Loading...
HomeMy WebLinkAboutCrane Creek Channel Improvements Augusta Richmond GA DOCUMENT NAME: ("Vctne C){ce~ LhOLnh~\ =-C h1"\./Y"O vehle~ DOCUMENT TYPE: UJ VI -\-vact- YEAR: JCJCf<:j BOX NUMBER: 5 FILE NUMBER: 13~% NUMBER OF PAGES: IOC) I I I I I I I I I I I I I I I I I I I LIST OF PROJECT DOCUMENTS Crane Creek Channel Improvements Project Number: 55-8369-323 SECTION PAGES Instruction to Bidders IB-I thru IB-3 Georgia Prompt Pay Act PPA-I Minority and Economically Disadvantaged Business Support ME-I Special Conditions SP-I thru SP-3 Special Provisions SPP-I Agreement A-I thru A-4 General Conditions 1 thru 33 Supplementary Conditions SC-I thru SC-2 Proposal P-I thru P-3 General Notes G-I thru G-13 Traffic Control TC-I thru TC-23 Corps of Engineers Permit COE-I thru COE-13 I I I I I I I I I I I I I I I I I I I SECTION IB INSTRUCTION TO BIDDERS IB-Ol GENERAL All proposals must be presented in a sealed envelope, addressed to the Owner. The proposal must be filed with the Owner on or before the time stated in the invitation for bids. Mailed proposals will be treated in every respect as though filed in person and will be subject to the same requirements. Proposals received subsequent to the time stated will be returned unopened. Prior to the time stated any proposal may be withdrawn at the discretion of the bidder, but no proposal~ay be withdrawn for a period of sixty (60) days after bids have been opened, pending the execution of contract with the successful bidder. IB-02 EXAMINATION OF WORK Each bidder shall, by careful examination, satisfy himself as to the nature and location of the work, the conformation of the ground, the character, quality and quantity of the facilities needed preliminary to and during the prosecution of the work, the general and local conditions, and all other matters which can in any way affect the work or the cost thereof under the contract. No oral agreement or conversation with any officer, agent, or employee of the Owner, either before or after ,the execution of the contract, shall affect or modify any of the terms or obligations therein. IB-03 ADDENDA AND INTERPRETATIONS No interpretation of the meaning of plans, specifications or other prebid documents will be made to any bidder orally. Every request for such interpretation should be in writing addressed to the Director of Public Works, 1815 Marvin Griffin Road, Augusta, Georgia 30906, and to be given consideration must be received at least five days prior to the date fixed for the opening of bids. Any and all such interpretations and any supplemental instructions will be in the form of written addenda to the specifications which, if issued, will be sent by certified mail with return receipt requested to all prospective bidders (at the respective addresses furnished for such purposes), not later than three days prior to the date fixed for the opening of bids. Failure of any bidder to receive any such addendum or interpretation shall not relieve such bidder from any obligation under his bid as submitted. All addenda so issued shall become part of the Contract Documents. IB-l I I I I I I I I I I I I I I I I I I I 1B-04 PREPARATION OF BIDS Bids shall be submitted on the forms provided and must be signed by the bidder or his authorized representative. Any corrections to entries made on bid forms should be initialed by the person signing the bid. Bidders must quote on all items appearing on the bid forms, unless specific directions in the advertisement, on the bid form, or in the special specifications allow for partial bids. Failure to quote on all items may disqualify the bid. When quotations on all items are not required, bidders shall insert the words "no bid" where appropriate. Alternative bids will not be considered unless specifically called for. Telegraphic bids will not be considered. Modifications to bids already submitted will be allowed if submitted by telegraph prior to the time fixed in the Invitation for Bids. Modifications shall be submitted as such, and shall not reveal the total amount of either the original or revised bids. Bids by wholly owned proprietorships or partnerships will be signed by all owners. Bids of corporations will be signed by an officer of the firm and his signature attested by the secretary thereof who will affix the corporate seal to the proposal. NOTE: A 10% Bid Bond is required in all cases. IB-05 BASIS OF AWARD The bids will be compared on the basis of unit prices, as extended, which will include and cover the furnishing of all material and the performance of all labor requisite or proper; and completing of all the work called for under the accompanying contract, and in the manner set forth and described in the specifications. Where estimated quantities are included in certain items of the proposal, they are for the purpose of comparing bids. While they are believed to be close approximations, they are not guaranteed. It is the responsibility of the Contractor to check all items of construction. In case of error in extension of prices in a proposal, unit bid prices shall govern. IB-2 I I I I I I I I I I I I I I I I I I I IB-06 BIDDER'S OUALIFICATIONS No proposal will be received from any bidder unless he can present satisfactory evidence that he is skilled in work of a similar nature to that covered by the contract and has sufficient assets to meet all obligations to be incurred in carrying out the work. He shall submit with his proposal, sealed in a separate envelope, a FINANCIAL EXPERIENCE AND EQUIPMENT STATEMENT, giving reliable information as to working capital available, plant equipment, and his experience and general qualifications. The Owner may make such investigations as are deemed necessary to determine the ability of the bidder to perform the work and the bidder shall furnish to him all such additional information and data for this purpose as may be requested. The Owner reserves the right to reject any bid if the evidence submitted by the bidder or investigation of him fails to satisfy the Owner that such bidder is properly qualified to carry out the obligations of the contract and to complete the work contemplated therein. Part of the evidence required above shall consist of a list of the names and addresses of not less than five (5) firms or corporations for which the bidder has done similar work. IB-07 PERFORMANCE BOND At the time of entering into the contract, the Contractor shall give bond to the Owner for the use of the Owner and all persons doing work or furnishing skill, tools, machinery or materials under or for the purpose of such contract, conditional for the payment as they become due, of all just claims for such work, tools, machinery, skill and terms, for saving the Owner harmless from all cost and charges that may accrue on account of the doing of the work specified, and for compliance with the laws pertaining thereto. Said bond shall be for the amount of the contract satisfactory to the Owner and authorized by law to do business in the State of Georgia. Attorneys-in-fact who sign bonds must file with each copy thereof a certified and effectively dated copy of the power of attorney. IB-08 REJECTION OF BIDS These proposals are asked for in good faith, and awards will be made as soon as practicable, provided satisfactory bids are received. The right is reserved, however to waive any informalities in bidding, to reject any and all proposals, or to accept a bid other than the lowest submitted if such action is deemed to be in the best interest of the Owner. IB-3 I I I I I I I I I I I I I I I I I I I GEORGIA PROMPT PAY ACT This contract is intended by the parties to, and does, supersede any and all provisions of the Georgia Prompt Pay Act, o. C. G. A. Section 13-11-1, et seg. In the event any provision of this Contract is inconsistent with any provision of the Prompt Pay Act, the provision of this contract shall control. NOTICE All references in this document, which includes all papers, writings, drawings, plans or photographs to be used in connection with this document, to "Richmond County Board of Commissioners" shall be deemed to mean "Augusta-Richmond County cornmission- Council and all references to "Chairman" shall be deemed to mean "Mayor". DISPOSALS Prior to any material from this project being wasted or otherwise disposed of outside the project limits the Contractor shall furnish the Engineer a copy of written permission, signed by the property owner (or his authorized agent) describing the estimated amount and type of material to be placed on said property. If any portland cement concrete, asphaltic concrete, wood or other such materials are to be wasted on the property, a copy of the owner's inert landfill permit, issued by the Environmental Protection Division shall be furnished to the Engineer prior to any such waste being removed from the project. In all cases, regardless of the material being wasted, a grading permit issued by Augusta-Richmond County must be furnished to the Engineer. PPA-1 I I I I I I I I I I I I I I I I I I I MINORITY AND ECONOMICALLY DISADVANTAGED BUSINESS SUPPORT It is the intent of the Augusta-Richmond County- council to increase the involvement of qualified minority and economically disadvantaged businesses in the contracted work of County Government. In an effort to support this intention, this project is offered to all qualified firms. The bids will be evaluated based on qualifications, price and construction time . with all other items being considered equal, the contract, if awarded will be awarded to a minority and economically disadvantaged firm or a firm that has included such firms as subcontractors on this project. The bidders shall include with their bid a statement of qualification for themselves and/or any qualified subcontractors explaining why they should be considered a minority or economically disadvantaged firm. If the firm does not fall into this category, no information is necessary. ME-l I I .1 I I I I I I I I I I I I I I I I CRANE CREEK CHANNEL IMPROVEMENTS project Number: 55-8369-323 SPECIAL CONDmONS SCOPE: This project includes channel clearing, the cleaning of debris and other obstructions from a 9,300 foot long section of the existing Crane Creek Channel in accordance with the specifications, plans, and the United States Armv Corps of Enqineers permit approved December 18. 1997 and the relocation of 600 linear feet of the Crane Creek Channel. Also, the installation of approximately 1544 LF of sanitary sewer pipe. The Contractor shall supply all materials, equipment, labor and supervision necessary to properly complete this project. TERMINI AND LENGTH: This project begins at Interstate Highway 20 and extends in a southwesterly direction to 1-20 Frontage Road. The total length of this project is 1.75 miles. LUMP SUM CONSTRUCTION: (CHANNEL IMPROVEMENTS) Item Number 230-1000 Lump Sum Construction includes, but is not limited to, the following: channel clearing, traffic control, clear and grub, locating, maintaining and reclaiming disposal area (s), complying with the terms of the United States Army Corps of Engineers permit (copy included in contract documents), Construction staking, removals and relocations not covered by a separate pay item and any other work required by the contract documents that does not have a separate pay item. LUMP SUM CONSTRUCTION: (SANITARY SEWER) Lump Sum Construction includes, but is not limited to, the following: ties to existing manholes; demolition of existing sanitary sewer pipes and manholes; plug existing sanitary sewer lines. CHANNEL CLEARING: 1. Contractor to remove and haul off all loose debris from creek channel and banks. 2. Contractor to clear and haul off all vegetation within grading limits. SP-1 I I I I I I I I I I I I I I I I I I I 3. Contractor to clear and haul off all vegetation from creek channel and banks in accordance with the following schedule and detail on Plan Sheet 25: a) Trim all limbs which overhang the bank to the limits of the top of bank. b) cut and remove any tree or brush excluding ground cover, from the area bounded by the top of bank on each side, provided its diameter is less than 6 inches. c) Trim all branches of trees remaining, from (b) above, flush with trunk to an elevation level with the top of bank. 4. Contractor to clean and clear all drainage ditches and gulleys in accordance with the above notes and within the established easements. 5. Contractor to clear all permanent access easements over 5' in width and make them accessible for truck traffic. I 'r:-rY'r-.~~ ~ '1 r " 'y )' ''"'! .J!OP OF BANK ~~ .... ELEVATION '\ .._~ ~~. ~"""''''''-e'''' --?' -t* - - - \ '. -o_';';c~~ f\ ~'i TRIM ALL BRANCHES OF TREES 6- '\~~,-~.~'k ~R7r! GR~~R IN DIAMETER FLUSH -:\~J~ ~\ ~- -.--. 7"- - ~'-v-v-ry- ~ r ~ ~ < \ "\ ~".. ~ ~~'~'~(W' ~~~ .-b r~.~ ~! \ '-.. J / 1'-- I ! " 1 . \ ~ -/,.., CUT AND REMOVE SECTION OF UMBS WHICH EXTENO BaOW TOP OF BANK ELEVATION \ ',-- ----- :'_" :,....~,? :. ~ \ \ \~..:~~..:~~~ :'>~"~l' 1.~::' . ~ REMOVE COMPLETELy ALL TREES LESS 7r!AN 6- IN DIAMEiER CHANNEL CLEARING DETAIL NOT TO SCALE SP-2 I I I I I I I I I I I I I I I I I I I GENERAL: 1) The Contractor shall give Richmond County and the Army Corns of Enqineers (CDE) a 2-weeks notice nrior to beqinninq work on this nroiect. 2) All graded slopes 3:1 or greater must be hydroseeded and covered with Georgia Department of Transportation approved wheat, wood fiber matting or coir coconut fabric. If not hydroseeded, Georgia Department of Transportation approved matting that has been incorporated with seed and fertilizer must be used. All slopes must be properly protected until a permanent vegetative stand is established; 3) Georgia Department of Transportation type "C" silt fence must be installed where silt fencing is required on the entire site and a double row must be installed between the land disturbing activities and state waters; 4) All disturbed areas must be seeded, fertilized and mulched as soon as final grade is achieved. Also, these disturbed areas must be protected until permanent vegetation is established; 5) Project be conducted in strict adherence to an erosion and sedimentation control nlan approved by the Briar Creek Soil and Water Conservation District and a Land Disturbing Activity Permit issued by Augusta/Richmond County. I SP-3 I I I I I I I I I I I I I I I I I I I CRANE CREEK CHANNEL IMPROVEMENTS 1-20 TO FRONTAGE ROAD PROJECT NUMBER: 55-8369-323 SPECIAL PROVISION CHANNEL EXCAVATION All waste material excavated within the project limits shall be wasted on upland, highground sites. No waste shall be placed on any wetlands. ENVIRONMENTAL CONCERNS All work performed during construction shall be done in a manner so as not to violate applicable water quality standards. The Contractor shall take extreme precautions to make certain no oils, grease or pollutants of any type are discharged from the construction activities on this project reach public waters. Equipment utilized in the dredging operations shall be maintained free of any petro chemical product (gasoline, oils, cleaners, etc.) leakage. In the event that any such leak develops, the equipment involved shall be removed immediately for repairs and any contaminants reaching the creek shall be skimmed and disposed of in a manner and at a location which has the approval of the Engineer. The Contractor shall utilize only those storage areas for equipment and/or materials which have been approved by the Engineer. Above ground storage areas shall be diked areas. All disturbed areas shall be returned to the original profile, dressed and grassed. All costs for the work described herein will not be paid for separately but included in the overall price bid for this project. u. S. ARMY CORPS OF ENGINEERS PERMIT A copy of the U. S. Army C.O.E. Permit has been included in this contract on pages COE-l through COE-13. The contractor shall comply with the terms of this permit. All costs for such compliance shall be included in Lump Sum Construction. SPP-l I I I I I I I I I I I I I I I I I I I .fl. A THIS AGREEMENT, made on the jg d~y of V61ST SECTION A AGREEMENT , 19 9! by and between AUQUsta-Richmond County Commission-Council party of the first part, hereinafter called the OWNER, and L - J, INC. party of the second part, hereinafter called the CONTRACTOR. WITNESSETH, that the Contractor and the Owner, for the considerations hereinafter named, agree as follows: ARTICLE I - SCOPE OF THE WORK The Contractor hereby agrees to furnish all of the materials and all of the equipment and labor necessary, and to perform all of the work shown on the plans and described in the specifications for the project entitled: Crane Creek Channel Improvements Project Number: 55-8369-323 and in accordance with the requirements and provisions of the Contract Documents as defined in the General and Special Conditions hereto attached, which are hereby made a part of this agreement. ARTICLE II - TIME OF COMPLETION - LIQUIDATED DAMAGES The work to be performed under this Contract shall be commenced within ~ calendar days after the date of written notice by the Owner to the Contractor to proceed. All work shall be completed within 145 calendar days with such extensions of time as are provided for in the General Conditions. It is hereby understood and mutually agreed, by and between the Contractor and the Owner, that the date of beginning, rate of progress and the time for completion of the work to be done hereunder are ESSENTIAL CONDITIONS of this contract. Contractor agrees that said work shall be prosecuted regularly, diligently, and uninterruptedly at such rate of progress as will ensure full completion thereof within the time specif ied. It is expressly understood and agreed by and between the Contractor and the Owner, that the time for completion of the work described herein is a reasonable time for completion of the same, taking into consideration the average climatic range and construction conditions prevailing in this locality. A-1 I I I I I I I I I I I I I I I I I I I IF THE CONTRACTOR SHALL NEGLECT, FAIL, OR REFUSE TO COMPLETE THE WORK WITHIN THE TIME HEREIN SPECIFIED, then the Contractor does hereby agree, as a part of the consideration for the awarding of this contract, to pay the Owner the sum of Five Hundred Dollars ($500), not as a penalty, but as liquidated damages for such breach of contract as hereinafter set forth, for each and every calendar day that the Contractor shall be in default after the time stipulated in the Contract for completing the work. The said amount is fixed and agreed upon by and between the Contractor and the Owner because of the impracticability and extreme difficulty of fixing and ascertaining the actual damages the Owner would, in such event, sustain, ,and said amounts shall be retained from time to time by the Owner from current periodical estimates. It is further agreed that time is of the essence of each and every portion of this Contract and the specifications wherein a definite portion and certain length of time is fixed for the additional time is allowed for the completion of an work, the new time limit fixed by extension shall be the essence of this contract. ARTICLE III - PAYMENT (a) The Contract Sum The Owner shall pay to the Contractor for the performance of the Contract the amount as stated in the Proposal and Schedule of Items. No variations shall be made in the amount except as set forth in the specifications attached hereto. (b) Proqress Payment On no later than the fifth day every month, the Contractor shall submit to the Owner's Engineer an estimate covering the percentage of the total amount of the Contract which has been completed from the start of the job up to and including the last working day of the proceeding month, together with such supporting evidence as may be required by the Owner and/or the Engineer. This estimate shall include only the quantities in place and at the unit prices as set forth in the Bid Schedule. On the vendor run following approval of the invoice for payment, the Owner shall after deducting previous payments made, pay to the Contractor 90% of the amount of the estimate on units accepted in place. The 10% retained percentage may be held by the Owner until the final completion and acceptance of all work under the Contract. A-2 I I I I I I I I I I I I I I I I I I I ARTICLE IV - ACCEPTANCE AND FINAL PAYMENT (a) Upon receipt of written notice that the work is ready for final inspection acceptance, the Engineer shall within 10 days make such inspection, and when he finds the work acceptable under the Contract and the Contract fully performed, he will promptly issue a final certificate, over his own signature, stating that the work required by this Contract has been completed and is accepted by him under the terms and conditions thereof, and the entire balance found to be due the Contractor, including the retained percentage, shall be paid to the Contractor by the owner within 15 days after the date of said final certificate. (b) Before final payment is due, the Contractor shall submit evidence satisfactory to the Engineer that all payrolls, material bills, and other indebtedness connected with work have been paid, except that in case of disputed indebtedness of liens of evidence of payment of all such disputed amounts when adjudicated in cases where such payment has not already been guaranteed by surety bond. (c) The making and acceptance of the final payment shall constitute a waiver of all claims by the Owner, other than those arising from unsettled liens, from faulty work appearing within 12 months after final payment, from requirements of the specifications, or from manufacturer's guarantees. It shall also constitute a waiver of all claims by the Contractor except those previously made and still unsettled. (d) If after the work has been substantially completed, full completion thereof is materially delayed through no fault of the Contractor, and the Engineer, so certifies, the Owner shall upon certification of the Engineer, and without terminating the Contract, make payment of the balance due for that portion of the work fully completed and accepted. Each payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. A-3 I I I I I I I I I I I I I I I I I I I , IN WITNESS WHEREOF, the parties hereto have executed this Agreement in three (3) counterparts, each of which shall be deemed an original, in the year and day first mentioned above. SEAL ~ - ~ Secretary "d filL . Witness ~ AUGUSTA-RICHMOND COUNTY COMMISSION-COUNCIL (Owner) Richmond County Commission-Council ~. omey ala CJ,..IoO r/,J,/q9 CONTRACTOR: L - J, INC. . ----E ~: l . . --~:._:~ Title: ~n:<==>-:::.' A a-<A- 1- Address: ~ ':lO ~ ~Y"'e.. \rt ct7 (' -.P y. ~ult-e.1-\-D S ~ \ u MA.. b \ P \ S:. C, ~9:L I 0 A-4 . , , . ~ THE AMERICAN INSTITUTE OF ARCHITECTS . AlA Document A312 Performance Bond Any singular reference to Contrador, Surety, Owner or other party shall be considered plural wher,e applicable. CONTRACTOR (Name and Address): L-J, Inc. 220 Stoneridge Drive, Suite 405 Columbia, South Carolina 29210 SURETY (Name and Principal Place of Business): Fireman's Fund Insurance Company 777 San Marin Drive Novato, California 94998 OWNER (Name and Address): Augusta-Richmond County Commission-Council . 530 Greene Street Augusta, Georgia 30909 CONSTRUCTION CONTRACT Date: Amount: Seven Hundred Thirty-Eight Thousand, Seven Hundred Fifty and 35/100 Dollars Description (Name and Location): Crane Creek Channel Improvements, Richmond County, Georgia Project No. 55-8369-323 BOND Date (Not earlier than Construction Contract Date): At/6vS'J Jf?) IQCff Amount: Seven Hundred Thirty-Eight Thousand, Seven Hundred Fifty and 35/100 Dollars Modifications to this Bond: rn None . 0 See Page 3 CONTRACTOR AS PRINCIPAL Company: L-J, Inc. (Corporate Seal) SURETY Fireman' Company: Insurance Company {Corporate Seal) . ~ " Signature: Name and Title: C. Criss Attorney- ,. , ..~ ;; f; Signatu~ - . ~ Name and ,Title: VA."'O !oJ. Jo~oM1 I ~SloE4JT Jr. ~ f ::,;'" (Any additional signatures appear on page 3) (FOR INFORMATION ONLY-Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or Cameron M. Harris of Columbia, Inc. other party): C .__ P.O. Box 386 OUrJ l i=RSIr-N 0 Columbia, SC 29202 BY:"""'- r r:;: 803/252-4542 Gt . AlA DOCUMENT A312 . PERFORMANa BOND AND PAVMENT BOND' DECEMBER 1984 ED. . AlA $ THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW VORK AVE" N.W., WASHINGTON, D.C. 20006 THIRD PRINT/NC . MARCH 1987 A312-1984 1 'j .' \. 1 The Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance 'of the Construction Contract, which is incorporated herein by reference. 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except to participate in conferences as provided in Subparagraph 3.1. 3 If there is no Owner Default, the Surety's obligation under this Bond shall arise after: 3.1 The Owner has notified the Contractor and the Surety at its address described in Paragraph 10 below that the Owner is considering declaring a Contractor Default and has requested and attempted to arrange a conference with the Contractor and the Surety to be held not later than fifteen days after receipt of such notice to discuss methods of performing the Construc- tion Contract. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reason- able time to perform the Construction Contract, but such an agreement shall not waive the Owner's right. if any, subsequently to declare a Contractor Default; and 3.2 The Owner has declared a Contractor Default and formally terminated the Contractor's right to complete the contract. Such Contractor Default shall not be de- . e1ared earlier than twenty days after the Contractor and the SuretY have received notice as provided in Sub- paragraph 3.1; and 3.3 The Owner has agreed to pay the Balance' of the Contract Price to the Surety in accordance with the terms of the Construction Contract or to a contractor selected to perform the Construction Contract in accor- dance with the terms of the contract with the Owner. 4 When the Owner has satisfied the conditions of Para- graph 3, the Surety shall promptly and at the Surety's ex- pense take one of the following actions: 4.1 Arrange for the Contractor, with consent of the Owner, to perform and complete the Construction Contract; or 4.2 Undertake to perform and complete the Construc-' tion Contract itself, through its agents or through inde- pendent contractors; or 4.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Con- struction Contract, arrange for a contract to be pre- pc:red for execution by the Owner and the contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Paragraph 6 in ex- cess of the Balance of the Contract Price incurred by the Owner resulting from the Contractor's default; or 4.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is deter- mined, tender payment therefor to the Owner; or .2 Deny liability in whole or in part and notiiy the Owner citing reasons therefor. 5 If the Surety does not proceed as provided in Paragraph 4 with reasonable promptness, the Surety shall be deemed to be in default on this Bond fifteen days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Subparagraph 4.4, and the Owner refuses the payment tendered or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. 6 After the Owner has terminated the Contractor's right to complete the Construction Contract, and if the Surety elects to act under Subparagraph 4.1, 4.2, or 4.3 above, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those oj the Owner under the Construction Contract. To the limit of the amount of this Bond, but subject to commitment by the Owner of the Balance of the Contract Price to mitigation of costs and damages on the Construction Contract, the Sure- ty is obligated without duplication for: 6.1 The responsibilities of the Contractor for correc- tion of defective work and completion of the Construc- tion Contract; 6.2 Additional legal, design professional and delay costs resulting from the Contractor's Default, and re- sulting from the actions or failure to act of the Surety under Paragraph 4; and 6.3 Liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual dam- ages caused by' delayed performance or non-perfor- mance of the Contractor. 7 The Su rety shall not be liable to the Owner or others for- -.. . I _ obligations of the Contractor that are unrelated to the Con- struction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators or successors. 8 The Surety hereby waives notice of any change, includ- ing changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obliga- tions. 9 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever oc. curs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation avail- AlA DOCUMENT A312 . PfRFORMANCE BOND AND PAYMENT BOND. DECEMBER 1964 ED. . AlA ~ THE AMERICAN INSTITUTE OF ARcHmcrs, 1735 NEW YORK AVE.. N.W.. WASHINGTON. D.C. 2llOO6 THIRD PRINTING. MARCH 1987 A312.1984 2 , . able to sureties as a defense in the jurisdidion of the suit shall be applicable. 10 Notice to the Surety, the Owner or the Contrador shall be mailed or delivered to the address shown on the sig- nature page. 11 When this Bond has been furnished to comply with a statutory or other legal requirement in the location' where the construdion was to be performed, any provision in this Bond confliding with said statutory or legal requirement shalf be deemed deleted herefrom and provisions con- forming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 12 DEFINITIONS 12.1 Balance of the Contrad Price: The total amount payable by the Owner to the Contractor under the Construdion Contrad after all proper adjustments have been made, including allowance to the Con- MODIFICATIONS TO THIS BOND ARE AS FOllOWS: trador of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contrador is entitled, re- duced by all valid and proper payments made to or on behalf of the Contractor under the Construction Con- trad. . 12.2 Construdion Contrad: The agreement between the Owner and the Contrador identified on the sig- nature page, including all Contract Documents and changes t.hereto_ 12.3 Contractor Default: Failure of the Contractor, which has neither been remedied nor waived, to per- form or otherwise to comply with the ~erms of the Construdion Contract. 12.4 Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Con- . trador as required by the Construction Contract or to perform and complete or comply with the other terms . thereof. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Signature: Name and Title: Address: SURETY Company: (Corporate Seal) Signature: Name and Title: Address: AlA DOCUMENT A.J12 . PERFORMANCE BOND ^ND P^YMENT BOND. DECEMBER 1984 ED. . ^I^ ~ THE ~ERICAN INSTITUTt OF AACHfTIcrS, 1735 NEW YORK ^VE.. N.W.. W.0.5HINc;ON. D.C. 20006 TLHOM DO'~TILJr .. .... JIo oru 10.~ A312-1984 3 j THE AMERICAN INSTITUTE OF ARCHITECTS W,,;::; \, ,':: 'I' . I",'; , ~ AlA Document A372 Payment Bond Any singular reference to Contrador, Surety, Owner or other party shall be considered plural where applicable, CONTRACTOR (Name and Address): L-J, Inc. 220 Stoneridge Drive, Suite 405 Columbia, South Carolina 29210 SURETY (Name and Principal Place of Business): Fireman's Fund Insurancp- Company 777 San Marin Drive Novato, California 94998 OWNER (Name and Address): Augusta-Richmond County Commission-Council 530 Greene Street Augusta, Georgia 30909 CONSTRUCTION CONTRACT . Date: Amount: Seven Hundred Thirty-Eight Thousand, Seven Hundred Fifty and 35/100 Dollars Description (Name and Location): Crane Creek Channel Improvements, Richmond County, Georgia Project No. 55-8369-323 BOND Date (Not earlier than Construction Contract Date): Amount: Seven Hundred Thirty-Eight Thousand, Seven Modifications to this Bond: IKJ None Hundred Fifty and 35/100 Dollars o See Page 6 CONTRACTOR AS PRINCIPAL Company: L-J, Inc. - ~ (Corporate Seal) SURETY Fireman's Fund Insur~nc~ Company Company: )Co[porate Seal) <:' ~ .-' '.. ? Signature:-=- ~ Name and Title: 'DAvIO ~. Jo:tOl4.l. Pu.c;,~( (Any additional signatures appear on page 6) Signatu re: Name and Title: C. Criss il, ams, Attorney-in-Fact -~ -~. -.-. ,:..,,-~..:..'~~ (FOR INFORMATION ONLY-Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or Cameron M. Harris of Columbia, Inc ..other party): P. O. Box 386 Columbia, SC 29202 803/252-4542 BY: Gl COUNTERQ~'~;\IC:D .. '- . "-1. ,~!.- . -- b. AlA DOCUMENT A312 . PfRFORMANCE BOND AND PAYMENT BOND. DECEMBER 1964 ED. . AlA ~ THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE.. NW., WASHINGTON, D.C. :zooo& THIRD PRINTlNC . MARCH 1967 A312.1984 4 .. 1 The Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the perfor- mance of the Construction Contract, which is incorpo- rated herein by reference. . 2 With respect to the Owner, this obligation shall be null and void if the Contractor: 2.1 Promptly makes payment, directly or indirectly, for all sums due Claimants, and 2.2 Defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity whose claim, demand, lien or suit is for the payment for labor, materials or equipment fur- nished for use in the performance of the Construction Contract. provided the Owner has promptly notified the Contractor and the Surety (at the address described in Paragraph 12) of any claims, demands, liens or suits and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety, and provided there is no Owner Default. 3 With respect to Claimants, this obligation shall be null and void if the Contractor promptly makes pay- ment, directly or indirectly. for all sums due. 4 The Surety shall have no obligation to Claimants under this Bond until: 4.1 Claimants who are employed by or have a direct contract with the Contractor have given notice to the Surety (at the address described in Paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 4.2 Claimants who do not have a direct contract with the Contractor: .1 Have furnished written notice to the Con- tractor and sent a copy, or notice thereof, to the Owner, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed; and .2 Have either received a rejection in whole or in part from the Contractor, or not received within 30 days of furnishing the above no- tice any communication from the Contractor by which the Contractor has indicated the claim will be paid directly or indirectly; and .3 Not having been paid within the above 30 days, have sent a written notice to the Surety (at the address described in Paragraph 12) and sent a copy, or notice thereof. to the Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to the Contractor. 5 If a notice required by Paragraph 4 is given by the Owner to the Contractor or to the Surety, that is suffi- cient compliance. 6 When the Claimant has satisfied the conditions of Paragraph 4, the Surety shall promptly and at the Surety's expense take the following actions: 6.1 Send an answer to the Claimant, with a copy to the Owner, within 45 days after receipt of the claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed. 6.2 Payor arrange for payment of any undisputed amounts. 7 The Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 8 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the perfor- mance of the Construction Contract and to satisfy claims" if any, under any Construction Performance Bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond, subject to the Owner's prior- ity to use the funds for the completion of the work. 9 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelat- ed to the Construction Contract. The Owner shall not be liable for payment of any costs or expenses of any Claim- ant under this Bond, and shall have under this Bond no obli- gations to make payments to, give notices on behalf of, or otherwise have obligations to Claimants under this Bond. 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. 11 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent juris- diction in the location in which the work or part of the work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice required by Subparagraph 4.1 or Clause 4.2.3, or (2) on which the last labor or service was performed by anyone or the last mate- rials or equipment were fumished by anyone under the Con- struction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page. Actual receipt of notice by Surety, the Owner or the Contractor, however accomplished, shall be sufficient compliance as of the date received at the address shown on the signature page. 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions con- forming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this AlA DOCUMENT A312 . PERfORMANCE BOND AND PAYMENT BOND. DECEMBER 1984 ED.. AlA- THE AMERICAN INSTITUTE OF ARCHITECTS. 1735 NEW YORK AVE.. NW., WASHINGTON, D.C. 20006 THIRD PRINTING. MARCH 1987 A312-1984 5 ... . - . . .' Bond shall be construed as a statutory bond and not as a common law bond. 14 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor shall promptly furnish a copy of this Bond or shall permit a copy to be made. 15 DEFINITIONS 15.1 Claimant: An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equip- ment for use in the performance of the Contract. The intent of this Bond shall be to include without limita- tion in the terms "labor, materials or equipment" that part of water, gas, power, light. heal, oil, gasoline, telephone service or rental equipment used in the MODIFICATIONS TO THIS BOND ARE AS FOllOWS: Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. 15.2 Construction Contract: The agreement between the Owner and the Contractor identified on the sig- nature page, including all Contract Documents and changes thereto. 