HomeMy WebLinkAboutConstruct 2 New Plants for Treatment of Ground Water
Augusta Richmond GA
DOCUMENT NAME. C t\ '" S r <2 UC T ~ rJ 15.,u f>) A ('1,,2> -1'0 IZ -hE It TM 6 III r <> 1
':> tZo t),J D W ~ '\ ~((:...
DOCUMENT TYPE: A c;e~/E.tn e.r1 J
YEAR: I q 0 '1
BOX NUMBER: "J
FILE NUMBER: 14 -:try ;;:t
NUMBER OF PAGES:
:J-)
t'
, 2 J;;>{ ~ N-r~
This document has important legal consequences: consultation with an attorney is encouraged with respect to its use.
completion or modification. This document should be adapted to the particular circumstances of the contemolated
project and the applicable laws of the jurisdiction in which the professional services tor the Project are' to be
performed.
STANDARD FORM OF AGREEMENT
BETWEEN OWNER AND ENGINEER
FOR
PROFESSIONAL SERVICES
Prepared by
ENGINEERS JOINT CONTRAer DOCUMENTS COMMlTIEE
and
Issued and Published Jointly By
~~
ACEC
PROFESSIONAL ENGINEERS ~RIVATE PRACTICE
a pracrice division of (he
NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS
AMERICAN CONSULTING ENGINEERS COUNCIL
AMERICAN SOCIETY OF CIVIL ENGINEERS
This Agreement has been prepared for use with the Standard General Conditions of the Construction Contract (No.
1910-8 (1990 Edition) of the Engineers Joint Contract Documents Committee. Their provisions are interrelated and
a change in one may necessitate a change in the other.
EJCDC No. 1910-1 (1992 Edition)
Reprinted 7/94
i .
TABLE OF CONTENTS
Page No.
IDENTIFICATION OF THE PARTIES. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 1
DESCRIPTION OF THE PROJECT. . . . . . . . . , . , . . , . . . . . . . . , . . . , . . . . . . . . . . . . . . . . . . . .
SECTION I-GENERAL. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2
1.1 Standard of Care ,......................................,................. 2
1.2 Coordination with Other Documents ......... , . . , . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2
1.3 Definitions. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . , . . . . . . . . . . . . . . . . . . . . . , . . . . . . 2
SECTION 2-BASIC SERVICES OF ENGINEER. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3
2.1 Study and Report Phase . . . , . . . . . . . . . . . . . . . . .. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3
2.2 Preliminary Design Phase .....,.......,.................. . . . . . . . . . . . . . . . . . . . 3
2.3 Final Design Phase . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 4
2.4 Bidding or Negotiating Phase. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .'. 4
2.5 Construction Phase . . . . , . . . . . . . . . : . , . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5
2.6 Operational Phase ........................................................ 7
SECTION 3-ADDmONAL SERVICES OF ENGINEER .................................. 7
3.1 Additional Services Requiring Authorization in Advance . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 7
3.2 Required Additional Services. . . . . . . . . . . . . . . . . . . , . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 9
SEcrION 4-0WNER'S RESPONSIBILITIES . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 9
SEcrION 5- TIMES FOR RENDERING SERVICES. . . . . . . , . . . . . . . . . . . . . . . . . . . . . , . . . . . . . . 11
SECTION 6-PAYNIENTS TO ENGINEER FOR SERVICES AND
RElt\1BURSABLE EXPENSES ........................................... 12
6.1 Methods of Payment for Services and Expenses of Engineer. . . . . . . . . . . . . . . . . . . . . . . . . . . 12
6.2 Other Provisions Concerning Payments .......................................... 12
SECTION ,7-0PINIONS OF COST .................................................. 13
7.1 Opinions of Probable Construction Cost . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 13
7.2 Designing to Construction Cost Limit. . . . . , . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 13
7.3 Opinions of Total Project Costs . . . . . . . . . . . . . . . . . . , . . . . . . . . . . . . . , . . . . . . . . . . . . . . 13
SECTION 8-GENERAL CONSIDERATIONS. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 13
8.1 Tennination. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .~. . . . . . . . . . . 13
8.2 Reuse of Documents. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . t3
8.3 Insurance . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 1-'1-
8.4 Controlling Law. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 14
8.5 Successors and Assigns . . . . . . . . . . . . . . . , . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 14
8.6 Dispute Resolution. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 14
8.7 Allocation of Risks-Indemnification . . . . . , . . . . . . . . . . . . . . , . . . . . . . . . . . . . . . . . . . . . . 15
8.8 Notices. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 15
8.9 Survival. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . [5
8.10 Severability...................................,...., . . . . . . . . . . . . . . . . . . . . . 15
SEcrION 9-EXHIBITS AND SPECIAL PROVISIONS . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . [5
\C
..;.'
This document has important legal consequences; consultation with an attorney is encouraged with
respect to its use, completion or modification. This document should be adapted to the particular
circumstances of the contemplated Project and the applicable laws of the jurisdiction in which the
professional services for the Project are to be performed.
STAl"lDARD FORM OF AGREEMENT
BETWEEN
OWNER AND ENGINEER
FOR
PROFESSIONAL SERVICES
TIllS IS AN AGREEMENT made as of
Ma.y 4
,19 99
between
CITY OF AUGUSTA
("OWNER") and
7.TMMFRMAN FVAN~ ANn T,Fopor.n. TNr'
("ENGINEER").
OWNER intends to -LCOnstrllct 2 new plants for treatment of qround water in the
Southern areas of Auqusta.
(the "Project").
OWNER and ENGINEER in consideration of their mutual covenants herein agree in respect of the c:=-
performance or furnishing of professional engineering services by ENGINEER with respect to the Project and
the payment for those services by OWNER as set forth below. Execution of this Agreement by ENGINEER
and OWNER constitutes OWNER's written authorization to ENGINEER to proceed on the date first above
written with the first phase of the Basic Services described in Section 2 below and as further set forth in Exhibit
A. "Further Description of Basic Engineering Services and Related Matters" ("Exhibit A") and in the other
exhibits listed in Section 9 below. This Agreement will become effective on the date first above written.
Page 1 of 16 pages
.r,
~c~
~:::::::::;
~ da:t(u()
.n<u /-7~~
/ueA.Iu ~cO
.Ltp< ZC-0.
CG~
~.~
..!J../..~ Yf?
- i'
SEerION l-GENERAL
1.1. Standard of Care.
ENGINEER shall perform for or furnish to OWNER
professional engineering and related services in all phases
of the Project to which this Agreement applies as herein-
after provided. ENGINEER shall serve as OWNER's
prime design professional and engineering representative
for the Project providing professional engineering consul-
tation and advice with respect thereto. ENG INEER may
employ such ENGINEER's Consultants as ENGINEER
deems necessary to assist in the performance or furnishing
of professional engineering and related services hereun-
der. ENGINEER shall not be required to employ any
ENGINEER's Consultant unacceptable to ENGINEER.
The standard of care for all professional engineering and
related services performed or furnished by ENGINEER
under this Agreement will be the care and skill ordinarily
used by members of ENGINEER's profession practicing
under similar conditions at the same time and in the same
locality. ENGINEER makes no warranties, express or
implied. under this Agreement or otherwise. in connec-
tion with ENGINEER's services.
1.2. Coordination with Other Documents.
It is the intention of the parties that the Standard General
Conditions will be used as the General Conditions for the
Project and that all amendments thereof and supplements
thereto will be generally consistent therewith. Except as
otherwise defined herein, the terms which have an initial
capital letter in this Agreement and are defined in the
Standard General Conditions will be used in this Agree-
ment as defined in the Standard General Conditions. The
term "defective" will be used in this Agreement as defined
in the Standard General Conditions.
~
1.3. Definitions.
Wherever used in this Agreement the following terms
have the meanings indicated which are applicable to hoth
the singular and plural thereof:
1.3.1. II dditionul Services. Addi tional Services means
the services to he performed for or furnished to OWNER
hy ENGINEER described in Section 3 of this Agree-
ment.
1.3.2. lI;;reement. Agreement means this Standard Form
of Agreement between OWNER and ENGINEER for
Professional Services including those exhibits listed in
Section lJ of this Agreement.
1.3.3. Busic Services. Basic Services means the services
to be performed for or furnished to OWNER by ENGI-
NEER described in Section 2 of this Agreement.
1.3.4. Construction Cost. Construction Cost means the
total cost to OWNER of those portions of the entire
Project designed or specified by ENG INEER. Construc-
tion Cost does not include ENG INEER 's compensation
and expenses. the cost of land. rights-of-way. or compen-
sation for or damages to properties. or OWNER's legal,
accounting, insurance counseling or auditing services. or
interest and financing charges incurred in connection with
the Project or the cost of other services to be provided by
others to OWNER pursuant to Section 4 of this Agree-
ment. Construction Cost is one of the items comprising
Total Project Costs.
1.3.5. Contractor. Contractor means the person or entity
with whom OWNER enters into a written agreement
covering construction work to be performed or furnished
with respect to the Project.
1.3.6. ENGINEER's Consultant. ENGINEER's Con-
sultant means a person or entity having a contract with
ENGINEER to perform or furnish Basic or Additional
Services as ENGINEER's independent professional asso-
ciate or consultant engaged directly on the Project.
1.3.7. Reimbursuble Expenses. Reimbursable Expenses
means the expenses incurred directly in connection with
the performance or furnishing of Basic and Additional
Services for the Project for which OWNER shall pay
ENGINEER as indicated in Exhibit B. "Payments to
Engineer for Services and Reimbursable Expenses" ("Ex-
hibit B").
1.3X Resident Project RepresentUlive. Resident Project
Representative means the authorized representative of
ENGINEER who will be assigned to assist ENGINEER
at the site during the Construction Phase. The Resident
Project Representative will be ENGINEER's agent or
employee and under ENGINEER's supervision. As used
herein. the term Resident Project Representative includes
any assistants of Resident Project Representative agreed
to by OWNER. The duties and responsibilities of the
Resident Project Representative are set forth in Exhibit
C. "Duties. Responsibilities and Limitations of Authority
of Resident Project Representative" ("Exhibit C').
