Loading...
HomeMy WebLinkAboutMAIN LIBRARY COSBY EVERETT WRIGHT LLC LUMP SUM AGREEMENT FOR ENVIRONMENTAL ENGINEERING SERVICES BETWEEN Augusta, Georgia, a political subdivision of the State of Georgia Acting by and through the Augusta Richmond County Commission Hereinafter Referred to as Owner AND Cosby, Everett & Wright, LLC Hereinafter Referred to as Environmental Consultant SPLOST IV PROJECT: Environmental Engineering & UST Closure Services for New Main Library DATE: November 6, 2007 Augusta-Richmond County CAPITAL IMPROVEMENTS PROGRAM MAN~GEMFiECE'VED HEERY International, Inc. NOV 501 Greene Street, Suite 313, Augusta, Georgia 30901 2 0 2007 (706) 842-5543; FAX (706) 821-2484 COUNTY ATTORNEY Letter of Transmittal X For approval D For Your Files D Revise & Submit D As requested D For Your Use D Furnish as requested D For Your Information D As Discussed D For Reproduction & Distribution DATE: 20 November 2007 TO: Steve Shepard Shepard, Plunkett, Hamilton, Boudreaux and Tisdale FROM: Jacques Ware SUBJECT: Contract for Main Library Phase II Environmental Engineering Services Q!y 4 Date 11/612007 Description of Item Lump Sum Agreement (Contract) & Supporting Data Comments: Steve, Attached you will find the Lump Sum Agreement for the New Main Library Environmental Engineering Services for Underground Storage Tank Abatement. The documents are updated/corrected per the instructions in your memorandum dated November 16,2007. ok you, ~wJ Ware ITEM: as described above ~ Attached o Under Separate Cover Via pickup from your courier If Enclosures are not as noted kindly notify us at once. cc: Bob Munger Article 1 Article 2 Article 3 Article 4 Article 5 Article 6 Article 7 Article 8 Article 9 Article 10 Article 11 Article 12 Article 13 Article 14 AGREEMENT FOR ENVIRONMENTAL ENGINEERING SERVICES TABLE OF CONTENTS Pag-e Definitions.......................................................................................................... 1 Relationship of the Parties ................... .............................. ....................... ........ 3 Basic Services..................................................................................................... 5 Compensation.................. ........... ........ .....,.... ............. ...... ................. ......... .........9 Period of Services............... .................. ....... ...................... ........................ ....... 11 Owner's Responsibilities. ............................. ..................... ........................ ....... 11 Notices.............................................................................................................. 12 Insurance....... .................. .................... ...................... .............................. ......... 13 Indemnification ............. ..................... ...................... ........... ............................. 14 Termination of Agreement................. ...................... ............................... ......... 15 Dispute Resolution......... .................... .......... ........... ................. ................ ........ 17 Successors/Assignment/Third Parties ........................ .......................... ........... 17 Ownership of Documents/ Confidential Information .................. ........... ............... ............................. ........ 18 Additional Provisions...... ................. ............ ............. ............................... ........ 19 Attachment AFee Schedule Attachment BProject Schedule Attachment CContingencies and Qualifications AGREEMENT FOR ENVIRONMENTAL CONSULTANT SERVICES AGREEMENT made this 6th day of November, 2007, BETWEEN the Owner: AUE:!usta. GeorE:!ia. a political subdivision of the State of Georcia. actinE:! bv and throuE:!h the AUE:!usta Richmond County Commission and the Environmental Consultant: Cosby. Everett & WriE:!ht. LLC. for Professional Services in connection with the Project known as: Environmental EncineerinE:! and UST Closure Services For the New Main Library. The Construction Program Manager for the Project is: Reery International, Inc. The Owner and the Environmental Consultant agree as set forth below: ARTICLE 1 DEFINITIONS The following words and phrases where appearing in initial capitalization, shall for the purposes of this Agreement have the following meanings: 1.1 PROJECT. The Project shall be all environmental services, as described herein, to be conducted in conjunction with the planned demolition of the former gasoline filling station located in downtown Augusta at the southeast corner of Ninth and Green Streets and the adjacent, 2-story commercial building located at 412 Ninth Street. Environmental services include assessment of hazardous materials such as asbestos, lead-based paint and polychlorinated biphenyl (PCB), meetings and abatement plan preparation. Services also include removal and closeout of four closed-in-place underground storage tanks (USTs), in association with the former gasoline filling station. 1.2 SERVICES. The Services to be performed by the Environmental Consultant under this Agreement shall consist of the Basic Services and any Additional Services both as defined herein. 1.3 BASIC SERVICES. Basic Services shall consist of environmental services as described in Article 3, to be performed and provided by the Environmental Consultant under this Agreement in connection with the Project. 1.4 ADDITIONAL SERVICES. Additional Services shall consist of the environmental services agreed to be performed by the Environmental Consultant in connection with the Project, but which are not specifically designated as Basic Services in Article 3. 1.5 WORK. The Work shall consist of tasks identified in Paragraph 1.1 above. 1.6 PROJECT DOCUMENTS. The abatement and demolition phase of the Project shall be completed in accordance with the Project Abatement Plan and Specifications, which will be prepared by the Environmental Consultant and approved by the Owner prior to the execution of the Agreement between the demolition Contractor and the Owner: 1. 7 CONTRACTOR. The Contractor is the person or entity which enters into an agreement with the Owner to perform the abatement and demolition on the Project, including, without limitation, the providing of labor, materials, and equipment necessary for the completion of the Project. The term "Contractor" means the Contractor or its authorized representative, but excludes the Construction Program Manager and the Environmental Consultant. 1.8 BASIC SERVICES COMPENSATION. Basic Services Compensation shall be fees designated in Article 4 to be paid by the Owner to the Environmental Consultant in connection with the performance of the Basic Services by the Environmental Consultant. 1.9 REIMBURSABLE EXPENSES. In connection with Additional Services, Reimbursable Expenses are those actual expenditures made by the Environmental Consultant, its employees, or its Professional Consultants in the interest of the Project including but not limited to, County standard per diem out-of-pocket expenses for travel and living expenses in connection with the Project, long distance telephone, expressage, professional consultants (other than those required for the performance of the Basic Services), and Owner-approved document reproduction. Pre-approved document reproduction expenses include expenses incurred for Bidding Documents, exclusive of addenda, and documents issued for permitting and/or construction. 1.10 OWNER/CONSTRUCTION PROGRAM MANAGER CONTRACT. The . Owner/Construction Program Manager Contract is the agreement between the Owner and the Construction Program Manager dated May 6, 2004 for the performance of construction program management services on the Project. 1.11 MASTER SCHEDULE. The Master Schedule is a graphic display of the major activities, phases, sequences and timing of the major project activities for design, construction procurement, construction and occupancy. 1.12 CHANGE ORDER. A Change Order is the form of documentation from the Owner approving and authorizing a modification to the Master Schedule or previously approved contract documents. 2 ARTICLE 2 RELATIONSHIP OF THE PARTIES 2.1 ENVIRONMENTAL CONSULTANT SERVICES. The Environmental Consultant shall provide professional environmental services for the Project in accordance with the terms and conditions of this Agreement. The Environmental Consultant's performance of services shall be as professional consultant to the Owner to carry out the activities of Project and to provide the technical documents and supervision to achieve the Owner's Project objectives. 2.2 OWNER REPRESENTATION. The Construction Program Manager is under separate contract with the Owner to provide construction program management services. The Construction Program Manager has no environmental responsibilities of any nature. None of the activities of the Construction Program Manager supplant or conflict with the services and responsibilities customarily furnished by the Environmental Consultant or subconsultants in accordance with generally accepted environmental consulting practices, except as otherwise modified by this Agreement. The Environmental Consultant understands and agrees that the Construction Program Manager is the Owner's exclusive representative to the Environmental Consultant and Contractor insofar as this Agreement is concerned. All instructions by the Owner to the Environmental Consultant relating to services performed by the Environmental Consultant will be issued or made through the Construction Program Manager. All communications and submittals of the Environmental Consultant to the Owner and Contractor shall be issued or made through the Construction Program Manager, unless the Construction Program Manager shall otherwise direct. The Construction Program Manager shall have the authority to establish procedures, consistent with this Agreement, to be followed by the Environmental Consultant and Contractor and to call periodic conferences to be attended by the Environmental Consultant, and subconsultants, throughout the term of this Agreement. 2.3 Environmental Consultant understands and agrees that it is not a third party beneficiary of any contract between the Owner and the Construction Program Manager or of their performance there under. Environmental Consultant waives any rights, claims or causes of action it may have as an alleged third party beneficiary of any such contract or of the performance of the parties there under. 2.4 ENVIRONMENTAL CONSULTANT REPRESENTATION 2.4.1 The Environmental Consultant shall provide a list of all consultants which the Environmental Consultant intends to utilize relating to the Project. The list shall include such information on the qualifications of the consultants as may be requested by the Owner. The Owner, through the Construction Program Manager, reserves the right to review the consultants proposed, and the 3 Environmental Consultant shall not retain a consultant to which the Owner, through the Construction Program Manager, has a reasonable objection. 2.4.2 The Environmental Consultant shall provide to the Owner, through the Construction Program Manager, a list of the proposed key project personnel of the Environmental Consultant and its consultants to be assigned to the Project. This list shall include such information on the professional background of each of the assigned personnel as may be requested by the Owner, through the Construction Program Manager. Such key personnel and consultants shall be satisfactory to the Owner and shall not be changed except with the consent of the Owner unless said personnel cease to be in the Environmental Consultant's (or its consultants, if applicable) employ. 2.5 DIVISION OF RESPONSIBILITIES/SERVICES. The Environmental Consultant understands and agrees that should the Construction Program Manager provide the Environmental Consultant with any estimating assistance, cost or time control recommendations or other consultation, recommendations or suggestions, any or all such activities on the part of the Construction Program Manager or any other representative of the Owner shall in no way relieve the Environmental Consultant of the responsibility of fulfilling its obligations and responsibilities under this Agreement. 4 ARTICLE 3 BASIC SERVICES 3.1 SCOPE OF SERVICES Augusta Richmond County proposes to demolish the former gasoline filling station at 848 Greene Street, in order to provide a building site for the proposed new Main Library. The former gas station is known to have four underground storage tanks (USTs) that were used to store gasoline and petroleum products. A recent Phase I ESA indicates that these tanks consist of (3) 2000 gallon tanks and (1) 550 gallon tank, all reported by the previous owners to be closed-in-place in 1969, whereupon they were emptied of petroleum products and filled with sand. There is no closure report for these tanks filed with the Georgia EPD. Augusta Richmond County also proposes to demolish the two-story masonry commercial and residential building located on the adjacent property (412 9th Street). The scope of work will include HAZMAT surveying and testing of these structures, preparation of a Abatement Plan and Specifications, air monitoring, abatement compliance inspections, excavation, analysis, removal and closeout of UST's and professional support of environmental issues that may arise during abatement and demolition work. Specific tasks included are: 1. Locate, sample and analyze suspected asbestos-containing materials (ACM) in the structures identified herein, in accordance with Attachment A Fee Schedule. 2. Locate, sample and analyze suspected lead-containing materials (LCM) in the structures identified herein, in accordance with Attachment A Fee Schedule. 3. Locate and analyze suspected Polychlorinated Biphenyls (PCB) in the structures identified herein, in accordance with Attachment A Fee Schedule. 4. Locate any other discovered suspected hazardous materials III the identified structures or otherwise within the property boundaries. 5. Produce a HAZMAT Building Survey Report summarizing findings and recommendations, with individual sections for ACM, LCM and PCB's. Include type and extent of each hazardous material, an estimated cost for abatement, and an estimated schedule for abatement. 6. Meet with Owner's Project Manager to discuss Survey Report, recommendations and preparation of abatement specifications and plans. 7. Prepare bidding/contract documents for demolition contractor, including 5 specifications, drawings and/or photographs, work procedures, air sampling, disposal requirements, etc., as required to provide a scope of work definition which facilitates production of a fixed cost bid by a Georgia licensed abatement contractor. Such contract documents shall require that all abatement work be done in accordance with Federal, State and Local regulations. 8. Attend Demolition Pre-Proposal Conference and subsequent tour of buildings. 9. Assist in analysis of Bids or Proposals for abatement work. 10. Prepare and submit a Closure Activity Form (GUST-29) to the UST Management Program of the Georgia EPD, prior to removal ofUST's. 11. Analyze existing surface and sub-surface site conditions including contacting the Utilities Protection Center, prior to undertaking excavation for removal of UST's. 12. Submit a Work Plan to the Owner's Representative, including a Health and Safety Plan, at least 1 week prior to commencing excavation for UST removal. 13. Excavate, open and analyze UST's, in accordance with Work Plan submitted to Owner. 14. Treat and remove UST's and dispose of in accordance with EPA and EPD regulations and Work Plan submitted to Owner. 15. Sample and analyze soil and groundwater surrounding the UST's for hydrocarbon contamination, in accordance with Georgia EPD regulations, utilizing geoprobe borings or other methods, in accordance with Attachment A Fee Schedule. 16. Remove and properly dispose of any contaminated soils found, and backfIll with clean, engineered fill, compacted to 95% of the maximum density as determined by ASTM D698. 17. Close out UST's with Georgia EPD, providing Owner's Representative with all associated closeout documentation. 18. In association with building demolition, provide oversight of abatement and remediation activities, including monitoring HAZMAT removal, compliance with contract documents, air sampling and testing. 19. Conduct air sampling during pre-building demolition abatement work and laboratory analysis of samples within 24 hours. 20. Provide daily site observation reports of abatement activities and a final inspection report once all abatement work is completed. 21. Provide a closeout report, within 30 days of completion of abatement work, 6 including description of completed abatement work and certification that work has complied with applicable Federal, State and Local laws and regulations. 22. Provide professional consulting on an "as needed" basis, for any Issue of environmental concern that arises during building demolition, subsequent to HAZMAT abatement. 23. Attachment C lists agreed contingencies, qualifications and assumptions as they relate to the services to be performed under this Agreement. 3.2 ENVIRONMENTAL CONSULTANT'S PROFESSIONAL RESPONSIBILITY AND STANDARD OF CARE 3.2.1 By execution of this Agreement, the Environmental Consultant warrants that (a) it is an experienced environmental firm having the skill and the legal and professional ability necessary to perform all the Services required of it under this Agreement in connection with the Project contemplated herein; (b) it has the capabilities and resources necessary to perform its obligations hereunder; and (c) it is familiar with all current laws, rules and regulations which are applicable to the Project (such laws, rules and regulations including, but not limited to, all local ordinances, city, county, state and federal authorities which are applicable to the Project, and all orders and interpretations by governing public authorities of such ordinances, requirements, laws, rules and regulations in effect at the time of commencement of services on the Project), and that all drawings, specifications and other documents prepared by the Environmental Consultant shall be prepared in accordance with and shall accurately reflect and incorporate all such laws, rules and regulations. 3.2.2 The Environmental Consultant hereby represents and agrees that the drawings, specifications and other documents prepared by it pursuant to this Agreement shall be complete and functional for the purposes intended, except as to any deficiencies which are due to causes beyond the control of the Environmental Consultant. 3.2.3 The Environmental Consultant shall be responsible for any errors, inconsistencies or omissions in the drawings, specifications, and other docl!ments. while the Environmental Consultant cannot guarantee the various documents required herein to be completely free of minor human errors and omissions, it shall be the responsibility of the Environmental Consultant throughout the period of performance under this Agreement to use due care with professional competence. The Environmental Consultant will correct at no additional cost to the Owner any and all errors and omissions in the drawings, specifications and other documents prepared by the Environmental Consultant. The Environmental Consultant further agrees, at no additional cost, to render assistance to the Owner in resolving problems relating to the design or specified materials. 7 3.2.4 It is the responsibility of the Environmental Consultant to make certain that all drawings, specifications and other documents are in accordance with applicable laws, statutes, building codes and regulations and that appropriate approvals are obtained from Federal, State and local governments. 3.3 PROJECT CONFERENCES Throughout all phases of the Project, the Environmental Consultant and its consultants shall meet periodically with the Owner and Construction Program Manager when reasonably requested. Attendees shall be as jointly determined by the Owner, Construction Program Manager and Environmental Consultant. As a minimum, regularly scheduled meetings which the Environmental Consultant will attend include: 1. Project Launch Meeting 2. Assessment Review/Pre-Abatement Plan Meeting 3. Abatement Plan Review Meeting 4. UST Work Plan Review Meeting 5. Demolition Contractor Pre-Abatement Meeting 8 ARTICLE 4 COMPENSATION 4.1 BASIC SERVICES COMPENSATION 4.1.1 The Owner shall compensate the Environmental Consultant in accordance with the terms and conditions of this Agreement, including the following: 4.1.2 For the Basic Services of the Environmental Consultant, Basic Services Compensation shall be in the not-to-exceed amount of EIGHTY-FIVE THOUSAND SIX HUNDRED AND SEVEN DOLLARS AND NINETY-TWO CENTS ($ 85.607.92 ). 4.1.3 The Basic Services Compensation stated in Paragraph 4.1.1 includes all compensation and other payments due the Environmental Consultant (manpower, overhead, profit, expenses, direct costs, etc.) in the performance of the Basic Services. 4.2 PAYMENTS TO THE ENVIRONMENTAL CONSULTANT. Payments on account of the Environmental Consultant shall be made as follows: 4.2.1 Payments for Basic Services shall be made upon completion of each of the following line items: Amount Due Asbestos Assessment......................................................... ...... ...$1007.50 Lead-Based Paint Assessment............... ... ... ...... ... ............ ... ...... ... ...$643.50 PCB Assessment........................................................................ $760.50 Abatement Plan Preparation/Review/Approval... ............... ..................... $6,700.00 Abatement Oversight and Air Monitoring......... ....................... ...... ....$6,630.00 Open and Analyze UST's......................................................... ..$23,920.60 Treat, remove & Dispose of UST's........................... ................... ..$25,006.83 Sample & Analysis of Soil at UST's ........................... .......... ........ ..$2,223.00 Sample & Analysis of Groundwater at UST's.................................... ...$416.00 Closeout Documentation Preparation............................................... .$3360.00 As-Needed Consulting Services......................... ................................ ... ..$672.00 Expenses and other direct costs (not to exceed).................................$14,267.99 4.2.2 No deductions shall be made from the Environmental Consultant's Basic Services Compensation on account of penalty, liquidated damages, retainage or other sums withheld from payments to Contractor. 4.2.3 If the Project is suspended for more than six months or abandoned in whole or in part by the Owner, the Environmental Consultant shall be paid compensation for services performed prior to receipt of written notice from the Owner of such suspension or abandonment, and all reasonable termination expenses resulting 9 from such suspension or abandonment. If the Project is resumed after being suspended for more than six months, the Environmental Consultant's Basic Services Compensation shall be equitably adjusted. 4.3 ADDITIONAL SERVICES COMPENSATION 4.3.1 With respect to any additional services performed by the Environmental Consultant hereunder, the Environmental Consultant and Owner shall negotiate an equitable adjustment to the Basic Services Compensation. However, if negotiations are not successful prior to the time the additional services are needed, the Owner may elect to contract with another entity to perform the Additional Service(s); or the Owner may direct the Environmental Consultant to proceed with the Additional Services on a time spent basis with Additional Compensation Services to be computed as follows: 4.3.1.1 Should the Owner elect to contract with a separate entity to perform Additional Services, as described under Paragraph 4.3.1, the Environmental Consultant shall comply with reasonable requests from Owner, without additional compensation, with regards to coordination of work with the respective separate entity. 4.3.2 Payments for Additional Services of the Environmental Consultant shall be made monthly upon presentation of the Environmental Consultant's statement of services, fully supported by invoices, time cards, and other documentation as requested by the Owner. 4.4 ACCOUNTING RECORDS 4.4.1 Records of the Environmental Consultant with respect to Additional Services and payroll, consultant and other expenses (including Reimbursable Expenses) pertaining to the Project, shall be kept on generally accepted accounting principals and shall be available to the Owner or its authorized representative for inspection and copying at mutually convenient times. 4.4.2 At the request of the Owner or its authorized representative the Environmental Consultant will supply in a timely manner and certify as accurate, unaltered copies of all time sheets, invoices, and other documents to substantiate and document any and all Additional Services and Reimbursable Expenses. 10 ARTICLE 5 PERIOD OF SERVICE 5.1 Specific dates relating to the period of services will be set forth in the Schedule "Attachment B.". 