HomeMy WebLinkAboutDaniel Feild Airport
DOCUMENT NAME:
DOCUMENT TYPE:
YEAR: ~19
BOX NUMBER: O'd.
FILE NUMBER: \6)QlaO
NUMBER OF PAGES: _80
Augusta Richmond GA
.1 cf..d.u# /c:<96 0 ~eU ~ ~ '.
.
CONTRACT DOCUMENTS
AND
SPECIFICATIONS
FOR
DANIEL FIELD AIRPORT
..
RUNWAY SAFETY OVERRUN AREA PA VING
.... 1996
-
"..
REFERENCE NO.: 94-060(C) ,
"
1
PREPARED BY
ENGINEERING DEPARTMENT
FOR
AUGUSTA-RICHMOND COUNTY
COMMISSION-COUNCIL
ROOM 701, MUNICIPAL BUILDING
530 GREENE STREET, AUGUSTA GA. 30911
AUGUST 1996 ~#=- "3
", ,
m:~ v AND CONF~~~SSNUc5l) RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND. EXTEND OR
ALTER THE COVERAGE AFFORDED BV THE POLICIES BELOW.
COMPANIES AFFORDING COVERAGE
DAVIS-GARVIN AGENCY, INC
POBOX 21627
COLUMBIA, SC 29221
803-732-0060
INSURED
COMPANY
A CAP IT AL CITY I NSURANCE CO
COMPANY
Beam's Pave~ent Maintenance
Co , I nc
POBox 398
Beech Island, SC 29841
I
~:P9yg:M9g!:~f:~ft H" ,,'......: 'H.H'H......... ,.. ........ '.. ":".H,:, ..":,:,:,, '. .,. ",... ""','" .. H ., ,.., "ii,,"',,<; ::::..
THISIS TOCERTIFY THA T THE POLlCtESOFINSURANCE L1STEDBELOWHAVE BEENISSuED TO THEINSURED NAMED ABOVE FOR THE POLICy PERIOD
INDICA TED,NOTWITHST ANDINGANYREOUIREMENT, TERtvlORCONDITIONOF ANYCONTRACT OROTHERDOCWENT WITHRESPECT TOWHICHTHIS
CERTIFICA TE MA Y BE ISSUED ORMA Y PERT AIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERtvlS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES LMITS SHOWNMAY HAVE BEEN REDUCED BY PAiD CLAMS
B
III Hartford
COMPANY
c
COMPANY
o
co TYPE Of INSURANCE POLICY NUMBER POLICV EffECTIVE POLICV EXPIRATION
L TR DATE (MMlDD/VV) DATE (MMIDDIVV) LIMITS
GENERAL LIABILITY GENERAL AOOREGATE $ 2000000
B X COMt.<ERCIAL GENERAL LIABILITY 22UUNBD7364 6/22/96 4/01/97 PROOUCTS,COMP/OP AGO $ 1000000
CLAIMS MADE I2Ll OCClJ'l PERSONAL B. AOV ItUJRY $ 1000000
OWNER'S B. CONIRACIOR'S PRO! EACH OCClJ'lRENCE $ 1000000
I--
FIRE DAMAGE (Any one lire) $ 100000
f--
t.<ED EXP (Any one person) $ 10000
AUTOMOBILE LIABILITV COMBINED SINGLE LIMIT $
I--
B rX ANY AIlTO 22UENBD7441 6/22/ 96 4/01/97 1000000
ALL OWNED AUTOS 800IL Y INJURY $
f-- (Per person)
SCt-t:Ol.lED AUTOS
I--
X HIRED AUTOS 800IL Y INJJlY $
I-'-'- (Per accident)
X NON.OWNED AUIOS
I-'-'-
I-- PROPERTY DAMAGE $
GARAGE LIABILITV AUTO ONl.. Y EA ACCIDENI $
- ~
ANY AUIO OTI-€R THAN AUTO ONl.. Y;
-
EACH ACCIDENT $
- AGGREGATE $
fXCESSLIABILITV EACH OCCWRENCE $ 3000000
B ~ UMBRELLA FORM 22XHUBE0853 6/22/96 4/01/97 AGGREGATE $ 3000000
OlltR THAN UMBRELLA FORM $
WORKERS COMPENSATION AND X I STATUTORY LIMITS ;;':>
EMPLOYERS'LIABILITV
A WC03680 6/22/96 4/01/97 EACH ACCIDENT $ 500000
II-E PROPRIETORI R'NCl DISEASE POliCY LIMIT $ 500000
PARTNERS/EXECUTIVE
OFFICERS ARE EXCL DISEASE EACH EtJPLOYEE $ 500000
OTHER
DESCRIPTION Of OPERATIONSILOCATIONS VEHICLESISPECIAL ITEMS
Project No 94-060(C) Daniel Field Airport, Runway Safety Overrun Area Paving
\PERlIFIPATI:'l:Ioi;;PER.,;(,
./,;';\:
..qANc:Ep:;ATlON.> ,..',;; ,':>:; ,.><. .;",;.. ;.. '.,....'
SHOULD ANY Of rHE ABOVE DESCRIBED POLICIES BE CANCELLED BEfORE THE
EXPIRATION DATE THEREOf. rHE ISSUING COMPANY WILL ENDEAVOR TO MAIL
30 DAYS WRITTEN NOTICE TO THE CERTifiCATE HOLDER NAMED TO THE LEfT.
Augusta Richmond County
Counc i I Commi 55 ion
Room 701 Municipal Bldg
530 Greene Street
.. ,.,"~.II 9 ,II~, ,ta,..G e, () r. ,9, ,i" <I.. ,3..0 ,9. .1..1.
iA9P8q'~Mn!l.~~):::: ::..: ',,;:"':": '" ".. "H.'
.......................
................... .
.... ............
BUT fAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY
Of ANV KIND UPON THE COMP~NV, ITSA AGENTS OR REPRESENTATIVES.
AUTHO~DREP~ENTATlVE A/ _/7 ~ 500122000
V2,.JffA~~./ H. ~~ A h.J
f~::::rW0:':\::)):'{;:::::::8:j:'::]::;~A9gRq:gARe9Mt@Kt~~~::
PUBLIC WORKS AND ENGINEERING
ROOM 701
530 GREENE STREET
AUGUSTA, GEORGIA 30911
(706) 821-1706 FAX (706) 821-1838
CHARLES DILLARD
Commissioner of Public Works and
Director of Engineering
November 26, 1996
Mr. Greg Beam, vice President
Beam Pavement Maintenance Co., Inc.
Post Office Box 398
Beech Island, SC 29842
Re: Daniel Field Airport Runway Safety
Overrun Area Paving, 1996
Project Reference: 94-060(C)
Dear Mr. Beam:
Please accept this as your "Notice To Proceed" with the
construction of the above referenced project in accordance with the
specifications prepared by the Engineering Department dated August,
1996. You are to begin work on or before December 3, 1996 and
fully complete the proj ect on or before February 5, 1997 (60
calendar days) .
We are enclosing herewith two (2) copies of the executed contract
documents. Please forward one (1) to your surety.
Cliff d A. Goins
Assistant Commissioner of Public Works and
Director of Engineering
CAG/jss
Enclosure
cc: Mrs. Lena Bonner, Clerk of Commission-Council, w/copy of
Contract Document
Mr. Stewart Walker, License & Inspection Department
Mr. Charles T. Dillard, Interim Administrator - Operations
""'
.
-
- INDEX TO SPECIFICATIONS
Section Pages
ADV Advertisement for Bids 1 - 2
IFB Information for Bidders 1 - 3
P Proposal 1 - 3
BB Bid Bond 1 - 2
A Agreement 1 - 2
PB Performance Bond 1 - 2
PB Labor & Materials Payment Bond 3 - 5
GC General Conditions 1 - 23
SGC Supplemental General Conditions 0 - 5
SC Special Conditions 0 - 3
TECHNICAL SPECIFICATIONS
SW Scope of Work 1
GN General Notes 1 - 2
SP Soil Sterilization-Airport Construction 1 - 4
SP Hot Mix Asphaltic Concrete Mixtures 1 - 2
SP Hot Mix Recyclied Asphaltic Concrete 1
SP Bituminous Surface Treatment 1 - 2
SP Painting Traffic Stripe 1 - 4
.
.
ADVERTISEMENT FOR BIDS
.
SEALED BIDS for furnishing all materials, tools,
machinery, etc. necessary for the Daniel Field Airport Runway
Safety Overrun Area Pavinq , Reference 94-060(C) by
AUGUSTA-RICHMOND COUNTY COMMISSION-COUNCIL
.
hereinafter referred to as the OWNER, at the office of the Clerk of
Commission-Council, Room 806, Municipal Building until 12 noon on
the ~h day of October, 1996, at which time all bids will be
publicly opened and read in the presence of those interested.
All work shall be in accordance with the contract
documents of the City Engineer and Commissioner of Public Works,
hereinafter referred to as the Engineer.
Copies of the Contract Documents may be examined during
regular business hours at the office of the City Engineer, 7th
Floor, Municipal Building, Augusta, Georgia; and at the following
locations:
.
-
-
The F. W. Dodge Division Plan Room
Augusta, Georgia
C.S.R.A. Business League
Augusta, Georgia
Copies may be obtained for bidding purposes at the office
of the City Engineer upon payment Twenty-Five ($25.00) Dollars for
each set of documents issued, (Non-refundable).
Bids shall be addressed to Augusta-Richmond County
Commission-Council, c/o Clerk of Council, Municipal Building,
Augusta, Georgia 30911, marking the envelope Daniel Field Airport
Runway Pavinq Pro;ect.
Bids shall be completed and submitted as described in the
Information for Bidders section of the Contract Documents.
-
A Bid Guarantee, Performance Bond, and a Labor and
Material Payment Bond will be required.
No bid may be withdrawn for a period of sixty (60) days
after the date and time set for the receipt of bids.
All bidders will be required to attend a Pre-Bid
Conference which will be held at the office of the City Engineer at
10:00 A.M. on October 3, 1996
ADY-l
.
.
The Owner reserves the right to waive any informalities
in bidding and to reject any or all bids.
.
-
-
Lena J. Bonner
Clerk of Commission-Council
806 Municipal Bldg.
Augusta, GA 30911
-
Advertised in Augusta Chronicle September 19. 20 & 23
1996.
ADY -2
.
INFORMATION FOR BIDDERS
.
Bids will be received by Augusta-Richmond County
Commission-Council, Georgia, (hereinafter called the "Owner"), at
the office of the Clerk of Commission-Council until 12 Noon on
and then at said office publicly opened ana
read aloud.
.
Each bid must be submitted in a sealed envelope,
addressed to Mayor and Augusta-Richmond County Commission-Council
at City-County Municipal Building, Augusta, Georgia 30911. Each
sealed envelope containing a bid must be plainly marked on the
outside as bid for Daniel Field Airport Runway safeth Overrun Area
Paving and the envelope should bear on the outside t e name of the
bidder, his address and his license number, if applicable. If
forwarded by mail, the sealed envelope containing the bid must be
enclosed in another envelope addressed to the Mayor and Augusta-
Richmond County Commission-Council, c/o Clerk of Commission-
Council, City-County Municipal Building, Augusta, Georgia 30911.
All bids must be made on the required bid form. All
blank spaces for bid prices must be filled in, in ink or
typewritten, and the bid form must be fully completed and executed
when submitted. Only one copy of the bid form is required.
-
-
The Owner may waive any informalities or minor defects or
reject any and all bids. Any bid may be withdrawn prior to the
above scheduled time for the opening of bids or authorized
postponement thereof. Any bid received after the time and date
specified shall not be considered. No bidder may withdraw a bid
within sixty (60) days after the actual date of the opening
thereof. Should there be reasons why the Contract cannot be
awarded within the specified period, the time may be extended by
mutual agreement between the Owner and the bidder.
Bidders must satisfy themselves of the accuracy of the
estimated quantities in the Bid Schedule by examination of the site
and a review of the drawings and specifications including addenda.
After bids have been submitted, the bidder shall not assert that
there was a misunderstanding concerning the quantities of work or
of the nature of the work to be done.
The Contract Documents contain provisions required for
the construction of the project. Information obtained from an
officer, agent, or employee of the Owner or any other person shall
not affect the risks or obligations assumed by the Contractor or
relieve him from fulfilling any of the conditions of the Contract.
Each bid must be accompanied by a bid bond payable to the
Owner for five percent of the total amount of the bid. As soon as
the bid prices have been compared, the Owner will return the bonds
of all except the three lowest responsible bidders. When the
Agreement is executed the bonds of the remaining unsuccessful
bidders will be returned. The bid bond of the successful bidder
will be retained until the payment and performance bond have been
executed and approved, . after which it will be returned. A
certified check may be used in lieu of a bid bond.
IFB-l
.
.
A performance bond and a payment bond, each in the amount
of 100 percent of the contract price, with a corporate surety
approved by the Owner, will be required for the faithful
performance of the Contract.
Attorneys-in-fact who sign bid bonds or payment bonds and
performance bonds must file with each bond a certified and
effective dated copy of their power of attorney.
The party to whom the contract is awarded will be
required to execute the Agreement and obtain the performance bond
and payment bond within ten calendar days from the date when notice
of award is delivered to the bidder. The notice of award shall be
accompanied by the necessary Agreement and bond forms. In case of
failure of the bidder to execute the Agreement, the Owner may at
his option, consider the bidder in default, in which case, the bid
bond accompanying the proposal shall become the property of the
Owner.
.
-
-
The Owner wi thin ten days of receipt of acceptable
performance bond, payment bond and Agreement signed by the party to
whom the Agreement was awarded, shall sign the Agreement and return
to such party an executed duplicate of the Agreement. Should the
Owner not execute the Agreement within such period, the bidder may,
by written notice, withdraw his signed Agreement. Such notice of
withdrawal shall be effective upon receipt of the notice by the
Owner.
The notice to proceed shall be issued within ten days of
the execution of the Agreement by the Owner. Should there be
reasons why the notice to proceed cannot be issued within such
period, the time may be extended by mutual agreement between t~e
Owner and the Contractor. If the notice to proceed has not been
issued wi thin the ten day period or wi thin the period mutually
agreed upon, the Contractor may terminate the Agreement without
further liability on the part of either party.
The . Owner may make such investigations as he deems
necessary to determine the ability of the bidder to perform the
work and the bidder shall furnish to the Owner all such information
and data for this purpose as the Owner may request. The Owner
reserves the right to reject any bid if the evidence submitted by
or investigation of such bidder fails to satisfy the Owner that
such bidder is properly qualified to carry out the obligations of
the Agreement and complete the work contemplated therein.
A conditional or qualified bid will not be accepted.
Award will be made as a whole to one bidder.
All applicable laws, ordinances and rules and regulations
of all authorities having jurisdiction over the construction of the
project shall apply to the contract throughout.
Each bidder is responsible for inspecting the site and
for reading and being thoroughly familiar with the Contract
Documents. The failure or omission of any bidder to do any of the
IFB-2
.
.
foregoing shall in no way relieve any bidder from any obligation in
respect to his bid.
The low bidder must supply the names and addresses of
major material suppliers and subcontractors when requested to do so
by the Owner.
Inspection trips for prospective bidders will be
conducted by the Owner if requested in writing by the bidder. Such
request shall be directed to the City Engineer by the bidder.
The bidder agrees. to abide by the requirements under
Executive Order No. ll246, as amended, including specifically the
provisions of the Equal Opportunity clause set forth in the
Supplemental General Conditions.
The engineer is the City Engineer.
All bidders are encouraged to utilize, to the maximum
extent possible, local labor forces and suppliers of materials
which have residences, offices or places of business within
Augusta-Richmond County, Georgia. While Augusta-Richmond County
encourages the utilization of local laborers and supplies on a
purely voluntary basis on local public works projects, nothing
contained herein shall impose any legal or contractual obligation
for any bidder to do so.
.
..
-
-
ff~
.
.
.
PROPOSAL
FOR
DANIEL FIELD AIRPORT
RUNWAY SAFETY OVERRUN AREA PAVING
PROJECT REFERENCE 94-060(C)
.
Augusta-Richmond County Commission-Council
Municipal Building
Augusta, Georgia 30911
Gentlemen:
..
-
The undersigned as bidder, herein referred to as
singular and masculine, declares as follows:
l. The only parties interested in the proposal as principals
are named herein;
.-
--
2. He has carefully examined and fully understands the Contract
Documents, including the drawings and technical
specifications;
3. He understands that information relative to existing
structures and underground utilities as furnished to him on
the drawings, Contract Documents or by the City Engineer,
carries no guarantee expressed or implied as to its
completeness or accuracy and he has made due allowances
therefor;
-
4. He has made a personal examination of the site of the proposed
work and has satisfied himself as to the actual conditions and
requirements of the work;
and hereby proposes and agrees that, if the Proposal is accepted,
he will contract with Augusta-Richmond County to furnish all
machinery, tools, apparatus and other means of construction and to
do all work and furnish all materials called for in accordance with
the requirements of the City Engineer and the true intent of the
Contract Documents and that he will take in payment for each item
of work, thereof, the unit or lump sum price applicable to that
item as stated in the schedule below.
(Note: Bidders must bid on each item.)
P-I
.