1.3.lJ. Stundurd Generul CO/ldition.\'. Standard General
Conditions means the Standard General Conditions of
the Construction Con tract (No. IlJ 10-1-;) (]lJ<)(} Edition) of
the Engineers Joint Contract Documents Committee.
I.J.IO. Total Project Cost.\'. Total Project Costs means
the sum of the Construction Cost. allowances for contin-
gencies. the total costs of design professional and related
Page 2 of 10 pages
services provided by ENGINEER and (on the basis of
information furnished by OWNER) allowances for such
other items as charges of all other professionals and
consultants. for the cost of land and rights-of-way, for
compensation for or damages to properties. for interest
and financing charges and for other services to be pro-
vided by others to OWNER under paragraphs 4.4. 4.5 and
4.7 through 4.14. inclusive.
SECTION 2-BASIC SERVICES OF ENGINEER
2.1. Study and Report Phase.
Upon this Agreement becoming effective. ENGINEER
shall:
2.1.1. Consult with OWNER to understand OWNER's
requirements for the Project and review available data.
2.1.2. Advise OWNER as to the necessity of OWNER's
providing or obtaining from others data or services of the
types described in paragraph 4.4 which are not pan of
ENGINEER's Basic Services. and assist OWNER in
obtaining such data and services.
2.1.3. Identify and analyze requirements of governmen-
tal authorities having jurisdiction to approve the portions
of the Project designed or specified by ENGINEER with
whom consultation is to be undertaken in connection with
the Project.
2.1.4. Evaluate various alternate solutions available to
OWNER as described in Exhibit A. and. after consulta-
tion with Owner. recommend to OWNER those solutions
which in ENGINEER's judgment best meet OWNER's
requirements for the Project.
2.1.5. Prepare a report (the "Report") which will con-
tain ~ statement of OWNER's requirements for the
Project and. as appropriate. will contain schematic lay-
outs, sketches and conceptual design criteria with appro-
priate exhibits to indicate the considerations involved and
those alternate solutions available to OWNER which
ENGINEER recommends. This Report will be accompa-
nied by ENGINEER's opinion of Total Project Costs for
each solution which is so recommended for the Project.
including the following which will be separately itemized:
opinion of probable Construction Cost. allowances for
contingencies and for the estimated total costs of design
professional and related services provided by ENGI-
NEER and, on the basis of information furnished by
OWNER. allowances for other items and services in-
cluded within the definition of Total Project Costs.
2.1.6. Furnish the Report to and review it with OWNER.
2.1.7. Revise the Report in response to OWNER's
comments. as appropriate. and furnish final copies of the
Report in the number set forth in Exhibit A.
2.1.8. Submit the Report within the stipulated period
indicated in Exhibit A.
2.1.9. ENGINEERs services under the Study and Re-
port Phase will be considered complete at the earlier of
(1) the date when the Report has been accepted by
OWNER or (2) thirty days after the date when such
Report is delivered to OWNER for final acceptance. plus
in each case such additional time as may be considered
reasonable for obtaining approval of governmental au-
thorities having jurisdiction to review the portions of the
Project designed or specified by ENGINEER. if such
approval is to be obtained during the Study and Report
Phase.
The duties and responsibilities of ENGINEER during the
Study and Report Phase as set forth in this paragraph 2.1
are amended and supplemented as indicated in Exhibit A.
2.2. Preliminary Design Phase.
After acceptance by OWNER of the Report. selection by
OWNER of a recommended solution and indication of
any specific modifications or changes in the scope. extent.
character or design req uirements of the Project desired by
OWNER. and upon written authorization from OWNER.
ENGINEER shall:
2.2.1. On the basis of the Report. the recommended
solution selected by OWNER and the specific modifica-
tions or changes in the scope. extent. character or design
requirements of the Project agreed upon by OWNER and
ENGINEER. prepare Preliminary Design documents
consisting of final design criteria. preliminary drawings.
outline specifications and written descriptions of the Project.
2.22. Advise OWNER if additional reports. data or
other information or services of the types described in
paragraph 4.4 are necessary and assist OWNER in ob-
taining such reports. data or other information and ser-
vices.
2.2.3. Based on the information contained in the Pre-
liminary Design documents. submit a revised opinion of
probable Construction Cost and any adjustments to Total
Project Costs known to ENGINEER. which will be
itemized as provided in paragraph 2.15.
2.2.4. Furnish the Preliminary Design documents to and
review them with OWNER.
Page 3 of 16 pages
. I
2.2.5. Submit the Preliminary Design documents and
revised opinion of probable Construction Cost within the
stipulated period indicated in Exhibit A.
2.2.6. ENG INEER's services under the Preliminary
Design Phase will be considered complete at the earlier of
(I) the date when the Preliminary Design documents
have been accepted by OWNER or (2) thirty days after
the date when such Preliminary Design documents are
delivered to OWNER for final acceptance. plus in each
case such additional time as may be considered reason-
able for obtaining approval of governmental authorities
having jurisdiction to approve the Preliminary Design
documentation. if such approval is to be obtained during
the Preliminary Design Phase.
The duties and responsibilities of ENGINEER during the
Preliminary Design Phase as set fonh in this paragraph
2.2 are amended and supplemented as indicated in Ex-
hibit A.
2.3. Final Design Phase.
After acceptance by OWNER of the Preliminary Design
Phase documents and revised opinion of probable Con-
struction Cost and indication of any specific modifications
or changes in the scope, extent. character or design
requirements of the Project desired by OWNER. and
upon written autborization from OWNER. ENGINEER
shall:
2.3.1. On the basis of the accepted Preliminary Design
documents. the modifications or changes in the scope,
extent, character or design requirements of the Project
agreed upon by OWNER and ENGINEER and the
revised opinion of probable Construction Cost. prepare
for incorporation in the Contract Documents final Draw-
ings showing the scope. extent and character of the work
to be performed and furnished by Contractor and Speci-
fications (which will be prepared, where appropriate. in
general conformance with the six1een division format of
the Construction Specifications Institute).
2.3.2. Provide technical criteria. written descriptions and
design data for OWNER's use in filing applications for
permits with or obtaining approvals of such governmental
authorities as have jurisdiction to review or approve the
final design of the Project. and assist OWNER in consul-
tations with appropriate authorities.
2.3.3. Advise OWNER of any adjustments to the opin-
ion of probable Construction Cost and any adjustments to
Total Project Costs known to ENGINEER. itemized as
provided in paragraph 2.1.5. as a result of changes in
scope. extent or character or design requirements of the
Project.
2.3.4. Prepare for review and approval by OWNER. its
legal counsel and other advisors. con tract agreement
forms. general conditions and supplementary conditions.
and (where appropriate) bid forms. invitations to bid and
instructions to bidders (all of which will be generally
consistent in form and substance with the forms and
pertinent guide sheets prepared by the Engineers Joint
Contract Documents Committee), and assist in the prep-
aration of other related documents.
2.3.5. Furnish the above documents. Drawings and
Specifications to and review them with OWNER.
2.3.6. Submit the above documents. Drawings and
Specifications and a revised opinion of probable Con-
struction Cost within the stipulated period indicated in
Exhibit A.
2.3.7. ENGINEER's services under the Final Design
Phase will be considered complete at the earlier of (1) the
date when the submittals have been accepted by OWNER
or (2) thirty days after the date when such submittals are
delivered to OWNER for final acceptance. plus in each
case such additional time as may be considered reason-
able for obtaining approval of governmental authorities
having jurisdiction to approve the portions of the Project
designed or specified by ENGINEER. if such approval is
to be obtained during the Final Design Phase.
The duties and responsibilities of ENGINEER during the
Final Design Phase as set forth in this paragraph 2.3 are
amended and supplemented as indicated in Exhibit A.
2.4. Bidding or Negotiating Phase.
After acceptance by OWNER of the ENGINEER's
Drawings. Specifications and other Final Design Phase
documentation (including the most recent opinion of
probable Construction Cost). and upon written authori-
zation to proceed. ENGINEER shall:
2.4.1. Assist OWNER in advertising for and obtaining
bids or negotiating proposals for the contract for con-
struction. materials. equipment and services: and. where
applicable. maintain a record of prospective bidders to
whom Bidding Documents have been issued. attend
pre-bid conferences. if any. and receive and process
deposits for Bidding Documents.
2.4.2. Issue Addenda as appropriate to clarify. correct
or change the Bidding Documents.
2.4.3. Consult with OWNER as to the acceptability of
subcontractors. suppliers and other persons and entities
proposed by Contractor for those portions of the work as
to which such acceptability is required by the Bidding
Documents.
Page 4 of 16 pages
2.4.4. Attend the bid opening, prepare bid tabulation
sheets and assist OWNER in evaluating bids or proposals
and in assembling and awarding contracts for construc-
tion. materials. equipmem and services.
2.4.5. The Bidding or Negotiating Phase will terminate
and the services to be performed or furnished thereunder
will be considered complete upon commencement of the
Construction Phase or upon cessation of negotiations
with prospective Contractors (except as may otherwise be
required to complete the services called for in paragraph
E7.2.5. if Exhibit E is a part of this Agreemem).
The duties and responsibilities of ENGINEER during the
Bidding or Negotiating Phase as set forth in this para-
graph 2.4 are amended and supplemented as indicated in
Exhibit A.
2.5. Construction Phase.
During the Construction Phase:
2.5.1. General Adminisrration of Constntction Contract.
ENGINEER shall consult with and advise OWNER and
act as OWNER's representative as provided in the Stan-
dard General Conditions. The extent and limitations of
the duties. responsibilities and authority of ENGINEER
as assigned in said Standard General Conditions shall not
be modified. except to the extent provided in Exhibit A
and except as ENGINEER may otherwise agree in
writing. All of OWNER's instructions to Contractor will
be issued through ENGINEER who shall have authority
to act on behalf of OWNER in dealings with Contractor
to the extent provided in th,is Agreement and said Stan-
dard General Conditions except as otherwise provided in
writing.