5.2 Unless earlier terminated as provided in Article 10 hereof, this Agreement shall remain in force for a period which may reasonably be required for the Basic Services and Additional Services hereunder. However, the provisions of the Agreement relating to Professional Responsibility (Paragraph 3.2); Dispute Resolution (Article 11); Professional Liability coverage (Article 8); Indemnification (Article 9); and Ownership of Documents/Confidential Information (Article 13) shall remain in effect after termination of the other provisions of the Agreement. 5.3 If the Project is delayed through no fault of the Owner or Environmental Consultant, all specific dates noted in the Attachment B Schedule that are affected by the delay will be adjusted by the number of calendar days of the delay. This includes delays beyond the control of the Owner or Environmental Consultant, and any unforeseen conditions. 5.4 If the Owner materially revises the Project, a reasonable time extension and/or credit shall be negotiated between the Environmental Consultant and the Owner. 5.5 Time is of the essence of this Agreement. ARTICLE 6 OWNER'S RESPONSIBILITIES 6.1 The Owner shall provide full information regarding the requirements for the Project. 6.2 The Owner shall examine documents submitted by the Environmental Consultant and shall render decisions pertaining thereto promptly, to avoid unreasonable delay in the progress of the Environmental Consultant's Services. 6.3 The Owner shall furnish information and approvals required of it expeditiously, for orderly progress of the Work and shall endeavor to adhere as closely as possible with the time conditions for such Owner activities as set forth in all approved schedules for the Project. 11 ARTICLE 7 NOTICES 7.1 Any notice required by this Agreement or other communications to either party by the other shall be in writing and deemed given when delivered personally or five (5) days after deposit in the United States Post Office, postage prepaid certified mail, return receipt requested, addressed as follows, or to such other address as shall be duly given by notice meeting the requirement of this Article. To Owner: Mr. Fred Russell Administrator Augusta Richmond County 530 Greene Street Augusta, GA 30901 7.2 To Environmental Consultant: Mr. John Wright Cosby, Everett & Wright, LLC 366 Augusta Avenue Atlanta, GA 30315 7.3 With Copy to:. Mr. Bob Munger Construction Program Manager Heery International, Inc. 501 Greene Street; Suite 313 Augusta, GA 30901 7.3.1 With Copy to: Mr. Garrett Weiss, P.G. Augusta Richmond County Environmental Engineer 1815 Marvin Griffin Road Augusta, GA 30906 12 ARTICLE 8 INSURANCE 8.1 The Environmental Consultant shall purchase and maintain insurance for protection from claims under worker's or workmen's compensation acts; claims resulting from negligent acts or omissions for damages because of bodily injury, including personal injury, sickness, disease or death of any of the Environmental Consultant's employees or any other person; claims for damages because of injury to or destruction of personal property including loss of use resulting there from; and claims arising out of the performance of this Agreement and caused by negligent acts or omissions for which the Environmental Consultant is legally liable. Minimum limits of coverage shall be: INSURANCE DESCRIPTION a. Worker's Compensation b. Public Liability Bodily Injury: Each Person Bodily Injury: Each Accident Property Damage: Each Accident c. Automobile Liability & Property Damage Bodily Injury: Each Person Bodily Injury: Each Accident Property Damage: Each Accident d. Professional Liability: Minimum Required Coverage Statutory $1,000,000 Combined Limit $100,000 $200,000 $100,000 $1,000,000 Combined Limit $100,000 $200,000 $100,000 $1,000,000 per Loss/Claim 8.2 Evidence of such insurance shall be furnished to the Owner, and the Owner shall receive thirty (30) days prior written notice of any cancellation, non-renewal or reduction of coverage of any of the policies. Upon notice of such cancellation, non- renewal or reduction, the Environmental Consultant shall procure substitute insurance so as to assure the Owner that the minimum limits of coverage are maintained continuously throughout the period of this Agreement. 8.3 The Environmental Consultant shall deliver to the Owner a certificate of insurance for its Professional Liability coverage. 8.4 All insurance policies (with the exception of Professional Liability) required under this Agreement shall name the Owner as an additional insured for the insurance and shall contain a waiver of subrogation against the Owner. 13 ARTICLE 9 INDEMNIFICATION 9.1 Notwithstanding anything to the contrary contained herein, the Environmental Consultant shall indemnify and hold harmless the Owner, the Construction Program Manager and their agents and employees from and against all claims, damages, losses and expenses, including but not limited to attorney's fees, to the extent arising out of or resulting from (i) the Environmental Consultant's performance or failure to perform its obligations under this Agreement and (ii) any claim, damage, loss or expense attributable to bodily injury, sickness, disease or death, or to injury to or destruction of personal property including the loss of use resulting there from and caused in whole or in part by any negligent act or omission of the Environmental Consultant, anyone directly or indirectly employed by the Environmental Consultant or anyone for whose acts the Environmental Consultant may be liable. Such obligation shall not be construed to negate, abridge or otherwise reduce any other right or obligation of indemnity which would otherwise exist as to any party or person described in this Article. 9.2 Except as otherwise set forth in this Agreement, the Environmental Consultant and the Owner shall not be liable to each other for any delays in the performance of their respective obligations and responsibilities under this Agreement which arise from causes beyond their control and without their fault or negligence, including but not limited to, any of the following events or occurrences: fire, flood, earthquake, epidemic, atmospheric condition of unusual severity, war, state or_ local government acting in its sovereign capacity, and strikes. Owner shall not be liable to the Environmental Consultant for acts or failures to act by Construction Program Manager, the Contractor, or the Owner's consultants. 14 ARTICLE 10 TERMINATION OF AGREEMENT 10.1 If (1), the Owner abandons the Project or the Project is stopped for more than six (6) months due to actions taken by the Owner, or under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable through no act or fault of the Environmental Consultant or its agents or employees, or (2), the Owner has failed to substantially perform in accordance with the provisions of this Agreement due to no fault of the Environmental Consultant and such non-performance continues without cure for a period of thirty (30) days after the Owner receives from the Environmental Consultant a written notice of such nonperformance (including a detailed explanation of the actions of the Owner required for cure), the Environmental Consultant may, upon fifteen (15) day's additional written notice to the Owner, terminate this Agreement, without prejudice to any right or remedy otherwise available to the Owner, and recover from the Owner payment for all services performed to the date of the notice terminating this Agreement. 10.2 Upon the appointment of a receiver for the Environmental Consultant, or if the Environmental Consultant makes a general assignment for the benefit of creditors, the Owner may terminate this Agreement, without prejudice to any right or remedy otherwise available to the Owner, upon giving three (3) working days written notice to the Environmental Consultant. If an order for relief is entered under the bankruptcy code with respect to the Environmental Consultant, the Owner may terminate this Agreement by giving three working days written notice to the Environmental Consultant unless the Environmental Consultant or the trustee: (1), promptly cures all breaches; (2), provides adequate assurances of future performance; (3), compensates the Owner for actual pecuniary loss resulting from such breaches; and (4), assumes the obligations of the Environmental Consultant within the statutory time limits. 10.3 If the Environmental Consultant persistently or repeatedly refuses or fails, except in cases for which extension of time is provided, to supply sufficient properly skilled staff or proper materials, or persistently disregards laws, ordinances, rules, regulations or orders of any public authority jurisdiction, or otherwise substantially violates or breaches any term or provision of this Agreement, then the Owner may, without prejudice to any right or remedy otherwise available to the Owner, and after giving the Environmental Consultant written notice, terminate this Agreement. 10.4 Upon termination of this Agreement by the Owner under Paragraph 10.2 or 10.3, it shall be entitled to furnish or have furnished the Services to be performed hereunder by the Environmental Consultant by whatever method the Owner may deem expedient. Also, in such cases, the Environmental Consultant shall not be entitled to receive any further payment until completion of the Work; and the total compensation to the Environmental Consultant under this Agreement shall be the amount which is equitable under the circumstances. If the Owner and the 15 Environmental Consultant are unable to agree on the amount to be paid under the foregoing sentence, the Owner shall fix an amount, if any, which it deems appropriate in consideration of all of the circumstances surrounding such termination, and shall make payment accordingly. 10.5 The Owner may, upon thirty day's written notice to the Environmental Consultant terminate this Agreement, in whole or in part, at any time for the convenience of the Owner, without prejudice to any right or remedy otherwise available to the Owner. Upon receipt of such notice, the Environmental Consultant shall immediately discontinue all services affected unless such notice directs otherwise. In the event of a termination for convenience of the Owner, the Environmental Consultant's sole and exclusive right and remedy is to be paid for all work performed and to receive equitable adjustment for all work performed through the date of termination. The Environmental Consultant shall not be entitled to be paid any amount as profit for unperformed services or consideration for the termination of convenience by the Owner. 10.6 Should the Owner terminate the Environmental Consultant as provided for under this Article, the Owner will acquire such documents, including the ownership and use of all drawings, plans, specifications, documents and materials relating to the Project prepared by or in the possession of the Environmental Consultant. The Environmental Consultant will turn over to the Owner in a timely manner and in good unaltered condition all such original documents and materials. 10.7 The payment of any sums by the Owner under this Article 10 shall not constitute a waiver of any claims for damages by the Owner for any breach of the Agreement by the Environmental Consultant. 16 ARTICLE 11 DISPUTE RESOLUTION If a dispute arises out of or related to this Agreement, or its alleged breach, and if that dispute has not been settled through direct discussions within a reasonable period, the parties to this Agreement agree to first endeavor to settle the dispute in an amicable manner by submitting the dispute to a mutually acceptable mediator under the Construction Industry Mediation Rules, before having recourse to a judicial forum. Each party further agrees that it will endeavor to follow a similar dispute resolution procedure to resolve any disputes against any third parties (including the Contractor and Construction Program Manager) which arise out of or relate to work. Should mediation of disputes prove unsuccessful, the parties to this Agreement agree that the matter(s) in question will be decided in the Superior Court of Richmond County, Georgia. By signing this Agreement, the Design Consultant waives any right to contest the venue in the Superior Court of Richmond County, Georgia. ARTICLE 12 SUCCESSORS/ASSIGNMENT 12.1 This Agreement shall inure to the benefit of and be binding on the heirs, successors, assigns, trustees and personal representatives of the Owner, as well as the permitted assigns and trustees of the Environmental Consultant. 12.2 The Environmental Consultant shall not assign, sublet or transfer its interest in this Agreement without the written consent of the other, except that the Environmental Consultant may assign accounts receivable to a commercial bank or financial institution for securing loans, without prior approval of the Owner. 17 ARTICLE 13 OWNERSHIP OF DOCUMENTS/CONFIDENTIAL INFORMATION 13.1 The Environmental Consultant agrees to transmit a digital copy of all plan text and drawings and closeout documents to Owner prior to project closeout. Said electronic fIles and documents are not to be used by the Owner on projects at separate facilities without a written agreement with the Environmental Consultant, except as provided for under Paragraph 10.6. 13.2 In order for the Environmental Consultant to fulfill this Agreement effectively, it may be necessary or desirable for the Owner to disclose to the Environmental Consultant confidential and proprietary information and trade secrets pertaining to the Owner's past, present and future activities. The Environmental Consultant hereby agrees to treat any and all information gained by it as a result of the Services performed hereunder as strictly confidential. The Environmental Consultant further agrees that it will not disclose to anyone outside of the authorized Project team (i) Owner's trade secrets during the period of this Agreement or thereafter or (ii) Owner's confidential and proprietary information during the period of this Agreement and thereafter for a period of 2 years. 18 ARTICLE 14 ADDITIONAL PROVISIONS 14.1 This Agreement and its Exhibits and Attachments represent the entire and integrated agreement between the Owner and the Environmental Consultant and supersedes all prior negotiations, representations or agreements, either written or oral. This Agreement may be amended only by written instrument signed by both Owner and Environmental Consultant. 14.2 This Agreement shall be governed by the law of the State of Georgia, U.S.A. 14.3 If anyone or more of the provisions contained in this Agreement, for any reason, are held to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality or unenforceability shall not affect any other provisions thereof and this Agreement shall be construed as if such invalid, illegal or unenforceable provision had never been contained herein. 14.4 Except where specifically stated otherwise, all periods of time stated in terms of days shall be considered periods calculated in calendar days. 14.5 The headings or captions within this Agreement shall be deemed set forth in the manner presented for the purposes of reference only and shall not control or otherwise affect the information set forth therein or interpretation thereof. 14.6 For the purpose of this Agreement unless the context clearly indicates otherwise, the singular includes the plural, and the plural includes the singular. 14.7 This Agreement may be executed in any number of counterparts, each of which shall be deemed an original, and the counterparts shall constitute one and the same instrument, which shall be sufficient evidence by anyone thereof. 19 ATTACHMENT A. FEE SCHEDULE Unit Units Rate Cost Task 1 - Asbestos Assessment Asbestos Inspection 5 Hour5 $ S 84.50 $ $ 422.50 Sample Collection Hour5 $ $ Sample Analysis 30 Samples $ S 19.50 $ $ 585.00 Reporting Hours $ $ note: assume analysis of 30 samples required Subtotal $ $ 1,007.50 Task II - Lead -Based Paint Assessment Lead Inspection 3 Hours $ S 84.50 $ $ 253.50 Sample Collection Hours $ $ Sample Analysis (XRF or 6010) 20 Samples $ $ 19.50 $ $ 390.00 Reporting Hours $ $ note: assume analysis of 20 samples required Subtotal $ $ 643.50 Task III - PCB Assessment PCB Inspection 3 Hours $ S 84.50 $ $ 253.50 Sample Collection Hours $ $ Sample Analysis (8081) 6 Samples $ S 84.50 $ $ 507.00 Reporting Hours $ $ note: assume anlaysis 6 samples required Subtotal $ $ 760.50 Task IV - Abatement Plan & Specification Preparation Note: Suitable for competitive bidding Lump Sum $ $ 6,700.00 Task V - Abatement Oversight and Air Monitoring (assume 10 working days) 10 Days $ S 663.00 $ $ 6,630.00 Task VI - Open & Analyze USTs Lump Sum $ $ 23,920.60 Task VII - Treat, Remove and Dipose of USTs Lump Sum $ $ 25,006.83 Task VIII - Sample & Analysis of Soil @ USTs assume 13 required for BTEX, TPH-GRO 13 Samples $ S 91.00 $ $ 1,183.00 assume 2 required for BTEX, TPH-GRO, TPH-DRO, PAH's 2 Samples $ S 520.00 $ $ 1,040.00 Subtotal $ $ 2,223.00 Task IX - Sample & Analysis of Groundwater @ UST's assume 1 required for BTEX Sample $ S 104.00 $ $ 104.00 assume 1 required for BTEX, PAH's Sample $ S 312.00 $ $ 312.00 Task X - Over-excavation of Contaminated Soil & Backfill/compaction Unit price only, with proper disposal, compaction as specified Cubic yards $ S 31.50 Task XI - Close Out Documeutation Lump Sum $ S 3,360.00 Task XII - As-Needed Consulting Services assume 8 hours 8 Hours $ S 84.00 $ S 672.00 FEE SUBTOTAL $ $ 71,339.93 EXPENSES, FEES & OTHER DIRECT COSTS $ $ 14,267.99 TOTAL (LUMP SUM) $ S 85.607.92 .... 0 - CO - - 0 - Ui ::) ~ <( C 'S ...., .::::::: W ..J ::::) C w J: (.) U> U> UJ (.) ~ w U> " Z [i: UJ UJ Z c; Z UJ o auC I::t:: g.!!l :> N Z W ~ :E ~ J: olS ~ U> ::::) >- I::t:: ~ ID :i z < :E < .... U) ::::) " ::::) < C :::l ...., : :~::::: : ~:~:~:~ +r:;> III C ." .s .:.c. CIl ." ~ {'!. :ij (ij (ij ell .5 E E '6 .s ~ '" )( ~ W W :5 .~ cO "0'- - CIl"-gi :5 ~ 0.- :2"'E~ .o:>'::)Q. "- "t: - )( CIl"'....Q) 5 c; 0... .. GicGi'1l .s:'S'e-. _cu-gc..co ~C:.<:c8 'c.2 g ON CIl:E: c'ii-.:- -5~'-2~ . ".:: en CD i 1;) 0 .... Q) 't:l - C g ..:.:.:........... C::;:, '" 8 ''''',' CIl c: .2 : ~ OIl -g ~.!: . ..!i'-Il!'O '-ca(l).oc Q) .c <11 ._ '" ~ "';-~ e 3: C) 0'- Cl 0.5 <11~-'" ~;gi'iQ)~ :::J<1I,c'" + ~ ~ II) E 01 ClI CIl ~ :::J 0.. c <11 en .s E tl j E ell :ij ::) 'e- rn 0.. <( Iii :E .cl CIl U. :1;I () CD Cl I . . . I U ..................~........... ......~.... .........~ ........ ... ...~.. ..........~...... ....... ........-. ....... ." 0 ..... ..... ..... ..... b au au ..... ..... ..... au 00 00 0 0 0 0 0 0 0 Q ~ ~ Q 0 ,c 1e iO en ~ co ~ N ~ ..... Ol en rn ~ .... ~ .... ~ ~ ~ a; c .... ..... .... N .... ... ... .... ..... Ir ... .... ... ... ..... ..... ~ ..... ..... ..... ..... ao ..... ..... ..... ..... ao au 0 0 0 0 Q 0 ~ 0 ~ ~ Q ~ 1e 1e iO 2s ... ~ in ~ 1:: ~ ~ M ~ N ~ ~ S .... .... .... N .... .... .sg .... ... .... ... .... rn ... ... ... ... .... rn III ~ - ~ ~ ~ &: m ~ z w :E J: ~ ~ ~ '" l5 +> c: () ~ <11 "8 0: c c: Gl .2 <11 a. c: iii 0: E (1\ =g ~ >< i!: (1\ 0: .8 0 rn g E s: l5 olS CD "0 S +> +> a:: E 0 - () rn '" c 'E '" c: '6 '0 III 0. 0 Cl CIl .c E :Q CD ~ ! :::l ~ l'O E .; en Cl 8 01 CIl "S; olS 0 c - a:: ~ - '" E "" olS ~ ~ 0 l!! rn 01 l!! III CD co l- E: :::J Z Q. I- ~ ..... l!! rn '0 0.. :::I 0.. iii .... ..0 0.... CIl ". .~s .t~ rn C n. .2 I- 1i Q) z E a rc l'O +> z c: 0 W r:: ~ .:.c. > Cl II) co c 0.. W I- W w LLI Q ::z: .... ~ ATTACHMENT C - QUALIFICATIONS & CONTINGENCIES The following assumptions/conditions govern this Agreement: . The field work will be completed in four (4) 10-hour work days, which does not include travel to and from the site, and entails the installation of approximately 10 to 15 geoprobes to a total depth of 12 ft-bgs, and the excavation and disposal of the USTs. . City of Augusta will provide CEW with a site map drawn to scale of the facility. · All permits and application fees will be covered by CEW. . Analytical services will be conducted following laboratory tw1taround time of three (3) days and is based on the parameters described herein. . Additional delineation activities for impacted soils that are above GA EPD action levels that are beyond the scope of services are not included and, if required, will be billed on a time and materials basis. . CEW will provide schedule to include 30 day notification to the GA EPD. · CEW will locate utilities prior to mobilization the site. . Silt fencing to be installed on down gradient areas only NTE 200 ft. . CEW assumes the tanks contents is sand (Not Concrete). If the tanks are filled with concrete this could significantly affect the schedule and disposal costs. · Dewatering of contaminated water is excluded. . CEW will not claim generator status for contaminated materials however, CEW will sign disposal documents as Agent for Generator. This Agreement executed the day and year frrst written above. OWNER ENVIRONMENTAL CONSULTANT Augusta, Georgia, a political Cosby, Everett. & Wrigbt, LLC ". "'.:: Subdivision of the State of Georgia Acting by and through the PV,It~~ - Richmond County Commission K15 .' (#;, ~:.;~ G 'oJ e l"{; .... ;; 0.- .4# d By: Title y~, ()etJ, { Ce-O AlleS~" ~. j Witnes~ eB '.aR., .' N1V" ~MY PUil.-C.. t,~W".8 ~\J ,1'':.. ,'f'(1M,,~N E*'~ APRIl .'i ,,.,~ 20 ~ {{1f'nJ(!{{lj((Jjnellt {j}}'r;xw-..tment S11i' fj-eri (jJk111rJ, {j)fi;.eeto-I' ADDENDUM Faxed and Mailed TO: All Bidders FROI\1: DATE: SUBJ: Geri A. Sams fIn'l tf)0 ~J71n"J . May 11,2007 ADDENDUM #2 RFP Item #07-128 Phase II Environmental Engineering Services for the New Main Library New RFP Date: Tuesday, May 22,2007 @ 3:00 p.m. This is to notify all potential vendors that the RFP opening date f01; RFP #07~128 Phase II Environmental Engineering Services for the New Main Library has been changed: From: Friday, May 18,2007 @ 11:00 a.m. To: Tuesday, May 22, 2007 @ 3:00 p.m. Please note the Fee Schedule. has been modified for RFP 07-128 and is attached. Please acknowledge receipt of addendum in your RFP package. If you have any questions regarding this correspondence, please contact me at (706) 821-2422. cc: Tameka Allen Bob Munger. Interim Deputy Administrator Heery Int'l Room 605 - 530 Greene Street, Augusta, Georgia 30911 (706) 821-2422 - Fax (706) 821-2811 www.augustal!a.l!ov Register at www.demandstar.com/supplier for automatic bid notification FEE SCHEDULE ADDENDUM NO.2 Unit Units Rate Cost Task 1 . Asbestos Assessment Asbestos Inspection Hours $ $ Sample Collection Hours $ $ Sample Analysis 30 Samples $ $ Reporting Hours $ $ note: assume analysis of 30 samples required Subtotal $ Task 11- Lead -Based Paint Assessment Lead Inspection Hours $ $ Sample Collection Hours $ $ Sample Analysis (XRF or 6010) 20 Samples $ $ Reporting Hours $ $ note: assume analysis of 20 samples required Subtotal $ Task III - PCB Assessment PCB Inspection Hours $ $ Sample Collection Hours $ $ Sample Analysis (8081) 6 Samples $ $ Reporting Hours $ $ note: assume anlaysis 6 samples required Subtotal $ Task IV - Abatement Plan & Specification Preparation Note: Suitable for competitive bidding Lump Sum $ Task V - Abatement Oversight and Air Monitoring (assume 10 working days) 10 Days $ $ Task VI - Open & Analyze USTs Lump Sum $ Task VII - Treat, Remove and Dipose of USTs Lump Sum $ Task VIII - Sample & Analysis of Soil @ USTs assume 13 required for BTEX, TPH-GRO 13 Samples $ $ assume 2 required for BTEX, TPH-GRO, TPH-DRO, P AH's 2 Samples $ $ Subtotal $ Task IX " Sample & Analysis of Groundwater @ UST's assume 1 required for BTEX Sample $ $ assume 1 required for BTEX, P AH's Sample $ $ Task X - Over-excavation of Contaminated Soil & BackfiIl/compaction Unit price only, with proper disposal, compaction as specified Cubic yards $ Task XI - Close Out Documentation Lump Sum $ Task XII - As-Needed Consulting Services assume 8 hours 8 Hours $ $ FEE SUBTOTAL $ EXPENSES, FEES & OTHER DIRECT COSTS $ TOTAL (LUMP SUM) $ ~ {fji51me{(;}t(7Jnent Ylf'~U712~ 9i1i' fled' (j]/CMlltJ, {jJ)j'?'e.etCPJ' ADDEIVDUM Faxed and Mailed TO: All Bidders 11dJ,t? ) Geri A. S ams \6 n?:)" May 10,2007 FROM: DATE: SUBJ: ADDENDUM #1 RFP Item #07-128 Phase II Environmental Engineering Services for the New Main Library RFP Due: Friday, May 18,2007 @ 11:00 a.m. Please note the following change to your RFP package: Survey Drawing which is attached Please acknowle~ge receipt of addendum in your RFP package. If you have any questions regarding this correspondence, please contact me at (706) 821-2422. cc: Tameka Allen. Bob Munger Interim Deputy Administrator Reery Int'l Room 605 - 530 Greene Street, Augusta, Georgia 30911 (706) 821-2422 - Fax (706) 821-2811 www.aUlmstaEa.lwv Register at www.demandstar.com/suoplierfor automatic bid notification , I BSMH ,I ,I ~V: ~~S4.43 T=135.35 , " I ~1~~'~173 " 9 ! i ~ ~~1~~1~~.90 GREEN E ST. R /W V A I I I I " Y ~~~5 43 (A.K.A. GA. H~ 1/28) ... I I IE;"N=127,23 f:>'~~3 97 I STMH tt' I GPM , IEouT=127.02 IE-;-N=127'~3 T=135,47 T= ,46 1EouT=127,79 , , p-p-p-p-p-p-p -~"" SSMH WV -r-r-: ~;:----t-T=134'99_ w_ " ... IEIN=127.77 GT "-,, - w 1'\.1. )t 1 iEoUT=127, 44 T,=.13-1:.:N - - --~- - - - ~--------.{)= =- == ~ y.. V 134.80 1%21 - 13IT3 '." ;~4.Oa - - - -:- - - '134.50 13'I'9~ I, I~" / 134,9~ II CONCRETE PAVING 13,1.57 V. 135-'0 I V II ::::: 134 9'" , I / II 0 ~ " O::;::J I '&"1 WVI3~~1 TS CONCR~W PA\~M~9 [35:80 ~~ I 1 'III ~t:=:QI 567.58'40"E 62.95' ~129,Z6 ... 'III [.;;r-:~ m8 WV~ILLER CAP PH8N _ ---, ..)-i... " I I 1 /I I~~:r~ 134'~'L;g~ ~ 0 BO TH L I "-X- J+-I ;:;:.--< II :::> !!3-Nn.