GRADES: . with the approval of the Engineer, grades may be field adjusted to provide for best drainage. GRADING: In contracts where grading, including excavation for drainage structures, is accomplished under Section 210 (Grading Complete or Grading Per Mile) or Section 230 (Lump Sum construction) the Lump Sum amount bid will include all work necessary to obtain the line, grade and compaction in accordance with the Specifications and other contract documents. There will be no separate payment for any work of this nature including borrow and the removal of unsuitable and/or unstable material. However, the Contractor shall make whatever investigations he deems necessary to determine the extent of any borrow or removal necessary to meet contract G-S I I I I I I I I I I I I I I I I I I I requirements. ,If it develops that removal of unsuitable/unstable materials quantities could not have been predicted . by the Contractor from a reasonably thorough investigation of project conditions, the Contractor may request negotiation for payment for excavation of this nature in areas where the depth exceeds' three (3) feet below subgrade. The Owner will consider negotiation only when this type of removal is excessi ve and the Contractor provides evidence that he thoroughly investigated project conditions prior to entering his bid. Only those quantities in excess of three (3) feet below finished subgrade and/or normal excavation for drainage structures, ordered by the Engineer, 'will be considered for payment. GRASSING AND EROSION CONTROL: The Contractor shall bid on grassing, lump sum, and it shall be his responsibili ty to determine the actual area to be grassed. No claims will be considered for extra compensation if the Contractor relies on plan information to prepare his bid. All slope areas are to be grassed unless shown otherwise on plans. Temporary grass is required if permanent grass season is out. The Contractor shall be responsible for all soil erosion and sediment control practices including Temporary Grassing, Temporary Mulch and other temporary measures. All on-site erosion control shall comply with local erosion and sediment control ordinances. The cost of this work shall be included in the cost of the project unless shown as a separate pay item. All unpaved and natural areas which are disturbed by the construction of this project are to be returned to the pre- existing shape and slope and then finished ,and dressed. No separate payment will be made for grassing, fertilizing and mulching of disturbed areas, unless specifically' shown as a pay item. Discontinued roads or other' areas inside or outside the project construction limits, but within 'the existing or required right-Of-way, shall be obliterated and restored as nearly as possible to the original contour of the ground (See Section 205 of the Standard Specifications). No separate payment will be made for this work. ' Where item number 700-6001 is shown as a pay item Georgia Department of Transportation Specifications are modified to provide that the lump sum price bid shall be full payment for all fertilizer, lime and nitrogen. No separate measurement for payment will be made for any work or materials required to accomplish a stand of permanent grass. G-6 I I I I I I I I I I I I I I I I I I I . INFESTATION: The entire project is considered to be within the limits of an ' insect infested area. The Contractor's attention is called to the following sections of the Standard Specifications: (A) 155 Insect Control (B) 893 Miscellaneous Planting Materials. INSPECTION: This project will be inspected by the Engineer or his Representative. LEVELING COURSE: Leveling shall be placed at the locations and in amounts as approved by the Engineer or his Representative. Measurement and payment shall be made in accordance with the Standard Specifications on a unit price basis. The quantities included in the schedule of items are approximate and subj ect to ,change. All changes will be made at the unit prices, as bid. MISCELLANEOUS DRAINAGE STRUCTURES: All miscellaneous drainage structure such as Catch Basins, Drop Inlets, Manholes, Junction Boxes, Spring Boxes, Drain Inlets, Special Inlets, etc. whether standard or special design shall be paid for Per Each. There will be no separate payment for additional depth unless specifically shown as a pay item. NOTE: All Catch Basins, Drop Inlets, Manholes, exposed Junction Boxes, etc. wi th concrete tops labs shall include manhole rings and covers. PATCHING AND REPAIR OF MINOR DEFECTS: Where necessary, the Contractor is required to patch and repair existing potholes, minor pavement defects and base failures in accordance with the Specifications. PAYMENT FOR PIPE CULVERT INSTALLATION: 1. Payment for pipe culvert or utility installation includes sawing and/or cutting and removing existing pavement and replacing the pavement as specified in accordance with Standard 1401. 2. Payment for pipe culvert includes plugging existing pipe with Class "A" or "B" concrete (See Georgia Standard 9031-L). 3. Payment for pipe culvert includes any required concrete collars (See Georgia Standard 9~31-U). PIPE CULVERTS: Unless otherwise noted, all cross drain, longitudinal and stub pipe are to be reinforced concrete. All required pipe culverts shall be in accordance with Standard 1030-0. G-7 I I I' I I I I I I I 1 I I I ,I I I I I Foundation Backfill Material Type I shall conform to Georgia Standard 1030-0. No separate pay item will be made for this material or its placement. Payment for pipe culvert or utility installation includes sawing and/ or cutting and removing existing pavement and replacing the pavement as specified in accordance with Standard 1401. Payment for pipe culvert includes plugging existing pipe with Class "A" or "B" concrete and for constructing concrete collars. The Contractor shall include in his price bid for pipe, the additional cost of bends, tees, fasteners, appropriate gaskets (see section 848 of the Standard Specifications), and structure excavation. PRECAST CONCRETE UNITS: Precast Concrete Units, other than those specifically allowed by Georgia Department of Transportation Specifications, such as Drop Inlets, Catch Basins, Manholes, etc shall not be installed without written permission from the Engineer. Any such units installed without such written permission shall be removed from the project. PROPERTY CORNERS AND MARKERS: All right-of;...way markers where required shall conform to Georgia Standard 9003. Right-of-way markers shall be flush with the finished ground-line when directed by the Engineer. REMOVAL AND RESETTING OF ORNAMENTAL SHRUBS AND BUSHES AND SOD: It shall be the Contractor's responsibility to remove and rese~ any and all existing ornamental shrubs and bushes and sod in conflict with proposed construction. Coordination wi:th the property owners is essential in this endeavor. The Contractor will not be held responsible, for ,care and maintenance .after removing and resetting these plants and sod except in cases where the Contractor's equipment causes irreparable damage or' where plants and/ or sod, dies as the result of negligence on the Contractor's part. In which cases, the Contractor will be held responsible for replacement. Sod shall be reset with ground preparation in accordance with Subsection 700.0S.A. No additional soil or fertilizer is required for resetting sod. The Contractor shall remove the sod in a manner that will be conducive to insuring that the reset sod will live. At the Contractor's option he may replace any sod he removes with new sod of the same type. No separate payment will be made for this work or replacements unless specifically shown as a pay item. REMOVING AND RESETTING OF OBSTRUCTIONS: It shall be the Contractor's responsibility to remove and reset any and all obstructions such as fences, signs, concrete or brick planters, steps, walkways, brick or concrete entrance columns, etc. which are in conflict with construction and are G-8 I I I I I I I I I I I I I I I I I I I responsible for the security of pets and/or personal property through the use of temporary fence if necessary. No separate payment will be made for this work except when shown as a separate pay item. RIGHT-OF-WAY AND EASEMENTS: The Contractor shall not perform any work outside the limits of the right-of-way or easements. In addition, no equipment or material shall be placed outside these areas without written permission of both the property owner and the Engineer. In the event that the Contractor elects to utilize private property for any'purpose connected with the project such as, but not limited to, staging areas, equipment and/or material storage or simply as a convenience, he shall submit a written agreement to the Engineer containing vital information such as limits of both area and time the property is to be utilized and a description of the intended use. The agreement must be signed by both the property owner and the Contractor and will be reviewed and recorded by the Engineer. Such agreements must be submitted prior to the Contractor's use of the property. SAW CUTS: When matching existing conditions, saw cuts shall be used as required by Augusta-Richmond County. Only saw cuts in Portland Cement Concrete which are shown as contract pay items will be paid for separately. No saw cuts in asphaltic concrete will be paid for separately. SHOULDER WORK: All necessary cleaning of the ,existing pavement including clipping of shoulders required prior to resurfacing shall be the responsibility of the Contractor. The material displaced shall be removed, lowered or spread over the shoulder to an elevation and slope which will provide adequate drainage. The -cost of such work shall be included in the prices bid,for other items ' SPECIFICATIONS, STANDARDS AND OTHER DATA: All references in this document, which includes all papers, writings, documents, drawings, or photographs used, or to be used in connection with this document, to State Highway of Georgia, State Highway Department, Highway Department, or Department when the context thereof means the Georgia Department of Transportation mean, and shall be deemed to mean, Augusta-Richmond Colinty, ,Augusta-Richmond County Commission-Council Department of Engineering Services. The data, together with all other information shown on these plans, or indicated in any way thereby, whether by drawings or notes or in any other matter, are based upon field investigations and are believed to be indicative of actual G-g I I I I I I I I I I I I I I I I I I I conditions. However, the same are shown as information only, are not guaranteed, and do not bind Augusta-Richmond County, Georgia in any way. Only the actual quantities completed and accepted will be paid for. The attention of the bidder is specifically directed to Subsections 102.04, 102.05, and 104.03 of the Standard Specifications, of the Georgia Department of Transportation, current edition, which will be part of this contract. This project is based on and shall be constructed in accordance with the State of Georgia Department of Transportation Standard Specifications for Construction of Roads and Bridges, current Edition and any supplements thereto. All of these specifications shall be considered as though fully contained herein. In cases where conflicts arise within these specifications, they will be revised to resolve such conflict. Until the conflict is resolved, the interpretation of the Engineer shall control the situation. STORM DRAIN PIPE: Unless otherwise noted, all storm drain, longitudinal and stub pipe are to be reinforced concrete. SUBCONTRACTORS: The Contractor shall furnish the official name of all firms he proposes to use as Subcontractors in the work. This information should be furnished at the Preconstruction Conference. However, no work shall be done on this project by. a Subcontractor until the Contractor receive written approval of his Subcontractor(s) from the Engineer. The Engineer shall notify the Contractor, in writing within 10 calendar days whether or not approval of the Subcontractor(s) is granted. SUPERELEVATION: All horizontal circular curves are to be superelevated in accordance with Georgia Standard9028-C as directed by the Engineer. TESTING OF THE WORK: The Contractor shall employ a qualified materials testing laboratory to monitor more fully the quality of materials and work and to perform such tests as may be required under the contract documents as conditions for acceptance of materials and work. THE ENGINEER MAY ORDER TESTING AT ANY TIME HE DEEMS PROPER TO CONTROL THE QUALITY OF THE WORK. Concrete compressive strength project (see Section 500 of Transportation Specifications). where necessary. tests are required on this the Georgia Department of Other tests may be required All test results are 'to be submitted to the Engineer. No separate payment will be made for employing the testing laboratory or any required tests. G-10 I I I I I I I I I I I I I I I I I I I On projects that include asphaltic concrete, cores shall be cut in the asphaltic concrete at random locations, selected by the Engineer, to verify thicknesses. A minimum of three (3) cores per mile or three (3) cores per project, whichever is greater, shall be cut by the Contractor.' If all thicknesses are satisfactory, in accordance with section 400 of the Department of Transportation specifications, no further cores will be required. If cores indicate an unsatisfactory thickness, additional cores, as determined by the Engineer and at locations of the Engineer's choosing, shall be cut to determine the extent of the unsatisfactory thickness. Corrections as shown in Section 400 of the Department of Transportation Specifications shall be made where required. There will be no separate payment for cutting cores, filling core holes or corrective work. Payment shall be included in the price bid for asphaltic concrete items or in the overall bid price of the contract. TEST ROLLING: Prior to placing any base course the subgrade shall be test rolled on six feet centers using a loaded dump truck or other equipment approved by the Engineer. TRAFFIC CONTROL: The Contractor shall provide construction signs in accordance wi th requirements of "Manual on Uniform Traffic Control Devices for Streets and Highways", current edition with added supplements and special provisions. The attention of the Contractor is specifically directed to Subsection 107.09 of the Standard Specifications regarding barricades, danger, warning, and detour signs. All temporary signs, barricades', flashing lights, striping and 'any other traffic control devices required during constru'ction of this project shall meet all requirements of the M.U.T.C,.D., current edition, as directed by the. Engineer and furnished ,by the Contractor with payment in accordance with se~tion l?O. The Contractor shall so conduct