15.3 Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Con- tractor as required by the Construction Contract or to perform and complete or comply with the other terms thereof. CONTRACTOR AS PRINCIPAL Company: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) (Corporate Seal) Signature: Name and Title: Address: SURETY Company: (Corporate Seal) Signature: Name and Title: Address: AlA DOCUMENT A312 . PERFORMANCE BOND AND PAYMENT BOND . DEC~MBER 1984 ED. . AlA ~ THE AMERICAN INSTITUTE OF ARCHITECTS. 1735 NEW YORK AVE.. N.W.. WASHINGTON, D.C. 20006 THIRD PRINTlNC . MARCH 1987 A312.1984 6 GE.'iERAl. PO'WER OF ATrOR.'iEY FIRE;\-1AN'S FUND INSUR-\.NCE COMPANY K.'iOW ALL ME:-I BY TIIESE PRESEXTS: That FIRE~N'S FUND INSURANCE COMPA.NY. a Corpor3tion duly organi::ed and existing under the laws of the Sl3te of California. and having iu principal office in the County of Marin. Sl3te of Califomi3. has made. constituted and appointed, and docs bv these preseoumake,constituteandappoint LAURA W. DE~NISON AND C. CRISS WILLIA:fS, JR. jOintly' or severally . COLUM3IA SC . F 'hf . h ' . IU trJe and Tawlill.~ttorney(s)-IO- act. Wlt ull power and authonty ereby conferTed In lU name. place and stad. to e:tec'Jte, seal. aclc::1owlecge and deliver any and all bonds. undertaking. re-;:ogni;;::lnce:i or other written obligatioll5 in the nature thereof ------------------------------- and to bind the Corporation thereby :u fully and to the same e."ttent as if sue!l bonds Were signed by the Preside:tt. Se:lled with the corporate seal of the Corporation and duly attested by iu Sccr~ary. hereby ratifying and conflfIIling all that the said Attorney(s)-in-Fact may do in the pre:nises. This power of attorney i5 granted pursuant to Article VII. 5ec'.ioDS 45 and 46 of By-laws of FIRE~'i'S FUND INSUR..1...'iCE COMPA."!' now in full force and e:~~~ ".<Vtkle vn. AppoiJJlJ1Jel1t md .~atbority 01 ResideDt 5<<re~rie3. AttorrJe}'-iD-F~ct ud AgeDu to .~pt LepJ Process md ,'-lake ,~ppe2r2lJ=. Sedoa 45. AppoiJJlJ1JeDt. Toe Cbairmsa of the Board of DirKton, the Pn:sideat. any Vi~Presideat or any other persoa aathorized by tbe Board of Diret:1on. tbe ClIairmsa of the Board of DirKton, the P~nt or a.n,. YI~Presideat 011.,.. from time to time. appou!t Resident ..o..ssUuat Secretaries aad ..o\ttorneys-in-Fact to ~prc:sent and act for lnd oa behalf of the COrpoT'J.tiOD and ..o\&eau to a~ptl~al process aDd make appeann~ lor a.nd oa behalf of the C~rpoT'J.t1oa. SedoD 46. .~atbority. The aatborify of suc!! Resideat ..usUunt Se-cretaries. .~ttorneys-iD-Fact and .-\geat! shJ..iJ lle as prescribed in the ilUlI''IImeat evidencing their appointment. .-\llY such appointment lIId J..iJ authority inated tbe~by may be T"Cvolted It aay time by the Board of Diret:1ors or by any persoa empowered to ma.lr.e saeh appointment." This ~we':" of attorney is sig::ee and Se:lled uncie':" and by the authority of the following Re:iolution adopted by :he Board oi Direc:ors oi FIRE.\f...1..."i'S FUND I)iSt.:R.~'iCE COMPA."!' at a :n~:ing duly called and held on the ith day oi August. 1984. and said Resolution has not b~::: ame:::ded or re~ed: "RESOLVED, that the signature of any Vic:-Preside:::t. Assistant Se::re:.ary, and Reside:::t Assistant Sccr::ary oi this COr,loration, and the Se:ll of this Cor;x:ration :nay be affIXed or pr'oIUed on any power of attorney. on any revOc:ltion of any power oi attoney, or on any ce:-.ificate relating there:o, by facsimile. and any power oi attorney, any revocation oi any power of attoney, or certificate bearing sue;" facsimile sipat'Jre or facsimile seal shall be valid and binding upon ~he Corporation:' INWID"'ESS 'W"HEREOF, FIRE.\1A..'i'S Fl.;ND INSURA."iCE COMP..1...'IY h:u caused :h= prese:::u :0 be signed by iu Vice.Preside:u, and iu eOr,lorate sc:1l :0 be !lere'.tIlto a::IXed this 2 2 n d day of A? r iI, 19 ~. FIRE.\1A..'i'S FtiND INSUR..1...'iCE COMP.~'<Y By fr~~ } D. 00 this ?? ~,..l day of A..., - ~ 1 . 19.....9....:..... be:'ore:ne ;>erson.al.ly =e M. A. Mallonee , to >!Ie (:lOW"."!, WQO, being by :Ile duly Sworn. did de;losc::md say: that!le is Viee-Presicie:::t oi :IR.E~'i'S F"I..::-'U INSt:R..l...'<CE COMP,~""Y. the Cot;XlrJtion des~Cc:d in and whic!l exe::-Jted the above instrJmc::1t; that !lc: ,mows :he sc::U oi said COr,loration; that :he Se:ll ai:ued .0 the said inst.r\lme:1t is suc!l cor;:orate sai: :hat it ....as so affIXed by orde':" of the Board oi w=ors oi said COr,loratioo and that he sig::ed !lis name ther~o by lilee order. S7ATE OF C.UIFOR.'lIA COL'1'<'TY OF~:-< IN WI~"'ESS WHEREOF. I have hereunto se: :ny hand and affued ::JY oific:aJ seal. the day and 'fear herein :IISt above writte:::. A. KRJEGE? C:MM.#~~11 :: ..... f I ) ~~ r ............ ...... ........... .......... ........ C~~ ~~ 0.t~. ~~ ). ..; :;o.~ '-' ......... ......... .......... ..-. ..-.... ~ NC"U'" ~'.:gL:C.C;'L:F~KNIA C ~..:1IN C':t.:N'r'1 My C::r.r.t ~=~ .\olaI. :?C. 1999 ~ .......,,- --...r ~ __ .....". CERTtFl C.UE ......,,- .....".. } M I. :~e '~:::dersig!:d:Resic-e=; A~~i-su.;t Sccr:~rv of FIREY{A. "'5 F\..; 'ND rNS1.:R.-\:-<CE COMP.~ ,,-t. a c.UrF.:) R. 'iIA Cvr;:eration. DO HER.S3 Y CE~\jF':: .hat :~e :'or:;oir;g JIld:ii~chci ?OVv"'E3 OF AilOR:-'"'EY :e=:a.ins:n:uil :'or:: JIle ~as :lOt :ee~ :e'/ct.:d;:u:c :';.:r::1e:-:nor: :h:lt Ar:ie:e VII, Se-::ions':~ and ~ I,)r the 3y,;aws vi ihe C~rporation. and the'~'e:iolution of .he 30ard vi Dir~ors: se: ;or:h in :he Power of A::er.:ey, are :lew::1 :orce. S7.-\:= OF C.UIFOR."lA COL:.'TY OF ~IN Sig::e<: J.l:C sc::Jl:d at-dle County oi ~1ar:::. Da~ed :he da y 0 f .1938-. ~gd~ ~alc:lC':Jl .\J,.S.Ut.a.Dl Sc:c:-rury . I I I I I I I I I I I I I I I I I I I GENERAL CONDITIONS I I I I I I I I I I I I I I I I I I I TABLE OF CONTENTS OF GENERAL CONDITIONS Article Number Title ~ DEfINITIONS. . ...... ....... ...... ... .... ... .......... .... . . ... .. .. PRELIMINARY MATTERS ........................................ CONTRACT DOCUMENTS: INTENT. AMENDING AND REUSE............................... AVAILABILITY Of LANDS: PHYSICAL CONDITIONS: REFERENCE POINTS.............................................. BONDS AND INSURANCE........................................ CONTRACTOR'S RESPONSiBILITIES............................ OTHER WORK ..................................................... OWNER'S RESPONSiBILITIES.................................... ENGINEER'S STATUS DURING CONSTRUCTION.............. CHANGES IN THE WORK. ................ .. ...... .. . . . . .. .., . .. .. CHANGE OF CONTRACT PRiCE.................................. CHANGE OF CONTRACT TIME ................................... WARRANTY AND GUARANTEE: TESTS AND INSPECTIONS: CORRECTION. REMOVAL OR ACCEPTANCE OF DEfECTIVE WORK........................... PA YMENTS TO CONTRACTOR AN D COMPLETION ............ SUSPENSION OF WORK AND TERMINATION....... .......... ARBITRATION.................................................... . MISCELLANEOUS............................................... .. 3 4 5 6 7 8 9 10 II 12 13 14 15 16 17 3 PaRe ., I 8 9 10 II 14 18 19 19 21 21 24 24 26 29 31 32 I I INDEX TO GENERAL CONDITIONS I Anicl~ or Paragraph Numb~r Acceptance of Insurance ............................. 5.13 Access to the Work ..................................13.2 Addenda-<1efinition of (see definition of Specifications) ....................,................... I Agreement-definition of ................................ I All Risk Insul'3nce ..................................... 5.6 Amendment. Written ............................. 1. 3.1.1 Application for Payment-definition of .................. I Application for Payment, Final ..,................... 14.12 Application for Progress Payment .................... 14.2 Application for Progress Payment-review of .... 14.4-14.7 Arbitration ........,....................,............,.. 16 Authorized Variation in Work......................... 9.5 A vailability of Lands .................................. 4.1 Award. Notice of -defined .............................. I I I I I I Before Starting Construction ...................... :.5.2.i Bid-definition of ....................................... 1 Bonds and Insurance-in general ........................ 5 Bonds-definition of . . . . . .. . . .. . . . .. . .. .. . .. . . . .. .. .. .... I Bonds. Delivery of .......,..................... _. :.1. 5.1 Bonds. PeIformance and Other .................... 5.1.5.2 I I Cash AIJowances ..................................... 11.8 Change Order-derinition of ......,..................,... I Change Orders-to be executed ...................... 10.4 Changes in the Work ................................... 10 Claims. Waiver of-on Final Payment ............... 14.16 Clarifications and Interpretations .......,.............. 9.4 Cleaning ..............,.............................. 6.1 i Completion. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . , .. 14 Compietion. Suostantial ..................,...... 14.8-14.9 Conference. Preconstructlon ..............,........... :.8 Conflict. Error. Discrepancy-Contractor to Report ...................................... :;..5.3.3 Construction Machinery. Equipment. etc. ..........,.. 604 ContinUing Work ...................................... 6.19 Contract Documents-amending and supplementing ................................... 3.4-3.5 Contract Documents--derinition of ....................:. I Contract Documents-Intent...................... 3.1.3.3 Contract Documents-Reuse of .............,'........ 3.6 Contract Price. Change of .............................. 11 Contract Price--Jefinition ............................... I Contract Time. Change of ...................,.......... 12 Contract Time. Commencement of .................... :.3 Contract Time--Jerinition of ............................ 1 Contractor-derlnition of .............................,.. I Contractor May Stop Work or Terminate ...,......... 15.5 Contractor's Continuing Obligation.................. 14.15 Contractor's Duty to Repon Discrepancy in Documents .................................. :.5.3.:; Contractor's Fee-Cost Plus '" 11.4.5.6.11.5.1. 11.6-11.7 Contractor's Liability Insurance...............,....... 5.3 Contractor's Responsibilities-in general .....,.......... 6 I I I I I I I I I Contractor's Warranty ofTitJe ........................ 14.3 Contractors--other ... . . . . . . , . . . , . . . . . . , . . . . . . . . . . . . . . . .' 7 Contractual Liability Insurance ........................ 5.4 Coordinating Contractor--<Jefinition of ............,... 7.4 Coordination ....,..................................... 7.4 Copies of Documents .................................. 2.2 Correction or Removal of Defective Work ........... 13. II Correction Period. One Year ........................ 13.12 Correction. Removal or Acceptance of Defective W ork-in general ..................... . .. ... 13.11-13. 14 Cost-net decrease ................................. 11. 6.1 Cost of Work.................................... 11.4-11.5 Costs. Supplemental. . . . . . . . . . . . . . . .. . . . . . . . . . . . . . .. 11.4.5 Day--<Jefinition of ......,...,...,.....,.".......,.,..... 1 D~f~ctive--<Jefinition of ..............,.................. 1 Defective Work. Acceptance of .....,.........,...... 13.13 Defective Work. Correction or Removal of ..,....... 13.11 . DefectiveWork-ingeneral ............... 13.14.7.14.11 Defective Work. Rejecting. .. . . .. .... .. ...... ...... .. .. 9.6 Definitions .............................................. 1 Delivery of Bonds ..................................... 2.1 Determination for Unit Prices ........................ 9. J 0 Disputes. Decisions by Engineer................. 9.11-9.12 Documents. Copies of ................................. :.2 Documents. Record '................................. 6.19 Documents. Reuse .................................... 3.6 Draw;ng~efinition of ......................,.......... I Easements ............,............,.................. 4.1 Effective date of Agreement-definition of ..... . .. . .. .. .. I Emergencies ......................................... 6.:: Engineer--(jefinition of ...............,.,................ 1 Engineer's Decisions ............................ 9. 10-9. 12 Engineer's-Notice Work is Acceptable ...,......... 14.13 Engineer's Recommendation of Payment ...... 14.4. 14.13 Engineer's Responsibilities. Limitations on ................. 6.6,9.11 , 9.13 -9.16,18.2 Engineer's Status During ConstrUction-in general ...,.. 9 Equipment. Labor. Materials and...,.............. 6.3-6.6 Equivalent Materials and Equipment .................. 6.7 Explorations of physical conditions. . ... .,. . .. .. .... .. 4.1 Fee. Contractor's-Costs Plus... ..................... 11.6 Field Order--(jefinition of ............................... I Field Order-issued by Engineer ........,......, 3.5.1.9.5 Final Application for Payment. ...................... 14.12 Final Inspection ..................................... 14. I 1 Final Payment and Acceptance ...................... 14.13 Final Payment. Recommendation of ........... 14:13-14.14 General Provisions ...........,.,................ 17.3.li.4 General Requirement~erinition of . . . " . . . . . . . . . . . . . . .. I General Requlrements--principal references to ................. 2.6.4.4.6.4.6.6-6.7. 6.23 ~ 1 I: I 1 I 1 1 I I 1 1 1 I 1 1 1 1 I 1 Giving Notice............................. ........... 17.1 Guarantee of Worlc-by Contractor................... 13.1 Indemnification. . , , . . . . . . . . . . . .. . . .. . . . . . . .. 6.30-6.32. 7.5 Inspection. final .................................... 14.11 Inspection. Tests and ................................. 13.3 Insurance. Bonds and-in general ....................... 5 Insurance. Certificates of ........................... 2.7. 5 Insurance-completed operations................ ...... 5.3 Insurance. Contractor's Liability ...................... 5.3 Insurance. Contractual Liability ....................... 5.4 Insurance. Owner's Liability .......................... 5.5 Insurance. Property.............................. 5.6-5.13 Insurance-Waiver of Rights ......................... 5.11 Intent of Contract Documents ................... 3.3. 9.14 Interpretations and Clarifications ..,................... 9.4 Investigations of physical conditions................... 4.1 Labor. Materials and Equipment .................. 6.3-6.5 Laws and Regulations-<iefinition of ............... . . . . .. I Laws and Regulations-general. . . . . . . . . . . . . . . . . . . . . .. 6.14 Liability Insurance-Contractor's ............,........ 5.3 Liability lnsurance-Owner"s ......................... 5.5 Liens-<iefinitions of ................................ 14.1 Limitations on Engineer's Responsibilities ....................' 6.6, 9.11. 9.13-9.16 Materials and equipment-furnished by Contractor .... 6.3 Materials and equipment-not incorporated in Work .............................. 14.2 Materials or equipment--equivalent ................... 6.7 Miscellaneous Provisions ............................... 17 Multi-prime contracts ................................... 7 Notice. Giving of............................... ...... 17.1 Notice of Acceptability of Project ................... 14.13 Notice of A ward-<iefinition of .......................... I Notice to Proceed-definition of ......................... 1 Notice to Proceed-giving of ............................ 1.3 "Or-Equal" Items..........,.. ...... ....... ........... 6.7 Other contractors ........................."............ j Other work. . . . . . . . . . .. .. .. ....... . .....,. ........ ..... ... 7 Overtime Work-prohibition of . ........ ...... .... .. ... 6.3 Owner-<iefinition of ........,........................... I Owner May Correct Defective Work................. 13.14 Owner May Stop Work .............................. 13.10 Owner May Suspend Work. Terminate ........., 15,1-15A Owner's Duty to Execute Change Orders........,.... 11.8 Owner's Liability Insurance ........................... 5.5 Owner's Representative-Engineer to serve as ........ 9.1 Owner's Responsibilities-in general .................... 8 Owner's Separate Representative at site ............... 9.3 Partial Utilization .................................. 14.10 Partial Utilization-derlnition of ......................... 1 Partial Utilization-Property Insurance............ ... 5.15 Patent Fees and Royalties..........................., 6.1: Payments. Recommendation of ........... 14.4-14.7, 14.13 Payments to Cuntractor-in general ........,........... 14 Payments to Contractor-when due ........... 14.4. 14.13 Payments to Contractor-withholding ................ 14.7 Performance and other Bonds ..................... 5.1-5,2 Permits.......,..... .. ................................ 6.13 Physical Conditions ................................... 4.2 Physical Conditions-Engineer's review ............. 4.2.4 Physical Conditions-<:xisting strUctures. . . . . .. . . .. .. 4.2.2 Physical Conditions-<:xplorations and repom ....... 4.2.1 Physical Conditions-possible document change ..... 4.2.~ Physical Conditions-price and time adjustments .... 4.1.5 Physical Conditions-report of differing ............. 4.2.3 Physical Conditions-Underground facilities.......... 4.3 Preconstruction Conference .....'..................... 2.8 Preliminary Matters ..................,...........,...... 2 Premises. Use of ..........................,..... 6.16-6.18 Price. Change of Contract .............................. 11 Price-Contract-definition of ............................ 1 Progress Payment. Applications for..... .............. 14.2 Progress Payment-retainage ......................... 14.2 Progress schedule ............... 2.6.1.9.6.6.6.29. 15.2.6 Project-definition of .................................... 1 Project Representation--provision for ............'.... 9.3 Project Representative, Resident-definition of .......... I Project. Starting the ................................... 2A Property Insurance ............................... 5.6-5.13 Property Insurance-Partial Utilization............... 5.15 Property Insurance-Receipt and Application of Proceeds .........................."....... 5.12-5.13 Protection. Safety and........................... 6.20-6.21 Punch list ........................................... 14.11 Recommendation of Payment.................. 14.4. 14.13 Record Documents ................................... 6.19 Reference Points ...................................... 4.4 Regulations. Laws and ............................... 6.14 Rejecting Defective Work ............................. 9.6 Related Work at Site .............................. 7.1-7.3 Remedies Not Exclusive ...........................'. 17.4 Removal or Correction of Defective Work ........... 13.11 Resident Project Representative-definition of .......,... 1 Resident Project Representative-provision for........ 9.3 Responsibilities. Contractor's-in general .,............. 6 Responsibilities. Engineer's-in general .,............... 9 Responsibilities. Owner's-in general.................... 8 Retainage ......,........'.....'".................... 14.2 Reuse of Documents .................................. 3.5 Rights of Way. ................... .... ................. ~.1 Royalties. Patent Fees and ........................... 6.12 Safety and Protection....... 6.20-6.21, 18.1-18.2 Samples .,................................,...... 6.23-6.28 Schedule of progress ........ 2.6.2.8-2.9.6.6.6.29. 15.2.6 Schedule of Shop Drawing submissions. .... ................. :.6.2.8-2.9.6.23. 14.1 Schedule of values ...................... 2.6. 2.8-2.9. 1~.1 Schedules. Finalizing....... ........................... 2.9 Shop Drawings and Samples. .. .. .. .. .... . . .. .... 6.23-6.28 Shop Drawings-Jefinition of . . . . .. .. . . .. . . .. . .. .. .. .. ... 1 Shop Drawings. use to approve substitutions ...................................... 6.7.3 5 I I Site. Visits to--by Engineer ........................... 9.2 Specitications-<ietinition of ............................. I Staning Construction. Before.. . .. . . . .. . . .. . . . . . ... 2.5-2.8 Staning the Project .................................... 2.4 Stopping Work-by Contractor....................... 15.5 Stopping Work-by Owner.......................... 13.10 Subcontractor-detinition of ............................. 1 Subcontractors-in general ....................... 6.8-6.11 Subcontracts-required provisions ............ 5.11.1. 6.11 11.4.3 Substantial Completion-<:enitication of .............. 14.8 Substantial Completion-detinition of . . . . . . . . . . . . . . . . . . .. I Substitute or "Or-Equal" ltems ....................... 6.7 Subsurface Conditions. . . . . . . . . . . . . . . . . .. . . . . . . . ... 4.2-4.3 Supplemental costs ................................. 11.4.5 Supplementary Condition~etinition of ................ I Supplementary Conditions-principal references to .. 2.2, 4.2.5.1.5.3. 5.6-5.8. 6.3, 6.13. 6.23, 7.4,9.3 Supplementing Contract Documents ............... 3.4-3.5 Supplier-detinition of . . . . . . . . , . . . . . . . . . , . . . . . . . . . . . . . . .. I Supplier-principal references to ... 3.6.6.5,6.7-6.9.6.20, 6.24.9.13.9.16. 11.8. 13.4. 14.12 Surety-consent to payment.................. 14.12. 14.14 Surety-Engineer has no duty to ..................... 9.13 Surety-notice to .......................... 10.1. 10.5. 15.2 Surety-qualification of ........................... 5.1-5.2 Suspending Work. by Owner ......................... 15.1 Suspension of Work and Termination-in general....... 15 Superintendent-Contractor's ......................... 6.2 Supervision and Superintendence.................. 6.1-6.2 I I I I I I I I I Taxes-Payment by Contractor. . . . . . . . . , . . . .. . . . . . . .. 6.15 Termination-by Contractor.... ...................... 15.5 Termination-by Owner. .. .... ................'. 15.2-15.4 Termination. Suspension of Work and-in general ...... 15 Tests and Inspections ........................... 13.3-13.7 Time. Change of Contract .............................. 12 I I I I I I I I Time. Computation of ................................ 17.2 Time. Contract-definition of ..,...... .......... ......... I UncoveringWork ............................... 13.8-13.9 Underground Facilitie~etinition of .................... 1 Underground Facilities-not shown or indicated..... 4.3.2 Underground Facilities-protection of ..,........ 4.3.6.20 Underground Facilities-shown or indicated......... 4.3.1 Unit Price Work-detinition of .......................... I Unit Price Work-general ................. 11.9. 14.1. 14.5 Unit Prices......................................... 11.3.1 U nit Prices. Determinations for . . . .. .. . . . . .. .. .. .. .. .. 9.10 Use of Premises ................................. 6.16-6.18 Utility owners .....,.................... 6.13.6.20.7.2-7.3 Values. Schedule of ......................... 2.6.2.9. 14.1 Variations in Work-Authorized............ 6.25.6.27. 9.5 Visits to Site-by Engineer............................ 9.2 Waiver of Claims-on Final Payment ................ 14.16. Waiver of Rights by insured panies ............. 5.10.6.11 Warranty and Guarantee-by Contractor ............. 13.1 Warrantv of Title. Contractor's....................... 14.3 Work. Access to .....................................13.2 Work-byothers ........................................ 7 Work Continuing During Disputes ..'................. 6.29 Work. Cost of ................................... 11.4-11.5 Work-detinition of ..................................... I Work Directive Change-detinition of ................... 1 Work Directive Change-principal references to ............................ 3.4.3. 10.1-10.2 Work. Neglected by Contractor ..................... 13.14 Work. Stopping by Contractor........................ 15.5 Work. Stopping by Owner....................... 15.1-15.4 Written Amendment-detinition of ...................... 1 Written Amendment-principal references to ..................... 3.4.1. 10.1. 11.:. 1:.1 6 I I GENERAL CONDITIONS ARTICLE I-DEFINITIONS I I Wherever used in these General Conditions or in the other Contract Documents the following terms have the meanings indicated which are applicable to both the singular and plural thereof: I Addenda-Written or graphic instruments issued prior to the opening of Bids which clarify. correct or change the bidding documents or the Contract Documents. I Agreeml'l/f- The written agreement between OWN ER and CONTRACTOR covering the Work to be performed: other Contract Documents are attached to the Agreement and made a part thereof as provided therein. I Applicatiol/ jl)r Paymellf- The form accepted by ENGI- N EER which is to be used by CONTRACTOR in requesting progress or tinal payments and which is to include such sup- porting documentation as is required by the Contract Documents. I I Bid-The offer or proposal of the bidder submilled on the prescribed form selling forth the prices for the Work to be performed. I Bonds-Bid. performance and payment bonds and other instruments of security. I Change Order-A document recommended by ENGINEER. which is signed by CONTRACTOR and OWNER and autho- rizes an addition. deletion or revision in the Work. or an adjustment in the Contract Price or the Contract Time. issued on or after the Effecti\'e Date of the Agreement. I Conrracf Doclfmenrs- The Agreement. Addenda (which per- tain to the Contract Documents!. CONTRACTOR's Bid I including documentarion accompanying rhe Bid and any post- Bid documentarion submitted prior to rhe Notice of Award) when attached as an exhibit to the Agreement. the Bonds. these General Conditions. the Supplementary Conditions. the Specifications and the Drawings as the same are more spe- cifically identified in the .-\greement. together with all amend- ments. modifications and supplements issued pursuant to paragr.1phs 3.4 and 3.5 on or after the Effective Date of the Agreement, I I I CV/lIracr Price-The moneys payable by OWNER to CON- TRACTOR under the Contract Documents as stated in the Agreement (subject to the provisions of paragraph 11.9./ in the case of Unit Price Work). I I CO/llraef Til/ll'- The number of days I computed as provided in paragraph 17.~) or the date Slated in the Agreement for the completion of the Work. I CONTRA CTOR- The person. tirm or corporation with whom OWN ER has entered inlO the Agreement. I Jefectil'e-An adjective which when modifying the word Work refers to Work that is unsatisfacrory. faulty or deficient. or does not conform to the Contract Documents. or does not meet the requirements of any inspection. reference standard. test or approval referred to in the Contract Documents. or has been damaged prior to ENGINEER's recommendation of final payment (unless responsibility forthe protection thereof has been assumed by OWNER at Substantial Completion in accordance with paragraph 14.8 or 14,101. Drall"ings- The drawings which show the character and scope of the Work to be performed and which have been prepared or approved by ENGIN EER and are referred to in the Con- tract Documents, Effecril'e Dme of the Agreemel/t- The date indicated in the Agreement on which it becomes effective. but if no such date is indicated it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. E.VGIN EER- The person. firm or corporation named as such in the Agreement. Field Order-A written order issued by ENGINEER which orders minor changes in the Work in accordance with para- graph 9.5 but which does not involve a change in the Contract Price or the Contract Time. Gt'lIeral Req/firemellts-Sections of Division I of the Speci- fications. Lall's and Reg/flatiolls: Lal\'s or Regulations-Laws. rules. regulations. ordinances. codes and/or orders. NO/ice of .-III'ard- The written notice by OWNER to the apparent successful bidder stating that upon compliance by the apparent successful bidder with the conditions precedent enumerated therein. within the time specified. OWNER will sign and deliver the Agreement. Notice to Proceed-A written notice given by OWNER 10 CONTRACTOR (with a copy to ENGINEER) fixing the date on which the Contract Time will commence to run and on which CONTRACTOR shall start to ~erform CONTRAC- TOR'S obligations under the Contract Documents. OWNER-The public body or authority. corporation. asso- ciation. firm or person with whom CONTRACTOR has entered into the Agreement and for whom the Work is to be provided. Partial Utili::.atioll-Placing a portion of the Work in service for the purpose for which it is intended lor a related purpose) before reaching Substantial Completion for all the Work. Project-The total construction of which the Work to be provided under the Contract Documents may be the whole. or a part as indicated elsewhere in rhe Contract Documents. Rl'sidel// P/"(~ie('/ Rl'pre.H'lIt/ftil'e- The authorized represen- tative of E;-JGINEER who is assignt:d to the site or any part thereof. 7 I I Shop Drawings-All drawings, diagrams. illustrations, schedules and other data which are specifically prepared by or for CONTRACTOR to illustrate some portion of the Work and all illustrations. brochures, standard schedules, perfor- mance chans. instructions, diagrams and other infonnation prepared by a Supplier and submitted by CONTRACTOR to illustrate material or equipment for some portion of the Work. I I Specijications- Those portions of the Contract Documents consisting of written technical descriptions of materials. equipment. const!'uction systems. standards and workman- ship as applied to the Work and certain administrative details applicable thereto. I I Subcontractor-An individual. finn or corporation having a direct contract with CONTRACTOR or with any other Sub- contractor for the performance of a pan of the Work at the site. I Substantial Completion- The Work (ora specified part thereot) has progressed to the point where, in the opinion of ENGI- NEER as evidenced by ENGINEER's definitive certificate of Substantial Completion. it is sufficiently complete, in accordance with the Contract Documents. so that the Work (or specified pan) can be utilized for the purposes for which it is intended; or if there be no such certificate issued. when final payment is due in accordance with paragraph 14.13. The terms "substantially complete" and "substantiaily com- pleted" as applied to any Work refer to Substantial Comple- tion thereof. I I I I Supplementary Conditions-The part of the Contract Docu- ments which amends or supplements these General Condi- tions. I Supplier-A manufacturer. fabricator. supplier. distributor. materialman or vendor. I Underground Facilities-All pipelines. conduits. ducts. cables. wires. manholes. vaults. tanks. tunnels or other such facilities or attachments. and any encasements containing such facil- ities which have been installed underground to furnish any of the following services or materials: electricity. gases. steam. liquid petroleum products. telephone or other communica- tions. cable television. sewage and drainage removal. traffic or other control systems or water. I I Unit Price Work-Work to be paid for on the basis of unit pnces. I Work-The entire completed construction orthe various sep- arately identifiable pans thereof required to be furnished under the Contract Documents. Work is the result of per- fonning services. furnishing labor and furnishing and incor- porating materials and equipment into the construction. all as required by the Contract Documents. I I Work Directive Change-A written directive to CONTRAC- TOR. issued on or after the Effective Date of the Agreement and signed by OWNER and recommended by ENGINEER. I ordering an addition. deletion or revision in the Work. or responding to differing or unforeseen physical conditions under which the Work is to be perfonned as provided in paragraph 4.2 or 4.3 or to emergencies under paragraph 6.22. A Work Directive Change may not change the Contract Price or the Contract Time, but is evidence that the panies expect that the change directed or documented by a Work Directive Change will be incorporated in a subsequently issued Change Order following negotiations by the panies as to its effect. if any, on the Contract Price or Contract Time as provided in paragraph 10.2. Written Amendment-A written amendment of the Contract Documents. signed by OWNER and CONTRACTOR on or after the Effective Date of the Agreement and nonnally deal- ing with the nonengineering or nontechnical rather than strictly Work-related aspects of the Contract Documents. ARTICLE 2-PRELlMINARY MATTERS Delivery of Bonds: 1.1. When CONTRACTOR delivers the executed Agree- ments to OWNER. CONTRACTOR shall also deliver to OWNER such Bonds as CONTRACTOR may be required to furnish in accordance with paragraph 5.1. Copies of Docume1lJS: 2.1. OWNER shall furnish to CONTRACTOR up to ten copies (unless otherwise specified in the Supplementary Con- ditions) of the Contract Documents as are reasonably nec- essary for the execution of the Work. Additional copies will be furnished. upon request. at the cost of reproduction. Commencement ofContrtKt Time: Notice to Proceed: 2,3. The Contract Time will commence to run on the thinieth day after the Effective Date of the Agreement. or. if a Notice to Proceed is given. on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within thirty days after the Effective Date of the Agree- ment. In no event will the Contract Time commence to run later than the seventy-fifth day after the day of Bid opening or the thirtieth day after the Effective Date of the Agreement. whichever date is earlier. SUUTing the Project: 1.4. CONTRACTOR shall start to perfonn the Work on the date when the Contract Time commences to run. but no Work shall be done at the site prior to the date on which the Contract Time commences to run. Before SlIlrting Construction: 1.5. Before undertaking each part of the Work. CON- TRACTOR shall carefully study and compare the Contract Documents and check and verify pertinent figures shown 8 I I thereon and all applicable tield measurements. CONTRAC- TOR shall promptly report in writing to ENGINEER any conflict. error or discrepancy which CONTRACTOR may discover and shall obtain a written interpretation or clarifi- cation from ENGINEER before proceeding with any Work affected thereby: however. CONTRACTOR shall not be lia- ble to OWNER or ENGINEER for failure to report any conflict. error or discrepancy in the Contract Documents. unless CONTRACTOR had actual knowledge thereof or should reasonably have known thereof. I I I 2.6. Within ten days after the Effective Date of the Agree- ment (unless otherwise specified in the General Require- ments). CONTRACTOR shall submit to ENGINEER for revIew: I 2.6.1. an estimated progress schedule indicating the starting and completion dates of the various stages of the Work: I 2.6.2. a preliminary schedule of Shop Drawing sub- missions: and I 2.6.3. a preliminary schedule of values for all of the Work which will include quantities and prices of items aggregating the Contract Price and will subdivide the Work into component parts in sufficient detail to serve as the basis for progress payments during construction. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work which will be con- firmed in writing by CONTRACTOR at the time of sub- mission. I I I 2.7. Before any Work at the site is started. CONTRAC- TOR shall deliver to OWNER. with a copy to ENGINEER. certificates (and other evidence of insurance requested by OWNER) which CONTRACTOR is required to purchase and maintain in accordance with paragraphs 5.3 and 5A. and OWNER shall deliver to CONTRACTOR certificates (and other evidence of insurance requested by CONTRACTOR) which OWNER is required to purchase and maintain in accordance with paragraphs 5.6 and 5.7. . I I I Preconstruction Conference: 2.8. Within twenty days after the Effective Date of the Agreement. but before CONTRACTOR starts the Work at the site. a conference attended by CONTRACTOR. ENGI- NEER and l)thers as appropriate will be held to Jiscuss the schedules referred to in paragraph 2.6. to discuss procedures for handling Shop Drawings and other submittals and for processing Applications for Payment. and to establish a working understanding among the parties as to the Work. I I I Finali:.irzg Schedules: 2.9. At least ten days before submission of the first Appli- cation for Pa,'ment a conference attended by CONTRAC- TOR. ENGINEER and others as appropriate will be held to finaliu the ~chedules submitted in accordance ,,'ith para- I I graph 2.6. The finalized progress schedule will be acceptable to ENGINEER as providing an orderly progression of the Work to completion within the Contract Time. but such acceptance will neither impose on ENGINEER responsibility for the progress or scheduling of the Work nor relieve CON- TRACTOR from full responsibility therefor. The finalized schedule of Shop Drawing submissions will be acceptable to ENGINEER as providing a workable arrangement for pro, cessing the submissions. The finalized schedule of values will be acceptable to ENGINEER as to form and substance. ARTICLE 3-CONTRACT DOCUMENTS: INTENT. AMENDING. REUSE Intent: 3.1. The Contract Documents comprise the entire agree- ment between OWNER and CONTRACTOR concerning the Work. The Contract Documents are complementary: what is called for by one is as binding as if called for by all. The Contract Documents will be construed in accordance with the law of the place of the Project. 3.2. It is the intent of the Contract Documents to describe a functionally complete Project (or part thereot) to be con- structed in accordance with the Contract Documents. .