2.5.2. Visits to Site and Observation of Constntction. In
connection with observations of the work of Contractor
while it is in progress:
2.5.2.1. ENGINEER shall make visits to the site at
intervals appropriate to the various stages of construc-
tion as ENGINEER deems necessary in order to
observe as an experienced and qualified design profes-
sional the progress and quality of the various aspects of
Contractor's work. In addition, ENGINEER shall pro-
vide the services of a Resident Project Representative
at the site to assist ENGINEER and to provide more
continuous observations of such work. The furnishing
of such Resident Project Representative services will
nor extend ENGINEER's responsibilities or authority
beyond the specific limits set forth elsewhere in this
paragraph 2.5. Such visits and observations by El'\lGI-
NEER and the Resident Project Representative are not
imended to be exhaustive or to extend to every aspect
of the work in progress. or to involve detailed inspec-
tions of the work beyond the responsibilities specificallv
assigned to ENGINEER in this Agreement and th~
Contract Documents. but rather are to be limited to
spot checking. selective sampling and similar methods
of general observation of the work based on ENG I-
NEER's exercise of professional judgment as assisted
by the Resident Project Representative. Based on
information obtained during such visits and such obser-
vations. ENGINEER shall endeavor to determine in
general if such work is proceeding in accordance with
the Contract Documents and ENGINEER shall keep
OWNER informed of the progress of the work. The
responsibilities of ENGINEER contained in this para-
graph are expressly subject to the limitations set fonh in
paragraph 2.5.2.2 and other express or general limita-
tions in this Agreement and elsewhere.
2.5.2.2. The purpose of ENGINEER's V1SItS to and
representation by the Resident Project Representative
at the site will be to enable ENGINEER to better carry
oUI the duties and responsibilities assigned to and
undertaken by ENGINEER during the Construction
Phase, and. in addition. by the exercise of ENGI-
NEER's efforts as an experienced and qualified design
professionaL to provide for OWNER a greater degree
of confidence that the completed work of Contractor
will conform in general to the Contract Documents and
that the integrity of the design concept of the completed
Project as a functioning whole as indicated in the
Contract Documents has been implemented and pre-
served by Contractor. On the other hand, ENGINEER
shall not, during such visits or as a result of such
observations of Contractor's work in progress, super-
vise. direct or have control over Contractor's work nor
shall ENGINEER have authority over or responsibility
for the means. methods. techniques. sequences or pro-
cedures of construction selected by Contractor, for
safety precautions and programs incident to the work of
Contractor or for any fail~f Contractor to comply
with laws. rules. regulations. ordinances. codes or or-
ders applicable to Contractor's furnishing and perform-
ing the work. Accordingly, ENGINEER neither guar-
antees the performance of any Contractor nor assumes
responsibility for any Contractor's failure to furnish and
perform its work in accordance with the Contract
Documents.
2.5.3. Defective Work. During such VISitS and on the
basis of such observations. ENGINEER shall have au-
thority to disapprove of or reject Cor;tractor's work while
it is in progress if ENGINEER believes that such work
will not produce a completed Project that conforms
generally to the Contract Docume:nts or that it will
Page 5 of 16 pages
prejudice the integrity of the design concept of the
completed Project as a functioning whole as indicated in
the Contract Documents.
2.5.4. Clarifications and Imerpretarions; Field Orders.
ENGINEER shall issue necessary clarifications and inter-
pretations of the Contract Documents as appropriate to
the orderly completion of the work. Such clarifications
and interpretations will be consistent with the intent of
and reasonably inferable from the Contract Documents.
ENGINEER may issue Field Orders authorizing minor
variations from the requirements of the Contract Docu-
ments.
2.5.5. Change Orders and Work Change Directives. EN-
GINEER shall recommend Change Orders and Work
Change Directives to OWNER as appropriate. and shall
prepare Change Orders and Work Change Directives as
required.
2.5.6. Shop Drawings. ENGINEER shall review and
approve (or take other appropriate action in respect of)
Shop Drawings and Samples and other data which Con-
tractor is required to submit. but only for conformance
with the information given in the Contract Documents
and compatibility with the design concept of the com-
pleted Project as a functioning whole as indicated in the
Contract Documents. Such reviews and approvals or
other action will nor extend to means. methods. tech-
niques. sequences or procedures of construction or to
safety precautions and programs incident thereto.
2.5.7. Subsritwes. ENGINEER shall evaluate and deter-
mine the acceptability of substitute or "or-equal" materi-
als and equipment proposed by Contractor. but subject to
the provisions of paragraph 3.2.2.
2.5.8. Inspections and TesfS. ENGINEER may require
special inspections or tests of the work. and shall receive
and review all certificates of inspections, tests and approv-
als required by laws, rules. regulations, ordinances. codes,
orders or the Contract Documents. ENGINEER's review
of such certificates will be for the purpose of determining
that the results certified indicate compliance with the
Contract Documents and will not constitute an indepen-
dent evaluation that the content or procedures of such
inspections. tests or approvals comply with the require-
ments of the Contract Documents. ENGINEER shall be
entitled to rely on the results of such tests.
2.5.9. DL~agreemenfS between OWNER and Conrraccor.
ENGINEER shall render the initial decisions on all
claims of OWNER and Contractor relating to the accept-
ability of the work or the interpretation of the require-
ments of the Contract Documents pertaining to the
execution and progress of the work. In rendering such
decisions. ENGINEER shall be fair and not show partial-
ity to OWNER or Contractor and shall not be liable in
connection with any decision rendered in good faith in
such capacity.
2.5.10. Applicarions for Paymenr. Based on ENGI-
NEER's on-site observations as an experienced and qual-
ified design professional and on review of Applications
for Payment and the accompanyiD.g data and schedules:
2.5.10.1. ENGINEER shall determine the amounts
that ENGINEER recommends Contractor be paid.
Such recommendations of payment will be in writing
and will constitute ENGINEER's representation to
OWNER. based on such observations and review, that.
to the best of ENGINEER's knowledge. information
and belief. the work has progres:;ed to the point indi-
cated. the quality of such work is generally in accor-
dance with the Contract Documents (subject to an
evaluation of such work as a functioning whole prior to
or upon Substantial Completion. to the results of any
subsequent tests called for in the Contract Documents
and to any other qualifications stated in the recommen-
dation), and the conditions precedent to Contractor's
being entitled to such payment appear to have been
fulfilled in so far as it is ENGINEER's responsibility to
observe the work. In the case of ,unit price work,
ENGINEER's recommendations of payment will in-
clude final determinations of quantities and classifica-
tions of such work (subject to any subsequent adjust-
ments allowed by the Contract Documents). The
responsibilities of ENGINEER contained in paragraph
2.5.10.1 are expressly subject to the limitations set forth
in paragraph 2.5.10.2 and other express or general
limitations in this Agreement and elsewhere.
2.5.10.2. By recommending any payment ENGINEER
shall not thereby be deemed to have represented that
on-site observations made by ENGINEER to check the
quality or quantity of Contractor's work as it is per~
formed and furnished have been exhaustive. extended
to every aspect of the work in progress. or involved
detailed inspections of the work beyond the responsi-
bilities specifically assigned to ENGINEER in this
Agreement and the Contract Documents. Neither EN-
GINEER's review of Contractor's work for the pur-
poses of recommending payments nor ENGINEER's
recommendation of any payment (including final pay-
ment) will impose on ENGINEER responsibility to
supervise. direct or control such work or for the means.
methods. techniques. sequences or procedures of con-
struction or safety precautions or programs incident
thereto. or Contractor's compliance: with laws. rules.
regulations. ordinances. codes or orders applicable to
Contractor's furnishing and performing the work. It will
also not impose responsibility on ENGINEER to make
t
I
Page 6 of 16 pages
any examination to ascertain how or for what purposes
Contractor has used the moneys paid on account of the
Contract Price. or to determine that title to any of the
work. materials or equipment has passed to OWNER
free and clear of any liens. claims. security interests or
encumbrances. or that there may not be other matters
at issue between OWNER and Contractor that might
affect the amount that should be paid.
2.5.11. Contractor's Completion Documents. ENGI-
NEER shall receive. review and transmit to OWNER with
written comments maintenance and operating instructions,
schedules. guarantees. Bonds. certificates or other evi-
dence of insurance required by the Contract Documents,
certificates of inspection, tests and approvals. and marked-
up record documents (including Shop Drawings, Samples
and other data approved as provided under paragraph 2.5.6
and marked-up record Drawings) which are to be assem-
bled by Contractor in accordance with the Contract
Documents to obtain fmal payment. ENGlNEER's review
of such documents will only be to determine generally that
their content complies with the requirements of. and in the
case of certificates of inspections. tests and approvals that
the results certified indicate compliance with. the Contract
Documents.
2.5.12. Substantial Completion. Following notice from
Contractor that Contractor considers the entire work
ready for its intended use. ENGINEER and OWNER.
accompanied by Contractor. shall conduct an inspection
to determine if the work is substantially complete. If after
considering any objections of OW"NER. ENGINEER
considers the work substantially complete. ENGINEER
shall deliver a certificate of Substantial Completion to
OWNER and Contractor.
2.5.13. Final Notice of Acceptability of the Work. ENG I-
NEER shall conduct a final inspection to determine if the
completed work of Contractor is acceptable so that
ENGINEER may recommend. in writing. final payment
to Contractor. Accompanying the recommendation for
final payment. ENGINEER shall also provide a notice in
the form attached hereto as Exhibit 0 (the "Notice of
Acceptability of Work") that the work is acceptable
(subject to the provisions of paragraph 2.5.10.2) to the
best of ENGINEER's knowledge. information and belief
and based on the extent of the services performed and
furnished by ENGINEER under this Agreement.