his operations that there will be a minimum of interference with, or interruption of, traffic on the travelway. This applies to the initial installation and the continuing maintenance and operation of the facility. At least one-lane, two-way traffic shall be maintained at all times unless approved otherwise by the Engineer. As a minimum, the Contractor must comply with the manual on Uniform Traffic Control Devices, current edition and Georgia Standard 9102. TRAFFIC CONTROL DEVICES: The Contractor shall provide all temporary traffic control devices needed to safely direct traffic through the construction area. G-11 I I I I I I I I I I I I I I I I I I I All temporary traffic control devices are to be placed in accordance with Georgia Department of Transportation standards and Specitications. UTILITIES: The Contractor's attention is directed to the probability of encountering private utility installations consisting of sanitary sewers, water, sprinkler systems, ornamental light systems, gas and underground telephone cables, etc. that either are obstructions to the prosecution of the, work and need to be moved out of the way or, if not, must be properly protected during construction. No separate payment will be made for this work. Public utilities of this nature will be handled by the utility owner. THE FOLLOWING UTILITY COMPANIES SHALL BE NOTIFIED BEFORE WORK BEGINS: Georgia Power Company Post Office Box 488 Augusta, Georgia 30904 Telephone (706)724-0892 Attention: Michael O'Meara Georgia Natural Gas Company Post Office Box 1426 Augusta, Georgia 30913 Telephone (706)722-7791 Southern Bell Telephone 3841 Wrightsboro Road Augusta, Georgia 30909 Telephone (706)828-8500 Attention: Bert Neese Jones Intercable, Inc. 1424 Monte Sano Avenue Augusta, Georgia 30904 Telephone (706)736-6515 Augusta-Richmond Co. Water 2760 Peach Orchard Road Augusta, Georgia 30906 Telephone (706)796-5000 & Sewer All utility facilities which are in conflict with construction, not covered as specific items in ,the detailed estimate, are to be removed and relocated to clear construction by the respective owners, unless added later to the contract as 'a supplemental item. All "above ground" utility structures will be located as near as possible, to the right-of-way line. The Contractor will not be paid for expense caused by utility facilities, other items not being removed or construction in advance of his work. any delays or extra obstructions or any relocated to clear All known utility facilities are shown schematically on highway plans, and not necessarily accurate in location as to plan or elevation. utility facilities such as service lines or unknown facilities not shown on the plans will not relieve the Contractor of his responsibility under this requirement except as noted below. "Existing utility Facilities" means any utility facility that exists on the highway project in its original, relocated or newly installed position. G-12 I I I I I I I I I I I I I I I I I I I other than service lines from street mains to the abutting, property the Contractor will not be held responsible for the cost of repairs to damaged underground utility facilities when such facilities are not shown on the plans and their existence is unknown to the Contractor prior to the damage occurring, providing the Engineer determines the Contractor has otherwise fully complied with the Specifications. The following utility owners have facilities which may The Contractor shall use the one-call center telephone number 1-800-282~7411 for the purposes of coordinating the marking of underground utilities. UTILITY ACCOMMODATION POLICY: In so far as possible work shall be scheduled so that open excavations will not be left overnight. Where trenches, pits or other excavations are within the clear roadside areas and cannot be backfilled before leaving the job site, they shall be covered by timbers or metal plates and protected by reflectorized and/or lighted barricades as appropriate and as directed by the Engineer. Barricades sufficient to prevent a person from falling into an excavated or work area must be erected in areas where these conditions exist. G-13 I I I' I I I 1 I I I I 1 I I I 1 I I I DEPARTMENf OF TRANSPORTATION STATE OF GEORGIA SPECIAL PROVISION SECTION 1SD-TRAFFIC CONTROL August 28, 1995 First Use: October 20, 1995 Modification of Special Provision Section 150 - Traffic Control (Rev. June 21, 1994) Retain Section 150 as written and add the following: For this project, all references to flags on construction warning signs in the Standard Construction Details listed below are deleted except for signs which are mounted at less than seven (7') feet in height (portable signs). Standard Construction Details · Typical By-Pass Detour for Two-Lane Highway · Typical Detour Across Median · Transition of 4-Lane Divided Highway to 2-Lane Highway · Traffic Control General Notes, Standard Legend, Miscellaneous Details In addition, G20-1, G20-2A, and W20-1 signs shown on Georgia Standards 9102, 9106, 9107, and applicable Standard Construction Details shall conform to Part VI of the MUTCD, Revision S, dated September 3, 1993. 150.02 WORK ZONES: Delete "Work Zones" and substitute: Temporary Traffic Control Zones. 150.02. B.2.: Delete last sentence and substitute: Channelization device spacing shall be 10 feet for 200 feet in advance of the temporary gore, and 10 feet for the first 100 feet of the temporary gore. 150.03. F.1. MATERIALS - INTERIM SIGNS: Retain as written and add second paragraph. Posts for all interim signs shall be constructed to yield upon impact unless the posts are,protected by guardrail, portable barrier, impact attenuator or other type of positive barrier protection. Unprotected posts shall meet the breakaway requirements of the "1985 AASHTO Standard Specifications for Structural Supports for Highway Signs, Luminaries and Traffic Signals". Unprotected post splices will not be permitted any higher than four inches above the ground line to lessen the possibility of affecting the undercarriage of a vehicle. 150.0S.H, CONSTRUCTION WARNING SIGNS: CONSTRUCTION WARNING SIGNS THAT ARE REQUIRED TO BE MOUNTED AT SEVEN FEET IN HEIG~ NO LONGER REQUIRE THE USE OF WARNING FLAGS. Delete first sentence of second paragraph and substitute.' Construction warning signs which are mounted at less than seven feet in height (portable signs) shall have two 18 inch x 18 inch fluorescent red-orange or orange-red warning flags mounted on each sign. TC-/ I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 150.04.E.2.a.2.: Retain as written and add: In lane' shift areas skip lines are not allowed. Solid lines are required. 150.04. E.2.b.1.: Retain as written and add: In lane shift areas skip lines are not allowed. Solid lines are required. 150.05 . D. TEMPORARY GUARDRAIL ANCHORAGE: Delete all references to Type 9 and substitute Type 11 (eleven). 150.10 PAYMENT: Item No. 641 - Delete reference to Type 9 and substitute Type 11 (eleven). SPECIAL PROVISION SECTION 150-TRAFFIC CONTROL June 22, 1994 First Use: July 24, 1994 Modification of Standard Specifications, 1993 Edition Retain Section 150 as written and add the following: For this project, all references in the Standard Construction Details listed below to Type I Barricades, Type II Barricades, Type "A" flashing-lights and Type "C" steady bum lights are deleted, except that Type "C" lights will be required for tapers in nighttime lane closures. Standard Construction Details · Typical By-Pass Detour for Two-Lane Highway · Typical Detour Across Median · Transition of 4-Lane Divided Highway to 2-Lane Highway · Traffic:: Control General Notes, Standard Legend, Miscellaneous Details In addition, G20-1, G20-2A, and W20-1 signs shown on Georgia Standards 9102, 9106, 9107, and- applicable Standard Construction Details shall conform to Part VI of the MUTeD, Revision 3, dated September 3,1993. Detail "A" as shown on Georgia Standard 4960 is deleted. SPECIAL PROVISION SECTION 150-TRAFFIC CONTROL Rev. June 21, 1994 First Use: July 24, 1994 Rev.: August 16, 1994 Modification of the Standard Specifications, Current Edition Delete Section 150 as written and substitute the following: 150.01 DESCRIPTION: This section as supplemented by the Plans, Specifications, and MUTCD shall be considered the Traffic Control Plan. Activities shall consist of furnishing, installing, maintaining, and removing necessary traffic signs, barricades, lights, signals, cones, pavement markings and other traffic control devices and shall include flagging and other means for guidance and protection of vehicular and -rc-z I I I I I I I I I I I I I I 1 I I, I 1 DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA pedestrian traffic through the Work Zone. This Work shall include both maintaining existing devices (excluding Traffic Signals) and installing additional devices as necessary in construction work zones. When any provisions of this Specification or the Plans do not meet the minimum requirements of the Manual on Uniform Traffic Control Devices (MUTCD), the MUTCD controls. The 1988 Edition of the MUTCD and Revision 3, dated September, 1993, of Part VI shall be in effect for the duration of the project. A The Contractor shall designate a qualified individual as the Worksite Traffic Control Supervisor (WTCS) who shall be responsible for selecting, installing and maintaining all traffic control devices in accordance With the Plans, Specifications, Special Provisions and the MUTCD. This individual's traffic control responsibilities shall have priority over all other assigned duties. As the representative of the Contractor, the WTCS shall have full authority to act on behalf of the Contractor in administering the Traffic Control Plan. The WTCS shall have appropriate training in safe traffic control practices in accordance with Part VI of the MUTCD. In addition to the WTCS all others making decisions regarding traffic control must meet the training requirements of Part VI of the MUTCD. On projects where traffic control duties will not require full time supervision, the Engineer may allow the Contractor's Project Superintendent to serve as the WTCS as long as satisfactory results are obtained. The WTCS shall have a copy of the MUTCD on the job site. Copies of current MUTCD may be obtained from: U.S. Government Printing Office Superintendent of Documents Mail Stop: SSOP Washington, D.C. 20402-9328 The WTCS shall be available on a 24-hour basis as needed to maintain traffic control devices with access to all personnel, materials and equipment necessary to respond effectively to an emergency situation within forty-five (45) minutes of notification of the emergency. The WTCS shall supervise the initial installation of traffic control devices which,will be reviewed by the Engineer prior to the beginning of construction. Modifications to traffic control devices as required by sequence of operations or staged construction must be reviewed by the WTCS. The WTCS shall , regularly perform inspections to ensure that traffic control is maintained., B. All traffic control devices used during the construction o( a project shall meet the Standards utilized in the MUTeD, and shall comply with the requirements of these Specifications, Project Plans', and Special Provisions. Reference is made to Subsections 104.05, 107.07, and 107.09. C. All reflectorization for construction (black on orange) signs, object markers, and channelization devices shall meet the requirements of Section 913, Type II or III unless otherwise specified. All other signs shall meet the requirements of Type I unless otherwise specified. D. No work shall be started on any project phase until the appropriate traffic control devices have been placed in accordance with Project requirements. Changes to traffic flow shall not commence unless all labor, materials, and equipment necessary to make the changes are available on the Project. E. The Contractor shall secure the Engineer's approval of the Contractor's proposed plan of operation, sequence of work and methods of providing for the safe passage ofvehicu1ar and pedestrian traffic before it is placed in ope..ation. The proposed plan of operation should supplement the approved traffic control plan. Any major changes to the approved traffic control plan, proposed by the Contractor, are to be submitted to the Department for approval in accordance with Subsection 104.03 of the Standard Specifications. . /C'-3 I I I I I I I I I I I I I I I 'I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA Some additional traffic control details will be required prior to any major shifts of traffic. The traffic control details shall include, but not be limited to, the following: 1. A detailed drawing showing traffic location and laneage for each step of the change. 2. The location, size, and message of all signs required by the MUTCD, Plans, Special Provisions, and other signs as required to fit conditions. 3. The method to be used in, and the limits of, the obliteration of conflicting lines and markings. 4. Type, location, and extent of new lines and markings. 5. Horizontal and vertical alignment and superelevation rates for detours, iIlcluding cross section and profile grades along each edge of existing pavement. 6. Drainage details for temporary and permanent alignments. 7. Location, length, and/or spacing of channelization and protective devices (temporary barrier, guardrail, barricades, etc.) 8. Starting time, duration and date of planned change. 9. For each traffic shift, a paving plan, erection plan, or work site plan, as appropriate, detailing workforce, materials, and equipment necessary to accomplish the proposed work. This will be the minimum resource allocation required in order to start the work. The above details shall be submitted to the Engineer for approval at least 14 days prior to the anticipated traffic shift. The Contractor shall have traffic control details for a traffic shift which has been approved by the Engineer prior to commencement of the physical shift. All preparatory work relative to the traffic shift which does not interfere with traffic shall be accomplished prior to the designated starting time. The Engineer and the Contractor's representative will verify that all conditions have been met prior to the Contractor obtaining materials for the actual traffic shift. F. Traffic control devices shall be in acceptable condition when first erected on the project and shall be maintained in accordance with Subsection 104.05 throughout the construction period. All unacceptable traffic control devices shall be replaced within 24 hours. When not in use, all traffic control devices shall be removed, placed or covered so as not to be visible to traffic. If traffic control devices are left in p1ace for more than ten days after completion of the W.ork, the Department shall have the right to remove such devices, claim possession thereof, and deduct the cost of such removal from any monies due, or which may become due, the Contractor. G. The Department reserves the right to restrict construction operations when, in the opinion of the Engineer, the continuance of the Work would seriously hinder traffic flow on days immediately before, ,on, or after holidays or other days in which unusual traffic conditions exist, including threatening or inclement weather. 