--< MW ~ MA OLE(2) I \ F.:i.H ... "rJU'I'! ~~01~ LP5j(jJ:3.!.lw-_~~~ I I 136,11 ~ F ~ ~ M$(2) I ~TANK LOCATION 135 I 0 CD L - -1-APPROXIMATE ~ NG I ~I "/ I ~II "I"~ ~~ MW MW(Z) , ~I .1 ~... I~I! I ~~ ~ 3548 13 ;~I I" ~ I I~II.." 134.5 ~ I I I~ ... ~i~11 II 135.77 f35.76 ~I ,,~ to I~" .. Vi '" : i ! ~~ il~I..I!I! i '~1 ,,,. ~ ~~ ,,= -I ~ k" . _.135,43 I ~ : : (Uis r ov i OON"'" "~NO "" ~ I 1 ~ I !"I~ ..".. ~ -CD .. :Ui III I .! -! rMi r- . M 1'1 !~I:rb J I .. 1 I I I ~Ii' 134.43 tr" ... ; I 0~ .. · ,JI" 11 .. L~ .... III I . II !Il ~ b ,~" .ifo~:L t; lol ii i~r~n ,~~ J ~ "/"'1. 1,'./1,' "/1 ~ -- <I: p::!::[/ ~ "1/ ~ >;.~l-:; ~I j . i I !!ll I:f ,<."N6724'37'W -j'" IL~~~II ;'::.:<r ~u~:~~~ /LP.. j IH~~i w .:~.;;lf'L-. ~ I B~J~ 1~1134.rr ~ - .::l~:.T I.. ./1':.11" ~ ~ . ..... I II I, /" i<l N !'3~~+ ~ . 134~4e- II.IH+~ 0 .' 134mB II I.. :'W\i.,,:'.:, o 10' 0 .:, II" " WM .....: GM T ---S.6.I4.~T " ... I, I I I ::.~:. U, 64.26' I I 'r I' ::'< L. ~ METAL CAGE p N/F DONALD R. , REYNOLDS 64.19' 56724'37" E 136.6S 13k 3b 00 N ..... I l:'-- o ~ ~ z o ~ E-I < E-I rJJ ~ Z ~ ~ o rJJ ~ ~ ~ ~ o ~ ~ o ~ .....:i ~ cJ ~ I ~ r-- o o N o' - ;>, c<:l ~ ~ Request for Proposal RFP Item #07-128 Phase II Environmental Engineering Services For the New Main Library For Augusta Main Library RFP Due: Friday, May 18, 2007 @ 11:00 a.m. Thanks for doing business with us . . . Geri A. Sams, Procurement Director 530 Greene Street, Room 605 Augusta, Georgia 30911 'J; Request for Proposal RFP's will be received at this office until 11:00 a.m., Friday, May 18, 2007 RFP Item #07-128 Phase IT Environmental Engineering Services for the New Main Library RFP's will be received by Augusta, GA Commission hereinafter referred to as the OWNER at the offices of: Geri A. Sams Procurement Department 530 Greene Street - Room 605 Augusta, Georgia 30911 706-821-2422 RFP documents may be obtained at the office of the Augusta, GA Procurement Department, 530 Greene Street - Room 605, Augusta, GA 30911. Documents may be examined during regular business hours at the offices of Augusta, GA Procurement Department. . A Mandatory Pre-Proposal Conference will be held on Friday, April 27, 2007 @ 10:00 a.m. in Room 605 of the Procurement Department. All questions must be submitted in writing to the office of the Procurement Department by fax at 706-821-2811 or by mail. The last day to submit questions is Friday, May 4, 2007 by 4:00 p;m. No RFP will be accepted by fax, all must be received by mail or hand delivered. The local bidder preference program is applicable to this project. To be approved as a local bidder and . receive bid preference on an eligible local project, the certification statement as a local bidder and all supporting documents must be submitted to the Procurement Department with your bonafide RFP package. No RFP may be withdrawn for a period of 90 days after time has been called on the date of opening. Bidders will please note that the number of copies requested; all supporting documents including financial statements and references and such other attachments that may be required by the bid are material conditions of the package. Any bid package found incomplete or submitted late shall be rejected by the Procurement Office. Any bidder allegedly contending that he/she has been improperly disqualified from bidding due to an incomplete bid submission shall have the right to. appeal to the appropriate committee of the Augusta Commission. Please mark RFP number on the outside of the envelope. Bidders are cautioned that sequestration of RFP documents through any source other than the office of the Procurement Department is not advisable. Acquisition ofRFP documents from unauthorized sources places the vendor at the risk of receiving incomplete or inaccurate information upon which to base his qualifications. GERI A. SAMS, Procurement Director Publish: Augusta Chronicle Augusta Focus AprilS, 12, 19,26,2007 April 12, 2007 cc: Tameka Allen Bob Munger Interim Deputy Administrator Heery/Capital Improvements Manager 1.0 PROJECT AND OWNERSHIP OF DATA The Project consists of professional HAZMA T surveys of two structures, production of abatement plans and removal and closeout of four closed-in-place underground storage tanks (USTs), formerly used to store gasoline and petroleum products. All RFP responses will be retained as property of Augusta-Richmond County 2.0 RESPONSES The responses to this RFP shall be submitted in sealed opaque envelopes no later than Friday, May 18, 2007 @ 11 :00 a.m. Ms. Geri A. Sams, Procurement Director Augusta-Richmond County 530 Greene Street, Rm 605 Augusta, GA 30911 Submit one (1) original clipped and six (6) bound copies. Include a second, sealed envelope inside the main envelope, with the proposed Fee Schedule (attached). Label the inner envelope "Fee Proposal for RFP 07-128." Clearly mark outside of outer envelope "RFP No. 07-128 Phase IT Environmental Engineering Services for the New Main Library." Augusta Richmond County assumes no responsibility for proposals received after the advertised deadline, or at locations other than as specified herein. A mandatory Pre-Proposal Conference will beheld on Friday, April 27, 2007 @ 10:00 a.m. in the conference room of the Procurement Department. There will be a site visit following the Pre-Proposal Conference. 3.0 SCOPE OF WORK The Project includes professional HAZMA T surveys of two structures, production of abatement plans, oversight of abatement work, and removal and closeout of four closed-in-place underground storage tanks (USTs), in association with a former gasoline filling station. . The buildings included are the former gasoline filling station (most recently used as a car wash) located in downtown Augusta at the southeast comer of Ninth and Green Streets and the adjacent, 2-story commercial building located at 412 Ninth Street. There are no dra\yings of the buildings available. The four USTs were used to store gasoline and petroleum products for the former gas station. A recent Phase I ESA indicates that these tanks consist of (3) 2000 gallon tanks and (1) 550 gallon tank, all reported by the previous owners to be closed-in-place in 1969, whereupon they were emptied of petroleum products and filled with sand. There is no closure report for these tanks filed with the Georgia EPD. Proposals in response to thisRFP should include HAZMA T survey and testing of these structures, preparation of a Remediation Action Plan, intermittent abatement compliance inspections and professional support of environmental issues that may arise during abatement and demolition work. 2 Specific tasks included are: 1. Locate, sample and analyze all suspected asbestos-containing materials (ACM) in the structures identified herein. 2. Locate, sample and analyze all suspected lead-containing materials (LCM) in the structures identified herein. 3. Locate and analyze all suspected Polychlorinated Biphenyls (PCB) in the structures identified herein. 4. Locate and analyze any other suspected hazardous materials in the identified structures or otherwise within the property boundaries. 5. Produce a HAZMAT Building Survey Report summarizing findings and recommendations, with individual sections for ACM, LCM and PCB's. Include type and extent of each hazardous material, an estimated cost for abatement, and an estimated schedule for abatement. 6. Meet with Owner's Project Manager to discuss Survey Report, recommendations and preparation of abatement specifications and plans. 7. Prepare bidding/contract documents for demolition contractor, including specifications, drawings and/or photographs, work procedures, air sampling, disposal requirements, etc., as required to provide a scope of work definition which facilitates production of a fixed cost bid by a Georgia licensed abatement contractor. Such contract documents shall require that all abatement work be done in accordance with Federal, State and Local regulations. 8. Open existing USTs and analyze contents for safety and environmental considerations associated with their removal. 9. Treatment, removal and disposal of the tanks. 10. Sample and laboratory analysis of soil and groundwater surrounding UST's for hydrocarbon contamination, in accordance with Georgia EPD regulations. 11. Removal and proper disposal of any contaminated soils found, and backfilling with clean, engineered fill, compacted to 95% of the maximum densityas determined by ASTM D698. 12. Preparation and submission of a tank closure report to the Georgia EPD. 13. Attend Demolition Pre-Proposal Conference and subsequent tour of buildings. 14. Assist in analysis of Bids or Proposals for abatement work. 15. Provide periodic oversight of abatement and remediation activities for compliance with contract documents. 16. Provide site observation reports of abatement activities and a final inspection report once all abatement work is completed. 17. Provide professional consulting on an "as needed" basis, for any issue of environmental concern that arises during building demolition, subsequent to HAZMA T abatement. . 4.0 DELIVERABLES Two bound copies, and one unbound copy, of the HAZMA T Building Survey Report shall be submitted to the OWNER's Project Manager. Two bound sets of Contract Documents shall be submitted to the OWNER's Project Manager for review. One final set of reproducible Contract Documents, following OWNER review, suitable for inclusion in a set of demolition bid documents or an RFP, shall be submitted to the OWNER's Project Manager. 3 5.0 COMPENSATION Submit proposed fees in accordance with Section 10.0. Please submit the proposed fee in a separate sealed envelope labeled RFQ 07-128. The OWNER reserves the right to negotiate final terms of the Contract, including fees, with the highest ranked technical proposals. 6.0 FORM AND CONTENTS OF SUBMITTAL Submittal Form Provide one (1) original and six (6) bound copies of your submittal. Submittal shall utilize letter-size (8 Y2 x 11 inches) or, zee folded to that dimension from 11 x 17 inch stock. Submittal should be clear and concise and follow the format described herein. Submittal Contents Cover Letter: Include a (one page maximum) cover transmittal letter which clearly states the single contact (principal-in-charge) proposed for this project; the firm (or firms) mailing address ( es), telephone and facsiinile numbers. Specifically designate the applicant's representative who will serve as lead contact in all communications and who is authorized to negotiate on behalf of the firm or team. If a joint venture team is proposed, indicate the approximate fee percentage of each organization. Do not indicate actual fee amounts, only fee percentages. Scope of Services: Describe how services will be provided, including a detailed listing and description of tasks and deliverables. Experience and Capacity: Describe background and experience of the firm demonstrating ability to provide . required services. References: List references with telephone numbers from enyironmental engineering work performed on other relevant contracts. Personnel: Identify all key professionals to be directly involved in work, with resumes and specific applicable experience including subcontractors, if applicable. RFP Submittal: Write the title of the RFP on front of the sealed envelope. Total proposal shall not exceed thirty pages. Submit in accordance with Section 2.0 Experience Modification Rate:_ Submit a letter from your workers comp insurance company" on their company letterhead, signed by a company official, stating your Experience Modification Rate (EMR) for the last three available years Fee Schedule: Complete the included Fee Schedule, filling in all requestedinformation. Fee Schedule should be included in a separate sealed. envelope, contained within the main envelope, and labeled ''Fee Proposal for RFP #07-128." Proposals must be received by 11:00 a.m. on Friday, May 18,2007. 4 , 8.0 EVALUATION CRITERIA Qualifications will be evaluated using the following factors and assigned values, # Criteria A vailable Points 1 Quality and clarity of submission relative to the project requirements and 40 organizational approach of team 2 Qualifications and experience of key professionals, particularly related to 25 HAZMA T surveys and abatement plans, including references. 3 Fee amount 20 4 Participation of local organizations 15 Fee points will be scored as follows: Fee Points Lowest 20 . Within 5 % of lowest 17.5 Within 10% of lowest 15 Within 20% of lowest 12.5 Within 30% of lowest 10 All Others 0 Local participation will be computed as follows: Location Points Within Augusta Richmond County 15 Within the CSRA 12 Within Georgia: 9 Within SE United States (includesAL, GA, TN, NC, SC, FL) 6 Within United States 2 All Others 0 For the purposes of this RFQ, the CSRA (Central Savannah RiverArea) consists of these Counties in GA and SC: Georgia: Richmond, Columbia, Burke South Carolina: Aiken In the event of a joint venture or similar agreement, with fIrms from different regions/point categories, the teams' points will be calculated in accordance with the following example: Team Member Location . Points Fee % Factored points A Augusta 15 30% .3 x 15 = 4.5, B Atlanta 9 55% .55 x 10 = 4:95 C New York 2 15% .15 x 2 = 0.3 Total Calculated Team Points: 9.75 5 - 9.0 SCHEDULE Advertise Enviro Engr' g PH II Mandatory Pre-Proposal Conference Proposals Due Env Engr NTP Produce Remediation Plan, Remove UST's BidlNegotiate Demolition Note: Schedule is preliminary and subject to change AprilS, 12, 19,26,2007 April 27, 2007 @ 10:00 a.m. May 18,2007 @ 11:00 a.m. June 2007 June - August 2007 August 2007 6 10.0 FEE SCHEDULE Unit Units Rate Cost Task 1 - Asbestos Assessment Asbestos Inspection Hours $ $ Sample Collection Hours $ $ Sample Analysis 24 Samples $ $ Reporting Hours $ $ note: assume analysis of 30 samples required Subtotal $ Task II - Lead -Based Paint Assessment Lead Inspection Hours $ $ Sample Collection Hours $ $ Sample Analysis (XRF or 6010) 16 Samples $ $ Reporting Hours $ $ note: assume analysis of 20 samples required Subtotal $ Task III ~ PCB Assessment PCB Inspection Hours $ $ Sample Collection Hours $ $ Sample Analysis (8081) 5 Samples $ $ Reporting Hours $ $ note: assume anlaysis 6 samples required Subtotal $ Task IV - Abatement Plan & Specification Preparation Note: Suitable for competitive bidding Lump Sum $ Task V - Abatement Observations (Periodic) (assume 8 visits) 8 Trips $ $ Task VI - Open & Analyze USTs Lump Sum $ Task VII - Treat, Remove and Dipose of USTs Lump Sum $ Task VIII - Sample & Analysis of Soil @ USTs assume 13 required for BTEX, TPH-GRO 13 Samples $ $ assume 2 required for BTEX, TPH-GRO, TPH-DRO, PAH's 2 Samples $ $ Subtotal $ Task IX - Sample & Analysis of Groundwater @ UST's assume 1 required for BTEX Sample $ $ assume 1 required for BTEX, P AH's Sample $ $ Task X - Over-excavation of Contaminated Soil & Backfill/compaction. Cubic yards $ $ Task XI - Close Out Documentation Lump Sum $ Task XII - As-Needed (unforeseen) Consulting Services assume 4 hours 4 Hours $ $ FEE SUBTOTAL $ EXPENSES, FEES & OTHER DIRECT COSTS $ TOTAL (LUMP SUM) $ 7 .----: 11.0 PROJECT MANAGEMENT The City will be assisted by Heery International, Inc., Program Management consultants for Augusta Richmond County Capital Improvements. Project Communications prior to A ward shall be in writing, sent to: Ms. Geri Sams Procurement Director Augusta Richmond County 530 Greene Street, Rm 605 Augusta, GA 30911 The last day to submit questions to the Procurement Department is Friday, May 4, 2007 @ 4:00 p.m. 8 ~ A CONFLICT OF INTEREST: It shall be unethical for any City of Augusta business or participant directly or indirectly in a procurement contract when the employee or official knows that: (a) the employee or official or any member of the employee's or official's immediate family has a substantial interest or financial interest pertaining to the procurement contract, except that the purchase of goods and services from businesses which a member of the Commission or other City of Augusta employee has a financial interest is authorized as per a.C.G.A. 36-1-14, or the procurement contract is awarded pursuant to a. C. G .A. 45-10-22 and 45-10- 24, or the transaction is excepted from said restrictions by a.c.G.A. 45-10-25; (b) Any other person, business, or organization with whom the employee or official of any member of an employee's or officials immediate family is negotiating or has an arrangement concerning prospective employment is involved in the procurement contract. Any employee or official or any member of an employee's or official immediate family who holds a substantial interest or financial interest in a disclosed blind trust shall not be deemed to have a conflict of interest with regard to matters pertaining to that substantial interest or financial interest. I, (vendor) have read and understand the information contained in the bid specifications. Vendor Name: Address: City & State: Phone #: ( Fax # Signature: Date: RFP Item Number and Name: TillS FROM MUST BE SUBMITTED WITH RFP PACKAGE. NO EXCEPTION(S) WILL BE GRANTED 9 ~ A Certification Statement Local Vendor Preference I certify that my company meets all of the following qualifications to be eligible for the local vendor preference: (1) That my company has a fixed office or distribution point located in and having a street address within Augusta for at least six (6) months immediately prior to the issuance of the request for competitive bids or request for proposals by Augusta; and (2) That my company holds any business license required by the Augusta Richmond County Code for at least 6 months (3) That my company employs at least one (1) full time employee, or two (2) part time employees whose primary residence is in Augusta, or if the business has no employees, the business shall be at least fifty percent (50%) owned by one or more persons whose primary residence is in Augusta. . (4) Attached is a copy of my Augusta Business License. Company Name: Address: Business License Number: Phone Number: Fax Number: Owner's Name: Signature: Sworn to before me this . day of ,20 Notary Public for the State of My Commission Expires Notary Public Signature Printed Name: II VENDOR DO NOT COMPLETE II To be completed by Authorized City Representative from Business License & Inspection Department: Vendor Certified: Date: Authorized Signature This form MUST be submitted with RFP package. NO Exception ( s) will be granted 10 GUIDELINES 1. Augusta, Georgia will not be liable for any EXPENSES INCURRED by respondents in their preparation of proposals. Augusta reserves the right to reject any and all proposals and to make an award that is determined to be in the best overall interests of Augusta, Georgia. Under no circumstance will any bid be accepted by fax or email. All RFP' s must be labeled and received in the Purchasing office by the due date and time. There will be no exceptions made for any late. lost by the post office or express camero or misdirected submittals. All bidders must submit a copy of the comr,any's business licenses. 2. JOINT PROPOSALS will be accepted; however, Augusta, GA reserves the right to select the most qualified underwriters. 3. Augusta reserves the right to make any INQUIRES regarding any proposals of any or all respondents and. request additional information. 4. When submitting your proposal FEE STRUCTURE. Price information shall be separated from the proposal in a sealed envelope and opened only after the proposals have been reviewed 'and ranked. The names of the respondents will be identified at the proposal opening; however, no proposal will be handled so as to permit disclosure of the detailed contents of the responses until after award of contract. A record of all responses shall be prepared and maintained for the files and audit purposes. Please include the fee structure in a separate sealed envelope. 5. PUBLIC INSPECTION. The responses will be open for public inspection only after contract award. Proprietary or confidential information marked, as such in proposals will not be disclosed without written consent of the offeror. 6. EV ALUA TION AND SELECTION. The Request for Proposals shall state the relative importance of price and other evaluation factors that will be used in the context of proposal evaluation and contract award. 7. SELECTION COMMITTEE. A selection committee, minimally consisting of representatives of the purchasing office, the using agency, and the'Administrator's office or their choice shall convene for the purpose of evaluating the proposals. 8. PRELIMINARY NEGOTIATIONS. Discussions with the offerors and technical revisions to the proposals may occur. Discussions maybe conducted with the responsible offerors who submit proposals for the purpose of clarification and to assure full understanding of, and conformance to, the solicitation requirements. Offerors shall be accorded fair and equal treatment with respect to any opportunity for discussions and revision of proposals and such revisions may be permitted after submission and prior to award for the purpose of obtaining best and final offers. In conducting discussions, there shall be no disclosure of information derived from proposals submitted by competing offerors. 9. FINAL NEGOTIATIONS AND LETTING THE CONTRACT. The Committee shall rank the technical proposals, submitted by each offeror, and request final and best offers from the top ranked three firms if available. A ward shall be made or recommended for award through the Augusta Administrator, to the responsible offeror whose proposals is determined to be the most advantageous to the Augusta, GA, taking into consideration price and the evaluation factors set forth in the Request for Proposals. Other factors or criteria shall be used in the evaluation. The contract file shall contain a written report of the basis on which the award is made/recommended. The contract shall be awarded or let in accordance with the procedures set forth in the Request for Proposals. Other factors or criteria shall be used in the evaluation. The contract file shall contain a written report of the basis on which the award is made/recommended. The contract shall be awarded or let in accordance with the procedures set forth in the Augusta, Georgia Code. 11 10. PROHIBITION AGAINST CONTINGENT FEES. It shall be unethical for a person to be retained, or to retain a person, to solicit or secure the Augusta contract upon any agreement or understanding for a commission, percentage, brokerage, or contingent fee, except for retention of bona fide employees or bona fide established commercial selling agencies for the purpose of securing business. 11. RIGHT OF REJECTION. We reserve the right to accept or reject any or all responses to this RFP and to enter into discussions and/or negotiations with one or more qualified vendors at the same time, if such action is in the best interest of the Augusta Commission. 12. REQUEST FOR PROPOSALS. Proposals shall be handled in the same manner as the bid process as described above for solicitation and awarding of contracts for goods or services with the following exceptions: (a) Only the names of the vendors making offers shall be disclosed at the opening. .(b) Content of the proposals submitted by competing persons should not be disclosed during the process of the negotiations. (c) Proposals shall be open for public inspection after the award is made. (d) Proprietary or confidential information, marked as such in each proposal package, shall not be disclosed without the written consent of the offeror. (e) Discussions may be conducted with responsible persons submitting proposals determined to have a reasonable chance of being selected for the award. These discussions will only be for the purpose of clarification to assure a full understanding of the solicitation requirement and responsiveness thereto. (f) Nonmonetary revisions maybe permitted after submissions and prior to award for the purpose of obtaining the best and final offers. (g) In conducting discussions with the persons submit~ing the proposals, there shall be no disclosure of any information derived from the other persons submitting proposals.. 13. AUGUSTA, GA COMMISSION RIGHT TO INCORPORATE PROPOSALS INTO CONTRACT. Upon acceptance of the vendor proposals by the Augusta Commission, the vendor shall enter into a contract with Augusta to provide the services called out in this RFP. This RFP and the winning proposal shall be incorporated for reference into the contract. 14. USE OF CONFIDENTIAL INFORMATION. It shall be unethical for any Augusta employee or official knowingly to use confidential information for actual or anticipated personal gain, or for the actual or anticipated personal gain of any other person. 15. PREFERENCE FOR LOCAL SUPPLIERS AND CONTRACTORS. (a) Augusta encourages the use of local suppliers of goods, services and construction products whenever possible. Augusta also vigorously supports the advantages of an open competitive market place. Nothing in this Section shall be interpreted to mean that the City Administrator or Purchasing Director is restricted in any way from seeking formal bids or proposals from outside the Augusta market area. (b) When the quotation or informal bids selection method is used by the Purchasing Director or using agency head to seek firms to quote on Augusta commodity, service and construction products, local firms should be contacted, if possible, first. Then if the Purchasing Director or using agency head believes that there may not be at least three qualified informal bidders, quotes shall be sought from outside the Augusta market area. . (c) In the event of a tie of bid (see 1-10-43 (h)), when all other factors are equal, the City Administrator is encouraged to select the bid from within the local market area. The City Administrator shall retain the flexibility to make the award of contract to a bidder outside of the local market area if evidence supports collusive bidding in favor of a locai source. . 