SCHEDULE OF PRICES
. Contr. Estimated Unit Total
Docu.# Item# Quantities Description Price Price
1- 725 Lump Sum Soil Sterili-
zation and :(v ~;Ttf23 ;2, ~7-/f,!Ls
Cleaning
. 2 . 424 3,556 Sy Single Surface
Treatment
Stone Size #7 I, 7~ t) ;)...1 ~, <J j)
Group 1 or 2
3. 413 200 Gal. Bituminous /9~ ;2 6 0 , 0--,)
- Tack Coat
4 . 402 320 Tons Hot Mix Recycled
Asphaltic Concrete
"F" Group l'or 2
Includes Bi tumi~ q II">> 1:2 4"! d. <fl)
ous Materials '
- r'
5. 652 Lump Sum Runway & Taxi-
way Painting
& Marking, Type 'f1r-D.tE">> 1./ I)J . ..rD
2, Class B / ,J
TOTAL $ ;< 6-; !7~/' :23.
The Contract covering the construction of all work described above
will be completed within 60 calendar days from the date specified
in the "Notice to Proceed"Of the City Engineer for:
~ .. ~~~~
.~ Dollars ($ ,;(S'1?)"'7. Q:3 )
su Je to re uct1ons, a 1t1ons an deletions provided herein on
the basis of measured quantities of completed work and the prices
bid. Bidder further agrees to pay as liquidated damages the sum of
$ 300.00 for each consecutive calendar day thereafter as
hereinafter provided in Section 15 of the General Conditions.
It is understood that the Owner reserves the right to reject any or
all proposals or to accept any proposal as deemed to be to the best
interest of the Owner.
It is also understood that the following addenda as issued during
the bid period shall be included as part of the Contract Documents:
Addendum
Date
7Lr> .. -
P-2
'~
.
-
-
The undersigned bidder understands and agrees that should the Owner
accept this proposal, the bidder will within ten (10) days from the
date of notification of acceptance of his proposal, execute the
contract and furnish the Owner satisfactory performance and payment
bonds in the amount equal to one hundred percent (100%) of the
total base bid sum. Enclosed herewith is a Bid Bond or a Certified
Check in the a~ ~ ~ r _
~~ _ ~,-F--~~~~r.J<< _"J~
Dollars ($ / ~ ).. I 7' 31 ) being not less than 5 (5%) percent
of the total base bid sum.
.-
...
.-
Should the bidder fail to execute the Contract and furnish the
Performance and Payment Bonds in case this proposal is accepted,
the Owner shall have the right to receive the amount of the bid
security as liquidated damages. If the security is a Certified
Check, it may be cashed by the Owner and the amount received shall
become the property of the Owner. If the security is a Bid Bond,
the value thereof shall be paid to the Owner by the Surety.
The undersigned by submittal of this proposal, agrees that the
above stated amount is proper measure of liquidated damages which
the Owner will sustain by the failure of the undersigned to execute
the Contract and furnish the Performance and Payment Bonds.
The successful bidder shall have a current Business License.
The Owner is an Equal Opportunity Employer.
~~69~~~, _._
,40- t/.~
/ i~nature & Title of
Authorized Representative
~-~
,
1?, J,/'SJ{t 31 ~
Business
~UJ
City atid
.233~~d.
Address
5c.. 2- ~ f-f:::u
State
Date: el~ 1J /<1t;; Co
.
;/).~Y
~ :_:'.';. __. ~.~~7~ 6-
...-...-.- -------
p- 3
SBCTION BB
BID BOND
KNOW ALL MEN BY THESE PRESENTS, that we, the undersigned,
Beam's Pavement Maintenance Company, Inc.
as Principal, and
Reliance Insurance Company
aeSurety,arehereby
held and firmly bound unto Augusta-Richmond County COmmission-
Council, Georgia, as Owner in the penal sum of Ten Percent 00%) of Total Amount
of Principals Bid
for the payment of which, well and truly to-, be
made, we hereby jointly and severally bind ourselves, our heirs,
executors, administrators, successors and assigns.
Signed, this
9th
, 1996.
day of
October
The condition of the above obligation is such that
whereas the Principal has submitted to Augusta-Richmond County
Commission-Council, Georgia a certain Bid, attached hereto and
hereby made a part hereof to enter into a contract in writing for
Daniel Field Airport Runway Safety Overrun Area Pavinq
NOW, THEREFORE,
(a) If said Bid shall be rejected, or in the alternate,
(b) If said Bid shall be accepted and the Principal shall
execute and deliver a contract in the Form of Contr~ct
attached hereto (properly completed in accordance with
said Bid) and shall furnish a l;)ond for his faithful
performance of said contract, and for the payment of all
persons performing labor or furnishing materials in
connection therewith, and shall in all other respects
p~rform the agreement created by the acceptance of said
Bid,
BB.l
perform the aqreemant ~r8atBd by the a~ceptanc. of said
Bid,
then this o:Cligation shall De void, o't.herwise the same
~hc.~l remain in force and af~ect; it being expressly tU1Qers't.ood and
Agreed -:.hat the liability of the Surety fo= any and all cla..imS
hereunder shall, in no event, exceed t.he pena.l amount of this
o:Cliqation as herein stated.
'!'he sure~y, for vAlue received, here!:)y stipu12ltes and
-.
Agrees thet the obligations of sAid Sura1:Y and its Bond shall be in
no way impaired or affected by l1ny e~ension of the time w-i thin
which the Owner may accept such Bid; and said Surety does hereby
waive notice of any such extension.
IN w=~ss ~O?, the Principal and the surety have
hereunto :set 'Chese hands and seals, and ,such ot them as a:e
corporations have caused thei.r corporate seals to ~e hereto affixed
and these presen~ to De signed by the~r proper officers, the day
and year f ir51: sat f ort.h above.
Beam's
Company, Inc.
By:
L.S.
Reliance Insurance Company
(Sc.:e-:y)
~Q lli \\, r QAI<..
De a B. Case ATTORNEY IN FACT
By
st1\L
BB- 2
.
~LUNCE~TYCOMPANY
UNITED P Acmc INSURANCE COMPANY
RELlA.J"ICE INSURANCE COMPANY
RELIANCE NATIONAL INDEM1'-rITY COMPANY
ADMINISTRATIVE OFFICE. PHILADELPHIA. PENNSYLVANIA
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS. that RELIANCE SURETY COMPANY is a corporation duly organized under the laws of the State of Del-
awere. and that RELIANCE INSURANCE COMPANY and UNITED PACIFIC INSURANCE COMPANY. are corporations duly organized under the laws
of the Commonwealth of Pennsylvania and that RELIANC: NATIONAL INDEMNITY COMPANY is a corcoratlon duly organIzed undar tne laws of
the State of Wisconsin (herein collectively call ad "the Companies") and that [he Companies by virtue of signature and seals do hereby malee.
constitute and appoint Frank W. Hafner. Jr.. David J. Wells. Jr.. Jana McCoy. Carolyn D. Owans. A.T. Johnson. Darelle E. BiQby. Roben J.
Lavisky. DaUa B. Casa. W. Scon Hull.. ot Columbia. South Carolina the,r tNe and lawful Attorneylsl.in.Fact. to make. execute. seal and deliver
for and on the.. behalf. and as their act and deed any and all bonds and undenakings ot suretyship and to bind the Comoanles thereby es fully and
to tne same extent as if such bonds and undanakings and otrler writings obligatory in the nature thereof were signad by an Executive Officer of
the Companies and sealed end attested by one othar of such oHicars. and haraby ratifies and confirms all that their said Attorney(sHn-;:act mey
do in pursuance hereof.
This Power of Attorney is granted under end by the authority of Article VII ot the Bv-Laws of RELlANC: SURETY COMPANY.
RELIANCE INSURANCE COMPANY. UNITED PACIFIC INSURANCE COMPANY. end RELIANCE NATIONAL INDEMNITY COMPANY which
provisions are now in full force and effect. reading as follows:
ARTICLE V11. EXECVT10N OF aONOs AND UNCERTMINGS
1. The Bo.-a of Oi.rectO"., u-. PT-oent. the Cn.rm... 01 tr. 80.,12, any s.-.ot VIe:.- PT.....a.ent. "'v V.r;.e PT...o.nt ot AaI.,.". Vice PT...aent Of "..,., OftIC.' dOStQnat.::i bY t""- BO"d of
OIlK101"l II\IIU, n.a.. 00"''' .rid IUtnotlry to taj aoOOlnt AnOt"...,.~~flC'l"" to eutnonze t1W'n to ox.cuta on tJet\eif of,,... Comgenv. Done. IIf"'IQ U"Oert&ll..ll'lO'. lOCOQI'\IZances. contraca ot I~,..rv
end ou.., ...,,"unO. 00h081ory an U. ~h". t,.,.ol, and lbt to 'en"lO'l;'e ."., -...en Ano"....,(.~fKt at .,.., tun. at"d '..0&. I'" 00"'_ ana M,JU'Of'U., QI'l;'en to u..m. -'
2. Anor"'.I'I~.....fect anau nave 00"''' and M.IlI\otlt." .uo,.ct 10 U.. l.,m. ."., hnuUh~ 0' U''4 ;:ao...... 01 Anew".. l....a to l,..m. to ...cut. det.",... on 0.""-,, 0' U.. COt'l"IoatW. bo"."
at'IIS U"'CIetl..uno-. 'ecOQnlZ"'-':", conneCta 0' Inde1T'u'''IY ..., ot,.., .....nttnQl. oOltQatotv In ,t'le nalure n'..nol. Tn. cotDOtaCe .... .. not ,.,.c....,., 10' tn. lI.abGlt. 0' an., oona. M"O \6"lQeftMtOQ..
t.cOQI'lllW\Ca. c:.onuacu 0' tnaemt'IIlV end oCnet wlltll"lQ. OCIlNO_IOlY lI\ u" Ntute 1I''''.0f. .
J. Anor",.,I.~F~ "'611 ",."'. POW'" ....., ...Ilnollty to execute a"lda"ft. 'OQu,od to CIe attaC1"leCl to bonal. '.COO"lII.nca. ContrKtI 0' Inclemnl., Of otnet ConGltlon" Of oOttOalot.,
Ul"IiCM:It......-.oa .,.. tN. ~ ....0 na",. 1)0....., and MAnontV' to cand., the hnanc;J" .tat""""" of tn. Como....". II"lCJ to COOMa 0' tne 8-rt..a.... ot tne Comoanv 01 an., WUCIO 01 Malon tl'WIIOt.
The Po...... 0' 4n0l"fW" te ~ W"ld ..-...d by 'aQ.Imlloe ...,.,. wid by aAl'\only ot U.. fo4lo...~ t.ohJtlon edODt.d by tn. e...cutl..... end FIt\.W'lCe Commm... 0' u.. Gawel. 0' Olf.clon ot A....nc.
t......-.c:tI Como..-rt, Unled Paahc t,...ance Como."., and Reaanc. H.UOt\otII II"Idemt'lCY Como.,., by V".,..mo.A Cor.enl deled _ 0' Fooruwy 28. 1 gg... Iif"d by 1'" U.cutIV. Il"d Fu",.no.
Commltt.. of ..". 80_0 of OM'ectOt""e 0' R.ehWtCe S\Aocy Comp.,..-y by Unwwnou. COfWeI'Tt deted es of Mwcn J 1, 19ft....
.~ mat IN IIQ'NtU'_ 0' RICh dlfec:ton and ottIC.. and t'" ..aI of .,... Como.,.,., m.y be .'fi.ed to "''W tud1 Pow... 0' Anon..y a. ....., cwt,hc:atn '''.tll''lO thef.IO Oy
f~end ..,.., IUCI'I Pow., of AnOlt"lllY 01 c:ettlflcal. tlllIat'1I'IO eucn f~ "OnacU'.. at f8CSU"l'l114 .... 11\..1 l>e ""-'ICS and btna1no uoon tn. Comoany and env auc:n Po.... 10
...cuted .....0 cwafi.ed by 'acaanvJ.e l;IQn.etU'_ ...., 'acsunll.e .... aI\6lJ be vlIhd end bt.nd,ng UQOn tro. Comoanv. tn trw tutut. WIt" re::aoeC1 ta ."y OOl"d 01 ",.-..aeflM.u"'O to wr.c:n It t.
anacr.s. .
IN WITNESS WHEREOF. the Companies have causad thase presents to be signed and thair corporate saals to be herato affixad. this Feb,uary 21.
1995.
ST A TE OF Pennsylvania
COUNTY OF Philadelphi8
}
} S5.
RELIANCE SURETY COMPANY
RELlANCE INSURANCE COMPANY
UNITED PAClFlC INSURANCE COMPANY
azzTI~:-ANY
On this. Febru8ry 21. 1995. before me. Temmy Sue Kayat;. personally appaared Charles B. Schmalz. who acknowledged himself to be the
executive Vice President of the Reliance Suraty Compenv. and the Vice President of Reliance Insurance Company. United Pacific Insurance
Company. and Reliance National Indemnity Company and that as such. being authorized to do so. executed tha foregoing instNmant for the
purpose therein contained by signing tha name of the corporation by himself as its duly authorized officer.
In witness whereof, I heraunto set my hand and official saal.
NOTARIAL SEAL
TAMMY SUE KAYAn. Notary Public
Ciry ot P;,ilade'on'iJ. Phi~. Counly
Mv Cc",,::-',,=,~., ':.:'l:.'~'" .V" -:>0. 1C??8
~nUYltL;' ~tL k{uAl.t~
Notary Public in ahd for the S tate of PeA),sylvania
Residing at PhiladelPhia
I. Anita Zippen. Sacretary of RELIANCE SURETY COMPANY. RELIANCE INSURANCE COMPANY. UNITED PACIFIC INSURANCE COMPANY. end
RELIANCE NATIONAL INDEMNITY COMPANY do hareby cenify that the above and foregoing is a trua and correct copy of the Power of Attorney
executad by said Companies, which is still in full force and effect.
IN WITNESS WHEREOF, I h... h,,~"'O '" my h,", '"' ,m.., <h, .",. of .." Com,,",.. Ihl. ~~ 19 ~
Secretary
.
SECTION BB
BID BOND
.-
-
KNOW ALL MEN BY THESE PRESENTS, that we, the undersigned,
as Principal, and
.
as Surety, are hereby
held and firmly bound unto Augusta-Richmond County Commission-
Council, Georgia, as Owner in the penal sum of
for the payment of which, well and truly to be
-
made, we hereby jointly and severally bind ourselves, our heirs,
executors, administrators, successors and assigns.
-
Signed, this
day of
, 1996.
The condition of the above obligation is such that
whereas the Principal has submitted to Augusta-Richmond County
Commission-Council, Georgia a certain Bid, attached hereto and
hereby made a part hereof to enter into a contract in writing for
Daniel Field Airport Runway Safety Overrun Area Paving
NOW, THEREFORE,
(a) If said Bid shall be rejected, or in the alternate,
(b) If said Bid shall be accepted and the Principal shall
execute and deliver a contract in the Form of Contract
attached hereto (properly completed in accordance with
said Bid) and shall furnish a bond for his faithful
performance of said contract, and for the payment of all
persons performing labor or furnishing materials in
connection therewith, and shall in all other respects
perform the agreement created by the acceptance of said
Bid,
BB-l
.
perform the agreement created by the acceptance of said
.-
-
Bid,
then this obligation shall be void, otherwise the same
.
shall remain in force and effect; it being expressly understood and
agreed that the liability of the Surety for any and all claims
hereunder shall, in no event, exceed the penal amount of this
obligation as herein stated.
.-
-
The Surety, for value received, hereby stipulates and
agrees that the obligations of said Surety and its Bond shall be in
no way impaired or affected by any extension of the time within
-
.....
which the Owner may accept such Bid; and said Surety does hereby
waive notice of any such extension.
IN WITNESS WHEREOF, the Principal and the Surety have
-
hereunto set these hands and seals, and ,such of them as are
corporations have caused their corporate seals to be hereto affixed
and these presents to be signed by their proper officers, the day
and year first set forth above.
L. S.
(Principal)
(Surety)
By
ATTORNEY IN FACT
SEAL
BB- 2
.
SECTION A
AGREEMENT
-
...
THIS AGREEMENT, made this Z,Z---day of IJC\/.
, 1996,
by and between the Augusta-Richmond County Commission-Council as
.
Successors by Consolidation to the City Council of Augusta,
~'6 iJ~
hereinafter called "Owner" and1Y)~ GO ',) ~ . d 0 i n g
business as a corporation hereinafter called "Contractor."
WITNESSETH: That for and in consideration of the
-
payments and agreements as hereinafter mentioned:
1. The Contractor will commence and complete construction of
Daniel Field Airport Runway Safety Overrun Area Pavinq
-
2.
The Contractor will furnish all material, supplies, tools,
equipment, labor and other services necessary for the
construction and completion of the project described herein.
3. The Contractor will commence the work required by the Contract
Documents within Ten (lO) calendar days after the date of the
Notice to Procee~nd-Will complete same'within 60
calendar days unless the period of completion is extended
otherwise by the Contract Documents.
4. The Contractor agrees to perform all
Contract Documents for the sum of $
~~ . ,.-...1
5. The term "Contract Documents" means and includes the
following:
Advertisement for Bids
Information for Bidders
Proposal
Bid Bond
Notice of Award
Agreement
Performance/Payment Bond
Certificate of Owner's Attorney
Notice to Proceed
Change Order
General Conditions
Supplemental General Conditions
Special Conditions
Technical Specifications
Drawings
A-I
.