150.02 WORK ZONES: A. In addition to the other provisions contained herein, work zone traffic control shall be accomplished using the following means and materials: ' 1. Portable advance warning signs as required by the contract or meeting the requirements of the MUTCD and Sub-Section 150.03. 2. Portable sequential or flashing arrow panels as shown in the Plans or Specifications for use on Interstate or multi-lane highway lane closure only, shall be a minimum size of 48" high by 96" -rc-~ I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION , STATE OF GEORGIA wide with not le~s than 15 lamps used for the arrow. The arrow will occupy virtually the entire size of the arrow panel and shall have a minimum legibility distance of one mile. The minimum legibility distance is that distance at which the arrow panel can be comprehended by an observer on a sumiy day, or clear night. Arrow panels shall be equipped with automatic dimming features for use during hours of darkness. The arrow panels shall also meet the requirements as shown iri the MUTeD. The sequential or flashing arrow panels shall not be used for lane closures on two- lane, two-way highways when traffic is restricted to one-lane operations in which case, appropriate signing, flaggers and when required, pilot vehicles will be deemed,sufficient. 3. ,Portable changeable 'message signs meeting the requirements of Section 632 and the MUTCD. 4. Channelization devices meeting the standards of the MUTCD and Subsection 150.05. 5. Precast concrete barrier meeting the requirements of Section 622. 6. Temporary traffic signals meeting the requirements of Section 647. 7. Pavement marking materials complying with Subsection 150.04.A. B. LANE CLOSURES: 1. All lane closures shall have prior approval of the Engineer. Lane closures that require same direction traffic to be split around the Work Area will not be approved for roadways with posted speeds of 35 mph or greater, excluding turn lanes. 2. On multilane highways where traffic has been shifted to the inside lanes for overnight use, the entrance and exit ramps shall have channelization devices placed on both sides of the ramp. The temporary ramp taper length shall be greater than, or equal to, the existing taper length. Interim EXIT gore signs shall be placed at the ramp divergence. Channelization device spacing in the first 100 feet of the temporary gore shall be 25 feet. 3. Termination Area: The transition to normal or full width highway at the end of a lane closure shall be a maximum of 150 feet. , , 4. To provide the greatest possible convenience to the public in accordance with Subsection 107.07, the Contractor shall remove all signs, lane closure markings, and devices immediately when lane closure work is completed or temporarily suspended for 'any length of time or as directed by the Engineer. C. TRAFFIC PACING METHOD: 1. PACING OF TRAFFIC: With prior approval from the Engineer, traffic may be paced allowing the Contractor up to ten (10) minutes maximum to work in or above all lanes of traffic for the following purposes: a Placing bridge members or other bridge work. b. Placing overhead sign structures. c. Other work items requiring interruption of traffic. The Contractor shall provide a uniformed police officer with patrol vehicle and blue flashing light for each direction of pacing. The police officer, Engineer, and flaggers at ramps shall be provided with a radio which will provide continuous contact with the Contractor. TC-S- I I I I I I I I I I I I I I I ,I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA When ready to start the work activity, the police vehicle will pull into the travel lanes and act as a pilot vehicle slowing the traffic thereby providing a gap in traffic allowing the Contractor to perform the Work. Anyon-ramps between the pace and the work area shall be blocked during pacing of traffic, with a flagger properly dressed and equipped with a Stop/Slow paddle. Each ramp should be opened after the police vehicle has passed. Pilot vehicles shall travel at a safe pace speed, desirably not less than' 20 mph interstate and 10 mph non-interstate. The Contractor shall provide a vehicle to proceed in front of the police vehicle and behind the other traffic in order to inform the Contractor's work force when all vehicles have cleared the area. ' Traffic will not be permitted to stop during pacing except in extreme cases as approved by the Engineer. 2. METHODS OF SIGNING FOR TRAFFIC PACING: At a point not less than 1,000 feet in advance of the beginning point of the pace, the Contractor shall erect and cover a W-special sign (72 inch x 72 inch) with a Type "B" flashing light, with the legend "TRAFFIC SLOWED AHEAD SHORT DELAY" (See Detail 150-A). A portable changeable message sign may be used in lieu of the W -special sign. On divided highways this sign shall be double indicated. A worker with a two-way radio shall be posted at the sign, and upon notice that the traffic is to be paced shall turn on the flashing light and reveal the sign. When traffic is not being paced, the flashing light shall be turned off and the sign covered or removed. W -special signs are reflectorized black on orange, Series "C" letters and border of the size specified. -rc-t; I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 1m ... 'LlSNING LIGMT aN TRAF"C SIDE: ,. IMfIGIN tl~. 8ORIl(R ,. IUDIUS , 518 ".,. 5. 7z. ....flF ~ ~ ~ ~ ~(C 10. r 5Z. rl 10. ~~(Q)'[g~ 1$.~' 42. 'J15 ~[H]~~~ ~~@~] ..~~~~ W t.,.I. :: ,L.,:/- I. SEJI. .c. 12. 1Z. SER. .c. ,. 12- ,,8 SER. -c. ,8 ". '2. SEA. .C. --.. .. ,. I-srEClAL 51. (Tt..-clWrf JIOS T wtUfTED I SIGN SHALL NAVE lua UCEIC) AaI) 8(JtD[R ON CIIWCiE R['LECTORIZID IAaGRCIJND DETAIL '50~A D. The Contractor's trucks and other vehicles shall travel in the direction of normal roadway traffic unless separated by a positive barrier, or when construction' activity necessitates otherwise, and shall not reverse direction except at intersections, interchanges, or approved temporary crossings. E. The Contractor shall ensure that dust, mud, and other debris from construction activities do not interfere with normal traffic operations or adjacent properties. F. Existing street lighting shall remain lighted as long as practical and until removal is approved by the Engineer. G. Adequate temporary lighting shall be provided at all nighttime work sites where workers will be immediately adjacent to traffic. H. For their own protection, workers in or adjacent to traffic during nighttime operation shall wear reflectorized vests. ' / K'-7 I I I I I I I I I I I I I I I I I' I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 1. The parking of Contractor's and/or workers personal vehicles within the work area or adjacent to traffic is prohibited. J. The Worksite Traffic Control Supervisor (WTCS) shall monitor the work to ensure that all the rocks, boulders, construction debris, stockpiled materials, equipment, tools and other potential hazards are kept clear of the travel way. These items shall be stored in a location, in so far as practical, where they will not be subject to a vehicle running off the road and striking them. K. All existing pedestrian walkways shall be maintained. Whenever changes to the worksite necessitate changes to existing walkways, temporary walkways shall be provided and maintained, with appropriate signs as necessary, to allow safe passage of pedestrian traffic. 150.03 SIGNS: A. When required for proper traffic control during construction of the project, all existing guide, warning, and regulatory signs shall be maintained by the Contractor in accordance with these Specifications. Existing street name signs shall be maintained at street intersections. All existing illuminated signs shall remain lighted and be maintained by the Contractor. B. When not in use, all inappropriate traffic signs or portions thereof shall be removed, placed or covered so as not to be visible to traffic. All construction warning signs shall be removed within seven calendar days after time charges are stopped or pay items are complete. Subsequent punch-list or other work to be performed shall be accomplished utilizing temporary construction warning signs that shall be removed daily. C. The Contractor shall not remove any existing signs and supports without prior approval from the Engineer. All existing signs and supports which are to be removed shall be stored and protected as directed by the Engineer, and become the property of the Department unless otherwise specified in the contract documents. D. Interim guide, warning, or regulatory sign~ required to direct traffic shall be furnished, installed, reused and maintained by the Contractor in accordance with the MUTCD, the Plans, Special Provisions, or as directed by the Engineer. These signs shall remain the property of the Contractor. The bottom of all interim signs shall be at least seven feet above the level of pavement edge. E. Existing special guide signs on the Project shall be maintained until conditions require a change in location or legend content. When change is required, eXisting signs shall be modified and continued in use if the required modification can be made within existing sign borders using design requirements Oegend, letter size, spacing, border, etc.) equal to that 'of the existing signs, or of Subsection 150.03.E.5. Differing legend designs shall not be mixed in the same sign. 1. SPECIAL GUIDE SIGNS: Special guide signs are those expressway or freeway guide signs that are designed with a message content Oegend) that applies to a particular roadway location. When an existing special guide sign is in conflict with work to be performed, the Contractor shall remove the conflicting sign and reset it in a new, non-conflicting location which has been approved by the Engineer. 2. INTERIM SPECIAL GmDE SIGNS: When it is not possible to utilize existing signs, either in place or relocated, the Contractor shall furnish, erect, maintain, modify, relocate, and remove new interim special guide signs in accordance with the Plans or as directed by the Engineer. 3. INTERIM OVERHEAD GmDE SIGN STRUCTURES: Interim overhead special guide sign structures are not required to be lighted unless specifically required by the Plans. Iflighting is required the sign shall be lighted as soon as erected and shall remain lighted, during the hours of darkness, until the interim sign is no longer required. The Contractor shall notify the Power Company at least thirty (30) days prior to desiring connection to the power source. -rc- a I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 4. The installation of new permanent special guide signs and the permanent modification or resetting of existing special guide signs, when included in the contract, shall be accomplished as soon as practical to minimize the use of interim special guide signs. If lighting is required by the Plans, all new permanent overhead special guide signs shall be lighted as soon as erected. 5. Interim special guide signs that may be required in addition to, or a replacement for, existing expressway and freeway (interstate) signs must be designed and fabricated in compliance with the minimum requirements for guide signing contained in Part 2E "Guide Signs Expressways" and Part 2F "Guide Signs Freeways" of the MUTeD, except that the minimum size of allletters and numerals in the names of places, streets and highways on all signs shall be 16 inches Series ''E'' initial upper-case and 12 inches lower-case. All interstate shields on these signs shall be 48 inches and 60 inches for two-numeral and three-numeral routes, respectively. Additionally, the exit road name or route shield shall be placed on the exit gore sign. F. MATERIALS - INTERIM SIGNS: 1. POSTS - Posts for all interim signs shall meet the requirements of Section 911 except that green or silver paint may be used in lieu of galvanization for steel posts or structural shape posts. Wood posts are not required to be pressure treated. 2. SIGN BLANKS AND PANELS - All sign blanks and panels shall conform to Section 912 ofthe Specifications except that blanks and panels may be ferrous based or other metal alloys. Type 1 and Type 2 sign blanks shall have a minimum thickness of 0.08 inches regardless of the sign type used. Alternative sign blank materials (composites, poly carbonates, fiberglass reinforced plastics, recycled plastics, etc.) shall have a letter of approval from the Office of Materials and Research for use as interim construction signs before these materials are allowed to be incorporated into the work. Signs shall be painted to prevent rust if other metals are used in lieu of aluminum. Plywood blanks or panels will not be permitted. G. All existing, interim and new permanent signs shall be installed so as to be completely visible for an advance distance in compliance with the MUTCD. Limbs, brush, construction equipment and materials shall be kept clear of the driver's line of sight to the signs. H. Advance warning signs shall be placed ahead of construction in accordance with Part VI of the MUTeD and shall include a series of at least three advance road construction (W20-1) signs placed . 'at the termini of the project. The series shall have the legend ROAD WORK (1500 FEET, 1000 FEET, AND 500 FEET.) In addition to the above, multi-lane divided highways shall also have the legend ROAD WORK (2 MILES, 1 MILE, AND 1/2 MILE.) On-ramps and at grade intersecting roadways shall be signed with a minimum of one ROAD WORK AHEAD sign. All construction warning signs shall have two 18 inch x 18 inch fluorescent red-orange or orange-red warning flags mounted on each including the project construction signs (G20-1 and G20-2A.) PrOject mileage indicated on the G20-1 sign shall be the actual project mileage rounded up to the nearest whole mile. All construction warning signs on divided highways shall be double indicated (i.e., on the left and right sides of the roadway.) 