2.5.14. Limitarion of Responsibilities. ENGINEER shalI
not be responsible for the acts or omissions of any
Contractor. or of any subcontractor. any supplier. or of
any other person or organization performing or furnish-
ing any of the work. ENGINEER shall not be responsible
for Contractor's failure to perform or furnish the work in
accordance with the Contract Documents.
2.5.15. Duration of Consrrl/crion Phase. The Construc-
tion Phase wilI commence with the execution of the
construction contract for the Project or any part thereof
and will terminate upon written recommendation bv
ENGINEER of final payment. l:f the Project involve~
more than one prime contract as indicated in paragraph
5.5. Construction Phase services may be rendered at
different times in respect of separz,te prime contracts.
The duties and responsibilities of ENGINEER during the
Construction Phase as set forth in this paragraph 2.5 are
amended and supplemented as indicated in Exhibit A.
2.6. Operational Phase.
During the Operational Phase. ENGINEER shall. when
requested by OWNER:
2.6.1. Provide assistance in conne:tion with the refining
and adjusting of any equipment or system.
2.6.2. Assist OWNER in training OWNER's staff to
operate and maintain the Project.
2.6.3, Assist OWNER in developing systems and proce-
dures for control of the operation and maintenance of and
record keeping for the Project.
2.6.4. Prepare a set of reproducible record drawings
showing record information which ENGINEER consid-
ers significant based on the Drawings. Shop Drawings.
and other record documents furnished by Contractor to
ENGINEER which were annotated by Contractor to
show all changes made during constlUct!On. ENGINEER
will not be responsible for any errors in or omissions in
the information provided by Contractor that is incorpo-
rated in the record drawings or other record documents.
2.6.5. In company with OWNER. visit the Project to
observe any apparent defects in the completed work.
assist OWNER in consultations and discussions with
Contractor concerning correction of such defects. and
make recommendations as to replacement or correction
of defective work.
2.6.6. Provide miscellaneous services as requested by
OWNER in connection with Project closeout.
2.6.7. The Operational Phase may commenc~ng
the Construction Phase and will temlinate one year after
the date of Substantial Completion.
The duties and responsibilities of ENG INEER during the
Operational Phase as set forth in this paragraph 2.6 are
amended and supplemented as indicated in Exhibit A.
SECTION 3-ADDITIONAL SERVICES OF
ENGINEER
3.1. Additional Services Requiring Authorization in
Advance.
If authorized in writing by OWNER. ENGINEER shall
furnish or obtain from others Additional Services of the
Page 7 of 16 pages
I
1
types listed in paragraphs 3.1.1 through 3.1.19. inclusive.
as amended and supplemented as indicated in Exhibit A.
These services are not included as part of Basic Services
except to the extent otherwise provided in Exhibit A.
These services will be paid for by OWNER as indicated in
Section 6.
3.1.1. Preparation of applications and supporting docu-
ments (in addition to those furnished under Basic Ser-
vices) for private or governmental grants. loans or ad-
vances in connection with the Project: preparation or
review of environmental assessments and impact state-
ments: review and evaluation of the effect on the design
requirements of the Project of any such statements and
documents prepared by others; and assistance in obtain-
ing approvals of authorities having jurisdiction over the
anticipated environmental impact of the Project.
3.1.2. Services to make measured drawings of or to
investigate existing conditions or facilities. or to verify the
accuracy of drawings or other information furnished by
OWNER.
r
3.1.3. Services resulting from evaluation by ENGINEER
during the Study and Report Phase at OWNER's request
of alternative solutions in addition to those specified in
Exhibit A.
3.1.4. Services resulting from significant changes in the
scope. extent or character of the portions of the Project
designed or specified by ENGINEER or its design re-
quirements including, but not limited to, changes in size.
complexity, OWNER's schedule, character of construc-
tion or method of financing; and revising previously
accepted studies. reports. Drawings. Specifications or
Contract Documents when such revisions are required by
changes in laws, rules. regulations. ordinances. codes or
orders enacted subsequent to the preparation of such
studies. reports. Drawings. Specifications. or Contract
D~ents. or are due to any other causes beyond
ENGINEER's control.
3.1.5. Services resulting from facts revealed about con-
ditions:
3.1.5.1. which are different from information about
such conditions that OWNER previously provided to
ENGINEER under paragraph 4.4 and upon which
ENGINEER was entitled to rely; or
3.1.5.2. as to which OWNER had responsibility to
provide information under paragraph 4.4 if such infor-
mation was not previously provided.
3.1.6. Providing renderings or models for OWNER's
use.
3.1.7. Preparing documents for alternate bids requested
by OWNER for Contractor's work which is not executed
or documents for out-of-sequence work.
3.1.8. Undertaking investigations and studies including,
but not limited to. detailed consideration of operations.
maintenance and overhead expenses; the preparation of
feasibility studies, cash flow and economic evaluations,
rate schedules and appraisals: assistance in obtaining
financing for the Project: evaluating processes available
for licensing and assisting OWNER in obtaining process
licensing; detailed quantity surveys of materials. equip-
ment and labor: and audits or inventories required in
connection with construction performed by OWNER.
3.1.9. Furnishing services of ENGJNEER's Consultants
for other than Basic Services: and furnishing data or
services of the types described in paragraph 4.4 when
OWNER employs ENGINEER to provide such data or
services in lieu of furnishing the same under paragraph
4.4.
3.1.10. Services attributable to a variation in the number
of prime contracts from the number :5pecified in Exhibit A
for work designed or specified by ENGINEER.
3.1.11. . Services during out-of-town travel required of
ENGINEER other than visits to the site or OWNER's
office as required by Section 2.
3.1.12. Preparing for. coordinating with. participating in
and responding to structured independent review pro-
cesses. including. but not limited to. Construction Man-
agement. Cost Estimating, Project Peer Review, Value
Engineering and Constructability Review requested by
OWNER: and performing or furnishing services required
to revise studies. reports. Drawings. Specifications or
Contract Documents as a result of nch review processes.
3.1.13. Detennining the acceptabdity of substitute ma-
terials and equipment proposed during the Bidding or
Negotiating Phase when substitution prior to the award of
contracts is allowed by the Bidding Documents.
3.1.14. Assistance in connection with bid protests. rebid-
ding or renegotiating contracts for construction. materials.
equipment or services. except when such assistance is
required to complete services called for in paragraph
E7.2.5. if Exhibit E is a part of this Agreement.
3.1.15. Providing field ~lJrvPYs for ri~~ig;1 pl:lFf'03f:3. en-
gineering surveys and staking to enable Contractor to
proceed with its work, and any type of property surveys or
related engineering services needed for the transfer of
interests in real property; and providing other special field
surveys.
Page 8 of 16 pages
-,
3.1.16. Preparation of operating, maintenance and staff-
ing manuals to supplement Basic Services under para-
graph 2.6.3.
3.1.17. Preparing to serve or serving as a consultant or
witness for OWNER in any litigation. arbitration or other
legal or administrative proceeding involving the Project
(except for assistance in consultations which is included as
part of Basic Services under paragraphs 2.1.3 and 2.3.2).
3.1.18. Providing more extensive services required to
enable ENGINEER to issue notices or certifications
requested by OWNER under paragraph 4.12.
3.1.19. Other additional services performed or furnished
by ENGINEER in connection with the Project, including
servlces which are to be furnished by OWNER under
Section 4, and services not otherwise provided for in this
Agreement.
3.2. Required Additional Services.
When required by the Contract Documents in connection
with the performance or furnishing of ENGINEER's
services during the Construction Phase, ENGINEER
shall perform or furnish, without waiting for specific
authorization from OWNER, Additional Services of the
types listed in paragraphs 3.2.1 through 3.2.6, inclusive.
These services are not included as part of Basic Services
except to the extent provided in Exhibit A. Required
Additional Services will be paid for by OWNER as
indicated in Section 6. ENGINEER shall advise OWNER
in writing promptly after starting any such Additional
Services.
3.2.1. Services in connection with Work Change Direc-
tives and Change Orders to reflect changes requested by
OWNER if, because of the method of compensation
agreed upon by OWNER and ENGINEER. the resulting
change in compensation for Basic Services is not com-
mensurate with the extent of the additional services
rendered. ~
3.2.2. Services in making reVlSlOns to Drawings and
Specifications occasioned by the acceptance of substitute
materials or equipment other than "or-equal" items: and
services after the award of the construction contract in
evaluating and determining the acceptability of a substi-
tution which is inappropriate for the Project or an exces-
sive number of substitutions.
3.2.3. Services resulting from significant delays. changes
or price increases occurring as a direct or indirect result of
materials, equipment or energy shortages.
3.2.4. Additional or extended services during construc-
tion made necessary by (1) work damaged by fire or other
cause during construction. (2) a significant amount of
defective. neglected or delayed work of Contractor. (3)
acceleration of the progress schedule involving services
beyond normal working hours, or (4) default by Contrac-
tor.
3.2.5. Services (other than Basic Services during the
Operational Phase) in connection with any partial utiliza-
tion of any part of the Project by OWNER prior to its
Substantial Completion.
3.2.6. Evaluating an unreasonable claim or an excessive
number of claims submitted by Contractor or others in
connection with the work.
SECTION 4-0WNER'S RESPONSIBILmES
Except as otherwise provided in Exhibit A. OWNER
shall do the following in a timely manner so as not to
delay the services of ENGINEER and shall bear all costs
incident thereto:
4.1. Designate in writing a person to act as OWNER's
representative with respect to the services to be per-
formed or furnished by ENGINEER under this Agree-
ment. Such person will have complete. authority to trans-
mit instructions, receive information. interpret and define
OWNER's policies and decisions with respect to ENGI-
NEER's services for the Project.