.
Addenda: No.
No.
No.
, dated
, dated
, dated
, 19
, 19
, 19
6.
The Owner will pay to the Contractor in the manner and at such
times as set forth in the General Conditions such amounts as
required by the Contract Documents.
.
7. This Agreement shall be binding upon all parties hereto and
their respective heirs, executors, administrators, successors
and assigns.
.
IN WITNESS WHEREOF, the parties hereto have executed or
caused to be executed by their duly authorized officials, this
Agreement in 5 (number of copies) each of which shall be
deemed an original on the date first above written.
-
-
COMMISSION-COUNCIL
(SEAL)
.-.
CONTRACTOR:
Name ~ R.. Q..~ ~.e.o fY'.-
( ype or Print)
Title \lIce ~R.Q5'ldltV\--t-
/~
Name
Rn 'olR.J S
(Type
S~c.tL~~
6 Q.. U Le...
or Print)
A-2
-
-
SECTION PB
PERFORMANCE BOND
-
(NOTE:
THIS BOND IS ISSUED SIMULTANEOUSLY WITH PAYMENT BOND ON
PAGE PB-3, IN FAVOR OF THE OWNER CONDITIONED FOR THE
PAYMENT OF LABOR AND MATERIAL.)
KNOW ALL MEN BY THESE PRESENTS:
That
~s Principal, hereinafter called Contractor, and
-.
.'
a
corporation
organized and existing under the laws of the State of
, with its principal office in the City of
, State of
, as
Surety, hereinafter called Surety, are held and firmly bound unto
Augusta-Richmond County Commission-Council, Georgia, as Obligee,
hereinafter called the OWner, in the penal amount of
Dollars ($
) f.:)r the payment whereof Contractor and Surety bind
themselves, their heirs, executors, administrators, successors,
and assigns, jointly and severally, firmly by these presents for
the faithful performance of a certain written agreement.
WHEREAS, Contractor has by said written agreement dated
entered into a contract with
OWner for the construction of Daniel Field Airport Runway Safety
Overrun Area Paving, Augusta, Georgia, in accordance with the
drawings and specifications issued by Augusta-Richmond County
Engineering Department which contract is by reference made a part
hereof, and is hereinafter referred to as the CONTRACT.
NOW, THEREFORE, the condition of this obligation is
such that, if Contractor shall promptly and faithfully perform
said CONTRACT, then this obligation shall be null and void;
otherwise it shall remain in full force and effect.
The Surety hereby waives notice of any alteration or
extension of time made by the OWner.
PB-l
(l) Complete the CONTRACT in accordance with its terms and
conditions, or
-
-
(2) Obtain a bid or bids for completing the Contract in
accordance with its terms and conditions, and upon
determination by Surety of the lowest responsible bidder,
or, if the OWner elects, upon determination by the Owner
and the Surety jointly of the lowest responsible bidder,
arrange for a contract between such bidder and OWner, and
make available as Work progresses (even though there
should be a default or a succession of defaults under the
contract or contracts of completion arranged under this
paragraph) sufficient funds to pay the cost of completion
less the balance of the contract price; but not
exceeding, including other costs and damages for which
the Surety may be liable hereunder, the amount set forth
in the first paragraph hereof. The term "balance of the
contract price," as used in this paragraph, shall mean
the total amount payable by Owner to Contractor under the
Contract and any amendments thereto, less the amount
properly paid by Owner to Contractor.
-
Any suit under this bond must be instituted before the
expiration of two (2) years from the date on which final payment
under the CONTRACT falls due.
No right of action shall accrue on this bond to or for
the use of any person or corporation other than the Owner named
herein or the heirs, executors, administrators or successors of the
OWner.
Signed and sealed this
day of
A.D.1996.
(Seal)
(Contractor)
Witness
By
(Seal)
(Title)
(Seal)
(Surety)
(Seal)
(Title)
By
Attest
Witness
Attest
Note:
Date of Bond must be prior to date of Contract. If
Contractor is Partnership, all partners should execute
Bond.
PB-2
SECTION PB
PERFORMANCE BOND
(NOTE:
THIS BOND IS ISSUED SIMULTANEOUSLY WITH :PAYMENT BOND ON
PAGE PB-3, IN FAVOR OF THE OWNER CONDITIONED FOR THE
PAYMENT OF L1-.BOR .AND MATERIAL.)
KNOW ALL MEN BY THESE' PRESENTS:
That Beam I s Pavement Maintenance Company, Inc.
3.S Principal, hereinafter called Contractor, and Reliance Insurance
Company
a
corporation
organized and existing under the laws of the State of Pennsylvania
, with its principal office in the City of
Philadelphia
, State of Pennsylvania
, as
Surety, hereinafter called Surety, are held and firmly bound unto
Augusta-Richmond County Commission-Council, Georgia, as Obligee,
hereinafter called the OWner, in the penal amount of Twenty. Five
Thousand Five Hundred Seven & 23/100--------------------------- Dollars ($_
25.507.23-----) f::>r the payment whereof Contractor and Surety bind
themselves, their heirs, executors, administrators, successors,
and assigns, jointly and severally, firmly by these presents for
the faithful performance of a certain written agreement.
1,/' / jWHEREAS, Contractor has by said written agreement dated
u/~Z19~ entered into a contract with
OWner far the construction of Daniel Field Airport Runway Safety
Overrun Area Paving, Augusta, Georgia, in accordance with the
drawings and specifications issued by Augusta-Richmond County
Engineering Department which contract is by reference made a part
hereof, and is hereinafter referred to as the CONTRACT.
NOW, THEREFORE, the condition of this obligation is
such that, .if Contractor shall promptly and faithfully perform
said CONTRACT, then this obligation shall be null and void;
otherwise it shall remain in full force and effect.
The Surety hereby waives notice of any alteration or
extension of time made by the OWner.
PB-l
,
7
(1) Complete the CONTRACT in accordance with its terms and
conditions, or
(2) Obtain a bid or bids for completing the Contract in
accordance with its terms and conditions, and upon
determination by Surety of the lowest responsible bidder,
or, if the Owner elects, upon determination by the OWner
and the Surety jointly of the lowest re5ponsible bidder,
arrange for a contract between such bidder and Owner, and
make available as Work progresses (even though there
should be a default or a succession of defaults under the
contract or contracts of completion arranged under this
paragraph) sufficient funds to pay the cost of completion
less the balance of the contract price; but not
exceeding, including other costs and damages for which
the Surety may be liable hereunder, the amount set forth
in the first paragraph hereof. The term "balance of the
contract price," as used in this paragraph, shall mean
the total amount payable by Owner to Contractor under the
Contract and any amendments thereto, less the amount
properly paid by Owner to Contractor.
....y
.~.
\.".
..;.,'
...'
..~
:~
'Cl:,
.....
.>1'
,'''':
1.
Any suit under this bond must be instituted before the
expiration of two (2) years from the date on which final payment
u~der the. CONTRACT falls due.
~
No right of action shall accrue on this bond to or for
the use of any person or corporation other than the Owner named
herein or the heirs, executors, administrators or successors of the
OWner.
Re liance Insurance Company ( Seal)
It (Surety)
By QtUa M, l CLJQ (Seal)
Della B. Case (Title)
Attorney-in-Fact
must be prior to date of Contract. If
Partnership, all partners should execute
.:
r
~
0.-Jm 55
A-tLtfS't
Hitness Ai -.L.
Kt~ Oj~ .
Note:
Date of Bond
Contractor is
Bond.
z,z. day of
IJbV.
,
Beam's Pavement Maintenance cor~~~r)Inc.
(Contractor)
By tr t--
f/ '
-,J -I
(Seal)
(Title)
PB-2
B.
It
~.~
~
~
;}
(NOTE:
SECTION PE
"LABOR AND MATERIAL P.AYMENT BOND
THIS BOND IS ISSUED SIMULTANEOUSLY WITH PERFORMANCE
BOND ON PAGE PE-l, IN FAVOR OF THE OWNER CONDITIONED
FOR THE PERFORMANCE OF THE CONTRACT.)
KNOW ALL MEN BY THESE PRESENTS:
u
"
-
"~:
.~.
-:-.
~,
<
..
.\1
That Beam's Pavement Maintenance Company, Inc.
,
~z.
as Principal, hereinafter called Contractor, and Reliance
existing under the laws of the State of Penns)'il-vania
Insurance Company
a corporation organized and
I ; .
with its principal office' in the City of Philadelphia
;f
,
State of Pennsylvania , as Surety, hereinafter called
Surety, are held and firmly bound unto Augusta-Richmond County
Commission-Council Georgia, as Obligee, hereinafter called the
OWner, for the use and benefit of claimants as hereinbelow
defined in the amount of Twenty Five Thousand Five Hundred Seven & 23/100
------------------------------------------ Dollars ($ 25,507. 23-------------)
for the payment whereof Contractor and Surety bind themselves,
their heirs, executors, administrators, successors, and assigns,
jointly and severally, firmly by these presents.
WHEREAS, Contractor has by written agreement dated _____
1//Ud~V entered into a contract with OWner for the
construotion af ~aniel Field Airport Runway Safety OVerrun ~rea
pavi~i! AUt~sta~ Geodrgbia . v~ff-~~ffY~n~ ~~U~~ydraWhi~ghs and t
speC1 1ca l.ons l.ssue y En l.neen.n De t. , W 1.C con ract is
by reference made a part hereof, and is hereinafter referred to
as the CONTRACT.
~
NOW, THEREFORE, the condition of this obligation is
such that, if the Contractor shall promptly make payment to all
claimants as hereinafter defined, for all labor and material used
.or reasonably required to use in the performance of the CONTRACT,
then this obligation shall be void; otherwise it shall remain in
full force and effect, subject, however, to the following
conditions:
(1) A claimant is defined as one having a direct oontract with
the Contractor or with a subcontractor of the Contractor for
labor, material, or both~ used or reasonably required for
use in the performance of the contract, labor and material
being construed as to include that part of water, gas,
power, light, heat, oil, gasoline, telephone service or
rental of equipment directly applicable to the CONTRACT.
PB-3
~
~
~
:'~'~ :-
"-t.\.;
"'
.:.
.'
(2) The above .named Contractor and Surety hereby jointly and
severally agree with the Owner that every claimant as herein
defined, who has not been paid in full before the expiration of a
period of ninety (90) days after ~he date on which the last of such
claimant's work or labor was done or performed, or materials were
furnished by such claimant, may sue on this bond for the use of
such claimant, prosecute the suit to final judgement for such sum
or sumG as may be justly due claimant, and have execution thereon.
The Owner shall not be l.table for the payment .of any costs or
expenses of any such suit. .
~';
'.'
.~
.:'i
...
.~
(3) No suit or action shall be commenced hereunder by any
claimant,
:1'
(a) Unless claimant, other than one having adlrect contract
with the Contractor, shall have given written notice to
any two of the following:' The Contractor, the Owner, or
the Surety above named, within ninety (90) days after
such claimant did or performed the last of the work or
labor, or furnished the last of the materials for which
said claim is made, stating with substantial accuracy the
amount claimed and the name of the party to whom the
materials were furnished, 'or for whom the work or labor
was done or performed. Such notice shall be served by
mailing the same by registered mail or certified mail,
. postage prepaid, in an envelope addressed to the
Contractor, Owner or Surety, at any place where an office
regularly maintained for the transaction'of business, or
served in any manner in which legal p~ocess may be served
in the state in which the, aforesaid 'project is located,
save that such service need not be made by a public
officer.
I':
:;;
:~
1
',"
'~
J'
"~
'1
~,
....
'If
(b) After the expiration of one (1) year following the date
on which Contractor ceased work on said CONTRACT,' it
being understood, however, that if any limitation
embodied in this bond is prohibited by any law
controlling the construction hereof, such lirni tation
shall be deemed to be amended so as to be equal to the
minimum period of limitation permitted by such law.
(c) ~ther than in a state court of competent jurisdiction in
and for the county or other political subdivision of the
sta te in which the project, or any part thereof, is
situated, or in the United States District .Court for the
district in which the project, or any part thereof, is
situated, and not elsewhere.
:-.
( 4 )
The amount of this bond shall be reduced by and to the extent
of any payment or payments made in good faith hereunder,
inclusive of the payment by ,Surety of mechanics' liens which
may be filed of record against said improvement,
., ,
PB-4
signed and sealed this
A.D. 1996.
Witness ~ (j/J1!a/:ta-
t Z- day 0 f J...Ye5\1\
whether or not claim for the amount of such lien be
pre5ented under and against this bond.
Witness
Or~11
cru ynec(
!
~,4tt
Beam's Pavement Maintenace Compt~al~c.
- (Contractor)
By ~~ 01-1 (Seal)
(surety)
I/J) h11s- 5
Att.est.
Reliance Insurance Company (Seal)
( Surety)
Wi tness : /1J
~ t6.fOhoj~
By
Duh
~. f~(Seal)
(Title)
Della B. Case
Attorney-in-Fact
Note:
Date of Bond must be prior to date of Contract. If
Contractor is Partnership, all partners should execute
Bond.
L
j
i t.
",
I'
, ,
i..'
!~
j.'
I;
b
I,
I"
I
I
.,
~~.
PB-5
'RELIANCE SURETY COMPANY
UNITED PACIFIC INSURANCE COMPANY
RELIANCE INSURANCE COMPANY
RELIANCE NATIONAL Il\'DEM:~'ITY COMPANY
ADMINISTRATIVE OFFICE. PHILADELPHIA, PENNSYLVANIA
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS. that RELIANCE SURETY COMPANY is a corporation duly organized under the laws of the Stata of Del-
awere, and that RELIANCE INSURANCE COMPANY and UNITED PACIFIC INSURANCE COMPANY. are corporations duly organized under the laws
of the Commonwealth of Pennsylvania and that RELIANCE NATIONAL INDEMNITY COMPANY is a corporation duly organized under tha laws of
the State of Wisconsin (herein collectively called "the Companies') end thet the Compenies by virtue of signature and seals do heraby make,
constitute and appoint Frank W. HaIner, Jr., David J. Wells, Jr.. Jane McCoy, Carolyn D. Owens. A.T. Johnson, Deralle E. Bigby, Roban J.
Layisky, Dalla B. Cne. W. Scon Hull.. of Columbia. South Carolina their true and lawful Attorney(s)-in-Fact. to make. execute, seal and deliver
for and on their behalf, and as thair act and deed any and all bonds and undanakings of suretyship and to bind the Companies thereby as lully and
to the same extent as il such bonds and undertakings and other writings obligatory in the nature thereof were signed by an Executive Officer of
the Companies end sealed and attested by one other of such officers, and hereby ratifies and confirms all that their said Attorney(s)-in-Fact may
do in pursuance hereof.
Thi9 Power of Anorney is granted under and by the euthority of Article VII of the By-Laws of RELIANCE SURETY COMPANY,
RELIANCE INSURANCE COMPANY, UNITED PACIFIC INSURANCE COMPANY, and RELIANCE NATIONAL INDEMNITY COMPANY which
provisions ara now in full force and effect, reading a9 follows:
ARTICLE VII . EXECUTION OF eONDs AND UNDERT MINGS
1. The Bowd of Oirecton. the Pra.ident. the Ch.etrmen at (hie Board. ."y ~Of Vu:. P'.....o.nt. vrt Vice P'~nt Of Aa:at'8unt Vlca Pra.i<Sent Of Ot/'lcf' cllte:_ dntQnated by t~ Bo.,d of
Olf.ClOt. ""'1 MV. po....., end authotiry to Ie) apDomt AnOlnevl....in-F.ct end to authOttll tt'Iem to execute on behalf of tho Comoany. bOt"'l>> end I..ndertwngs. recOQruanc~. contncU 0' InOemnlY
end olhel W"t~ obt19atOty It\ In. natt..... ''''''00'. and (blto ,.mo..... any 1ucJ"l AnC>>',.,..,.I.h~F.ct a( ""Y 1Imo and ,e",oa.. the power and .\.IU'\otltV o,v.n to, tl"lom.
2. AnOl"'vl.~F.ct aharIl Mv. go,wer end a.uthOtuy. a\Jbtect to tho term. at"Id hmlt.tlor. 01 the PO'Wer of AnOtnov"'uod to th41m, to ..ecute deft..... on behalf a' the Company. bond_
erd Lr'dwt~l. recOQnIZ~. contfaCta 0' Indemnity and other Wrlt1no' ObhO.tOty lfI tne n.cUl'CI tnereof. Tho CorpoutCl ...r II not noccs:a.,y lot the ....behty of eny bond. and \l"'derl~no',
recogn..zenc:... contr.". 0' .noemnty and OH'ler writing_ obhoatory In the NtUl'e 1"'-,eaL
3. AnOlnevt'M~F.ct aharIl tuv. pcwer and euthOrny to, exeC\lU .llld....lt. reQuued 10 be .Cllched to bondl. ,ecoon..zanca. contractl cf Indemnity 01 o,tr"ler cordltlon" or obho.tOfY
U"de:n~ ...-.:t \My ahAlU ..0 ha..... powet end .uthOflty 10, certlly cho lInM'lCJel II'Comet'll af tha Como."... a.nd 10, caPles of lha By-L....... o,f tf'l,a ComClWYf Of' any article Of aecllon Chareof.