1. The sequential or flashing arrow panels shall be placed on the shoulder at or near the point where the lane closing transition begins. The panels shall be mounted on a vehicle, trailer, or other suitable support. Vehicle mounted panels shall be provided with remote controls. Minimum mounting height shall be seven feet above the roadway to the bottom ofthe panel; except on vehicle mounted panels which should be as high as practical. J. The portable changeable message sign, when specified, shall be placed ahead of construction activities and shall meet the requirements of Section 632 and the MUTCD. -rc- f' I I I I I I I I I I I I I I I I I' I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA K. The flashing beacon assembly, when specified, shall be used in conjunction with construction warning' signs, regulatory, or guide signs to inform traffic of special road conditions which require additional driver attention. The flashing beacon assembly shall be installed in accordance with the requirements of Section 647. . 150.04 PAVEMENT MARKINGS A Generally, full pattern pavement markings in accordance with Section 652 and in conformance with Section 3A and 3B, except 3B-3 and 3B-5, of the MUTeD are required on all courses before the roadway is opened to traffic. No passing zones shall be marked to conform to Section 150.04 E. During oonstruction and maintenance activities on all highways open to traffic, both existing markings and markings applied under this Section shall be fully maintained until Final Acceptance. If the pavement markings are, or become, unsatisfactory in the judgement of the Engineer due to wear, weathering, or construction activities, they shall be restored immediately. On resurfacing projects pavement markings shall be provided on all surfaces that are placed over existing markings. On widening and reconstruction projects (where the lane configuration is altered from the pre-construction layout) pavement markings will be as required by the Plans or the Engineer. On new construction projects pavement marking plans will be provided. B. MATERIALS: All traffic striping applied under this Section shall be a minimum four inches in width and shall conform to the requirements of Section 652, except as modified herein. Raised pavement markers (RPMs) shall meet the requirements of Section 654. Markings on the final surface course which must be removed shall be a removable type. The Contractor will be permitted to use paint, thermoplastic, or tape on pavement which is to be overlaid as part of the project, unless otherwise directed by the Engineer. Partial (skip) reflectorization (Le. reflectorizing only a portion of a stripe) will not be allowed. C. USAGE: The Contractor shall sequence the work in such a manner as to allow the installation of markings in the fmallane configuration at the earliest possible stage. Inappropriate or conflicting existing pavement markings shall be removed. When shifting of traffic necessitates removal of centerline, lane lines, or edge lines, all such lines shall be removed prior to, during, or immediately after any change so as to present the least interference with traffic. Before any change in traffic lane(s) alignment, marking removal equipment shall be present on the project for immediate use. If marking removal equipment failures occur, the equipment shall be repaired or replaced (including leasing equipment if necessary), so that the removal can be accomplished without delay. Except for the final surface, markings on asphaltic concrete may be obliterated by an overlay course, when approved by the Engineer. When an asphaltic concrete overlay is placed for the sole purpose of eliminating conflicting markings and the in place asphaltic concrete section will allow, said overlay will be eligible for payment only if designated in the Plans. Overlays to obliterate lines will be paid for only once and further traffic shifts in the same area shall be accomplished with removable markings. Only the minimum asphaltic ooncrete thickness required to cover lines (generally 60 IbJsq. yd. of Asphaltic Concrete "Hit) will be allowed. Excessive build-up will not be permitted. When an overlay for the sole purpose of eliminating oonflicting markings is not allowed, the markings no longer applicable shall be removed in accordance with Subsection 656.02. The elimination of conflicting pavement markings by overpainting with paint or liquid asphalt is not accept.able. D. Raised pavement markers (RPMs) are required as listed below for all asphaltic concrete pavements before the roadway is open to traffic. When Portland Cement Concrete is an intermediate or fmal surface and is open to traffic, one calendar day is allowed for cleaning and drying before the installation of RPMs is required. TC-/t? I I I I I ,I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION , STATE OF GEORGIA 1. On Interstate and limited a~ess highways under construction, excluding projects consisting primarily of asphalt resurfacing items, retro-reflective raised pavement markers (RPMs) shall be placed and/or maintained on intermediate pavement surfaces opened to traffic as follows: a' SUPPLEMENTING LANE LINES: 80 foot centers on skip lines with curvature less than three degrees. (Includes tangentS.) 40 foot centers on solid lines and all lines with ~rvature between three degrees and six degrees. 20 foot centers on curves over six degrees. 20 foot centers on lane transitions or shifts. b. SUPPLEMENTING RAMP GORE LINES: 20 foot centers, two each, placed side by side. c. OTHER LINES: As shown on the plans or directed by the Engineer. 2. On other highways under construction RPMs shall be used and/or maintained on intermediate pavement surfaces as follows: a SUPPLEMENTING LANE LINES AND SOLID LINES: 40 foot centers except on lane shifts. (When required in the Plans or Contract.) 20 foot centers on lane shifts. (Required in all cases.) b. SUPPLEMENTING DOUBLE SOLID LINES: 40 foot centers (one each beside each line) except on lane shifts. (When required in the Plans or Contract.) 20 foot centers on lane shifts. (Required in all cases.) RPMs are n2t allowed on right edge lines. E. EXCEPTIONS FOR INTERIM MARKINGS: Some exceptions to the time of placement and pattern of markings are permitted as noted below, however, full pattern pavement markings are required for the completed project. 1. '!WO-LANE, '!WO-WAY ROADWAYS a SKIP LINES: All interim skip (broken) stripe shall conform to Section 652 except that stripes shall be at least four feet long with a maximum gap of 36 feet. On curves greater than six degrees, a two-foot stripe with a maximum gap of 18 feet shall be used. In lane shift areas skip lines will not be allowed. Solid Lines will be required. Interim skip lines will be permitted for a period not to exceed 14 calendar days. Interim skip lines must be replaced with markings in full compliance with Section 652 prior to expiration of the 14 calendar day period. -rc-// I I I I I I I, I I I I 1 I I I ,I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA Interim raised pavement markers may be substituted for the interim skip (broken) stripes. Ifraised pavement markers are substituted for the four foot interim skip stripe, four markers spaced at equal intervals over a four feet distance will be required. No separate payment will be made if the interim raised pavement markers are substituted for interim skip lines. Interim raised pavement markers shall be retro-reflective; shall be the same color as the pavement markers for which they are substituted, and shall be visible during daytime. The type of interim marker and method of att;achment to the pavement must be approved by the Office of Materials and Research but in no case will the markers be attached by the use of nails. The interim: raised pavement markers must be maintained until the full pattern pavement markings are applied. At the time full pattern pavement markings are applied the interim raised markers shall be remov~d in a manner that will not interfere with application of the full pattern pavement markings. b. NO PASSING BARRIER: On two-lane, two-way roadways for periods not to exceed three calendar days where skip centerlines are in place, no-passing zones may be identified by using post or portable mounted DO NOT PASS regulatory signs (R4-1 24" x 30") at the beginning and at intervals not to exceed 1/2 mile within each no-passing zone. A post or portable mounted PASS WITH CARE regulatory sign (R4-124" x 30") shall be placed at the end of each no-passing zone. Post mounted signs shall be placed in accordance with the MUTCD. Portable signs must have a minimum vertical height of thr~e feet above the pavement surface to the bottom of the sign and be secured in such a manner as to not be easily blown over or misaligned. c. EDGELlNES: (1) Bituminous Surface Treatment Paving: Edgelines will not be required on intermediate surfaces (including asphaltic concrete leveling for bituminous surface treatment paving) that are in use for a period of less than 60 calendar days except at bridge approaches, on lane transitions, lane shifts, and in such other areas as determined by the Engineer. On the final ,surface, edgelines must be placed within 30 calendar days of the time that the final surface was placed. (2) All Other Types of Pavement: Edgelines will not be required on intermediate surfaces that are in use for a period of less than 30 calendar days except at bridge approaches, on lane transitions, lane shifts, and in such other areas as determined by the Engineer. On the final surface, edgelines must be placed within 14 calendar days of the time that the surface was placed. d. MISCELLANEOUS PAVEMENT MARKINGS: School zones, railroads, stopbars, symbols, words and other similar markings shall be placed on final surfaces conforming to Section 652 within 14 calendar days of completion of the final surface. On intermediate surfaces these markings will generally not be required unless specified by the Engineer because of special conditions or when the intermediate surface will be in use for more than 45 calendar days. 2. MULTI-LANE HIGHWAYS - WITH NO PAVED SHOULDER(S) OR PAVED SHOULDER(S) FOUR FEET OR LESS a. UNDIVIDED HIGHWAYS (INCLUDES PAVED CENTER TURN LANE) (1) Centerlines and No-Passing Barrier - Full pattern centerlines and no-passing barriers shall be restored before nightfall. . TC-/& I I I I I I 1 1 I I 1 1 I I 1 1 I' I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA (2) Lanelines - Interim skip (broken) stripe as described in Subsection 150.04.E.1.a. may be used for periods not to exceed three calendar days. (3) Edgelines - Edgelines shall be placed on intermediate and fin~ surfaces within three calendar days of obliteration. b. DIVIDED HIGHWAYS (GRASS OR RAISED MEDIAN) (1) Lanelines - Full pattern skip stripe shall be restored before nightfall. (2) CenterlinelEdgeline - Solid lines shall be placed on intermediate and final surfaces within three calendar days of obliteration. c. Miscellaneous Pavement Markings Same as Subsection 150.04.E.1.d. 3. LIMITED ACCESS ROADWAYS AND ROADWAYS WITH PAVED SHOULDERS GREATER THAN FOUR FEET a. Same as Subsection 150.04.E.2. except as noted in (b) below. b. EDGELINES- (1) Asphaltic Concrete Pavement - Edgelines shall be placed on intermediate and fmal surfaces prior to opening to traffic. (2) Portland Cement Concrete Pavement - Edgelines shall be placed on any surface open to ' traffic no later than one calendar day after work is completed on a section of roadway. All water and residue shall be removed prior to daily striping. F. APPLICATION OF PAVEMENT MARKINGS: The Contractor shall furnish layout, clean as necessary, and preline the surface for the placement of pavement markings applied under this Section. All existing marking tape on final surfaces shall be removed prior to placement of final markings. . Pavement markings shall re-establish No-Passing Zones in the locations and configuration that existed prior to construction. Existing No-Passing Zones shall be clearly identified as to'location prior to construction by staking or erection of DO NOT PASS and PASS WITH CARE signs. On new location projects and on projects where either horizontal or vertical alignments have been modified, the location of No-Passing Zones will be identified by the Engineer. ' G. MOBILE OPERATIONS: When pavement markings (centerlines, lane lines, and edge lines) are applied in a continuous operation by moving vehicles and equipment, the following ,minimum . equipment and warning devices shall be required in addition to the requirements of the MUTCD: 1. A lead vehicle is required for two-way traffic conditions and shall have an approved sequential or flashing arrow panel mounted so as to be easily visible to oncoming traffic. A lead vehicle is not required for low volume off-system routes and one-way traffic applications. 2. The work vehicle applying markings shall have a sequential or flashing arrow panel mounted on ' the rear. If the work vehicle is also functioning as the lead vehicle then an approved arrow panel shall be mounted so aE to be easily visible to oncoming traffic. The work vehicle shall follow directly behind the lead vehicle. 3. The work vehicle placing cones shall follow directly behind the work vehicle applying the markings. The cone work vehicle shall have a sequential or flashing arrow panel mounted on the rear. -/ V-/3 I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 4. For multi-lane roadways a protection vehicle shall follow the above vehicles and the protection vehicle shall also display a prominent sign with the legend PASS ON LEFT (RIGHT). On interstate and limited access roadways, the protection vehicle shall be equipped with a truck mounted attenuator (TMA) that is certified for impacts not less than 45 mph in accordance with NCHRP 230. 5. All vehicles shall be equipped with the official slow moving vehicle symbol sign and left and right- side rear mounted flashing yellow lights. 150.05 CHANNELIZATION A GENERAL: Channelization should clearly delineate the travelway through the work zone and alert drivers and pedestrians to conditions created by work activities, in or near the travelway. Channelization shall be done in accordance with the plans and specifications, the MUTCD, and the following requirements. 