4.2. Provide all criteria and full information as to OWN-
ER's requirements for the Project, including design ob-
jectives and constraints. space, capacity and performance
requirements. flexibility and expendability, and any bud-
getary limitations: and furnish copies of all design and
construction standards which OWNER will require to be
included in the Drawings and Specifications.
4.3. Assist ENGINEER by placing at ENGINEER's
disposal all available information pertinent to the Project
including previous reports and any other data relative to
design or construction of the Project.
4.4. Furnish to ENGINEER. as requested by ENGI-
NEER for performance of Basic Services or as required
by the Contract Documents. the following:
4.4.1. data prepared by or services of others. including
without limitation explorations and tests of subsurface
conditions at or contiguous to the site. drawings of
physical conditions in or relating to existing surface or
subsurface structures at or contiguous to the site. or
hydrographic surveys:
Page 9 of 16 pages
4.4.2. the services of an independent testing labora-
tory to perform all inspections. tests and approvals of
samples. materials and equipment prior to and after
installation. or to evaluate the performance of materi-
als. equipment and facilities of OWNER. prior to
specification. and during construction;
4.4.3. appropriate professional interpretations of all of
the foregoing;
4.4.4. environmental assessments. audits, investigations
and impact statements. and other relevant environmen-
tal or cultural studies as to the Project, the site and
adjacent areas;
4.4.5. field surveys for design purposes and property,
boundary. easement, right-of-way, topographic and util-
ity surveys or data, including relevant reference points;
4.4.6. property descriptions;
4.4.7. zoning, deed and other land use restrictions; and
4.4.8. other special data or consultations not covered
in Section 2.
OWNER shall be responsible for, and ENGINEER may
rely upon, the accuracy and completeness of all reports.
data and other information furnished pursuant to this
paragraph. ENGINEER may use such reports, data and
information in performing or furnishing services under
this Agreement.
4.5. Provide, as required by the Contract Documents,
engineering surveys and staking to enable Contractor to
proceed with the layout of the work. and other special
field surveys.
4.6. Arrange for access to and make all provisions for
ENGINEER to enter upon public and private property as
required for ENGINEER to perform services under this
Agreement.
4.7. Examine all alternate solutions. studies, reports,
sketches. Drawings. Specifications, proposals and other
documents presented by ENGINEER (including obtain-
ing advice of an attorney, insurance counselor and other
consultants as O\VNER deems appropriate with respect
to such examination) and render in writing decisions
pertaining thereto.
4.8. Provide approvals and permits from all governmen-
tal authorities having jurisdiction to approve the portions
of the Project designed or specified by ENGINEER and
such approvals and consents from others as may be
necessary for completion of such portions of the Project.
4.9. Provide. as may be required for the Project:
4.9.1. accounting, bond and financial advisory. inde-
pendent cost estimating and insurance counseling ser-
vices;
4.9.2. such legal services as OWNER may require or
ENGINEER may reasonably request with regard to
legal issues pertaining to the Project. including any that
may be raised by Contractor; and
4.9.3. such auditing services as OWNER may require
to ascertain how or for what purpose Contractor has
used the moneys paid on account of the Contract Price.
4.10. Provide such inspection or monitoring services by
an individual or entity other than ENGINEER as OWNeR
may desire to verify:
4.10.1. that Contractor is complying with any law. rule,
regulation, ordinance, code or order applicable to Con-
tractor's performing and furnishing the work; or
4.102. that Contractor is taking all necessary precau-
tions for safety of persons or property and complying
with any special provisions of the Contract Documents
applicable to safety.
ENGINEER does not undertake in this Agreement to
perform the services referred to in 4.10.1 and 4.10.2
above. The identity of any- individual or entity em-
ployed to perform such services and the scope of such
services will be disclosed to ENGINEER.
4.11. Advise ENGINEER of the identity and scope of
services of any independent consultants employed by
OWNER to perform or furnish services in regard to the
Project, including, but not limited to, Construction Man-
agement, Cost Estimating, Project Peer Review, Value
Engineering and Constructability Review. If OWNER
designates a person or entity other than. or in addition to,
c:.:::>ENGINEER to represent OWNER at the site, OWNER
shall define and set forth in an exhibit that is to be
mutually agreed upon and attached to and made a part of
this Agreement before such services begin. the duties.
responsibilities and limitations of authority of such other
party and the relation thereof to the duties, responsibili-
ties and authority of ENGINEER.
4.12. Prior to the commencement of the Construction
Phase. notify ENGINEER of any variations in the lan-
guage of the Notice of Acceptability of Work, or of any
notice or certification other than such Notice that ENGI-
NEER will be requested to provide to OWNER or third
parties in connection with the financing or completion of
the Project. OWNER and ENGINEER shall reach agree-
ment on the terms of any such requested notice or
Page 10 of 16 pages
certification and OWNER shall authorize such Addi-
tional Sc::rvices as are necessary to enable ENGINEER to
provide the notice or certification requested under this
paragraph.
4.13. If more than one prime contract is to be awarded
for work designed or specified by ENGINEER designate
a person or entity to have authority and responsibility for
coordinating the activities among the various prime con-
tractors, and define and set forth the duties, responsibili-
ties and limitations of authority of such person or entity
and the rdation thereof to the duties. responsibilities and
authority of ENGINEER in an exhibit that is to be
mutually agreed upon and attached to and made a part of
this Agreement before such services begin.
4.14. Furnish to ENGINEER data or estimated figures
as to OWNER's anticipated costs for services to be
provided by others for OWNER (such as services pursu-
ant to paragraphs 4.4. 4.5 and 4.7 through 4.14. inclusive)
and other costs of the types referred to in paragraph 2.1.5
so that ENGINEER may make the necessary calculations
to develop and periodically adjust ENGINEER's opinion
of Total Project Costs.
4.15. Attend the pre-bid conference. bid opening, pre-
construction conferences, construction progress and other
job related meetings and Substantial Completion and
final payment inspections.
4~6. Give prompt written notice to ENGINEER when-
ever OWNER observes or otherwise becomes aware of
any development that affects the scope or time of perfor-
mance or furnishing of ENGINEER's services, or any
defect or nonconformance in ENGINEER's services or in
the work of any Contractor.
4.17. Furnish. or direct ENGINEER to provide. Addi-
tional Services as stipulated in paragraph 3.1 of this
Agreement or other services as required.
~
SECTION 5-TIMES FOR RENDERING
SERVICES
5.1. ENGINEER's services and compensation under this
Agreement have been agreed to in anticipation of the
orderly and continuous progress of the Project through
completion of the Construction Phase. Unless specific peri-
ods of time or specific dates for providing services are
specified in this Agreement, ENGINEER's obligation to
render services hereunder will extend for a period which
may reasonably be required for the design, award of con-
struction contracts, construction and initial operation of the
Project including extra work and required extensions thereto.
5.2. If in this Agreement specific periods of time for
rendering services are set forth or specific dates by which
services are to be completed are provided and if such
periods of time or dates are changed through no fault of
ENGINEER. the rates and amounts of compensation
provided for herein shall be subject to equitable adjust-
ment. If OWNER has requested changes in the scope.
extent or character of the Project. the time of perfor-
mance of ENGINEER's services shall be adjusted equi-
tably.
5.3. If OWNER fails to give prompt written authoriza-
tion to proceed with any phase of services after comple-
tion of the immediately preceding phase. or if the Con-
struction Phase has not commenced within the stipulated
period identified in this Agreement (plus such additional
time as may be required to complete the services called
for under paragraph E7.2.5 of Exhibit E is a part of this
Agreement) after completion of the Final Design Phase
. or does not proceed in an orderly and continuous pro-
gression. ENGINEER may, after giving seven days' writ-
ten notice to OWNER. suspend services under this Agree-
ment.
SA. If ENGINEER's services for design or during con-
struction of the Project are delayed or suspended in whole
or in part by OWNER:
504.1. for more than three months through no fault of
ENGINEER. ENGINEER shall be entitled to equita-
ble adjustment of rates and amounts of compensation
provided for elsewhere in this Agreement to reflect.
among other things. reasonable costs incurred by EN-
GINEER in connection with such delay or suspension
and reactivation and the fact that the time for perfor-
mance under this Agreement has been revised: or
504.2. for more than one year through no fault of
ENGINEER. or if ENGINEER for any reason is
required to render Construction Phase services more
than one year after Substantial Completion is achieved.
the rates and amounts of compensation provided for
elsewhere in this Agreement will be subject to equitable
adjustment to reflect. among other things, changes in
the various elements that comprise such rates of com-
pensation.
5.5. In the event that the work designed or specified by
ENGINEER is to be performed or furnished under more
than one prime contract. or if ENG INEER's services are
to be separately sequenced with the work of one or more
prime contractors (such as in the case of fasHracking),
OWNER and ENGINEER shall. prior to commence-
ment of the Final Design Phase. develop a schedule for
performance of ENGINEER's services during the Final
Design. Bidding or Negotiating and Construction Phases
Page 11 of 16 pages
in order to sequence and coordinate properly such ser-
vices as are applicable to the work under such separate
prime contracts. This schedule is to be prepared and
included in Exhibit A whether or not the work under such
contracts is to proceed concurrently.
SECTION 6-PAYMENTS TO ENGINEER FOR
SERVlCES AND REIMBURSABLE EXPENSES
6.1. Methods of Payment for Services and Expenses of
ENGINEER.
6.1.1. For Basic Services. OWNER shall pay ENGI-
NEER for Basic Services performed or furnished under
Section 2 on the basis set forth in Exhibit B.
6.1.2. For Additional Services. OWNER shall pay EN-
GINEER for Additional Services performed or furnished
under Section 3 on the basis set forth in Exhibit B.
6.1.3. For Reimbursable Expenses. In addition to pay-
ments provided for in paragraphs 6.1.1 and 6.1.2, OWNER
shall pay ENGINEER for Reimbursable Expenses in-
curred by ENGINEER and ENGINEER's Consultants
as set forth in Exhibit B. The amount payable for Reim-
bursable Expenses will include a factor to the extent so
indicated in Exhibit B.