-\ny Wor'". materials or equipment that may reasonably be inferred from the Contract Documents as being required to produce the intended result will be supplied whether or not specifically called for. When words which have a well-known technical or trade meaning are used to describe Work. materials or equipment such words shall be interpreted in accordance with that meaning. Reference to standard specifications. manuals or codes of any technical society. organization or association. or to the Laws or Regulations of any governmental authority. whether such reference be specific or by implication. shall mean the latest standard specification. manual. code or Laws or Regulations in effect at the time of opening of Bids lor. on the Effective Date of the Agreement if lhere were no Bids). except as may be otherwise specifically stated. However. no provision of any referenced standard specification. manual or code (whether or not specifically incorporaled by reference in the Contract Documents) shall be effective to change the duties and responsibilities of OWNER. CONTRACTOR or ENGINEER. or any of their consultants. agents or emplov, ees from those set forth in the Contract Documents. nor shall it be effective to <\ssign to ENGINEER. or any of ENGI- NEER's consultants. agents or employees. any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or authority to undertake responsi- bility contrary to the provisions of paragraph 9.15 or 9.16. Clarifications and interpretations of the Contract Documents ,hall be issued by ENGINEER as provided in paragraph I}A. 3.3. If. during the performance of the Work. CONTRAC- TOR tinds a conflict. error or discrepancy in the Contract Documents. CONTRACTOR shall so report to ENGINEER in writing at once and before proceeding with the Work alfected thereby shall obtain a wrilten interpretation or clarification 9 1 I from ENGINEER; however. CONTRACTOR shall not be liable to OWNER or ENGINEER for failure to repon any conflict. error or discrepancy in the Contract Documents unless CONTRACTOR had actual knowledge thereof or should reasonably have known thereof. 1 1 Amending and Suppleme1Uing Contract Documents: 3.4. The Contract Documents may be amended to pro- vide for additions. deletions and revisions in the Work or to modify the tenns and conditions thereof in one or more of the following ways: 1 1 3.4.1. a fonnal Written Amendment. 3.4.2. a Change Order (pursuant to paragraph 10.4), or I 3.4.3. a Work Directive Change (pursuant to para- graph 10.1). 1 As indicated in paragraphs 11.2 and 12.1. Contract Price and Contract Time may only be changed by a Change Order or a Written Amendment. 1 3.5. In addition. the requirements of the Contract Docu- ments may be supplemented. and minor variations and devia- tions in the Work may be authorized. in one or more of the following ways: I. 3.5.1. a Field Order (pursuant to paragraph 9.5). I 3.5.2. ENGINEER's approval of a Shop Drawing or sample (pursuant to paragraphs 6.26 and 6.27), or 1 3.5.3. ENGINEER's written interpretation or clarifi- cation (pursuant to paragraph 9.4). I Reuse of Documerrts: 3.6. Neither CONTRACTOR nor any Subcontractor or Supplier or other person or organization performing or fur- n~shing any of the Work under a direct or indirect contract with OWNER shall have or acquire any title to or ownership rights in any of the Drawings. Specifications or other docu- ments (or copies of any thereoO prepared by or bearing the seal of ENGINEER; and they shall not reuse any of them on extensions of the Project or an yother project without written consent of OWNER and ENGINEER and specific written verification or adaptation by ENGINEER. 1 1 I ARTICLE 4-A V AILABILITY OF LANDS; PHYSICAL CONDITIONS: REFERENCE POINTS I I A vailabiJiIy of lATUis: 4.1. OWNER shall furnish. as indicated in the Contract Documents. the lands upon which the Work is to be per- fonned. rights-of-way and easements for access thereto. and 1 . . such other lands which are designated for the use of CON- TRACTOR. Easements for permanent structures or perma- nent changes in existing facilities will be obtained and paid for by OWNER. unless otherwise provided in the Contract Documents. If CONTRACTOR believes that any delay in OWNER's furnishing these lands. rights-of-way or ease- ments entitles CONTRACTOR to an extension of the Con- tract Time. CONTRACTOR may make a claim therefor as provided in Anicle 12. CONTRACTOR shall.provide for all additional lands and access thereto that may be required for temporary constructior. facilities or storage of materials and equipment. Physit:aJ Conditions: 4.2.1. Explorations and Reports: Reference is made to the Supplementary Conditions for identification of those repons of explorations and tests of subsurface conditions at the site that have been utilized by ENGINEER in prep- aration of the Contract Documents. CONTRACTOR may rely upon the accuracy of the technical data contained in such repons. but not upon nontechnical data. interpreta- tions or opinions contained therein or for the completeness thereof for CONTRACTOR's purposes. Except as indi- cated in the immediately preceding sentence and in para- graph 4.2.6. CONTRACTOR shall have full responsibility with respect to subsurface conditions at the site. 4.2.2. Existing Structures: Reference is made to the Supplementary Conditions for identification of those drawings of physical conditions in or relating to existing surface and subsurface structures (except Underground Facilities referred to in paragraph 4.3) which are at or contiguous to the site that have been utilized by ENGI- NEER in preparation of the Contract Documents. CON- TRACTOR may rely upon the accuracy of the technical data contained in such drawings. but not for the complete- ness thereof for CONTRACTOR's purposes. Except as indicated in the immediately preceding sentence and in paragraph 4.2.6. CONTRACTOR shall have full respon- sibility with respect to physical conditions in or relating to such structures. 4.2.3. Report of Differing Condirions: If CONTRAC- TOR believes that: 4,2.3.1. any technical data on which CONTRAC- TOR is entitled 10 rely as provided in paragraphs 4.2.1 and 4.2.2 is inaccurate. or 4.2.3.2, any physical condition uncovered or revealed at the site differs materially from that indi. cated. reflected or referred to in the Contract Docu- ments. CONTRACTOR shall. promptly after becoming aware thereof and before perfonning any Work in connection therewith (except in an emergency as pennitted by para- graph 6.221. notify OWNER and ENGINEER in writing about the inaccuracy or difference. 10 I I 4.2,4. ENGINEER's RI:'I';I:'\\': ENGINEER will promptly review the pertinent conditions. determine the necessity of obtaining additional explorations or tests with respect thereto and advise OWN ER in writing (with a copy to CONTRACTORl of ENGINEER's findings and con- clusions. I I 4.2.5. Possihll:' Document Change: If ENGINEER concludes that there is a material error in the Contract Documents or that because of newly discovered condi- tions a change in the Contract Documents is required. a Work Directive Change or a Change Order will be issued as provided in Article 10 to reflect and document the consequences of the inaccuracy or difference. I I 4,2.6. Possihle Pricl:' and Time Adju,HlIll:'nts: In each such case. an increase or decrease in the Contract Price or an extension or shortening of the Contract Time. or any combination thereof. will be allowable to the extent that they are attributable to any such inaccuracy or difference. If OWNER and CONTRACTOR are unable to agree as to the amount or length thereof. a claim may be made therefor as provided in Articles j I and 12. I I I Physical C onditions-Cnderground F acUities: 4.3.1. Sholl'n or Indicated: The information and data shown or indicated in the Contract Documents with respect to existing Underground Facilities at or contiguous to the site is based on information and data furnished to OWNER or ENGINEER by the owners of such Underground Facil- ities or by others. Unless it is otherwise expressly pro- vided in the Supplementary Conditions: I I 4,3.1.1. OWNER and ENGINEER shall not be responsible for the accuracy or completeness of any such information or data: and. I 4,3.1.2. CONTRACTOR shall have full responsi- bility for revie\ving and checking all such information and data. for locating all Underground Facilities shown or indicated in (he Contract Documents. for coordina- tion of the Work with the owners of such Underground Facilities during construction. for the safety and pro- tection thereof as provided in paragraph 6.20 and repairing any damage thereto resulting from the Work. the cost of all of which will be considered as having been included in the Contract Price. I I I 4.3.2. Nor Sholl'n or II/c1iclIfl:'d. If an Underground Facility is uncovered or revealed at or contiguous to the site which was not shown or indicated in the Contract Documents and which CONTRACTOR could not reason- ably have been expected to be aware of. CONTRACTOR shall. promptly after becoming aware thereof and before performing any Work affected thereby (except in an emer- gency as permitted by paragraph 6.22>. identify the owner of such U ndergrounJ Facility and give wrillen notice thereof to that owner and tl) OWNER and ENGINEER. ENGI- NEER will promptl\' review the Underground Facility 10 I I I I determine the extent to which the Contract Documents should be modified to reflect and document the conse- quences of the existence of the Underground Facility. and the Contract Documents will be amended or supplemented to the extent necessary, During such time. CONTRAC- TOR shall be responsible f{)r the safety and protection of such Underground Facility as provided in paragraph 6.20. CONTRACTOR shall be allowed an increase in the Con- tract Price or an extension of the Contract Time. or both. to the extent that they are attributable to the nistence of any Underground Facility that was not shown or indicated in the Contract Documents and which CONTRACTOR could not reasonably have been expected to be aware of. If the parties are unable to agree as to the amount or length thereof. CONTRACTOR may make a claim therefor as provided in Articles II and 12. Reference Points: 4.4. OWNER shall provide engineering surveys to estab- lish reference points for construction which in ENGIN EER's judgment are necessary to enable CONTRACTOR to proceed with the Work. CONTRACTOR shall be responsible for lay- ing out the Work 1 unless otherwise specified in the General Requirements). shall protect and preserve the established reference points and shall make no changes or relocations without the prior written approval of OWNER. CONTRAC- TOR shall report to ENGINEER whenever any reference point is lost or destroyed or requires relocation because of necessary changes in grades or locations. and shall be respon- sible for the accurate replacement or relocation of such ref. erence points by professionally qualified personnel. ARTICLE 5-BONDS AND INSURANCE Performance and Other Bonds: 5.1. CONTRACTOR shall furnish performance and pay- ment Bonds. each in an amount at least equal to the Contract Price as security for the faithful performance and payment of all CONTRACTOR's obligations under the Contract Docu- ments. These Bonds shall remain in effect at least until one year after the date when final payment becomes due. except as otherwise provided by Law or Regulation or by the Con- tract Documents. CONTRACTOR shall also furnish such other Bonds as are required by the Supplementary C ondi- tions. All Bonds shall be in the forms prescribed by Law or Regulation or by the Contract Documents and be executed by such sureties as are named in the curre'nt list of "Com- panies Holding Certificates of Authority as Acceptable Sure- ties on Federal Bonds and as Acceptable Reinsuring Com- panies" as published in Circular 570 (amended) by the Audit Staff Bureau of Accounts. U.S. Treasury Department. All Bonds signed by an agent mllst be accompanied by a certified copy of the authority to act. 5.2. If (he surety on any Bond furnished by CONTR.\C- TOR is declared a bankrupt or becomes insolvent or its right 10 do business is terminated in any state where any part of I] I I the Project is located or it ceases to meet the requirements of paragraph 5.1, CONTRACTOR shall within five days thereafter substitute another Bond and Surety. both of which must be acceptable to OWNER. I I C OfllraCWr' s LiabiJi.ty Insurance: 5.3. CONTRACTOR shall purchase and maintain such comprehensive general liability and other insurance as is appropriate for the Work being performed and furnished and as will provide protection from claims set forth below which may arise out of or result from CONTRACTOR's perfor- mance and furnishing of the Work and CONTRACTOR's other obligations under the Contract Documents. whether it is to be penormed or furnished by CONTRACTOR. by any Subcontractor. by anyone directly or indirectly employed by any of them to perform or'furnish any of the Work. or by anyone for whose acts any of them may be liable: I I I 5.3.1. Claims under workers' or workmen's compen- sation. disability benefits and other similar employee ben- efi t acts: I 5.3.2. Claims for damages because of bodily injury. occupational sickness or disease. or death of CONTRAC- TOR's employees; I I 5.3.3. Claims for damages because of bodily injury. sickness or disease. or death of any person other than CONTRACTOR's employees; I 5.3.4. Claims for damages insured by personal injury liability coverage which are sustained lal by any person as a result of an offense directly or indirectly related to the employment of such person by CONTRACTOR. or (bl by any other person for any other reason: I 5.3,5. Claims for damages. other than to the Work itself. because of injury to or destruction of tangible prop- erty wherever located. including loss of use resulting therefrom: I I 5.3,6. Claims arising out of operation of Laws or Reg- ulations for damages because of bodily injury or death of any person or for damage to property: and I 5.3.7. Claims for damages because of bodily injury or death of any person or property damage arising out of the ownership. maintenance or use of any motor vehicle. I The insurance required by this paragraph 5.3 shall include the specific coverages and be written for not less than the limits of liability and coverages provided in the Supplemen- tary Conditions. or required by law. whichever is greater. The comprehensive general liability insurance shall include completed operations insurance. All of the policies of insur- ance so required to be purchased and maintained tor the certificates or other evidence thereot) shall contain a provi- sion or endorsement that the coverage afforded will not be cancelled. materially changed or renewal refused until at least I I I thiny days' prior written notice has been given to OWNER and ENGINEER by certified mail. All such insurance shall remain in effect until final payment and at all times thereafter when CONTRACTOR may be correcting. removing or replacing defective Work in accordance with paragraph 13.12. In addition. CONTRACTOR shall maintain such completed operations insurance for at least two years after final payment and furnish OWNER with evidence of continuation of such insurance at final payment and one year thereafter. Co1llraCtlull LiabiJily InsurtUJCe: 5.4. The comprehensive general liability insurance required by paragraph 5.3 will include contractual liability insurance applicable to CONTRACTOR's obligations under paragraphs 6.30 and 6.31. Owner's LiDbiJi.ty Insuranu: 5.5. OWNER shall be responsible for purchasing and maintaining OWNER's own liability insurance and. at OWNER's option. may purchase and maintain such insur- ance as will protect OWNER against claims which may arise from operations under the Contract Documents. Property Insurance: 5.6. Unless otherwise provided in the Supplementary Conditions. OWNER shall purchase and maintain propeny insurance upon the Work at the site to the full insurable value thereof (subject to such deductible amounts as may be pro- vided in the Supplementary Conditions or required by Laws and Regulationsl. This insurance shall include the interests of OWNER. CONTRACTOR. Subcontractors. ENGINEER and ENGINEER's consultants in the Work. all of whom shall be listed as insureds or additional insured parties. shall insure against the perils of fire and extended coverage and shall include "a1l risk" insurance for physical loss and damage including theft. vandalism and malicious mischief. collapse and water damage. and such other perils as may be provided in the Supplementary Conditions. and shall include damages. losses and expenses arising out of or resulting from any insured loss or incurred in the repair or replacement of any insured property (including but not limited to fees and charges of engineers. architects. attorneys and other professionalsl. If not covered under the "all risk" insurance or otherwise pro- vided in the Supplementary Conditions, CONTRACTOR shall purchase and maintain similar property insurance on portions of the Work stored on and ofT the site or in transit when such portions of the Work are to be included in an Application for Payment. 5.7. OWNER shall purchase and maintain such boiler and machinery insurance or additional property insurance as may be required by the Supplementary Conditions or Laws and Regulations which will include the interests of OWNER. CONTRACTOR. Subcontractors, ENGINEER AND ENGINEER's consultants in the Work. all of whom shall be listed as insured or additional insured parties. 12 I I 5.8. All the policies of insurance lor the certificates or other evidence thereof) required to be purchased and main- tained by OWNER in accordance with paragraphs 5.6 and 5.7 will contain a provision or endorsement that the coverage afforded will not be cancelled or materially changed or renewal refused until at least thirty days' prior written notice has been given to CONTRACTOR by certified mail and will contain waiver provisions in accordance with paragraph 5.11.2. I I I 5.9. OWNER shall not be responsible for purchasing and maintaining any property insurance to protect the inten:sts of CONTRACTOR. Subcontractors or others in the Work to the extent of any deductible amounts that are provided in the Supplementary Conditions. The risk of loss within the deductible amount. will be borne by CONTRACTOR. Sub- contractor or others suffering any such loss and if any of them wishes property insurance coverage within the limits of such amounts. each may purchase and maintain it at the purchas- er's own expense. I I I 5.10. If CONTRACTOR requests in writing that other special insurance be included in the property insurance pol- icy. OWNER shall. if possible. include such insurance. and the cost thereof will be charged to CONTRACTOR by appro- priate Change Order or Written Amendment. Prior to com- mencement of the Work at the site. OWNER shall in writing advise CONTRACTOR whether or not such other insurance has been procured by OWNER. I I Waiver of Rights: 5.11.1. OWNER and CONTRACTOR waive all rights against each other for all losses and damages caused by any of the perils covered by the policies of insurance provided in response to paragraphs 5.6 and 5.7 and any other property insurance applicable to the Work. and also waive all such rights against the Subcontractors. ENGI- NEER. ENGINEER's consultants and all other parties named as insureds in such policies for losses and damages so caused. As required by paragraph 6.11. each subcon- tract between CONTRACTOR and a Subcontractor will contain similar waiver provisions by the Subcontractor in favor of OWNER. CONTRACTOR. ENGINEER. ENGI- NEER's consultants and all other parties named as insureds. None of the above waivers shall extend to the rights that any of the insured panies may have to the proceeds of insurance held by OWN ER as trustee or othenvise pay- able under any policy so issued. I I I I I 5.11.2. OWN ER and CONTRACTOR intend that any policies pro\'ided in response to paragraphs 5.6 and 5.7 shall protect all of the panies insured and provide primary coverage for all losses and damages caused by the perils co\'ered thereby. Accordingly. all such policies shall con- tain provisiLlOs to the dTect that in the e:vent of payment of any loss or damage: the insurer will have no rights Ill' recove:ry against any of the parties named as insureds or additional insureds. and if the insurers require: separ;lle waiver forms to be signed by ENGINEER or ENGI- NEER's c\lnsultant OWNER will obtain the same. and if I I I I such waiver forms are required of any Subcontractor. CONTRACTOR will obtain the same. Receipt and Application of Proceeds: 5.12. Any insured loss under the policies of insurance required by paragraphs 5.6 and 5.7 will be adjusted with OWNER and made payable to OWNER as trustee for the insureds. as their interests may appear. subject to the require- ments of any applicable mortgage clause and of paragraph 5.13. OWNER shall deposit in a separate account any money so received. and shall distribute it in accordance with such agreement as the panies in interest may reach. If no other special agreement is reached the damaged Work shall be repaired or replaced. the moneys so received applied on account thereof and the Work and the cost thereof covered by an appropriate Change Order or Written Amendment. 5.13. OWNER as trustee shall have power to adjust and settle any loss with the insurers unless one of the panies in interest shall object in writing within fifteen days after the occurrence of loss to OWNER's exercise of this power. If such objection be made. OWNER as trustee shall make set- tlement with the insurers in accordance with such agreement as the panies in interest may reach. If required in writing by any party in interest. OWNER as trustee shall. upon the occurrence of an insured loss. give bond for the proper per- formance of such duties. Acceptance of Insurance: 5.14. If OWNER has any objection to the coverage afforded by or other provisions of the insurance reqcired to be pur- chased and maintained by CONTRACTOR in accordance with paragraphs 5.3 and 5.4 on the basis of its not complying with the Contract Documents. OWNER shall notify CON- TRACTOR in writing thereof within ten days of the date of delivery of such certificates to OWNER in accordance with paragraph 2.7. If CONTRACTOR has any objection to the coverage afforded by or other provisions of the policies of insurance required to be purchased and maintained by OWNER in accordance with paragraphs 5.6 and 5.7 on the basis of their not. complying with the Contract Documents. CON- TRACTOR shall notify OWNER in writing thereof within ten days of the date of delivery of such cenificates to CON- TRACTOR in accordance with paragraph 2.7. OWNER and CONTRACTOR shall each provide to the other such addi- tional information in respect of insurance provided by each as the other may reasonably request. Failure by OWNER or CONTRACTOR to give any such notice of objection within the time provided shall constitute acceptance of such insur- ance purchased by the other as complying with the Contract Documents. Partilll Uti/i:.ation-Property Insurance: 5.15. If OWNER finds it necessary to occupy or use a ponion or portions of the Work prior to Substantial Comple- tion of all the Work. such use or occupancy may be accom- plisheu in accordance with paragraph 14.10: provided that no 13 I I such use or occupancy shall commence before the insurers providing the property insurance have acknowledged notice thereof and in writing effected the changes in coverage neces- sitated thereby. The insurers providing the property insur- ance shall consent by endorsement on the policy or policies, but the property insurance shall not be cancelled or lapse on account of any such partial use or occupancy. I I I ARTICLE 6-CONTRACTOR'S RESPONSIBILITIES I Supervision and Su~rinundtnct: 6,1. CONTRACTOR shall supervise and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Doc- uments. CONTRACTOR shaH be solely responsible for the means. methods. techniques. sequences and procedures of construction. but CONTRACTOR shall not be responsible for the negligence of others in the design or selection of a specific means. method. technique, sequence or procedure of construction which is indicated in and required by the Contract Documents. CONTRACTOR shall be responsible to see that the finished Work complies accurately with the Contract Documents. I I I I 6.2. CONTRACTOR shall keep on the Work at all times during its progress a competent resident superintendent. who shall not be replaced without written notice to OWNER and ENGINEER except under extraordinary circumstances. The superintendent will be CONTRACTOR's representative at the site and shall have authority to act on behalf of CON- TRACTOR. All communications given to the superintendent shall be as binding as if given to CONTRACTOR. I I I Labor. MaJerials and Equipment: 6.3. CONTRACTOR shall provide competent. suitably qualified personnel to survey and layout the' Work and per- form construction as required by the Contract Documents. CONTRACTOR shall at all times maintain good discipline and order at the site. Except in connection with the safety or protection of persons or the Work or property at the site or adjacent thereto. and except as otherwise indicated in the Contract Documents. all Work at the site shall be performed during regular working hours. and CONTRACTOR will not permit overtime work or the performance of Work on Sat- urday. Sunday or any legal holiday without OWNER's writ- ten consent given after prior written notice to ENGINEER. I I I 6.4. Unless otherwise specified in the General Require- ments. CONTRACTOR shall furnish and assume full respon- sibility for all materials. equipment. labor. transportation. construction equipment and machinery. tools. appliances. fuel. power. light. heat. telephone, water. sanitary facilities. temporary facilities and all other facilities and incidentals necessary for the furnishing. performance. testing. start-up and completion of the Work. I I I 6.5. All materials and equipment shall be of good quality and new. except as otherwise provided in the Contract Doc- uments. If required by ENGINEER. CONTRACTOR shall furnish satisfactory evidence (including reports of required tests) as to the kind and quality of materials and equipment. All materials and equipment shall be applied. installed. con- nected. erected. used. cleaned and conditioned in accordance with the instructions of the applicable Supplier except as otherwise provided in the Contract Documents: but no pro- vision of any such instructions will be effective to assign to ENGINEER. or any of ENGINEER's consultants. agents or employees. any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or author- ity to undertake responsibility contrary to the provisions of paragraph 9.15 or 9.16. Adjusting Progress Schedule: 6.6. CONTRACTOR shall submit to ENGINEER for acceptance (to the extent indicated in paragraph 2.9) adjust- ments in the progress schedule to reflect the impact thereon of new developments: these win conform generally to the progress schedule then in effect and additionally will comply with any provisions of the General Requirements applicable thereto. Substitutes or "Or-EqU4l" Items: 6.7.1. Whenever materials or equipment are specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier the naming of the item is intended to establish the type. function and quality required. Unless the name is followed by words indicating that no substitution is permitted. materials or equipment of other Suppliers may be accepted by ENGINEER if sufficient information is submitted by CONTRACTOR to allow ENGINEER to determine that the material or equipment proposed is equivalent or equal to that named. The procedure for review by ENGINEER will include the following as supplemented in the General Requirements. Requests for review of substitute items of material and equipment will not be accepted by ENGI- NEER from anyone other than CONTRACTOR. If CON- TRACTOR wishes to furnish or use a substitute item of material or equipment. CONTRACTOR shall make writ- ten application to ENGINEER for acceptance thereof. certifying that the proposed substitute will perform ade- quately the functions and achieve the results called for by the general design. be similar and of equal substance to that specified and be suited to the same use as that spec- ified. The application will state that the evaluation and acceptance of the proposed substitute will not prejudice CONTRACTOR's achievement of Substantial Comple- tion on time. whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with OWNER for work on the Project) to adapt the design to the proposed substitute and whether or not incorporation or use of the substitute in connection with the Work is subject to payment of any license fee or 14 I I royally. All variations of the proposed substitute from that specified will be identified in the application and available maintenance. repair and replacement service will be indi- cated. The application will also contain an itemized esti- mate of all COSts that will resull directly or indirectly from acceptance of such substitute. including costs of redesign and claims of other contractors affected by the resulting change. all of which shall be considered by ENGINEER in evaluating the proposed substitute. E;-.JGINEER may require CONTRACTOR [0 furnish at CONTRACTOR's expense additional data about the proposed substitute. I I I 6. 7.~. If a specific means. method. technique. sequence or procedure of construction is indicated in or required by the Contract Documents. CONTRACTOR may furnish or utilize a substitute means. method. sequence. technique or procedure of construction acceptable to ENGINEER. if CONTRACTOR submits sufficient information to allow ENGIN EER to determine that the substitute proposed is equivalent to that indicated or required by the Contract Documents. The procedure for review by E:-JGINEER will be similar to that orovided in paragraph 6.7. I as applied by E;-.JGINEER and as may be supplemented in the Gen- eral Requirements. I I I I 6.7.3. ENGINEER will be allowed a reasonable time within which to evaluate each proposed substitute. ENGI- NEER will be the sole judge of acceptability. and no substitute will be ordered. installed or utilized without ENGINEER's prior written acceptance which will be evi- denced by either a Change Order or an approved Shop Drawing. OWNER may require CONTRACTOR to fur- nish at CONTRACTOR's expense a special performance guarantee or other surety with respect to any substitute. ENGINEER will record time required by ENGINEER and ENGINEER's consullants in evaluating substitutions proposed by CONTRACTOR and in making changes in the Contract Documents occasioned thereby, \Vhether or not ENGINEER accepts a proposed substitute. CON- TRACTOR shall reimburse OWNER for the charges of ENGINEER and ENGINEER's consultants for evaluat- ing each proposed substitute. I I I I I Conceming Subcontractors. Suppliers and Others: 6.8. I. CONTRACTOR shall not employ any Subcon- tractor. Su pplier or other person or organization Ii ncluding those acceptable to OWNER and ENGINEER as indi- cated in paragraph 6.8.~). whether initially or as a substi- tute. against whom OWNER or ENGINEER may ha\e reasonable objection. CONTRACTOR shall nOl be required to employ any Subcontractor. Supplier or other person or organization to furnish or perform any of the Work against whom CONTRACTOR has reasonable objection. 6.l:!.~. If the Supplementary Conditions require the identity of certain Subcontractors. Suppliers llr other per, sons or organizations (including those who are to furnish the principal items of materials and equipment) to be sub- mitted to OWN ER in advance of the specified date prior to the Efkctive Oat.: of the Agreement for aCl:.:ptance b\' I I I I I OWNER and ENGINEER and if CONTRACTOR has submitted a list thereof in accordance with the Supple- mentary Conditions. OWN ER's or ENGIN EER's accept- ance (either in writing or by failing to make written objec- tion thereto by the date indicated for acceptance or objec- tion in the bidding documents or the Contract Documents) of any such Subcontractor. Supplier or other person or organization so identified may be revoked on the basis of reasonable objection after due investigation. in which case CONTRACTOR shall submit an acceptable substitute. the Contract Price will be increased by the difference in the cost occasioned by such substitution and an appropriate Change Order will be issued or Wrillen Amendment signed. No acceptance by OWNER or ENGINEER of any such Subcontractor. Supplier or other person or organization shall constitute a waiver of any right of OWNER or ENGI- NEER to reject defecril'e Work. 6.9. CONTRACTOR shall be fully responsible to OWNER and ENGINEER for all acts and omissions of the Subcon- tractors. Suppliers and other persons and organizations per- forming or furnishing any of the Work under a direct or indirect contract with CONTRACTOR just as CONTRAC- TOR is responsible for CONTRACTOR's own acts and omis- sions. Nothing in the Contract Documents shall create any contractual relationship between OWNER or ENGINEER and any such Subcontractor. Supplier or other person or organization. nor shall it create any obligation on the part of OWNER or ENGINEER to payor to see to the payment of any moneys due any such Subcontractor. Supplier or other person or organization except as may otherwise be required by Laws and Regulations. 6.10. 'The divisions and sections of the Specifications and the identifications of any Drawings shall not control CON- TRACTOR in dividing the Work among Subcontractors or Suppliers or delineating the Work to be performed by any specific trade. 6.11. .-\11 Work performed for CONTRACTOR by a Sub- contractor will be pursuant to an appropriate agreement between CONTRACTOR and the Subcontractor which spe- cifically binds the Subcontractor to the applicable terms and conditions of the Contract Documents for the benefit of OWNER and ENGINEER and contains waiver provisions as required by paragraph 5.11. CONTRACTOR shall pay each Subcontractor a just share of any insurance moneys received by CONTRACTOR on account of losses under pol- icies issued pursuant to paragraphs 5.6 and 5.7. Patent Fees and Royalties: 6.12. CONTRACTOR shall pay all license fees and roy- alties and assume all costs incident to the use in the perfor- mance of the Work or the incorporation in the Work of any invention. design. process. product or device which is (he subject of patent rights or l:opyrights held hy others. If a particular invention. design. process. product or device is specified in the Contract Documents for use in (he perfor- mance of [he Work and iftn (he actual knowledge of OWNER 15 I I or ENG INEER its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others. the existence of such rights shall be disclosed by OWNER in the Contract Documents. CONTRACTOR shall indemnify and hold harmless OWNER and ENGINEER and anyone directly or indirectly employed by either of them from and against all claims. damages. losses and expenses (including attorneys' fees and court and arbitration costs) arising out of any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention. design. process. product or device not specified in the Contract Documents. and shall defend all such claims in connection with any alleged infringement of such rights. I I I I I Permils: 6.13. Unless otherwise provided in the Supplementary Conditions. CONTRACTOR shall obtain and pay for all con- struction permits and licenses. OWNER shall assist CON- TRACTOR. when necessary. in obtaining such permits and licenses. CONTRACTOR shall pay all governmental charges and inspection fees necessary for the prosecution of the Work. which are applicable at the time of opening of Bids. or if there are no Bids on the Effective Date of the Agreement. CON- TRACTOR shall pay all charges of utility owners for con- nections to the Work, and OWNER shall pay all charges of such utility owners for capital costs related thereto such as plant investment fees. I I I I Lilws and Regulations: 6.14.1. CONTRACTOR shall give all notices and comply with all Laws and Regulations applicable to fur- nishing and performance of the Work. Except where oth- erwise expressly required by applicable Laws and Regu- lations. neither OWNER nor ENGINEER shall be respon- sible for monitoring CONTRACTOR's compliance with any Laws or Regulations. I I 6.14.2. If CONTRACTOR observes that the Specifi- cations or Drawings are at variance with any Laws or Regulations. CONTRACTOR shall give ENGINEER prompt written notice thereof. and any necessary changes will be authorized by one of the methods indicated in paragraph 3.4. If CONTRACTOR performs any Work knowing or having reason to know that it is contrary to such Laws or Regulations. and without such notice to ENGINEER. CONTRACTOR shall bear all costs arising therefrom: however. it shall not be CONTRACTOR's pri- mary responsibility to make certain that the Specifications and Drawings are in accordance with such Laws and Regulations. I I I I Taxes: I 6.15. CONTRACTOR shall pay all sales. consumer. use and other similar taxes required to be paid by CONTRAC- TOR in accordance with the Laws and Regulations of the I place of the Project which are applicable during the perfor- mance of the Work. Use of Premises: 6.16. CONTRACTOR shall confine construction equip- ment. the storage of materials and equipment and the oper- ations of workers to the Project site and land and areas iden- tified in and pennitted by the Contract Documents and other land and areas permitted by Laws and Regulations. rights- of-way. permits and easements. and shall not unreasonably encumber the premises with construction equipment or other materials or equipment. CONTRACTOR shall assume full responsibility for any damage to any such land or area. or to the owner or occupant thereof or of any land or areas contig- uous thereto. resulting from the performance of the Work. Should any claim be made against OWNER or ENGINEER by any such owner or occupant because of the performance of the Work. CONTRACTOR shall promptly attempt to settle with such other party by agreement or otherwise resolve the claim by arbitration or at law. CONTRACTOR shall. to the fullest extent permitted by Laws and Regulations. indemnify and hold OWNER and ENGINEER harmless from and against all claims. damages. losses and expenses (including. but not limited to. fees of engineers. architects. attorneys and other professionals and court and arbitration costs) arising directly. indirectly or consequentially out of any action. legal or equi- table, brought by any such other party against OWNER or ENGINEER to the extent based on a claim arising out of CONTRACTOR's performance of the Work. 6.17. During the progress of the Work. CONTRACTOR shall keep the premises free from accumulations of waste materials. rubbish and other debris resulting from the Work. At the completion of the Work CONTRACTOR shall remove all waste materials. rubbish and debris from and about the premises as well as all tools. appliances. construction equip- ment and machinery. and surplus materials. and shall leave the site clean and ready for occupancy by OWNER. CON- TRACTOR shall restore to original condition all propeny not designated for alteration by the Contract Documents. 