1. Types of Devices Permitted for Channelization in Construction Work Zones: a. DRUMS: (1) DESIGN: Drums shall meet the minimum requirement of the MUTCD and shall be reflectorized as required in Subsection 150.01.C. (2) APPLICATION: Drums shall be used as the required channelizing device to delineate the full length of a lane closure, shift, or encroachment, except as modified by this Subsection. (a) TRANSITION TAPERS AND LANE CLOSURES: Drums shall be used on all transition tapers. The minimum length of the approach transition taper for a lane closure, shift, or encroachment for highways with posted speed of 45 mph or greater shall be equal to the lane width oflateral shift (Ft.) x the posted speed limit (Mph), (L = WS), but not less than 150 feet. For multiple lane closures, only one lane may be closed per taper with a minimum tangent length of 2"1 between tapers. The length of a closed lane, excluding the transition taper, will be limited to two mile, unless otherwise approved or directed by the Engineer. Drums shall be placed the fulllength of the taper spaced at maximum _ intervals in feet equal to the numerical speed limit (EXAMPLE: 55 Mph Speed Limit = 55 feet maximum spacing). For taper lengths on urban, residential or other streets where the posted speed is 40 mph or less, the minimum length of the approach transition taper may be computed using the formula L = WS2/60. Greater taper length shall be used when required for individual situations. Drums with steady burning lights, for the length of the taper only, are required if the condition exists into the night. (b) LONGITUDINAL CHANNELIZATION: Drums shall be spaced as listed below for various roadside work conditions except as modified by Subsection 150.06. Spacing shall be used for situations meeting any of the conditions listed as follows: (1) 50 FOOT SPACING MAXIMUM: (a) For difference in elevation exceeding two inches. (b) For healed sections no steeper than 4:1 as shown in Subsection 150.06, Detail ISO-E.. -rc-/? I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA (2) 100 FOOT SPACING MAXIMUM: (a) For difference in elevation of two inches or less. (b) Flush areas ~here equipment or workers are within ten feet of the travel lane. (3) 200 FOOT SPACING MAXIMUM: Where equipment or workers are more than ten feet from travel lane. Lateral offset clearance to be four feet from the travellane. (a) For paved areas eight feet or greater in width that are paved flush with a standard width travellane. (b) For disturbed shoulder areas not completed to typical section that are flush to the travel lane and considered a usable shoulder. When the appropriate signs are posted advising of conditions such as soft or low shoulder, drums may be removed after shoulders are completed to typical section and grassed and after guardrail or other safety devices have been installed. b. VERTICAL PANELS: (1) DESIGN: All vertical panels shall have a minimum of270 square inches ofretro-reflective area facing the traffic and shall meet the I'equirements of the MUTCD. (2) APPLICATION: Lane encroachment by the drom on the travel way should permit a remaining lane width of ten feet. When encroachment reduces the travel way to less than ten feet, vertical panels shall be used to restore the travel way to ten feet or greater. No other application of vertical panels will be permitted. c. CONES: (1) DESIGN: All ccines shall be a minimum of28 inches in height regardless of application and shall meet the requirement of the MUTCD. (2) APPUCATION: For longitudinal channelizing only, cones will be permitted for daylight closures or minor shifts. (Drums are required for all tapers.) The use of cones for nighttiine work Will not be permitted. - ' d. BARRICADES: (1) DESIGN: The use of Type I. and Type II barricades will not be permitted. Type III barricades shall meet the minimum requirements of the MUTCD and shall be reflectorized as required in Subsection l50.01.C. (2) APPLICATION: Type III barricades shall be placed as required by the plans, the Standards, and as directed by the Engineer. e. WARNING LIGHTS: (1) DESIGN: All warning lights shall meet the requirements of the MUTCD. (2) APPLICATION: (a) Type A low-intensity flashing lights shall be used as shown in the Plans, the Standards, and as directed by the Engineer. Flashing lights are not required for advance warning signs in Subsection l50.03.H. -rC-/5 I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA (b) Type C Steady-Burn lights shall be used on all tapers when the condition exists intO the night. Steady-burn lights shall also be used as shown in the Plans, the Standards, and as directed by the Engineer. f. PORTABLE BARRIERS: (1) DESIGN: Portable Barriers shall meet the requirements of Section 622 - PRECAST CONCRETE BARRIER. (2) APPLICATION: Portable'Barriers shall be placed as required by the plans. standards, and as directed by the Engineer. When Portable Barrier is located 20 feet or less from a travel lane, yellow reflectors shall be fixed to the top of the barrier at intervals not greater than 50 feet and shall be mounted approximately two inches above the barrier. The reflectors shall , be either 10" x 10" square Type V (or equal) reflective sheeting mounted on flat-sheet panels, or 8" diameter center-mounted sealed prismatic reflex reflectors housed in an aluminum backing with a single grommeted hole. Approach end of Portable Barrier shall be flared or protected by an impact attenuator (crash cushion) or other approved treatment in accordance with Georgia Standard 4960, Construction Details and Standard Specifications. On interstate or other controlled access highways where lane shifts or crossovers cause opposing traffic to be separated by less than 40 ft., precast concrete barrier shall be used as a separator. B. TEMPORARY SAND LOADED AlTENUATOR MODULES 1. DESCRIPTION: This work consists of the furnishing, installation, maintenance, relocation, reuse as required, and removal of Temporary Sand Loaded Attenuator Modules for traffic impact attenuators. 2. MATERIALS: Materials used in the Att.enuator shall meet the requirements of Subsection 648.02 for Type 2 Sand Loaded Modules - Cylindrical Drums or Type 2-A Sand Loaded Modules - Stabilizer Drums with Wine Glass shaped Inner Containers. 3. CONSTRUCTION: TempOrary Sand Loaded Att.enuator Module installation shall conform ,to the requirements of Subsection 648.03, Manufacturer's recommendations, and Georgia Standard 4960 and shall be installed at locations designated by the Engineer-. C. PORTABLE IMPACT ATTENUATORS: 1. DESCRIPTION: This work consists of the furnishing (including spare parts), installation, maintenance, relocation, reuse as required, and removal of Portable Impact Attenuators. 2. MATERIALS: Materials used in the Attenuator shall meet the requirements of Section 650 for Type A Portable Impact Attenuators. 3. CONSTRUCTION: Portable ImpactAttenuator installation shall conform to the requirements of Subsection 650.03, Manufacturer's recommendations, and Georgia Standard 4960 and shall be installed at locations designated by the Engineer, and/or shown on the plans. D. TEMPORARY GUARDRAIL ANCHORAGE - Type 11: 1. 'DESCRIPTION: This work consists of the furnishing, installation, maintenance and removal of Temporary Guardrail Anchorage - Type 11 used for Portable Barrier or temporary guardrail end treatment. TC-/~ I 'I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 2. MATERIALS: Materials used m the Temporary Guardrail Anchorage - Type 11 shall meet the requirements of Subsection 641.02 of the Standard Specifications and current Georgia Standards and may be new or used. Materials salvaged from the Project which meet the requirements of Standards may be utilized if available. The use of any salvaged materials will require prior approval of the Engineer. 3. CONSTRUCTION: Installation of the Temporary Guardrail Anchorage - Type 11 shall conform to the requirements of the Plans, current Georgia Standards and Subsection 641.03 of the Standard Specifications. Installation shall also include sufficient additional guardrail and , appurtenances to effect the transition and connection to Temporary Concrete Barrier as required by the de,tails in Georgia Standard 4960. ' 150.06 EXCAVATION ADJACENT TO A TRAVEL LANE: Construction work involving trenching adjacent to a travel way shall not begin until the Contractor is able to continuously place the required typical section to within two inches of the existing pavement elevation, or heal the remaining difference in elevation to the traveled way as shown in Detail150-E. Channelization devices and placement during the construction period shall conform to the requirements of Subsection 150.05 and Details l50-B, l50-C, l50-D, and l50-E shown herein. In addition to the signs specified in Section 150 and the MUTCD, a W-20 sign with the legend "(LEFT) (RIGHT) LANE NARROWS" with two flags shall be kept just off the paving edge and 500 feet upstream of the point where channelization devices are erected on the paving edge. A. STONE BASES, SOIL AGGREGATE BASES, AND SOIL BASES: Drop-offs in elevation of more than two inches between surfaces carrying, or adjacent to, traffic will not be allowed for more than 24 hours. However, where the Contractor has demonstrated the ability to continuously excavate and backfill in a proficient manner, a single length of excavated area not to exceed 1000 feet may be left open as a start up area for periods not to exceed 48 hours. B. ASPHALT BASES/BINDERS: Drop-offs in elevation of more than two inches between surfaces carrying or adjacent to traffic will not be allowed for more than 48 hours. C. PORTLAND CEMENT CONCRETE AND CEMENT STABILIZED BASES: Construction work adjacent to the traveled way which involves these types of bases shall be healed within 48 hours after , the curing period is complete for each section placed. During the placement period, traffic control devices will be in accordance with Subsection 150.05 and Detail 150-B. D. MISCELLANEOUS EXCAVATIONS OR DROP-OFFS'ADJACENT TO TRA VELWAY: Work such as drainage structures, utility facilities, or any other work which results in a drop-off adjacent to the travel way shall be performed expeditiously so as to minimize the exposure to the hazard. As soon as practical, the excavation shall be backfilled to the minimum requirements 'of Detail150-E. In no case will the drop-offbe allowed to exist more than five calendar days. This may require stage construction, such as plating and backfilling the incomplete work. -rc- /7 I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA NOTE. Drums reQUired for thTa 10cotlon,sPoced at 50 F'T. Intervals. If the traveled way wfdth fs reduced to leas than 10 feet by the use of drums. vertical panels shall be used In lieu of drums. LocatIon of drums when drop-off exceeds ~ Inches. ----------~.. ----~--------\ III( t NEW CONSTRUCTION + TRAVEL LANE 'r+ DROP-OFF GREATER THAN 4 INCHES DEl AIL 150-8 Drums spaced at SO feet InterYols. LocatIon of drum$ when drop-off Is ,2+ Inches to ~ Inches. _1_~~______~. -----------\ III( t NEW CONSTRUCTION + TRAVEL LANE 'r+ DROP-OFF OF 2 + INCHES TO 4 INCHES DEl AIL 150-C -y-c-/? I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA Drums spaced at 100 feet Infervals. Location of drums when drop-off fs 2 Inches ar less. ~f~:"I- ______~. -----------~ + TRAVEL LANE ~ ~ t NEW CONSTRUCTION Compacted graded aggregote, subbase materIal or dlrt. ' NO STEEPER THAN 4:1 ~ DROP-OFF OF 2 INCHES OR LESS DET AIL 150-0 Location of drums ImmedIately ofter completIon of healed section. spoced ot 50 ft.lntervols. TOP OF DRUM TO BE LEVEL + TRAVEL LANE ~ t NEW CONSTRUCTION 1r--+ HEALED SECTION 'DET AIL 150-E TC- /f I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 150.07 FLAGGING AND PILOT CARS: A. Flaggers shall be provided as required to handle traffic, as specified in the Plans or Special Provisions, and as required by the Engineer. B. All flaggers shall meet the requirements of the MUTCD and must have received training and a certificate upon completion of the training from a Department approved training program. Failure to provide certified flaggers as required above shall be reason for the Engineer suspending work involving the flagger(s) until the Contractor provides the certified flagger(s). ' C. Flaggers shall wear high-visibility clothing in compliance with'the MUTCD and shall use a Stop/Slow paddle meeting the requirements of the MUTCD for controlling traffic. The Stop/Slow paddles shall have a shaft length of seven (7) feet minimum. In addition to the Stop/Slow paddle, a flagger may use a 24 inches square red/orange flag as an additional device to attract attention. For night work, the vest shall have reflectorized stripes on front and back. D. Pilot vehicles shan be provided if specified in the Plans or Specifications and meet the requirements of the MUTCD. E. Signs for flagger traffic control shall be placed in advance of the flagging operation in accordance with the MUTeD. In addition to the signs required by the MUTCD, signs at regular intervals, warning of the presence of the flagger shallbe placed beyond the point where traffic can reasonably be expected to stop under the most severe conditions for that day's work. 150.08 ENFORCEMENT: The safe passage of pedestrians and traffic through and around the temporary traffic control zone, while minimizing confusion and disruption to traffic flow, shall have priority over all other Contractor activities. Continued failure of the Contractor to comply with the requirements of Section 150 (TRAFFIC CONTROL) will result in non-refundable deductions of monies from the Contract as shown in this Subsection for non-performance of Work. Failure of the Contractor to comply with this Specification shall be reason for the Engineer suspending all other work on the Project, except erosion control and traffic control, taking corrective action as specified in Subsection 105.15, and/or withholding payment of monies due the Contractor for any work on the Project until traffic control deficiencies are corrected. These other actions shall be in addition to the deductions for non-performance of traffic control. -rc- ~ 0 I I I 1 1 I I I I I I I, I I I 1 1 I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA SCHEDULE OF DEDUCTIONS FOR EACH CALENDAR DAY OF DEFICIENCIES OF TRAFFIC CONTROL INSTALLATION AND/OR MAINTENANCE ORIGINAL TOTAL CONTRACT AMOUNT From More Than To and Includine- Dailv Chare-e $0 $100,000 $100 100,000 1,000,000 250 1,000,000 5,000,000 500 5,000,000 20,000,000 750 20,000,000 40,000,000 1,000 40,000,000 - 1,500 150.09 MEASUREMENT: A TRAFFIC CONTROL: When listed as a pay item in the Proposal, payment will be made at the Lump Sum price bid, which will include all traffic control not paid for separately, and will be paid as follows: When the first Construction Report is submitted, a payment of25 (twenty-five) percent of the Lump Sum price will be made. For each progress payment thereafter, the total of the Project percent complete shown on the last pay statement plus 25 (twenty-five) percent will be paid Oess previous payments), not to exceed one hundred (100) percent and subject to normal retainage. When no payment item for Traffic Control-Lump Sum is shown in the Proposal, all of the requirements of Section 150 and the Traffic Control Plan shall be in full force and effect. The cost of complying with these requirements will not be paid for separately, but shall be included in the overall bid submittal. B; SIGNS: When shown as a pay item in the contract, interim special guide signs will be paid for as ' listed below. All other regulatory, warning, and guide signs, as required by the Contract, will be paid for under Traffic Control Lump Sum or included in the overall bid submitted. ' 1. Interim ground mounted or interim overhead special guide signs will be measured for payinent by the square foot. This payment shall be full compensation for furnishing the signs, including supports as required, erecting, illuminating overhead signs, maintaining, removing, re-erecting, and final removal from the Project. Payment will be made only one time regardless of the number of moves required. 