Tt'oi-e Pow<< 0' AnOtney tI -..g~ end ,,".cI by f~miloe U"'d... ..-.::I by .euthOtlty 0,' the loUo,wtnO r..oIutlon lIdoClted by Ihd Exocutlvl ...-.;t FInM'\C1 Commln~ oltN Bo,ald. af OLlecton o,f Aeh.,-..co
I,...uune. ComCl'..-.y. UrwlDd Pe.ciflc 1fWU'ww:-. ComCl."y and Reliance NetJon.aI Indomnty Company by Ur\M'lImOlA ConNnt dlted .. af Febtu.l'Y 28. '994 anc:J by the Executive and Fln.no"
Commln.. af the Boltd af C.,IC1011 of R.ehenc. S~ety Cempeny by Unanrnout C~ dated a af Mltet\ 31.1994.
"R..ofved ~I thII alQt'\at\A''' of auch dltleton ...-.;t offlcell and tl"W Mal af I'" Como.....y may b4 .nixed 10 on.,. luch Power 0' AnOf'ney or any certlhCalO'l relellno tMreto by
tacaimjJ.e.end any e:uch Po...., of AItOfney Of cort"lc.te beallng auc.h faClIn'\t~ aJQnelU'u Of hc:su'r\.ll. ...,., -.haJl be valid end bl"";lng uoon t"" COtTlOlt"\y and any luch Pawer 10,
...cuted ...-d eenl'~ by f~mll.. alQt\acur.. end flealmile Mal anell be ...elJd ...-.d blndlng uoon tN Comp....w. In tho future With rMQect to any bOl"lO or Llf"'CUrt.....no to, which Ie I'
.nKhed."
IN WITNESS WHEREOF, tha Companias have caused these presents to be signed and thair corporate seals to be hereto affixed, this February 21.
1995.
STATE OF Pennsylvania
COUNTY OF Philadelphia
}
} ss.
RELIANCE SURETY COMPANY
RELIANCE [NSURANCE COMPANY
UNITED PACIFIC INSURANCE COMPANY
azZTIa;w:z::;;:y
On this, February 21. 1995. before me, Tammy Sue Kayati, personally appeered Charles B. Schmalz, who acknowledged himself to be the
Executive Vice President of the Relience Surety Company, and the Vice President of Raliance Insurance Company, United Pacific Insurance ,
Company, and Reliance National Indemnity Company and that es such, being authorized to do so, executed the foregoing instrument for the
purpose tharain containad by signing the name of tha corporation by himself as its duly authorized officer.
In witness wharaot, I haraunto sat my hand and official seal.
NOTARIAL SEAL
TAMMY SUE KAYAil. Notary Public
City of F;lilad-;!oh;a. Phil:!. COUnly
Mv o:."T';-:-'~'~':-" ::\':1:'~"' .,1;)'\1 ":!O, 1'??B
~V)lA1t
tL.
Notary Public in a~ for the State of Pe~sylvania
Residing at Philade'Tphia
I. Anita Zippen, Secretary of RELIANCE SURETY COMPANY, RELIANCE INSURANCE COMPANY, UNITED PACIFIC INSURANCE COMPANY, and
RELIANCE NATIONAL INDEMNITY COMPANY do hereby certify that the above and foragoing is a true and correct copy of the Power of Attorney
exacuted by said Companies, which is still in full force and effect.
IN WITNESS WHEREOF, I hovo h.",",o ,.f mv h..d .M ,ff'... <h, ,.,1, of "id Comp,.i., <hi, ~~ 19
Secretary
.
SECTION PB
LABOR AND MATERIAL PAYMENT BOND
.
(NOTE:
THIS BOND IS ISSUED SIMULTANEOUSLY WITH PERFORMANCE
BOND ON PAGE PB-1, IN FAVOR OF THE OWNER CONDITIONED
FOR THE PERFORMANCE OF THE CONTRACT.)
KNOW ALL MEN BY THESE PRESENTS:
.
That
as Principal, hereinafter called Contractor, and
a corporation organized and
.
existing under the laws of the State of
with its principal office in the City of
,
.
State of , as Surety, hereinafter called
Surety, are held and firmly bound unto Augusta-Richmond County
Commission-Council Georgia, as Obligee, hereinafter called the
Owner, for the use and benefit of claimants as hereinbelow
defined in the amount of
for the
their
jointly
Dollars ($ )
payment whereof Contractor and Surety bind themselves,
heirs, executors, administrators, successors, and assigns,
and severally, firmly by these presents.
..
...
WHEREAS, Contractor has by written agreement dated
entered into a contract with Owner for the
construction of Daniel Field Airport Runway Safety Overrun Area
Paving, Augusta, Georgia in accordance with drawings and
specifications issued by , which contract is
by reference made a part hereof, and is hereinafter referred to
as the CONTRACT.
NOW, THEREFORE, the condition of this obligation is
such that, if the Contractor shall promptly make payment to all
claimants as hereinafter defined, for all labor and material used
or reasonably required to use in the performance of the CONTRACT,
then this obligation shall be void; otherwise it shall remain in
full force and effect, subject, however, to the following
conditions:
(1} A claimant is defined as one having a direct contract with
the Contractor or with a subcontractor of the Contractor for
labor, material, or both, used or reasonably required for
use in the performance of the contract, labor and material
being construed as to include that part of water, gas,
power, light, heat, oil, gasoline, telephone service or
rental of equipment directly applicable to the CONTRACT.
PB-3
.
.
(2) The above named Contractor and Surety hereby jointly and
severally agree with the Owner that every claimant as herein
defined, who has not been paid in full before the expiration of a
period of ninety (90) days after the date on which the last of such
claimant's work or labor was done or performed, or materials were
furnished by such claimant, may sue on this bond for the use of
such claimant, prosecute the suit to final judgement for such sum
or sums as may be justly due claimant, and have execution thereon.
The Owner shall not be liable for the payment of any costs or
expenses of any such suit.
.
(3) No suitor action shall be commenced hereunder by any
claimant,
.-
-
(a) Unless claimant, other than one having a direct contract
with the Contractor, shall have given written notice to
any two of the following: The Contractor, the Owner, or
the Surety above named, within ninety (90) days after
such claimant did or performed the last of the work or
labor, or furnished the last of the materials for which
said claim is made, stating with substantial accuracy the
amount claimed and the name of the party to whom the
materials were furnished, or for whom the work or labor
was done or performed. Such notice shall be served by
mailing the same by registered mail or certified mail,
postage prepaid, in an envelope addressed to the
Contractor, Owner or Surety, at any place where an office
regularly maintained for the transaction of business, or
served in any manner in which legal process may be served
in the state in which the aforesaid project is located,
save that such service need not be made by a public
officer.
(b) After the expiration of one (l) year following the date
on which Contractor ceased work on said CONTRACT, it
being understood, however, that if any limitation
embodied in this bond is prohibited by any law
controlling the construction hereof, such limitation
shall be deemed to be amended so as to be equal to the
minimum period of limitation permitted by such law.
(c) Other than in a state court of competent jurisdiction in
and for the county or other political subdivision of the
state in which the project, or any part thereof, is
situated, or in the United States District Court for the
district in which the project, or any part thereof, is
situated, and not elsewhere.
(4) The amount of this bond shall be reduced by and to the extent
of any payment or payments made in good faith hereunder,
inclusive of the payment by Surety of mechanics' liens which
may be filed of record against said improvement,
PB-4
.. '.
.
whether or not claim for the amount of such lien be
presented under and against this bond.
.
Signed and sealed this
A.D. 1996.
day of
Witness
(Seal)
(Contractor)
.
Attest
By
(Seal)
(Surety)
.
Witness
(Seal)
(Surety)
Attest
By
(Seal)
(Title)
-
-
Note:
Date of Bond must be prior to date of Contract. If
Contractor is Partnership, all partners should execute
Bond.
PB-5
.
CERTIFICATE OF OWNER'S ATTORNEY
.
I, the undersigned
~e5 1? tJa-l/
, the
authorized and acting legal representative of Augusta-Richmond
.
County Commission-Council do hereby certify as follows:
.
I have examined the attached Contract(s) and surety bonds
and the manner of execution thereof, and I am of the opinion that
each of the aforesaid agreements has been duly executed by the
proper parties thereto acting through their duly authorized
representati ves; that said representatives have full power and
authority to execute said agreements on behalf of the respective
parties named thereon; and that the foregoing agreements constitute
valid and legally binding obligations upon the parties executing
the same in accordance with the terms, conditions and provisions
thereof.
-
~
DATE:
COA-I
.
.
.
Page No.
GC-01.
GC-02.
GC-03.
GC-04.
GC-05.
GC-06.
GC-07.
GC-08.
GC-09.
GC-10.
GC - l1.
GC-12.
GC-13.
GC-14.
GC-15.
GC-16.
GC-17.
GC-18.
GC-19.
GC-20.
GC - 2 1.
GC-22.
GC-23.
GC-24.
GC-25.
GC-26.
GC-27.
GC-28.
GC-29.
GC-30.
GC - 3 1-
GC-32.
GC-33.
GC-34.
GC-35.
GC-36.
.
.
-
-
SECTION GC
GENERAL CONDITIONS
INDEX TO ARTICLES OF GENERAL CONDITIONS
Section
Definitions
Additional Instructions and Detail Drawings
Schedules, Reports and Records
Drawings and Specifications
Shop Drawings
Materials, Services and Facilities
Inspection and Testing
Substitutions
Patents
Surveys, Permits and Regulations
Protection of Work, Property and Persons
Supervision by Contractor
Changes in the Work
Changes in Contract Price
Time for Completion and Liquidated Damages
Correction of Work
Subsurface Conditions
Suspension of Work, Termination and Delay
Payments to Contractor
Acceptance of Final Payment as Release
Insurance
Contract Security
Assignments
Indemnification
Separate Contracts
Subcontracting
Engineer's Authority
Land and Rights-of-Way
Guarantee
Taxes
Work Adjacent to Railway or Other Property
Order and Discipline
Warning Devices and Signs
Special Restrictions
As-Built Drawings
Contractor Not to Hire Employees of the OWner
GC-I
2
4
4
4
5
6
6
7
8
8
9
lO
10
10
11
II
l2
l2
14
l6
l6
18
19
19
19
20
20
21
21
22
22
22
22
22
23
23
.
.
GC-Ol.
DEFINITIONS:
.
Wherever used in the Contract Documents, the following
terms shall have the meanings indicated which shall be applicable
to both the singular and plural thereof.
.
1. ADDENDA: Written or graphic instruments issued prior to the
execution of the Agreement which modify or interpret the
Contract Documents, Drawings and Specifications, by addition,
deletion, clarifications or corrections.
2. BID: The offer or proposal of the Bidder submitted on the
prescribed form setting forth the prices for the work to be
performed.
.
3. BIDDER: Any person, firm or corporation submitting a bid for
the work.
4. BONDS: Bid, Performance and Payment Bonds and other
instruments of security furnished by the Contractor and his
Surety in accordance with the Contract Documents.
-
-
5. CHANGE ORDER: A written order to the Contractor authorizing
an addition, deletion or revision in the work wi thin the
general scope of the Contract Documents or authorizing an
adjustment in the contract price or contract time.
6. CONTRACT DOCUMENTS: The contract including Advertisement for
Bids, Information for Bidders, Proposal, Bid Bond, Notice of
award, Agreement, Performance Bond, Payment Bond, Notice to
Proceed, Change Order, General Conditions, Supplemental
General Conditions, Special Conditions, Technical
Specifications, Drawings and Addenda.
7. CONTRACT PRICE: The total monies payable to the Contractor
under the terms and conditions of the Contract Documents.
8. CONTRACT TIME: The number of calendar days stated in the
Contract Documents for the completion of the work.
9. LIFE OF THE CONTRACT: The total duration of the contract from
Notice to Proceed to completion of all the work.
10. CONTRACTOR: The person, firm or corporation with whom the
Owner has executed the Agreement.
11. DRAWINGS: The part of the Contract Documents which show the
characteristics and scope of the work to be performed and
which have been prepared or approved by the Engineer.
GC-2
.
.
12. ENGINEER: The person, firm or corporation named as such in
the Contract Documents.
13. FIELD ORDER: A written order effecting a change in the work
not involving an adjustment in the contract price or an
extension of the contract time issued by the Engineer to the
Contractor during construction.
.
14. NOTICE OF AWARD: The written notice of the acceptance of the
Bid from the Owner to the successful Bidder.
.
15. NOTICE TO PROCEED: Written communication issued by the Owner
to the Contractor authorizing him to proceed with the work and
establishing the date of commencement of the work.
16. OWNER: A public or quasi-public body or authority,
corporation, association, partnership or individual for whom
the work is to be performed.
.
17. PROJECT: The undertaking to be performed as provided in the
Contract Documents.
18. RESIDENT PROJECT REPRESENTATIVE: The authorized
representative of the Owner who is assigned to the project
site or any part thereof.
-
-
19. SHOP DRAWINGS: All drawings, diagrams, illustrations,
brochures, schedules, and other data which are prepared by the
Contractor, a Subcontractor, Manufacturer, Supplier or
Distributor, which illustrate how specific portions of the
work shall be fabricated or installed.
20. SPECIFICATIONS: A part of the Contract Documents consisting
of written descriptions of a technical nature or materials,
equipment, construction systems, standards and workmanship.
21. SUBCONTRACTOR: An individual, firm or corporation having a
direct contract with the Contractor or any other Subcontractor
for the performance of a part of the work at the site.
22. SUBSTANTIAL COMPLETION: That date as certified by the
Engineer when the construction of the project or a specified
part can be utilized for the purposes for which it is
intended.
23. SUPPLEMENTAL GENERAL CONDITIONS: Modifications and/or
addi tions to the General Conditions of a specific nature
generally aimed at the specific contract of which it is a
part.
24. SUPPLIERS: Any person, supplier or organization who supplies
materials or equipment for the work, including that fabricated
to a special design, but who does not perform labor at the
site.
GC-3
.
.
25. WORK: All labor necessary to produce the construction
required by the Contract Documents and all materials and
equipment incorporated or to be incorporated in the project.
.
26. WRITTEN NOTICE: Any notice to any party of the Agreement
relative to any part of this Agreement in writing and
considered delivered and the service thereof completed, when
posted by certified or registered mail to the said party at
his last given address or delivered in person to said party or
his authorized representative on the work.
GC-02.
ADDITIONAL INSTRUCTIONS AND DETAIL DRAWINGS:
.
1. The Contractor may be furnished additional instructions and
detail drawings, by the Engineer, as necessary to carry out
the work required by the Contract Documents.
.
2. The additional drawings and instructions thus supplied will
become a part of the Contract Documents. The Contractor shall
carry out the work in accordance with the additional detail
drawings and instructions.
GC-03.
SCHEDULES, REPORTS AND RECORDS:
-
-
1. The Contractor shall submit to the Owner such schedule of
quantities and costs, progress schedules, payrolls, reports,
estimates, records and other data as the Owner may request
concerning the work performed or to be performed.
2. Prior to the first partial payment estimate, the Contractor
shall submit schedules showing the order in which he proposes
to carry on the work, including dates at which he will start
the various parts of the work, estimated date of completion of
each part and as applicable:
2.1 the dates at which special detail drawings will be
required; and
2.2
respecti ve dates for submission of shop drawings,
beginning of manufacture, the testing and
installation of materials, supplies and equipment.
the
the
3. The Contractor shall also submit a schedule of payments that
he anticipates he will earn during the course of the work.
GC-04.
DRAWINGS AND SPECIFICATIONS;
1. The intent of the drawings and specifications is that the
Contractor shall furnish all labor, materials, tools,
equipment and transportation necessary for the proper
execution of the work in accordance with the Contract
Documents and all incidental work necessary to complete the
project in an acceptable manner, ready for us, occupancy or
operation by the Owner.
GC-4
.
.
2. In case of conflict between the drawings and specifications,
the specifications shall govern. Figure dimensions on
drawings shall govern over general drawings.
.
3. Any discrepancies found between the drawings and
specifications and site conditions or any inconsistencies or
ambiguities in the drawings or specifications shall be
immediately reported to the Engineer, in writing, who shall
promptly correct such inconsistencies or ambiguities in
writing. Work done by the Contractor after his discovery of
such discrepancies, inconsistencies or ambiguities shall be
done at the Contractor's risk.
.
4. All work that may be called for in the specifications and not
shown on the drawings, or shown and not called for in the
specifications, shall be executed and furnished by the
Contractor as if described in both these ways and should any
work or material be required which is not detailed in the
specifications or drawings, either directly or indirectly, but
which is nevertheless necessary for the proper carrying out of
the intent thereof, the Contractor is to understand the same
to be implied and required and shall perform all such work and
furnish any such material as fully as if they were
particularly delineated or described.
.
-
-
5. It is understood and agreed that the Contractor, by careful
examination, has satisfied himself as to the nature and
location of the work, the conformation of the ground, the
character, quality and quantity of the materials to be
encountered, the character of equipment and facilities needed
preliminary to and during the prosecution of the work, the
general and local conditions and all other matters which can
in any way affect the work under this contract. No verbal
agreement or conversation with any officer, agent or employee
of the Owner, either before or after the execution of this
contract, shall affect or modify any of the terms or
obligations herein contained.