6.18. CONTRACTOR shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure. nor shall CONTRACTOR subject any part of the Work or adjacent propeny to stresses or pressures that will endanger it. Record Docume1llS: 6.19. CONTRACTOR shall maintain in a safe place at the site one record copy of all Drawings. Specifications. Addenda. Written Amendments. Change Orders. Work Directive Changes. Field Orders and written interpretations and clarifications (issued pursuant to paragraph 9.4) in good order and annotated to show all changes made during con- struction. These record documents together with all approved samples and a counterpan of all approved Shop Drawings will be available to ENGINEER for reference. Upon com- 16 I I pletion of the Work. these record documents. samples and Shop Drawings will be delivered to ENGINEER for OWNER. I Safety and Protection: 6.20. CONTRACTOR shall be responsible for initiating. maintaining and supervising all safety precautions and pro- grams in connection with the Work. CONTRACTOR shall take all necessary precautions for the safety of. and shall provide the necessary protection 10 prevent damage. injury or loss 10: I I I 6.20.1. all employees on the Work and other persons and organizations who may be atfected thereby: 6.20.2. all the Work and materials and equipment 10 be incorporated therein. whether in slOrage on or off the site: and I 6.20.3. other property at the site or adjacent thereto. including trees. shrubs. lawns. walks. pavements. road, ways. structures. utilities and Underground Facilities not designated for removal. relocation or replacement in the course of construction. I I CONTRACTOR shall comply with all applicable Laws and Regulations of any public body having jurisdiction for the safety of persons or property or to protect them from damage. injury or loss: and shall erect and maintain all necessary safeguards for such safety and protection. CONTRACTOR shall notify owners of adjacent property and of Underground Facilities and utility owners when prosecution of the Work may atTect them. and shall cooperate with them in the pro- tection. removal. relocation and replacement of their prop- erty. ,-\11 damage. injury or loss to any property referred to in paragraph 6.20.2 or 6.20.3 caused. directly or indirectl\'. in whole or in part. by CONTRACTOR. any Subcontractor. Supplier or any other person or organization directly or indi- rectly employed by any of them to pert"orm or furnish any at the Work or anyone for whose acts any of them may be liable, shall be remedied by CONTRACTOR (except damage or loss attributable to the fault of Drawings or Specifications or to the acts or omissions of OWN ER or ENGINEER or anyone employed by either of them or anyone for whose acts either of them may be liable. and not attributable. direl:tly or indi- rectly. in whole or in part. to the fault or negJigen-:e of CON- TRACTOR!. CONTRACTOR's duties and responsibilities for the safet\' and protection of the Work shall continue until such time as all the Work is completed and ENGI:"JEER has issued a notice to OWNER and CONTRACTOR in al:cord- ance with paragraph 14.13 that the Work is acceptable (exl:ept as otherwise expressly provided in connection \\'ith Substan- tial Completion!. I I I I I I I I 6,21. CONTRACTOR shall designate a respl'nsible rep- resentative at the site whose duty shall be the rre\'ention lIt accidents. This person shall be;: CONTRACTOR' s superin- tendent unless otherwise Jesignaled in writing by CO:\- TR.-\CTOR 10 OWN ER, I I Emergencies: 6.22. In emergencies affecting the safety or protection of persons or the Work or property at the site or adjacent thereto. CONTRACTOR. without special instruction or authorization from ENGINEER or OWNER. is obligated to act to prevent threatened damage. injury or loss. CONTRACTOR shall give ENGINEER prompt written notice if CONTRACTOR believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. IfENGl- NEER determines that a change in the Contract Documents is required because of the action taken in response to an emergency. a Work Directive Change or Change Order will be issued to document the consequences of the changes or variations. Shop Drawings and Samples: 6.23. After checking and verifying all field measurements and after complying with applicable procedures specified in the General Requirements. CONTRACTOR shall submit to ENGINEER for review and approval in accordance with the accepted schedule of Shop Drawing submissions (see para-' graph 2.9), or for other appropriate action if so indicated in the Supplementary Conditions. five copies lunless otherwise specified in the General Requirements) of all Shop Drawings. which will bear a stamp or specific written indication that CONTRACTOR has satisfied CONTRACTOR's responsi- bilities under the Contract Documents with respect to the review of the submission. All submissions will be identified as ENGINEER may require. The data shown on the Shop Drawings will be complete with respect to quantities. dimen- sions. specified performance and design criteria. materials and similar data to enable ENGINEER to review the infor- mation as required. 6..24. CONTRACTOR shall also submit to ENGINEER for review and approval with such promptness as to cause no delay in Work. all samples required by the Contract Doc- uments. All samples will have been checked by and accom- panied by a specific written indication that CONTRACTOR has satisfied CONTRACTOR's responsibilities under the Contract Documents with respect to the review of the sub- mission and will be identified clearly as to material. S4Pplier. pertinent data such as catalog numbers and the use for which intended. 6.25.1. Before submission of each Shop Drawing or sample CONTRACTOR shall have determined and veri- fied all quantities. dimensions. specified performance cri- teria. installalion requirements. materials. catalog num- bers and similar dala \\ith respect thereto and reviewed or coordinated each Shop Drawing or s"mple with other Shop Drawings and samples and with the requirements of the Work and the Contract Documents. 6.25.2. Al Ihe time llf each submission. CONTRAC- TOR shall give ENGIN EER spel:iric wrilten nOlic~ of each variation that the Shop Drawings or samples may have from the requirements llf the Cllntract Documents. and. in addilion. shall cause a specitil: notal ion 10 be made on 17 I I each Shop Drawing submitted to ENGINEER for review and approval of each such variation. I 6.26. ENGINEER will review and approve with reason- able promptness Shop Drawings and samples. but ENGI- NEER's review and approval will be only for conformance with the design concept of the Project and for compliance with the information given in the Contract Documents and shall not extend to means, methods. techniques. sequences or procedures of construction (except where a specific means. method. technique. sequence or procedure of construction is indicated in or required by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. CON- TRACTOR shall make corrections required by ENGINEER. and shall return the required number of corrected copies of Shop Drawings and submit as required new samples for review and approval. CONTRACTOR shall direct specific attention in writing to revisions other than the corrections called for by ENGINEER on previous submittals. I I I I I 6.27. ENGINEER's review and approval of Shop Draw- ings or samples shall not relieve CONTRACTOR from responsibility for any variation from the requirements of the Contract Documents unless CONTRACTOR has in writing called ENGINEER's attention to each such variation at the time of submission as required by paragraph 6.15.2 and ENGINEER has given written approval of each such varia- tion by a specific written notation thereof incorporated in or accompanying the Shop Drawing or sample approval; nor will any approval by ENGINEER relieve CONTRACTOR from responsibility for errors or omissions in the Shop Draw- ings or from responsibility for having complied with the pro- visions of paragraph 6.25.1. I I I I 6.28. Where a Shop Drawing or sample is required by the Specifications. any related Work performed prior to ENGI- NEER's review and approval of the pertinent submission will be the sole expense and responsibility of CONTRACTOR. I I Continuing the Work: 6.29. CONTRACTOR shall carry on the Work and adhere to the progress schedule during all disputes or disagreements with OWNER. No Work shall be delayed or postponed pend- ing resolution of any disputes or disagreements. except as permitted by paragraph 15.5 or as CONTRACTOR and OWNER may otherwise agree in writing. I I I ruhmnificalion: 6.30. To the fullest extent permitted by Laws and Regu- lations CONTRACTOR shall indemnify and hold harmless OWNER and ENGINEER and their consultants. agents and employees from and against all claims. damages, losses and expenses. direct. indirect or consequential (including but not limited to fees and chargcs of enginccrs. architccts, attorneys and other professionals and court and arbitration costs) aris- ing out of or resulting from the performance of the Work, I I I provided that any such claim. damage. loss or expense (a) is attributable to bodily injury. sickness. disease or death. or to injury to or destruction of tangible property (other than the Work itselO including the loss of use resulting therefrom and (b) is caused in whole or in part by any negligent act or omission of CONTRACTOR. any Subcontractor. any person or organization directly or indirectly employed by any of them to perform or furnish any of the Work or anyone for whose acts any of them may be liable. regardless of whether or not it is caused in pan by a pany indemnified hereunder or arises by or is imposed by Law and Regulations regardless of the negligence of any such pany. 6.31. In any and all claims against OWNER or ENGI- NEER or any of their consultants. agents or employees by any employee of CONTRACTOR. any Subcontractor. any person or organization directly or indirectly employed by any of them to perform or furnish any of the Work or anyone for whose acts any of them may be liable. the indemnification obligation under paragraph 6.30 shall not be limited in any way by any limitation on the amount or type of damages. compensation or benefits payable by or for CONTRACTOR or any such Subcontractor or other person or organization under workers' or workmen's compensation acts, disability benefit acts or other employee benefit acts. 6.32. The obligations of CONTRACTOR under para- graph 6.30 shall not extend to the liability of ENGINEER. ENGINEER's consuJtants. agents or employecs arising out of the preparation or approval of maps, drawings, opinions. reports, surveys. Change Orders. designs or specifications. ARTICLE 7-OTHER WORK Relaled Work at Sue: 7. I . OWNER may perform other work related to the Proj- ect at the site by OWNER's own forces. have other work performed by utility owners or let othcr direct contracts therefor which shall contain General Conditions similar to these. If the fact that such other work is to be performed was not noted in the Contract Documents. written notice thereof will be given to CONTRACTOR prior to starting any such other work; and. if CONTRACTOR believes that such perfor- mance will involve additional expcnse to CONTRACTOR or requires additional time and the panies are unable to agree as to the extent thereof. CONTRACTOR may make a claim therefor as provided in Articles II and 12. 7.2. CONTRACTOR shall afford each utility owner and other contractor who is a party to such a direct contract (or OWNER, if OWNER is performing the additional work with OWNER's employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work. and shall properly connect and coordinate the Work with theirs. CONTRACTOR shall do all cutting, fitting and patching of the Work that may be required to make its several pans come together properly and integrate with such other work. CON- 18 1 1 I I' 1 I I I I 1 I 1 I 1 I I I I 1 TRACTOR shall not endanger any work of others by cutting, excavating or otherwise altering their work and will only cut or alter their work with the written consent of ENGINEER and the others whose work will be affected. The duties and responsibilities of CONTRACTOR under this paragraph are for the benefit of such utility owners and other contractors to the extent that there are comparable provisions for the benefit of CONTRACTOR in said direct contracts between OWN ER and such utility owners and other contractors. 7.3. If any part of CONTRACTOR's Work depends for proper execution or results upon the work of any such other contractor or utility owner (or OWNERl. CONTRACTOR shall inspect and promptly report to ENGINEER in writing any delays. defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. CONTRACTOR's failure so to report will constitute an acceptance of the other work as fit and proper for integra- tion with CONTRACTOR's Work except for latent or non- apparent defects and deficiencies in the other work. Coordination: 7.4. If OWNER contracts with others for the perfor, mance of other work on the Project at the site. the person or organization who will have authority and responsibility for coordination of the activities among the various prime con- tractors will be identified in the Supplementary Conditions. and the specific matters to be covered by such authority and responsibility will be itemized. and the extent of such author- ity and responsibilities will be provided. in the Supplementary Conditions. Unless otherwise provided in the Supplementary Conditions. neither OWNER nor ENGINEER shall have any authority or responsibility in respect of such coordination. ARTICLE 8-0WNER'S RESPONSIBILITIES 8.1. OWNER shall issue all communications to CON- TRACTOR through ENGINEER. 8.2. In case of termination of the employment of ENGI- NEER. OWNER shall appoint an engineer against whom CONTRACTOR makes no reasonable objection. whose sta- tus under the Contract Documents shall be that of the former ENGINEER. Any dispute in connection with such appoint- ment shall be subject to arbitration. 8.3. OWNER shall furnish the data required of OWNER under the Contract Documents promptly and shall make pay- ments to CONTRACTOR promptly after they are due as provided in paragraphs 14.4 and 14.13. 8.4. OWNER's duties in respect of providing lands and easements and providing engineering surveys to establish reference points are set forth in paragraphs 4.1 and 4.4. Para- graph 4.2 refers to OWNER's identifying and making avail- able to CONTRACTOR copies of reports of explorations and tests of subsurt'ace conditions at the site and in existing struc- tures which have been utilized by ENGINEER in preparing the Drawings and Specifications. 8.5. OWNER's responsibilities in respect of purchasing and maintaining liability and property insurance are set forth in paragraphs 5.5 through 5.8. 8.6. OWNER is obligated to execute Change Orders as indicated in paragraph 10.4. 8.7, OWNER's responsibility in respect of certain inspections. tests and approvals is set forth in paragraph 13.4. 8.8. In connection with OWNER's right to stop Work or suspend Work. see paragraphs 13.10 and I ).1. Paragraph 15.2 deals with OWNER's right to terminate services of CON, TRACTOR under certain circumstances, ARTICLE 9-ENGINEER'S STATUS DURING CONSTRUCTION Owner's Representative: 9.1. ENGINEER will be OWNER's representative dur- ing the construction period. The duties and responsibilities and the limitations of authority of ENGINEER as OWNER's representative during construction are set forth in the Con- tract Documents and shall not be extended without written consent of OWNER and ENGINEER. Visits to Site: 9.2. ENGINEER will make visits to the site at intervals appropriate to the various stages of construction to observe the progress and quality of the executed Work and to deter- mine. in general. if the Work is proceeding in accordance with the Contract Documents. ENGINEER will not be required to make e:<haustive or continuous on-site inspections to check the quality or quantity of the Work. ENGINEER's efforts will be directed toward providing for OWNER a greater degree of confidence that the completed Work will conform to the Contract Documents. On the basis of such visits and on-site observations as an experienced and qualified design profes- sional. ENGINEER will keep OWNER informed ofth~ prog- ress of the Work and will endeavor to guard OWNER against defects and deficiencies in the Work. Project Representation: 9.3. If OWNER and ENGINEER agree. ENGINEER will furnish a Resident Project Representative to assist ENGINEER in observing the performance of the Work. The duties. responsibilities and limitations of authority of any such Resident Project Representative and assistants will be as provided in the Supplementary Conditions. If OWNER designates another agent to represent OWNER at th~ site who is not ENGlNEER's agent or employee. the duties. responsibilities and limitations of authority of such other person will be as provided in the Supplementary Conditions, 19 I I Clarifications and lnurpreuuions: 9.4. ENGINEER will issue with reasonable promptness such wrinen clarifications or interpretations of the require- ments of the Contract Documents (in the form of Drawings or otherwise) as ENGINEER may determine necessary, which shall be consistent with or reasonably inferable from the overall intent of the Contract Documents. If CONTRACTOR believes that a wrinen clarification or interpretation justifies an increase in the Contract Price or an extension of the Contract Time and the panies are unable to agree to the amount or extent thereof. CONTRACTOR may make a claim therefor as provided in Article II or Anicle 12. I I I I AUlhoriud Variations in Work: 9.5. ENGINEER may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Time and are consistent with the overall intent of the Contract Documents. These may be accomplished by a Field Order and will be binding on OWNER. and also on CONTRACTOR who shall perform the Work involved promptly, If CONTRACTOR believes that a Field Order justifies an increase in the Contract Price or an extension of the Contract Time and the parties are unable to agree as to the amount or extent thereof. CONTRACTOR may make a claim therefor as provided in Article II or 12. I I I I Rejecting Defective Work: 9.6. ENGINEER will have authority to disapprove or reject Work which ENGINEER believes to be defective. and will also have authority to require special inspection ortesting of the Work as provided in paragraph 13.9. whether or not the Work is fabricated. installed or completed. I I Shop Drawings. Ciulnge Orden and Payments: 9.7. In connection with ENGINEER's responsibility for Shop Drawings and samples. see paragraphs 6.23 through 6.29 inclusive. I I 9.8. In connection with ENGINEER's responsibilities as to Change Orders. see Anicles 10. II and 12. 9.9. In connection with ENGINEER's responsibilities in respect of Applications for Payment. etc.. see AMicle 14. I DetermilUUions for UniJ Pmes: 9.10. ENGINEER will determine the actual quantities and classifications of Unit Price Work performed by CON. TRACTOR. ENGINEER will review with CONTRACTOR ENGINEER's preliminary determinations on such matters before rendering a written decision thereon (by recommen- dation of an Application for Payment or otherwise). ENGI- N EER . s written decisions thereon will be final and binding upon OWNER and CONTRACTOR. unless. within ten days after the date of any such decision. either OWNER or CON- TRACTOR delivers to the other pany to the Agreement and I I I I to ENGINEER written notice of intention to appeal from such a decision. Decisions on Displlles: 9.11. ENGINEER will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. Claims. disputes and other maUCrs relating to the acceptability of the Work or the interpretation of the requirements of the Contract Documents penaining to the performance and furnishing of the Work and claims under Anicles II and 12 in respect of changes in the Contract Price or Contract Time will be referred initially to ENGINEER in writing with a request for a formal decision in accordance with this paragraph. which ENGINEER will render in writing within a reasonable time. Written notice of each such claim, dispute and other matter will be delivered by the claimant to ENGINEER and the other pany to the Agreement promptly (but in no event later than thiny days) after the occurrence of the event giving rise thereto. and written supponing data will be submitted to ENGINEER and the other pany within sixty days after such occurrence unless ENGINEER allows an additional period of time to ascenain more accurate data in suppon of the claim. 9.12. When functioning as interpreter and judge under paragraphs 9.10 and 9.11. ENGINEER will not show par- tiality to OWNER or CONTRACTOR and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by ENGINEER pursuant to paragraphs 9.10 and 9.11 with respect to any such claim. dispute or other matter (except any which have been waived by the making or acceptance of final pay. ment as provided in paragraph 14.16) will be a condition precedent to any exercise by OWNER or CONTRACTOR of such rights or remedies as either may otherwise have under the Contract Documents or by Laws or Regulations in respect of any such claim. dispute or other matter. LimiIalions on ENGINEER's Responsibililies: 9.13. Neither ENGINEER's authority to act under this Anicle 9 or elsewhere in the Contract Documents nor any decision made by ENG INEER in good faith either to exercise or not exercise such authority shall give rise to any duty or responsibility of ENGINEER to CONTRACTOR. any Sub- contractor. any Supplier. or any other person or organization performing any of the Work. or to any surety for any of them. 9. ]4. Whenever in the Contract Documents the terms "as ordered". .. as directed". .. as required". .. as allowed", .. as approved" or terms of like effect or impon are used. or the adjectives "reasonable", "suitable", "acceptable". "proper" or "satisfactory" or adjectives of like effect or impon are used to describe a requirement. direction. review or judgment of ENGINEER as to the Work. it is intended that such requirement. direction. review or judgment will be solely to evaluate the Work for compliance with the Contract Docu- ments (unless there is a specific statement indicating other- wise!. The use of any such term or adjective shall not be 20 I I effective to assign to ENGINEER any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or authority to undertake responsibility contrary to the provisions of paragraph 9.15 or 9.16. I 9.15. ENGINEER will not be responsible for CON- TRACTOR's means. methods. techniques. sequences or pro- cedures of construction. or the safety precautions and pro- grams incident thereto. and ENGINEER will not be respon- sible for CONTRACTOR's failure to perform or furnish the Work in accordance with the Contract Documents. I I 9.16. ENGINEER will not be responsible for the acts or omissions of CONTRACTOR or of any Subcontractor. any Supplier. or of any other person or organization performing or furnishing any of the Work. I I ARTICLE IO-CHANGES IN THE WORK I ] O. I. Without invalidating the Agreement and without notice to any surety. OWNER may. at any time or from time to time. order additions. deletions or revisions in the Work: these will be authorized by a Written Amendment. a Change Order. or a Work Directive Change. Upon receipt of any such document. CONTRACTOR shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). I I I 10.2. If OWNER and CONTRACTOR are unable to agree as to the extent. if any. of an increase or decrease in the Contract Price or an extension or shortening of the Contract Time that should be allowed as a result of a Work Directive Change, a claim may be made therefor as provided in Article II or Article 12. I I 10.3. CONTRACTOR shall not be entitled to an increase in the Contract Price or an extension of the' Contract Time with respect to any Work performed that is not required by the Contract Documents as amended. modified and supple- mented as provided in paragraphs 3.4 and 3.5. except in the case of an emergency as provided in paragraph 6.22 and except in the case of uncovering Work as provided in para- graph 13.9, I I 10,~. OWNER and CONTRACTOR shall execute appro- priate Change Orders lor Written Amendments) covering: I 10.4.1. changes in the Work which are ordered by OWNER pursuant to paragraph 10.\. are required because of acceptance of JefeCTil'e Work under paragraph 13. U or correcting deFee/iI'e Work under paragraph 13 .14. or are agreed to by the parties: I I 10.4.2. changes in (he Contract Price or Contract Time which are agreed to hy the parties: and I 10.4.3. changes in the Contract Price or Contract Time which embody the substance of any written decision ren- dered by ENGINEER pursuant to paragraph 9.11: provided that. in lieu of executing any such Change Order. an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations. but during any such appeal. CON- TRACTOR shall carryon the Work and adhere to the prog- ress schedule as provided in paragraph 6.29. 10.5. If notice of any change affecting the general scope of the Work or the provisions or the Contract Documents (including, but not limited to. Contract Price or Contract Time) is required by the provisions of any Bond to be given to a surety. the giving of any such notice will be CONTRAC- TOR's responsibility. and the amount of each applicable Bond will be adjusted accordingly. ARTICLE ll-CHANGE OF CONTRACT PRICE 11.1. The Contract Price constitutes the total compen- sation (subject to authorized adjustments) payable to CON- TRACTOR for performing the Work. All duties. responsibil- ities and obligations assigned to or undertaken by CON- TRACTOR shall be at his expense without change in the Contract Price. 11.2. The Contract Price may only be changed by a Change Order or by a Written Amendment. Any claim for an increase or decrease in the Contract Price shall be based on written notice delivered by the party making the claim to the other party and to ENGINEER promptly (but in no event later than thirty days) after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the amount of the claim with supporting data shall be delivered within sixty days after such occurrence !Unless ENGINEER allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by claimant" s written statement that the amount claimed covers all known amounts (direct. indirect and con- sequential) to which the claimant is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Price shall be determined by ENGINEER in accor- dance with paragraph 9.11 if OWNER and CONTRACTOR cannot otherwise agree on the amount involved. No claim for an adjustment in the Cuntract Price will be valid if not submitted in accordance with this paragraph 11.2. 11.3. The value of any Work covered by a Change Order or of any claim for an increase or decrease in the Contract Price shall be determined in one of the following ways: 11.3.1. Where the Work involved is covered by unit prices contained in the Cuntract Documents. by applica- tion of unit prices 10 the quantities of the items involved (subject to the provisions of paragraphs 11.9. I. through 11.9.3. inclusive!. 2J I I I I I 1 I 1 I I 1 I I I 1 I I I I. 11..3.2. By mutual acceptance of a lump sum (which may include an allowance for overhead and profit not necessarily in accordance with paragraph 11.6.2.1). 11..3..3. On the basis of the Cost of the Work (deter- mined as provided in paragraphs 1104 and 11.5) plus a CONTRACTOR's Fee for overhead and profit (deter- mined as provided in paragraphs 11.6 and] 1.7). Cost of the Work: 11.4. The term Cost of the Work means the sum of all costs necessarily incurred and paid by CONTRACTOR in the proper perfonnance of the Work. Except as otherwise may be agreed to in wriung by OWNER. such costs shall be in amounts no higher than those prevailing in the locality of the Project. shall include only the following items and shall not include any of the costs itemized in paragraph 11,5: ] ] 04.1. Payroll costs for employees in the direct employ of CONTRACTOR in the perfonnance of the Work under schedules of job classifications agreed upon by OWNER and CONTRACTOR. Payroll costs for employees not employed full time on the Work shall be apponioned on the basis of their time spent on the Work. Payroll costs shall include. but not be limited to, salaries and wages plus the cost of fringe benefits which shall include social security contributions. unemployment. excise and payroll taxes. workers' or workmen's compensation. health and retirement benefits, bonuses. sick leave. vacation and hol- iday pay applicable thereto. Such employees shall include superintendents and foremen at the site. The expenses of perfonning Work after regular working hours. on Satur- day, Sunday or legal holidays. shall be included in the above to the extent authorized by OWNER. 11.4,2. Cost of all materials and equipment furnished and incorporated in the Work. including costs of trans- portation and storage thereof. and Suppliers' field services required in connection therewith. All cash discounts shall accrue to CONTRACTOR unless OWNER deposits funds with CONTRACTOR with which to make payments. in which case the cash discounts shall accrue to OWNER. All trade discounts. rebates and refunds and all returns from sale of surplus materials and equipment shall accrue to OWNER. and CONTRACTOR shall make provisions so that they may be obtained. 11.4.3. Payments made by CONTRACTOR to the Subcontractors for Work perfonned by Subcontractors. If required by OWNER. CONTRACTOR shall obtain competitive bids from Subcontractors acceptable to CON- TRACTOR and shall deliver such bids to OWNER who will then detennine. with the advice of ENGINEER. which bids will be accepted. If a subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work Plus a Fee. the Subcontractor's Cost of the Work shall be determined in the same manner as CONTRAC- TOR's Cost of the Work. All subcontracts shall be subject to the other provisions of the Contract Documents insofar as applicable. 11.404. Costs of special consultants (including but not limited to engineers. architects. testing laboratories. sur- veyors. attorneys and accountants) employed for services specifically related to the Work. 11.4.5. Supplemental costs including the following: 11.4.5.1. The proponion of necessary transpona- tion. travel and subsistence expenses of CONTRAC- TOR's employees incurred in discharge of duties con- nected with the Work. 11.4.5.2. Cost. including transportation and main- tenance. of all materials. supplies. equipment. machin- ery. appliances. office and temporary facilities at the site and hand tools not owned by the workers. which are consumed in the perfonnance of the Work. and cost less market value of such items used but not consumed which remain the propeny of CONTRACTOR. 11.4.5.3. Rentals of all construction equipment and machinery and the pans thereof whether rented from CONTRACTOR or others in accordance with rental agreements approved by OWNER with the advice of ENGINEER. and the costs of transportation. loading. unloading. installation, dismantling and removal thereof-all in accordance with terms of said rental agreements. The rental of any such equipment. machin- ery or pans shall cease when the use thereofis no longer necessary for the Work. 11.4.5.4. Sales. consumer. use or similar taxes related to the Work. and for which CONTRACTOR is liable, imposed by Laws and Regulations. 11.4.5.5. Deposits lost for causes other than negli- gence of CONTRACTOR. any Subcontractor or any- one directly or indirectly employed by any of them or for whose acts any of them may be liable. and royalty payments and fees for pennits and licenses. 11.4.5.6. Losses and damages (and related expenses>. not compensated by insurance or otherwise. to the Work or otherwise sustained by CONTRACTOR in connection with the perfonnance and furnishing of the Work (except losses and damages within the deductible amounts of propeny insurance established by OWNER in accordance with paragraph 5.9), pro- vided they have resulted from causes other than the negligence of CONTRACTOR. any Subcontractor. or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses shall include settlements made with the written consent and approval of OWNER. No such losses. damages and expenses shall be included in the Cost of the Work for the purpose of detennining CONTRAC- TOR's Fee. If. however. any such loss or damage 22 I I allowances, No demand for additional payment on account of any thereof will be valid. I Prior to final payment. an appropriate Change Order will be issued as recommended by ENGINEER to reflect actual amounts due CONTRACTOR on account of Work covered by allowances. and the Contract Price shall be correspond- ingly adjusted. I I VniJ Price Work: 11.9.1. Where the Contract Documents provide that all or pan of the Work is to be Unit Price Work. initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the established unit prices for each separately identified item of Unit Price Work times the estimated quantity of each item as indi- cated in the Agreement. The estimated quantities of items of Umt Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quan- tities and classifications of Unit Price Work performed by CONTRACTOR will be made by ENGINEER in accor- dance with Paragraph 9.]0. I I I I 11.9.2. Each unit price will be deemed to include an amount considered by CO~lRACTOR to be adequate to cover CONTRACTOR's overhead and profit for each sep- arately identified item. I 11.9.3. Where the quantity of any item of Unit Price Work performed by CONTRACTOR differs materially and significantly from the estimated quantity of such item indicated in the Agreement and there is no corresponding adjustment with respect to any other item of Work and if CONTRACTOR believes that CONTRACTOR has incurred additional expense as a result thereof. CON- TRACTOR may make a claim for an increase in the Con- tract Price in accordance with Article 1 I if the parties are unable to agree as to the amount of any such increase. I I I I ARTICLE 12-CHANGE OF CONTRACT TIME I 12.1. The Contract Time may only be changed by a Change Order or a Written Amendment. Any claim for an extension or shortening of the Contract Time shall be based on written notice delivered by the pany making the claim to the other pany and to ENGINEER promptly (but in no event later than thirty days) after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be deliv- ered within sixty days after such occurrence (unless ENGI- NEER allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accom- panied by the claimant's written statement that the adjust- ment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Time I I I I shall be determined by ENGINEER in accordance with para- graph 9.11 if OWNER and CONTRACTOR cannot otherwise agree. No claim for an adjustment in the Contract Time will be valid if not submined in accordance with the requirements of this paragraph 12.1. 