2. Remove and reset existing special guide signs, ground mount or overhead, complete, in place, will be measured for payment per each. Payment will be made only one time regardless of the number of moves required. 3. Modify special guide signs, ground mount or overhead, will be measured for payment by the square foot. The area measured shall include only that portion of the sign modified. Payment shall include materials, removal from posts or supports when necessary, and remounting as required. ~c-z/ I I I ,I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA C. PRECAST MEDIAN BARRIER: PreCast Median Barrier will Be measured as specified in Section 622. D. CHANGEABLE MESSAGE SIGN, PORTABLE: Changeable Message Sign, Portable will be measured as specified in Section 632. E. TEMPORARY GUARDRAIL ANCHORAGE, Type 11: Temporary Guardrail Anchorage - Type 11 will be measured by each assembly, complete in place and accepted according to the details shown in the plans, which shall also include the additional guardrail and appurtenances necessary for transition and connection to Temporary Concrete Barrier. Payment shall include all necessary materials, equipment, labor, site preparation, maintenance and removal. F. TRAFFIC SIGNAL INSTALLATION - TEMPORARY: Traffic Signal Installation - Temporary will be measured as specified in Section 647. ' G. FLASHING BEACON ASSEMBLY: Flashing Beacon Assemblies will be measured as specified in Section 647. H. TEMPORARY, SAND LOADED ATrENUATOR MODULES: Each Sand Loaded Attenuator Module of the type specified includes all material components, hardware, incidentals, labor, site preparation and maintenance. Each module will be measured for payment by the drum only o~ce regardless of the number oflocations installed. Modules to replace those damaged or destroyed by traffic impact will also be measured by the unit for payment. Upon completion of the project, the modules shall be removed and retained by the Contractor. 1. PORTABLE IMPACT ATTENUATORS: Each Portable Impact Attenuator will be measured by the unit which shall include all material components, hardware, incidentals,labor, site preparation, and maintenance, including spare parts recommended by the manufacture for repairing minor accident damage. Each unit will be measured only once regardless of the number oflocations installed, moves required, or number of repairs necessary because of traffic. damage. Upon completion of the project, the units shall be removed and retained by the Contractor. J. PAVEMENT MARKINGS: Pavement markings will be measured as specified in Section 150. 150.10 PAYMENT: When shown in the Schedule ofItems in the Proposal, the following items will be paid for separately. Item No. 150. Traffic Control. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . Lump ~um Item No. 150. Traffic Control, Solid Traffic Stripe _ Inch, (Color) ............. per Linear Mile Item No. 150. Traffic Control, Skip Traffic Stripe_ Inch, (Color) .............. per Linear Mile Item No. 150. Traffic Control, Solid Traffic Stripe, Thermoplastic _ Inch, (Color) ........................... per Linear Mile Item No. 150. Traffic Control, Skip Traffic Stripe, Thermoplastic _ Inch, (Color) ........................... per Linear Mile Item No. 150. Traffic Control, Pavement Arrow with Raised Reflectors ................. per Each Item No. 150. Traffic Control, Raised Pavement Markers - All Types. . . . . . . . . . .. . . . . . .. per Each Item No. 150. Interim Ground Mounted Special Guide Signs. . . . . . . . . . . . . . . . . . .. per Square Foot Item No. 150. Interim Overhead Special Guide Signs .......................... per Square Foot 7&Z Z I I Item No. 150. I Item No. 150. Item No. 150. I Item No. 150. I Item No. 150. Item No. 150. I Item No. 150. Item No. 150. I Item No. 622. Item No. 632. I Item No. 641 I Item No. 647. Item No. 647. I Item No. 647. I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA Remove & Reset Existing Special Guide Signs, Ground Mount, Complete in Place. . . .. . . . . . . . . . . . . . . . . . . . . . . . . . . . .. per Each Remove & Reset, Existing Special Guide Signs, , Overhead,Complete in Place ..................................... Per Each Traffic Control, Temporary Sand Loaded Attenuator Modules ............ per Each , , Traffic Control, Portable Impact Attenuator . . . . . ~ . . . . . . . . . . . . . . . . . . . . .. Per Each Traffic Control, Pavement Markers, Words and Symbols .... . . . . . .. ,per Square Foot Traffic Control, Pavement Arrow (Painted) With Raised Reflectors .... ~ . .. per Each Modify Special Guide Sign, Ground Mount. . . . . . . . . . . . . . . . . . . . . .. per Square Foot Modify Special Guide Sign, Overhead ........................... per Square Foot Precast Concrete Median Barrier. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . per Linear Foot Changeable Message Sign, Portable .................................. per Each Temporary Guardrail Anchorage, Type 11 ............................. per Each Traffic Signal Installation, Temp ..................................., Lump Sum Flashing Beacon Assembly, Structure Mounted. . . . . . . . . . . . . . . . . . . . . . . .. per Each Flashing Beacon Assembly, Cable Supported. . ~ . . . . . . . . . . . . . . . . . . . . . . .. per Each -rc - Z 3 I I DEPARTMENT OF TRANS~ORTATION STATE OF GEORGIA CONTRACT I I I 1 1 I I Il. I I 1 J ' II oJ . I I I DO NOT UNSTAPLE THIS BOOKLET... . ENTER ALL REQUIRED INFORMATION ---------------------------- EITHER BY HAND OR BY STAMP. DATE OF OPENING : NONE CALL ORDER : NONE CONTRACT ID : C31654-97-000-0 PCN PROJECTS AND CONTRACT NO. 3291042C10000 TSAP-121 (46) Cl COUNTY : RICHMOND CODE: 102450 RICHMOND COUNTY cc-/ I I I I I I I I I I I I I I I I I I I THIS AGREEMENT MADE AND ENTERED INTO THIS THE ___DAY OF 19 BY AND BETWEEN THE DEPARTMENT OF TRANSPORTATION - ~.. i<'" PARTY OF THE FIRST PART (HEREINAFTER CALLED THE DEPARTMENT) AND THE COMMISSIONERS OF--- RICHMOND ---COUNTY (HEREINAFTER CALLED THE COUNTY) WHO HAVE BEEN DULY AUTHORIZED TO EXECUTE THIS AGREEMENT: WITNESSETH: WHEREAS, THE DEPARTMENT AND THE COUNTY DESIRE THE IMPROVEMENT AND CONSTRUCTION OF A CERTAIN FACILITY AND THE COUNTY DESIRES AND AGREES TO FURNISH AND DELIVER ALL THE MATERIAL AND TO DO AND PERFORM ALL THE WORK AND LABOR FOR SAID PURPOSE. THE PROJECT BEING MORE PARTICULARLY DESCRIBED HEREIN. NOW THEREFORE IN CONSIDERATION OF THE PREMISES, THE MUTUAL COVENANTS HEREIN CONTAINED AND THE SUM OF ONE DOLLAR ($1.00) BY EACH OF THE PARTIES TO THE OTHER IN HAND PAID, THE RECEIPT WHEREOF IS HEREBY ACKNOWLEDGED, THE PARTIES HERETO AGREE AS FOLLOWS: (1) THE WORK AND MATERIALS SHALL BE IN STRICT AND ENTIRE CONFORMITY WITH THE PROVISIONS OF THIS CONTRACT AND THE PLANS AND SPECIFICATIONS PREPARED (OR APPROVED) BY THE CHIEF ENGINEER OR HIS AUTHORIZED REPRESENTATIVE THE ORIGINALS OF WHICH ARE ON FILE IN THE OFFICE OF THE CHIEF ENGINEER AND WHICH SAID PLANS AND SPECIFICATIONS ARE HEREBY MADE PART OF THIS AGREEMENT AS FULLY AND TO THE SAME EFFECT AS IF THE SAME HAD BEEN SET FORTH AT LENGTH IN THE BODY OF THIS AGREEMENT. THIS CONTRACT WILL BE EXECUTED AND CONSTRUCTED IN ACCORDANCE WITH THE STANDARD SPECIFICATIONS, 1993 EDITION AND THE 1996 SUPPLEMENTAL SPECIFICATION BOOK SPECIAL PROVISIONS INCLUDED IN AND MADE A PART OF THIS CONTRACT. (2) IT IS UNDERSTOOD THAT MATERIAL PITS ARE TO BE FURNISHED BY THE COUNTY AT NO COST TO THE DEPARTMENT OF TRANSPORTATION. (3) IT IS UNDERSTOOD THAT THE DEPARTMENT OF TRANSPORTATION WILL NOT , PARTICIP~TE IN THE COST OF ANY UTILITY FACILITY REMOV~L AND RELOCATIONS NECESSARY IN CONNECTION WITH CONSTRUCTION OF THIS PROJECT, UNLESS OTHERWISE SPECIFIED IN THE CONTRACT. THE (COUNTY/CITY) SHALL BE RESPONSIBLE FOR HANDLING THE ARRANGEMENTS WITH UTILITY OWNERS FOR ANY REMOVAL AND RELOCATIONS NECESSARY. THE (COUNTY/CITY) SHALL GIVE THE UTILITY OWNERS AMPLE NOTICE, OF. THE IMPENDING CONSTRUCTION, TO ALLOW TIME FOR ENGINEERING AND MATERIAL ORDERS REQUIRED FOR ANY REMOVAL AND RELOCATIONS NECESSARY. ALSO, THE (COUNTY/CITY) AGREES TO CLEAR RIGHTS-OF-WAY OBSTRUCTIONS WITHOUT EXPENSE TO THE DEPARTMENT OF TRANSPORTATION. FOR PURPOSES OF APPLYING PROVISION OF THIS PARAGRAPH, RAILROADS ARE CONSIDERED UTILITIES. IN ADDITION TO THE FOREGOING, THE (COUNTY/CITY) SHALL OBTAIN APPROVAL OF PLANS AND ACQUIRE EASEMENTS OR OTHER PROPERTY RIGHTS FROM THE RAILROAD FOR CONSTRUCTION WITHIN RAILROAD PROPERTY/RIGHT OF WAY AND SHALL PROVIDE FOR THE PROTECTION OF RAILROAD INTERESTS, INCLUDING FLAGGING AND INSPECTION, AS MAY BE REQUIRED BY THE RAILROAD. (4) IT IS UNDERSTOOD THAT THE QUANTITIES SHOWN ARE APPROXIMATE ONLY AND SUBJECT EITHER TO INCREASE OR DECREASE AND ~~ INCREASES OR DECREASES ARE TO BE PAID FOR AT THE CONTRACT UNIT PRICE GIVEN. (5) THE WORK SHALL BEGIN WITHIN TEN DAYS AFTER NOTIFICATION TO BEGIN WORK BY THE CHIEF ENGINEER TO THE COUNTY THE WORK SHALL BE CARRIED THROUGH TO COMPLETION WITHOUT UNREASONABLE DELAY AND WITHOUT SUSPENSION OF WORK UNLESS AUTHORIZED IN WRITING BY THE CHIEF ENGINEER. IF THERE ARE UNREASONABLE DELAYS OR UNAUTHORIZED SUSPENSIONS OF WORK, THE DEPARTMENT RESERVES THE RIGHT TO CHARGE THE COUNTY, NOT AS A ~~_~ I I I I I I I I I I I I I I I I I I I PENALTY BUT AS LIQUIDATED DAMAGES, THE COST TO THE DEPARTMENT OF MAINTAINING ITS ENGINEERING AND INSPECTION FORCE ON THE WORK OR TO CANCEL THIS CONTRACT AND COMPLETE THE WORK BY CONTRACT OR OTHERWISE. (6) THE WORK SHALL BE DONE IN ACCQRDANCE WITH THE LAWS OF THE STATE OF GEORGIA AND TO THE SATISFACTION OF THE DEPARTMENT OF TRANSPORTATION THE DECISION OF THE CHIEF ENGINEER UPON ANY QUESTION CONNECTED WITH THE EXECUTION OR FULFILLMENT OF THIS AGREEMENT AND INTERPRETATION OF THE SPECIFICATIONS OR UPON ANY FAILURE OF DELAY IN THE PROSECUTION OF THE WORK BY THE COUNTY SHALL BE FINAL AND CONCLUSIVE (7) THE COUNTY AGREES TO PERFORM ALL EXTRA WORK THAT MAY BE REQUIRED OF THEM ON THE BASIS OF ACTUAL COST. (8) THE FINANCING OF THIS PROJECT SHALL BE AS FOLLOWS: PAYMENTS WILL BE MADE ON MONTHLY STATEMENTS AS THE WORK PROGRESSES. (9) DRUG-FREE WORKPLACE CERTIFICATION: THE UNDERSIGNED CERTIFIES THAT THE PROVISIONS OF CODE SECTIONS 50-24-1 THROUGH 50-24-6 OF THE OFFICIAL CODE'OF GEORGIA ANNOTATED, RELATED TO THE **DRUG-FREE WORKPLACE ACT**, HAVE BEEN COMPLIED WITH IN FULL. THE UNDERSIGNED FURTHER CERTIFIES THAT: (1) A DRUG-FREE WORKPLACE WILL BE PROVIDED FOR THE CONTRACTOR'S EMPLOYEES DURING THE PERFORMANCE OF THE CONTRACT; AND (2) EACH CONTRACTOR WHO HIRES A SUBCONTRACTOR TO WORK IN A DRUG-FREE WORKPLACE SHALL SECURE FROM THAT SUBCONTRACTOR THE FOLLOWING WRITTEN CERTIFICATION: 'AS PART OF THE SUBCONTRACTING AGREEMENT WITH (CONTRACTOR'S NAME) (SUBCONTRACTOR'S NAME) ---------------------------- -------------------------- CERTIFIES TO THE CONTRACTOR THAT A DRUG-FREE WORKPLACE WILL BE PROVIDED FOR THE SUBCONTRACTOR'S EMPLOYEES DURING THE PERFORMANCE OF THIS CONTRACT PURSUANT TO PARAGRAPH (7) OF SUBSECTION (B) OF CODE SECTION 50-24-3.' , ALSO THE UNDERSIGNED FURTHER CERTIFIES THAT HE WILL NOT ENGAGE IN THE UNLAWFUL MANUFACTURE, SALE, DISTRIBUTION, DISPENSATION, POSSESSION, OR, USE OF A CONTROLLED SUBSTANCE OR MARIJUANA DURING THE PERFORMANCe OF THE CONTRACT. ------------------------------------------------------------------- C~3 IN WITNESS WHEREOF THE DEPARTMENT OF TRANSPORTATION HAS CAUSED THESE PRESENTS TO BE EXECUTED, BY THE COMMISSIONER OF SAID DEPARTMENT, WHO HAS BEEN DULY AUTHORIZED, AND BY THE BOARD MEMBER FOR THE COUNTY, WHO HAS BEEN DULY AUTHORIZED BY THE COMMISSIONERS OF SAID COUNTY, WHO HAVE HERETO SET THEIR HAND THIS DAY AND YEAR AS SHOWN BELOW. I I I I I I I I I I I I I I I I I I I *************************************** FED ID NO. fIRS NO. ******************************~******** EXECUTED ON BEHALF OF THE DEPARTMENT OF TRANSPORTATION THIS EXECUTED ON BEHALF OF ---RICHMOND COUNTY THIS s (I) co . "OE Q,) :>,E e"O o.c 0.10 co ...~ Cc CZ>Q,) Eo B~ o :3 "00 o in, -bQ ~~ 19 1922 U)J.j COMMISSIONER MEMBER DAY OF THE BY: COMMISSIONER "RECOMMENDED: DIVISION DIRECTOR DATE: WITNESS FOR THE DEPARTMENT OF TRANSPORTATION: 1921 C c- 9- I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA SPECIAL PROVISIONS DATE: 04/29/~ PAGE: CONTRACT 1D : C31654-97-000-0 ACCEL/DECEL LANE CONSTRUCTION ON SR 121 AT PEPPERIDGE RD. S.P. CODE ------------------------------------------------------------------------------ SPECIAL PROVISIONS DESCRIPTION -~---------------------------------------------------------------------------- 107-1-93-SP 10B-1-93-SP 161-2-93-SP 400-2-93-SP 402-1-93-SP A97-0-00-SP A9B-O-OO-SP A99-0-00- LEGAL REGULATIONS (ENVIRONMENTAL)COUNTY/CITY CONTRACTS WAIVE PROGRESS SCHEDULE SOIL EROSION & SEDIMENTATION (COUNTY/CITY CONTRACTS) ASPHALTIC CONCRETE (COUNTY CONTRACTS) . RECYCLED A HALTlf CON R~TE (C UNTY CONTRACTS) o rt~ (l cc-s I I I I I I I I I I I I I I I I I I I ., Revised: April 23, 1997 DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA SPECIAL PROVISION SECTION 106 - CONTROL OF MATERIALS 106.03 SAMPLES, TESTS, CITED SPECIFICATIONS: Delete the second paragraph in this Sub-Section and substitute the following: For work perfonned under Section 400, Hot Mix' Asphaltic Concrete Construction, all materials will be inspected and tested by the Hot Mix Producer before incorporation into the Work. All quality control samples will be taken and tested by the Hot Mix Producer's designated quality control technician. Such tests shall be perfonned at the Hot Mix Producer's expense and in accordance with the methods of tests established by the Department. Copies of all tests performed by the Hot Mix Producer will be furnished to the Engineer and will become a part of the project records. At the discretion of the Department, the Hot Mix Producer's quality control tests may be used as acceptance tests. The Department will maintain surveillance of the Hot Mix Producer's Quality Assurance Acceptance Prog~arn and shall take samples and conduct tests as necessary to verify correctness of the Hot Mix Producer's quality control tests and determine acceptability of materials and ' construction. The Hot Mix Producer will be responsible for the quality of the materials incorporated therein. Office of Materials and Research cc- C; I I I I I I I I I I I I I I I I I I I . I . Revision: May 1, 1994 DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA SPECIAL PROVISION SECTION 107 -_LEGAL REGULATIONS AND RESPONSIBILITY TO THE PUBLIC DELETE SUB-SECTION 107.23 AS WRITTEN AND SUBSTITUTE THE FOLLOWING: 107.23 ENVIRONMENTAL CONSIDERATIONS: All environmental considerations and clearances shall be the responsibili ty of the County or municipali ty to meet, including the requirements of Section 404 of the Clean Water Act (33 USC 1344). Af::c. July I, 1991, State funded projects must comply with the requirements of Chapter 16 of Title 12 of the Official Code of Georgia Annotated, the Georgia Environmental Policy Act (GEPA), of 1991. In compliance with GEPA. those projects for which Federal funding is sought, and NEPA compliance is, accomplished, are exempt from the requirements of GEPA. GEPA requires that environmental documentation be accomplished for County or City projects if more than 50 percent of the total project cost is funded by a grant of a State Agency or a grant of more than $250,000 is made by the State Agency to the municipality or County. The "responsible official of the government agency shall determine if a proposed governmental action is a proposed governmental action which may significantly adversely affect the quality of the environment". . A.' THE FOLLOWING PROJECTS WOULD NOT SIGNIFICANTLY ADVERSELY AFFECT THE QUALITY OF THE ENVIRONMENT: Non-land disturbing' ac'tivities and minor land disturbing activities which would not be anticipated to significantly adversely af~ect the quality of the environment include the follOWing list. These types of projects funded with state money would not be subject to environmental assessment of any kind. Hearing procedures outlined in GEPA would not be applicable. 