12 (d) The local vendor preference policy shall be applied when the lowest local bidder is within 5 % or $10,000, whichever is less, of the lowest non-local bidder. The lowest local bidder will be allowed to match the bid of the lowest non-local bidder; if matched, the lowest local bidder will be awarded the contract. . For purposes of this section, "local bidder" shall mean a business which: 1) Has had a fixed office or distribution point located in and having a street address within Augusta for at least six (6) months immediately prior to the issuance of the request for competitive bids or' request for proposals by Augusta; and 2) Holds any business license required by the Augusta~Richmond County Code and 3) Employs at least one (1) full time employee, or two (2) part time employees whose primary residence is in Augusta, or if the business has no employees, the business shall be at least fifty percent (50%) owned by one or more persons whose primary residence is in Augusta. e) The Purchasing Director shall develop a program to routinely search out local firms that offer products or services which Augusta may purchase and encourage such firms to place themselves on the bidder's list. (f) The Purchasing Director shall work closely with Augusta's Disadvantaged Business Enterprise Program (see Article 7) in an effort to place such qualified firms on the approved list and their products on the qualified products list. (g) Nothing in this section shall be interpreted to mean that the City Administrator may abrogate the provisions ofO.C.G.A. 36-10-1 through 36-10-5, Public Works Contracts. This provision of the State Code requires that all County public works contracts of $20,000 or more as defined therein, be publicly advertised before letting out the contract to the lowest bidder. Further, nothing in this section shall be interpreted to mean the City Administrator may abrogate the provisions of the Augusta-Richmond County Code requiring public advertising before letting certain contracts." Section 2. This Ordinance shall become effective upon adoption. All Ordinances or parts of Ordinances in conflict with this Ordinance are hereby repealed. Section 3. Section 4. If any section, provision, or clause of any part of this Ordinance be declared invalid or unconstitutional, or if the provisions of any part of this Ordinance as applied to any particular situation or set of circumstances be declared invalid or unconstitutional, such invalidity shall not be construed to affect portions of this Ordinance not so held to be invalid, or the application of this Ordinance to other circumstances not so held to be invalid. It is hereby declared as the intent that this Ordinance would have been adopted had such invalid portion not be included herein. This ordinance shall become effective May 16,2006. 13 May 22, 2007 ORIGINAL n A Technica.l Sprv~es FirmP MS.Geri A. Sams, Procurement Director 530 Greene Street, Room 605 Augusta, GA 30911 Subject: Augusta, Richmond County, Georgia Request for Proposal Item #07-128 Phase II Environmental Engineering Services for the New Main Library Dear Ms. Sams Cosby, Everett & Wright, LLC. (CEW) and our Team subcontractors (Metcalf & Eddy, CCI, Thompson Demolition [Local Vendor] and Severn Trent Laboratory) have strategically aligned to benefit the City of Augusta; we bring the resources, experience, and drive of highly reputable, diverse, and stable individuals, each with a commitment to being a part of the Augusta business community for the long haul. ) We bring exactly the demonstrated success, technical accomplishment, and cooperative spirit the. City needs to achieve a clean closure for the property slated to become part of the footprint for the new Augusta Main Library. The CEW Team has the capability to implement all of the various elements of the Scope of Services and to Pcomply with the schedule of the commencement and completion of the services as required by the City." Our Team recognizes that Reery International, Inc., is the Augusta-Richmond County, Program Management Consultant for Capital Improvements, and the Project Manager for this RFP. Therefore, our technical approach to this contract recognizes the City's programmatic requirements, and is sensitive to the specific needs and processes of the City and the specific requirements of this individual project. We have carefully reviewed and considered all aspects of the City's Request for Proposal (RFP) and prepared a proposal and corresponding cost estimate that we believe is responsive in all respects. CEW hereby states that we take no exceptions to the requirements of the contract provided in the RFP. Please forward questions concerning our proposal to our Project Manager, John Wright at (404) 933-2250 or at iwright@cewtechservices.com. We genuinely appreciate the opportunity to submit this proposal to Augusta, Richmond County. S~~ J~~:~f?'w! Managing Partner COSBY, EVERETT & WRIGHT, LLC "A CONSULTING AND TECHNICAL SERVICES FIRM" 366 AUGUSTA AVENUE . ATLANTA. GEORGIA 30315. TELEPHONE: (404) 933-2250. FACSIMILE: (404) 627-2250 "A Technical S..vlc~. Firm" Cosby, Everett & Wright,LLC. } Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 J Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 TABLE OF CONTENTS A SCOPE OF SERVICES................ ..... ........ ....... ............. ..........................1 Al PHASE 1 - HAZMATSURVEYS.......... .... ....... .......... ............. ..... ...2 Al.l Asbestos Containing Material (ACM). ...... ... ...... .............. ...... ...2 Al.2 . Lead Containing Material (LCM).. ... ........ ......... ...... ............ .....3 A.l.3 PCB Inspection......... .........................................................4 A.IA Other Suspected Hazardous Materials. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .4 A2 PRODUCTION OF ABATEMENT PLANS. . .. . . . . . . . . . . . . . . . . . . . . . . .. . . . . . . . . . . ...4 A.3 PHASE II - UST REMOV AL...... .......... .......... ....... ...... ......... .........5 AA PHASE III - REMEDIAL ACTION PLANS........................................7 A5 PHASE IV - OVERSIGHT OF REMEDIAL ACTIVITIES.................... ...8 B. EXPERIENCE AND CAPACITY............................................................ ...8 ) B.l B.2 EXPERIENCE........................................................................... 9 CAPACITY. . . . . . . . .. . . . . . . . . . . . . . . . . . .. . .. .. . . . . . . . . . . . . . .... . . .. . . .. . . . . . . . . . . . . . . . . . . .10 C. REFERENCES........................................ ............................................ ..12 D. PERSONNEL........................,..............................,....................,...... ...18 E. FEE SCHEDULE..................................................................................30 APPENDICES A CITY OF AUGUSTA ADDENDUMS B CONFLICT OF INTEREST FORM C CERTIFICATION STATEMENT - LOCAL VENDOR PREFERENCE D CONTINGENCES ATTACHMENTS A EXPERIENCE MODIFICATION RATE I t @2007 Cosby, Everett & Wright, LLC Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 A. SCOPE OF SERVICES For this project, CEW has the resources needed to handle all aspects of the Phase II Environmental Engineering Services for the New Main Library. Our environmental and engineering staff while small is diverse, and strong and has been privileged to work with a wide range of clients, including healthcare systems, institutions of higher learning, state agencies, government entities, industrial entities, and many within the private sector. BACKGROUND. This project specifically consists of conducting a professional hazardous materials survey of two structures; the production of abatement plan; and the removal and closeout of four (4) in-ground underground storage tanks (USTs) ( 3-2,000 G and 1-550 GUST) and the oversight of the subsequent removal action of a former gasoline filling station (most recently used as a car wash) and an adjacent 2-story commercial building (412 9th Street) both of which are located at the southeast comer of 9th and Greene streets. The buildings because of their age are suspected to contain hazardous materials such as asbestos lead, PCBs, mercury, waste oil, fuel, transmission fluid, and potentially radioactive materials. The soils on the property could be impacted by all, none, or any combination thereof of the suspected waste products. The USTs were abandoned in- place in 1969 without a "Clean Closure" designation from the GA EPD. CEW is proposing for this project four phases: Phase I (hazardous material surveys), Phase II (UST Removal), Phase III (Development of Remedial Action Plans) and Phase IV (Oversight of the Remedial Activities). This approach has been developed in response to the Augusta- Richmond County Phase II Environmental Engineering Service for the New Mani Library RFP and preliminary review of existing data. The following sections of this proposal will describe: . How the services outlined in the RFP will be provided, including a detailed listing and description of tasks and deliverables . Background and experience of our firm including our demonstrated ability to provide the required services, . List of complete references for work completed that is similar in scope and size to this project . Our key professionals that will be directly involved with this project, their resumes with specific emphasis on their relevant experience, . CEW's insurance coverage; Workers Compensation; General Liability; Pollution Liability; and Professional Liability Insurances, and . Our fee schedules in separate sealed envelope per the RFP's instructions. . -41'_.~"_,,,,,',,'" <<)2007 Cosby, Everett & Wright, LLC. Page 1 Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 A.I Phase 1- HAZMA T Surveys The overall goal of Phase I activities is to provide supporting documentation for the production of abatement work plans and to develop an approach for the oversight of the actual abatement work. Prior to performing the hazardous material surveys a Health and Safety Plan will be prepared for the two structures present on-site. The plan will identifY the level of protection needed to prevent exposure to contaminants present at the site. Level D personal protection equipment is expected to be used during the geotechnical investigation outside of the waste boundaries. Drilling or excavating activities associated with the USTs may require Level C protection, because of the potential of unknown hazards and established respiratory protection standards. The plan will also identifY the chemical and physical hazards present at the site and an emergency evacuation route. Special attention will also be given to areas of the facilities that are insufficiently lighted to allow effective hazardous materials assessment. The hazardous materials surveys will include suspected asbestos containing materials (ACM), suspected lead-containing materials (LCM), suspected Polychlorinated Biphenyls (PCB), and other suspected hazardous materials such as mercury, waste oil, fuel, transmission fluid, radioactive materials, contaminated soil, etc. within the property boundaries. The methodologies for these surveys will be conducted are presented in the following sections. A.I.I Asbestos Containing Materials } .? The purpose of the ACMs assessment is to establish the relative ability of various types of ACMs to release fibers into the air should they be disturbed. An assessment was carried out by CEW personnel as part of the site tour on April 27 2007, as it requires no knowledge about the building . use etc. Our experienced, well-trained AHERA- Certified Asbestos Inspector, familiar with the range of asbestos products, determined that some of the material present in the two buildings can be 'presumed' to contain asbestos. However, this presumption can only be verified via testing by laboratory analysis of representative samples of the materials. A low magnification stereo microscope examination of the sample followed by polarized light microscopy (PLM) of selected fibers is the most widely used and cost-effective method in current use. The suspect ACM samples will be sent to Severn Trent laboratory, of Savannah, Georgia. . CEW is experienced in conducting three types of ACM surveys. The three types are as follows: , ) TYPE 1: LOCATION AND ASSESSMENT SURVEY (PRESUMPTIVE SURVEY) The purpose of the survey is to locate, as far as reasonably practicable, the presence and extent of any suspect ACMs in the building and assess their condition. This survey essentially defers the need to sample and analyze for asbestos (or the absence thereof) until a later time (eg prior to demolition or major refurbishment). The owner bears potential additional costs of management for some non-asbestos-containing materials. All areas should be accessed and inspected as far as reasonably practicable (eg abqve false ceilings and inside risers, service ducts, lift shafts, etc) or must be presumed to contain asbestos. Any material which can reasonably be expected to contain asbestos must be presumed to contain asbestos, and where it appears highly likely to contain asbestos, there should be a strong presumption that it does. All materials which are presumed to contain asbestos must be assessed. @2007 Cosby, Everett & Wright, LLC+ Page 2 "AT,du.ll-alS."IrnFI,m" '$ Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 TYPE 2: STANDARD SAMPLING, IDENTIFICATION AND ASSESSMENT SURVEY (SAMPLING SURVEY) The purpose and procedures used in this survey are the same as for Type 1, except that representative samples are collected and analyzed for the presence of asbestos. Samples from each type of suspect ACM found are collected and analyzed to confirm or refute the surveyor's judgment. If the material sampled is found to contain asbestos, other similar homogeneous materials used in the same way in the building can be strongly presumed to contain asbestos. Less homogeneous materials will require a greater number of samples. The number should be sufficient for the surveyor to make an assessment of whether asbestos is or is not present. Sampling may take place simultaneously with the survey, or as in the case of some larger surveys, can be carried out as a separate exercise, after the Type 1 survey is complete. TYPE 3: FULL ACCESS SAMPLING AND IDENTIFICATION SURVEY (PRE-DEMOLITION/MAJOR REFURBISHMENT SURVEYS) This type of survey is and may involve destructive inspection, as necessary, to gain access to all areas, including those that may be difficult to reach. A full sampling program is undertaken to identify possible ACMs and estimates of the volume and surface area of ACMs made. The survey is designed to be used as a basis for tendering the removal of ACMs from the building prior to demolition or major refurbishment so the survey does not assess the condition of the asbestos, other than to note areas of damage or where additional asbestos debris may be expected to be present. ) CEW has determined, based on the site walk through, that a Type 3 Survey will be implemented to locate, describe, and sample as far as reasonably practicable; all ACMs in the building. Approximately 30 samples will be taken to confirm the presence ACMs. The analytical results will be summarized in a report and added to the overall abatement workplan. A.1.2 Lead Containing Materials CEW will conduct a limited. risk assessment that involves limited paint and dust sampling as described in 40 CFR 745.227<<J). The on-site lead assessment investigation will be conducted to specifically determine and report the existence, nature, severity and location of lead-based paint hazards in the residential dwellings, including --(A) information gathering regarding the age and history of the housing and occupancy by children under age 6; (B) visual inspection; (C) limited wipe sampling or other environmental sampling techniques; (D) other activity as may be appropriate; and (E) provision of a report explaining the results of the investigation. The suspect lead-based paint samples will be sent to Severn Trent laboratory, of Savannah, Georgia for analysis using the Inductively Coupled Plasma method. The Risk Assessment report will include a summary that answers two basic questions: 1) Is there lead-based paint hazard at the property? 2) If there is a lead-based paint hazard, where is it located and what is its condition? ) Lead in soil cleanup levels are based specifically on land use determinations. For residential land use, the soil cleanup level isset at 400 mg/kg. For commercial or industrial land use, the cleanup level is set at 1,000 mg/kg. An alternative cleanup level may be proposed through an approved risk assessment. The lead screening level for soil is set at 40 mg/kg, one-tenth of the residential cleanup level. The screening level for lead in groundwater is set at 0.0015 mg/L. (92007 Cosby, Everett & Wright, LLC. Page 3 .AT..,f...hIS....k-nftom" f Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 Note: While the Lead Rules are only mandatory for specified lead-based paint activities in target housing and child-occupied facilities, other building owners can make any or all of them mandatory for their projects by placing them in their project specifications. This voluntary use of the Lead Rules for circumstances in which they are not mandatory can help control lead hazards and reduce legal liability, In addition to the Lead Rules, which are limited to target housing and child occupied facilities, there are three other sets ofEPD Rules that can be applied to all building and facility projects: . HAZARDOUS SITE RESPONSE INVENTORY (HSRI) RULES, which require.a limited choice of actions when soil is found to contain more than 400 PPM lead, and . SOLID WASTE RULES, which require non-hazardous waste to be disposed of offsite at a landfill permitted to receive such wastes, and . HAZARDOUS WASTE RULES, which allows residential waste to be exempted from Hazardous Waste determination, but requires lead-contaminated waste from other sources to be tested by Toxicity Characteristic Leachate Procedure (TCLP) to determine if it is Hazardous Waste. A.1.3 PCB Inspection CEW will assess the buildings' fluorescent light fixtures, transformers, and other equipment for . PCBs. PCB in soil cleanup levels are based on land use determinations as well. For residential land use, the subsurface and surface soil cleanup levels are 10 mglkg and 1 mglkg, respectively. For commercial or industrial land use, the cleanup level 4 for PCBs in surface soils is 10 mglkg and for subsurface soil is 25 mglkg. A responsible person may also propose an alternative cleanup level through an approved risk assessment. The PCB screening level is equal to 0.1 mg/kg, one- tenth of the residential surface soil cleanup level. These values are for total PCBs and not the individual congener or Aroclors. The screening level for PCBs in groundwater is set at 6.0005 mg/L. The suspect PCB samples will be sent to Severn Trent laboratory, of Savannah, Georgia. A.1.4 Other Suspected Hazardous Materials CEW will also identify and categorize all other suspected hazardous material associated with the site and can include such waste as mercury, waste oil, fuel, transmission fluid, radioactive materials, contaminated soil, etc. within the property boundaries. A.2 Production of Abatement Plans \ J At the conclusion of the assessments a HAZMA T Building Survey Report with individual sections for each type of hazardous material that is identified will be prepared. The sections will describe the location, condition, and extent of the hazardous material, an estimated abatement cost, and an estimated schedule for the subsequent abatement. The report will also contain a summary of the findings and recommendations for remedial action. Two (2) bound copies and one (1) unbound copy of the HAZMA T Building Survey Report will be delivered to the City project manager <<J2007 Cosby, Everett & Wright, LLC. Page 4 .AT..d"'i<.ISn.IrnFh.... ~ ;~ ; Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 A.3 Phase II - UST Removal The objective of this assessment is to confrrm whether the former underground storage tanks (USTs) are present or absent at the site and to evaluate whether the subsurface soils and/or groundwater (if encountered) have been impacted with chemicals of concerns (COCs) associated with the USTs. Additionally, this assessment will be performed to delineate the horizontal and vertical [maximum depth of 16 feet below ground surface (ft-bgs)] extent of subsurface impacts. The analytical costs presented herein are based on the submittal of specific soil samples (total of 15 soil samples and 2 groundwater samples) to identify UST related COCs. Analytical costs associated with a hazardous waste characterization profile are included within this cost estimate. At least 30 days prior to closing the USTs, CEW will complete and submit an original signed Closure Activity Form (GUST-29) to the Underground Storage Tank Management Program (USTMP) at the GAEPD. The form is included in Appendix A. CEW will also contact the local fire marshal and the Utilities Protection Center before beginning an UST closure. The fire marshal and sometimes other local governmental agencies have jurisdiction over USTs and may require their oversight during removal. State law requires you to notify the Utilities Protection Center at 1-(800)-282-7411 at least 72 hours before you start to dig. We will consult with City Project Manager about construction permit requirements. Specific tasks associated with this assessment are discussed below. TASK 1 - HEALTH & SAFETY PLAN A site-specific Health and Safety Plan will be developed to include the proposed and potential anticipated field services to be implemented at the New Main Library property. The purpose of this plan is to provide guidance procedures to ensure the personal safety and protection of the CEW field personnel performing the assessment. This plan will address the project-specific activities and supplement CEW's health and safety policies, rules and regulations. Also in this task, CEW will prepare the field equipment to be utilized and secure the materials to be consumed during field activities. In addition, CEW will coordinate with City of Augusta representatives on the location of site-specific utilities; subcontract a geoprobe subcontractor, and an analytical laboratory which l;1as provided demonstrated Quality Assurance/Quality Control (QAlQC) programs acceptable to the City of Augusta, the U.S. EP A, GA EPD and CEW. TASK 2 - GEOPROBE INVESTIGATION CEW proposes to attempt to advance a total of 10 to 15 geoprobe borings (based one day of probing activities) to a total depth of 12 ft-bgs at specific locations throughout the facility. The location of the borings will be field-selected and will be based on information provided by site representatives regarding the location of the former USTs. Once, the USTs are identified and confirmed, a step-out approach will be used to delineate the boundaries of the contamination. Screening criteria used to identify the boundary limits of the contamination is discussed below. Soil Sampling and Screening Procedures Geoprobe actlvItIes will consist of the advancement of sample rods by hydraulically pushing or hammering the rods to the designated sample collection depth. Soil samples will be collected by hydraulically (f)2007 Cosby, Everett & Wright, LLC. Page 5 Augusta, Riclunond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 pushing or hammering a I V4-inch diameter piston-type sampler to the top of the desir~d sample interval. The piston within the sampler will then be released and the pipe advanced though the sample interval. The soil core will enter the sampler, which contains a non-reactive plastic or stainless steel liner. After the sampler is retrieved, the liner containing the soil column will be removed, and a portion of the soil sample will be placed into a Ziploc baggie for field screening and laboratory analysis. Soil probe sample collection rods will be decontaminated by steam cleanin.g prior to the initiation of sample collection activities and between each sample location. Soil sampling equipment will be decontaminated with a non-phosphate detergent (Alconox) and distilled water wash, followed by a triple rinsing with distilled water between each sample collection event. Each soil probe will be continu6usly sampled on approximately four foot centers. Soil samples will be examined in the field for the purpose of describing soil lithology and assessing the potential presence of contamination. Soil samples will be visually classified in accordance with the Unified Soil Classification System (USCS), equivalent to ASTM D 2488. Sample depth, lithology, color, structure, staining, and hydrocarbon observations (if any) will be described and recorded. In order to minimize analytical costs, CEW proposes to assess the horizontal extent based on visual and olfactory signs of impact to native soils due