12.2. The Contract Time will be extended in an amount equal to time lost due to delays beyond the control of CON- TRACTOR if a claim is made therefor as provided in para- graph 12.1. Such delays shall include. but not be limited to. acts or neglect by OWNER or others performing additional work as contemplated by Article 7, or to fires. floods, labor disputes. epidemics, abnormal weather conditions or acts of God. 12.3. All time limits stated in the Contract'Documents are of the essence of the Agreement. The provisions of this Article 12 shall not exclude recovery for damages (including but not limited to fees and charges of engineers. architects. attorneys and other professionals and coun and arbitration costs) for delay by either pany. ARTICLE 13-W ARRANTY AND GUARANTEE: TESTS AND INSPECTIONS: CORRECTION. REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK Wamuuy and GlUUTJllUe: 13.1. CONTRACTOR warrants and guarantees to OWNER and ENGINEER that all Work will be in accor- dance with the Contract Documents and will not be defective. Prompt notice of all defects shall be given to CONTRAC- TOR. All defective Work. whether or not in place. may be rejected. corrected or accepted as provided in this Article 13. Access 10 Work: 13.2. ENGINEER and ENGINEER's representatives. other representatives of OWNER. testing agencies and gov- ernmental agencies with jurisdictional interests will have access to the Work at reasonable times for their observation. inspecting and testing. CONTRACTOR shall provide proper and safe conditions for such access. Tests and Inspections: 13.3. CONTRACTOR shall give ENGINEER timely notice of readiness of the Work for all required inspections. tests or approvals. 13.4. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereoO to specifically be inspected. tested or approved, CONTRACTOR shall assume full responsibility therefor. pay all costs in connection therewith and furnish ENGINEER the required certificates of inspection. testing or approval. CONTRACTOR shall also 24 I I be responsible for and shall pay all costs in connection with any inspection or testing required in connection with OWN- ER's or ENGIN EER's acceptance of a Supplier of materials or equipment proposed to be incorporated in the Work. or of materials or equipment submitted for approval prior to CON- TRACTOR's purchase thereof for incorporation in the Work. The COSt of all inspections. tests and approvals in addition to the above which are required by the Contract Documents shall be paid by OWNER (unless otherwise specified!. I I I 13.5. All inspections. tests or approvals other than those required by Laws or Regulations of any public body having jurisdiction shall be performed by organizations acceptable to OWNER and CONTRACTOR (or by ENGI;-';EER if so specified!. I I 13.6. If any Work (including the work of others) that is to be inspected. tested or approved is covered without written concurrence of ENGINEER. it musl. if requested by ENGI- NEER. be uncovered for observation. Such unco\'ering shall be at CONTRACTOR's expense unless CONTRACTOR has given ENGINEER timely notice ofCONTRACTOR's inten- tion to cover the same and ENGINEER has not acted with reasonable promptness in respons~ 10 such notice. I I 13.7. Neither observations by ENGINEER nor inspec- tions. tests or approvals by others shall relieve CONTRAC- TOR from CONTRACTOR's obligations to petfonn the Work in accordance with the Contract Documents. I I Uncovering Work: 13.8. lfany Work is covered contrary 10 the written request of ENGINEER. it musl. if requested by ENGI;-;EER. be unco\'ered for ENGI;-.JEER's observation and replaced at CONTRACTOR's expense. I I 13.9. If E;-.JGINEER considers it necessary or advisable that covered Work be observed by ENGINEER or inspected or tested by others. CONTRACTOR. al ENGINEER's request. shall uncover. expo~e or otherwise mak~ available for observation, insp~ction or testing as ENGI:\EER may require, that portion of the Work in question. furnishing all necessary labor. material and equipment. If it is found that such Work is "t'.fectil'l', CONTRACTOR shall bear all direct. indirecI and consequential costs of such uncovering. expo- sure. observation. inspection and testing and of ~atisfactor\' reconstruction. I including but nOllimited 10 fees and charges of engineers. :1rchitecls, allorneys and other pro(essionalsJ. and OWN ER shall be entitled to an appropriate decrease in the Contract Price. and. if the parties are unable to agree as to the amount thereof. may make a claim therefor as provided in Article II, If. hlll\ e\er. "lIcn \Vlll'k is not (,'und to be deIL'nil'(', CCY\"TR.-\CTOR ,hall be allowed an Increase in the Cl1ntract Pi"I\.L .1" ..il c\iension of the Contract Time. "I' both. Jirectl\ allril1l1tabk (v such uncovering. .::xposure. obsen'alion. inspection. testing and reconstructi,'n: and. if the parties are lInahk 10 agree as to the amount ,11' extent I I I I I I thereof. CONTRACTOR may make a claim therefor as pro- vided in Articles II and 12. Owner May Stop the Work: 13.10. If the Work is defeeth'e. or CONTRACTOR fails to supply sufficient skilled workers or suitable materials or equipment. or fails to furnish or perform the Work in such a way that the completed Work will conform to the Contract Documents. OWNER may order CONTRACTOR to s;op the Work. or any portion thereof. until the cause for such order has been eliminated; however. this right of OWN ER 10 stop the Work shall not give rise 10 any duty on the pan of OWNER to exercise this right for the benefit of CONTRACTOR or any other party. Correction or Removal of Defective Work: 13.11. Ifrequired by ENGINEER. CONTRACTOR shall promptly. as directed. either correct all defectil'e Work. whether or not fabricated. installed or completed. or. if ihe Work has been rejected by ENGINEER. remove it from the site and replace it with nondefecth'e Work. CONTRACTOR shall bear all direct. indirecr and consequential costs of such correction or removal (including but not limited to fees and charges of engineers. architects. attorneys and other profes- sionals) made necessary thereby. One Year Correction Period: 13.12. If within one year after the date of Substantial Completion or such longer period of time as may be pre- scribed by Laws or Regulations or by the terms of any appli- cable special guarantee required by the Contract Documents or by any specific provision of the Contract Documents. any Work is found to be defertil'e. CONTRACTOR shall promptly. without cost to OWNER and in accordance with OWNER's written instructions. either correct such defeerh'e Work. or. if it has been rejected by OWNER. remove it from the site and replace it with IIondefecti1'e Work. If CONTRACTOR does not promptly comply with the terms of such instructions. or in an emergency where delay would cause serious risk of loss or damage. OWNER may have the defeerh'e Work cor- rected or the rejected Work removed and replaced. and all direct. indirect and consequential costs of such removal and replacement (including but not limited to fees and charges of engineers. architects. atlOrneys and other professionals) will be paid by CONTRACTOR. In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work. the correction period for that item may start to run from an earlier dale if so provided in the Specifications or by Written Amendment. Acceptance of Defective Work: \3,13. If. inslead of requiring correction or removal and replacemenl of d((('eti,'" Work. OWNER (and. prior 10 ENGIN EER's recommendalion of final payment. also ENGINEER) prefers 10 accept it. OWNER may do so. CON- TRACTOR shall hear all direct. indirect and consequential 25 I I costs attributable to OWNER's evaluation of and determi- nation to accept such defective Work (such costs to be approved by ENGINEER as to reasonableness and to include but not be limited to fees and charges of engineers. architects. attor- neys and other professionals). If any such acceptance occurs prior to ENGINEER's recommendation of final payment. a Change Order will be issued incorporating the necessary revi- sions in the Contract Documents with respect to the Work; and OWNER shall be entitled to an appropriate decrease in the Contract Price. and. if the panies are unable to agree as to the amount thereof. OWNER may make a claim therefor as provided in Anicle 11. If the acceptance occurs after such recommendation, an appropriate amount will be paid by CONTRACTOR to OWNER. I I I I I OWNER May Cornet Defective Work: 13.14. If CONTRACTOR fails within a reasonable time after written notice of ENGINEER to proceed to correct and to correct defective Work or to remove and replace rejected Work as required by ENGINEER in accordance with para- graph 13.11. or if CONTRACTOR fails to perform the Work in accordance with the Contract Documents. or if CON- TRACTOR fails to comply with any other provision of the Contract Documents, OWNER may, after seven days' writ- ten notice to CONTRACTOR. correct and remedy any such deficiency. In exercising the rights and remedies under this paragraph OWNER shall proceed expeditiously. To the extent necessary to complete corrective and remedial action. OWNER may exclude CONTRACTOR from all or pan of the site, take possession of all or pan of the Work. and suspend CON- TRACTOR's services related thereto. take possession of CONTRACTOR's tools. appliances, construction equipment and machinery at the site and incorporate in the Work all materials and equipment stored at the site or for which OWNER has paid CONTRACTOR but which are stored elsewhere. CONTRACTOR shall allow OWNER. OWNER's represen- tatives. agents and employees such access to the site as may be necessary to enable OWNER to exercise ,the rights and remedies under this paragraph. All direct. indirect and con- sequential costs of OWNER in exercising such rights and remedies will be charged ~nst CONTRACTOR in an amount approved as to reasonableness by ENGINEER. and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work: and OWNER shall be entitled to an appropriate decrease in the Contract Price. and. if the panies are unable to agree as to the amount thereof. OWNER may make a claim therefor as provided in Article II. Such direct. indirect and consequen- tial costs will include but not be limited to fees and charges of engineers. architects. attorneys and other professionals, all court and arbitration costs and all costs of repair and replacement of work of others destroyed or damaged by correction. removal or replacement of CONTRACTOR's defective Work. CONTRACTOR shall not be allowed an extension of the Contract Time because of any delay in per- formance of the Work attributable to the exercise by OWNER of OWNER's rights and remedies hereunder. I I I I I I I I I I I I ARTICLE I4-PA YMENTS TO CONTRACTOR AND COMPLETION Scludllk ofVames: 14.1. The schedule of values established as provided in paragraph 2.9 will serve as the basis for progress payments and will be incorporated into a form of Application for Pay- ment acceptable to ENGINEER. Progress payments on account of Unit Price Work will be based on the number of units completed. Application for Progress Payment: 14.2. At least twenty days before each progress payment is scheduled (but not more often than once a month). CON- TRACTOR shall submit to ENGINEER for review an Appli. cation for Payment filled out and signed by CONTRACTOR covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the site or at another location agreed to in writing. the Application for Payment shall also be accompanied by a bill of sale. invoice or other documentation warranting that O~ER has received' the materials and equipment free and clear of all liens. charges. security interests and encumbrances (which are hereinafter in these General Conditions referred to as "Liens") and evidence that the materials and equipment are covered by appropriate property insurance and other arrangements to protect OWNER's interest therein. all of which will be sat- isfactory to OWNER. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. CONTRACTOR's Wamurry of Tille: 14.3. CONTRACTOR warrants and guarantees that title to all Work. materials and equipment covered by any Appli- cation for Payment. whether incorporated in the Project or not. will pass to OWNER no later than the time of payment free and clear of all Liens. Rev~w of Applications for Progress Payment: 14.4. ENGINEER will, within ten days after receipt of each Application for Payment. either indicate in writing a recommendation of payment and present the Application to OWNER. or return the Application to CONTRACTOR indi- cating in writing ENGINEER's reasons for refusing to rec- ommend payment. In the latter case. CONTRACTOR may make the necessary corrections and resubmit the Applica- tion. Ten days after presentation of the Application for Pay- ment with ENGINEER's recommendation. the amount rec- ommended will (subject to the provisions of the last sentence of paragraph 14,7) become due and when due will be paid by OWNER to CONTRACTOR. 14.5. ENGINEER's recommendation of any payment requested in an Application for Payment will constitute a 26 I I representation by ENGINEER to OWNER. based on ENGI- NEER's on-site observations of the Work in progress as an experienced and qualified design professional and on ENGI- NEER's review of the Application for Payment and the accompanying data and schedules that the Work has pro- gressed to the point indicated: that. to the best of ENGI- NEER's knowledge. information and belief. the quality of the Work is in accordance with the Contract Documents Isubjectto an evaluation of the Work as a functioning whole prior to or upon Substantial Completion. to the results of any subsequent tests called for in the Contract Documents. to a final determination of quantities and classifications for Unit Price Work under paragraph 9.10. and to any other qualifi- cations stated in the recommendation I: and that CONTRAC- TOR is entitled to payment of the amount recommended. However. by recommending any such payment ENGINEER will not thereby be deemed to have represented that exhaus- tive or continuous on-site inspections have been made to check the quality or the quantity of the Work beyond the responsibilities specitically assigned to ENGINEER in the Contract Documents or that there may not be other matters or issues between the parties that might entitle CONTRAC- TOR to be paid additionally by OWNER or OWNER to withhold payment to CONTRACTOR. I I I I I I I 14.6. ENGINE~R's recommendation of final payment will constitute an additional representation by ENGINEER to OWNER that the conditions precedent to CONTRAC- TOR's bemg entitled to final payment as set forth in paragraph 14.13 have been fulfilled. I 14.7. ENGINEER may refuse to recommend the whole or any part of any payment if. in ENGINEER's opinion. it would be incorrect to make such representations to OWNER. ENGINEER may also refuse to recommend any such pay- ment. or. because of subsequently discovered evidence or the results of subsequent inspections or tests. nullify any such payment previously recommended. to such extent as may be necessary in ENGINEER's opinion to protect OWNER from loss because: I I I 14.7.1. the Work is defee/il'e. or completed Work has been damage~ requiring correction or replacement. I 14.7.::!. the Contract Price has been reduced by Writ- ten Amendment or Change Order. I 14.7.3. OWNER has been required to correct defec- {h'e Work or complete Work in accordance with paragraph 13.14. or I 14.7.4. of ENGINEER's actual knowledge of the occurrence of any of the events enumerated in paragraphs 15.::!.1 through 15.2.9 inclusive. I OWNER may refuse to make payment of the full amount recommended by ENGINEER because claims have been made against OWNER on account ofCONTRACTOR's per- formance or furnishing of the Work or Liens have been filed in connection with the Work or there are other items entitling I I OWNER to a set-off against the amount recommended. but OWNER must give CONTRACTOR immediate written notice (with a copy to ENGIN EER) stating the reasons for such action. Substantial Completion: 14.8. When CONTRACTOR considers the entire Work ready for its intended use CONTRACTOR shall notify OWNER and ENGINEER in writing that the entire Work is substantially complete (except for items specifically listed by CONTRACTOR as incomplete) and request that ENGI- NEER issue a certificate of Substantial Completion. Within a reasonable time thereafter. OWNER. CONTRACTOR and ENGINEER shall make an inspection of the Work to deter- mine the status of completion. If ENGINEER does not con- sider the Work substantially complete. ENGINEER will notify CONTRACTOR in writing giving the reasons therefor. If ENGINEER considers the Work substantially complete. ENGINEER will prepare and deliver to OWNER a tentative certificate of Substantial Completion which shall fix the date of Substantial Completion. There shall be attached to the certificate a tentative list of items to be completed or cor- rected before final payment. OWNER shall have seven days after receipt of the tentative certificate during which to make written objection to ENGINEER as to any provisions of the certificate or attached list. If. after considering such objec- tions. ENGINEER concludes that the Work is not substan- tially complete. ENGINEER will within fourteen days after submission of the tentative certificate to OWNER notify CONTRACTOR in writing. stating the reasons therefor. If. after consideration of OWNER's objections. ENGINEER considers the Work substantially complete. ENGINEER will within said fourteen days execute and deliver to OWNER and CONTRACTOR a definitive certificate of Substantial Completion (with a revised tentative list of items to be com- pleted or corrected) reflecting such changes from the tentative certificate as ENGINEER believes justified after consider- ation of any objections from OWNER. Atthe time of delivery of the tentative certificate of Substantial Completion ENGI- NEER will deliver to OWNER and CONTRACTOR a wrinen recommendation as to division of responsibilities pending final payment between OWNER and CONTRACTOR with respect to security. operation. safety. maintenance. heat. utilities. insurance and warranties. Unless OWNER and CONTRACTOR agree otherwise in writing and so inform ENGINEER prior 10 ENGINEER's issuing the definitive certificate of Substantial Completion. ENGINEER's afore- said recommendation will be binding on OWNER and CON- TRACTOR until final payment. 14.9. OWNER shall have the right to exclude CON- TRACTOR from the Work after the date of Substantial Com- pletion. but OWN ER shall allow CONTRACTOR reasonable access to complete or correct items on the tentative list. Partwl Utili:.ation: 14.10. Use by OWNER of any finished pan of the Work. which has specifically b~~n identified in the Cuntract Do.:u- 27 I I ments. or which OWNER. ENGINEER and CONTRAC- TOR agree constitutes a separately functioning and useable part of the Work that can be used by OWNER without sig- nificant interference with CONTRAcrOR's perfonnance of the remainder of the Work. may be accomplished prior to Substantial Completion of all the Work subject to the follow- Ing: I I 14.10.1. OWNER at any time may request CON- TRACTOR in writing to pennit OWNER to use any such part of the Work which OWNER believes to be ready for its intended use and substantially complete. If CON- TRACTOR agrees. CONTRAcrOR will certify to OWNER and ENGINEER that said part of the Work is substantially complete and request ENGINEER to issue a certificate of Substantial Completion for that part of the Work. CON- TRACTOR at any time may notify OWNER and ENGI. NEER in writing that CONTRAcrOR considers any such part of the Work ready for its intended use and substan- tially complete and request ENGINEER to issue a cenif- icate, of Substantial Completion for that part of the Work. Within a reasonable time after either such request. OWNER. CONTRACTOR and ENGINEER shall make an inspec- tion of that part of the Work to detennine its s.atus of completion. If ENGINEER does not consider that part of the Work to be substantially complete. ENGINEER will notify OWNER and CONTRAcrOR in writing giving the reasons therefor. lfENGINEER considers that part of the Work to be substantially complete. the provisions of para- graphs 14.8 and 14.9 will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. I I I I I I I 14.10.1. OWNER may at any time request CON- TRACTOR in writing to permit OWNER to take over operation of any such part of the Work although it is not substantially complete. A copy of such request will be sent to ENGINEER and within a reasonable time there- after OWNER. CONTRAcrOR and ENGINEER shall make an inspection of that part of the Work to determine its status of completion and will prepare a list of the items remaining to be completed or corrected thereon before final payment. If CONTRAcrOR does not object in writ- ing to OWNER and ENGINEER that such part of the Work is not ready for separate operation by OWNER. ENGINEER will finalize the list of items to be completed or corrected and will deliver such list to OWNER and CONTRACTOR together with a written recommendation as to the division of responsibilities pending final payment between OWNER and CONTRAcrOR with respect to security. operation. safety. maintenance. utilities. insur- ance. warranties and guarantees for that part of the Work which will become binding upon OWNER and CON- TRACTOR at the time when OWNER takes over such operation (unless they shall have otherwise agreed in writ- ing and so infonned ENGINEER). During such operation and prior to Substantial Completion of such pan of the Work. OWNER shall allow CONTRAcrOR reasonable access to complete or correct items on said list and to complete other related Work. I I I I I I I I 14.10.3. No occupancy or separate operation of part of the Work will be accomplished prior to compliance with the requirements of paragraph 5.15 in respect of property insurance. Final Inspection: 14.11. Upon written notice from CONTRACTOR that the entire Work or an agreed portion thereof is complete. ENGI- NEER will make a final inspection with OWNER and CON- TRACTOR and will notify CONTRAcrOR in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. CONTRACTOR shall immediately take such measures as are necessary to remedy such defi. ciencies. Final App/iaJJion for Paymelll: 14.12. After CONTRAcrOR has completed all such cor- rections to the satisfaction of ENGINEER and delivered all maintenance and operating instructions. schedules. guaran- tees. Bonds. certificates of inspection. marked-up record documents (as provided in paragraph 6.191 and other docu- ments-all as required by the Contract Documents. and after ENGINEER has indicated that the Work is acceptable (sub- ject to the provisions of paragraph 14.16). CONTRAcrOR may make application for final payment following the pro- cedure for progress payments. The final Application for Pay- ment shall be accompanied by all documentation called for in the Contract Documents. together with complete and legally effective releases or waivers (satisfactory to OWNER) of all Liens arising out of or filed in connection with the Work. In lieu thereof and as approved by OWNER. CONTRAcrOR may furnish receipts or releases in full: an affidavit of CON- TRAcrOR that the releases and receipts include all labor. services. material and equipment for which a Lien could be filed. and that all payrolls. material and equipment bills. and other indebtedness connected with the Work for which OWNERorOWNER's property might in any way be respon- sible. have been paid or otherwise satisfied: and consent of the surety. if any, to final payment. If any Subcontractor or Supplier fails to furnish a release or receipt in full. CON- TRAcrOR may furnish a Bond or other collateral satisfac- tory to OWNER to indemnify OWNER against any Lien. FiTUJi Payment and Accepumce: 14.13. If. on the basis of ENGINEER's observation of the Work during construction and final inspection. and ENGINEER's review of the final Application for Payment and accompanying documentation-all as required by the Contract Documents. ENGINEER is satisfied that the Work has been completed and CONTRACTOR's other obligations under the Contract Documents have been fulfilled. ENGI- NEER will. within ten days after receipt of the final Appli- cation for Payment. indicate in writing ENGlNEER's rec- ommendation of payment and present the Application to OWNER for payment. Thereupon ENGINEER will give written notice to OWNER and CONTRAcrOR that the Work is acceptable subject to the provisions of paragraph 14.16. 28 I I Otherwise. ENGINEER will return the Application to CON- TRACTOR. indicating in writing the reasons for refusing to recommend final payment. in which case CONTRACTOR shall make the necessary corrections and resubmit the Appli- cation. Thirty days after presentation to OWNER of the Application and accompanying documentation. in appropri- ate form and substance. and with ENGINEER's recommen- dation and notice of acceptability. the amount recommended by ENGINEER will become due and will be paid by OWNER to CONTRACTOR. I I I 14.14. If. through no fault of CONTRACTOR. final com- pletion of the Work is significantly delayed and if ENGI- NEER so confinns. OWNER shall. upon receipt of CON- TRACTOR's final Application for Payment and recommen- dation of ENGINEER. and without tenninating the Agree- ment. make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by OWNER for Work not fully completed or corrected is less than the retainage stipulated in the Agree- ment. and if Bonds have been furnished as required in para- graph 5.1. the written consent of the surety to the payment of the balance due for that portion of the Work fully com- pleted and accepted shall be submitted by CONTRACTOR to ENGINEER with the Application for such payment. Such payment shall be made under the terms and conditions gov- erning final payment, except that it shall not constitute a waiver of claims, I I I I I Contractor's Continuing Obligation: 14.15. CONTRACTOR's obligation to perfonn and com- plete the Work in accordance with the Contract Documents shall be absolute. Neither recommendation of any progress or final payment by ENGINEER, nor the issuance of a cer- tificate of Substantial Completion. nor any payment by OWNER to CONTRACTOR under the Contract Documents. nor any use or occupancyof the Work or any part thereof by OWNER. nor any act of acceptance by OWNER nor any failure to do so. nor any review and approval of a Shop Drawing or sample submission. nor the iss!lance of a notice of acceptability by ENGINEER pursuant to paragraph 14.13. nor any correction of defectil'e Work by OWNER will con- stitute an acceptance of Work not in accordance with the Contract Documents or a release of CONTRACTOR's obli- gation to perform the Work in accordance with the Contract Documents lexcept as provided in paragraph 14.16l. I I I I I Wail'er of Claims: 1~.16, The making and acceptance of final payment will conslitute: I 1~.16.1. a waiver of all claims by OWNER against CO~TRACTOR. except claims arising from unsellleJ Liens. from de./('ctil'l' Work appearing after tinal inspec, til," pursuant to paragraph 14, II or from failure tl) comply with the Contract Documents or the terms of any special guarantees specitleJ therein: however. it will nlH consti- llIle a waiver hy OWNER of any rights in rcsp.:ct llf I I I CONTRACTOR's continuing obligations under the Con- tract Documents: and 14.16.2. a waiver of all claims by CONTRACTOR against OWNER other than those previously made in writ- ing and still unsettled. ARTICLE IS-SUSPENSION OF WORK AND TERMINA TION Owner May Suspend Work: 15.1. OWNER may. at any time and without cause. sus- pend the Work or any portion thereof for a period of not more than ninety days by notice in writing to CONTRACTOR and ENGINEER which will fix the date on which Work will be resumed. CONTRACTOR shall resume the Work on the date so fixed. CONTRACTOR shall be allowed an increase in the Contract Price or an extension of the Contract Time. or both. directly attributable to any suspension if CONTRACTOR makes an approved claim therefor as provided in Articles 11 and 12. Owner May TermilUlte: 15.2. Upon the occurrence of anyone or more of the following events: 15.2.1. if CONTRACTOR commences a voluntary case under any chapter of the Bankruptcy Code (Title II. United States Code). as now or hereafter in effect. or if CON- TRACTOR takes any equivalent or similar action by filing a petition or otherwise under any other federal or state law in effect at such time relating to the bankruptcy or insolvency: 15.2.2. if a petition is filed against CONTRACTOR under any chapter of the Bankruptcy Code as now or hereafter in effect at the time of filing. or if a petition is filed seeking any such equivalent or similar relief against CONTRACTOR under any other federal or state law in effect at the time relating to bankruptcy or insolvency,: 15.2.3. if CONTRACTOR makes a general assignment for the benefit of creditors: 15.2.4. if a trustee. receiver. custodian or agent of CONTRACTOR is appointed under applicable law or under contract. whose appointment or authority to take charge of property of CONTRACTOR is for the purpose of enforcing a Lien against such property or for the purpose of general administration of such property for the benefit of CONTRACTOR's creJitors: 15.2.5. if CONTRACTOR admits in writing an inabil- ity to pay its Jebts generally as they become due: 15.2.6. if CONTRACTOR persistently fails to perform the Work in accordance \\'ilh the Conlract Documents 29 I I (including. but not limited to. failure to supply sufficient skilled workers or suitable materials or equipment or failure to adhere to the progress schedule established under paragraph 2.9 as revised from time to time): I 15.2.7. if CONTRACTOR disregards Laws or Regu. lations of any public body having jurisdiction: I 15.2.8. if CONTRACTOR disregards the authority of ENGINEER: or I 15.2.9. if CONTRACTOR otherwise violates in any substantial way any provisions of the Contract Docu. ments; I OWNER may. after giving CONTRACTOR (and the surety, if there be one) seven days' written notice and to the extent permitted by Laws and Regulations. terminate the services of CONTRACTOR. exclude CONTRACTOR from the site and take possession of the Work and of all CONTRACTOR's tools. appliances. construction equipment and machinery at the site and use the same to the full extent they could be used by CONTRACTOR (without liability to CONTRACTOR for trespass or conversion). incorporate in the Work all materials and equipment stored at the site or for which OWNER has paid CONTRACTOR but which are stored elsewhere. and finish the Work as OWNER may deem expedient. In such case CONTRAcrOR shall not be entitled to receive any further payment until the Work is finished. If the unpaid balance of the Contract Price exceeds the direct. indirect and consequential costs of completing the Work (including but not limited to fees and charges of engineers. architects. attor. neys and other professionals and court and arbitration costs) such excess will be paid to CONTRACTOR. If such costs exceed such unpaid balance. CONTRACTOR shall pay the difference to OWNER. Such costs incurred by OWNER will be approved as to reasonableness by ENGINEER and incor- porated in a Change Order. but when exercising any rights or remedies under this paragraph OWNER shall not be required to obtain the lowest price for the Work performed. I I I I I I I I I 15.3. Where CONTRACTOR's services have been so terminated by OWNER. the termination will not affect any rights or remedies of OWNER against CONTRACTOR then existing or which may thereafter accrue. Any retention or payment of moneys due CONTRACTOR by OWNER will not release CONTRACTOR from liability. 15.4. Upon seven days' written notice to CONTRAC. TOR and ENGINEER. OWNER may. without cause and without prejudice to any other right or remedy. elect to aban. don the Work and terminate the Agreement. In such case. CONTRAcrOR shall be paid for all Work executed and any expense sustained plus reasonable termination expenses. which will include. but not be limited to. direct. indirect and con. sequential costs (including. but not limited to. fees and charges of engineers. architects. attorneys and other professionals and court and arbitration costs). COrrlraClOr May SlOp Work or Termituue: 15.5. If. through no act or fault of CONTRACTOR. the Work is ~uspended for a period of more than ninety days by OWNER or under an order of court or other public authority. or ENGINEER fails to act on any Application for Payment within thirty days after it is submitted. or OWNER fails for thirty days to pay CONTRACTOR any sum finally deter. mined to be due. then CONTRACTOR may. upon seven days' written notice to OWNER and ENGINEER. terminate the Agreement and recover from OWNER payment for all Work executed and any expense sustained plus reasonable termination expenses. In addition and in lieu of terminating the Agreement. if ENGINEER has failed to act on an Appli. cation for Payment or OWNER has failed to make any pay- ment as aforesaid. CONTRACTOR may upon seven days' written notice to OWNER and ENGINEER stop the Work until payment of all amounts then due. The provisions of this paragraph shall not relieve CONTRACTOR of the obligations under paragraph 6.29 to carry on the Work in accordance with the progress schedule and without delay during disputes and disagreements with OWNER. I . [The remainder of this page was left blank intentionally.J I I I 30 I I I ARTICLE 16--ARBITRATION 16.1 All claims, disputes and other matters in question between OWNER and CONTRACTOR arising out of, or relating to, the Contract Docu- ments or the breach thereof shall be decided under Georgia Law in the Superior Court of Richmond County, Georgia. I I (The remainder of this page was left blank intentionally.) I I I I I I I I I I I I I I 31 I I I I I I I I I I I I I I I I I I I (This page was left blank intentionally.) 32 I I ARTICLE l7-MISCELLANEOUS I Giving Notice: 17.1. Whenever any provision of the Contract Docu- ments requires the giving of written notice, it will be deemed to have been validly given if delivered in person to the indi- vidual or to a member of the firm or to an officer of the corporation for whom it is intended. or if delivered at or sent by registered or cenified mail. postage prepaid. to the last business address known to the giver of the notice. I I Computalion of Time: 17.2.1. When any period of time is referred to in the Contract Documents by days. it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction. such day will be omitted from the computa- tion. I I 17.2.2. A calendar day of twenty-four hours measured from midnight to the next midnight shall constitute a day. I General: I 17.3. Should OWNER or CONTRACTOR suffer injury or damage to person or propeny because of any error, omis- I I I I I I I I I I sion or act of the other pany or of any of the other pany's employees or agents or others for whose acts the other pany is legally liable. claim will be made in writing to the other pany within a reasonable time of the first observance of such injury or damage. The provisions of this paragraph 17.3 shall not be construed as a substitute for or a waiver of the pro- visions of any applicable statute of limitations or repose. 17.4. The duties and obligations imposed by these Gen- eral Conditions and the rights and remedies available here- under to the panies hereto. and. in panicular but without limitation. the warranties. guarantees and obligations imposed upon CONTRACTOR by paragraphs 6.30. 13.1. 13.12. 13.14. 14.3 and 15.2 and all of the rights and remedies available to OWNER and ENGINEER thereunder. are in addition to. and are not to be construed in any way as a limitation of. any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations. by special warranty or guarantee or by other provisions of the Contract Documents. and the provisions of this paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each panicular duty. obliga- tion. right and remedy to which they apply. All representa- tions. warranties and guarantees made in the Contract Doc- uments will survive final payment and termination or com- pletion of the Agreement. 33 I I I I I I I I I I I I I I I I I I I SUPPLEMENTARY CONDITIONS 1.1 OWNER'S LIABILITY & PROPERTY INSURANCE: section 5.5, 5.6, 5.7, 5.8, 5.9, 5.10 of the General Conditions shall be amended as follows: No additional liability or property insurance will be purchased by Augusta-Richmond County for this project. Current insurance coverages will remain in effect for the life of this Contract. 1.2 CONTRACTOR'S LIABILITY: As indicated under Section 5.3 of the General Conditions, the Contractor's Liability Insurance shall be in an amount not less than $200,000 for injuries, including accidental death, to anyone person, and subject to the same limit for each person, in an amount not less than $500,000 on account of one accident, and Contractor's Property Damage Insurance in an amount not less than $100,000 for all property damage sustained by anyone person in anyone accident; and a limit of liability of not less than $200,000 for any such damage sustained by two or more persons in anyone accident. The Contractor shall either (1) require each of his subcontractors to procure and to maintain during the life of his subcontract, Subcontractor's Liability and Property Damage Insurance of the type and in the same amounts as specified in the preceding paragraph, or (2) insure the activities of his subcontractors in his own policy. 