1. Minor roadway and non-historic bridge projects. a. Modernization of an existing highway by resurfacing, restoration. rehabilitation. adding shoulders. widening a single lane or less in each direction. and the addition of a median within previously !disturbed existing right-of-way. Adding auxiliary lanes for localized purposes (weaving, climbing. speed changes. etc.), and correcting substandard curves and intersections within previously disturbed existing right-of- way. b. c. Non-historic bridge replacement projects in existing alignment with no detour bridge. CC-7 .;.. ...-...>...oI!__-_ I.' .. -. . I I' I I I I I I I I I I I I I I I I 2. Lighting, signing, pavement marking, signalization, freeway surveillance and control systems, and railroad protective devices. 3. Safety projects such as grooving, glare screen, safety barriers, energy attenuators, median barriers, etc. 4. Highway landscaping and landscape modification, rest area projects and truck weigh stations within previously disturbed existing right- of way. 5. Construction of bus shelters and bays within existing right-of-way. 6. Temporary replacement of a highway facility which is commenced immediately after, the occurrence of; a natural disaster or catastrophic failure to restore the highway for the health, welfare, and safety of the public. B. THE FOLLOWING PROJECTS MAY NOT SIGNIFICANTLY ADVERSELY AFFECT THE QUALITY OF THE ENVIRONMENT: For projects wh'ich will cause land disturbance and for which there is no anticipation that the project may significantly adversely affect the quality of the environment, certain studies will be undertaken. These studies would serve to document whether or not" the County or municipality should anticipate that a project might significantly adversely affect the quality of the environment. Documentation of the studies will be accomplished through ,he use of the "GEPA Investigation Studies" checklist. The types of project which would fall under the category would includ~: 1. Bridge replacement project on new location or with a detour bridge, w~ere there are no significant adverse impacts to historic or archaeological resources, no involvement with Federally listed threatened and endangered species and no significant adverse impact to wetlands. 2. Passing lanes, median additions and widening projects, where there are no significant adverse impacts to historic or archaeological resources, no involvement with Federally listed threatened and endangered speci~s and no significant adverse impact to wetlands. 3. Safety and intersection improvements where there are no significant adverse impacts to historic or archaeological resources, no involvement with Federally listed threatened and endangered species and no significant adverse impact to wetlands. 4. Rest area projects and truck weight stations with no purchase of additional right-of-way. 5. New location projects where there are no significant adverse impacts to historic or archaeological resources, no involvement with Federally listed threatened and endangered species and no significant adverse impact to wetlands. CC-B ,'"""""'-- ' ~ .'~-'''''.'' . I . .. ... . I I I I I I I I I I I I I I I I I I "',...:...~i,..:::~\::'r.'''~1Ii.:.1.oOY..t"!,~, . --'-~._._".- . ..-..... -.. If studies demonstrate that the project will not significantly adversely affect the quality of the environment, project files will be documented~ If studies demonstrate that the project may significantly adversely affect the quality of the environment, development of an environmental effects report (EER) will be undertaken along with full GEPA compliance. c. THE FOLLOWING PROJECTS MAY SIGNIFICANTLY ADVERSELY AFFECT THE QUALITY OF THE ENVIRONMENT: This category of project may projects. If such projects an EER shall be prepared. include major widening and new location result in a significant. adverse effect, D. EER PROCEDURE: GEPA calls for consideration of the "cumulative effect of the proposed government actions on the environment....if a series of proposed government actions are related either geographically or as logical parts in a chain of contemplated actions". Therefore, EER I S for sections of roadways to be widened' or built as new location facilities will include all projects which are connected geographically or as logical parts in a chain of contemplated actions. 1. During preparation of an environmental effect report, the County or municipality will consult with and solicit comments from agencies which have jurisdiction by law, special expertise, or other interest with respect to environmental impacts. 2. In compliance with GEPA the fOllowing shall be contained in the EER, at a minimum: a. Cover sheet; b. Executive summary; c. Alternatives, including the no-build; d. Relevant environmental setting; Geology, soils, water supply and wetlands, flor~l fauna, archaeology/history, economic environment, energy, cultural resources; e. The environment~l impact of the proposed action of the relevant setting and mitigation measures proposed to avoid or minimize adverse impact; f. Unavoidable adverse environmental effects; g. Value of 'short-term uses of the environment and maintenance . and enhancement of its long-term value; h. Beneficial aspects, both long term ,and short term and its economic advantages and disadvantages; i. Comments of agencies which have jurisdiction by law, special CC- CJ expertise, or other interest with respect to any environmental impact or resource; ..'~ .:".'......._~;..a:r'_____.......__~ -~ ~_.-.. ..... ..~_._----~ - . I' I I . . ..... . 3. At least 45 days prior wi th the undertaking, in which the proposed to occur notice that prepared". to.making a decision as to whether to proceed publish in the "legal organ of each county governmental action or any part thereof is an environmental effects report has been I I 4. The County or municipality shall send a copy of the EER and all other comments to the Director, EPD. I I' 1 I I 5. The County or municipality shall make the document available to the,public and agencies, upon request. 6. A public hearing will be held in each affected county if a least 100 residents of the State of Georgia request on within' 30 'days of publication in the legal organ of an affected county. The responsible official or his designee may hold ~ public hearing if less than 100 requests are received. [The County or municipality is not relieved of other State legal requirements of publi~ hearings, however. J 7. Following' the public notice period and/or public hearing a summary of the document, comments received and recommendation as to whether, to proceed wi th the act ion as originally prepared, to proceed wi th changes, or not to proceed will be prepared (Notice of Decision). I 1 I 8. This decision document, when signed by the responsible official, will be sent to the Director, EPD, and an abbreviated notice of the decision will be published in the legal organ of each county in which the proposed governmental action or any part thereof is to OCcur. 9. A copy of the decision document, the EER, anq public hearing comments (if any) will be sent to the DEPARTMENT OF TRANSPORTATION, OFFICE OF ENVIRONMENT AND LOCATION a~d the, DEPARTMENT OF NATURAL RESOURSES, ENVIRONMENTAL PROTECTION DIVISION for their files. I 1 I I I I DEPARTMENT OF TRANSPORTATION OFFICE OF ENVIRONMENT AND LOCATION 3993 AVIATION CIRCLE ATLANTA, GEORGIA 30336 DEPARTMENT OF NATURAL RESOURSES ENVIRONMENTAL PROTECTION DIVISION 205 BUTLER STREET, SE SUITE 1152 ATLANTA" GEORGIA 30334 Any mitigation ,measures identified in the EER will be incorporated. into the final project plans. Office of State Aid CC-/tJ I I I I I I I I I I I I I I I I I I I 108193SP DEPARTMENT OF TRANSPORTATION ,STATE OF GEORGIA SPECI_~ PROVISION FIRST USE 1993 SPECIFICATIONS JULY 1, 1993 SECTION 108 - PROSECUTION AND PROGRESS FOR THIS PROJECT, THE PROGRESS SCHEDULE REQUIRED BY ARTICLE 108.03, NEED NOT BE SUBMITTED. cc-// I I I I I I I I I I I I I I I I I I I Revised: April 23, 1997 DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA SPECIAL PROVISION SECTION 152 - FIELD LAB ORA TORY BUILDING 152.03 Plant Laboratory Building: Add the following to requirements for Laboratory buildings at asphaltic concrete plants: ITEM 6: 1 Each - Computer, ffiM or ffiM Compatible - 540 Megabyte Hard Disk Drive or bigger - 3 1/2 inch High Density Floppy Disk Drive - CD-ROM Drive (4X or faster) -, Windows 95 Operating System - Mouse - Modem 9600 Baud or Higher - 1 Parallel and 2 Serial Ports - 16 Megabyte Random Access Memory Expandable to at Least 32 Megabytes - VGA Monitor - 486 Microprocessor Operatirig at 33 Megahertz or faster microprocessor ITEM 7: 1 Each - Printer (Desk Jet HP Letter quality printer) Office of Materials and Research CC-/l- I I I I I I I I I I I I I I I I I I I ~- --.--.-----........-.- .....----....------:.....--- -...--.- 161293SP DEPARTMENT OF TRANSPORTATION , STATE OF GEORGIA , SPECIAL PROVISION FIRST USE 1993 SPECIFICATIONS JULY 1, 1993 REVISED: NOVEMBER 6, 1995 SECTION 161 - CONTROL OF SOIL EROSION ,AND SEDIMENTATION RETAIN AS WRITTEN AND ADD THE FOLLOWING: IT SHALL BE THE RESPONSIBILITY OF THE COUNTY OR CITY TO MEET THE REQUIREMENTS OF CHAPTER 7 OF TITLE 12 OF THE OFFICIAL CODE OF GEORGIA ANNOTATED, THE EROSION AND SEDIMENTATION ACT OF 1975, AS CURRENTLY AMENDED. CC-/3 I I I I I I I I I I I I I I I I I I I April 23, 1997 DEPARTl\1ENT OF TRANSPORTATION STATE OF GEORGIA SPECIAL PROVISION SECTION 400 - HOT MIX ASPHALTIC CONCRETE CONSTRUCfION (LAR, LAU, PR & SCH-PR) 400.05 CONSTRUCTION: 4oo.05.CA: LEVELING COURSE: Delete second paragraph and substitute the 'following: Mixtures for leveling courses shall meet the requirements of the approved Job Mix Formula as defined in subsection 400.06 and all appropriate requirements of Section 828 and will be'subject to Acceptance as stated in Sub-section 4oo.07.A. TABLE 400.05.CA.a.: PATCHING AND LEVELING: Add the following statement after Table 4oo.05.CA.a. Where the surface mix is to be a Sand Asphalt, Sand Asphalt will be allowed for Leveling and/or Patching in addition to the above mixes. Sand Asphalt will not be allowed as Leveling under surface treatment, slurry seal, or other asphaltic concrete mixtures. 4oo.05.F.: CONSTRUCTION OF CONTROL STRIPS AND DETERMINATION OF TARGET DENSITY: Delete this Sub-Section in its entirety and substitute the following: ' Construction of control strips will not be required and 96% of Laboratory Density should be used to control compaction or if job conditions warrant, the Engineer may establish a maximum practical density. 400.05.G.: MIXTURE NOT REQUIRING CONTROL STRIPS: Delete this Sub-Section in its entirety and substitute the following: 4oo.05.G.: MIXTURE NOT REQUIRING COMPACTION TESTS: For Asphaltic Concrete and Sand Asphalt with a plan spread rate of 140 IbsJyds.2 or less, density tests will not be required. These courses shall be compacted as follows: 1. COMPACTION EQUIPMENT: The compaction equipment must ,be in good mechanical condition and capable of compacting the mixture. The number, type, size, operation, and condition of the compaction equipment shall be subject to the approval of the Engineer. A minimum of the following equipment shall be required: cc - /if r I: 1 I I 1 I I I 1 I I I I I I I I I I SECTION 400 Page 2 of 8 April 23, 1997 a. One steel wheel breakdown roller weighing at least 10 tons or vibratory roller operating at a low amplitude and at a minimum frequency of 47 Hz. b. One rubber tire roller weighing at least 8 tons or exerting at least 80 IbsJ in.2 contact pressure. c. One steel wheel finishing roller weighing at least 8 tons or vibratory roller operating in static mode. 2. ROLLING OPERATION: Rolling shall be started as close behind the spreader as possible without excessive distortion of the mix and shall be continued until roller marks are no longer visible. A minimum rolling pattern shall consist of 2 coverages with the breakdown roller, 6 coverages with the Pneumatic-Tired roller, and 2 coverages with the steel wheel fini,sh roller. 400.07. ACCEPTANCE PLANS: Delete all references to pay adjustments and pay factors. In addition, Delete 4oo.07.A, Gradation and Asphalt Cement Content, except for Tables 400.07 A.I. and 400.07 A.2., and substitute the following: 4oo.07.A. HOT MIX PRODUCER ACCREDITATION OF MATERIALS SAMPLING AND TESTING OF ASPHALTIC CONCRETE: Asphaltic Concrete Mixture will be randomly sampled and tested by the, Hot Mix Producer or Hot Mix Producer's Representative. In addition, these tests results may be used for Acceptance on a Lot basis. 