6.1. Other Provisions Concerning Payments.
6.2.1. Preparation of Invoices. Invoices for Basic and
Additional Services and Reimbursable Expenses will be
prepared in accordance with ENGINEER's standard
invoicing practices and will be submitted to OWNER by
ENGINEER at least monthly. The amount billed for
Basic Services and Additional Services in each invoice
will be calculated on the basis set forth in Exhibit B.
Invoices are due and payable on receipt.
6.2.2. Unpaid Invoices. If OWNER fails to make any
payment due ENGINEER for services and expenses
within thirty days after receipt of ENGINEER's invoice
therefor. the amounts due ENGINEER will be increased
at the rate of 1.5% per month (or the maximum rate of
interest permitted by law. if less) from said thirtieth day:
and, in addition. ENGINEER may. after giving seven
days' written notice to OWNER, suspend services under
this Agreement until ENGINEER has been paid in full
all amounts due for services. expenses and charges. Pay-
ments will be credited first to interest and then to princi-
pal. In the event of a disputed or contested billing. only
that portion so contested may be withheld from payment.
and the undisputed portion will be paid.
6.23. Payments Upon Termination.
6.2.3.1. Termination by OWNER for CaLise. In the
event of termination by OWNER for cause under
paragraph 8.1.1:
6.2.3.1.1. Upon the completion of any phase of
Basic Services. progress payments due ENGINEER
in accordance with this Agreement for all such ser-
vices performed or furnished by ENGINEER and
ENGINEER's Consultants through the completion
of such phase will constitute total payment for such
services. ENGINEER also will be paid for all unpaid
Additional Services and unpaid Reimbursable Ex-
penses.
6.2.3.1.2. During any phase of the Basic Services.
ENGINEER also will be paid for such services
performed or furnished in accordance with this Agree-
ment by ENGINEER during that phase through the
date of termination on the basis specified in Exhibit
B. ENGINEER also will be paid for the charges of
ENGINEER's Consultants employed to perform or
furnish Basic Services to the extent such services have
been performed or furnished in accordance with this
Agreement through the effective date of the termi-
nation. ENGINEER also will be paid for all unpaid
Additional Services and unpaid Reimbursable Ex-
penses.
6.2.3.2. Termination by OWNER for Convenience. In
the event of termination by OWNER under paragraph
8.1.2:
6.2.3.2.1. Upon the completion of any phase of
Basic Services, progress payments due ENGINEER
in accordance with this Agreement for all such ser-
vices performed or furnished by ENGINEER and
ENGINEER's Consultants through the completion
of such phase will constitute total payment for such
services. ENGINEER also will be paid for all unpaid
Additional s-ert'ices and unpaid Reimbursable Ex-
penses. and for termination expenses under subpara-
graph 6.2.3.2.3 below.
6.2.3.2.2. During any phase of Basic Services. EN-
GINEER also will be paid for such services per-
formed or furnished by ENGINEER during that
phase through the date of termination on the basis
specified in Exhibit B. In addition. ENGINEER
will be paid for the charges of ENGINEER's
Consultants employed to perform or furnish Basic
Services through the effective date of the termina-
tion. ENGINEER also will be paid for all unpaid
Additional Services and unpaid Reimbursable Ex-
penses. and for termination expenses under sub-
paragraph 6.2.3.2.3 below.
Page 12 of 16 pages
'.
6.2.3.2.3. In the event of termination by OWNER
for convenience during or at completion of any phase
of Basic Services. OWNER shall pay ENGINEER's
reasonable expenses directly attributable to termina-
tion in accordance with rates applicable to the various
categories of Additional Services measured from the
date of termination. including other fair and reason-
able sums for overhead and profit. and costs of
terminating contracts with ENGINEER's Consult-
ants.
6.2.3.3. Termination By ENGINEER for Cause. In the
event of termination by ENGINEER for cause under
paragraph 8.1.1. ENGINEER shall be entitled to re-
ceive compensation calculated as set forth in paragraph
6.2.3.2.
6.2.4. Records of ENGINEERs Costs. Records of EN-
GINEER's costs pertinent to ENGINEER's compensa-
tion under this Agreement will be kept in accordance with
generally accepted accounting practices. Copies will be
made available to OWNER at cost on request prior to
final payment for ENGINEER's services.
SECTION 7-0PINIONS OF COST
7.1. Opinions of Probable Construction Cost.
ENGINEER's opinions of probable Construction Cost
provided for herein are to be made on the basis of
ENGINEER's experience and qualifications and repre-
sent ENGINEER's best judgment as an experienced and
qualified professional engineer generally familiar with the
construction industry. However. since ENGINEER has
no control over the cost of labor, materials. equipment or
services furnished by others. or over the Contractor's
methods of determining prices. or over competitive bid-
ding or market conditions. ENGINEER cannot and does
not guarantee that proposals. bids or actual Construction
Cost will not vary from opinions of probable Construction
Cost prepared by ENGINEER. If OWNER wishes greater
assurance as to probable Construction Cost. OWNER
shall employ an independent cost estimator as provided in
paragraph 4.9.1.
7.2. Designing to Construction Cost Limit.
If a Construction Cost limit is established between OWNER
and ENGINEER. such Construction Cost limit and a
statement of ENGINEER's rights and responsibilities
with respect thereto will be specifically set forth in Exhibit
E. "Construction Cost Limit", to this Agreement.
7.3. Opinions of Total Project Costs.
ENGINEER assumes no responsibility for the accuracy
of opinions of Total Project Costs provided for in Section
2.
SECTION 8-GENERAL CONSIDERATIONS
8.1. Tennination.
The obligation to provide further servIces under this
Agreement may be terminated:
8.1.1. For cause.
8.1.1.1. by either party upon thirty days' written notice
in the event of substantial failure by the other party to
perform in accordance with the terms hereof through
no fault of the terminating party. Notwithstanding the
foregoing, this Agreement will not terminate as a result
of such substantial failure if the party receiving such
notice begins. within seven days of receipt of such
notice. to correct its failure to perform and proceeds
diligently to cure such failure within no more than thirty
days of receipt thereof: provided, however. that if and to
the extent such substantial failure cannot be reasonably
cured within such thirty-day period. and if such party
has diligently attempted to cure the same and thereafter
continues diligently to cure the same. then the cure
period provided from herein shall extend up to. but in
no case more than. sixty days after the date of receipt of
the notice.
8.1.1.2. by ENGINEER:
8.1.1.2.1. upon seven days' written notice if ENGI-
NEER believes that ENGINEER is being requested
by OWNER to furnish or perform services contrary
to ENGINEER's responsibilities as a licensed design
professional: or
8.1.1.2.2. upon seven days' written notice if the
ENGINEER's services for design or during the con-
struction of the Project are delayed or suspended for
more than ninety days for reasons beyond ENGI-
NEER's control.
c:.:=-
8.1.1.2.3. In the case of termination under this para-
graph 8.1.1.2. ENGINEER shall have no liability to
OWNER on account of such termination.
8.1.2. For convenience. by OWNER effective upon the
receipt of notice by ENGINEER.
8.2. Reuse of Documents.
All documents including Drawings and Specifications
provided or furnished by ENGINEER (or ENGINEER's
Consultants) pursuant to this Agreement are instruments
of service in respect of the Project. and ENG INEER and
ENGINEER's Consultants. as appropriate. shall retain an
Page 13 of 16 pages
ownership and property interest therein (including the
right of reuse by and at the discretion of ENGINEER and
ENGINEER's Consultants. as appropriate) whether or
not the Project is completed. OWNER may make and
retain copies for information and reference in connection
with the use and occupancy of the Project by OWNER
and others: however. such documents are not intended or
represented to be suitable for reuse by OWNER or others
on extensions of the Project or on any other project. Any
such reuse without written verification or adaptation by
ENGINEER and ENGINEER's Consultants. as appro-
priate. for the specific purpose intended will be at OWN-
ER's sole risk and without liability or legal exposure to
ENGINEER. or to ENGINEER's Consultants. and
OWNER shall indemnify and hold harmless ENGI-
NEER and ENGINEER's Consultants from all claims,
damages. losses and expenses including attorneys' fees
arising out of or resulting therefrom. Any such verifica-
tion or adaptation will entitle ENGINEER to further
compensation at rates to be agreed upon by OWNER and
ENGINEER.
8.3. Insurance.
8.3.1. ENGINEER shall procure and maintain insur-
ance as set forth in Exhibit F, "Insurance". for protection
from claims under workers' compensation acts. claims for
damages because of bodily injury including personal
injury. sickness or disease or death of any and all employ-
ees or of any person other than such employees. and from
claims or damages because of injury to or destruction of
property including loss of use resulting therefrom. ENGI-
NEER shall list OWNER as an additional insured on
ENGINEER's general liability insurance policy.
8.3.2. OWNER shall list ENG INEER and ENG INEER 's
Consultants as additional insureds on any general liability
or property insurance policies carried by OWNER which
\~ applicable to the Project. OWNER shall require
Contractor to purchase and maintain general liability and
other insurance as specified in the Contract Documents
and to list ENGINEER and ENGINEER's Consultants
as additional insureds with respect to such liability. prop-
erty and other insurance purchased and maintained by
Contractor. All policies of property insurance shall con-
tain provisions to the effect that ENGINEER's and
ENGINEER's Consultants' interests are covered and
that in the event of payment of any loss or damage the
insurers will have no rights of recovery against any of the
insured or additional insureds thereunder.
8.3.3. At any time OWNER may request that ENGI-
NEER, at OWNER's sole expense. provide additional
insurance coverage. different limits or revised deductibles
in excess of those specified in Exhibit F. If so requested by
OWNER. and if commercially available. ENGINEER
shall obtain and shall require ENGINEER's Consultants
to obtain such additional insurance coverage. different
limits or revised deductibles. for such periods of time as
requested by OWNER. at OWNER's sole expense. and
Exhibit f will be supplemented to incorporate these
req uirements.