1.3 SPECIAL HAZARDS: The contractor's and his Subcontractor's Liability and property Damage Insurance shall provide adequate protection against the following special hazards: (a) Work within the right-of-ways of the Augusta-Richmond County Road System. (b) Work within easements granted by property owners in connection with the construction of the project. (c) Work in close proximity to existing water lines, power lines, telephone lines, gas lines, other utilities and private structures contiguous to the job site. SC-1 I I I I I I I I I I I I I I I I I I I 1.4 TESTING LABORATORY: All testing and laboratory work in connection therewith shall be performed by an independent firm and paid for by the Contractor. Copies of all test reports shall be forwarded to Augusta-Richmond County Public Works. There will be no separate payment for this work. 1.5 SURVEYS: The Contractor will provide surveying for construction staking, horizontal control and vertical control as necessary. 1.6 PROGRESS PAYMENT: section 14.2 of the General Conditions shall be amended as follows: The contractor may submit monthly estimate for work completed and materials properly stored as approved by the Engineer. When an estimate includes materials stored, a bill of sale, invoice or other documentation warranting that the Owner is receiving the material free and clear of all liens, charges, security interest and other encumbrances shall be attached to the payment request. 1.7 ENGINEER: All references to "Engineer" shall be interpreted to mean the Augusta-Richmond County Engineer, or his official designee. 1.8 UNDERGROUND UTILITIES: (References 4.3, 1.4, 3.2) The Contractor shall coordinate with all utility companies through the "one call" method or other appropriate steps to locate and avoid damage to all utilities that may affect or be affected by the Contractor's work. (Reference 6.20) 1.9 SAFETY: The Contractor shall use certified flagmen, barricades and signs as necessary to notify the public, in particular those persons driving in the vicinity of the project, of the construction and its affect on traffic. SC-2 I I I I I I I I I I I I I I I I I I I SECTION P PROPOSAL Date: JV'-j zz. , lens Gentlemen: In compliance with your invitation for bids dated jVu~ ~~ , 19~, the undersigned hereby proposes to furnish all labor, eqhipment, and materials, and to perform all work for the installation of streets, and appurtenances referred to herein as: Crane Creek Channel Improvements Project Number: 55-8369-323 in strict accordance with the Contract Documents and in consideration of the amounts shown on the Bid Schedule attached hereto and totaling: S~lJf?f.J fJ",uc/ucl ThleT1 EIGHT 7hokS,4Nd Se'vCf.o I-J."Ndud. . fr {:"T~ b. J)M~S 1---rhi e'rtj h v'5- duotLARs ($ ~:38.. 7$0. 3S' The undersigned hereby agrees that, upon written acceptance of this bid, he will within 10 days of receipt of such notice execute a formal contract agreement with the OWNER, and that he will provide the bond or guarantees required by the Contract Documents. The undersigned hereby agrees that, if awarded the contract, he will commence the work within 10 calendar days after the date of written notice to proceed, and that he will complete the work within 145' calendar days. The undersigned acknowledges receipt of the following adgenda: By: Respectfully Submitted L -J J .tole. (Name of Firm) Zzo S-ro"h:~e.1>6E 'DlZ,v':-l SUITt::: CoL..UMgl~ I Sc. Zqz.,o (Business Address) "7'! ~ ?~ -~~/ 40S Title: P-l I I I I I I I I I I I I I I I I I I I CRANE CREEK CHANNEL IMPROVEMENTS PROJECT NUMBER: 55-8369-323 DETAILED ESTIMATE 5118/98 ..'.........., . ,.,",...,............"...,........,........... ............... ........... !............... "l.. .................. .. ,........... ". ................. ...... ..... ............ ....... .... ........... ..... ...... . ....... ..... ...... ......... ............ ::::::::::::::::::::;:;::>: :::::::;:::::::::::::::::>:o'>>e>:;s;:::C:';';R::':'I:P';::T::::l::O::-::N:::':;:::;:::::::::::::::;:::,::: ::::::;'U::>:N;\~:::;::> :::::;;':+J::> ::U::>:N::':~;:'P'::::R::::'I:C:>>E::::: ;>::::A>:::M:::::O>>:U:::>N:::::';':;:::: i?Tf:~~:~g:~: i:i!i:i!:::i:::::':~iiiiiii':;::::::::::i:i;:::::: :::::::::::::;:::::::~i:iii!iij!i}!!iiii~mj: !:i:ijr~::::::i::~{t? i?jr:~!ii!: :!:i::::: ::~::i:i:::~:::::::::i::::::' :!i!::i::;:::::::::::::::::::;:T: :::i CHANNEL IMPROVEMENTS 171-0010 TEMP SILT FENCE TYPE A LF 171-0030 TEMP SILT FENCE TYPE C CHANNEL EXCAVATION (1,560 CY 204-0001 ESTIMATED) IN PLACE EMBANKMENT (2000 CY 208-0100 ESTIMATED) LF LUMP LUMP *230-1000 LUMP SUM CONSTRUCTION LUMP 318-3000 AGGR SURF CRS TON 550-5018 STORM DRAIN PIPE, 18", RCP, H 1-10 LF 550-5024 STORM DRAIN PIPE, 24", RCP, H 1-10 LF 603-2018 STONE PLAIN RIP RAP. TP 1, 18" SY 603-2997 FILTER BLANKET 6" SY 643-1152 CHAIN LINK FENCE 6',11 GA LF 643-8010 GATE, CHAIN L1NKZC COAT 16', 9 GA EACH 700-5000 GRASSING COMPLETE (1.45 ACRES EST) LUMP SANITARY SEWER **230-1000 LUMP SUM CLASS A CONCRETE (SEWER LINE 500-3101 ENCASEMENT) 660-0018 SAN SEWER PIPE, 18", PVC 660-0030 SAN SEWER PIPE, 30", PVC 660-0808 SAN SEWER PIPE, 8" DUCTILE IRON 660-0830 SAN SEWER PIPE, 30" DUCTILE IRON 668-3300 SAN SEWER MANHOLE, TP 1 SAN SEWER MANHOLE, TP 1, ADDL DEPTH, 668-3311 CL 1 SAN SEWER MANHOLE, TP 1, ADDL DEPTH, 668-3312 CL 2 LUMP CY LF LF LF LF EACH LF LF TOTAL P-2 1000 .:1. 1~ .d 150.60 1500 .5. f./ 0 8J ~(J .0 fJ 1 3S,d..sd.d 0 34, ~S6 .00 1 ..:2 ~ 11 fJ4 ..~ ~~t'Joa.OQ 1 J q:J lI-~ /l. de) Jg 3 C/~d .4~ 500 / 8. ,~ 4 3 J5.0d 32 <13. ". I .3 J~ . go 72 4J.fJIJ J t./~~ .Da 5200 .3~. (.~ ItS.7t/.o.OQ 5200 'i .'a 4", ?Jd .dO 60 1.5 , () a <1 (Jo.d 0 1 '156.60 7:5d 4 " 1 1<1. 0 lit{ . t1 d IS! 0110.00 1 19. 4~.s. 40 13.6 4QS.oo 25 44.(..0 1326 "4-.75 53 35.85 140 '11$.00 8 4.4Z.S.olJ 27 t 87. 50 5 287. So 3~ 738. 7.5(). - 7Q, <){...<,tJ (J '-,73.2.00 1,115.00 es, !S~.So (,'too.oS /3,300.00 35,4-00.00 7/ 7~)... ~ 0 1.4-37. $0 I I I .1 I I I I I I I I I I I I I I I *230-1000 LUMP SUM CONSTRUCTION (CHANNEL IMPROVEMENTS) Lump Sum Construction includes, but is not limited to, the following: channel clearing, traffic control, clear and grub, locating, maintaining and reclaiming disposal areas(s), complying with the terms of the United States Army Corps of Engineers permit (copy included in contract documents), Construction staking, removals and relocations not covered by a separate pay item and any other work required by the contract documents that does not have a separate pay item. **230-1000 LUMP SUM CONSTRUCTION (SANITARY SEWER) Lump Sum Construction includes, but is not limited to, the following: ties to existing manholes; demolition and disposal of existing sanitary sewer pipes and manholes; plug existing sanitary sewer lines. P-3 I I I I I I I I I I I I I I I I I I I CRANE CREEK CHANNEL IMPROVEMENTS ~NERAL NOTES AGGREGATE SURFACE COURSE: The item aggregate surface course is for use in inclement weather to facilitate the movement of local traffic along roadway construction and to permit ingress and egress at drives. When used for this purpose, section 318, Georgia Standard Specifications, is modified to permit truck dumping on unprepared and muddy subgrade. Section 318 is further modified to permit the use of crusher run stone as described in Subsection 806.02. The Contractor will have the choice of the following materials. Graded Aggregate Coarse Aggregate Size 467 Stabilizer Aggregate Type 1 or 2 Crushed stone Subsection 815.01 Subsection 800.01 section 803 Subsection 806.02 All materials to be used as directed by the Engineer. AS-BUILT PLANS: The Contractor shall retain the services of the consultant who designed the project to furnish three (3) complete sets of "as-built" plans, in good condition, to the Project Inspector prior to final payment being made. Such plans shall have all s ignif icant changes marked in red. The proj ect Inspector shall review the marked plans for accuracy, legibility and completeness. As-built plans, approved by the Project Inspector, must have the Inspector's signature on the cover sheet. No "as-built" plans will be accepted without the approval of the proj ect Inspector. Payment for as-built plans shall be includeq in the price bid for other items. COMPACTION: All compaction shall be as defined in the current edition of Georgia Department of Transportation Specifications. Special attention shall be given to the backfill of minor structures (pipe, box culverts, manholes, catch basins, drop inlets, etc.). Compaction shall be achieved using approved tamps and soil layers of approximately 6 inches (loose measure) and in accordance with Georgia Department of Transportation Standards 1030-D and 1401. Backfilling operations of this nature shall not begin until the Contractor has on hand all equipment in good working condition, and competent operators. The backfilling of pipe and other minor structures shall be in accordance with Georgia Department of Transportation Standard Specifications, Current Edition. Backfilling with sand using G-l I I I I I I I I I I I I I I I I I I I jetting and/or flooding will not be allowed in any case without the written permission of the Engineer. CONCRETE: The Contractor shall have a slump cone on the project at all times when concrete is being placed. He shall, in the Engineer's presence, perform slump tests as directed by the Engineer. Tests shall be performed by qualified personnel with a properly cleaned slump cone. Allowable slumps are 2" minimum and 4" maximum. Class "A" concrete shall have a minimum of 611 lbs. cement per cubic yard. Class "B" concrete shall have a minimum of 470 lbs. cement per cubic yard. Concrete not meeting these requirements will be rejected by the Engineer. CONSTRUCTION: At locations where new pavement is to be placed adjacent to existing pavement without an overlay or where curbing is to be placed across paved parking lots, a joint shall be sawed on a line to ensure pavement removal to be neat. Only those joints sawed in concrete pavement will be paid for under the pay item - Sawed Joints...Per Linear Foot when shown in the contract as a specific pay item. The Contractor shall provide borrow and/or waste pits for this project. All pits acquired for use on this project shall be reclaimed in accordance with Section 160 of the Standard Specifications. The Contractor's attention is directed to Subsection 107.23 of the Specifications. All storm drain pipe, side drain pipe, pipe culvert wingwalls, steps, retaining walls, curbs and gutters, headwalls, all types of pavement, wooden structures, except those specifically shown as a removal pay item shall be removed as Clearing and Grubbing, Grading Complete, Grading Per Mile or Lump Sum Construction. All miscellaneous construction details shall be in accordance with Georgia Standard 9031-H. CONSTRUCTION LAYOUT: Construction layout work shall be performed by the Contractor. See section 149 of the Standard Specifications. The survey for this project was made by Cranston. Robertson & Whitehurst Phone (706)722-1588. DESIGN ALTERATIONS: The Commission-Council recognizes that various changes in design may be made as the project progresses. Any requests for additional payment will be processed based on actual work in place and the unit prices submitted as a part of this bid. Items not covered in this bid shall be priced separately and no work shall be done on these items until approved, in writing, by the Engineer. G-2 I I I I I I I I I I I I I I I I I I I EROSION AND SEDIMENT CONTROL: The Contractor shall be responsible for all soil erosion and sediment control practices. All on-site erosion control shall comply with local Augusta-Richmond County erosion and sediment control ordinances. The cost of this work shall be included in the cost of the project unless shown as a separate pay item. EXCESS MATERIAL: All excess material is to be disposed of as directed by the Engineer or as noted in Subsection 107.23 of the Specifications, page PPA-1 and page SPP-1 of this contract. FENCE: All new fence called for on the plans and/or contract documents shall meet the requirements of Section 643 of the Georgia Department of Transportation Standard Specifications, current edition. New fence not meeting these Specs will be rejected. In contracts where remove and reset fence items are involved (either as pay items or as Lump Sum Construction) all replacement fence shall be equal to or better than the existing fence as approved by the Engineer. This means equal to or better than the original fence at the time of it' s installation. In accordance with Subsection 643. 03D the Contractor must furnish positive locking devices, padlocks and keys with all gate assemblies. FINISHING AND DRESSING: All unpaved and natural areas which are disturbed by the construction of this project are to be returned to the pre- existing shape and slope and then finished and dressed. No separate payment will be made for grassing, fertilizing and mulching of disturbed areas, unless specifically shown as a pay item. FLAGGING: Flaggers shall be provided as required to handle traffic, as specified in the Plans or Special Provisions, and as required by the Engineer. All flaggers shall meet the requirement of part 6F of the MUTCD and must have received training and a certificate upon completion of the training from a Department approved training program. Failure to provide certified flaggers as required above shall be reason for the Engineer suspending work involving the flagger(s) until the Contractor provides the certified flagger(s). G-3 I I I I I I I I I I I I I I I I I I I Flaggers shall wear a fluorescent orange cap or hat, and a fluorescent orange vest, shirt, or jacket, and shall use a Stop/Slow paddle meeting the requirements of Section 6F-2 of the MUTCD for controlling traffic. The Stop/Slow paddle shall have a shaft length of seven (7) feet minimum. In addition to the stop/slow paddle, a flagger may use a 24 inches square red/orange flag as an additional device to attract attention. For night work, the vest shall have reflectorized stripes on front and back. Signs for flagger traffic control shall be placed in advance of the flagging operation in accordance with the MUTCD. In addition to the signs required by the MUTCD, signs at regular intervals, warning of the presence of the flagger shall be placed beyond the point where traffic can reasonably be expected to stop under the most severe conditions for that day's work. FOUNDATION BACKFILL MATERIAL, TYPE I: Foundation Backfill Material Type I shall conform to Georgia Standard 1030-D and section 207 of the Standard Specifications. No separate payment will be made for this material or its placement. FOUNDATION BACKFILL MATERIAL, TYPE II: Foundation Backfill Material, Type II shall conform to Georgia Standard 1030-D and section 207 of the Standard Specifications and shall be used in wet/unstable conditions as directed by the Engineer. It shall also be used beneath all concrete box culverts. Quantities shall be measured for payment in accordance with Georgia Standard 1030-C or as directed by the Engineer. Payment shall be per cubic yard unless otherwise specified in the contract. GRADES: with the approval of the Engineer, grades may be field adjusted to provide for best drainage. GRADING: In contracts where grading, including excavation for drainage structures, is accomplished under Section 210 (Grading Complete or Grading Per Mile) or Section 230 (Lump Sum Construction) the Lump Sum amount bid will include all work necessary to obtain the line, grade and compaction in accordance with the Specifications and other contract documents. There will be no separate payment for any work of this nature including borrow and the removal of unsuitable and/or unstable material. However, the Contractor shall make whatever investigations he deems necessary to determine the extent of any borrow or removal necessary to meet contract requirements. If it develops that removal of unsuitable/unstable materials quantities could not have been predicted by the Contractor from a reasonably thorough investigation of project conditions, the Contractor may G-4 I I I I I I I I I I I I I I I I I I I request negotiation for payment for excavation of this nature in areas where the depth exceeds three (3) feet below subgrade. The Owner will consider negotiation only when this type of removal is excessive and the Contractor provides evidence that he thoroughly investigated project conditions prior to entering his bid. Only those quantities in excess of three (3) feet below finished subgrade and/or normal excavation for drainage structures, ordered by the Engineer, will be considered for payment. GRASSING AND EROSION CONTROL: The Contractor shall bid on grassing, lump sum, and it shall be his responsibility to determine the actual area to be grassed. No claims will be considered for extra compensation if the Contractor relies on plan information to prepare his bid. All slope areas are to be grassed unless shown otherwise on plans. Temporary grass is required if permanent grass season is out. The Contractor shall be responsible for all soil erosion and sediment control practices including Temporary Grassing, Temporary Mulch and other temporary measures. All on-site eros~on control shall comply with local erosion and sediment control ordinances. The cost of this work shall be included in the cost of the project unless shown as a separate pay item. All unpaved and natural areas which are disturbed by the construction of this project are to be returned to the pre- existing shape and slope and then finished and dressed. No separate payment will be made for grassing, fertilizing and mulching of disturbed areas, unless specifically shown as a pay item. Discontinued roads or other areas inside or outside the project construction limits, but within the existing or required right-of-way, shall be obliterated and restored as nearly as possible to the original contour of the ground (See section 205 of the Standard Specifications). No separate payment will be made for this work. Where item number 700-6001 is shown as a pay item Georgia Department of Transportation Specifications are modified to provide that the lump sum price bid shall be full payment for all fertilizer, lime and nitrogen. No separate measurement for payment will be made for any work or materials required to accomplish a stand of permanent grass. INFESTATION: The entire project is considered to be within the limits of an insect infested area. The Contractor's attention is called to the following sections of the Standard Specifications: (A) 155 Insect Control (B) 893 Miscellaneous Planting Materials. G-5 I I I I I I I I I I I I I I I I I I I INSPECTION: This project will be inspected by the Engineer or his Representative. MISCELLANEOUS DRAINAGE STRUCTURES: All miscellaneous drainage structure such as Catch Basins, Drop Inlets, Manholes, Junction Boxes, Spring Boxes, Drain Inlets, Special Inlets, etc. whether standard or special design shall be paid for Per ~ach. There will be no separate payment for additional depth unless specifically shown as a pay item. NOTE: All Catch Basins, Drop Inlets, Manholes, exposed Junction Boxes, etc . with concrete tops labs shall include manhole rings and covers. PATCHING AND REPAIR OF MINOR DEFECTS: Where necessary, the Contractor is required to patch and repair existing potholes, minor pavement defects and base failures in accordance with the Specifications. PAYMENT FOR PIPE CULVERT INSTALLATION: 1. Payment for pipe culvert or utility installation includes sawing andjor cutting and removing existing pavement and replacing the pavement as specified in accordance with Standard 140l. 2. Payment for pipe culvert includes plugging existing pipe with Class "A" or liB" concrete (See Georgia Standard 9031-L). 3. Payment for pipe culvert includes any required concrete collars (See Georgia Standard 9031-U). PIPE CULVERTS: Unless otherwise noted, all storm drain, longitudinal and stub pipe are to be reinforced concrete. All required pipe culverts shall be in accordance with Standard 1030-D. ' Foundation Backfill Material Type I shall conform to Georgia Standard 1030-D. No separate pay item will be made for this material or its placement. Payment for pipe culvert or utility installation includes sawing andj or cutting and removing existing pavement and replacing the pavement as specified in accordance with Standard 1401. Payment for pipe culvert includes plugging existing pipe with Class "A" or "B" concrete and for constructing concrete collars. The Contractor shall include in his price bid for pipe, the additional cost of bends, tees, fasteners, appropriate gaskets (see Section 848 of the Standard Specifications), and structure excavation. G-6 I I I I I I I I I I I I I I I I I I I PRECAST CONCRETE UNITS: Precast Concrete Units, other than those specifically allowed by Georgia Department of Transportation Specifications, such as Drop Inlets, Catch Basins, Manholes, etc shall not be installed without written permission from the Engineer. Any such units installed without such written permission shall be removed from the project. PROPERTY CORNERS AND MARKERS: Existing property corners in conflict with construction, disturbed by construction, or to be in a new location due to right-of-way acquisition are to be reset by the Contractor at the proper time. No separate payment will be made for this work. REMOVAL AND RESETTING OF ORNAMENTAL SHRUBS AND BUSHES AND SOD: It shall be the Contractor's responsibility to remove and reset any and all existing ornamental shrubs and bushes and sod in conflict with proposed construction. Coordination with the property owners is essential in this endeavor. The Contractor will not be held responsible for care and maintenance after removing and resetting these plants and sod except in cases where the Contractor's equipment causes irreparable damage or where plants and/ or sod dies as the result of negligence on the Contractor's part. In which cases, the Contractor will be held responsible for replacement. Sod shall be reset with ground preparation in accordance with Subsection 700.05.A. No additional soil or fertilizer is required for resetting sod. The Contractor shall remove the sod in a manner that will be conducive to insuring that the reset sod will live. At the Contractor's option he may replace any sod he removes with new sod of the same type. No separate payment will be made for this work or replacements unless specifically shown as a pay item. REMOVING AND RESETTING OF OBSTRUCTIONS: It shall be the, Contractor's responsibility to remove and reset any and all obstructions such as fences, signs, concrete or brick planters, steps, walkways, brick or concrete entrance columns, etc. which are in conflict with construction and are responsible for the security of pets and/or personal property through the use of temporary fence if necessary. No separate payment will be made for this work except when shown as a separate pay item. RIGHT-OF-WAY AND EASEMENTS: The Contractor shall not perform any work outside the limits of the right-of-way or easements. In addition, no equipment or material shall be placed outside these areas without written permission of both the property owner and the Engineer. G-7 I I I I I I I I I I I I I I I I I I I In the event that the Contractor elects to utilize private property for any purpose connected with the project such as, but not limited to, staging areas, equipment and/or material storage or simply as a convenience, he shall submit a written agreement to the Engineer containing vital information such as limits of both area and time the property is to be utilized and a description of the intended use. The agreement must be signed by both the property owner and the Contractor and will be reviewed and recorded by the Engineer. Such agreements must be submitted prior to the Contractor's use of the property. SALVAGEABLE MATERIALS: As directed by the Engineer or his Representative, all salvageable materials, such as drainage pipe, which require removing but are not to be used on this project, are to be cleaned and stored within the right-of-way by the Contractor. These materials shall be picked up and transported by Augusta- Richmond County forces. The Contractor is responsible and shall make restitution to Augusta-Richmond County for materials damaged through his negligence. SAW CUTS: When matching existing conditions, saw cuts shall be used as required by Augusta-Richmond County. Only saw cuts in Portland Cement Concrete which are shown as contract pay items will be paid for separately. No saw cuts in asphaltic concrete will be paid for separately. SHOULDER WORK: All necessary cleaning of the existing pavement including clipping of shoulders required prior to resurfacing shall be the responsibility of the Contractor. The material displaced shall be removed, lowered or spread over the shoulder to an elevation and slope which will provide adequate drainage. The cost of such work shall be included in the prices bid for other items SPECIFICATIONS: This project is based upon, and shall be constructed in accordance with, the State of Georgia Department of Transportation Standard Specifications for Construction of Roads and Bridges, current Edition and any supplements thereto. All of these specifications shall be considered as though fully contained herein. In cases where conflicts arise within these specifications, they will be revised to resolve such conflict. until the conflict is resolved, the interpretation of the Engineer shall control the situation. SPECIFICATIONS, STANDARDS AND OTHER DATA: All references in this document, which includes all papers, writings, documents, drawings, or photographs used, or to be used in connection with this document, to State Highway of G-8 I I I I I I I I I I I I I I I I I I I Georgia, state Highway Department, Highway Department, or Department when the context thereof means the Georgia Department of Transportation mean, and shall be deemed to mean, Augusta-Richmond County, Augusta-Richmond County Commission-Council Department of Engineering Services. The data, together with all other information shown on these plans, or indicated in any way thereby, whether by drawings or notes or in any other matter, are based upon field investigations and are believed to be indicative of actual condi tions. However, the same are shown as information only, are not guaranteed, and do not bind Augusta-Richmond County, Georgia in any way. Only the actual quantities completed and accepted will be paid for. The attention of the bidder is specifically directed to Subsections 102.04, 102.05, and 104.03 of the Standard Specifications, of the Georgia Department of Transportation, current edition, which will be part of this contract. This project is based on and shall be constructed in accordance with the State of Georgia Department of Transportation Standard Specifications for Construction of Roads and Bridges, current Edition and any supplements thereto. All of these specifications shall be considered as though fully contained herein. In cases where conflicts arise within these specifications, they will be revised to resolve such conflict. Until the conflict is resolved, the interpretation of the Engineer shall control the situation. This project shall be constructed in accordance with current Georgia Department of Transportation Roadway Standards and Construction Details. STORM DRAIN PIPE: Unless otherwise noted, all storm drain, longitudinal and stub pipe are to be reinforced concrete. SUBCONTRACTORS: The Contractor shall furnish the official name of all firms he proposes to use as Subcontractors in the work. This information should be furnished at the Preconstruct ion Conference. However, no work shall be done on this project by a Subcontractor until the Contractor receives written approval of his Subcontractor(s) from the Engineer. The Engineer shall notify the Contractor, in writing within 10 calendar days whether or not approval of the Subcontractor(s) is granted. the Contractor shall send copies of all proposed Subcontractors, including the company name, description of work to be done, phone number and contact person for each Subcontractor to Ms. Brenda Byrd-Pelaez at the following address: Ms. Brenda Byrd-Pelaez, Room 211 Municipal Building, 530 Greene Street, Augusta, Georgia 30911. NOTE: All submissions shall include the following information for each Subcontractor: G-9 I I I I I I I I I I I I I I I I I I I 1) Name of Subcontracting Firm 2) Description of Work To Be Done 3) Contact Person's Name and Phone Number Copies of all submissions shall be submitted to: Ms. Brenda Byrd-Pelaez Room 211 Municipal Building 530 Greene Street Augusta, Georgia 30911 TESTING OF THE WORK: The Contractor shall employ a qualified materials testing laboratory to monitor more fully the quality of materials and work and to perform such tests as may be required under the contract documents as conditions for acceptance of materials and work. THE ENGINEER MAY ORDER TESTING AT ANY TIME HE DEEMS PROPER TO CONTROL THE QUALITY OF THE WORK. Concrete compressive strength project (see section 500 of Transportation Specifications). where necessary. tests are required on this the Georgia Department of Other tests may be required All test results are to be submitted to the Engineer. No separate payment will be made for employing the testing laboratory or any required tests. On projects that include asphaltic concrete, cores shall be cut in the asphaltic concrete at random locations, selected by the Engineer, to verify thicknesses. A minimum of three (3) cores per mile or three (3) cores per project, whichever is greater, shall be cut by the Contractor. If all thicknesses are satisfactory, in accordance with Section 400 of the Department of Transportation Specifications, no further cores will be required. If cores indicate an unsatisfactory thickness, additional cores, as determined by the Engineer and at locations of the Engineer's choosing, shall be cut to determine the extent of the unsatisfactory thickness. Corrections as shown in section 400 of the Department of Transportation Specifications shall be made where required. There will be no separate payment for cutting cores, filling core holes or corrective work. Payment shall be included in the price bid for asphaltic concrete items or in the overall bid price of the contract. TRAFFIC CONTROL: The Contractor shall provide construction signs in accordance with requirements of "Manual on Uniform Traffic Control Devices for Streets and Highways", current edition with added supplements and special provisions. The attention of the Contractor is specifically directed to Subsection 107.09 of the Standard Specifications regarding barricades, danger, warning, and detours signs. G-10 I I I I I I I I I I I I I I I I I I I All temporary signs, barricades, flashing lights, striping and any other traffic control devices required during construction of this project shall meet all requirements of the M. U. T. C. D. , current edition, as directed by the Engineer and be furnished by the Contractor with payment in accordance with section 150. All traffic signs shown are minimum. other signs may be required by the Engineer with payment included under the appropriate items. All temporary traffic control devices are to be placed in accordance with Georgia Department of Transportation standards and Specifications. In accordance with Section 150 of the Standard Specifications and it's Supplement, the Contractor shall file for approval a detour plan of operation for this project. This plan shall include details of staging and rerouting of traffic including estimated length of time for use of the detours. The Contractor shall so conduct his operations that there will be a minimum of interference with, or interruption of, traffic upon and along the highway. This applies to the initial installation and the continuing maintenance and operation of the facility. At least one-lane, two-way traffic shall be maintained at all times unless approved otherwise by the Engineer. As a minimum, the Contractor must comply with the Manual on Uniform Traffic Control Devices, current edition and Georgia Standard 9102. TRAFFIC CONTROL DEVICES: The Contractor shall provide all temporary traffic control devices needed to safely direct traffic through the construction area. All temporary traffic control devices are to be placed in accordance with Georgia Department of Transportation Standards and Specifications. UTILITIES: The Contractor's attention is directed to the possibility of encountering private utility installations consisting of sanitary sewers, water, sprinkler systems, ornamental light systems, gas and underground telephone cables, etc. that either are obstructions to the prosecution of the work and need to be moved out of the way or, if not, must be properly protected during construction. No separate payment will be made for this work. Public utilities of this nature will be handled by the utility owner. G-ll I I I I I I I I I I I I I I I I I I I THE FOLLOWING UTILITY COMPANIES SHALL BE NOTIFIED BEFORE WORK BEGINS: Georgia Power Company Post Office Box 488 Augusta, Georgia 30904 Telephone (706)724-0892 Attention: Parker Land Atlanta Gas Light Post Office Box 1426 Augusta, Georgia 30913 Telephone (706)722-7791 Bell South 3841 Wrightsboro Road Augusta, Georgia 30909 Telephone (706)828-8500 Attention: Bert Neese Jones Intercable, Inc. 1424 Monte Sano Avenue Augusta, Georgia 30904 Telephone (706)736-6515 Urban Services Water & Sewer 2760 Peach Orchard Road Augusta, Georgia 30906 Telephone (706)796-5000 A T & T 2001 Backhall Drive North Augusta, SC 29841 Telephone (800)252-1133 Attention: Paul Prescott UTILITIES: All utility facilities which are in conflict with construction, not covered as specific items in the detailed estimate, are to be removed and relocated to clear construction by the respective owners, unless added later to the contract as a supplemental item. All "above ground" utility structures will be located as near as possible to the right-of-way line. The Contractor will not be paid for expense caused by utility facilities, other items not being removed or construction in advance of his work. any delays or extra obstructions or any relocated to clear All known utility facilities are shown schematically on highway plans, and not necessarily accurate in location as to plan or elevation. utility facilities such as service lines or unknown facilities not shown on the plans will not relieve the Contractor of his responsibility under this requirement except as noted below. "Existing utility Facilities" means any utility facility that exists on the highway project in its original, relocated or newly installed position. Other than service lines from street mains to the abutting property the Contractor will not be held responsible for the cost of repairs to damaged underground utility facilities when such facilities are not shown on the plans and their existence is unknown to the Contractor prior to the damage occurring, providing the Engineer determines the Contractor has otherwise fully complied with the Specifications. G-12 I I I I I I I I I I I I I I I I I I I The following utility owners have facilities which may conflict with construction of this project: NAME OF UTILITY OWNER TYPE OF FACILITY Georgia Power Company Georgia Natural Gas Company Jones Cable T.V. Bell South Augusta-Richmond Co. Water and Sewer Power Gas Cable Telephone Water, Sewer The Contractor shall use the one-call center telephone number 1-800-282-7411 for the purposes of coordinating the marking of underground utilities. The Contractor's attention is directed to the probability of encountering private utility installations consisting of sanitary sewers, water, sprinkler systems, ornamental light systems, gas and underground telephone cables that either are obstructions to the prosecution of the work and need to be moved out of the way or, if not, must be properly protected during construction. No separate payment will be made for this work. Public utilities of this nature will be handled by the utility owner. UTILITY ACCOMMODATION POLICY: In so far as possible work shall be scheduled so that open excavations will not be left overnight. Where trenches, pits or other excavations are within the clear roadside areas and cannot be backfilled before leaving the job site, they shall be covered by timbers or metal plates and protected by reflectorized and/or lighted barricades as appropriate and as directed by the Engineer. Barricades sufficient to prevent a person from falling into an excavated or work area must be erected in areas where these conditions exist. G-13 I I I I I I I I I I I I I I I I I' I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA SPECIAL PROVISION SECTION 1SD-TRAFFIC CONTROL August 28, 1995 First Use: October 20, 1995 Modification of Special Provision Section 150 - Traffic Control (Rev. June 21,1994) Retain Section 150 as written and add the following: For this project, all references to flags on construction warning signs in the Standard Construction Details listed below are deleted except for signs which are mounted at less than seven (7') feet in height (portable signs). Standard Construction Details · Typical By-Pass Detour for Two-Lane Highway · Typical Detour Across Median · Transition of 4-Lane Divided Highway to 2-Lane Highway · Traffic Control General Notes, Standard Legend, Miscellaneous Details In addition, G20-1, G20-2A, and W20-1 signs shown on Georgia Standards 9102, 9106, 9107, and applicable Standard Construction Details shall conform to Part VI of the MUTCD, Revision S, dated September 3, 1993. 150.02 WORK ZONES: Delete "Work Zones" and substitute: Temporary Traffic Control Zones. 