to chemical impacts (soil staining). Additionally, to identify COCs associated with the historical operation of the property, soil samples will be collected from areas of investigation exhibiting apparent signs of oil and gas impacts and submitted for laboratory analysis. Groundwater Sampling Procedures (If applicable) In the event shallow groundwater is encountered, groundwater samples will be collected from four of the ten (10) geoprobe locations for a general field water quality parameter evaluation. Collected groundwater samples will be tested for pH, specific conductivity (Se), temperature (T), and oxidation potential (REDOX). Additionally, it should be noted that two (2) groundwater samples will be submitted for laboratory analysis. The purpose of this phase of the investigation is to assess whether the shallow groundwater underlying the former gas station has been impacted by oil and gas related COCs. The groundwater collection process will involve hydraulically pushing a steel drop screen to the prescribed depth, and when reaching the sample collection depth, the bottom of the drop screen pipe will be opened, and groundwater will be allowed to enter the sample pipe. The groundwater sample will be collected with a stainless steel check valve connected to dedicated polyethylene tubing. The tubing will be lowered and raised until sufficient groundwater has been collected to perform a general field water quality evaluation. \ J Laboratory Analysis For proposal estimates, a maximum of five (15) soil samples and . two (2) groundwater samples will be submitted for laboratory analysis. The soil samples will be analyzed for pH (laboratory), BTEX, TPH-GRO, TPH-DRO and PAH's. The analyses selected are based on the most probable COCs present at the site from the operation at the former property. Samples will be sent to Severn Trent laboratory, of Savannah, Georgia <<;)2007 Cosby, Everett & Wright, LLC. Page 6 I;.,{ Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 As previously mentioned and if applicable, groundwater samples will be collected from the newly installed soil probes after purging sufficient volumes from each probe to ensure that the SC, T and pH measurements of the purged water have stabilized. Laboratory analysis for two (2) samples will be performed on the collected groundwater samples. Samples for laboratory analysis will be placed in pre-cleaned glass jars and capped with fluorocarbon-lined lids." Each sample jar label.will include the location, ID number, depth, date, time, sampling personnel, and analyses required. This information will also be entered on a Chain-of-Custody (Cae) form. Each sample will then be chilled to a temperature of approximately 40 Celsius by placement in a cooling chest containing . containerized ice or coolant for shipment to an approved laboratory for analysis. The Chain-of-Custody form will also serve as documentation of sample collection, description, location, and laboratory receipt. Plug and Abandonment Procedures After completion of soil and groundwater sampling, each probe location will be plugged and abandoned with a 5% bentonite- cement slurry from the total depth of investigation to the ground surface. The soil probe will be finished flush with the surrounding surface. All plugging and abandonment procedures will be conducted in accordance with applicable state regulations. TASK 3 - MANAGEMENT OF FIELD-DERIVED WASTE Soil cuttings, purged water, and decontamination fluids generated during the field investigation will be placed into individual drums, labeled, and sealed. A drum inventory will be prepared, and these drums will be relocated on-site for temporary storage pending analytical laboratory results. . If the laboratory results indicate cac impacts above action levels, the proper characterization and disposal of the field-derived wastes will be handled according to applicable federal, state and local regulations during any subsequent remedial activities, and is not included in the Scope of Services for this investigation. TASK 4 - REpORTING Upon completion of the field investigation, a letter report detailing the findings of the investigation and. recommendations for any corrective action measures will be prepared. The report will include, but will not be limited to, the following topics: · Site-specific and regional geologic and hydrogeologic conditions; · Discussion of field procedures and investigation activities; · Evaluation of the soil and groundwater sampling analytical results and comparison of the results to applicable remedial action goals; and, · Conclusions and recommendations. A.4 Phase III - Remedial Action Plans ) The CEW project manager will meet with the City Project Manager to discuss the finding and recommendations of the HAZMAT Building Survey Report prior to preparing the abatement specifications and plans. ~2007 Cosby, Everett & Wright, LLC. Page 7 .AT..,hnl<.Is....i<oo.FI..... Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 CEW will then prepare and submit for review two (2) bound sets of Contract Documents to be used by contractors to prepare fixed cost bids for the abatements and subsequent removal actions. The Contract Document will include specifications, drawings, photographs, work procedures, air sampling procedures, disposal requirements, and other work needed to define the scope of work for Georgia-licensed abatement contractors. The Contract Documents will require that all abatement work be done in accordance with Federal, Sate, and Local regulations, including but not limited to: 40 CFR 61 Subpart M (NESHAP) 40 CFR 763 (AHERA) 29 CFR 1926.1101, AND 29 CFR 1910.134 After approval of the draft Contact Documents by the City project manager, one (1) final set of reproducible Contract Documents, suitable for inclusion in the demolition bid documents or a Request for Proposal (RFP), will be submitted to the City Project Manager. A.S Phase IV - Oversight of Remedial Activities CEW will work closely with the City Project Manager to coordinate Pre-Proposal Conference and subsequent tour of buildings for the prospective demolition contractors. Once the bids are submitted, CEW will assist in reviewing the bids or proposals. for the most respondent bidder to conduct the remedial action. CEW will also provide oversight of abatement and remedial activities including monitoring of hazardous materials removal, compliance with contract documents, and compliance with air sampling and testing procedures. As part of the abatement and remedial action oversight CEW will specifically conduct air monitoring; daily site observation reports; photographic documentation log, sample analytical data package, copies of waste manifests and their respective disposal facilities, certificates of destruction and lor final disposition of the various waste stream and all certification that work complies with applicable Federal, State, and Local laws and regulations. The report will be submitted to the City Project Manager within 30 days of completion of abatement work. CEW will also provide additional professional consulting on an "as needed" basis for issues of environmental concern that may arise after the completion of the project, including correspondence with GA EPn through the City Project Manager to ensure that any and all concerns with the Clean Closure report are addressed in timely manner. B. EXPERIENCE AND CAPACITY } This section describes the background and experience of the firm's ability to provide the services outlined in the RFP. The experience is based on contracts awarded to, or conducted by, members of CEW and our team. ~)2007 Cosby, Everett & Wright, LLC. Page 8 .~T.dl..i<.Is..,.Io.."b"" t ~- Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 B.1 Experience CEW provides the specialized management consulting services that assist clients in identifying industry-specific problems and defining appropriate solutions. We also provide the technical services required to implement these solutions. We believe that we are Ii leader in this market and understanding our Client's needs has and will distinguish CEW from our competitors. Since our inception in 2006, the partners of CEW have previously provided innovative consulting and engineering services to CERM, Montgomery Watson Harza and Tetra Tech, respectfully. For these firms the partners were very successful in leveraging this foundation of scientific and engineering capabilities into other areas, including infrastructure, operations and communications. Our services are provided by a broad range of professionals including: biologists, chemists, civil engineers, computer scientists, environmental engineers, environmental scientists, geologists, hydro geologists, and mechanical engineers. Because of the experience that we haye gained from thousands of completed projects, we maximize opportunities to apply proven solutions to client problems without the time-consuming process of developing new approaches. Our clients have become subject to an increasing number of frequently overlapping Federal, state and local laws concerned with the protection of the environment, as well as regulations promulgated by administrative agencies pursuant to these laws. We provide services with respect to Federal environmental laws and regulations including: the Clean Water Act; the Resource Conservation and Recovery Act; the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA); the National Environmental Policy Act; the Safe Drinking Water Act; and other laws. Because of these Federal statutes environmental laws can impose extensive liability on owners and operators of contaminated property, therefore Environmental Site Assessments (ESA) have become a critical element of the majority of commercial and industrial real estate transactions. CEW perform ESA's and environmental due diligence assessments for both developed and undeveloped properties where we seek to identify actual or potential adverse environmental conditions. Through the use of sound remedial management methods, technical expertise and regulatory awareness, CEW will be assisting CCI with the actual removal of the USTs, subsequent over- excavation and backfilling of the site. CEW will conduct the sampling of the UST's, groundwater if encountered, and backfill used to fill the excavation. CCI has been providing a wide range of environmental services for over 15 years. CCI' s personnel have been involved in projects varying widely in scope and level of protective equipment. Whether in a controlled situation involving known materials or in an uncontrolled environment, CCI can provide the environmental services and experienced personnel to evaluate, plan and implement procedures to control any environmental problem you or your company may encounter. ) THOMPSON BUILDING WRECKING COMPANY, a local vendor, will provide roll-off trucks and containers for the activities associated with the site, including handling of investigation derived wastes. Thompson will serve as a backup contractor for the asbestos assessment and subsequent abatement if needed. Thompson being located, in historic downtown Augusta, blocks away from 1Q2007 Cosby, Everett & Wright, LLC. Page 9 m --,- t.l!i. \ ; Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 the site and can provide unmatched response time with providing the roll-off waste containers. Thompson also has a state approved inert landfill. SEVERN TRENT LABORATORY -SAVANNAH was founded in 1975 and now occupies a 55,000 sq. ft.custom designed facility located in Savannah, Georgia. With a staff of 120 environmental professionals, STL Savannah has built a nationwide reputation for consistent quality performance at competitive prices by specializing in custom project management services to meet client's project~specific needs. STL Savannah maintains that scientifically sound, legally defensible analytical data is one of the most critical elements for the success of an environmental project. To ensure a project's data quality objectives are met, STL Savannah provides a superior standard of service using the latest technological advances and a strong commitment to quality, planning and customer service, If! III fi! 1!ll I Ii!i I lljj ! ._._.1 ~ I'~ !1iJ B.2 Capacity An added value that CEW brings to this project, and the City of Augusta, is a Mentor-Protege agreement with Metcalf and Eddy (M&E). This agreement fosters the on-going growth and subsequent new capabilities of CEW; and assistance in quality assurance and quality control provided the M&E's commitment to Total Quality Management and Client Service QualityTM. Metcalf & Eddy, Inc. (M&E) is a major national and international environmental engineering company, with a reputation for techniCal innovation and a strong client service orientation. M&E and its subcontractors have a strong record of service to city, federal and state agencies and private clients. ) @2007 Cosby, Everett & Wright, LLC. Page 10 .A.T.d.......IS.......FI..... '~ 1\ , Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 Founded in 1907, the company first earned recognition in water supply issues and wastewater treatment. Over the last thirty years the firm has also developed wide-ranging capabilities in aviation environmental management, environmental compliance, environmental planning and permitting, and hazardous waste remediation. The firm prides itself on its leadership with regulatory compliance issues providing solutions not just to the technical side of the environmental engineering challenges, but to the increasingly complex regulatory, institutional, and public policy issues that surround them. M&E's current employees total over 800 include civil, environmental, chemical, hydraulic structural, structural, mechanical, electrical and soils engineers; certified industrial hygienist; environmental scientist; resident representatives and construction managers; computer applications specialist; architects and planners; and a variety of specialist in support fields such as cost estimating and specification writing. The size and multi-disciplinary capabilities of this staff provide the flexibility to meet the demands of intensive, long-term projects and respond to clients short-term needs. ) Our capacity to "comply with the schedule of the commencement and completion of the services as required by the City" is demonstrated by the combined team resources that our Team brings to this project. The workforce for this project includes 8 available staff in the Atlanta/ Augusta, Richmond County area and over 800 additional staff, through our Mentor-Metcalf & Eddy, across country. The proposed individuals chosen to lead these task areas are presented in the table below. II Program Management III Health and Safety III Engineering & Environmental Services/Expertise ill Environmental Services/ Expertise Ill! Design Engineering Il Contract Administration 1lI Land Acquisition Service ll! Construction Services I ill Quality Assurance ~ Geotechnical Services/Expertise ! _~...oJl.Jj_ JI,,,,_o<llP._ ...1 II Construction Services ! II Asbestos, Lead & Mold Abatement l1! Asbestos Assessment and Abatement ill Investigation Derived Waste Handling and storage 1II Analytical Services I' j ! i i ,___ _________.J ~2007 Cosby, Everett & Wright, LLC+Page 11 Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 CEW's collective staffing approach for this contract is based upon the Project Manager's author- ity to put the best resources on projects. The staffing approach will involve aggressive resource management and planning to support the workload environment, and is patterned after other similar type, size, and scope projects the Team firms have been awarded in the past. Project team members have been selected based on their technical expertise, experience on projects of similar scope and size, support systems and resources, and their availability to begin work immediately. Asst. Project 20 BS Civil Engineer Manager Environmental 10 BS Senior Scientist Scientist Environmental 7 MS Junior Scientist Scientist Environmental 13 BS Senior Scientist Scientist Environmental 10 BS Scientist Scientist 16 Field Service Supervisor Once we determined the position and disciplinary requirements for. this contract, CEW then surveyed all our team's resources to identify the best person to fill each key position. As a result, we are confident we are offering the best available personnel our team has to offer. Our proposed key personnel have an average of 13 years of relevant project experience. CEW also has the necessary Health and Safety and Quality Assurance (Tina Houston, M&E) personnel, programs, equipment, planning tools, and standard procedures to ensure that the appropriate staff and resources are available and appropriately trained to support this program. C. REFERENCES Collectively, over the past 30 years the partners of CEW and Team firms (M&E, CCl, Severn Trent Laboratory) have performed thousands of projects demonstrating our experience, expertise, and capacity to provide the full range of resources called for in the scope of work for this contract. This depth of experience and accomplishment will provide this closely watched contract with constancy in policies, procedures, and performance. Our team firms also have numerous references that demonstrate this fact. This Section provides examples of actual, completed, or ongoing projects comparable in scope and nature to the City's projects. ) @2007 Cosby, Everett & Wright, LLC+Page 12 "\ \ .'Ii Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 ~--1 i I I i ! j I I I i I I I i John Wright, for his previous employer Tetra Tech, was i tasked to:(1) prevent or substantially reduce potential j c~xposure to total petroleum hydrocarbons (TPH) and oil I ;~pd grease (0&0) and (2) reduce potential direct .1 '.~~posure to local tributaries, waterways, and ultimately, j,.tJ.1~ Ocmulgee River. Mr. Wright instituted various '[Ftnedial alternatives to mitigate off-site migration of <S()t1tarninated surface water. Tetra Tech collected :.hundreds of water samples during the project. Tetra "~ech installed and maintained an oil-water separator },.9!1site handle stOITn water runoff. At the conclusion of .!~e removal action, over 900,000 gallons of water were .treated and discharged. I I ~ I ~~CI removed seven USTs that ranged in size from 1,000 I' c(,?~llon to 10,00.0 gallo.ns. The scope involved the I ;r~~()Val and re-mstallatIon of the tank systems. CCI i ~~,~p~talled a petroleum hydrocarbon venting transported to I <;.lllocallandfill. Re-installation of the USTs included the I ~,t~i~~:;~~ons~:t~~~~leT~:II:~:I~erf~::il~~IU~;~sOf ~~:~"I !~uipped with an inclon sentinel system capable of! ,'~~Ild~ng. a leak detection report to a central office for I .:,~oll1tonng. I I I j r i I I i ;'Xl1is project involved the removal of 30 underground I ist()fage tanks, CCI personnel backfilled and poured I jiconcrete pads for ASTs and transferred fuel from old I USTs to new ASTs. i @2007 Cosby, Everett & Wright, LLC+Page 14 'ATKhnlo~Is,....,""flt"" :li. .ii 'I ) \ J Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 ; j I . I 'CCI personnel performed removal of an AST and two I UST/ separators. The project also involved soil and I 'liquid disposal. I j ! ....... . i ;,~CI removed one 3,000 gallon UST for International I ;,faper. The project scope included barricading the area i (,~~d removing the dispensers, fuel island, and concrete I 'pad before extracting the UST. Once the UST was I .:~einoved, CCI personnel sampled the bottom and side I >Walls for possible contamination. No contamination was i 'detected and CCI filled the excavation and installed a i ~0 I :Ilew concrete pad. I . .. i I i I I ! i ! I I 'JRver the span of this contract, Mr. Wright along with I I ;~.endy Floyd managed UST Program Report backlogs ! j~~~ has performed over 2,300 Technical Reviews. I, e!ncluded among these reviews is: 430 CAP Part A rgeports, 215 CAP Part B Reports, and 1,655 Closure I !;~lans. In addition, the team has implemented CAP B I' ',;R,emediation Systems at over 15 sites in the State of "georgia. Tetra Tech has had many technical ! ~accomplishments within this contract, Among th.em are: I . Soil and groundwater sampling . Technical reviews for compliance with Federal I and State regulations and guidelines . Remediation design and oversight . Risk-based corrective actions . Construction oversight for UST removal I , ! i I i I I .___..~.,._,__,__,.._.___.___..~_._..J <<;:12007 Cosby, Everett & Wright, LLC. Page 15 .AT..,hnloallHon.....Fln... ~'.. 't. t ) Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 -------.----..-.-..---.---.---.-~--.---.--.-1 , I i i i I I I ! i I ! i i I I I i .! i I ! I i I i I j I i i I ! "", I (The State of Georgia, Environmental Protection Division I """ I (yAEPD), Hazardous Sites Response Program has I tasked Tetra Tech to provide all technical support to the i ,,(i7~igning and engineering at the Northside Drive i';~llf1dfill in order to better reduce the amount of ""contaminants at the site. The GAEPD, Hazardous Sites Response Program has "tasked Tetra Tech to provide all technical support to the designing and engineering at the Northside Drive :Landfill in order to better reduce the amount of 'contaminants at the site. 10hn Wright, for his previous employer Tetra Tech, co~ducted a methane gas soil survey at the Northside >l)rive Landfill. Methane monitoring was performed to a,ccess the potential for a explosive environment on the ',site. Tetra Tech conducted Geoprobe@ boring down to 4,Jeet bgs. Methane field screening was performed at 'a,c.cessible locations on an approximate 75- by 75-ft grid ,,~~heme. Weather conditions, including barometric ,',pressure, temperature, percent humidity and sky and 'W~nd conditions, were recorded prior to field activities arid in the afternoons. '1'1'v1r' Wright made the determination that no detectable iFlevels of methane gas existed on the site. {':\~:-:',:, !(Jglm Wright, for his previous employer Tetra Tech, ! ggwided technical support to the GA EPD to design ! e~gineering controls to minimize off-site migration of ! sp~taminants at the Northside Drive Landfill (formally I ,!l,~.l11don Homes) Site. This is the first time the State of I '(}~orgia opted to use their Type 5 cleanup criteria. Tetra I ~)'J:'ech used the information gathered durjng the site I {wxestigation to design a soil-bentonite slurry trench i j"9~!Offwall (slurry wall) in conjunction with an i !,~#gineered low-permeability cap that will divert I :"~o)ll1dwater flow around the landfill area and minimize I ,pff-site transport of contaminants by preventing contact I 'Bttween the landfill waste and groundwater. The site I ;in"estigation involved geotechnical, soil, surface water ! and groundwater investigations. Mr. Wright assisted the I i .'XAEPD with assessing the site for redevelopment or i >!lOluse for a potential Brownfield's classification given ! ,t~at the Georgia World Congress Center is anticipating ! ;'ijsing the cap to serve as a potential parking lot. Tetra "Tech continues to regularly participate, in collaboration :,With GAEPD, in community projects associated with the ", Northside Drive Landfill. <Gl2007 Cosby, Everett & Wright, LLC. Page 16 'ATKhn...1 s........ FInn" \ ~ ! ) ) Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 ------l i I John Wright, for his previous employer Tetra Tech, was retained to conduct clean closure remedial action at the Manchester Tank and Equipment Company in ,Cedartown, Georgia. Manchester Tank facility was >engaged in the manufacture of cylinders for containing .' liquid compressed gases, and other related products. 'John Wright previously conducted a limited Phase II YcESA involving a buried waste assessment (BW A) of a ;~uspected historical acid pit or impoundment at the site. <}:lIe remedial action selected for this site included: ;.~xcavation of impacted soils; confirmatory sampling of {fFx,cavation soils; hazardous waste characterization; on- ;;~i~e treatment of soil and off-site disposal of soil; \Iegrading and backfilling with clean, compacted tXJ.aterial; and onsite treatment of impacted stormwater. ..'~8il analysis indicated elevated concentrations ofVOCs .;~~follows: 1, I-Dichloroetthane, cis-l,2-Dichloretene, .,rthylbenzene, toluene, 1,1,1- Trichloroethane, TCE and y,;xylenes. At the completion of the remedial action about .'??3 tons of impacted soils were excavated and treated, ('~"I'ld transported as non-hazardous waste to the Subtitle f'p,Three Comers Regional Landfill in Piedmont, ?~.t\labama. A total of about 38,000 gallons of storm ',(;"'(ater was also treated and discharged on-site. ! i ! ;!2(;1 mobilized and began by disconnecting and I \0~p:toving a 200-gallon propane tank. The crew utilized a I !partner saw to scar and a backhoe to bust up the concrete I "y, .... . I ';9?ver over the tank to gam access. The propane tank I .;';"'(as carefully removed via a backhoe and sling. The I ',!YST contained No. 2 diesel fuel, which was removed 'I "'i~tilizing a flammable liquid rated Pl,lIllP. The tank ',spntents were placed in 17-E DOT approved drums for I ;!'~~ipment to an approved disposal! recycle facil!ty. CCII :;PFrsonnel also removed a 700-gallon UST. The tank i {~xcavation was lined with a high-visibility orange I ;~arrier fencing as means of demarking the bottom of the I ;e((cavation prior to backfilling. This barrier aided in re- I :excavation of contaminated soils pending results of! sampling analysis. CCI filled the excavation to grade I 'With crush and run in one-foot lifts with compaction I 'being accomplished by bucket tamping the material with ! ,the backhoe bucket. The propane tank was relocated and i 'connected to its original location. i I I I _.