1. QUALITY CONTROL PROGRAM: This Quality Control Program allows the Department to accept the Hot Mix Producer's quality control tests as Acceptance Tests for Asphaltic Concrete mixtures. The Hot Mix Producer's, Quality Control Program as established in S.O.P. 27, "Quality Assurance for Hot Mix Asphaltic Concrete Plants in Georgia," shall include, but not be'limited to: a The assignment of all quality control responsibilities to specifically named individuals who have been duly certified by the Office of Materials and Research. b. Provisions for prompt implementation of control and corrective measures. c. Provisions for liaison with the Project Manager, Bituminous Construction Engineer and Testing Management Supervisor at all times. c c - /5 I. I. I I, I I I I I I I I I I I I I I I SECTION 400 Page 3 of 8 April 23, 1997 d. Provisions for reporting daily through Office of Materials and Research computer Bulletin Board Service (BBS) the test results for extractions, lime checks, and stripping tests. Other tests, checks, calibrations, etc. will be reported on a form developed by the Hot Mix Producer and shall become a part of the project records. The Quality Control Program shall be submitted for approval prior to beginning of work. 2. CERTIFICATION REQUIREMENTS: The Office of Materials and Research will certify the Hot Mix Producer's Laboratory and testing equipment to assure that the equipment to be used is accurate and meets Departmental testing standards. Laboratories which participate in and maintain AASHTO Accreditation for testing Asphaltic Concrete Mixtures will be acceptable for certification by the Department provided other contract requirements are met. The designated Quality Control personnel must be certified by the Office of Materials and Research prior to commencement of work. There are two certification Levels for Quality Control Technicians. To become a certified Level 1- Quality Control Technician (QCT), such persons must be able to demonstrate that they are competent in performing the process control and acceptance tests and procedures related to Hot Mix Asphaltic Concrete production. The Level 2-QCT shall, in addition to Level 1 requirements, be capable of and responsible for,making process control adjustments. The Engineer shall be notified in writing of any change in Quality Control personnel. The Hot Mix Producer shall have at least one designated QCT personnel at the plant at all times except when daily total weight for all mix types is to be less than 250 tons. If daily production for all mix types is less than 250 tons, the QCT - may 'be responsible for conducting tests for up to two plants. In addition, the Hot Mix Producer is also required to have available, either at the plant site or within irnrnediate contact by phone or radio, a Level 2-QCT person responsible for making prompt process control adjustments as necessary to correct the mix. 3. SAMPLING, TESTING AND INSPECTION REQUIREMENTS: Mixtures will be randomly sampled according to GDT-73 (Method C) and tested by the QCT on a Lot basis. A copy of the computer generated random sampling data shall be maintained as a part of the project records. The Hot Mix Producer's QCT shall perform all ,Sampling and Inspection duties In accordance with GSP-21. cc- /6 r~ I I I I I I I I I I I I I I I ,I I I I SECTION 400 Page 4 of 8 April 23, 1997 The Hot Mix Producer's Qcr shall perform extraction or ignition (GDT-83 or GDT-I25) and gradation' analysis (GDT -38) of samples of the mixture produced each day and sampled in accordance with GSP-15. ' The Hot Mix Producer shall maintain a Process, Control Flow chart for each sieve specified on the Job Mix Formula and including the percent asphalt content Such chart should include a graph plot of he deviations from the Job Mix Formula for each test as well as the allowable range based on the mixture control tolerances specified in Section 828 of the Standard Specifications. If the Hot Mix Producer's QCT obtains 2 consecutive samples out of the Mixture Control Tolerances specified in Section 828, production will stop immediately and the problem with mixture control will be investigated and corrected by the Hot Mix Producer's Level 2 QCT personnel prior to restarting production. The QCT shall measure the temperature of the mixture and record the results on the load ticket each time a sample is taken. This will be required for all mixes except Asphaltic Concrete "D" "D modified", or "Porous European Mix" mix where the temperature shall be measured and the results recorded at least once for each hour of production. The respective load ticket shall also be signed by the QCT for each load from which a sample is taken. When hydrated lime is to be included in the mixture, calibration of the lime system shall be checked for accuracy a minimum of twice weekly during production and the results of these calibration checks shall be posted at the plant for review. Additionally, records of materials (Asphalt Cement, Aggregates, Hydrated Lime,' etc.) invoices shall be made ' available for review u,pon request at all times for the'duration of the wo~k. ' 4. COMPARATIVE AND QUALITY ASSURANCE PROGRAM: Periodic comparative testing will be required of each Qcr and will be coordinated by the Department to monitor consistency of equipment and test procedures. In addition, the Department will take independent samples to monitor the Hot Mix Producer's Quality Control Program. For clarification, Department samples taken from opposite quarters of material sampled by the Hot Mix Producer are defined as Comparison Samples. Other independent samples which are taken by the Department from material produced during the same Lot are defined as Quality Assurance samples. This Program is further defined as follows: a. Comparison Sampling and Testing: During the quartering process of Hot Mix 'samples, the opposite quarters from the test specimen shall be labeled and retained for Department comparison testing. In addition, the remaining CC-/7 ~. I. I ,I I I I I I I I I I I I I I I I ~~~ SECTION 400 Page 5 of8 material removed from the total sample shall be labeled and retained for possible Referee testing. These samples shall be stored in a suitable container and secured in a protected environment. If the Hot Mix Producer's Acceptance Test -results meet a 1.0 Pay Factor and if the Department does not procure these samples retained within two working days of the represented mix being produced, these samples may be discarded. April 23, 1997 The Department will test comparison samples on a random basis at a frequency deemed necessary to assure that the Hot Mix Producer's testing techniques are yielding accurate results. Results of Department tests will be compared to the respective Hot Mix' Producer's Acceptance tests. The. maximum tolerance allowed for Comparison Samples as defined above shall be as follows: SIEVE SIZE , MAXIMUM DIFFERENCE lNTERMEDIA TE SURFACE and BASE 1 112" 1" 3.5% 3.5% 3.5% 3.5% 2.5% 2.0% .4% 4.0% 4.0% 4.0% 4.0% 3.5% 3.0%, 2.0% .5% ' 1/2" 3/8" No.4 No.8 No. 200 A.C. If Comparison tests are within these tolerances, production may continue arid at the discretion of the Engineer, the Hot Mix Producer's tests can be used as the acceptance tests for the affected Lot. If test results are not within these tolerances, the corresponding Referee Samples shall be tested by another Departmental Technician and compared to the tolerance for Comparison Samples as given above. If test Results of Referee Samples, when compared to the respective QCT's sample, are within these tolerances, the Hot Mix Producer's tests can be used as Acceptance Tests for the effected Lot. If tests results are not within these tolerances, the Hot Mix Producer's Quality, Control methods shall be reviewed and a thorough investigation will be made if deemed' necessary . b. Quality Assurance Sampling and Testing: . The Department will take samples for the purpose of monitoring the, effectiveness of the Hot Mix Producer's CC...18 !!f" -! I' .1 I I I I, I I I I I I I I I I I I I April 23. 1997 SEcrION 400 Page 6 of 8 Quality Control Program. These samples may be obtained from the same load as Qcr samples were taken or other loads at the plant or roadway. or samples obtained immediately behind the spreader and prior compaction. The samples will be tested and analyzed by the Department in accordance with standard procedures. c. The Department shall randomly take and test a minimum of two ,Quality Assurance (QA) samples from each five days of production to assure that the mixture is being adequately controlled and accurately sampled and tested. The maximum tolerance for QA samples as defined above. when compared to the Job Mix Formula, shall be the same as the Mixture Control Tolerances as outlined in Section 828. If test results are not within these tolerances. the Department shall immediately take another sample from the respective mix. If tests results of the additional sample are within these tolerances, production may continue. If test results of the additional sample are not within these tolerances, the Department will investigate by taking at least three random samples from throughout the Lot in accordance with Sub-Section 4oo.07.F.. Should the Engineer determine that Quality Control requirements are not being met or that unsatisfactory results are being obtained, prompt corrective action shall be taken by the Hot Mix Producer. Failure' to take prompt, effective action will be cause for the Engineer to discontinue acceptance of the mix. If it is determined by the Department that the QCT has provided erroneous' information, ' his or her certification may be withdrawn, and the Hot Mix Producer may be subject to punitive or legal action. Technicians who lose their certification due to falsification of test data will not be eligible for re-certification in the future. In-place material represented by unacceptable tests will be evaluated by cores in accordance with Sub-Section 400.07.F. These samples shall be used for acceptance. 5. GRADATION AND ASPHALT CEMENT CONTENT: A Lot shall consist of the number of megagrams of Asphaltic Concrete produced an'd placed'each production day; however. if this production is less than 500 tons, or its square yard equivalent, it may be incorporated in the next working day's production. ' In the event the final day's production is insufficient to constitute a Lot. it may be included in the Lot for the previous day's run, or at the discretion of the Engineer, may be treated as a separate Lot with a corresponding lower number of tests. CC~/1 t1 .1' .1 I .1 I I I I I I I I I I I I I I I SECTION 400 Page 7 of 8 April 23, 1997 Quality Control of the mixture will be based upon the mean of the deviations from the , Job Mix Formula of the specified number of test results per Lot in accordance with the Mixture Acceptance Schedule. This mean will be determined by averaging the actual numeric value of the individual deviations from the Job Mix Formula, disregarding whether the deviations are positive or negative amounts. Table 400.07.A.1. shall be used to determine acceptance of all surface mixes and Table 4OO.07.A.2. shall be used to determine' acceptance of all subsurface mixes. The samples will be taken randomly in accordance with GDT-73. In the event less than the specified number of samples are taken, acceptance will be based on the mean of the deviations from the Job Mix Formula of the number of tests run, 400.07B.: COMPACTION: Delete this Sub-Section in its entirety. 400.07.C.: SURFACE TOLERANCE: Delete as written and substitute the following: All paving shall be subject to visual and straightedge inspection during construction operations and thereafter prior to final acceptance. A 10 feet straightedge shall be retained in the vicinity of the paving operation at all times for the purpose of measuring surface irregularities on all courses. The straightedge and labor for its use shall be provided by the contractor. The surface of base, intermediate, and surface courses shall be inspected with the straightedge as necessary to detect irregularities. All irregularities in excess of 3/16 inch in 10 feet for base, intermediate, and surface courses shall be corrected. Irregularities such as rippling, tearing, or pulling which in the judgment of the Engineer indicate a continuing problem in equipment, mixture, or operating technique shall not be permitted to recur. The paving operation shall be stopped until appropriate steps are t~en by the contractor to correct the problem; 4oo.07.D.: MATERIALS PRODUCED AND PLACED DURING ADJUSTh1ENT PERIOD: Delete this Sub-Section in its entirety. 400.10. PAYMENT: Delete this Sub-section in its entfrety and substitute the following: Hot mix asphaltic concrete of the various types will be paid for at the contract unit price per Ton or Square Yard which payment shall be full compensation for furnishing and placing all materials including asphalt cement, hydrated lime when required and for all approved additives, for ail cleaning and repairing or preparation of surfaces, for all other operations necessary to complete the Contract Item. c c - ZO I I I I I I I I I I I I I I I I I I I SECITON 400 Page 8 of 8 April 23, 1997 PAYMENT WILL BE MADE UNDER: ITEM NO. 400. Asphaltic Concrete (Type), (Group-Blend) including Bituminous material........Per Ton. ITEM NO. 400. mm Asphaltic Concrete (Type), (Group-Blend) including Bituminous material........Per Square Yard. ITEM NO. 400. Asphaltic Concrete Patching including Bituminous material........Per Ton. ITEM NO. 400. Asphaltic Concrete Leveling including Bituminous material.......Per Ton. Office of Materials and Research C C-Z,/ I I 1 I 1 I I 1 I I I I I' I 1 I "754P I ~ I ( 4~) , R \ C. ~ f-'l () tV b CD. C,-r'':-'' 0;:: A \,.4G-LA.~ 'fA 88 MILEPOST \. ~' ~AREA- @ @) UXA1lCiN M}F N.f5. PHINIZ'( ROi\O , ,.. '( €.1-~~€.~'-N '( JO~€.s '00'0'0 l:.'loY ~-~ TOBACCO ROAO CC-Z'l- z o . a s S fii., i 'ft:i!i", , r ' ',;. \' ..., '" o ::x: -f o t"" ~ ~ 2 ::d :<::0 .....> s~ ::::;; ..< ;;d ..... C1 <"- ;::;;:i ::J ~o :::.., :C ?< .(1 .,."" ;:;a ;It'l :z:;i ~ t-- - '-'J ~ 7G ~ ~ ~ ~ ~ ~ - \.Q ,.1 I: \' ~ C) (\J I..,j ~ ~ ~ "- ...... ~ f '71- -:ll J 0-4 ::r .. :2 5 cr ~ 01 o :J ,.. ::r .... lA ~ .... 01 n (A ::r o c: ~ a. n o 01 .., ~ en -0 o :J C. C .... n :1', ,.. :1' Q :J c: 5- Q 01 o .... n :1' ~ (ZI n .., ~ ~ ('T o :2 ('T ::r ~ 9 ~ "t:I . , " I "1 ,I :;1 ~ I. . " . s II 1': !I i " II I I I I -~ ~"'__"IR'-"""'.1;",.I,L'!!rl. . , . . . ~ NOTE: THE JjEPARTMENT OF TRANSPORTA nON'S PARTICIPA nON IN CONSTRUcrING !HIS PROJECT IS LIMITED TO THE ITEMS Sgr UP FOR PAYMENT UNDER THIS CONTRAcr. ALL WORK NOT COVERED BY THIS CONTRACT WILL BE IN ACCORDANcE WITH PLANS PREPARED BY W R TOOl E ENGlNEFRS INC FOR THE CITY OF A l1GlJ~T ~ DATED OCTOBER 21 1996, ANY llEMS OR WORK REQUIRED BY llfESE PLANS AND NOT COVERED BY THIS CONTRAcr \" BE THE RESPONSIBILITY OF THE COUNTY AT NO COST TO THE DEPARTMENT OF TRANSPORTA nON, ' .......-.-. -...... ..~ ,:.: :..:... ,.. ....,.,1 I r:#-'I. ^.. .... ~., if.~:!frt.'~i~.!~~~,..:::::,..:,~~~~ I).) 1St ~PH Co /II c:. ~ , ..., Z 00 ~fsy AsP 1\ ~ N(.. 13 or- _. ....'"... ... \.. . ... ..... . _. . :.: .. .. ........ .... .. .. '0 .. .. .. .... .. : ... .. .. ... .. .... ..:.. 't.... .. ,:... "'.. ...... " ,', '6'. GRAD'ED AGGREGATE BASE., ': ~ WI~ PA\feNfNf CROSS 5eCllON N .f.5. NOTE: The Local Government shall be responsible for placement, maintenance, and inspection of all traffic control devices, NOTE: The Local Government will certify all necessary RJW. and remove or adjust all utilities at no cost to the Department of Transportation. 1&.1 j ~ ~ S , '-NEW ASPHALT PAVING -rS /1 P /;).l (4{,':] U.S. 'rfN( #27 (S.R. 121) WIGAL CROSS 5€CllON N .f.5. & GUTTER TO BE REMOVED. c c- t-1-