150.02. B.2.: Delete last sentence and substitute: Channelization device spacing shall be 10 feet for 200 feet in advance of the temporary gore, and 10 feet for the first 100 feet ofthe temporary gore. 150.03. F.1. MATERIALS - INTERIM SIGNS: Retain as written and add second paragraph. Posts for all interim signs shall be constructed to yield upon impact unless the posts are protected by guardrail, portable barrier, impact attenuator or other type of positive barrier protection. Unprotected posts shall meet the breakaway requirements of the "1985 AASHTO Standard Specifications for Structural Supports for Highway Signs, Luminaries and Traffic Signals". Unprotected post splices will not be permitted any higher than four inches above the ground line to lessen the possibility of affecting the undercarriage of a vehicle. lS0.0S.H. 'CONSTRUCTION WARNING SIGNS: CONSTRUCTION WARNING SIGNS THAT ARE REQUIRED TO BE MOUNTED AT SEVEN FEET IN HEIGHT NO LONGER REQUIRE THE USE OF WARNING FLAGS. Delete first sentence of second paragraph and substitute: Construction warning signs which are mounted at less than seven feet in height (portable signs) shall have two 18 inch x 18 inch fluorescent red-orange or orange-red warning flags mounted on each sign. TC-/ I. I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 150.04.E.2.a.2.: Retain as written and add: In lane shift areas skip lines are not allowed. Solid lines are required. 150.04. E.2.b.1.: Retain as written and add: In lane shift areas skip lines are not allowed. Solid lines are required. 150.05 . D. TEMPORARY GUARDRAIL ANCHORAGE: Delete all references to Type 9 and substitute Type 11 (eleven). 150.1 0 PAYMENT: Item No. 641 - Delete reference to Type 9 and substitute Type 11 (eleven). SPECIAL PROVISION SECTION 150-TRAFFIC CONTROL June 22, 1994 First Use: July 24, 1994 Modification of Standard Specifications, 1993 Edition Retain Section 150 as written and add the following: For this project, all references in the Standard Construction Details listed below to Type I Barricades, Type II Barricades, Type "A" flashing-lights and Type "C" steady burn lights are deleted, except that Type "C" lights will be required for tapers in nighttime lane closures. Standard Construction Details · Typical By-Pass Detour for Two-Lane Highway · Typical Detour Across Median · Transition of 4-Lane Divided Highway to 2-Lane Highway · Traffic Control General Notes, Standard Legend, Miscellaneous Details In addition, G20-1, G20-2A, and W20-1 signs shown on Georgia Standards 9102, 9106, 9107, and applicable Standard Construction Details shall conform to Part VI of the MUTCD, Revision 3, dated September 3, 1993. Detail "A" as shown on Georgia St.a.ndard 4960 is deleted. SPECIAL PROVISION SECTION 150-TRAFFIC CONTROL Rev. June 21, 1994 First Use: JUly 24,1994 Rev.: August 16, 1994 Modification of the Standard Specifications, Current Edition Delete Section 150 as written and substitute the following: 150.01 DESCRIPTION: This section as supplemented by the Plans, Specifications, and MUTCD shall be considered the Traffic Control Plan. Activities shall consist of furnishing, installing, maintaining, and removing necessary traffic signs, barricades, lights, signals, cones, pavement markings and other traffic control devices and shall include flagging and other means for guidance and protection of vehicular and -rc-z I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA pedestrian traffic through the Work Zone. This Work shall include both maintaining existing devices (excluding Traffic Signals) and installing additional devices as necessary in construction work zones. When any provisions of this Specification or the Plans do not meet the minimum requirements of the Manual on Uniform Traffic Control Devices (MUTCD), the MUTCD controls. The 1988 Edition of the MUTCD and Revision 3, dated September, 1993, of Part VI shall be in effect for the duration of the project. A The Contractor shall designate a qualified individual as the Worksite Traffic Control Supervisor (WTCS) who shall be responsible for selecting, installing and maintaining all traffic control devices in accordance with the Plans, Specifications, Special Provisions and the MUTCD. This individual's traffic control responsibilities shall have priority over all other assigned duties. As the representative of the Contractor, the \VTCS shall have full authority to act on behalf of the Contractor in administering the Traffic Control Plan. The WTCS shall have appropriate training in safe traffic control practices in accordance with Part VI of the MUTeD. In addition to the WTCS all others making decisions regarding traffic control must meet the training requirements of Part VI of the MUTCD. On projects where traffic control duties will not require full time supervision, the Engineer may allow the Contractor's Project Superintendent to serve as the WTCS as long as satisfactory results are obtained. The WTCS shall have a copy of the MUTCD on the job site. Copies of current MUTCD may be obtained from: U.S. Government Printing Office Superintendent of Documents Mail Stop: SSOP Washington, D.C. 20402-9328 The WTCS shall be available on a 24-hour basis as needed to maintain traffic control devices with access to all personnel, materials and equipment necessary to respond effectively to an emergency situation within forty-five (45) minutes of notification of the emergency. The WTCS shall supervise the initial installation of traffic control devices which will be reviewed by the Engineer prior to the beginning of construction. Modifications to traffic control devices as required by sequence of operations or staged construction must be reviewed by the WTCS. The WTCS shall regularly perform inspections to ensure that traffic control is maintained. B. All traffic control devices used during the construction of a project shall meet the Standards utilized in the MUTeD, and shall comply with the requirements of these Specifications, Project Plans, and Special Provisions. Reference is made to Subsections 104.05, 107.07, and 107.09. C. All reflectorization for construction (black on orange) signs, object markers, and channelization devices shall meet the requirements of Section 913, Type II or III unless otherwise specified. All other signs shall meet the requirements of Type I unless otherwise specified. D. No work shall be started on any project phase until the appropriate traffic control devices have been placed in accordance with Project requirements. Changes to traffic flow shall not commence unless all labor, materials, and equipment necessary to make the changes are available on the Project. E. The Contractor shall secure the Engineer's approval ofthe Contractor's proposed plan of operation, sequence of work and methods of providing for the safe passage of vehicular and pedestrian traffic before it is placed in operation. The proposed plan of operation should supplement the approved traffic control plan. Any major changes to the approved traffic control plan, proposed by the Contractor, are to be submitted to the Department for approval in accordance with Subsection 104.03 of the Standard Specifications. /C'-3 I I I I I I I I I I I I I I I I I, I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA Some additional traffic control details will be required prior to any major shifts of traffic. The traffic control details shall include, but not be limited to, the following: 1. A detailed drawing showing traffic location and laneage for each step of the change. 2. The location, size, and message of all signs required by the MUTCD, Plans, Special Provisions, and other signs as required to fit conditions. 3. The method to be used in, and the limits of, the obliteration of conflicting lines and markings. 4. Type, location, and extent of new lines and markings. 5. Horizontal and vertical alignment and supere1evation rates for detours, including cross section and profile grades along each edge of existing pavement. 6. Drainage details for temporary and permanent alignments. 7. Location, length, and/or spacing of channelization and protective devices (temporary barrier, guardrail, barricades, ete.) 8. Starting time, duration and date of planned change. 9. For each traffic shift, a paving plan, erection plan, or work site plan, as appropriate, detailing workforce, materials, and equipment necessary to accomplish the proposed work. This will be the minimum resource allocation required in order to start the work. The above details shall be submitted to the Engineer for approval at least 14 days prior to the anticipated traffic shift. The Contractor shall have traffic control details for a traffic shift which has been approved by the Engineer prior to commencement of the physical shift. All preparatory work relative to the traffic shift which does not interfere with traffic shall be accomplished prior to the designated starting time. The Engineer and the Contractor's representative will verify that all conditions have been met prior to the Contractor obtaining materials for the actual traffic shift. F. Traffic control devices shall be in acceptable condition when first erected on the project and shall be maintained in accordance with Subsection 104.05 throughout the construction period. All unacceptable traffic control devices shall be replaced within 24 hours. When not in use, all traffic control devices shall be removed, placed or covered so as not to be visible to traffic. If traffic control devices are left in place for more than ten days after completion of the Work, the Department shall have the right to remove such devices, claim possession thereof, and deduct the cost of such removal from any monies due, or which may become due, the Contractor. G. The Department reserves the right to restrict construction operations when, in the opinion of the Engineer, the continuance of the Work would seriously hinder traffic flow on days immediately before, on, or after holidays or other days in which unusual traffic conditions exist, including threatening or inclement weather. 150.02 WORK ZONES: A In addition to the other provisions contained herein, work zone traffic control shall be accomplished using the following means and materials: 1. Portable advance warning signs as required by the contract or meeting the requirements of the MUTCD and Sub-Section 150.03. 2. Portable sequential or flashing arrow panels as shown in the Plans or Specifications for use on Interstate or multi-lane highway lane closure only, shall be a minimum size of 48" high by 96" /c-~ I I I I I I I I I I I I I I I I I' I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA wide with not less than 15 lamps used for the arrow. The arrow will occupy virtually the entire size of the arrow panel and shall have a minimum legibility distance of one mile. The minimum legibility distance is tbat distance at which the arrow panel can be comprehended by an observer on a sunny day, or clear night. Arrow panels shall be equipped with automatic dimming features for use during hours of darkness. The arrow panels shall also meet the requirements as shown in tbe MUTeD. The sequential or flashing arrow panels shall not be used for lane closures on two- lane, two-way highways when traffic is restricted to one-lane operations in which case, appropriate signing, flaggers and when required, pilot vehicles will be deemed sufficient. 3. Portable changeable message signs meeting the requirements of Section 632 and the MUTCD. 4. Channelization devices meeting the standards of the MUTCD and Subsection 150.05. 5. Precast concrete barrier meeting the requirements of Section 622. 6. Temporary traffic signals meeting the requirements of Section 647. 7. Pavement marking materials complying with Subsection 150.04.A. B. LANE CLOSURES: 1. All lane closures shall have prior approval of the Engineer. Lane closures that require same direction traffic to be split around the Work Area will not be approved for roadways with posted speeds of 35 mph or greater, excluding turn lanes. 2. On multilane highways where traffic has been shifted to the inside lanes for overnight use, the entrance and exit ramps shall have channelization devices placed on both sides of the ramp. The temporary ramp taper length shall be greater tban, or equal to, the existing taper length. Interim EXIT gore signs shall be placed at tbe ramp divergence. Charmelization device spacing in the first 100 feet of the temporary gore shall be 25 feet. 3. Termination Area: The transition to normal or full width highway at the end of a lane closure shall be a maximum of 150 feet. 4. To provide tbe greatest possible convenience to the public in accordance with Subsection 107.07, the Contractor shall remove all signs, lane closure markings, and devices immediately when lane closure work is completed or temporarily suspended for any length of time or as directed by the Engineer. C. TRAFFIC PACING METHOD: 1. PACING OF TRAFFIC: Witb prior approval from tbe Engineer, traffic may be paced allowing the Contractor up to ten (10) minutes maximum to work in or above all lanes of traffic for the following purposes: a Placing bridge members or other bridge work. b. Placing overhead sign structures. c. Other work items requiring interruption of traffic. The Contractor shall provide a uniformed police officer with patrol vehicle and blue flashing light for each direction of pacing. The police officer, Engineer, and flaggers at ramps shall be provided with a radio which will provide continuous contact with the Contractor. TC-S- I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE'OF GEORGIA When ready to start the work activity, the police vehicle will pull into the travel lanes and act as a pilot vehicle slowing the traffic thereby providing a gap in traffic allowing the Contractor to perform the Work. Anyon-ramps between the pace and the work area shall be blocked during pacing of traffic, with a flagger properly dressed and equipped with a StoplSlow paddle. Each ramp should be opened after the police vehicle has passed. Pilot vehicles shall travel at a safe pace speed, desirably not less than 20 mph interstate and 10 mph non-interstate. The Contractor shall provide a vehicle to proceed in front of the police vehicle and behind the other traffic in order to inform the Contractor's work force when all vehicles have cleared the area. Traffic will not be permitted to stop during pacing except in extreme cases as approved by the Engineer. 2. METHODS OF SIGNING FOR TRAFFIC PACING: At a point not less than 1,000 feet in advance of the beginning point of the pace, the Contractor shall erect and cover a W-special sign (72 inch x 72 inch) with a Type "B" flashing light, with the legend "TRAFFIC SLOWED AHEAD SHORT DELAY" (See Detail 150-A). A portable changeable message sign may be used in lieu of the W -special sign. On divided highways this sign shall be double indicated. A worker with a two-way radio shall be posted at the sign, and upon notice that the traffic is to be paced shall turn on the flashing light and reveal the sign. When traffic is not being paced, the flashing light shall be turned off and the sign covered or removed. W-special signs are reflectorized black on orange, Series "C" letters and border of the size specified. -rc-c I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA T~ ,. FU.SHIMC L ICHl Dll nun IC SIDE SJ- 1"'s. 7z. ...' ~ ~ ffi\ ~ ~ ~ ~ 10. r $Z. 'I 10. ~~(Q) '~[Q) u.-r. ~2. 'J15' ffi\~~ffi\[Q) ~~@Iffi] ."~~~~ W t..,!. :'," 1':1 w-5I"[ C I AI. S I GIl (TttrClWn' ~ T IIlCUCTE 0 , S J CN $HAL L HA V[ It. AClt L[ C[IC) AN) ICJtD[ R CII CIRANGE RE'LECTOR I rED BAClc;RQJHD DETAIL 150-A ,. IlIlMG IN ',~. BCJa:A ,. IUDIUS ,. fl. '2- SER. .C. ,. u- ". SEA. .c. ,- 1'. U. SER. .C. ~. I. .. S[JI. .C. ,. D. The Contractor's trucks and other vehicles shall travel in the direction of normal roadway traffic tmless separated by a positive barrier, or when construction activity necessitates otherwise, and shall not reverse direction except at intersections, interchanges, or approved temporary crossings. E. The Contractor shall ensure that dust, mud, and other debris from construction activities do not interfere with normal traffic operations or adjacent properties. F. Existing street lighting shall remain lighted as long as practical and until removal is approved by the Engineer. G. Adequate temporary lighting shall be provided at all nighttime work sites where workers will be immediately adjacent to traffic. H. For their own protection, workers in or adjacent to traffic during nighttime operation shall wear reflectorized vests. / (::'-7 I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 1. The parking of Contractor's and/or workers personal vehicles within the work area or adjacent to traffic is prohibited. J. The Worksite Traffic Control Supervisor (WTCS) shall monitor the work to ensure that all the rocks, boulders, construction debris, stockpiled materials, equipment, tools and other potential hazards are kept clear of the travel way. These items shall be stored in a location, in so far as practical, where they will not be subject to a vehicle running off the road and striking them. K All existing pedestrian walkways shall be maintained. Whenever changes to the worksite necessitate changes to existing walkways, temporary walkways shall be provided and maintained, with appropriate signs as necessary, to allow safe passage of pedestrian traffic. 150.03 SIGNS: A When required for proper traffic control during construction of the project, all existing guide, warning, and regulatory signs shall be maintained by the Contractor in accordance with these Specifications. Existing street name signs shall be maintained at street intersections. All existing illuminated signs shall remain lighted and be maintained by the Contractor. B. When not in use, all inappropriate traffic signs or portions thereof shall be removed, placed or covered so as not to be visible to traffic. All construction warning signs shall be removed within seven calendar days after time charges are stopped or pay items are complete. Subsequent punch-list or other work to be performed shall be accomplished utilizing temporary construction warning signs that shall be removed daily. C. The Contractor shall not remove any existing signs and supports without prior approval from the Engineer. All existing signs and supports which are to be removed shall be stored and protected as directed by the Engineer, and become the property of the Department unless otherwise specified in the contract documents. D. Interim guide, warning, or regulatory signs required to direct traffic shall be furnished, installed, reused and maintained by the Contractor in accordance with the MUTCD, the Plans, Special Provisions, or as directed by the Engineer. These signs shall remain the property of the Contractor. The bottom of all interim signs shall be at least seven feet above the level of pavement edge. E. Existing special guide signs on the Project shall be maintained until conditions require a change in location or legend content. When change is required, existing signs shall be modified and continued in use if the required modification can be made within existing sign borders using design requirements Oegend, letter size, spacing, border, etc.) equal to that 'of the existing signs, or of Subsection 150.03.E.5. Differing legend designs shall not be mixed in the same sign. 1. SPECIAL GUIDE SIGNS: Special guide signs are those expressway or freeway guide signs that are designed with a message content Oegend) that applies to a particular roadway location. When an existing special guide sign is in conflict with work to be performed, the Contractor shall remove the conflicting sign and reset it in a new, non-conflicting location which has been approved by the Engineer. . 2. INTERIM SPECIAL GUIDE SIGNS: When it is not possible to utilize existing signs, either in place or relocated, the Contractor shall furnish, erect, maintain, modify, relocate, and remove new interim special guide signs in accordance with the Plans or as directed by the Engineer. 3. INTERIM OVERHEAD GUIDE SIGN STRUCTURES: Interim overhead special guide sign structures are not required to be lighted unless specifically required by the Plans. Iflighting is required the sign shall be lighted as soon as erected and shall remain lighted, during the hours of darkness, until the interim sign is no longer required. The Contractor shall notify the Power Company at least thirty (30) days prior to desiring connection to the power source. -rC-8 I, I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 4. The installation of new permanent special guide signs and the permanent modification or resetting of existing special guide signs, when included in the contract, shall be accomplished as soon as practical to minimize the use of interim special guide signs. If lighting is required by the Plans, all new permanent overhead special guide signs shall be lighted as soon as erected. 5. Interim special guide signs that may be required in addition to, or a replacement for, existing expressway and freeway (interstate) signs must be designed and fabricated in compliance with the minimum requirements for guide signing contained in Part 2E "Guide Signs Expressways" and Part 2F "Guide Signs Freeways" of the MUTCD, except that the minimum size of all letters and numerals in the names of places, streets and highways on all signs shall be 16 inches Series "E" initial upper-case and 12 inches lower-case. All interstate shields on these signs shall be 48 inches and 60 inches for two-numeral and three-numeral routes, respectively. Additionally, the exit road name or route shield shall be placed on the exit gore sign. F. MATERIALS - INTERIM SIGNS: 1. POSTS - Posts for all interim signs shall meet the requirements of Section 911 except that green or silver paint may be used in lie.u of galvanization for steel posts or structural shape posts. Wood posts are not required to be pressure treated. 2. SIGN BLANKS AND PANELS - All sign blanks and panels shall conform to Section 912 of the Specifications except that blanks and panels may be ferrous based or other metal alloys. Type 1 and Type 2 sign blanks shall have a minimum thickness of 0.08 inches regardless of the sign type used. Alternative sign blank materials (composites, poly carbonates, fiberglass reinforced plastics, recycled plastics, etc.) shall have a letter of approval from the Office of Materials and Research for use as interim construction signs before these materials are allowed to be incorporated into the work. Signs shall be painted to prevent rust if other metals are used in lieu of aluminum. Plywood blanks or panels will not be permitted. G. All existing, interim and new permanent signs shall be installed so as to be completely visible for an advance distance in compliance with the MUTCD. Limbs, brush, construction equipment and materials shall be kept clear of the driver's line of sight to the signs. H. Advance warning signs shall be placed ahead of construction in accordance with Part VI of the MUTeD and shall include a series of at least three advance road construction CW20-1) signs placed at the termini of the project. The series shall have the legend ROAD WORK (1500 FEET, 1000 FEET, AND 500 FEET.) In addition to the above, multi-lane divided highways shall also have the legend ROAD WORK (2 MILES, 1 MILE, AND 1/2 MILE.) On-ramps and at grade intersecting roadways shall be signed with a minimum of one ROAD WORK AHEAD sign. All construction warning signs shall have two 18 inch x 18 inch fluorescent red-orange or orange-red warning flags monnted on each including the project construction signs (G20-1 and G20-2A..) Project mileage indicated on the G20-1 sign shall be the actual project mileage ronnded up to the nearest whole mile. All construction warning signs on divided highways shall be double indicated (i.e., on the left and right sides of the roadway.) 1. The sequential or flashing arrow panels shall be placed on the shoulder at or near the point where the lane closing transition begins. The panels shall be monnted on a vehicle, trailer, or other suitable support. Vehicle monnted panels shall be provided with remote controls. Minimum monnting height shall be seven feet above the roadway to the bottom of the panel, except on vehicle monnted panels which should be as high as practical. J. The portable changeable message sign, when specified, shall be placed ahead of construction activities and shall meet the requirements of Section 632 and the MUTCD. -rL- 'Y I I I I I I I I I I I I I I I I I. I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA K. The flashing beacon assembly, when specified, shall be used in conjunction with construction warning signs, regulatory, or guide signs to inform traffic of special road conditions which require additional driver attention. The flashing beacon assembly shall be installed in accordance with the requirements of Section 647. 150.04 PAVEMENT MARKINGS A Generally, full pattern pavement markings in accordance with Section 652 and in conformance with Section 3A and 3B, except 3B-3 and 3B-5, of the MUTCDare required on all courses before the roadway is opened to traffic. No passing zones shall be marked to conform to Section 150.04 E. During construction and maintenance activities on all highways open to traffic, both existing markings and markings applied under this Section shall be fully maintained until Final Acceptance. If the pavement markings are, or become, unsatisfactory in the judgement of the Engineer due to wear, weathering, or construction activities, they shall be restored immediately. On resurfacing projects pavement markings shall be provided on all surfaces that are placed over existing markings. On widening and reconstruction projects (where the lane configuration is altered from the pre-construction layout) pavement markings will be as required by the Plans or the Engineer. On new construction projects pavement marking plans will be provided. B. MATERIALS: All traffic striping applied under this Section shall be a minimum four inches in width and shall conform to the requirements of Section 652, except as modified herein. Raised pavement markers CRPMs) shall meet the requirements of Section 654. Markings on the fmal surface course which must be removed shall be a removable type. The Contractor will be permitted to use paint, thermoplastic, or tape on pavement which is to be overlaid as part of the project, unless otherwise directed by the Engineer. Partial (skip) reflectorization (Le. reflectorizing only a portion of a stripe) will not be allowed. C. USAGE: The Contractor shall sequence the work in such a manner as to allow the installation of markings in the fmallane configuration at the earliest possible stage. Inappropriate or conflicting existing pavement markings shall be removed. When shifting of traffic necessitates removal of centerline, lane lines, or edge lines, all such lines shall be removed prior to, during, or immediately after any change so as to present the least interference with traffic. Before any change in traffic lane(s) alignment, marking removal equipment shall be present on the project for immediate use. If marking removal equipment failures occur, the equipment shall be repaired or replaced (including leasing equipment if necessary), so' that the removal can be accomplished without delay. Except for the final surface, markings on asphaltic concrete may be obliterated by an overlay course, when approved by the Engineer. When an asphaltic concrete overlay is placed for the sole purpose of eliminating conflicting markings and the in place asphaltic concrete section will allow, said overlay will be eligible for payment only if designated in the Plans. Overlays to obliterate lines will be paid for only once and further traffic shifts in the same area shall be accomplished with removable markings. Only the minimum asphaltic concrete thickness required to cover lines (generally 60 IbJsq. yd. of Asphaltic Concrete "H") will be allowed. Excessive build-up will not be permitted. When an overlay for the sole purpose of eliminating conflicting markings is not allowed, the markings no longer applicable shall be removed in accordance with Subsection 656.02. The elimination of conflicting pavement markings by overpainting with paint or liquid asphalt is not acceptable. D. Raised pavement markers CRPMs) are required as listed below for all asphaltic concrete pavements before the roadway is open to traffic. When Portland Cement Concrete is an intermediate or fmal surface and is open to traffic, one calendar day is allowed for cleaning and drying before the installation of RPMs is required. /c-/CJ I I I I I I I I I I I I I I I I I. I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 1. On Interstate and limited access highways under construction, excluding projecUi consisting primarily of asphalt resurfacing items, retro-reflective raised pavement markers (RPMs) shall be placed and/or maintained on intermediate pavement surfaces opened to traffic as follows: a SUPPLEMENTING LANE LINES: 80 foot centers on skip lines with curvature less than three degrees. (Includes tangents.) 40 foot centers on solid lines and all lines with curvature between three degrees and six degrees. 20 foot centers on curves over six degrees. 20 foot centers on lane transitions or shifts. b. SUPPLEMENTING RAMP GORE LINES: 20 foot centers, two each, placed side by side. c. OTHER LINES: As shown on the plans or directed by the Engineer. 2. On other highways under construction RPMs shall be used and/or maintained on intermediate pavement surfaces as follows: a SUPPLEMENTING LANE LINES AND SOLID LINES: 40 foot centers except on lane shifts. (When required in the Plans or Contract.) 20 foot centers on lane shifts. (Required in all cases.) b. SUPPLEMENTING DOUBLE SOLID LINES: 40 foot centers (one each beside each line) except on lane shifts. (When required in the Plans or Contract.) _ 20 foot centers on lane shifts. (Required in all cases.) RPMs are n21 allowed on right edge lines. E. EXCEPTIONS FOR INTERIM MARKINGS: Some exceptions to the time of placement and pattern of markings are permitted as noted below, however, full pattern pavement markings are required for the completed project. 1. TWO-LANE, TWO-WAY ROADWAYS a SKIP UNES: All interim skip (broken) stripe shall conform to Section 652 except that stripes shall be at least four feet long with a maximum gap of 36 feet. On curves greater than six degrees, a two-foot stripe with a maximum gap of 18 feet shall be used. In lane shift areas skip lines will not be allowed. Solid Lines will be required. Interim skip lines will be permitted for a period not to exceed 14 calendar days. Interim skip lines must be replaced with markings in full compliance with Section 652 prior to expiration of the 14 calendar day period. -rc-// I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA Interim raised pavement markers may be substituted for the interim skip (broken) stripes. Ifraised pavement markers are substituted for the four foot interim skip stripe, four markers spaced at equal intervals over a four feet distance will be required. No separate payment will be made if the interim raised pavement markers are substituted for interim skip lines. Interim raised pavement markers shall be retro-reflective, shall be the same color as the pavement markers for which they are substituted, and shall be visible during daytime. The type of interim marker and method of attachment to the pavement must be approved by ilie Office of Materials and Research but in no case will the markers be attached by the use of nails. The interim raised pavement markers must be maintained until the full pattern pavement markings are applied. At the time full pattern pavement markings are applied the interim raised markers shall be removed in a manner that will not interfere with application of the full pattern pavement markings. b. NO PASSING BARRIER: On two-lane, two-way roadways for periods not to exceed three . calendar days where skip centerlines are in place, no-passing zones may be identified by using post or portable mounted DO NOT PASS regulatory signs (R4-1 24" x 30") at the beginning and at intervals not to exceed 1/2 mile within each no-passing zone. A post or portable mounted PASS WITH CARE regulatory sign (R4-1 24" x 30") shall be placed at the end of each no-passing zone. Post mounted signs shall be placed in accordance with the MUTCD. Portable signs must have a minimum vertical height of three feet above the pavement surface to the bottom of the sign and be secured in such a manner as to not be easily blown over or misaligned. c. EDGELINES: (1) Bituminous Surface Treatment Paving: Edgelines will not be required on intermediate surfaces (including asphaltic concrete leveling for bituminous surface treatment paving) that are in use for a period of less than 60 calendar days except at bridge approaches, on lane transitions, lane shifts, and in such other areas as determined by the Engineer. On the final surface, edgelines must be placed within 30 calendar days of the time that the final surface was placed. (2) All Other Types of Pavement: Edgelines will not be required on intermediate surfaces that are in use for a period of less than 30 calendar days except at bridge approaches, on lane . transitions, lane shifts, and in such other areas as determined by the Engineer. On the final surface, edgelines must be placed within 14 calendar days of the time that the surface was placed. d. MISCELLANEOUS PAVEMENT MARKINGS: School zones, railroads, stopbars, symbols, words and oilier similar markings shall be placed on final surfaces conforming to Section 652 within 14 calendar days of completion of the final surface. On intermediate surfaces these markings will generally not be required unless specified by the Engineer because of special conditions or when the intermediate surface will be in use for more than 45 calendar days. 2. MULTI-LANE HIGHWAYS - WITH NO PAVED SHOULDER(S) OR PAVED SHOULDER(S) FOUR FEET OR LESS a. UNDIVIDED HIGHWAYS (INCLUDES PAVED CENTER TURN LANE) (1) Centerlines and No-Passing Barrier - Full pattern centerlines and no-passing barriers shall be restored before nightfall. TC-/Z I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA (2) Lanelines - Interim skip (broken) stripe as described in Subsection 150.04.E.1.a. may be used for periods not to exceed three calendar days. (3) Edgelines - Edgelines shall be placed on intermediate and final surfaces within three calendar days of obliteration. b. DIVIDED HIGHWAYS (GRASS OR RAISED MEDIAN) (1) Lanelines - Full pattern skip stripe shall be restored before nightfall. (2) CenterlinelEdgeline - Solid lines shall be placed on intermediate and final surfaces within three calendar days of obliteration. c. Miscellaneous Pavement Markings Same as Subsection 150.04.E.1.d. 3. LIMITED ACCESS ROADWAYS AND ROADWAYS WITH PAVED SHOULDERS GREATER THAN FOUR FEET a. Same as Subsection"150.04.E.2. except as noted in (b) below. b. EDGELINES- (1) Asphaltic Concrete Pavement - Edgelines shall be placed on intermediate and fmal surfaces prior to opening to traffic. (2) Portland Cement Concrete Pavement - Edgelines shall be placed on any surface open to traffic no later than one calendar day after work is completed on a section of roadway. All water and residue shall be removed prior to daily striping. F. APPLICATION OF PAVEMENT MARKINGS: The Contractor shall furnish layout, clean as necessary, and preline the surface for the placement of pavement markings applied under this Section. All existing marking tape on final surfaces shall be removed prior to placement of final markings. Pavement markings shall re-establish No-Passing Zones in the locations and configuration that existed prior to construction. Existing No-Passing Zones shall be clearly identified as to location prior to construction by staking or erection of DO NOT PASS and PASS WITH CARE signs. On new location projects and on projecUi where either horizontal or vertical alignments have been modified, the location of No-Passing Zones will be identified by the Engineer. G. MOBILE OPERATIONS: When pavement markings (centerlines, lane lines, and edge lines) are applied in a continuous operation by moving vehicles and equipment, the following minimum equipment and warning devices shall be required in addition to the requirements of the MUTCD: 1. A lead vehicle is required for two-way traffic conditions and shall have an approved sequential or flashing arrow panel mounted so as to be easily visible to oncoming traffic. A lead vehicle is not required for low volume off-system routes and one-way traffic applications. 2. The work vehicle applying markings shall have a sequential or flashing arrow panel mounted on the rear. If the work vehicle is also functioning as the lead vehicle then an approved arrow panel shall be mounted so as to be easily visible to oncoming traffic. The work vehicle shall follow directly behind the lead vehicle. 3. The work vehicle placing cones shall follow directly behind the work vehicle applying the markings. The cone work vehicle shall have a sequential or flashing arrow panel mounted on the rear. / "C-/3 I I I I I I I I I I I I I I I I I" I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 4. For multi-lane roadways a protection vehicle shall follow the above vehicles and the protection vehicle shall also display a prominent sign with the legend PASS ON LEFT (RIGHT). On interstate and limited access roadways, the protection vehicle shall be equipped with a truck mounted attenuator (TMA) that is certified for impacts not less than 45 mph in accordance with NCHRP 230. 