______,~_~_,.___..'_.,_~_.,___._...__. ._._._._..'...________.._ ._"'...~.._'___. ..... ~'...'_' _._,,__".~.__,.,,_".._'".._. .',." ,I @2007Cosby, Everett & Wright, LLC. Page 17 .ATK.....,.Is.-..i<'nl'lrm" .~ Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 D. PERSONNEL CEW has taken great care to ensure that we offer a team of professionals who will meet the City's needs and exceed your expectations. Our key staff has been selected because of their expertise, leadership, and reputation. The people assigned to Phase II Environmental Engineering Services for the Main Library contract lend exceptional quality to the CEW Team. As a result, we are confident we are offering the best available personnel our team has to offer. The key to any successful project is a strong project manager able to provide a single point of contact, make timely decisions, and provide recommendations based on practical experience gained through management of similar tasks. As such, we propose John Wright as the project manager for this assignment. John will be responsible for the management of all environmental, planning, and engineering segments of the project. He will also be responsible for oversight, scope definition, developing schedule and task budgets, managing the support team, monitoring progress and taking action to ensure that perfomiance meets plan. John will report directly to the City's Program Manager, Heery International, Inc. \ ) CEW Support Stafflocated in Georgia M&E, CEW, CCI, Thompson and Severn Trent Laboratory 11:>2007 Cosby, Everett & Wright, LLC. Page 18 .ATI'<""I<~IS...IoHFIt"" l Education BS, Biology, Southern University, at Baton Rouge, 1992 Coursework, MA Public Policy, Georgia Institute of Technology 1998 \ } Registra tions/certifications 40-Hour OSHA Health and Safety Training Certified Lead Inspector lO-Hour OSHA Construction Safety and Health 8-Hour Annual OSHA Hazardous Waste Operations Site Supervisor Health and Safety U.S, EPA Hazard Ranking System U.S. EP A Contractor Standard Operating Procedures and Overview U.S. EPA Quality Assurance/Quality Control U.S. EP A Safety Program Administration U.S. EPA Hazardous Materials Handling . and Shipping U.S. EPA DOT Hazmat Shipping Loss Management Safety and Health Program Administration Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 John Wright Project Manager Mr. Wright has more than 17 years of years of diverse technical and practical experience in the envirolunenta1 industry, including extensive experience in forming, coordinating, and managing multidisciplinary program and project teams within the government and private sectors. Mr. Wright specialized on a range of topics including strategic planning, institutional analysis, business process reengineering, program development and evaluation, engineering support and establishment of environmental program goals and measurements. Mr, Wright also has supported the design and delivery of conferences, workshops, and training courses on various environmental subjects and initiatives for numerous federal agency clients. Before starting Cosby, Everett and Wright, LLC, Mr. Wright, was the Southeast Operations Manager, for Dynamac Corporation and managed the operations of the Southeast offices (Atlanta, GA, Research Triangle Park, NC, and Cape Canaveral, FL) including all of the contracts, and professional and clerical staff assigned to those offices. Professional Experience PROGRAM MANAGER, STATE OF GEORGIA, HAZARDOUS SITES RESPONSE ACT (HSRA) - Mr. Wright, at Tetra Tech, served as program manager for State of Georgia Hazardous Sites Response Act (HSRA) contract - Site Investigation and Cleanup Activities Services Contract under Authority of State Superfund Law. As program manager, Mr. Wright was responsible for overall contractual and technical management of the contracts, including communicating with federal agency ordering officials; coordinating with each contract's financial manager, including the development of cost proposals; supporting Tetra Tech staff development of technical proposals, work plans, staffing plans, and schedules; tracking the financial progress of ongoing delivery orders, including preparing revenue projections and profit analyses; and ensuring the overall quality and integrity of contract deliverables. For these contracts, assigQillents included CERCLA investigation, design, and cleanup; ReRA corrective action; geographic information systems and associated databases; environmental assessments; integrated natural resource management plans; storm water and wastewater management; EPCRA reports; statistical analysis and verification of and reporting on innovative remediation technologies; groundwater monitoring, sampling, and analysis; Superfund and other regulatory support activities, various regional initiatives, sensitive public involvement issues, and coordination of challenges with numerous federal, state, and local agencies and the private sector. Professional associations Society of American Military Engineers (SAME) 2005-07 @2007 Cosby, Everett & Wright, LLC+Page 19 Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main LibraI)' FRP Item #07-128 PROJECT MANAGER, NORTHSIDE DRIVE LANDFILL, STATE OF GEORGIA, HAZARDOUS SITES RESPONSE ACT (HSRA) Program and Project Manager for the $6.8 M design-build contract for the installation and construction of the soil-bentonite slurry trench cutoff wall (slurry wall) in conjunction with an engineered low-permeability cap. Tetra Tech provided engineering design services to minimize off-site migration of contaminants at the NorthsideDrive Landfill (formally Herndon Homes) Site. It was the first time the State of Georgia utilized their Type 5 cleanup criteria for a project. Mr. Wright used the information gathered during the site investigation to manage the design of a soil-bentonite slurry trench cutoff wall (slurry wall) in conjunction with an engineered low-permeability cap that diverted groundwater flow around the landfill area and minimize off-site transport of contaminants by preventing contact between the landfill waste and groundwater. Mr. Wright also managed the prior site investigation that involved geotechnical, soil, surface water and groundwater investigations, predesign activities and laboratory analysis to establish performance criteria, verified implementability, and evaluated constructability and prepared the final design of the slurry wall and engineered cap for the Landfill Site. EMERGENCY RESPONSE ACTION SUPPORT TO EP A REGION 4. For 5+ years, Mr. Wright has served as an on-call first responder and site manager under the Region 4 TAT, START I and II programs. During this time, he worked on more than 45 emergency responses and oil spills, over 30 removal actions, and several containment projects, as well as providing support to the Regional Response Center. Mr. Wright's responsibilities included working with EPA OSCs, state and local officials, performing multimedia sampling, performing HAZCA T analysis of waste samples, and assisting the OSCs in community relations efforts and site documentation. Emergency Responses have included spills of Vinyl Chloride, Ferrous Sulfate, Hydrofloric Acid, Oil and Gas and petroleum based wastes, to name a few. CERCLA ASSESSMENT ACTIVITIES. Based on site conditions, information obtained during the removal assessment, and the potential threats to human health and the environment, Mr. Wright provided removal oversight, at sites throughout the southeast, which at minirilUm included but were not limited to the following activities: assist in maintenance of Completion Environmental Response Compensation and Liability Act (CERCLA) paperwork; organize site files in accordance with the American Record Guide document; Review site records; Conduct multimedia sampling (air, water, soil, sediment, and waste); Provide cost tracking and reporting; Document on-site activities (videotape, photographic, and written), releases, and site access; Monitor contractor performance and site safety; Prepare reports and site sketch/map, and provide Draft Removal Report to OSC; Public Relations; Support removal in accordance with OSC needs. VARIOUS PRIVATE CLIENTS 1996-2003 - Phase I and II Environmental Site Assessments of more than 50 Sites. Managed and completed Phase I Environmental Site Assessments and Regulatory Compliance Audits, and NEP A Compliance Evaluations for sites in Georgia, Florida, Tennessee, Alabama, North and South Carolina, Virginia, Utah, and Texas. Clients include: Fortune 500 Companies, real estate developers, financial institutions, investment firms, law firms, utilities, telecommunications companies, and industrial and commercial entities. Facility types assessed include: light and heavy manufacturing, rail yards, commercial developments, automotive repair and salvage facilities, landfills and historic dumps, package and cargo distribution facilities, and places of historical significance. . 11:)2007 Cosby, Everett & Wright, LLC+ Page 20 ....T..""..aIS.nloo.fl..... .~ .!f Education B,S, Civil Engineering, Louisiana State University B.S. (Zoology & Chemistry) Louisiana State University State of Georgia Board of Registration License No: PE019519 State of Louisiana Board of Registration Professional Engineer (Civil Engineering) Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 John Brunson, P.E. Civil Engineer Mr. Brunson has more than 20 years of diverse experience in civil and environmental engineering and management, solid and hazardous waste management, program management, and project management He maintains professional technical competence while understand the business and financial aspects that drive projects and schedules. He is experienced in leading and in being a part of multidisciplinary teams assembled to construct a large project with excellent quality and timely completion. He has frequently been chosen to make presentations of project information to public bodies and to private business interests. PROFESSIONAL EXPERIENCE Site investigations and assessments · Served as project manager for the assessment of contaminants associated with the removal and closure of an Industrial building containing asbestos containing materials and associated underground storage tanks at the Bolton Road Landfill site in Atlanta, GA. . ,) · Managed a Phase 1 site investigation of a pair of multistory commercial office buildings to be acquired by DeKalb County Government. · Performed numerous site investigations, and reports for a group of landfills in Southern Louisiana identifying problems and participating in revisions to solve these problems with local and senior management. Some of these issues involved permitting and or government requirement issues but most also involved company performance and quality standards that exceeded any requirements of the regulations. · Managed quarterly evaluations and reporting for groundwater assessment a group of landfills in Southern Louisiana. · Managed numerous investigations and assessments of potential landfill acquisitions throughout the Eastern US. The majority of these investigations were incomplete as once a potential fatal flaw was identified, the project was concluded without a formal report or presentation. Many of these investigations also included an economic evaluation during which facts were presented to clients and to existing owners. Quite frequently the investigation revealed potential political, economic, social or permitting issues that caused potential purchasers to reduce the amounts they were willing to risk and left the present owners looking for other purchasers who had not so carefully evaluated the identified risks. ) · Project manager for a cultural resources investigation for a site in Virginia once thought to have been occupied by historically significant figures (G. Washington, ~2007 Cosby, Everett & Wright, LLC. Page 21 \- :) Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 American Indians etc.) assessment at the site used forces from the nearby College of William and Mary's History Department to evaluate the shell middens left by Indian populations near the lowland creeks and to evaluate to assess the significance of remains of 16Th century colonial structures. . Project manager for development of a site that was near the habitat of an endangered salamander. A study was conducted using PhD level biologists to manage sampling of tadpole populations in summer and springtime ponds on the site that would become inaccessible or disappear later in the year. Results showed the absence of the species in question and the evidence, though the official report was never formally presented, it was available to answer any challenge to the permit application based on that issue that took place near October. . Project Manager for a feasibility study for a South Pacific Island nation that sought to use its otherwise disused highlands to grow trees for use as fuel. This project, funded by the US Department of Trade and Development; revealed a potential for both replacement for imported fuel oil and provision for significant jobs in the fuel gathering and drying process. Political issues mainly the question of ownership of these lands was a stumbling block to completing the project at that time. Municipal water and wastewater . Served as project manager for design and installation of a vacuum sewer system for ) parts of Sarasota County Florida. . Construction manager for installation of a package sanitary sewage treatment plant for installation on US Forest service property near a recreation facility. . Design of a small water system for a town in South Georgia that was the first public water supply for the town. Issues were cost of well treatment and the elevated water tower as well as balancing the cost with installation of pipe suitable for future full fire protection. . Permitting for a new elevated water storage tank. This required historical structure surveys for sensitive locations and dealing with the Federal Department ofFish and Wildlife to ensure that endangered species were not adversely affected. . Preparation of a grant / loan application to the US Department of Rural Development for funding of a significant wastewater treatment plant expansion for a town in north Georgia. This work required justification of the expansion based on future continued growth of population and of commercial interests. Since Federal funds were involved, the full agency review of the State Historic Preservation Officer, the Federal Department of Fish and Wildlife and compliance with endangered species requirements were conducted. All these efforts were in addition to permitting for the discharge of the facility into local streams. ~2007 Cosby, Everett & Wright, LLC. Page 22 '\ .~ Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 American Indians etc.) assessment at the site used forces from the nearby College of William and Mary's History Department to evaluate the shell middens left by Indian populations near the lowland creeks and to evaluate to assess the significance of remains of 16Th century colonial structures. · Project manager for development of a site that was near the habitat of an endangered salamander. A study was conducted using PhD level biologists to manage sampling of tadpole populations in summer and springtime ponds on the site that would become inaccessible or disappear later in the year. Results showed the absence ofthe species in question and the evidence, though the official report was never formally presented, it was available to answer any challenge to the permit application based on that issue that took place near October. · Project Manager for a feasibility study for a South Pacific Island nation that sought to use its otherwise disused highlands to grow trees for use as fuel. This project, funded by the US Department of Trade and Development, revealed a potential for both replacement for imported fuel oil and provision for significant jobs in the fuel gathering and drying process. Political issues mainly the question of ownership of these lands was a stumbling block to completing the project at that time. Municipal water and wastewater · Served as project manager for design and installation of a vacuum sewer system for parts. of Sarasota County Florida. · Construction manager for installation of a package sanitary sewage treatment plant for installation on US Forest service property near a recreation facility. · Design of a small water system for a town in South Georgia that was the first public water supply for the town. Issues were cost of well treatment and the elevated water tower as well as balancing the cost with installation of pipe suitable for future full fire protection. · Permitting. for a new elevated water storage tank.. This required historical structure surveys for sensitive locations and dealing with the Federal Department ofFish and Wildlife to ensure that endangered species were not adversely affected. · Preparation of a grant I loan application to the US Department of Rural Development for funding of a significant wastewater treatment plant expansion for a town in north Georgia. This work required justification of the expansion based on future continued growth of population and of commercial interests. Since Federal funds were involved, the full agency review of the State Historic Preservation Officer, the Federal Department of Fish and Wildlife and compliance with endangered species requirements were conducted. All these efforts were in addition to permitting for the discharge of the facility into local streams. ) <<:>2007 Cosby, Everett & Wright, LLC+ Page 22 W "$-- Education BS, Western Kentucky University, 1982 Registrations! certifica tio ns 40-Hour OSHA Hazardous Waste Site Health and Safety (OSHA 29 CFR 1910.120) to-Hour OSHA Construction Safety and Health 8-Hour Annual OSHA Hazardous Waste Operation Health and Safety 8-Hour Annual OSHA Hazardous Waste Operations Site Supervisor Health and Safety U.S. EPA Hazard Ranking System U.S. EPA Contractor Standard Operating Procedures and Overview U.S. EPA Quality Assurance/Quality Control U.S. EPA Safety Program Administration U.S. EPA Hazardous Materials Handling and Shipping U.S. EPA DOT Hazmat Shipping Loss Management Safety and Health Program Administration Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 Cindy L. Treadway Environmental ScientistlWork Assignment Manager Ms. Treadway has over 10 years of significant environmental project management experience in the environmental engineering industry. Her diverse qualifications and experience include budget negotiation, construction project management oversight, and staff development. She specializes in industry specific reporting on preliminary assessments, site inspection prioritizations, site inspections, expanded site inspections, and hazard ranking system documentation records. Professional Experience Project ManagementIWork Assignment Manager . Served as the project manager on numerous hazardous waste sites in U.S. EPA Region 4 in negotiating and managing site-specific work assignment budgets. . Conducted construction project management oversight at U.S. EP A remedial i investigation/remedial assessment sites. . Prepared monthly progress reports, variance reports, cost reports, site-specific budgets, and task order reports for the U.S. EP A Contracting Officer. . Provided project management oversight to subcontracted drilling companies responsible for the installation of stainless steel and PVC cased permanent and temporary monitoring wells. Site investigations and assessments · Served as field project manager for a remedial investigation at the ILCO Lead facility, in Leeds, Alabama, which included a major soil remediation. Soil was sampled and treated for removal and cleanup of site contaminants. · Managed a groundwater remediation project at the Kerr-McGhee facility in Jacksonville, Florida, to assess the extent of contamination of pesticides and impacts to off-site receptors. . Managed a groundwater assessment at Pensacola Gas facility in Pensacola, Florida, to assess the extent of contamination and impacts to off-site receptors. Also, conducted oversight for installation of monitoring wells at the facility. · Managed soil contamination assessment at St. Augustine Airport in St. Augustine, Florida, to determine the extent of contamination and impact of off-site receptors which resulted in a recommendation for further investigation." I 1 ~2007 Cosby, Everett & Wright, LLC. Page 23 ) , ) ) Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 . Prepared HRS Documentation Records and generated scores for Superfund sites based on Hazardous Ranking System for inclusion in NPL. Historical and analytical data was evaluated and incorporated into the HRS Documentation Record to provide characterization of onsite contaminant sources. Managed and reviewed numerous U.S. EPA Region 4 final and draft HRS Documentation Records for NPL proposal. Notable HRS Documentation Records for NPL proposal are as follows: LCP Chemicals, Eglin AFB, Escambia Wood, Normandy Park Apartments, MRI, Stauffer Chemical Company, Fort Gillem, Weekly Lumber, and Pelham Phosphate. Authored numerous site assessment reports accompanied by a site-specific Hazard Ranking System score and the final recommendation. Prepared Field Study Plans and Work Plans determining the selection of sampling locations and media to be sampled, thereby, characterizing potential hazardous contamination at the site. Reviewed and approved Field Study Plans, Work Plans, Health and Safety Plans, and site assessment reports. Conducted field sampling in accordance with the U.S. EP A Standard Operating Procedures as well as generating the site-specific Health and Safety Plan. . . . . . Prepared Site Inspection Prioritization numerous reports for submittal to the U.S. EP A. · Acted as the Field Project Manager directly responsible for the supervision of scientific teams conducting sampling and oversight. · Conducted Hazard Ranking System review of pre-remedial site assessment reports. · Acted as the Health and Safety Officer at numerous site investigations. · Identified site-specific analytical data gaps that were presented and resolved during U.S. EP A scoping meetings. Site Manager; CERCLAlSARA Site Assessments; FDEP; Various Florida Sites \ · Site Manager of the Site Inspection and Expanded Site Inspection reports prepared for FDEP. Responsible for coordination of staff efforts for the field sampling investigations. Prepared work plans and field study plans determining the sampling locations and media to be sampled to accurately characterize the site. Identified data gaps, developed schedules, and generated site-specific Health and Safety Plans. Trained personnel to prepare draft Site Inspection and Expanded Site Inspections reports to be submitted to FDEP for approval and finalization, Conducted HRS and technical reviews of Site Inspection and Expanded Site Inspection reports prepared for FDEP. . <<::'>2007 Cosby, Everett & Wright, LLC.Page 24 't ) } 1 Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 Satara Thomas Environmental Scientist Ms. Thomas brings over 7 years of experience in the management of environmental programs for the U. S. Environmental Protection Agency (EP A) and the U.S. Army Corps of Engineers (USACE). For 4 years she served as a Work Assignment Manager for private consulting firms working on the USEP A Enforcement Support Services (ESS) contract and over 2 years as a researcher for Dynamac's Potentially Responsible Party (PRP) Support contracts with the USACE. The technical activities conducted by Ms. Thomas through these contracts include all of the PRP Search, historical research, environmental records management, and other technical ' elements. Detailed information regarding these ProgramIProject Management and technical activities is presented below. Professional Experience Potentially Responsible Party Research Education BS, Molecular Biology, Florida A&M University, 1996 MS, Environmental Science, Florida A&M University, 1998 Emory University Paralegal Program, Presently Attending Registra tions/ certifications 40-Hour OSHA Health and Safety Training · Served as a Project Manager for the PRP Contracts for the USACE. Developed task orders and cost proposals, and selected key staff for implementation of PRP support to the USACE. Also responsible for the timely execution, implementation, and completion of all tasks to ensure that each project is completed on time and within budget, quality assurance/quality control reviews of deliverab1es, and the review and approvab1e of invoices corresponding to the month end period. Site investigations and assessments · Conducted over 50 Phase I Environmental Site Assessments (ESAs) to protect against liability of environmental cleanup. The ESAs consisted of a regulatory database review, aerial photograph and historic topographic review, interviews, and a noninvasive reconnaissance ofthe site and adjacent properties. · Conducted NEP A analyses for proposed telecommunication tower sites. Assessed designated wilderness areas; designated wildlife areas; endangered species or critical habitats; national register of historic places listed and eligible sites; Indian religious sites; 100-year flood plains; wetlands, deforestation; high intensity white light in residential areas; and radio frequency. . Served as a client manager for hundreds of telecommunication tower sites. Management responsibilities included data entry and tracking new work assignments, monitoring completion schedules, and preparing weekly progress reports. @2007 Cosby, Everett & Wright, LLC. Page 25 ) Education B,S" Building Construction Technology, 1986, Grambling State University Soil Identification and Determination of High Water Table Depth; Southwest Florida Water Management District, 2001 8 Hour Refresher OSHA HAZWOPER, 2004 . Radiation Safety and Use of Nuclear Soil Gauge, Humboldt Scientific Soil Augering/Coring, Ardaman . Piezometer and Monitoring well installation, Ardaman ) .' Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 Victor Nkwocha Environmental Scientist Mr. Nkwocha specializes in construction material testing, and conducts investigations relating to new construction, settlement of existing structures, roadway construction and pavement analysis, and general land development issues. Mr. Nkwocha's professional experience as an engineering technician encompasses environmental engineering, geotechnical engineering, hydrologic engineering, soil and construction materials testing, and construction inspection. He conducts safety audits and quality control inspections for commercial and residential construction as it pertains to compliance with construction specifications, including structural and building systems. Mr. Nkwocha's other responsibilities entail providing leadership to engineering technicians and training in the area of construction material testing. Professional Experience:., CITY OF ATLANTA QUALITY OF LIFE PROGRAM CONSTRUCTION INSPECTOR Mr. Nkwocka is providing inspection services for the construction of new concrete sidewalks throughout the City of Atlanta. STOCKADE BASIN CSS PROJECT, ATLANTA, GA MHJIT PROJECT, HARTSFIELD ATLANTA INTERNATIONAL AIRPORT. QC INSPECTOR As part of CERM, Mr. Nkwocha specialized in construction material testing, and conducting investigations relating to new construction, settlement of existing structures, roadway construction and pavement analysis, and general land development issues. GINARC CONSTRUCTION INC., ATLANTA, GA PROJECT MANAGER Mr. Nkwocha was responsible for the construction of concrete sidewalks. He provided overall project supervision and technical oversight. Senior Engineering Technician, Ardaman & Associates, mc, Sarasota, Florida. Mr. Nkwocha was responsible for various work activities as an engineering technician. His work involved geotechnical engineering, environmental engineering, hydrological engineering, construction inspection, and construction materials testing. ATLANTIC STATION REDEVELOPMENT, ATLANTA, GA SAFETY OFFICER Mr. Nkwocha served as safety coordinator at this 138+ acre, mixed-use site. This project consisted of horizontal construction of the infrastructure. He functioned as the Site Health and \ / ~2007 Cosby, Everett & Wright, LLC. Page 26 \ , ) ) Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 Safety Officer implemented the project health and safety manual and sampling plan for the hazardous site work. Field activities entailed site orientations, weekly and monthly meetings and reports, daily logs, and performed personnel and environmental monitoring. METRO ATLANTA RAIL TRANSIT AUTHORITY (MARTA) ENGINEERING TECHNICIAN Mr. Nkwocha functioned as an engineering technician in connection with construction ofa multi- million dollar railcar switching yard development. His field activities entail construction materials testing of soil and concrete in accordance with ASTM methods. He was responsible for quality assurance on site. ~2007 Cosby, Everett & Wright, LLC. Page 27 l Education B.S. - Geology, University of Zimbabwe/Cambridge M.S.- Earth Science (Geographic Information Systems concentration) Currently GA. State University Certified Environmental Inspector 40 hr. Hazwoper OSHA General Industry Cisco certified network Associate, 2002 Certified Asbestos Inspector Certified Lead Inspector Environmental Assessment ) Performed and developed skills on different projects University Lab Assistant in Physics, Science, and Geography Ground-penetrating radar Member of Atlanta Geologists Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 Aboulie O. Bojang Environmental Scientist Mr. Bojang comes with several years of experience in environmental, water quality and habitat assessments. He has hands on experience with building inspections for lead, testing and cleanup of affected sites, land and property. He also has software experience, such as Surpac and mapping. Mr. Bojang Provides abatement services in environmental services such as asbestos and lead abatement, survey, inspection, hazmat and selective and interior demolition. SACAL ENVIRONMENTAL ENVIRONMENTAL TECHNICIAN Mr. Bojang supervised a crew that performed overhead cleaning, pressure washing, ice blasting, high-pressure vacuuming and other services required by the industry and the clients. He was the lead in a crew performing lead and asbestos abatement for several municipal clients. INDEPENDENCE MINING ARCTURUS ZIMBABWE GEOLOGIST Mr. Bojang worked for a large mineral exploration company. His duties involved underground and surface mapping (cross section construction, correlating lithologic and geophysical logs etc) logged about 10 OOOft of core, surveying, using ground- penetrating radar, sample collection (soil, rock and water) including stream sediment sampling and gold reserve calculation using software such as Surpac. He was also responsible for all report wntmg. Mr. Bojang was also a part of the team that performed air monitoring and stream monitoring around mines. His duties included watershed surveys, habitat assessments, surface and groundwater sampling assessing water quality. MUSIW A ENVIRONMENTAL ASSISTANT GEOLOGIST Mr, Bojang worked with a team on Environmental Impact Assessment Projects for large mines. His duties included sample collection (soil and rock using geoprobes and augers), sample analysis using X-Ray diffraction, statistical analysis of data, data management and report writing. ) '/l.T_hnko.1 5....10.. rlt.... ~2007 Cosby, Everett & Wright, LLC. Page 28 ~ f Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 Keith Frederick Operator/Supervisor Over fifteen (15) years experience in heavy equipment operations and project supervision on a variety of environmental remediation projects. Mr. Frederic spent almost fourteen (14) years with OHM Corporation/IT Corporation/Shaw E&I before joining CCl. EXPERTISE Project Supervisor responsible for managing work crews and delivering projects on schedule and within budget. Education 40-Hour OSHA Hazardous Waste Certification (1910.120) 8-Hour OSHA Hazardous Waste Certification Annual Renewal (1910.120) Competent Person/Trenching and Shoring (as per 29 CFR 1926.650(b) American Red Cross First Aid/CPR Training Function - Foreman Key Projects: Location - Anniston, Alabama Client - Solutia, Inc. Function - Project Supervisor This Superfund Site project required the excavation and restoration of local residents yards that had PCBs contamination. The project also required the transportation and disposal of the excavated soils. Location - Memphis Tennessee Client - DuPont Function - Project Supervisor The project required the installation and initial operations of a storm water testing system within a major outfall area. Location - Ft. Lee Virginia Client - Shaw E&I The project involved the construction of a capping system. Large amount of soils, backfill material, liner material, rock, etc. were installed in accordance with a detailed project specification. · LCP Chemicals Superfund Site, Brunswick, Georgia - Equipment Operator and Foreman. Worked on this site for almost three years while with IT Corporation/Shaw E&l. The project involved mercury decontamination and remediation of wetlands. Various levels of PPE were required and the project was high profile and under the on- site authority of both the USEP A Region IV and the Georgia Environmental Protection Division. ) :t <<;)2007 Cosby, Everett & Wright, LLC. Page 29 \ ~ ! ) ) ;/ E. FEE SCHEDULE Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 The fee Schedule is enclosed in a separate sealed envelope along with this proposal. (g2DD7 Cosby, Everett & Wright, LLC. Page 30 I j . ) J ) Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 APPENDIX A CITY OF AUGUSTA ADDENDUMS (3 pages) <Gi2007 Cosby, Everett & Wright, LLC ~ rf?Jf'me{{/)Ce?nellt {5}f'tjxvJWwnt S1:ti: @'e/'i- r;;:tCUJbJ, Q)JlfWtfYJ< R G I A ADDEl\TDUM Faxed and Mailed SUBJ: All Bidders II Geri A. Sams W M~y 10,2007 ADDENDUM #1 RFP Item #07 -128 Phase II Environmental Engineering Services for the . New Main Library . RFP Due: Friday, May 18,2007 @ 11:00 a.m.. TO: FROM: DATE: Please note the following change to your RFP package: Survey Drawing which is attached Please acknowledge receipt of addendum in your RFP package. If you have any questions regarding this correspondence, please contact me at ) (706) 821-2422. cc: ' Tameka Allen Bob Munger Interim Deputy Administrator Heery Int'l ) Room 605 - 530 Greene Street, Augusta, Georgia 30911 (706) 821-2422 - Fax (706) 821-2811 www.augustae:a.I!:Ov Register at www.demandstar.com/supplierfor automatic bid notification \ , II ~ i " 134'8:;~i34'43 I BSMH II . WV I ~= T=135,3\J I I SSMH =132,\73 . 9 :.1 ~ !t:=c2~~i~), 90 G R E ENE 5T. R /W VA I I I' ,: I · Y f~~5, 43 (A.K.A. GA. ~Wv #28) " ... I I IEIN=127.23 r?~33 97 I S1MH tt I I GPM I IEO\JT=127.02 IE~N=127.=-t3 T=135,4-7 ~ T= .46 1EouT=127,79 I I p--p--p--P--P--P--P -~w 'II SSMH WV T:""I-: tr--+T=134'99- 'II -", " ... ~IEIN=127'77 GT -"'-'11 H , 4,87 _I '\..t. :;J.? IEouT=127.44 T'=.1:a.;m - - --;~ = = = ===...,.--.().; ). =:- =:1....{ >( -.. 134.80 13421-134.l3 13408 '13-;:50 1~;;:~0 '....'..'., I . / 134.95. 1/ CONCRETE PAVING 134.5f W " .. Ir", v~ 1/ 134, B " 134 9 I I .::C.. / // c ~ ~ 0 .~:J 1........'.!~..........rt1... ~I WY... 13;7/ TS 135.00 CONC~~~5 PA~3~~9 r35~80;~ I 1)711 I ':)tz=-d 56758'40"E 62.95' '129,26 ... 1,:\li I [:::;,..:~ ",8 wy~ILLER CAP PHON _ .}.(... I /.' III Ili~u 134,~'0 ~"!...; . BOOTH L I "-X-}+-- I';. ~~ II !:; !f5N"'~ t& t& MA HOLE(Z) , \ (.111 ~,!!.~~ LP :c~'jj' ~ 00 I I 136.11 I ~ .. IrWK11 I ~,!!.~~ ~ MW(2)1 ~TANK LOCATION 135" FH VN I '....... 0 00 L_.J-APPROXIMATE l'j NG I" - 1:~II.r :c~ MW MW(2) ~ I It.. I.f.':.~;:r ~II ~~:2 ~I I ~ ~ I I~~j! ~- 13..5 ~ 13. I I I I~ '" ~ t.J*JI II 135'77~~,:: 135.76 <0 ' I".CDII .- ii r ~Ii 'j ~ "="'= I ~. ~il ., ~ I ' t'. ~:! il " i II i,1:lllij j 41 ~ I tl,s ij " ~ h:, ~. . --.J LPI _ '" IJ:t I ~ II ,A"t \0' .. ~~ ~~ ]'.~t; ~ o ~ II 'Jillll n '-J~.< a . '" .'.....1,...,.'..,..-'.:.11 ~ I W 'I ~':.i;!;.:l,.::. NZ II IIHJh I ~ :.' :.', .:.:-.:;,........1,..:.: '1';1'1 ~ 1 ~ ~ I.I"HI ~ -~ '[ '1) . "011 .,'", ~11~ 11~~~,r ".,oN6T24'31'W ~ . '" !I!~II~:~I-I ','~<T: ~u~Z~~~ r', B~J :~.I!...:t..'~~l'~ . lr~ ~~~r~D~' I I \ Ill, ~ to ,'l::~'..r' ~ 11'1,' ~ "'to '''.' ,'" I 1'1" IHfI /- E ~ ..f'o~~,F " 134-~4e- I z '. '. ''''':-: UILDING 134mB /1'.1 ~ : w:<.' .,', ORNER " ,"/ . '.:' .'" I d - WM1,. , . ", G T --S.6I4.c.3.8:.:.E T i 11~1 ,I I /':J:. ~ 64.26' CONCRETE ,PAVING :.: <l: ) ) 64~ 1 9' . 56724'37" E w '-' t:i "- '" 3: 5 z ;;: :c '-' p dub 00 N "'"' I t"- o ~ ~ z o ~ Eo-< < Eo-< rJJ. ~ Z ~ ~ o rJJ. ~ ~ ~ ~ o ~ ~ o ~ ~ ~ ~ rJJ. .r--- o o C":-l o~ ..... ;:.., c<:S :::E ~. o--l cJ u:J o E-< E-< o Z ~ ~?'(J(!([l}((3jnent W'~JUf1l.t S1;t;' ~e-j(f. (j2klJbJ, !:ifh--e.et&J< ADDENDUM Faxed and Mailed TO: All Bidders SUBJ: Geri A. Sams ~ t~ Q/ffJ7tn~ May 11,2007 ADDE1\1J)UM #2 RFP Item #07-128 Phase II Environmental Engineering Services for the New Main Library New RFP Date: Tuesday, May 22,2007 @ 3:00 p.m. FROM: DATE: This is to notify all potential vendors that the RFP opening date for RFP #07-128 Phase II Environmental Engineering Services for. the New Main Library has been changed: From: Friday, May 18,2007 @ 11:00 a.m. To: Tuesday, May 22,2007 @ 3:00 p.m. Please note the Fee Schedule has been modified for RFP 07-128 and is attached. ) Please acknowledge receipt of addendum in your RFP package. . If you have any questions regarding this correspondence, please contact me at (706) 821-2422. cc: Tameka Allen Bob Munger Interim Deputy Administrator Reery Int'I Room 605 - 530 Greene Street, Augusta, Georgia 30911 (706) 821-2422 - Fax (706) 821-2811 www.aul!1lstae:a.~ov Register at www.demandstar.com/sup~lier for automatic bid notification ) ) J Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 APPENDIX B CONFLICT OF INTEREST FORM (2 pages) ~2007 Cosby, Everett & Wright, LLC .AT...hn....IS...o-I"~.Flr.... '" , ~ A CONFLICT OF INTEREST: It shall be unethical for any City of Augusta bus:iness or participant direCtly or :indirectly in a procurement contract when the employee or official knows that: (a) the employee or official or any member of the employee's or official's immediate family has a substantial interest or financial :interest pertmning to the procurement contract, except that the purchase of goods and services from businesses which a member of the Commission or other City of Augusta employee has a financial :interest is authorized as per O.C.G.A. 36-1-14, or the procurement contract is awarded pursuant to O.C.G.A. 45-10-22and45-10~24, orthetrans.action is excepted from said restrictions by O.C.G.A. 45-10-25; (b) Any other person, business, or organization withwhom the employee or official of any member of an employee's or officials immediate family is negotiating or has an arrangement concerrring prospective employment is involved in the procurement contract Any employee or' official or any member of an employee's or official immediate family who holds a substantial interest or fiD.ancial interest in a disclosed blind trust shall. not be deemed to have a conflict of interest with regard to matters pertaining to that substantial interest or financial interest. I, (vendor) C1)$~ I E\,iEllt:.if ~ WI2Ibij.~ t.u:::..aave read and understand the information . contained in the bid specifications. . . Vendo, N""" C~BJ{ I ~~n- ~ W~b"~ t.I...e.. (('~W) Address: 3"~ ~ Pr\lf;Nttt- City & State: A 11J1t!11r J bPr 3 03\5 - \11 ~ -- 'll-So Fax # (4) to2:/. 2Zt;6 Signature: Date: ~. RFPltemNumberandName: ftt . :u: 8.)v\twNMeNrnt- ~Neetl.lN6 ~~Vt~ . . ~ n..\ p. ~et-J \...I a 4JWJt.J. ~ FP 01- lZ.~ THIS FROM MUST BE SUBMri'flffi WITH RFP P ACKAGE. "N~ EXCEPTION(S) WILL BE GRA1\l'fED ) 9 '), .~ v ) APPENDIX C Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 CERTIFICA nON STATEMENT - LOCAL VENDOR 'PREFERENCE (One Sheet) ~2007 Cosby, Everett & Wright, LLC ) ) ) ~ A Certification Statement Local Vendor Preference I certify that my company meets aU of the following qualifications to be eligible for the local vendor preference: (1) That my company has a fixed office or distribution point located in and having a street address within Augusta for at least six (6) months immediately prior to the issuance of the request for competitive bids or request for proposals by Augusta; and (2) That my company holds any business license required by the Augusta Richmond County Code for at least 6 months (3) That my company employs at iell.st one (1) full time employee, or two (2) part time employees whose primary residenceis.in Augusta, Qr if the business has no employ~s-, the business shall be at least fifty percent (50%) owned by one or more persons whose primary residence is in Augusta.. .... .... (4) Attached is a copy of my Augusta Business License. . Company Name: ~ Address: Business License Number: Phone Number: Fax Number: Owner' s. Name: Signature: Sworn to before me this day of ,20 Notary Public for the State of My Commission Expires Notary Public Signature Printed Name: II II VENDOR DO NOT COMPLETE To be completed by Authorized City Representative from Business License & Inspection Department: Vendor Certified: Date: Authorized Signature Thisfarm MUST be submitted with RFP package. NO Exception(s) will be granted 10 " t ) ) APPENDIX D CONTINGENCIES (2 pages) Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 (92007 Cosby, Everett & Wright, LLC CONTINGENCIES This proposal is based on the following assumptions/conditions: . The proposed field work will be completed in four (4) lO-hour work days, which . does not include travel to and from the site, and entails the installation of approximately 10 to 15 geoprobes to a total depth of 12 ft-bgs, and the excavation and disposal of the USTs. . City of Augusta will provide CEW with a site map drawn to scale of the facility. . All permits and application fees are covered by the Client. . The cost estimate in this proposal does not include costs to survey the site and geoprobe locations. . The costs for the drilling subcontractor is based on the subcontractors being on- site a total of one day. Additional days will be billed on a time and materials basis. . The costs for disposal, transportation, and waste characterization of the drill cuttings and purged water are not included in this proposal (if required). Costs for these services will be provided upon review of analytical results. . Analytical services will be conducted following standard laboratory turnaround time (7 days) and is based on the parameters described herein. . Labor hours estimated is dependent upon favorable weather conditions, site accessibility, and optimum subcontractor performance. . Additional delineation activities beyond the proposed scope of services are not included in this proposal and, if required, will be billed on a time and materials basis. . All field activities will be performed under Level D safety conditions. . CEW will provide schedule to include 30 day notification period for all agencies. . Utility locate notification will be completed prior to CEW mobilization by client. . Silt fencing to be installed on down gradient areas only NTE 200 ft. . CEW's contractor CCI will mechanically compact the excavation with the excavator to grade. . CEW assumes the tanks contents is sand. (Not Concrete) . . Imported fill estimated at 95 tons CEW will bill materials at cost plus 20%. . CEW assumes the excavation can be backfilled directly after conformation samples are collected. A daily rate of $2,405.00 will be applied if exceeds 3 days. . Shoring is excluded from our estimate. . . Dewatering is excluded in this estimate. . CEW will expose and remove all tanks consecutively so that all samples can be collected and shipped at the same time. . CEW will expose and remove all 4 tanks at the same time to have only one mob for the recycling company. . All applicable permits will be obtained and kept valid as required by all applicable regulatory agencies by CEW and the City. . The contract will be contingent on mutually accepted Terms and Condition. . CEW will not claim generator status for any such materials, however, CEW will sign disposal documents as Agent for Generator. . CEW's proposal will become by reference apart of any final services contract and must be incorporated by reference into any contract document. '\ l ) ) . This proposal is valid for 45 days from the date of submittal. CEW will be responsible for the accuracy of all information supplied to the disposal facility for disposal acceptance, generator information, etc. If any discrepancies are found within this information the client will be responsible for all costs associated with the correction of these discrepancies. All surcharges not mentioned in this estimate will be billed as received at cost plus 20%. Acceptance of this proposal contingent upon CEW receiving written estimates for all subcontracted items and lor vendor services. Estimate for transportation and disposal of steel tanks based on the tanks conditions being acceptable for over the road hauling (flat bed), meeting GA DOT regulations. (Included letter of destruction from disposal facility) . . . . CEW appreciates the opportunity to provide City of Augusta, with this estimate. If I can be of any further assistance please feel free to call me at (404) 933-2250. John Wright, Managing Partner Cosby, Everett & Wright, LLC iwrightCZV,cewtechservices. com REVISED CONTINGENCIES This proposal is based on the following assumptions/conditions: · The proposed field work will be completed in four (4) lO-hour work days, which does not include travel to and from the site, and entails the installation of approximately lO to 15 geoprobes to a total depth of 12 ft-bgs, and the excavation and disposal of the USTs. · City of Augusta will provide CEW with a site map drawn to scale of the facility. . All permits and application fees will be covered by CEW. . Analytical services will be conducted following laboratory turnaround time of three (3) days and is based onthe parameters described herein. . Additional delineation activities for impacted soils that are above GA EPD action levels that are beyond the proposed scope of services are not included in this proposal and, if required, will be billed on a time and materials basis. CEW will provide schedule to include 30 day notification to the GA EPD. CEW will locate utilities prior to mobilization the site. Silt fencing to be installed on down gradient areas only NTE 200 ft. CEW assumes the tanks contents is sand (Not Concrete). If the tanks are filled with concrete this could significantly affect the schedule and disposal costs. Dewatering of contaminated water is excluded in this estimate. CEW will not claim generator status for contaminated materials however, CEW will sign disposal documents as Agent for Generator. CEW's proposal will become by reference a part of any final services contract and must be incorporated by reference into any contract document. CEW appreciates the opportunity to provide City of Augusta, with this estimate. If I can be of any further assistance please feel free to call me at (404) 933-2250. John Wright, Managing Partner Cosby, Everett & Wright,LLC jwright@ iwright -associates.com ) .'!. '~ l ) Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 ATTACHMENT A EXPERIENCE MODIFICATION RATE (2 Pages) ~2007 Cosby, Everett & Wright, LLC , .~ I Augusta, Richmond County, Georgia Request for Proposal Phase II Environmental Engineering Services for the New Main Library FRP Item #07-128 Cosby, Everett & Wright, LLC (CEW), IS a fully insured, technically qualified firm with over fifty years of combined professional service experience. CEW has been in existence for about one year, therefore, an annual EMR rating has not been calculated by our Worker's Comp broker, World Risk Management. However, to date, we have had no recorded accidents within our firm. Attached for your additional review is a copy of our Liability Insurance certificate reflecting all of the industry standard requirements. ) @2007 Cosby, Everett & Wright, LLC 11/19/2007 8:09 PM FROM: Fax TO: 678-526-2688 PAGE: 001 OF 001 , UNITED STATES DISnuCT COURT SOUTHERN DISTRICT OF GEORGIA AUGUSTA DIVISION . I THOMPSON BUILDrnG WRECKING COMPANY, INC~ PAULETTE TUCKER ENTERPRISES, INe., d/b/a TUCKER. GRADING AND HAULING, RICHARn CALD\VELL, d/b/a CLASSIC ROCK HAULrnG, SIDNEY CtJLrARS, d/b/a SIDNEY CurJLARSTRUCI<ING, Plaintiffs, v. I07CYOI9 AUG(USTA, GEORGIA, I : Defendant. , I ORDE~ I. ~TRODUCTION rb this civil rights action, various plaintiffs chalI~nge the City of ~ugusta, Georgia's Disadvantaged Business Enterprises ("DBE'') Program as unconstitutionahy discriminatory. Doc. ~'1. They c1::iim that tbIe Program violates the Equal Protection Claus9 of the Fourteenth AmJ.dment to the United Stites Constitution, as well I as various provisionJ. of the Georgia Constitution. Id. BecaFe the Georgia Constitution claims raise novel issues of Georgia law -~ whether the AUgt!.sta prdinance violates the Georgia Constitution -- this Court declines to exercise any jurisdiction it m~y have over them. I I 28 V'iS'C' ~ 1367(c)(1); see Parker v. Scrap Metal P-rocessors, Inc., 468 Ff3d 733, 643 (11 th Crr. ~006) ("Anyone of the section 1367(c) factor~ is sufficient to give I the district court discretion to dismiss a case's supplemental state law clbs"). The only iss~e now before the I I Court,ithen, is whether Augusta'sDBEProgram should be enjoined becauSeitrl. olates the United. States IConstitution, I I I ,. I MUc~ of plaintiff's complaint COkd also be read as a Olull"'1' ~ tho PBE P"=" "",nod during bi_, I , i 1="lLED 'tfS.