GC-05.
SHOP DRAWINGS:
l. The Contractor shall provide shop drawings as may be necessary
for the prosecution of the work as required by the Contract
Documents. The Engineer shall promptly review all shop
drawings. The Engineer's approval of any shop drawings shall
not release the Contractor from responsibility for deviations
from the Contract Documents. The approval of any shop drawing
which substantially deviates from the requirement of the
Contract Documents shall be evidenced by a Change Order.
2. When submitted for the Engineer's review, shop drawings shall
bear the Contractor I s certification that he has reviewed,
checked and approved the shop drawings and that they are in
conformance with the requirements of the Contract Documents.
GC-5
.
.
3. Portions of the work that require shop drawing or sample
submission shall not begin until the shop drawing or
submission has been approved by the Engineer. A copy of. each
approved shop drawing and each approved sample shall be kept
in good order by the Contractor at the site and shall be
available to the Engineer.
.
GC-06.
MATERIALS, SERVICES AND FACILITIES:
.
1. It is understood that, except as otherwise specifically stated
in the Contract Documents, the Contractor shall provide and
pay for all materials, labor, tools, equipment, water, light,
power, transportation, supervision, temporary construction of
any nature and all. other services and facilities of any nature
whatsoever necessary to execute, complete and deliver the work
within the specified time.
.
2. Materials and equipment shall be so stored as to insure the
preservation of their quality and fitness for the work.
Stored materials and equipment to be incorporated in the work
shall be located so as to facilitate prompt inspection.
3. Manufactured articles, materials and equipment shall be
applied, installed, connected, erected, used, cleaned and
conditioned as directed by the manufacturer.
4. Materials, supplies or equipment shall be in accordance with
samples submitted by the Contractor and approved by the
Engineer.
5. Materials, supplies or equipment to be incorporated into the
work and purchased by the Contractor of the Subcontractor will
be subject to a chattel mortgage or under a conditional sale
contract or other agreement by which an interest is retained
by the seller.
GC-07.
INSPECTION AND TESTING:
1. All materials and equipment used in the construction of the
project shall be subject to adequate inspection and testing in
accordance with generally accepted standards.
2. The Contractor shall provide, at his expense, the necessary
testing and inspection services required by the Contract
Documents, unless otherwise provided.
3. The Owner shall provide all other inspection and testing
services required by the Contract Documents.
4. I f the Contract Documents, laws, ordinances, rules,
regulations or orders of any public authority having
jurisdiction require any work to specifically be inspected,
tested or approved by someone other that the Contractor, the
Contractor will give the Engineer timely notice of readiness.
GC-6
.
.
The Contractor will then furnish the Engineer the required
certificates of inspection, testing or approval.
5. Neither observation by the Engineer nor inspections, tests or
approvals by persons other than the Contractor shall relive
the Contractor from his obligations to perform the work in
accordance with the requirements of the Contract Documents.
.
6. The Engineer and his representatives will at all times have
access to the work. In addition, authorized representatives
and agents of any participating Federal or State Agency shall
be permitted to inspect all work, materials, payrolls, records
of personnel, invoices of materials and other relevant data
and records. The Contractor will provide proper facilities
for such access and observation of the work and also for any
inspection or testing thereof.
.
-
-
7. If any work is covered contrary to the written request of the
Engineer, it must, if requested by the Engineer, be uncovered
for his observation and replaced at the Contractor's expense.
8. If any work has been covered which the Engineer has not
specifically requested to observe prior to its being covered
or if the Engineer considers it necessary or advisable that
covered work be inspected or tested by others, the Contractor
at the Engineer's request, will uncover, expose or otherwise
make available for observation, inspection or testing as the
Engineer may require, that portion of the work in question,
furnishing all necessary labor, materials, tools and
equipment. If it is found that such work is defective, the
Contractor will bear all the expenses of such uncovering,
exposure, observation, inspection and testing and of
satisfactory reconstruction. If, however, such work is not
found to be defective, the Contractor will be allowed an
increase in the contract price or an extension of the contract
time, or both, directly attributable to such uncovering,
exposure, observation, inspection, testing and reconstruction
and an appropriate change order shall be issued.
9. The Contractor shall give the Engineer 24 hours notice of
starting any new work. No work shall be done or materials
used without suitable supervision and inspection by the
Engineer. The Contractor shall furnish the Engineer with
necessary samples of material for testing purposes.
GC-08.
SUBSTITUTIONS:
1. When a material, article or piece of equipment is identified
on the drawings or specifications by reference to brand name
or catalogue number, the performance or other salient
requirements and that other products of equal capacities,
quality and function shall be considered. The Contractor may
recommend the substitution of a material, article or piece of
equipment of equal substance and function for those referred
GC-7
.
.
to in the Contract Documents by reference to brand name or
catalogue number and if, in the opinion of the Engineer, such
material, article or piece of equipment is of equal substance
and function to that specified, the Engineer may approve its
substitution and use by the Contractor. Any cost differential
shall be deducted from the contract price and the Contract
Documents shall be appropriately modified by change order.
The Contractor warrants that if substitutes are approved, no
major changes in the function or general design of the project
will result. Incidental changes or extra component parts
required to accommodate the substitute will be made by the
Contractor without a change in the contract price or contract
time.
.
.
GC-09.
PATENTS:
-
-
1. The Contractor shall pay all applicable royalties and license
fees. He shall defend all suits or claims for infringement of
any patent rights and save the Owner harmless from loss on
account thereof except that the Owner shall be responsible for
any such loss when a particular process, design or the product
of a manufacturer or manufacturers is specified, but if the
Contractor has reason to believe that the design, process or
product specified is an infringement of a patent, he shall be
responsible for such loss unless he promptly gives such
information to the Engineer.
GC-10.
SURVEYS, PERMITS AND REGULATIONS:
l. The Owner shall furnish all land surveys and establish all
base lines for locating the principal component parts of the
work together with a sui table number of benchmarks adjacent to
the work as shown in the Contract Documents. From the
information provided by the Owner, unless otherwise specified
in the Contract Documents, the Contractor shall develop and
make all detail surveys needed for construction such as slope
stakes, batter boards, stakes for pile locations and other
working points, lines, elevations and cut sheets.
2. The Contractor shall carefully preserve benchmarks, reference
points and stakes and in case of willful or careless
destruction, he shall be charged with the resulting expense
and shall be responsible for any mistakes that may be caused
by their unnecessary loss or disturbance.
3. Permits and licenses of a temporary nature necessary for the
prosecution of the work shall be secured and paid for by the
Contractor. Permits, licenses and easements for permanent
structures or permanent changes in existing facilities shall
be secured and paid for by the Owner, unless otherwise
specified. The Contractor shall give all notices and comply
with all laws, ordinances, rules and regulations bearing on
the conduct of the work as drawn and specified. If the
Contractor observes that the Contract Documents are at
GC-8
.
.
variance therewith, he shall promptly notify the Engineer in
wri ting and any necessary changes shall be adjusted as
provided in Section 13, Changes in the Work.
GC-ll.
PROTECTION OF WORK, PROPERTY AND PERSONS:
.
l. The Contractor will be responsible for initiating, maintaining
and supervising all safety precautions and programs in
connection with the work. He will take all necessary
precautions for the safety of and will provide the necessary
protection to prevent damage, injury or loss to all employees
on the work and other persons who may be affected thereby, all
the work and all materials or equipment to be incorporated
therein, whether in storage on or off the site or other
property at the site or adjacent thereto, including trees,
shrubs, lawns, walks, pavements, roadways, structures and
utili ties not designated for removal, relocation or
replacement in the course of construction.
.
-
-
2. The Contractor will comply with all applicable laws,
ordinances, rules, regulations and orders of any public body
having jurisdiction. He will erect and maintain, as required
by the conditions and progress of the work, all necessary
safeguards for safety and protection. He will notify the
owners of adjacent utilities when prosecution of the work may
affect them. The Contractor will remedy all damage, injury or
loss to any property caused, directly or indirectly, in whole
or in part, by the Contractor, and subcontractor or anyone
directly or indirectly employed by any of them or anyone for
whose acts any. of them are liable, except damage or loss
attributable to the fault of the Contract Documents or to the
acts or omissions of the Owner or the Engineer or anyone
employed by either of them or anyone for whose acts either of
them may be liable and not attributable, directly or
indirectly, in whole or in part, to the fault or negligence of
the Contractor.
3. In emergencies affecting the safety of persons or the work or
property at the site or adjacent thereto, the Contractor,
without special instructions or authorization from the
Engineer or Owner, shall act to prevent threatened damage,
injury or loss. He ...'ill give the Engineer prompt written
notice of any significant changes in the work or deviations
from the Contract Documents caused thereby and a Change Order
shall be issued covering the changes and deviations involved.
4. The work under this Contract in every respect shall be at the
risk of the Contractor until finished and accepted, except to
damage or injury caused directly by the Owner's agents or employees.
GC-9
.
GC-12.
SUPERVISION BY CONTRACTOR:
.
l. The Contractor will supervise and direct the work. He will
be solely responsible for the means, methods, techniques,
sequences and procedures of construction. The Contractor will
employ and maintain on the work a qualified supervisor or
superintendent who shall have been designated in writing by
the Contractor as the Contractor's representative at the site.
The supervisor shall have full authority to act on the behalf
of the Contractor and all communications given to the
supervisor shall be as binding as if given to the Contractor.
The supervisor shall be present on the site at all times as
required to perform adequate supervision and coordination of
the work.
.
.
GC-13.
CHANGES IN THE WORK:
-
....
1. The Owner may at any time as the need arises, order changes
within the scope of the work without invalidating the
Agreement. If such changes increase or decrease the amount
due under the Contract Documents or in the time required for
performance of the work, an equitable adjustment shall be
authorized by Change Order.
2. The Engineer, also, may at any time, by issuing a field order,
make changes in the details of the work. The Contractor shall
proceed with the performance of any changes in the work so
ordered by the Engineer unless the Contractor believes that
such field order entitles him to a change in the contract
price or time or both, in which event he shall give the
Engineer written notice thereof within ten (lO) days after the
receipt of .the ordered change pending the receipt of an
executed change order or further instruction from the Owner.
GC-14.
CHANGES IN CONTRACT PRICE:
1. The contract price may be changed only by a change order. The
value of any work covered by a change order or of any claim
for increase or decrease in the contract _ price shall be
determined by one or more of the following methods in the
order of precedence listed below:
1.1 Unit prices previously approved.
1.2 An agreed lump sum.
1.3 The actual cost for labor, direct overhead, materials,
supplies, equipment and other services necessary to
complete the work. In addition there shall be added an
amount to be agreed upon but not to exceed fifteen (l5)
percent of the actual cost of the work to cover the cost
of general overhead and profit.
GC-10
.'
GC-15.
TIME FOR COMPLETION AND LIQUIDATED DAMAGES:
.
l. The date of beginning and the time for completion of the work
are essential conditions of the Contract Documents and the
work embraced shall be commenced on the date specified in the
Notice to Proceed.
.
2. The Contractor will proceed with the work at such rate of
progress to insure full completion within the contract time.
It is expressly understood and agreed, by and between the
Contractor and the. Owner, that the contract time for the
completion of the work described herein is a reasonable time,
taking into consideration the average climatic and economic
conditions and other factors prevailing in the locality of the
work.
.
-
-
3. If the Contractor shall fail to complete the work within the
contract time or extension of time granted by the Owner, then
the Contractor will pay to the Owner the amount for liquidated
damages as specified in the bid for each calendar day that the
Contractor shall be in default after the time stipulated in
the Contract Documents.
.-
--
4. The Contractor shall not be charged with liquidated damages or
any excess cost when the delay in completion of the work is
due to the following and the Contractor has promptly given
written notice of such delay to the Owner or Engineer.
4.1 To any preference, priority or allocation order duly
issued by the Owner.
4.2 To unforeseeable causes beyond the control and without
the fault of negligence of the Contractor, including but
not restricted to, acts of God or of the public enemy,
acts of the Owner, acts of another Contractor in the
performance of a contract with the Owner, fires, floods,
epidemics, quarantine restrictions, strikes, freight
embargoes and abnormal and unforeseeable weather; and
4.3 To any delays of subcontractors occasioned by any of the
causes specified in Paragraphs 4.1 and 4.2 of this
Article.
GC-16. CORRECTION OF WORK:
1. The Contractor shall promptly remove from the premises all
work rejected by the Engineer for failure to comply with the
Contract Documents, whether incorporated in the construction
or not and the Contractor shall promptly replace and re-
execute the work in accordance with the Contract Documents and
without expense to the Owner and shall bear the expense of
making good all work of other Contractors destroyed or damaged
by such removal or rep~acement.
2. All removal and replacement "Work shall be done at the
Contractor's expense. If the Contractor does not take action
GC-II
.
.
to remove such rejected work wi thin ten (10) days after
receipt of written notice, the Owner may remove such work and
store the materials at the expense of the Contractor.
-
-
3. Any omissions or failure on the part of the Engineer to
disapprove or reject any work or material shall not be
construed to be an acceptance of any defective work or
material. The Contractor shall remove, at his own expense and
shall rebuild and replace same without extra charge and in
defaul t thereof the same may be done by the Owner at the
Contractor's expense or in case the Engineer shall not
consider the defect of sufficient importance to require the
Contractor to rebuild or replace any imperfect work or
material, he shall have the power and is hereby authorized to
make an equitable deduction from the stipulated price.
-
GC-17.
SUBSURFACE CONDITIONS:
1. The Contractor shall promptly and before such conditions are
disturbed, except in the event of an emergency, notify the
Owner by written notice of:
1.1 Subsurface or latent physical conditions at the site
differing materially from those indicated in the Contract
Documents.
1.2 Unknown physical conditions at the site, of an unusual
nature, differing materially from those ordinarily
encountered and generally recognized as inherent in work
of the character provided for in the Contract Documents.
2. The Owner shall promptly investigate the conditions and if he
finds that such conditions do so materially differ and cause
an increase or decrease in the cost of, or in the time
required, for performance of the work, an equitable adjustment
shall be made and the Contract Documents shall be modified by
a Change Order. Any claim of the Contractor for adjustment
hereunder shall not be allowed unless he has given the
required written notice; provided that the Dwner may, if he
determines the facts so justify, consider and adjust any such
claims asserted before the date of final payment.
GC-18.
SUSPENSION OF THE WORK, TERMINATION AND DELAY:
1. The Owner may, at any time and without cause, suspend the work
or any portion thereof for a period of not more than ninety
days or such further time as agreed upon by the Contractor, by
written notice to the Contractor. The Engineer shall fix the
date on which work shall be resumed. The Contractor will
resume that work on the date so fixed. The Contractor will be
allowed an increase in the contract price, an extension of the
contract time, or both, directly attributable to any
suspension.
GC-12
.
.
2. If the Contractor is adjudged bankrupt or insolvent, or if he
makes a general assignment for the benefit of his creditors or
if a trustee or receiver is appointed for the Contractor or
for any of his property or if he files a petition to take
advantage of any debtor's act to reorganize under the
bankruptcy or applicable laws or if he repeatedly fails to
supply sufficient skilled workmen or suitable materials or
equipment, or if he repeatedly fails to make prompt payments
to subcontractors or for labor, materials or equipment or if
he disregards laws, ordinances, rules, regulations or orders
of any public body having jurisdiction of the work or if he
disregards the authority of the Engineer, or if, in the
opinion of the Engineer, the Contractor fails to make
satisfactory progress in prosecuting the work, or if he
otherwise violates any provision of the Contract Documents,
then the Owner may, without prejudice to any other right or
remedy and after giving the Contractor and his Surety a
minimum of ten (10) days from delivery of a written notice,
terminate the services of the Contractor and take possession
of the Project and of all materials, equipment, tools,
construction equipment and machinery thereon owned by the
Contractor and finish the work by whatever method he may deem
expedient. In such case, the Contractor shall not be entitled
to receive any further payment until the work is finished. If
the unpaid balance of the Contract Price exceeds the direct
and indirect costs of completing the Project, including
compensation for addi tional professional services, such excess
shall be paid to the Contractor. If such costs exceed such
unpaid balance, the Contractor will pay the difference to the
Owner. Such costs incurred by the Owner will be determined by
the Engineer and incorporated in a Change Order.
.
..
-
-
...
3. The Contractor must obtain permission from the Engineer before
any equipment can be removed from the job site. In the event
such equipment is removed without the Engineer's approval, the
job will be terminated until such time as the equipment is
returned to the project and any time and money lost by the
Contractor as a result of moving the equipment shall be
absorbed by the Contractor.
4. Where the Contractor's services have been so terminate by the
Owner, said termination shall not affect any right of the
Owner against the Contractor then existing or which may
thereafter accrue. Any retention or payment of monies by the
Owner due the Contractor will not release the Contractor from
compliance with the Contract Documents.
5. After ten (lO) days from delivery of a written notice to the
Contractor and the Engineer, the Owner, may, without cause and
wi thout prejudice to any other right or remedy, elect to
abandon the Project and terminate the Contract. In such case,
the Contractor shall be paid for all work executed and any
expense sustained plus reasonable profit.
OC-13
.
.