8.4. ControUing Law.
This Agreement is to be governed by the law of the
principal place of business of ENGINEER.
8.5. Successors and Assigns.
8.5.1. OWNER and ENGINEER each is hereby bound
and the partners. successors. executors. administrators
and legal representatives of OWNER and ENGINEER
(and to the extent permitted by paragraph 8.5.2 the
assigns of OWNER and ENGINEER) are hereby bound
to the other party to this Agreement and to the partners.
successors, executors. administrators and legal represen-
tatives (and said assigns) of such other party, in respect of
all covenants. agreements and obligations of this Agree-
ment.
8.5.2. Neither OWNER nor ENGINEER may assign,
sublet or transfer any rights under or interest (including,
but without limitation. moneys that may become due or
moneys that are due) in this AgreelT]ent without the
written consent of the other, except to the extent that any
assignment. subletting or transfer is mandated by law or
the effect of this limitation may be restricted by law.
Unless specifically stated to the contrary in any written
consent to an assignment. no assignment will release or
discharge the assignor from any duty or responsibility
under this Agreement.
8.5.3. Unless expressly provided otherwise in this Agree-
ment:
8.5.3.1. Nothing in this Agreement shall be construed
to create. impose or give rise to any duty owed by
ENGINEER to any Contractor. Subcontractor. Sup-
plier. other person or entity. or to any surety for or
employee of any of them. or give any rights in or
benefits under this Agreement to anyone other than
OWNER and ENGINEER.
8.5.3.2. All duties and responsibilities undertaken pur-
suant to this Agreement will be for the sole and
exclusive benefit of OWNER and ENGINEER and not
for the benefit of any other party. The OWNER agrees
that the substance of the provisions of this paragraph
shall appear in the Contract Documents.
8.6. Dispute Resolution.
If and to the extent that OWNER and ENGINEER have
agreed on a method and procedure for resolving disputes
between them arising out of or relating to this Agree-
ment. such dispute resolution method and procedure, if
Page 14 of 16 pages
any, is set forth in Exhibit G. "Dispute Resolution."
OWNER and ENGINEER agree to negotiate in good
faith for a period of thirty days from the date of notice of
all disputes between them prior to exercising their rights
under Exhibit G or other provisions of this Agreement. or
under law.
8.7. Allocation of Risks-Indemnification.
8.7.1. To the fullest extent pennitted by law. ENGI-
NEER shall indemnify and hold hannless OWNER.
OWNER's officers, directors, partners, employees and
agents from and against any and all claims, costs, losses
and damages (including but not limited to all fees and
charges of engineers, architects, attorneys and other pro-
fessionals and all court or arbitration or other dispute
resolution costs) caused solely by the negligent acts or
omissions of ENGINEER or ENGINEER's officers, di-
rectors. partners, employees, agents and ENGlNEER's
Consultants in the perionnance and furnishing of ENGI-
NEER's services under this Agreement. The indemnifi-
cation provision of the preceding sentence is subject to
and limited by the provisions agreed to by OWNER and
ENGINEER in Exhibit H. "Allocation of Risks". if any.
~
~
sh 1 indemnify and hold hannless ENGINEER, EN 1-
NE 's officers. directors. partners, employees and _ ents
and El INEER's Consultants from and against yand
all claim costs. losses and damages (includi but not
limited to fees and charges of enginee . architects.
attorneys an ther professionals and all c rt or arbitra-
tion or other dis ute resolution costs) co. ed solely by the
negligent acts or missions of 0 1 R or OWNER's
officers, directors, po. ners, employ s, agents and OWN-
ER's consultants with espect to is Agreement or the
Project.
8.7.3. In addition to the in nity provided under para-
ent. and to the fullest extent
permitted by law, 0\ ER sh indemnify and hold
harmless ENGINE and its office , directors. partners,
employees, and a ents and ENG 1 ER's Consultants
from and again all claims. costs, loss , and damages
(including b not limited to all fees a d charges of
engineers, chitects, attorneys and other ofessionals
and all c rt or arbitration or other dispute esolution
costs) used by, arising out of or relating to the p sence.
disc rge, release. or escape of Asbestos, PCBs. tro-
Ie . Hazardous Waste. or Radioactive Material at.
8.8. Notices.
Any notice required under this Agreement will be in
writing, addressed to the appropriate party at the address
which appears on the signature page to this Agreement
(as modified in writing from time to time by such party)
and given personally. by registered or certified maiL
return receipt requested, by facsimile. or by a nationally
recognized overnight courier service. All notices shall be
effective upon the date of receipt
8.9. Survival.
All express representations, indemnifications or limita-
tions of liability made in or given in this Agreement will
survive the completion of all services of ENGINEER
under this Agreement or the termination of this Agree-
ment for any reason.
8.10. Severability.
Any provision or part of the Agreement held to be void or
unenforceable under any law or regulation shall be deemed
stricken. and all remaining provisions shall continue to be
valid and binding upon OWNER and ENGINEER. who
agree that the Agreement shall be refonned to replace such
stricken provision or part thereof with a valid and enforce-
able provision that comes as close as possible to expressing
the intention of the stricken provision.
SECTION 9-EXHIBITS AND SPECIAL
PROVISIONS
9.1. This Agreement is subject to the provisions of the
following Exhibits which are attached to and made a part
of the Agreement
9.1.1. Exhibit A. "further Description of Basic Engi-
neering Services and Related Matters", consisting of
pages.
9.1.2. Exhibit B. "Payments to Engineer for Services
and Reimbursable Expenses". consisting of _ pages.
\..-
9.1.3. Exhibit C. "Duties. Responsibilities and Limita-
tions of Authority of Resident Project Representative ".
consisting of _ pages.
Exhibit D. "Notice of Acceptability o'
f _ pages.
9.1.6.
Page IS of 16 pages
t'->
/
9.2, This Agreement (consisting of pages I to ~.
inciusive and the Exhibits identified above) constitutes
the entire agreement between OWNER and E~GI-
NEER and supersedes all prior 'NTitten or oral under-
standings. This Agreement may only ~e amended. sup-
piemented. modified or cancelled by a duly executed
written inStrument.
IN WITNESS VlHEREOF. the parries hereto have executed this Agreement to be effective as of the date first above
written,
OWNER:
Cit
530 ~n""'n'" Sf- 1
Augusta, GA 30911
--=-
By:
Address for giving notices:
435 Telfair St.
Augusta, ,GA 30901
Page 16 of 16 pages
.'
te"
SUGGESTED FORMAT
(for use with 1910-L. 1992 Edition)
This is EXHIBIT A. consisting of _ pages. referred to
in the Agreement between OWNER and ENGINEER
for Professional Services. dated , 19 _ .
Further Description of Basic Engineering Services and Related Matters
Initial:
OWNER
ENGINEER~
Sections 2. 3. 4 and 5 of the Agreement are amended and supplemented and the time periods for the performance
of the Basic Services as indicated in Section 5 of the Agreement are established. all as indicated below:
SECTION A2-BASIC SERVICES OF ENGINEER
A2.0. General.
The Basic Services are premised on the following general scope of professional services:
See attached Proposal letter dated April 15, 1999.
~
Page 1 of _ pages
(Exhibit A-Basic Services and Related Matters)
..
'. .
t; '.
A2.0.l. The following services listed in Se:::tion 3. "Additional Services". are hereby specifically deleted from that
Section and will be performed or furnished by ENGINEER as pan of Basic Services in the phase(sl
identified below:
.-\2.0.2. The following services listed in Section 4. "OWNER's Responsibilities", are hereby specifically deleted
from that Section and will be performed or furnished by ENG INEER as part of Basic Services in the
phase(s) identified below:
..\2.0.3. Section 2, "Basic Services of ENGINEER", is hereby amended or supplemented to provide that the
following services will be performed or furnished by ENGINEER as pan of Basic Services in the phase(s)
identified below:
A,2.1. Study and Report Phase.
.-\2.1.0. During the Study and Report Phase ENGINEER shall:
(insert amendments or supplements to paragraph 2,1.)
.-\1.104. ENG INEER shall evaluate the following alternate solutions and. after consultation with OWNER.
determine which solutions to recommend in the Report:
A2.1.i. ~copies of the Report will be submitted.
A2.1.8. Toe Report will be submitted to OWNER within ~ calendar days following the effective date of the
Agreement.
A2.2. Preliminary Design Phase.
.-\2.1.0. During the Preliminary Design Phase ENGINEER shall:
(insert amendments or supplements to paragraph 2.2.)
A1.2.5.1. ~~ sets of ENGINEER's Preliminary Design documentation will be submitted.
..\2.2.5.1. The preliminary design documentation will be submitted to OWNER within .....9.0- calendar days following
written authorization from OWNER to ENGINEER to proceed with the Preiiminary Design Phase
servIces.
A2.3. Final Design P.hase.
.-\2.3.0.
During the Final Design Phase ENGINEER shall:
(insert amendments or supplements to paragraph 2..3.)
~
.-\2.3.6.1. --'L- sets of Contract Documents will be submitted to OWNER.
.-\1.3.6.2. The Contract Documents will be submitted to OWNER within --9..0- calendar days following written
authorization from OWNER to ENGINEER to proceed with the Final Design Phase Services.
.-\1.3.8. The number of prime contracts ['or work designed or specified by ENG INEER upon which the
ENGINEER's compensation has been established under this Agreement is Two
[Note: If work designed or specified by ENGINEER is to be performed or furnished under more than one
prime contract. this Section A.2 will need to be modified and expanded to cover the completion of
different sets of documents for the separate construction phases and the times of performance may have to
be staggered. The provisions of paragraph 5.5 will probably apply and it will be necessary to prepare a
special schedule for the Final Design Phase Services.]
Page 2 of _ pages
(Exhibit A-Basic Services and Related Matters)
~
:\.' .
A.2.4.
A.2.4.0.