5. All vehicles shall be equipped with tbe official slow moving vehicle symbol sign and left and right- side rear mounted flashing yellow lights. 150.05 CHANNELIZATION A GENERAL: Channelization should clearly delineate the travel way through the work zone and alert drivers and pedestrians to conditions created by work activities in or near the travel way. Channelization shall be done in accordance with the plans and specifications, the MUTCD, and the following requirements. 1. Types of Devices Permitted for Channelization in Construction Work Zones: a. DRUMS: (1) DESIGN: Drums shall meet the minimum requirement of the MUTCD and shall be reflectorized as required in Subsection 150.01.C. (2) APPLICATION: Drums shall be used as the required channelizing device to delineate the full length of a lane closure, shift, or encroachment, except as modified by this Subsection. (a) TRANSITION TAPERS AND LANE CLOSURES: Drums shall be used on all transition tapers. The minimum length of the approach transition taper for a lane closure, shift, or encroachment for highways with posted speed of 45 mph or greater shall be equal to the lane width oflateral shift (Ft.) x the posted speed limit (Mph), (L = WS), but not less than 150 feet. For multiple lane closures, only one lane may be closed per taper with a minimum tangent length of 2L between tapers. The length of a closed lane, excluding the transition taper, will be limited to two mile, unless otherwise approved or directed by the Engineer. Drums shall be placed the full length of the taper spaced at maximum intervals in feet equal to the numerical speed limit (EXAMPLE: 55 Mph Speed Limit = 55 feet maximum spacing). For taper lengths on urban, residential or other streets where the posted speed is 40 mph or less, the minimum length of the approach transition taper may be computed using the formula L = WS2/60. Greater taper length shall be used when required for individual situations. Drums with steady burning lights, for the length of the taper only, are required if the condition exists into the night. (b) LONGITUDINAL CHANNELIZATION: Drums shall be spaced as listed below for various roadside work conditions except as modified by Subsection 150.06. Spacing shall be used for situations meeting any of the conditions listed as follows: (1) 50 FOOT SPACING MAXIMUM: (a) For difference in elevation exceeding two inches. (b) For healed sections no steeper than 4:1 as shown in Subsection 150.06, Detail 150-E.. -rc-/?- I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA (2) 100 FOOT SPACING MAXIMUM: (a) For difference in elevation of two inches or less. (b) Flush areas where equipment or workers are within ten feet of the travel lane. (3) 200 FOOT SPACING MAXIMUM: Where equipment or workers are more than ten feet from travel lane. Lateral offset clearance to be four feet from the travel lane. (a) For paved areas eight feet or greater in width that are paved flush with a standard width travel lane. (b) For disturbed shoulder areas not completed to typical section that are flush to the travel lane and considered a usable shoulder. When tbe appropriate signs are posted advising of conditions such as soft or low shoulder, drums may be removed after shoulders are completed to typical section and grassed and after guardrail or other safety devices have been installed. b. VERTICAL PANELS: (1) DESIGN: All vertical panels shall have a minimum of 270 square inches of retro-reflective area facing the traffic and shall meet the requirements of the MUTCD. (2) APPLICATION: Lane encroachment by the drum on the travel way should permit a remaining lane widtb often feet. When encroachment reduces the travelway to less than ten feet, vertical panels shall be used to restore the travel way to ten feet or greater. No other application of vertical panels will be permitted. c. CONES: (1) DESIGN: All cones shall be a minimum of28 inches in height regardless of application and shall meet the requirement of the MUTCD. (2) APPLICATION: For longitudinal channelizing only, cones will be permitted for daylight closures or minor shifts. (Drums are required for all tapers.) The use of cones for nighttime work will not be permitted. d.- BARRICADES: (1) DESIGN: The use of Type I and Type II barricades will not be permitted. Type III barricades shall meet the minimum requirements of the MUTeD and shall be reflectorized as required in Subsection 150.01.C. (2) APPLICATION: Type III barricades shall be placed as required by the plans, the Standards, and as directed by the Engineer. e. WARNING LIGHTS: (1) DESIGN: All warning lights shall meet the requirements of the MUTeD. (2) APPLICATION: (a) Type A low-intensity flashing lights shall be used as shown in the Plans, the Standards, and as directed by the Engineer. F1ashing lights are not required for advance warning signs in Subsection 150.03.H. -rc- /5 I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA (b) Type C Steady-Burn lights shall be used on all tapers when the condition existl into the night Steady-bum lights shall also be used as shown in the Plans, the Standards, and as directed by the Engineer. . f. PORTABLE BARRIERS: (1) DESIGN: Portable Barriers shall meet the requirements of Section 622 - PRECAST CONCRETE BARRIER. (2) APPLICATION: Portable Barriers shall be placed as required by the plans. standards, and as directed by the Engineer. When Portable Barrier is located 20 feet or less from a travel lane, yellow reflectors shall be fixed to the top of the barrier at intervals not greater than 50 feet and shall be mounted approximately two inches above the barrier. The reflectors shall be eitber 10" x 10" square 'Type V (or equal) reflective sheeting mounted on flat-sheet panels, or 8" diameter center-mounted sealed prismatic reflex reflectors housed in an aluminum backing with a single grommeted hole. Approach end of Portable Barrier shall be flared or protected by an impact attenuator (crash cushion) or other approved treatment in accordance with Georgia Standard 4960, Construction Details and Standard Specifications. On interstate or other controlled access highways where lane shifts or crossovers cause opposing traffic to be separated by less than 40 ft., precast concrete barrier shall be used as a separator. B. TEMPORARY SAND LOADED ATI'ENUATOR MODULES 1. DESCRIPTION: This work consists oftbe furnishing, installation, maintenance, relocation, reuse as required, and removal of Temporary Sand Loaded Attenuator Modules for traffic impact attenuators. 2. MA TERIAI.S: Materials used in the Attenuator shall meet the requirements of Subsection 648.02 for Type 2 Sand Loaded Modules - Cylindrical Drums or Type 2-A Sand Loaded Modules - Stabilizer Drums with Wine Glass shaped Inner Containers. 3. CONSTRUCTION: Temporary Sand Loaded Attenuator Module installation shall conform to the requirements of Subsection 648.03, Manufacturer's recommendations, and Georgia Standard 4960 and shall be installed at locations designated by the Engineer. C. PORTABLE IMPACT ATTENUATORS: 1. DESCRIPTION: This work consists of the furnishing (including spare parts), installation, maintenance, relocation, reuse as required, and removal of Portable Impact Attenuators. 2. MATERIALS: Materials used in the Attenuator shall meet the requirements of Section 650 for Type A Portable Impact Attenuators. 3. CONSTRUCTION: Portable Impact Attenuator installation shall conform to the requirements of Subsection 650.03, Manufacturer's recommendations, and Georgia Standard 4960 and shall be installed at locations designated by the Engineer, and/or shown on the plans. D. TEMPORARY GUARDRAIL ANCHORAGE - Type 11: 1. DESCRIPTION: This work consists of the furnishing, installation, maintenance and removal of Temporary Guardrail Anchorage - Type 11 used for Portable Barrier or temporary guardrail end treatment. TC-/~ I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 2. MATERIALS: Materials used in the Temporary Guardrail Anchorage - Type 11 shall meet the requirements of Subsection 641.02 of the Standard Specifications and current Georgia Standards and may be new or used. Materials salvaged from the Project which meet the requirements of Standards may be utilized if available. The use of any salvaged materials will require prior approval of the Engineer. 3. CONSTRUCTION: Installation of the Temporary Guardrail Anchorage - Type 11 shall conform to the requirements of the Plans, current Georgia Standards and Subsection 641.03 of the Standard Specifications. Installation shall also include sufficient additional guardrail and appurtenances to effect tbe transition and connection to Temporary Concrete Barrier as required by the details in Georgia Standard 4960. 150.06 EXCAVATION ADJACENT TO A TRAVEL LANE: Construction work involving trenching adjacent to a travelway shall not begin until the Contractor is able to continuously place the required typical section to within two inches of the existing pavement elevation, or heal the remaining difference in elevation to the traveled way as shown in Detail 150-E. Channelization devices and placement during the construction period shall conform to the requirements of Subsection 150.05 and Details 150-B, 150-C, 150-D, and 150-E shown herein. In addition to the signs specified in Section 150 and the MUTCD, a W-20 sign with the legend "(LEFT) (RIGHT) LANE NARROWS" witb two flags shall be kept just off the paving edge and 500 feet upstream ofthe point where channelization devices are erected on the paving edge. A. STONE BASES, SOIL AGGREGATE BASES, AND SOIL BASES: DroJHlffs in elevation of more than two inches between surfaces carrying, or adjacent to, traffic will not be allowed for more than 24 hours. However, where the Contractor has demonstrated the ability to continuously excavate and backfill in a proficient manner, a single length of excavated area not to exceed 1000 feet may be left open as a start up area for periods not to exceed 48 hours. B. ASPHALT BASESIBINDERS: Drop-offs in elevation of more than two inches between surfaces carrying or adjacent to traffic will not be allowed for more than 48 hours. C. PORTLAND CEMENT CONCRETE AND CEMENT STABILIZED BASES: Construction work adjacent to the traveled way which involves these types of bases shall be healed within 48 hours after the curing period is complete for each section placed. During the placement period, traffic control devices will be in accordance with Subsection 150.05 and Detail 150-B. D. MISCELLANEOUS EXCAVATIONS OR DROP-OFFS ADJACENT TO TRAVELWAY:Worksuch as drainage structures, utility facilities, or any other work which results in a drop-off adjacent to the travel way shall be performed expeditiously so as to minimize the exposure to the hazard. As soon as practical, the excavation shall be backfilled to the minimum requirements of Detail 150-E. In no case will tbe drop-off be allowed to exist more tban five calendar days. This may require stage construction, such as plating and backfilling the incomplete work. -rc- /7 I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA NOTEI Drums reQUIred for thIs locotlon.sPoced ot 50 FT. Intervols. If the troveled way wIdth Is reduced to less than 10 feet by the use of drums. vertical panels sholl be used In lieu of drums. LocatIon of drums when drop-off exceeds ~ Inches. ----------\ ----~------_.!\ ~ -t NEW CONSTRUCTION + TRAVEL LANE ~ DROP-OFF GREATER THAN 4 INCHES DET AIL 150-8 Drums spoced ot 50 feet Intervols. Locotlon of drums when drop-off Is 2+ Inches to ~ Inches. _l_::~------\t -----------\ ~ -t NEW CONSTRUCTION + TRAVEL LANE ~ DROP-OFF OF 2 + INCHES TO 4 INCHES DET AIL 150-C -rc-/tf I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA Drums spaced at 100 feet Interyols. LocatIon of drums when drop-off Is Z Inches or less. ~f~-=~______~. -----------\ 4: t NEW CONSTRUCTION + TRAVEL LANE ~ DROP-OFF OF 2 INCHES OR LESS DET AIL 150-0 LocatIon of drums ImmedIately after completIon of healed sectIon. spaced at 50 ft.lnterYols. Compacted or oded oooreoote,subbose materIal or dlrt. TOP OF DRUM TO BE LEVEL 2 ft. +/- ----------~. -----------\ NO STEEPER THAN 4:1 ~ II( t NEW CONSTRUCTION + TRAVEL LANE ~ HEALED SECTION DEl AIL 150-E TC-If I I -I I I I I I I I I I I I I I I- I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA 150.07 FLAGGING AND PILOT CARS: A. Flaggers shall be provided as required to handle traffic, as specified in the Plans or Special Provisions, and as required by the Engineer. B. lul flaggers shall meet the requirements of the MUTCD and must have received training and a certificate upon completion of the training from a Department approved training program. Failure to provid-e certified flaggers as required above shall be reason for the Engineer suspending work involving the flagger{s) until the Contractor provides the certified flagger{s). C. Flaggers shall wear high-visibility clothing in compliance with the MUTCD and shall use a Stop/Slow paddle meeting the requirements of the MUTCD for controlling traffic. The Stop/Slow paddles shall have a shaft lengtb of seven (7) feet minimum. In addition to the Stop/Slow paddle, a flagger may use a 24 inches square red/orange flag as an additional device to attract attention. For night work, the vest shall have reflectorized stripes on front and back. D. Pilot vehicles shall be provided if specified in the Plans or Specifications and meet the requirements of the MUTCD. E. Signs for flagger traffic control shall be placed in advance of the flagging operation in accordance with the MUTeD. In addition to the signs required by the MUTCD, signs at regular intervals, warning of the presence of the flagger shall be placed beyond the point where traffic can reasonably be expected to stop under the most severe conditions for that day's work. 150.08 ENFORCEMENT: The safe passage of pedestrians and traffic through and around the temporary traffic control zone, while minimizing confusion and disruption to traffic flow, shall have priority over all other Contractor activities. Continued failure of the Contractor to comply with the requirements of Section 150 (TRAFFIC CONTROL) will result in non-refundable deductions of monies from the Contract as shown in this Subsection for non-performance of Work. Failure of the Contractor to comply with this Specification shall be reason for the Engineer suspending all other work on the Project, except erosion control and traffic control, taking corrective action as specified in Subsection 105.15, and/or withholding payment of monies due the Contractor for any work on the Project until traffic control deficiencies are corrected. These other actions shall be in addition to the deductions for non-performance of traffic control. -rc-co I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA SCHEDULE OF DEDUCTIONS FOR EACH CALENDAR DAY OF DEFICIENCIES OF TRAFFIC CONTROL INSTALLATION AND/OR MAINTENANCE ORIGINAL TOTAL CONTRACT AMOUNT From More Than To and Includine- Dailv Chare-e $0 $100,000 $100 100.000 1.000,000 250 1,000,000 5,000,000 500 5,000,000 20,000,000 750 20,000,000 40,000,000 1,000 40,000,000 - 1,500 150.09 MEASUREMENT: A TRAFFIC CONTROL: When listed as a pay item in the Proposal, payment will be made at the Lump Sum price bid, which will include all traffic control not paid for separately, and will be paid as follows: When the first Construction Report is submitted, a payment of 25 (twenty-five) percent of the Lump Sum price will be made. For each progress payment thereafter, the total of the Project percent complete shown on the last pay statement plus 25 (twenty-five) percent will be paid (less previous payments), not to exceed one hundred (100) percent and subject to normal retainage. When no payment item for Traffic Control-Lump Sum is shown in the Proposal, all of the requirements of Section 150 and the Traffic Control Plan shall be in full force and effect. The cost of complying with these requirements will not be paid for separately, but shall be included in the overall bid submittal. B. SIGNS: When shown as a pay item in the contract, interim special guide signs will be paid for as listed below. All other regulatory, warning, and guide signs, as required by the Contract, will be paid for under Traffic Control Lump Sum or included in the overall bid submitted. 1. Interim ground mounted or interim overhead special guide signs will be measured for payment by the square foot. This payment shall be full compensation for furnishing the signs, including supports as required, erecting, illuminating overhead signs, maintaining, removing, re-erecting, and final removal from the Project. Payment will be made only one time regardless of the number of moves required. 2. Remove and reset existing special guide signs, ground mount or overhead, complete, in place, will be measured for payment per each. Payment will be made only one time regardless of the number of moves required. 3. Modify special guide signs, ground mount or overhead, will be measured for payment by the square foot. The area measured shall include only that portion of the sign modified. Payment shall include materials, removal from posts or supports when necessary, and remounting as required. -rc-c/ I I I I I I I I I I I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA C. PRECAST MEDIAN BARRIER: Precast Median Barrier will be measured as specified in Section 622. D. CHANGEABLE MESSAGE SIGN, PORTABLE: Changeable Message Sign, Portable will be measured as specified in Section 632. E. TEMPORARY GUARDRAIL ANCHORAGE, Type 11: Temporary Guardrail Anchorage - Type 11 will be measur.ed by each assembly, complete in place and accepted according to the details shown in the plans, which shall also include the additional guardrail and appurtenances necessary for transition and connection to Temporary Concrete Barrier. Payment shall include all necessary materials, equipment, labor, site preparation, maintenance and removal. F. TRAFFIC SIGNAL INSTALLATION - TEMPORARY: Traffic Signal Installation - Temporary will be measured as specified in Section 647. G. FLASHING BEACON ASSEMBLY: Flashing Beacon Assemblies will be measured as specified in Section 647. H. TEMPORARY, SAND LOADED ATI'ENUATOR MODULES: Each Sand Loaded Attenuator Module of the type specified includes all material components, hardware, incidentals, labor, site preparation and maintenance. Each module will be measured for payment by the drum only once regardless of the number oflocations installed. Modules to replace those damaged or destroyed by traffic impact will also be measured by the unit for payment. Upon completion of the project, the modules shall be removed and retained by the Contractor. 1. PORTABLE IMPACT ATTENUATORS: Each Portable Impact Attenuator will be measured by the unit which shall include all material components, hardware, incidentals, labor, site preparation, and maintenance, including spare parts recommended by the manufacture for repairing minor accident damage. Each unit will be measured only once regardless of the number oflocations installed, moves required, or number of repairs necessary because of traffic damage. Upon completion of the project, the units shall be removed and retained by the Contractor. J. PAVEMENT MARKINGS: Pavement markings will be measured as specified in Section 150. 150.10 PAYMENT: When shown in the Schedule ofItems in the Proposal, the following items will be paid for separately. Item No. 150. Traffic Control. . .. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . Lump Sum Item No. 150. Traffic Control, Solid Traffic Stripe _ Inch, (Color) ............. per Linear Mile Item No. 150. Traffic Control, Skip Traffic Stripe_ Inch, (Color) .............. per Linear Mile Item No. 150. Traffic Control, Solid Traffic Stripe, Thermoplastic Inch, (Color) ............. . . . . . . . . . . . . . . per Linear Mile Item No. 150. Traffic Control, Skip Traffic Stripe, Thermoplastic Inch, (Color) .......... . . . . . . . . . . . . . . . . . per Linear Mile Item No. 150. Traffic Control, Pavement Arrow with Raised Reflectors .... . . . . . . . . . . . .. per Each Item No. 150. Traffic Control, Raised Pavement Markers - All Types. . . . . . . . . . . . . . . . . .. per Each Item No. 150. Interim Ground Mounted Special Guide Signs. . . . . . . . . . . . . . . . . . .. per Square Foot Item No. 150. Interim Overhead Special Guide Signs. . . . . . . . . . . . . . . . . . . . . . . . .. per Square Foot 7&ZZ I I Item No. 150. I Item No. 150. Item No. 150. I Item No. 150. I Item No. 150. Item No. 150. I Item No. 150. Item No. 150. I Item No. 622. I Item No. 632. Item No. 641 I Item No. 647. Item No. 647. I Item No. 647. I I I I I I I I I DEPARTMENT OF TRANSPORTATION STATE OF GEORGIA Remove & Reset Existing Special Guide Signs, Ground MOWlt, Complete in Place. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. per Each Remove & Reset, Existing Special Guide Signs, Overhead,Complete in Place ..................................... Per Each Traffic Control, Temporary Sand Loaded Attenuator Modules ............ per Each Traffic Control, Portable Impact Attenuator . . . . . . . . . . . . . . . . . . . . . . . . . . .. Per Each Traffic Control, Pavement Markers, Words and Symbols .. . . . . . . . " per Square Foot Traffic Control, Pavement Arrow (Painted) With Raised Reflectors ........ per Each Modify Special Guide Sign, Ground Mount. . . . . . . . . . . . . . . . . . . . . .. per Square Foot Modify Special Guide Sign, Overhead ....................... . . .. per Square Foot Precast Concrete Median Barrier. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . per Linear Foot Changeable Message Sign, Portable .................................. per Each Temporary Guardrail Anchorage, Type 11 ............................. per Each Traffic Signal Installation, Temp ........ . . . . . . . . . . . . . . . . . . . . . . . . . . . , Lump Sum Flashing Beacon Assembly, Structure MOWlted . . . . . . . . . . . . . . . . . . . . . . . .. per Each Flashing Beacon Assembly, Cable Supported. . : . . . . . . . . . . . . . . . . . . . . . . .. per Each -rC-Z3 I I I I I I I I I I I I I I I I I I I ~ This notice of authorization must be ~ conspicuously displayed at the site of work. United States Army Corps of Engineers 19 ge A 't t clean debris from stream, relocate a stream. perm' 0 at Crano Croek,tho upper reaches has been issued to Richmond County on Dec 18 19 96 Address of Permittee 1815 Marvin Griffin Rd Augusta, GA- 30906 Permit Number" 1960009940 I ENG FORM 4336. Jul 81 (ER 1145-2-303) EDITION OF JUl 70 MAY BE USED Comm for Gr nt M. Smith Colonel, U.S. Army (Proponent: DAEN. CWO) c::..o;' -\ I I I I I I I I I I I I I I I I I I I DEPARTMENT OF THE ARMY PERMIT Permittee: Richmond County Permit Number: 960009940 ISSUING OFFICE: Savannah District U.S. Army Corps of Engineers Post Office Box 889 Savannah, GA 31402-0889 NOTE: The term II you II and its derivatives, as used in this permit, means the permittee or any future transferee. The term "this office" refers to the appropriate district or division office of the U.S. Army Corps of Engineers having jurisdiction over the permitted activity or the appropriate official of that office acting under the authority of the commanding officer. You are authorized to perform work in accordance with the terms and conditions specified below. PROJECT DESCRIPTION: To fill 2.7 acres of wetlands in conjunction with a project to clean debris and other obstructions from a 9,300 foot long section of Crane Creek; relocate a 600 foot section of the creek near Whitestone and Sugar Mill Courts; and construct a regional storm water detention facility near the upper end of the drainage basin on the upper part of Crane Creek to improve conditions where flooding occurs along the creek. The debris removal from the 9,300 foot section of the creek will involve accessing the channel from adjacent highground, placing the removed debris in trucks, and hauling the debris to a highground disposal site or landfill. The 600 foot channel relocation will involve the excavation of a 600 foot long channel through highground which would have a top width of 38 feet and a bottom width of 18 feet. The excavated material will be placed in the old channel bed result- ing in the filling of 1.4 acres of waters of the United States. Waters of the U.S. will be created in the new streambed. Excess material will be removed to highground. The proposed detention pond will encompass 14 acres of land of which 10 acres is wetlands. A 700 feet long X 18 feet high X 45 to 120 feet wide dam will be constructed impacting 1.3 acres of wetlands. The impacts to remaining wetlands will be minimal, as the drawdown from the dam will be rapid (less than 24 hours in a 100 year storm event). During normal conditions, the proposed structure will allow the creek to flow uninhibited. Above normal water elevations will occur only during large storm events. Peak water elevations for various storm events will be as follows: c::.. 0 E: - ~ I I I I I I I I I I I I I I I I I I I -2~ STORM WATER ELEVATION WETLAND ACREAGE FLOODED a. 2 year 341.4 3.46 b. 5 year 343.7 4.16 c. 10 year 345.1 5.19 d. 25 year 346.5 6.02 e. 50 year 347.2 6.48 f. 100 year 347.3 6.65 The dam is designed to hold water at a peak surface elevation for approximately 60 minutes before drawdown begins. The reduc- tion in flow due to the dam during these large storm events will help decrease flooding and erosion downstream. PROJECT LOCATION: The site is located on the portion of Crane Creek north of Interstate 20 which flows under Interstate 520. The detention pond site is north of Interstate 20 and west of Interstate 520 in Richmond County, Georgia. PERMIT CONDITIONS: General Conditions: 1. The time limit for completing the work authorized ends on November 26, 2001. If you find that you need more time to complete the authorized activity, submit your request for a time extension to this office for consideration at least one month before the above date is reached. 2. You must maintain the activity authorized by this permit in good condition and in conformance with the terms and conditions of this permit. You are not relieved of this requirement if you abandon the permitted activity, although you may make a good faith transfer to a third party in compliance with General Condition 4 below. Should you wish to cease to maintain the authorized activity or should you desire to abandon it without a good faith transfer, you must obtain a modification of this permit from this office, which may require restoration of the area. 3. If you discover any previously unknown historic or archeological remains while accomplishing the activity authorized by this permit, you must immediately notify this office of what you have found. We will initiate the federal and state coordination required to determine if the remains warrant a recovery effort or if the site is eligible for listing in the National Register of Historic Places. ~cE-3 I I I I I I I I I I I I I I I I I I I -3- 4. If you sell the property associated with this permit, you must obtain the signature of the new owner in the space provided and forward a copy of the permit to this office to validate the transfer of this authorization. 5. If a conditioned water quality certification has been issued for your project, you must comply with conditions specified in the certification as special conditions to this permit. For your convenience, a copy of the certification is attached if it contains such conditions. 6. You must allow representatives from this office to inspect the authorized activity at any time deemed necessary to ensure that it is being or has been accomplished in accordance with the terms and conditions of your permit. Special Conditions: 1. All work performed during construction will be done in a manner so as not to violate applicable water quality standards. 2. No oils, grease, materials or other pollutants will be discharged from the construction activities which reach public waters. 3. All dredged or borrowed material used as fill on this project will be from clean, uncontaminated sources and free from cultural resources. 4. All work will be performed in accordance with the following attached plans and drawings which are incorporated in and made part of the permit: (a). Location Plan, Sheet 2 of 7. (b). General Project Map, Sheet 3 of 7. (c). Channel Relocation Plan, Sheet 4 of 7. (d). Sheet 5 of 7, 404 Permit Plan [earthen dam]. 5. All work conducted under this permit shall be located, outlined, designed, constructed and operated in accordance with the minimal requirements as contained in the Georgia Erosion and Sedimentation Control Act of 1975, as amended. Utilization of plans and specifications as contained in "Manual for Erosion and Sediment Control, Third Edition, 1992," publish~d by the Georgia Soil and Water Conservation Commission or their equivalent will C-o~-~ I I I I I I I I I I I I I I I I I I I -4 - aid in achieving compliance with the aforementioned minimal requirements. 6. The permittee shall insure that this project complies with 'all applicable rules, requirements and/or regulations of the Federal Emergency Management Agency with regard to construction of roads in designated flood plains. 7. A complete copy of this permit, including its drawings, special conditions and any amendments shall be maintained at the work site whenever work is being performed. The permittee shall assure that all contractors, subcontractors and other personnel performing the permitted work are fully aware of the permit's terms and conditions. FURTHER INFORMATION: 1. Congressional Authorities: You have been authorized to undertake the activity described above pursuant to: 403 ) ( ) Section 10 of the River and Harbor Act of 1899 (33 U.S.C. (X) Section 404 of the Clean Water Act (33 U.S.C. 1344). ( ) Section 103 of the Marine Protection, Research and Sanctuaries Act of 1972 (33 U.S.C. 1413). 2. Limits of this authorization. a. This permit does not obviate the need to obtain other federal, state, or local authorizations required by law. b. This permit does not grant any property rights or exclusive privileges. c. This permit does not authorize any injury to the property or rights of others. d. This permit does not authorize interference with any existing or proposed Federal projects. 3. Limits of Federal Liability. In issuing this permit, the Federal Government does not assume any liability for the following: a. Damages to the permitted project or uses thereof as a result of other permitted or unpermitted activities or from natural causes. ~ <:) a -5 I I I I I I I I I I I I I I I I I I I -5- b. Damages to the permitted project or uses thereof as a result of current or future activities undertaken by or on behalf of the United States in the public interest. c. Damages to persons, property, or to other permitted or unpermitted activities or structures caused by the activity authorized by this permit. d. Design or construction deficiencies associated with the permitted work. e. Damage claims associated with any future modification, suspension, or revocation of this permit. 4. Reliance on Applicant's Data. The determination of this office that issuance of this permit is not contrary to the public interest was made in reliance on the information you provided. 5. Reevaluation of Permit Decision. This office may reevaluate its decision on this permit at any time the circumstances warrant. Circumstances that could require reevaluation include, but are not limited to, the following: a. You fail to comply with the terms and conditions of this permit. b. The information provided by you in support of your permit application proves to have been false, incomplete, or inaccurate (see 4 above). c. Significant new information surfaces which this office did not consider in reaching the original public interest decision. Such a reevaluation may result in a determination that it is appropriate to use the suspension, modification, and revocation procedures contained in 33 CFR 325.7 or enforcement procedures such as those contained in 33 CFR 326.4 and 326.5. The referenced enforcement procedures provide for the issuance of an administrative order requiring you to comply with the terms and conditions of your permit and for the initiation of legal action where appropriate. You will be required to pay for any corrective measures ordered by this office, and if you fail to comply with such directive, this office may in certain situations (such as those specified in 33 CFR 209.170) accomplish the corrective measures by contract or otherwise and bill you for the cost. c.., 0 6 - '" I I I I I I I I I I I I I I I I I I I -6- 6. Extensions. General Condition 1 establishes a time limit for the completion of the activity authorized by this permit. Unless there are circumstances requiring either a prompt completion of the authorized activity or a reevaluation of the public interest decision, the U.S. Army Corps of Engineers will normally give favorable consideration to a request for an extension of this time limit. Your signature below, as permittee, indicates that you accept and agree to comply with the terms and conditions of this permit. ~~}}^'-- ( ERMITTEE) i 2.. / JJ tq & (D~ E) This permit becomes effective when the federal official, designated to act for the Secretary of the Army, has signed below. ~h/!~ ~ Issued for and i behalf of: Grant M. Smith Colonel, U.S. Army District Engineer /:< /;r //1f/ / <DATE) When the structures or work authorized by this permit are still in existence at the time the property is transferred, the terms and conditions of this permit will continue to be binding on the new owner(s) of the property. To validate the transfer of this permit and the associated liabilities with compliance with its terms and conditions, have the transferee sign and date below. (TRANSFEREE) ( DATE) ~CE.-" DEPARTMENT OF THE ARMY SAVANNAH DISTRICT. CORPS OF ENGINEERS P.O. BOX B89 SAVANNAH. GEORGIA 31402 REPl. Y TO ATTENTION OF: Regulatory Branch CERTIFICATION OF COMPLIANCE WITH DEPARTMENT OF THE ARMY PERMIT PERMIT NUMBER: 960009940 PERMITTEE: Richmond County Within 30 days of completion of the activity authorized by this permit, sign this certification and return it to the following address: Commander U.S. Army Engineer District, Savannah ATTN: Regulatory Branch P.O. Box 889 Savannah, Georgia 31402-0889 Please note that your permitted activity is subject to compliance inspection by an Army Corps of Engineers' representative. If you fail to comply with the permit conditions it may be subject to suspension, modification, or revocation. I hereby certify that the work authorized by the above referenced permit has been completed in accordance with the terms and conditions of the said permit. Signature of Permittee/Date c:, ~ ~ ...<6 I I I I I I I I I I I I I I I I I I I; LOCATION PLAN J~ . ,-fl-4_ ~J- , ,..~ '- 5IlE- DETENTION POND ~ , j t \ r / AUGUSTA SCALE : 1 - = 4000' t '- } l , t \ 452 nus Slll[[1' - P.o. DIlAJEll Z54I - AlJQJST~ ~ JQIlQ3 TEl... C7OS) 722-15ll11 fJQItEERS - FtMifRS- - StIM:)OItS AUGUSTA-RlOfWCH) CCUfIY coe.a.lSSOH COUNCJ.. 1815 MAlMN GRIFFIt ROAD AUQJSTA. GEORGIA 30906 m... (706) 796-5040 404 PERMIT LOCA liON PLAN SCALE: AS" SHOVIM DATE: JJ~ 20;-.1996 J:lB , 92.:..383 SHEET 2 r:F 7 . <::"'0 G -~ 1 I I I I I I 1 I I I I I I 1 I I I I REGIONAL DE:7ENnON POND SITE: SUJJJJARY OF tlrE7LANDS /J.IPACT EXCA VA TlON IN FlU. IN tfETUNOS tIE'TUtNDS 1.4 A~ 2.J.JA~ <D awiNEI.. REJ..OCA TlON @ DrnNT10N POND 1..1 ACRES N/A AUGUSTA-RlOIKH) caMY COI6'ISSK>>f COUHa. 1815 UNMN GRIFFIt ROAD AUWSTA, GEORCIA 30908 m:... (706) 796-5040 404- PEIVT GENERAl PRo..ECT YAP SCAL[;. NONE DAlE: .uNE-2o. 1996 .xs , 92-383 SJfiT 3 ~. 7 4a2 EWS STREET - P.o. DRAB Z546 - AUQlSTA. CiElIlliIA JOSIOJ TEl.. C7051 722-151l8 EJQtEERS - Pf.INE1lS - SUM')OItS . .' ~(:)~ - \0 I I I I I I I I I I I 1 I I I I I 1 1 SEA ~ RfO~ INe. .__IPLANDS----- ...... ... REBAII 'I. OPEN TCit'", FCUIO / IflOj FOUND ~" f6- IlEflAR ...... rOUNO "' \ , WARNER L ,k. MARY K. 8ROa( ~----- JAMES IJ. JOHNSON 452 WJS STIl[[J - P.o. DRAIIEJI 2:5otI - H.WSTA. GEORGIA J09Q3 tEL (70517%2-1_ EJIQIEERS - PIIMiERS - ~. AUGUSTA-Rlat.tCH> CClMY C()AIlSSJOH caMeL 1815 WAIMH GRIFf'W ROAD AUGUSTA. GEORGIA 30906 TEL (706) 796-5040 404 PERMIT QiAHNa RElCCA 110H PlAN SCAlE: 1- = SO' DA 1t: JJNE 20; 1996 JOB , 92~383 SHEET 4 r1!' 7 CO~ -\\ 1 I I I I 1 I I I I I 1 I I I I 1 I I / ~I ~, , , \ I / / / ''7\ :;/ \ \ \ \ \ \ \ \ \ I 1 \ I I I I ! 1 I / / r"- /- / '- , ,.--"',~NIGHT I ;~~llES. It:iC. ~Ol ~:..~~S '- " :)..> {( ,,/ " \1/// \, /r--.... \ Ilfll{ \ , \ " ) '111\ \ \' - ,I \ 1\'''-- \ \ ...---............ --~ \, -.......... ,---- - " ....__ ---7 '- -... '- , , '-'- .- ... ,. ... " .' ... ... ... .. I I , " , I I I I I I I 1 , , / , "/ /' ,- I I I \ / ( .., ,,1idfS p./" fA'It dJ I~~ '. APPRO)(\M~ jPE~iI/O: oF'fUiURE O.O.T. R ~ AUGUSTA-RlatKH) calm' COUUISSlClt cwo.. 1815 WAIMH GRIFFIt ROAD AUQJSTA, <BlRQA DOS m:. C7(6) 796-5040 404. PERt.IT PlAN ~ 1. = 27rt OA 1E: JJIE. 20. 1996 .a!" 92-383 StET 5 ~'7 ~ fllJS SlRaT - P.G. DWO 2541 - AIJlI'US't\ GD:IlIiIA JClllQ3 TEL C7D8J 722-15811 EJQEERS - PLWiBlS - SUIlE)QIlS .J. c.... C) Eo - \ ~ I I I I I I I I I I I I I I I I- I I I I~ i'~~ ~~I ~~i~ i1i~I~ ~Ie~ ~ - - ~- ~D --.t :JNRN:n:J ~ SLJ/fn f AUGUSTA-RI()II(H) aum ~ISSON COOtO.. 181S WAfMH GRIFFW ROAD AUQJSTA, ~ 30908 lEt.. (706) 796-5040 ~ tl1JS S11l[[T - P. Q. I:MlAIO ~ - AI.lllUSTA. GmlliIA JOllCa m... (7DI) 722-l58I DiGIIEERS - PlJIItERS - StIIllE)OI5'" ATIAC-H.*5 z o I- < U o ~ W 0:: ~ W Z Z < :I: Uui 1'-: z z o - I- U W Ul ~ < U (L >- I- 404- PERYIT T'I1'ICAL SEcn~ SCALE:.. NCH: OA 1[; JJNE 20. 1996 .aliI 92-383 SHErr 6 rE' 7 ~o~-\'3