6. If, through no act or fault of the Contractor, the work is
suspended for a period of more than ninety (90) days by the
Owner or under an order of court or other public authority of
the Engineer fails to act on any request for payment within
thirty (30) days after it is submitted or the Owner fails to
pay the Contractor substantially the sum approved by the
Engineer within thirty (30) days of its approval and
presentation, then the Contractor may after ten (10) days from
delivery of a written notice to the Owner and the Engineer,
terminate the Contract and recover from the Owner payment for
all work executed and all expenses sustained. In addition,
and in lieu of terminating the Contract, if the Engineer has
failed to act on a request for payment or if the Owner has
failed to make any payment as aforesaid, the Contractor may,
upon ten (lO) days notice to the Owner and the Engineer, stop
the work until he has been paid all amounts then due, in which
event and upon resumption of the work, Change Orders shall be
issued for adjusting the contract price or extending the
contract time or both to compensate for the costs and delays
attributable to the stoppage of the work.
.
-
-
-
7. If the performance of all or any portion of the work is
suspended, delayed, or interrupted as a result of a failure of
the Owner or the Engineer to act within the time specified in
the Contract Documents, or if no time is specified, within
reasonable time, an adjustment in the contract price or an
extension of the contract time or both, shall be made by
Change Order to compensate the Contractor for the costs and
delays necessarily caused by the failure of the Owner or the
Engineer.
GC-19.
PAYMENTS TO THE CONTRACTOR:
1. Between the first (1st) and the fifth (5th) of each month, the
Contractor will submit to the Engineer a partial payment
estimate filled out and signed by the Contractor on an
approved form covering the work performed during the period
covered by the partial payment estimate and supported by such
data as the Engineer may reasonably require-. If payment is
requested on the basis of materials and equipment not
incorporated in the work but delivered and suitably stored at
or near the site, the partial payment estimate shall also be
accompanied by such supporting data, satisfactory to the
Owner, as will establish the Owner's title to the material and
equipment and protect his interest therein, including
applicable insurance. The Engineer will, wi thin ten days
after receipt of each partial payment estimate, either
indicate in writing his approval of payment and present the
partial payment estimate to the Owner, or return the partial
payment estimate to the Contractor indicating in writing his
reasons for refusing to approve payment. In the latter case,
the Contractor may make the necessary corrections and resubmit
the partial payment estimate. The Owner will, wi thin ten days
of presentation to him of an approved partial payment
GC-14
.
.
estimate, pay the Contractor a progress payment on the basis
of the approved partial payment estimate. The Owner shall
retain ten (10%) percent of the amount of each payment until
final completion and acceptance of all work covered by the
Contract Documents. The Owner at any time, however, after
fifty (50%) percent of the work has been completed, if he
finds that satisfactory progress is being made, shall reduce
retainage to five (5%) percent on the current and remaining
estimates. On completion and acceptance of a part of the work
on which the price is stated separately in the Contract
Documents, payment may be made in full, including retained
percentages, less authorized deductions.
.
-
-
2. The request for payment may also include an allowance for the
cost of such major materials and equipment which are suitably
stored either at or near the site.
3. All work covered by partial payment shall thereupon become the
sole property of the Owner, but this provision shall not be
construed as relieving the Contractor of the sole
responsibility for the care and protection of the work upon
which payments have been made or the restoration of any
damaged work, or as a waiver of the right of the Owner to
require the fulfillment of all terms of the Contract
Documents.
4. Upon completion and acceptance of the work, the Engineer shall
issue a certificate attached to the final payment request that
the work has been accepted by him under the conditions of the
Contract Documents. The entire balance found to be due the
Contractor, including the retained percentages shall be paid
to the Contractor, except such sums as may be lawfully
retained by the Owner for saving the Owner or the Owner I s
agents harmless from all claims growing out of the lawful
demands of Subcontractors, laborers, workmen, mechanics,
materialmen and furnisher of machinery and parts thereof,
equipment, tools and supplies, incurred in the furtherance of
the performance of the work. The Contractor shall, at the
Owner's request, furnish satisfactory evidence that all
obligations of the nature designated above have been paid,
discharged, or waived. If the Contractor fails to do so, the
Owner may, after having notified the Contractor, either pay
unpaid bills or withhold from the Contractor's unpaid
compensation a sum of money deemed reasonably sufficient to
pay any and all such lawful claims until satisfactory evidence
is furnished that all liabilities have been fully discharged
whereupon payment to the Contractor shall be resumed, in
accordance with the terms of the Contract Documents, but in no
event shall the provisions of this sentence be construed to
impose any obligations upon the Owner to either the
Contractor, his Surety, or any third party. In paying any
unpaid bills of the Contractor, any payment so made by the
Owner shall be considered as a payment made under the Contract
Documents by the Owner to the Contractor and the Owner shall
GC-15
.
.
not be liable to the Contractor for any such payments made in
good faith.
5. If the Owner fails to make payment 30 days after approval by
the Engineer, in addition to other remedies available to the
Contractor, there shall be added to each such payment,
interest at the maximum legal rate commencing on the first day
after said payment is due and continuing until the payment is
received by the Contractor.
.
GC-20.
ACCEPTANCE OF FINAL PAYMENT AS RELEASE:
.
1. The acceptance by the Contractor of final payment shall be and
shall operate as a release to the OWner of all claims and all
liability to the Contractor other than claims in stated
amounts as may be specifically excepted by the Contractor for
all things done or furnished in connection with this work and
for every act and neglect of the OWner and other relating to
or arising out of this work. Any payment, however, final or
otherwise, shall not release the Contractor or his Sureties
from any obligations under the Contract Documents or the
Performance Bond and Payment Bonds.
.
GC-21.
INSURANCE:
-
1. The Contractor shall purchase and maintain during the life of
this Contract such insurance as will protect him from claims
set forth below which may arise out of or result from the
Contractor's execution of the work, whether such execution by
himself or by any Subcontractor or by anyone directly or
indirectly employed by any of them or by anyone for whose acts
any of them may be liable.
1.l Claims under Workman's Compensation, disability benefit
and other similar employee benefit acts,
1.2 Claims for damages because of bodily injury, occupational
sickness or disease or death of his employees,
1.3 Claims for damages because of bodily injury, sickness or
disease or death of any person other than his employees,
1.4 Claims for damages insured by usual personal injury
liability coverage which are sustained (l) by any person
as a result of an offense directly or indirectly related
to the employment of such person by the Contractor or (2)
by any other person; and
1.5 Claims for damages because of injury to or destruction of
tangible property, including loss of use resulting
therefrom.
2. Certificates of Insurance acceptable to the OWner shall be
filed with the Owner prior to commencement of the work. These
GC-16
.
.
Certificates shall contain a provision that coverages afforded
under the policies will not be cancelled unless at least
fifteen (15) days prior written notice has been given to the
Owner.
.
3. The Contractor shall procure and maintain, at his own expense,
during the life of the Contract, liability insurance as
hereinafter specified.
.
3.1 Contractor's General Public liability and Property Damage
insurance including vehicle coverage issued to the
Contractor and protecting him from all claims for
personal injury, including death, and all claims for
destruction of or damage to property, arising out of or
in connection with any operations under the Contract
Documents, whether such operations be by himself or by
any Subcontractor under him or anyone directly or
indirectly employed by the Contractor or by a
Subcontractor under him. Insurance shall be written with
a limit of liability of not less than $200,000 for all
damages arising out of bodily injury, including death, at
any time resulting therefrom, sustained by anyone person
in anyone accident; and a limit of liability of not less
than $500,000 for any such damages sustained by two or
more persons in anyone accident. Insurance shall be
wri tten with a limit of liability of not less than
$100,000 for all property damage sustained by anyone
person in anyone accident; and a limit of liability of
not less than $200,000 for any such damage sustained by
two or more persons in anyone accident.
.
-
-
3.2 The Contractor shall acquire and maintain, if applicable,
Fire and Extended Coverage insurance upon the Project to
the full insurable value thereof for the benefit of the
Owner, the Contractor and Subcontractor as their interest
may appear. This provision shall in no way release the
Contractor or Contractor's Surety from obligations under
the Contract Documents to fully complete the Project.
4. The Contractor shall procure and maintain, at his own expense,
during the life of the Contract, in accordance with the
provisions of the laws of the state in which the work is
performed, Workman's Compensation Insurance, including
occupational disease provisions, for all of his employees at
the site of the project and in case any work is sublet, the
Contractor shall require such Subcontractor similarly to
provide Workman's Compensation Insurance, including
occupational disease provision for all of the latter's
employees unless such employees are covered by the protection
afforded by the Contractor. In case any class of employees
engaged in hazardous work under this Contract at the site of
the Project is not protected under Workman's Compensation
statute, the Contractor shall provide and shall cause each
GC-17
.
.
Subcontractor to provide adequate and suitable insurance for
the protection of his employees not otherwise protected.
.
5. The Contractor shall secure, if applicable, "All Risk" type
Builder's Risk Insurance for work to be performed. Unless
specifically authorized by the Owner, the amount of such
insurance shall not be less than the contract price totaled in
the bid. The policy shall cover not less than the losses due
to fire, explosion, hail, lightening, vandalism, malicious
mischief, wind, collapse, riot, aircraft and smoke during the
contract time and until the work is accepted by the Owner.
The policy shall name as the insured the Contractor, the
Engineer and the Owner.
.
GC-22.
CONTRACT SECURITY:
-
.
1. The Contractor shall, within ten (10) days after the receipt
of the Notice of Award, furnish the Owner with a Performance
Bond and a Payment Bond in penal sums equal to the amount of
the contract price, conditioned upon the performance by the
Contractor of all undertakings, covenants, terms, conditions
and agreements of the Contract Documents and upon the prompt
payment by the Contractor to all persons supplying labor and
materials in the prosecution of the work provided by the
Contract Documents. Such bonds shall be executed by the
Contractor and a corporate bonding company licensed to
transact business in the state in which the work is to be
performed and named on the current list of "Surety Companies
Acceptable on Federal Bonds" as published in the Treasury
Department Circular Number 570. The expense of these bonds
shall be borne by the Contractor. If at any time a Surety on
any such bond is declared a bankrupt or loses its right to do
business in the state in which the work is to be performed or
is removed from the list of Surety Companies accepted on
Federal Bonds, Contractor shall within ten (10) days after
notice from the Owner to do so, substitute an acceptable bond
(or bonds) in such form and sum and signed by such other
Surety or Sureties as may be satisfactory to the Owner. The
premiums on such bonds shall be paid by the Contractor. No
further payments shall be deemed due nor shall be made until
the new Surety or Sureties shall have furnished an acceptable
bond to the Owner.
GC-23.
ASSIGNMENTS:
1. Neither the Contractor nor the Owner shall sell, transfer,
assign or otherwise dispose of the Contract or any portion
thereof, or his right, title or interest therein, or his
obligations thereunder, without written consent of the other
party.
GC. ] 8
.
GC-24.
INDEMNIFICATION:
.
1. The Contractor will indemnify and hold harmless the Owner and
the Engineer and their agents and employees from and against
all claims, damages, losses and expenses including attorney's
fees arising out of or resulting from the performance of the
work, provided that any such claim, damage, loss or expense is
attributable to bodily injury, sickness, disease or death, or
to injury to or destruction of tangible property, including
the loss of use resulting therefrom; and is caused in whole or
in part by any negligent or willful act or omission of the
Contractor and Subcontractor, anyone directly or indirectly
employed by any of them or anyone for whose acts any of them
may be liable.
.
.
.
2. In any and all claims against the Owner or the Engineer or any
of their agents or employees, by an employee of the
Contractor, Subcontractor, anyone directly or indirectly
employed by any of them, or anyone for whose acts any of them
may be liable, the indemnification obligation shall not be
limited in any way by any limitation on the amount or type of
damages, compensation or benefits payable by or for the
Contractor or any Subcontractor under Workman's Compensation
acts, disability benefit acts or other employee benefits acts.
-
-
3. The obligation of the Contractor under this paragraph shall
not extend to the liability of the Engineer, his agents or
employees arising out of the preparation or approval of maps,
drawings, opinions, reports, surveys, change orders, design or
specifications.
GC-25.
SEPARATE CONTRACTS:
l. The Owner reserves the right to let other contracts in
connection with this Project. The Contractor shall afford
other contractors reasonable opportunity for the introduction
and storage of their materials and the execution of their work
and shall properly connect and coordinate his work with
theirs. If the proper execution or results of any part of the
Contractor's work depends upon the work of any other
Contractor, the Contractor shall inspect and promptly report
to the Engineer any defects in such work that render it
unsuitable for such proper execution and results.
2. The Owner may perform additional work related to the Project
by himself or he may let other contracts containing provisions
similar to these. The Contractor will afford the other
Contractors who are parties to such contracts (or the Owner,
if he is performing the additional work himself), reasonable
opportunity for the introduction and storage of materials and
equipment and the execution of the work and shall properly
connect and coordinate his work with theirs.
OC-19
.
.
3. If the performance of additional work by other Contractors or
the Owner is not noted in the Contract Documents prior to the
execution of the Contract, written notice thereof shall be
given to the Contractor prior to starting any such additional
work. If the Contractor believes that the performance of such
addi tional work by the Owner or others involves him in
addi tional expense or entitles him to an extension of the
contract time, he may make a claim therefor as provided in
Sections GC-13 and GC-14. .
.
GC-26.
SUBCONTRACTING:
.
1. The Contractor may utilize the services of specialty
Subcontractors on those parts of the work which, under normal
contracting practices, are performed by specialty
Subcontractors.
.
2. The Contractor shall not award work to Subcontractor(s), in
excess of fifty (50%) percent of the Contract Price, without
prior written approval of the Owner.
3. The Contractor shall be fully responsible to the Owner for the
acts and omissions of his Subcontractors, and of persons
either directly or indirectly employed by them, as he is for
the acts and omissions of person directly employed by him.
4. The Contractor shall cause appropriate provisions to be
inserted in all subcontracts relative to the work to bind the
Subcontractors to the Contractor by the terms of the Contract
Documents insofar as applicable to the work of Subcontractors
and to give the Contractor the same power as regards
terminating any subcontract that the Owner may exercise over
the Contractor under any provision of the Contract Documents.
5. Nothing contained in this Contract shall create any
contractual relation between any Subcontractor and the Owner.
GC-27.
ENGINEER'S AUTHORITY:
l. The Engineer shall act as the Owner's representative during
the construction period. He shall decide questions which may
arise as to quality and acceptability of materials furnished
and work performed. He shall interpret the intent of the
Contract Documents in a fair and unbiased manner. The
Engineer will make visits to the site and determine if the
work is proceeding in accordance with the Contract Documents.
2. The Contractor will be held strictly to the intent of the
Contract Documents in regard to the quality of materials,
workmanship and execution of the work. Inspections may be
made at the factory or fabrication plant or the source of
material supply.
OC-20
.
.
3. The Engineer will not be responsible for the construction
means, controls, techniques, sequences, procedures, or
construction safety.
4. The Engineer shall promptly make decisions relative to
interpretation of the Contract Documents.
.
GC-28.
LAND AND RIGHTS -OF-WAY:
.
1. Prior to issuance of Notice to Proceed, the Owner shall obtain
all land and rights-of-way necessary for carrying out and for
the completion of the work to be performed pursuant to the
Contract Documents, unless otherwise mutually agreed.
2. The Owner shall provide to the Contractor information which
delineates and describes the lands owned and rights-of-way
acquired.
-
-
3. The Contractor shall provide at his own expense and without
liability to the Owner any additional land and access thereto
that the Contractor may desire for temporary construction
facilities, or for storage of materials.
GC-29.
GUARANTEE:
1. The Contractor shall guarantee all materials and equipment
furnished and work performed for a period of one (l) year from
the date of substantial completion. The Contractor warrants
and guarantees for a period of one (1) year from the date of
substantial completion of the system that the completed system
is free from all defects due to faulty materials or
workmanship and the Contractor shall promptly make such
corrections as. may be necessary by reason of such defects
including the repairs of any damage to other parts of the
system resulting from such defects. The Owner will give
notice of observed defects with reasonable promptness. In the
event that the Contractor should fail to make such repairs,
adjustments or other work that may be necessary by such
defects, the Owner may do so and charge the Contractor the
cost thereby incurred. The Performance Bond shall remain in
full force and effect though the guarantee period.
GC-30.
TAXES:
1. The Contractor will pay all sales, consumer, use and other
similar taxes required by the law of the place where the work
is performed.
GC-21
.
GC-31.
WORK ADJACENT TO RAILWAY OR OTHER PROPERTY:
.
.
1. Whenever the work embraced in this Contract is near the
tracks, structures or buildings of the Owner or of other
railways, persons, or property, the work shall be so conducted
as not to interfere with the movement of trains or other
operations of the railway, or, if in any case such
interference be necessary, the Contractor shall not proceed
until he has first obtained specific authority and directions
therefor from the proper designated officer of the Owner and
has the approval of the Engineer.
GC-32.
ORDER AND DISCIPLINE:
.
1. The Contractor shall at all" times enforce strict discipline
and good order among his employees and any employee of the
Contractor who shall appear to be incompetent, disorderly or
intemperate or in any other way disqualified for or unfaithful
to the work entrusted to him, shall be discharged immediately
on the request of the Engineer and he shall not again be
employed on the work with the Engineer's written consent.