A.2..5.
A.2..5.0.
Bidding or Negotiating Phase.
During the Bidding or Negotiating Phase ENGINEER shall:
(insert amendments or supplements to paragraph 2.4.)
[Note: If the work designed or specified by ENGINEER is to be performed or furnished under more than
one prime contract. the provisions of paragraph 5,5 will probably apply and it will be necessary to prepare
a special schedule for the Bidding or Negotiating Phase Services and the times of performance may have
to be staggered.]
Construction Phase.
During the Construction Phase ENGINEER shall:
(insert amendments or supplements to paragraph 2.5.)
[Note: If the work designed or specified by ENGINEER is to be performed or furnished under more than
one prime contract. the provisions of paragraph 5,5 will probably apply and it will be necessary to prepare
a special schedule for the Construction Phase Services and the times of performance may have to be
staggered. ]
A.2..5.15. The Construction Phase Services will commence within 90
completion of the Final Design Phase.
A.2.5.16.
A2.6.
.-\.2.6.0.
A2.6.8.
calendar days following the
[Note: If an outside date for completion of construction is to be added. it should be added here.]
[Note: This change has to be coordinated with those in lj(2.5.15,]
Operational Phase.
During the Operational Phase ENGINEER shall:
(insert amendments or supplements to paragraph 2.6.)
J
[Note: If an outside date for completion of all services is to be added, it should be added here.]
[Note: This change is to be coordinated with those in lj(2.6.6.]
SECTION A3-ADDmONAL SERVICES OF ENGINEER'
~
A3.0.1.
A3.0.2.
A3.0.3.
The following services listed in Section 2, "Basic Services", are hereby specifically deleted from that
Section and will be performed or furnished by ENGINEER as part of Additional Services under
paragraph 3.1 or 3.2 as indicated:
The following services listed in Section 4, "OWNER's Responsibilities", are hereby specifically deleted
from that Section and will be performed or furnished by ENGINEER as part of Additional Services
under paragraph 3.1 or 3.2 as indicated:
Section 3, "Additional Services of ENGINEER", is hereby amended or supplemented to provide that the
following services will be performed or furnished by ENGINEER as part of Additional Services under
paragraph 3.1 or 3.2 as indicated:
(insert amendments or supplements to paragraph 3.1 or 3.2 as applicable)
Page 3 of _ pages
(Exhibit A-Basic Services and Related Matters)
.'
.
,~>:
r'-
.
SECTION A4-0WNER'S RESPONSIBILITIES
A4.0.1.
A4.0.2.
A4.0.3.
A4.11.
~
The following services listed in Section 2. "Basic Services", are hereby specifically deleted from that
Section and will be performed or furnished by OWNER as part of OWNER's Responsibilities under
Section 4:
The following services listed in Section 3, "Additional Services", are hereby specifically deleted from that
Section and will be performed or furnished by OWNER as part of OWNER's Responsibilities under
Section 4:
Section 4, "OWNER's Responsibilities", is hereby amended or supplemented to provide that the following
services or responsibilities will be performed or furnished by OWNER as part of OWNER's
Responsibilities under Section 4:
OWNER intends to employ each of the independent consultants listed below to perform or furnish
services in regard to the Project for the respective scope of services listed below for each. Payments to
ENGINEER for Services in Section 6 hereof are based on the participation in the Project of OWNER's
independent consultants as described herein.
(The remainder of this page was left blank intentionally,]
Page 4 of _ pages
(Exhibit A-Basic Services and Related Matters)
.
\.:-~~ I
SUGGESTED FORMAT
(for use with :'-10, i910-i. 1992 Edition)
This is EXl-llBIT B. consisting at _ pages. referred to in
the Agreement between OWNER und ENGINEER for
Professional Services. dated . 19 _ '
Initial:
OWNER
ENGINEER _
Payments to ENGll'IEER for Services and Reimbursable Expenses
Section 6 of the .'\greement is amended and supplemented to include the following agreement or the parties:
Lump Sum Method of Payment
(with addirional payments on a Salary Costs basis for
Resident Project Representative and Operational Phase Services
and additional payments for Reimbursable Expenses)
SECTION B6-PA":0fE:NiS TO ENGINEER
B6.1. Methods of Payment for Services and Expenses
of ENG~"EER.
B6.I.I. For Basic Ser/ices. O\V~'ER shall pay ENGI-
~ER ror Basic Services as follows: . J.~. f
~ 28 Z , 000
B6.l.Ll, GeneraL A lump sum fee or :5:-.2Q1,....Q:ilii..
for all services of ENGINEER (except for services or
ENGINEER's Resident Project Representative performed
or furnished under paragraph 2.5.2.1 and Operational
Phase services performed or furnished under paragraph
2.6) including services of ENGINEER's Consultanrs.
B6.I.l.2.. Residenr Project Represencative Services. For
services or ENGINEER's Resident Project Representa-
tive performed or ~W1der paragraph 2.5.2.1. an
amount equal to ENGINEER's Salary Costs times a
factor or.1. 75 for services performed or furnished by
principals and employees engaged directly in resident
Project representation.
B6.I.1.3, Operational Phase Services. For Operational
Phase services performed or furnished W1der paragraph
2.6. an amount equal to ENGINEER's Salary COStS
times a factor of;cb.L for services performed or fur-
nished by principals and employees engaged directly on
the Project.
B6.1.2. For Additional Services. OWNER shall pay EN-
GINEER for Additional Services as follows:
B6.I.:?.I. General. For ser/ices of ENGINEER's orin-
cipals and employees engaged directly on the Pr~ject
performed or furnished ~JUrsuanr to pamgraph 3,1 or
3,2 (except services as a consultant or witness under
paragraph 3.1.17). an amount equal to ENGINEER's
Saiary COStS times a factor of 2. 1
B6,I.2.2. e'lGIlvEER's Consultants. For services of
ENGINEER's Consultants performed or furnished ?ur-
suant to !3aragraph 3.1 or 3.2. the amount billed to
ENGINEER therefor times a facwr of 1.15
B6.1.2..3. Casc-Plus or Incentive Savings Consrruction
Comrac:s. If any contract for work designed or specified
by ENGIi'l"EER for the Project contains cost-\Jlus or
incentive savings urovlsions for Contractor's basic com-
pensation, an a-dditional lump sum fee of :5 2,500
for each such contract for Basic Services under B6.1.1.1
and on the basis indicated in B6.I.l.2 and B6.1.1..3
except that the factors in B6.1.L2 :lI1d B6.1.l..3 shall be:
B6.1.1.:
B6.1.1..3
B6.1.2.-1-. Se\'erai Prime C()nmu,:ts. If more than one
separate prime contract is awarded for work designed
or specified by ENG INEER for the Project. :J.n :J.ddi-
tional lump sum fee of :s
for each such additional prime contract for Basic Ser-
vices under B6.l.1.1 :lI1d on tht:: basis indicated in
B6.1.1.2 and B6.1.1..3 except that the factors in B6.1.1.2
Page 1 of _ pages
(Exhibit B-Lump Sum Method)
I,. .
," - It
and B6,l.1.3 shall be:
B6,1.1.2
B6.l.l3
B6.1.2.5. Serving as a Wimess, For services performed
by ENGINEER's principals and employees as consult-
ants or witnesses in any litigation, arbitration or other
legal or administrative proceeding under paragraph
3.1.17, at the rate of $ 1 nnn per day or any
portion thereof (but compensation for time spent in
preparing to appear in any such litigation. arbitration or
proceeding will be on the basis provided in paragraph
B6.1).1). Compensation for ENGINEER's Consult-
ants for such services will be on the basis provided in
paragraph B6.122. '
B6.1.3. For Reimbursable Expenses. OWNER shall pay
ENGINEER for Reimbursable Expenses such as:
printinq cost above 5 r.o~ip.s
Travel out of Richmond Co.
The amount payable to ENGINEER for Reimbursable
Expenses will be the charge actually incurred or the
imputed cost allocated by ENGINEER therefor times a
factor of
leave. vacation and holiday pay applicable thereto,
The principals of ENG INEER and the imputed current
hourly Salary Costs of such principals are as follows:
Imputed Hourly
Principal (name and title) SalarY Costs
Jorge E. Jimenez
$ $50
$ $50
$ $50
$
Joseph J. Tankersley
J.R. Armstrong
B6.1.5. Adjusrmenc of Salary Costs. The Salary Costs
and the factor applied to Salary Costs in determining
compensation payable to ENGINEER will be adjusted
annually and equitably to reflect changes in the various
elements that comprise such Salary Costs and factor. All
such adjustments will be in accordance with generally
accepted accounting practices as applied on a consistent
basis by ENGINEER and consistent with ENGINEER's
overall compensation practices and procedures.
B6.2. Other Provisions Concerning Payments.
B6.2.1. Preparation of Invoices. The portion of the amount
billed for ENGINEER's services which is on account of
the Lump Sum will be based upon ENGINEER's esti-
mate of the proportion of the total services actually
completed at the time of billing, The portion related to
services rendered on a Salary Costs basis will be billed
based on the Salary Costs (multiplied by a factor. if any, as
stated above) incurred at the time of billing.
B6.2.3. Payments Upon Termination.
B6.2.3.4. In the event of termination during any phase
of the Basic Services, ENGINEER will be paid for
B6.1.4. Salary Costs. Salary Costs means salaries and services performed or furnished in accordance with this
wages (basic, premium and incentive) paid to personnel Agreement during that phase on the basis of ENGI-
plus the cost of customary and statutory benefits includ- NEER's Salary Costs times a factor of for
ing, but not limited to. social security contributions, --==-- services performed or furnished during that phase to
unemployment. excise and payroll taxes. workers' com- date of termination by ENGINEER's principals and
pensation. health and retirement benefits. bonuses, sick employees engaged directly on the Project.
[The remainder of this page was left blank intentionally.]
Page 2 of _ pages
(Exhibit B-Lump Sum Method)