.
GC-33.
WARNING DEVICES AND SIGNS:
.-
--
l. The Contractor shall furnish, erect, paint and maintain
warning devices when construction is on or near public streets
for the protection of vehicular and pedestrian traffic. Such
devices will be in accordance with the Georgia Manual on
Uniform Traffic Control Devices for Street and Highways, July,
1962, "Traffic Control for Highway Construction and
Maintenance Operations," Section III-l through III-75.
2. On a 20" x 30" sign, mounted on a solid post, 8 feet above the
ground, indicating the name and night phone number of the
Contractor in 4" letters, shall be erected at each end of the
project throughout the construction and maintenance periods.
The Contractor may remove the sign following the maintenance
period.
GC - 34 .
SPECIAL RESTRICTIONS:
l. No work shall be allowed after the hours of darkness or on
Sunday without permission of the Owner.
GC-35.
AS-BUILT DRAWINGS:
l. The Contractor shall furnish to the Engineer three (3) sets of
marked up drawings for an "As-built" record showing all
deviations from the Contract Drawings. The marked up sets
shall include actual dimensions from permanent markers
accurately locating all underground piping.
GC-22
.
GC-36.
CONTRACTOR NOT TO HIRE EMPLOYEES OF THE OWNER:
.
1. The Contractor shall not employ or hire any of the employees
of the Owner.
.
.
.
.-
GC-23
.
.
SECTION SGC-O
INDEX TO SUPPLEMENTAL GENERAL CONDITIONS
SECTION
TITLE
SGC-Ol.
Drawings
.
SGC-02.
Field Office Facilities
SGC-03.
Rights-of-Way
SGC-04.
Estimate of Quantities
.
SGC-05.
Existing Structures and Utilities
SGC-06.
Contractor's Breakdown of Lump Sum Payment Items
SGC-07.
Prior Use By Owner
-
-
SGC-08.
Cleaning Up
SGC-09.
Maintenance of Traffic
SGC-10.
Maintenance of Access
SGC-11.
Erosion Control and Restoration of Property
SGC-12.
Bypassing Sewage
SGC-13.
Safety and Health Regulations
SGC-14.
Pre-Construction Conference
SGC-l5.
General and Supplemental Conditions Not Applicable
To This Contract
SGC-O
.
.
SECTION SGC-O
SUPPLEMENTAL GENERAL CONDITIONS
SGC-Ol.
DRAWINGS:
.
The Owner will furnish to the Contractor, free of charge,
all copies of drawings and specifications reasonably necessary for
the execution of the work. Location of all features of the work
included in the Contract are indicated on the Contract Drawings.
The following drawings comprise,the plans for the Contract:
Note:
The Contract Drawings are listed under Special
Condition SC-02., LIST OF DRAWINGS:.
.
SGC-02.
FIELD OFFICE FACILITIES:
.
The Contractor shall provide, at a point convenient to
the work, suitable office facilities for housing records, plans and
contract documents. A telephone shall be provided at the
Contractor's office for expediting the work and be made available
for the use of the Engineer. A complete and up-to-date set of the
plans and specifications shall be available at the field office at
all times that the work is in progress.
SGC-03.
RIGHTS-OF-WAY:
-
-
The Owner will furnish all land and rights-of-way
necessary for the carrying out of this contract and the completion
of the work herein contemplated and will use due diligence in
acquiring said land and rights-of-way as speedily as possible. But
it is possible that all land and rights-of-way may not be obtained
as herein contemplated before construction begins, in which event
the Contractor shall begin his work upon such land and rights-of-
way as the Owner may have previously acquired and no claim for
damages whatsoever will be allowed by reason of the delay in
obtaining the remaining lands and rights-of-way. Should the Owner
be prevented or enjoined from proceeding with the work or from
authorizing its prosecution, either before the commencement, by
reason of any litigation or by reason of its inability to procure
any lands or rights-of-way for the said work, the Contractor shall
not be entitled to make or assert any claim for damage by reason of
said delay or to withdraw from the contract except by consent of
the Owner; but time for completion of the work will be extended to
compensate for the time lost by such delay; such determination to
be set forth in writing and approved by the Owner.
SGC-04.
ESTIMATE OF QUANTITIES:
The estimated quantities of work to be done and materials
to be furnished under this contract if shown in any of the
documents including the bid are given only for use in comparing
bids and to indicate approximately the total amount of the contract
and the right is especially reserved except as herein otherwise
specifically limited to increase or diminish them as may be deemed
SGC-l
.
.
reasonably necessary or desirable by the Owner to complete the work
contemplated by this contract and such increase or diminution shall
in no way vitiate this contract nor shall any such increase or
diminution give cause for claims or liability for damages.
SGC-OS.
EXISTING STRUCTURES AND UTILITIES:
.
The existence and location of structures and underground
utilities indicated on the plans are not guaranteed and shall be
investigated and verified in the field by the Contractor before
starting work. The Contractor shall be held responsible for any
damage to and for maintenance and protection of existing utilities
and structures.
.
SGC-06.
CONTRACTOR I S BREAKDOWN OF LUMP SUM PAYMENT ITEMS:
-
-
The Contractor shall, immediately after the contract has
been awarded, submit to the Engineer for his approval, a breakdown
showing estimates of all costs apportioned to the major elements of
equipment, material and labor comprising the total work included
under any of the lump sum items shown in the proposal. These
estimates as approved will serve as the basis for estimating of
payments due on all progress estimates.
SGC-07.
PRIOR USE BY OWNER:
Prior to completion of the work, the Owner may take over
the operation and/or use of the incomplete project or portions
thereof. Such prior. use of the facilities by the Owner shall not
be deemed as acceptance of any work or relieve the Contractor from
any of the requirements of the Contract Documents.
SGC-08.
CLEANING UP:
The Contractor shall keep the premises free from the
accumulation of waste material and rubbish and upon completion of
the work, prior to final acceptance of the completed project by the
Owner, he shall remove from the premises all rubbish, surplus
materials, implements, tools, etc., and leave his work in a clean
condition, satisfactory to the Engineer.
SGC-09.
MAINTENANCE OF TRAFFIC:
In any work within the public right-of-way, the
Contractor shall provide adequate warning and protection for
pedestrian and vehicular traffic from any hazard arising out of the
Contractor's operations and will be held responsible for any damage
caused by negligence on his part or by the improper placing of or
failure to display danger signs and road lanterns. All traffic
lanes, sidewalks and driveways will be kept open and clear at all
times except as provided below. The Contractor shall not block
traffic on any street more than 30 minutes or without written
permission from such agency. Before leaving the work each night,
it shall be placed in such condition as to cause the least possible
SGC-2
.
.
hazard therefrom. Should the Contractor fail to comply with the
provisions of this paragraph, the Owner may, with his own forces,
provide signs, flagmen, barricades and/or passageways or clear the
pavement and deduct the cost thereof from sums due to the
Contractor.
SGC-10.
MAINTENANCE OF ACCESS:
.
The Contractor will be required to maintain access to
business establishments during all time they are open for business,
to churches, schools and other institutions during the time they
are open and to all residential and other occupied buildings or
facili ties at all times. Bridges across open trenches and work
areas will be required to provide vehicular and pedestrian access.
Bridges with handrail protection will be required for crosswalks at
street intersections. It is recognized that it will be necessary
to remove bridges and to block cross traffic while equipment is in
operation. The Contractor shall, however, plan and pursue his
operations so as to minimize the time that direct entrance is
blocked.
-
-
-
...
SGC-ll.
EROSION CONTROL AND RESTORATION OF PROPERTY:
The Contractor will be required to schedule his work and
perform operations in such a manner that siltation and bank erosion
will be minimized during all phases of construction. Any areas
disturbed during the course of construction shall be restored to a
condition equal or better than the original condition.
SGC-12.
BYPASSING SEWAGE:
The Contractor will be required to schedule and
coordinate construction sequences and to use temporary construction
and other approved methods which will minimize the bypassing of
sewage during construction of the sewer facilities. The diversion
of sewerage to open ditches or streams will not be permitted.
SGC-13.
SAFETY AND HEALTH REGULATIONS:
The Contractor shall comply with the Department of Labor
Safety and Health Regulations for construction promulgated under
the Occupational and Health Act of 1970 (PL3l-596) and under
Section 107 of the Contract Work Hours and Safety Standards Act
(PL9l-54).
SGC-14.
PRE-CONSTRUCTION CONFERENCE:
A pre-construction conference shall be held at an
acceptable time to the Owner and the Contractor prior to the
"Notice to Proceed" to coordinate the work and satisfy all
requirements of the Contract Documents.
SGC-3
-
-
SGC-15.
GENERAL AND SUPPLEMENTAL CONDITIONS NOT APPLICABLE TO
THIS CONTRACT:
...
-
The sections listed in SGC-Appendix A shall not apply to
this contract and shall be construed as not existing.
.-
SGC-4
.
SUPPLEMENTAL GENERAL CONDITIONS
.
APPENDIX A
SGC-01. The following sections of Supplemental General Conditions
shall be deleted from the Contract Documents:
.
SGC-02. Field Office Facilities
SGC-10. Maintenance of Access
SGC-12. Bypassing Sewage
.
.
-
SGC-5
.
SECTION SC - 0
SPECIAL CONDITIONS
.
SC-Ol.
SCOPE:
.
The project referred to in the Agreem~nt sh~ll consist
Runway Safety Overrun Area Paving at Daniel Fleld Alrport,
(Runway 11-29).
of
SC-02.
LIST OF DRAWINGS:
.
The following drawings, prepared by Augusta-Richmond
County Engineering Department comprise the plans for the project.
Sheet
Date
No.
Title
Oriainal
Revised
-
-
Applicable drawings are included in appropriate Technical Specifica-
tion area.
SC-03.
PROTECTION OF THE ENVIRONMENT:
The Contractor will carefully schedule his work so that
a minimum amount of exposed earth will be subject to erosion by
rainfall or wind, and he will provide means satisfactory to the
Engineer to minimize the transportation of silt and other
deleterious material into the stream beds of water courses adjacent
to the project.
All chemicals used during project construction or
furnished for proj ect operation, whether herbicide, pesticide,
disinfectant, polymer, reactant or of other classification, must
show approval of either EPA or USDA. Use of all such chemicals and
disposal of residues shall be in conformance with printed
instructions. -
SC-04.
TEMPORARY TOILETS:
Contractor shall provide temporary toilet facilities on
the site for workmen employed in the construction work. Toilets
shall be adequate for the number of men employed and shall be
maintained in a clean and sanitary condition. Workmen shall be
required to use only these toilets. At completion of the work,
toilets used by Contractor shall be removed and premises left in
the condition required by the Contract.
5C-0
.
SC-05.
PLANS AND SPECIFICATIONS FURNISHED:
.
The Contractor will be furnished, free of charge, by the
Owner up to five (5) sets of direct blue line prints together w~th
a like number of complete bound specifications for construct~on
purposes. Additional sets of plans and/or specifications will be
furnished to the Contractor at the cost of reproduction upon his
written request.
.
SC-06.
EXISTING STRUCTURES:
.
Where sidewalks, street signs, private signs, walls,
sidewalks, fences, etc, are removed in accomplishing the work, each
and every item will be replaced in the same or better manner or
condition than that in which it was before construction began. The
Contractor will protect and hold harmless the Owner from any suit,
action, or dispute whatever arising from the Contractor I s work
adjacent to private property.
SC-07.
SALVAGE MATERIAL:
-
..
All grates, railroad ties, cobblestones, granite curbing,
manhole frames and covers, will remain the property of the Owner
and will be stockpiled at the Public Works Department, 1568 Broad
Street, in the manner directed by the Engineer.
SC-08.
REFERENCED SPECIFICATIONS:
Where specifications or standards of trade organizations
and other groups are referenced in these specifications, they are
made as much a part of these specifications as if the entire
standard or specification were reprinted herein. The inclusion of
the latest edition or revision of the referenced specification or
standard is intended.
SC-09.
TRAFFIC CONTROL:
Traffic control shall conform to the Manual on Uniform
Traffic Control Devices (MUTCD) of the Federal Highway
Administration, Edition of 1978. The Contractor shall give prior
written notification to and shall obtain the approval of the
Augusta-RiChmond County Fire and Police Department of any street
closures.
SC-10.
CONSTRUCTION ORDER AND SCHEDULE:
1. The Contractor shall be responsible for the detailed order,
schedule, and methods of construction activities within the
general guidelines specified for maintenance and protection of
highway and pedestrian, traffic; utility lines; drainage ways;
adjacent properties; and as otherwise specified.
SC-l
.
2. After notice to proceed and prior to the first payment on the
contract the Contractor shall submit the following for review:
A.
Breakdown of contract price into units of cost for each
item required to complete the total work; this breakdown
will be the basis for judging the percentage complete at
any time.
.
B.
A statement of the order of procedure to be followed that
will result in the required protection and completion of
the work within the contract time.
.
C. A bar chart showing the percentage of each item schedules
against time and so scheduled that Contractor's order of
construction is clearly shown.
.
3. With each request for payment the contractor shall submit two
copies of the bar chart clearly marked to show the work
completed at the date of the payment requested.
-
-
SC-ll.
CONSULTING ENGINEERS:
The Owner may engage consulting engineers to assist the
City Engineer, by preparing plans and specifications for the work
and by providing certain services during the bidding and
construction phases of the project. The consulting engineer,____
are authorized to represent the City Engineer within the
limits of the various duties delegated and assigned to the firm by
the City Engineer. Nevertheless the City Engineer remains the
final authority hereunder and is the "Engineer" as used throughout
the Contract Documents.
SC-12.
INSPECTION:
The Owner shall provide sufficient competent engineering
personnel for the technical observation and testing of the work.
The Engineer and his representatives shall at all times
have access to the work whenever it is in preparation or progress,
and the Contractor shall provide proper facilities for such access,
and for inspections.
Inspectors shall have the power to stop work on account
of a workman's incompetency, drunkenness, or willful negligence or
disregard of orders. An inspector may stop the work entirely if
there is not a sufficient quantity of suitable and approved
materials or equipment on the ground to carry it out properly or
for any good and sufficient cause. Inspectors may not accept on
behalf of the Owner any material or workmanship which does not
conform fully to the requirements of the contract and they shall
give no orders or directions under any possible circumstances not
in accordance with the Specifications. The Contractor shall
furnish the inspector with all required assistance to facilitate
SC-2
.
.
thorough inspection or the culling over or removal of defective
materials or for any other purpose requiring discharge of their
duties for which service no additional allowance shall be made.
The inspector shall, at all times, have full permission to take
samples of the materials that mayor may not be used in the work.
.
Any inspection provided by the Engineers is for the
purpose of determining compliance with provisions of the contract
specifications and is in no way a guarantee of the methods or
appliances use by the Contractor, nor for the safety of the job.
-
If the specifications, the Engineer's instructions, laws,
ordinances, or any public authority require any work to be
specially tested or approved, the Contractor shall give the
Engineer timely notice of its readiness for inspection, and if the
inspection is by an authority other than the Engineer, of the date
fixed for such inspection. Inspections by the Engineer shall be
made promptly, and where practicable at the source of supply. If
any work should be covered up without review or consent of the
Engineer, it must, if required by the Engineer, be uncovered for
examination and properly restored at the Contractor's expense.
Re-examination of any work may be ordered by the
Engineer, and, if so ordered, the work must be uncovered by the
Contractor. If such work is found to be in accordance with the
Contract Documents, the Owner shall pay the cost of re-examination
and replacement. I f such work is not in accordance with the
Contract Documents, the Contractor shall pay such cost.
SC-3
.
SCOPE OF WORK
.
This project shall consist of the following work at the Daniel
Field Airport:
-
A. Soil Sterilization and Cleaninq: A mixture of herbicide and
soil sterilant chemicals in accordance with project Special
provision Section 408.02A shall be applied to all vegetated
areas of pavement a minimum of two weeks prior to scheduling
cleaning and sealing operations.
Cleaninq: All cracks shall be cleaned to the satisfaction of
the Engineer prior to paving Joints and cracks shall be free of
vegetation, dirt, dust, moisture and other foreign material.
B. Resurfacinq: Areas identified on Sheet SP-2 shall be
resurfaced with 145 lbs. per square yard asphaltic concrete
"F", GP 1 or 2 inCluding bituminous material. Note that
Special provision 828 specifies that the design optimum
air voids for resurfacing mixes on airport construction shall
be 3.5 ~ 0.5% tapering to existing pavements shall be to the
satisfaction of the Engineer and shall be accomplished in such
a manner as to avoid a "hump" or "dip" and to leave no loose
aggregate. (See Special provision 828, Page SP-l)
Sinqle Surface Treatment Seal, Stone Size 7: A single surface
treatment seal, stone size 7 shall be placed on all pavements
to be resurfaced. Applicable portions of Georgia Department of
Transportation Specifications, Section 424 shall apply to this
project.
C. Pavement Markinq: Layout and paving of runway pavement
markings shall be in accordance with project details and
Special provision Section 652 - Painting Traffic Stripe
(applicable to airport) .
SW-l
.
GENERAL NOTES
.
Contractor shall provide 48 hours notice to and receive approval
from the Airport Manager prior to commencing any work.
.
The Airport Manager shall be responsible for issuing NOTAMs (Notice
to Airmen) through the Flight Service Station in accordance with
established procedures. It is important that NOTAMs be kept
current and reflect actual conditions with respect to construction
situations.
-
-
Contractor shall provide for the free and unobstructed movement of
aircraft during the time that work under this contract is being
performed. Contractor shall provide barricades, markings, lighting
and other means of identifying: Personnel, Equipment, Vehicles,
Storage Areas and any work area or condition that may be hazardous
to the operation of aircraft, as deemed necessary by the Engineer
and/or Airport Management.
-.
This proj ect shall be cons tructed in accordance wi th Georgia
Department of Transportation 1993 Specifications, Supplemental
Specifications, 1989 Edition and Project Special Provisions.
The Contractor shall provide two-way radio communication as deemed
necessary by the Engineer and/or Airport Management. Radio must be
manned at all times during working hours by a qualified operator
and shall be operated in conjunction with flag men and adequate
public address or other loud speaker system, as appropriate, so
that instructions may be immediately passed on to the contractor's
personnel. Failure to maintain the specified communications or to
obey instructions shall be cause for suspension at the contractor IS
operations until satisfactory conditions are provided.
Airport management will designate an area to be used by the
Contractor for a staging area. The staging area shall be used as
a site for the Contractor's field office, for stockpiling
materials, as a site for parking construction equipment, as an
automobile parking area and in general as a base of operations for
the contractor.
Airport Management will designate an access route to the project
site. The Contractor will be expected to use this route for
ingress and egress unless an alternate route is approved by
Engineer and Airport Management.
Contractor shall not be allowed to start work until a sufficient
number of days of good weather is forecast. Once work is started
Contractor is expected to be working everyday until work is
satisfactorily completed.
GN-1
.
General Notes cont'd.
.
Waste and loose material capable of causing damage to aircraft
landing gears, propellers or being ingested in jet engines should
not be placed on active aircraft movement areas. Materials tracked
on these areas shall be removed continuously during the work
proj ect.
.
Vehicular traffic crossing active airport operating areas must be
controlled either by two-way radio communication with the airport
operator who can communicate with aircraft, by escort, flagman or
means acceptable to the Engineer and Airport Management. The
clearance should be confirmed by the driver's personal observation
that no aircraft is approaching his position. Vehicles operating
during periods of darkness or poor visibility shall be equipped
with a flashing dome-type light, the color to be in accordance with
local and or state codes.
.
.
Contractor is cautioned that airport pavements are not designed to
handle the loads that highways are capable of handling. It shall
be the responsibility of the Contractor, Area Engineer and Airport
Management to inspect the pavement condi tion and determine the
allowable weights of equipment and material trucks to be used. If
pavement begins to show signs of failure under allowable loads, the
Engineer and Contractor shall immediately take action to correct
the problem. Contractor shall repair any pavement damaged by
trucks and/or equipment at no additional cost to the Department or
Airport Management.
Contractor shall be responsible for replacing or satisfactorily
repairing any damaged lights, fixtures, navigational aids, etc.
Upon completion of the work the Contractor shall restore all
disturbed areas inside and outside project limits to their original
condition. This shall include the removal and proper disposal of
all material, dirt, vegetation, aggregate, etc. from runway paved
and grassed shoulders, left as a result of this project.
All costs incurred in complying with the above requirements, shall
be considered incidental to the work under this contract and no
additional payment therefore shall be made.
GN-2
.
RUNAWAY SAFETY OVERRUN AREAS PAVING
.
SPECIAL PROVISION
SECTION 725 - SOIL STERILIZATION - AIRPORT CONSTRUCTION
Delete Section 725 as written and substitute the following:
.
725.01 DESCRIPTION: This work consists of furnishing and applying
a soil sterilant and then cleaning soil and vegetation to the level
of existing airport pavements before resurfacing.
.
725.02 MATERIALS: The soil sterilant shall contain one chemical
from each of the fOllowing groups (except where noted) :
Group Common Name
1 Dalapon
Gylphosate
. 2 Bromacil
prometon
Hexazinone
Quantity of Active Inqredient Required
10 lbs. per acre
3 lbs. per acre
6 Ibs. per acre
20 lbs. per acre
6 lbs. per acre
3
A non-ionic surfactant containing
alkyl poloxyethylene ether
2 qts. per 100
gallons sprayable
mixture
.
Listed below are trade names and rates of products which will
provide the quantity of active ingredient required above Similar
chemicals will be acceptable when approved by the Laboratory.
-
--
Trade Names
Rate
Per Acre
Manufacturer
Group
Trade Name
1
Dowpon M
13.5 lbs.
Dow Chemical Company
Agricultural Products
Dept. Midland, MI 48640
Roundup *
3 Qts.
Monsanto Co. MAP
800 North Lindbergh
St. Louis, Missouri 63166
*When Roundup is used the surfactant (Group 3) may be deleted.
SP - 1
.
.
Rate
Group Trade Name Per Acre
2 Hyvar X 7.5 lbs.
Hyvar X-L 3 gals.
Velpar 7 lbs.
Velpar L 3 gals.
pramitol 24E 10 gals.
pramitol 80% WP 25 lbs.
Ontrack WE-2 10 gals.
Ontrack 800 25 Ibs.
.
.
3 Wet Aid
2 Qts. per
100 gals
sprayable
mixture
X-77
2 Qs. per
100 gals.
sprayable
mixture
.
-
Surfactant WK
2 Qts. per
100 gals.
sprayable
mixture
Manufacturer
E.I. DuPont DeNemours & Co., Inc.
Sales Order Center
Biochemical Department
wilmington, Delaware 19898
Ciba-Geigy Corp.
Agricultural Division
Sawmill River Road
Ardsley, New York 10502
Woolfolk Chemical Works, Ltd.
P.O. Box 938
Fort Valley, Georgia 31030
Chevron Chemical Co.
Ortho Division
200 Bush Street
San Francisco, California 94120
E.I. DuPont DeNomours & Co., Inc.
Sales Order Center
Biochemical Department
Wilmington, Delaware 19898
725.03 APPLICATION: The soil sterilant shall be applied to all
areas indicated on Plans or directed by the Engineer at a time
acceptable to the Engineer. The soil sterilants shall be applied
at the above rates using a minimum of 40 and maximum of 100 gallons
of water per acre. The rates shown shall not be exceeded and no
other active ingredient shall be used in combination with these
chemicals.
Care shall be exercised to prevent spillage on slopes or other
grassed areas. Any vegetated areas that are damaged by the
careless handling of sterilants shall be repaired at the
Contractor's expense.
There shall be at least a two week waiting period after the soil
sterilant has been applied before cleaning soil and vegetation to
the level of the existing pavement.
725.04 MEASUREMENT: Application of soil sterilant an cleaning and
vegetative growth removal will not be measured separately for
payment.
725.05 PAYMENT: Furnishing and applying soil sterilant and
SP - 2
.
.
satisfactory cleaning and vegetative growth removal as specified
above will be paid for at the unit contract price bid. Such
payment shall be full compensation for furnishing all materials and
performing all work necessary to complete the item in accordance
with this specification.
Payment will be made under:
.
Item No. 725 - Soil Sterilization and Cleaning
Sum.
Lump
.
.
-
-
SP - 3
.
.
~
. ~
--4
~
~
. 0
- i
-
~
8' ~) -;
TO P.
-
-
'::.... ":smfp~'.Wr."''r'L.I::
... ...... ,(=(W)";I\o',lrJ , .
. ....... .. ......
. ........ ...... .
RUNWAY
11-29
SOIL STERILIZATION AREA
SCALE: 1....100.
ALl DOTTED HATCHED AREA
SP - 4
ARC ENGINEERING DEPT.
OW: N035I.
AUGUST 23. 18te
.
RUNWAY SAFETY OVERRUN AREAS
DANIEL FIELD AIRPORT
.
SPECIAL PROVISION
AIRPORT PROJECTS
.
SECTION 828-HOT MIX ASPHALTIC CONCRETE MIXTURES
828.03 Dense Graded Intermediate and Surface Mixtures:
Retain as written and "add the following:
.
The Design Optimum Air Voids for mixes in this Sub-Section used as
Surface Mixes on Airport Construction shall be 3.5% + 0.5% in lieu
of the 4.5% specified. This change in the mixture shall be
effected by increasing the asphalt cement requirement of any
current approved design as necessary to decrease the air voids to
3.5% + 0.5%.
-
-
-
-
SP - 1
.
\
"f-
I- z;' 1 \
.
.
~~
" 40' 40' /
"
v
8 I" /
co
II'
II'
. '" /
~
~
" V
~
"
" /
1()!-
150'
RUNWAY
11-29
-
-
-
-
-
--
z
~
<;]:
..-\
~
~
o
"f-
\
~
\
"f-
\
y..
\
y..
\
y..
\
y..
\
?J
o
~
HOT MIX RESURFACING AREA
SCALE: 1-=100'
SP - 2
ARC ENGINEERING DEPT.
DWQ: NOJ5C
AUGUST 23, 1tN
.
.
RUNWAY SAFETY OVERRUN AREA PAVING
PROJECT SPECIAL PROVISION
SECTION 402 - HOT MIX RECYCLED ASPHALTIC CONCRETE
.
Retain as written.
402.05 Payment:
Payment will be made under:
..
-
Item No. 402 - Recycled Asphaltic Concrete "F" GP 1 or 2
inCluding bituminous material... per ton.
SP - 1
.
.
RUNWAY SAFETY OVERRUN AREA PAVING
SPECIAL PROVISION
SECTION 424 - BITUMINOUS SURFACE TREATMENT
.
Retain as written.
427.07 PAYMENT; Payment will be made under:
~
~
Item No. 424. Single Surface Treatment
Stone Size 7 , Group 1 or 2 ....... .Per Square Yard.
...
...
SP - 1
.
.
~
~
. ~
..-\
~
~
-. 0
...
8
fO
-;A)
o
~
"0
~
, o'
RUN AY
11 29
SINGLE SURFACE TREATMENT AREA
SCALE: '.....'00.
SP - 2
NtC ENGINEERINO DfPT.
cwo: 8I03l5B
AUGUST .23, 1181
.
RUNWAY SAFETY OVERRUN AREAS
DANIEL FIELD AIRPORT
.
SPECIAL PROVISION
SECTION 652-PAINTING TRAFFIC STRIPE
Delete Section 652 in its entirety and substitute the following:
.
652.01 DESCRIPTION: This item shall consist of the painting of
numbers, markings and stripes on the surface of runways and
taxiways applied in accordance with these Specifications and at the
locations shown on the Plans or as directed by the Engineer.
-
-
652.02 MATERIALS:
A. The paint for painting numbers, markings and stripes shall
meet the requirements of Federal Specifications TT-P-1952
(Water Emulsion Base). White paint shall be designated as
Type 1. Yellow paint shall be designated as Type 2.
B. The paint for outlining numbers, markings and stripes on
concrete pavements shall meet the requirements of Federal
Specifications TT-P-110. TT-P-110 is a black oil base
paint and shall be designated as Type 3.
C. The paint used to cover old numbers, markings and stripes,
designated as Type 4, shall be a shade of gray that blends
with the color of existing pavement to satisfaction of the
Engineer. Type 4 paint shall consist of Type 1 paint
(white, Federal Specification TT-P-1952) and Lamp Black,
ASTM: D209. Lamp Black shall be added to Type 1 paint
until an acceptable shade of gray is produced.
D. Glass Spheres:
1. Class A - Glass Spheres are required and shall meet the
requirements of Federal Specification TT-B-1325, Type
III Gradation A.
2. Class B - Glass Spheres are not required.
652.03 EQUIPMENT: All equipment for the work shall be approved by
the Engineer and shall include the apparatus necessary to properly
clean the existing surface, a mechanical marking machine, and such
auxiliary hand painting equipment as may be necessary to
satisfactorily complete the job.
SP - 1
.
.
The mechanical marker shall be an atomizing spray- type marking
machine suitable for application of traffic paint. It shall
produce an even and uniform film thickness at the required coverage
and shall be designed so as to apply markings of uniform cross
section and clear-cut edges without running or spattering.
652.04 CONSTRUCTION:
.
A. WEATHER LIMITATIONS: The painting shall be performed only
when the surface is dry, when the atmospheric temperature
is above 45 degrees F. and when the weather is not foggy
or windy.
-
-
B. PREPARATION OF SURFACE: Immediately before application of
the paint, the surface shall be dry and free from dirt,
grease, oil, laitance or other foreign material which
would reduce the bond between the paint and the pavement.
The area to be painted shall be cleaned by sweeping and
blowing or by other methods as required to remove all
dirt, laitance and loose material.
C. LAYOUT OF MARKINGS: On those sections of pavement where
no previously applied markings are available to serve as
a guide or where markings are to be revised, the proposed
markings shall be laid out in advance of the paint
application.
D. APPLICATION: Markings shall be applied at the locations
and to the dimensions and spacing shown on the Plans.
Paint shall not be applied until the layout and condition
of the surface have been approved by the Engineer.
The paint shall be mixed in accordance with the
manufacturer's instructions and applied to the pavement
with a marking machine at the following rates:
1. On new pavements and resurfaced pavements. . . .. 100 -110
square feet per gallon.
2. On old unmarked pavements and over previOUSly applied
markings.... 60-80 square feet per gallon
The addition of thinner will not be permitted. A period
of 48 hours shall elapse between placement of a bi tuminous
surface course or seal coat and application of the paint.
The edges of the markings shall not vary from a straight
line more than 1/2 inch in 50 feet, and the dimensions
shall be within a tolerance of plus or minus 5 percent.
When required, glass spheres shall be distributed to the
surface of the marked areas immediately after application
of the paint. A dispenser shall be furnished which is
properly designed for attachment to the marking machine
SP - 2
...
-
.
and suitable for dispensing glass spheres. The spheres
shall be applied at the rate of 10 pounds per gallon of
paint.
.
The Contractor shall furnish certified test reports for
the materials shipped to the project. The reports shall
not be interpreted as a basis for final acceptance. The
Contractor shall notify the Engineer upon arrival of a
shipment of paint to the jOb site. All emptied containers
shall be made available for inspection by the Engineer.
The containers shall not be removed from the airport or
destroyed until authorized by the Engineer.
.-
-
E. PROTECTION: After application of the paint, all markings
shall be protected from damage until the paint is dry.
All surfaces shall be protected from disfiguration by
splatter, splashes, spillage or drippings of paint.
F. CORRECTIVE MEASURES: All work shall be subject to
application rate checks for both paint and glass spheres.
All work which fails to meet the specifications,
permissible tolerances and appearance requirements, or is
marred or damaged by traffic or from other causes, shall
be corrected at the Contractor's expense. All misted
areas, drip and spattered paint shall be removed to the
satisfaction of the Engineer. In all instances, when it
is necessary to remove paint it shall be done by means
satisfactory to the Engineer, which will not damage the
underlying surface of the pavement.
652.05 MEASUREMENT: The quantity of runway and taxiway markings
to be paid for shall be the number of square yards of paint, or one
complete item in place, performed in accordance with the
specifications and accepted by the Engineer.
625.06 PAYMENT: Payment for Runway and Taxiway painting and
Markings shall be made at the contract unit price bid per square
yard, or contract lump sum bid for each Paint Type and Glass Sphere
Class. This price shall be full compensation for furnishing all
materials for all labor, equipment, tools and incidentals necessary
to complete the item.
Payment will be made under:
- ,
Item No. 652 Runway and Taxiway Painting and Marking
(Paint Type) (Glass Sphere Class) . . . per square yard
Item No. 652 Runway and Taxiway Painting and Marking
(Paint Type) (Glass Sphere Class)
. Lump Sum
SP - 3
-
-
.
z.
~
. ~
.-\
~
.- ~
- 0
8
co
5' (TYP)
TO E.P.
b
~
25'
T
1 ·
-~
150.
RUNWAY
11- 29
..
PAVEMENT MARKING
.-,
11f"
SCALE: 1--100'
SP - 4
:x3
o
~
NtC E:NCIIHEERING DEPT.
DWO: lNlCWO
AUGUST 23. 1_
~l'~ ;.f' ~ 1 " I . . .'
: i i. ri ~J; ",.:,. : '
i4,' hl 1\.1 ,,~V" '.' ". . '.0
... ,~~" 1" ~t ' '
[J.:>'\' f'.t. "
{Ol ~
~. '\ t
~,<;,~~.,
t,. ~.~.
dUb t::'_, ,:
1"
. .
", ~ ,\ '<~. -', :.. ~.
, l,' ' ", ' " ~, '- ~,
\ \ I'" I: . ~ f" '" - -\ .
:, ,'. ~1"'" ".;t ,,' '~i ~'I ~,~r;
, I' \ '.' ~': i' lU;' ,.~ lJ
. ~ ,\.\ \1 1-.1 ". ~
II :;.. I , .' ' :, d: 'fl t,~ '
,,0 \' L; \.J,y ,U\:f
3
7 '/-
_ __~._--c-~
" .'
~ u tt.v,.fft'1 S;t~ .ovfDUU1N If~
A. u &-0 sTY't
J()/L
C; (",. 0 0-J~ :3 J.-II
.
rFlll.h tV~
....
-
.
.
.
-.
-
f"--;:'
/
,
~
....,
.-
~
",-
.~.
"{'
l,~
, ,,.,