-DfSTRICT C'OURT S}W td'{M ~\i1 D IV. Ziill MAR I q PH 3: 32 CLERK IkJ SO. OJ5T. OF GA. The plaintiffs allege that prime contract bids containing DBE participation at the subcontract level are' 'treated 'more favorably than bids without DBE participation at the subcontract level; in other words, the DBE Program encourages prime contractors to discriminate against subcontractors on the basis of. race, gender, and relative economic advantage. Doc. #1 at 14-15; see doc. # 5, exJ1. C at 1-66 (AUGUSTA CODE ~ 1-1 0-62(b )(9)); see also doc. # 13 at 1 (the parties have stipulated that the City currently adds up to "20 points" to a propos'!l or bid th.lt utilizes DBBs). According for a project to demolish the Caody Factory Buildings in Augusta. See doc. # 1 at 5-8 (descnoing fuets surroundiIlg the bidding for the Candy Factory Buildings demolition contract). At a 2/13/07 hearing, however, the parties . represented that the Candy F aetory Buildings contract was being litigated in state court, so the issue is not before tltis Coun. Doc. # 14. Thus, the plaintiffs here attlck the DBE Program facially, rather than based on an individual past application. AdditionAlly, the plaintiffs' complain.t discusses alleged violations of the DBE Program by the City. E.g. doc. # 1 at 15-16 (discussing businesses that Were given DBE advantages despite nor meeting DBE criteria. and not being registered with the City). This seans relevant only . to what could be read as an irlvocation of the due process "void for vagueness" doctrine. Id. at 19. The challenge is that because the ordinance bcb adequate objective criteria for awarding contracts, city officials are acting arbitrarily and capriciously In violation of due process. See generally Note, The Void-for. Vagur::n.ess Docrrine in the Supreme Court, 109 U. P A.. L. REv. 67 (1960); A.ndrew E. Goldsmith, The Void-for-Vagur::ness Doarine in rhe Supreme Court, Revisized. 30 AM. J. eRn.!. L. 279 (2003). Tne plaintiffs ignore this argument in thcir TRO briefing, , to the plaintiffs, this ~laces them at a COmpetitive disadvantage m bidding on Augusta projects. Doc. # 1 at 15. On 2/13/07, this Court heard arguments on whether a temporary restraining order (TRO) shoul~ ~ssue. The nex~ ~y~ it entered a 30-day restrairung order requmng that any contracts entered by the City of Augujsta be made vrithout reference to the challenged DBE Program. Doc. # 6. With bids before it, the/City of Augusta has stopped awarding cont:ra.ctS rather than award contracts without reference ~o the DBE Program. Doc: # 12 at 3 ("nine contrabt awards have been delayed since thee:ntry of the Court's Order'). Of course, nothing in the CdUIt's 2/14/07 Order requires the City to stop d.tering contracts; it simply requires that the Cit;\ treat all companies the same, regardless of DBE status or DBE partifipation iD a bid.. In any event, the parties have now briefed the Court on whether tha~ Order should be extended or dissolved. Doc. ## 8-9. Meanwhile, I the plaintiffs move for ~ contempt order, claiming tliat the Cityhas violated the TRO, doc. # 16, ibut the Court will Dot pkss on that until the City responds. II. ;B~CJ(GROUND In 1994, concerned abou the present effects of p~t discrimination in tugusta,' the City commissioned. the "Richmon~ County Disparity Study," (Study) -- Augusta being the county seat of Ri~hmond County. Doc. 1# -5, exh. A. . The Study, makes numerous ~ .findmgs, including "compelling evidence of a large disparity between the utilizatibn of minority and women vendors and their dvailability in the Richmond County market b... much of [whien] is attributable to th~ past and present effects of discrimination. " IIi. at vi. The Study examines the disparity in socioeconomic status among the various races. 2 Among the findings: · The Richmond County popUlation was 55.1% white, 42% black, .3% Native American, 1.7% Asian, and 2% Hispanic, id. at vii; · "Black families in Richmond County [in 1994 were] nearly ~our times more likely to have incomes below the . poverty level, [sic] than white families," id. at vi, 23; · Black unemployment was more than tvrice that of whites, id. at vi, 22; · The white high school gradUation rate was 76.8%; whereas the black high school graduation rate was.61.2%, id.; · The white college graduation rate was 21.7%, where& the b1ackcollege graduation rate was 9.8%, id.; · White median family income was $35,181, while black median family income was $21,'543; and Whites are more likely to be employed in management positions, id. at vi, 23. These socioeconomic diffeIences, the Study ccncludes, "have a significant impact on the ability of blacks to start and grow businesses, because they reduce the financial resources and market size and strength." ld. at vi. 2 The study compared the SocioecoIlol1lic srstus of whites, blacks, Hispanics, Asians, lllld Native Americans. Doe. # 5, exh. A at 22-23, 24-35. The C()DclusioDS drawn all refer only to the disparity between white. a.rui blacks. Jd. at vi-viii. 2 , ... The Study next compares black-o\Vned businesses in Augusta to those owned in other . regions and those O\VI'led by' other racial groups. Jd. at vii, 43-45. Accord4.g to the Study, the 925 black-o\Vned busmessds had a mean annual rev~. ~e ofS2:,787.1d. ~~. This,figure'was statlstlcally disparate froH~ annual revenue of black businesses in the rest of the state ($55,443) and country ($46,593). Id./The 197 non-black minority ii.rms had a mean annual revenue of $86,603, and the 1,900 fem4re--owned!inns had a mean annual revenue of $70,280. Id. The mean annual revenue of all Georgia firms was $159,859, and the mean annual revenue of all U.S. firms was $145,654. {d. at 44-45. A key datum, the mean. annual revenue of all businesses in RichmondCohnty, is missing. The Study then dise~ Georgia's racist history as it relates to contracting, including antebellum legislation zD..akmg it illegai to r contr,act with blacks "fat the erection of buildings, or for the repair or buildings." Id. at vii~viii, 49-61. Nex~ the StudydesCIibes the County's contracting outlays between ~992 and 1994. Id. at viii~x; id. at xvi-xxviii (charts of data). In 1992, the County awarded dver $27 million in . I contracts, of whlch 1.25% (around $350,000) went to minority and worn/en vendors. The percentages in 1993 and 19:14 were 1.72% and 4.33% respectively. Id. at it. The Study also noted, a disparity in the "ske,- in awards," 28 for white- firms, 5 for minority. Id. Though "skewness" is not explicitly ~efined, the Study notes that the disparity means that "disbursements to majority iiJns were five times more concentrated among a few .firms than Were disbursements to minority nrlns." Id.; see id. at xxi~xxii (charts 3.5 and 3.11)[ I I The Study next discusses the City's record of "purchase ,orders under $1,500.00" in 1993. Id. at ix. The City fielded three telephone quotes for each such order. ld. Only 8% oillie quotes . were fielded from minority vendors in 1993, and only 1 % of the dollar value went to minority _ vendors. !d.; see xxii~xxili (Charts 4.2 & 4.3). Minorities and WOmen received 1. 7% of contracts over $5,000 in1992 and 3.7% of such contracts in 1993. Id. The City had 1,608 vendors available. Id. 1v.l::inority and women firms constituted 12% (187) of them. !d. at ix-x. Of those 187, there were 88% black (85% male; 3% female); 8% wbite women; 3 % Asian; and 1 % Hispanic_ Of the minority firms, 81 % of those that responded to a survey never received a contract from the County, 47% believed white-male vendors were favored, 23% agreed or strongly agreed that their bus41ess had been discriminated, against, 48% agreed that they had faced discrimination in seeking financing, and 36% agreed that they had, encountered discrimination in pursuing contracts vrith majority firms. Id. at xi; Finally, the Study includes anecdotal evidence. of diScrimination from 22. interviews conducted with minority and women vendors. Id.; see also id., app. VIII (separatelypagmated section containing interview evidence). The Study characterizes the three types of discrimination encountered by the vendors as "Discrimination denying market access to competiti ve [ vendors]," "Discrimination adversely affecting the ability of [vendors] to compete," and "Discrimination adversely affecting the availability of [vendors]." Id. at 1. The Study draws the conclusion that "[tJhe evidence documented herein points to the existence of significant racial and. gender disparity in Richmond County Contracting [sic) and procurement." Id. at xiii-xiv. The Study ... :> makes seven recommendations to cure the disparity: (1) create a program t9 "mandate race and gender conscio~ '" goals in contracting and procurement,)1 including: bid preferences, requfung white-male firms subcontract with minority finns, prime contracts '\Vith minority firms, joint ventures between white-male and minority firms; (2) 21% utilization of minority- and I . femaIe-owned business7s - 16% black, 3% white women, 2% asian and hi sp anic; I, (3) waiver of goals inprLuct areas with few available minoritY and Women vendors; (4) only use of local minority- and female-owned businesses should count toward the established gbals;' , . I (~) the program should be fully staffed to deal with certi1ication lof businesses, contract monitoring, aIfd supervising contract compliance in rurchasing and procurennent; . , . (6) solicit more quotes from minority- and female-OW1led vendT on contracts under S 1 ,500; , (7) create periodic reviews, graduation of , I businesses from the program, and a sunset on the program. Id. at xiii-x.iv. Bas~ on the Study, the City of Augusta enacted its DBE, Program. S'le doc. # 5,exh. C (AUGUSTA CODE 99 1-10-58 to 1-10-62). The challenged part of the Program requires the City to [i]nclude language in ail fonnal bid documents requiring contractors to utilize . [minority.O\VI1ed. female- owned, and small businesses] to the maximum extent possible and economically feasible, as partners or subcontractors for service delivery or as suppliers of vario~s goods required in the performance of the contract. AUGUSTA CODE g 1-lO-62(b)(9). PursU2Ilt to this section, the City includes the fOllowing language in its bid documents: Augusta-Richmond . County encourages minority participation through subcontracting, joint ventures, or other methods in contracting for services, in order to expedite the evaluation process, we have attached the Checklist for Good Faith Efforts, Proposed Disadvantaged Business EnteIJlrise Participation, and Letter of Intent to Pexionn forms.. The bidder should complete the Proposed DBE Participation Form, indicating the percentage of participation for this proposal. The completed form must accompany the proposal. See doc. # 9 at 4 (Augusta's brief, quoting bid materials provided to contractors). The parties have stipulated that bids containing DBE participation in their "Proposed DBE Participation Fonn" are treated more favorably than bids without DBE participation, Doc. # 13 . at 1. 4 .' under similar circumstances. There the federal gov,ernment entered, pri:xhe contracts with 'vendors that provided for dtra compensation if subcontractors . were run I by "socially and economically disadvantaged individuals." Id. at 205. Most minority' gtoups' received a presumption of "SOCiallY! and economically disadvantaged" status. Id. Adarand, a subcontractor not entitled to the presumption, sued. The Court held that Adarand had standing to challenge prospective ap~lication of the race- based presumption and to seek inj unctive relief. Id. at 210-12. The Court limited its analysis to the ''injury in fact"standing requiremen,t, which it held was met. Id. at 211. A plaintiff ~uffers injury in fact by "an invasion of a lega1l~ protected interest which is (a) concrete and pamcularized, and (b) actual or irnminen~ n9t conjectural or hyPothetical." Jd. (quoting Lujan v. Deferuiers of Wildlife, 504 U.S. 555, 560 (~992)). Preventing a contractor from competing pn an equal footing is a particularized injury, so Adarand met the first portion of the "injury i~ fact" requirement. Jd. (citing He. Fla. Chapter., Associated Gen. Contractors of America v. [Jacks-onville, 508 U.S. 656, 667 (1993)). It met the second portion of "injury in fact" because it showed "that sometime in the relatiycly near future it will bid on another Government contract that offers financial incentives to f prime contractor for hiring disadvantaged subcontractors." ld. at 211-12. .Th~: Ad~and hadrt<mding to seek a prospective ID]llncbon. , In this. case, the plaintiffs are a prime demolition contractor (Thorhpson) and three hauling subcontractors (Tucker, Caldwell, and Cullars). See doc. # 1 at 8-9. Among the subcontractors, Tucker is a DBE on non-race I grounds and challenges the City's granting DBE status based on race; Caldwell and Cullars are I non-DBE subcontractors. All the plaintiffs regularly bid and work on Augusta projects. Id. at 10. Caldwell and Cullars have standing, under Adarand, to prospectively challenge the City's favoritism toward prime contract bids containing DBE participation. Because the 'Program, 'like the program in Adarand, encourages prime contractors to discriminate between subcontractors, Caldwell and Cullars suffer the particularized injury of not being able to compete on equal footing with other subcontractors. Adarand, 515 U.S. at 200. Tn addition, the subcontractors allege that they bid and work on City of Augusta projects, and will continue to do so. Doc. # 1 at 9-10 (Caldwell and Cullars are hauling subcontractors regUlarly working on Augusta proj ects; "Plaintiffs have and continue to bid on [Augusta's] projects, as contractors, subcontractors and/or vendors''). Because Augusta regularly enters contracts ("nine contract awards [were] delayed [in the 10 day period following] the entry of the Court's [2I14/07J Order," doc. # 12 at 3), the future injury to Caldwell and Cullars, like the future injury in A darand, is imminent Therefore, the Court rej ects the City's standing argument. 3 2. Substantial Likelihood of Success The Court must next determine whether the plaintiffs are SUbstantially likely to succeed in showing that the racial preference in the DBE Pro~ violates the Equal Protection Clause. "[A]l1 racial classifications, imposed by l Because Ccllars llIld Caldwell have standing, it is not necessary, for purposes of this Order, to discuss whether Thompson and Tucker also have standing. A:nyargument on that score should be raised in a motion to dismiss, 6 i I /' whatever federal, state, or I local. gov~enta1 actor, must be analyzed by a revie\Ving court under strict scrutiny. In lother words, such . classifications are constitutional only if they are I . narrowly tailored measures that further compelling governmental iterests." Adarand, 515 U.S. at 227. I The City first argues that "all that is required .1 . for vendors to comply Wlfh Augusta's DBE Program is to make an ap~ropriate good faith effort [to ensureDBE participation]." Doc. # 15 at 3. The implication is that requiring a good faith,. effo~ to emplo~ DB~s is not a rac~al cJas~.fication, even If som.e DBEs qualify simply on the basis of racf. Yet Augusta's bidding materials require contractors to submit a "Proposed DBE Participation" form, see doc; # 9 at 4 (Augusta's brief, qubting bid materials . provided'. to contractors), I and the, parties stipulate that bids containin~ DBE participation . are treated more favorably Ithan bids without such participation. Doc. # ~3 at 1. Because a person's business can qualify for the favorable treatment based on that person's race, while a similarly situated person of kother race would not qualify, the proiramr 'ontains a racial classification. This classification actually harms the subcontractors in hvo ways. I First, when bids are requested from prime contractors, the prime contractors will discriminat~ based on DBE I status because their bid will be treated more I favorably with DBE particfation. ,Second, when the City decides bernreen competing bids, with bid "one" containing minority DBE participation and bid "two" (!equal in all other respects or even superior to I bid one in other respects) containing a plaintiffs participation, the City will favor bid one: IBecause bid one would not be favored but for the plaintiff's owners failure to be of an I Augusta-blessed I racial makeup, the City must show that the discriminatory program is narrowly tailored to meet a compelling interest That brings the Court to Richmond v. lA. Croson Co., 488 U.S. 469 (1989). In Croson, a plurality of the Court noted that a city"'ha.s a compelling interest in assuring that public dollars, drawn from the tax contributions of all citizens, do not serve to finance the evil of private prejudice." Jd. at 492 (plurality). "Thus, if the city could show it had essentially'become a 'passive participant' in a system of racial exclusion practiced by elements of the local construction industry '" the city could take affirmative steps to dismantle such a system." Id. Though these statements Were made in a three~jllStice plurality opinion, they were endorsed in majority portions of the opinion, see, e.g., id. at 504 (Opinion of the Court) ("States and their subdivisions may take remedial action when they possess evidence that their own spending practices are exacerbating a , pattern of prior discrimination, [but] theymust identify that discrimination, public or private, with some specificity before they may use race- conscious relief'), and by the Eleventh Circuit, Eng'g Assocs., 122 F.3d at 907 (quoting the above, plurality portion of Croson). The Eleventh Circuit has described a method for government to prove the existence of tbis compelling interest: Public ~ployers may... justify affumative action by demonstrating "gross statistical disparities" between the proportion -of minorities hired by the public employer and the proportion of minorities willing and able to do the work. Anecdotal evidence may also be used to document discrimination, 7 III. ,!,NAL YSIS . This Court' s discretio~ to grant a IRO is limited: I The district court abus~s its discretion when it grants a [TROU in spite of the movant's failure to establish. (I) a substa.."1tial .1ikeIihood that the movant will ultimately prevail dn the merits; (2) th.at the movant will sJirer irreparable injury unless the injunction issues; (3) that the threatened injm1y to the movant outweighs whatever I damage the proposed injunction may cause the opposing party; and (4) that the inj unction, if issued, would not be adverse to the public interest. . , I' Wan:-en Publ'g, lne.v. Microdos Data Corp., 115 F.3d 1509, 1516 (11th ICir. 1997) (quotes and alterations omitted). "A preliminary injunction is an. extraorcqn.ary and drastic remedy not to be granted k.1ess the movan~ clearlyestablished.the burddn of persuasion as . I to each of the fourprerequisiies." Four Seasons Hotels & Resorts, E. V. v. CofrsorcioEarr, S.A., 320 F..3d 1205,1210 (11th eir. 2003). Initially, the Court poLts out that the plaintiffs fail to establish a ~elihood of SUccess on the merits insofar as they attack the DBE Program's discrimination baSed on gender and . I economIC status. See AUGUSFA CODE ~~ 1-10- S 8( a)-(b) (minority person ~cludes "female"; DBEs inclUde businesses "')not dominant in [theirJ field" and "regaxded 3;s small in size''). That is because the plaintiffs! arguments focus solely on the scheme's failure to meet strict scrutiny. Doc. i#f. 2, 8. Bu~ under the Equal Protection Clause, legislatiop discriminating based on gender and economic status is subject to lesser judicial. scrutiny. Se~ u.s. v. Virginia, 518 U.S. 515, 532-33 (1996) (intermediate scrutiny for gender-based legislative discrimination; "Sex classifications may be used to compensate women for particular economic disabilities they have suffered [and] to promote equal employment opportunity" (quotes, cite, and orig:in.a1 alterations omitted)); Hodel v. Indiana, 452 U.S. 314, 331 (1981) (rational-basis scrutiny for economic legislation; "Social and economic legislation... that does not employ suspect classifications or impinge on fundamental rights must be upheld against equal protection I attack when the legislative means are rationally related. to a legitimate governmental purpose"); see also Eng'g Assocs. S. Fla., Inc. v. Metropolitan Dade County, 122 F.3d 895,907-08 (11th eiI. 1997) (applying intermediate scrutiny to county program favoring female contractors). Therefore, the plaintiffs' TRO-extension request can s'ucceed only insofar as it attacks th~ DBE Program's discrimination based on race. 1. Standing The City primarily argues that plaintiffs are unlikely to succeed on the merits because they lack standing to challenge the DBE Program. Doc. #.9 at 9-12; doc. # 15 at 1-3. Article ill of the Constitution lim.itsthe jurisdiction of federal courts to "Cases" and "Controversies:' One component of the case-or-controversy requirement is standing) which requires a plaintiff to demonstrate the now-familiar elements ofinjuryin fact, causation, and redressability. Lance v. Coffman, 127 S.Ct. 1194,1196 (2007), In Adarand Constructors, Inc. \.I. Pena, 515 U.S., 200 (1995), the Court discussed. standing 5 ~ . . especially if b~tt:ressed by releVant statistical evidence. Ensley Branch, N.A.A. c.P. v. Seibels, 31 F.3d 1548, 1565 (11th eir. 1~94). The above- mentioned Study was Augusta's attempt to make this showing in 1994. . I The Stuc;ly found that of the 1,608 vendors available for cOntracting, riunority and women firms constitute 12% (l87)~ Doc. # 5, exh. A at ix-x. Fortheyears 1992, 1993, and 1994, these firms received 1.25%, 11.72%, and 4.33% respectively of overill City/contracting dollars. [d. at viii~ix. In other wordS, while white males ' . I ran only88% of the City's c0ntracting concerns, I they averaged around 98% of the annual contracting dollars. These ktatistics buttressed the Study's anecdotJl evidence of I discriminatio~ received from minority and women contracto'rs. Doc. # 5, exh. A, app. vm at 1-8. . The Study, however, is not without flaws. The discrimination the Ci'o/ is attempting to justify operates between. suocontractors. Only evidence Showing that sub~ontractors of race "A" are discriminated againkt to the advantage of subcontractors of rake "B" justifies governmental action attem~ting to cure the burden by favoring subcontractors of race A. See Croson, 488 U.S. at 504;Icf id. at 499 ("It is sheer specUlation how many minority firms there would be in Richmond ~bsent past societal discrimination.... Defining th~se sorts of inj uries I as 'identified discrirninationr would give local governments license to cI"9te a patchwork of racial preferences based on statistical generalizations about any particular field of endeavor"). For this reason, inuch of the Study is irrelevant to whether jtbe City has a compelling interest in discriminating behveen subcontractors on the basis 9f race. E.g., Doc. I # 5, exh. A at vi~vii"(socioeconomic status of racial groups in Augusta area). Furthermore, the Citymustrelyonnarrowly . tailored data to acbieve what precedent requires: a narrowly tailored program.. The Study's data lumps all minority and women vendors into a single group and compares that group to all ''majority'' vendors (i,e., whitemaIe vendors). Jd. at viii-x. But to establish a compelling interest thai justifies narrowly tailored, race-based discrimination, better evidence would. differentiate among. the , minority races. Cf Croson. 488 U.S. at 506 ("If a 30% s~t.aside was 'narrowly tailored' to compensate black contractors for past discrimination, one may legitimately ask why they are forced to share this 'remedial relief with an Aleut citizen who moves to Richmond tomorrow? The gross overinclusiveness of Richmond's racial preference strongly impugns the city's claim of remedial motivation"). Too, it seems impossible to enact a na..'TOwly tailored program by relying on evidence lumping gender~ and race-based . discrim:ination together, as the Study does. See Eng'g Assocs., 122 F.3d at 919 n.4 (describing "the statistical phenomenon known. as 'Simpson's Paradox,' which leads to illusory disparities in improperly aggregated data that disappear when the data are disaggregated''). . Forpurposes of this motion, however, the Court 'Nill assume that the City m.u be able to show !be existence of a compelling interest to enact an af:finnative action plan in 1994. The question then becomes whether the Program crafted in 1994 is narrowly tailored. Though it is possible that the substance of the attacked portion of the Program is narrowly 8 t' t.1ilored,4 the Court need go no further than point out that the Program is still in place 13 years after the Study was cO~piled without any further investigation into tb.~ UIiderlying reasons for creating a program., and with6ut)any sunset or expiration provision. I Doc. # 13 at 1-2 (stipulations that the Program "does not have an expiration or sunset provikion" and that the 1994 Study is "[t]he only I disparity study on behalf of the Defendant"). /whether thiS defect is framed as a failure to show that the City has a compelling interest in 2007 ,/as opposed to 1994, or a failure to prove that the Program adopted in 1994 Was narrowly tailored fempOra11y, the end resuJtis that the plaintiffs are substantially likely to succeed on the merits. This case demoIlStra1:fS the need. for unvarying vigilance ag~~ the arrogance of error too long unexanuned.Government favoritism. for one race over kother, long borne of and too often perpetuated by evil motives, is rightly prohibited by the Equal Protection Clause. Equal protection simply prohibits government from favoring one race OVer another in contracting. A.ffirmative ketion is permitted very sparingly, and only whdre the government is convinced that not to tak:~ action would be passively engaging in ~e very rac"ial discrimination that equal pro/it ection condemns. It would be impossible for Augusta to argue that, 13 years after last studying the issue, racial discrimination is so ramparit in the Augusta contracting industry" that I the "City must affinnatively act to avoid beingcomplicit · Again, AugtlSl:i requires biddcrj to submit "Proposed DBE Participation" vvilli. their bi1. See doc. # 9" at 4 (Augustl's brief, quoting bid materials provided to contractors), Bids w:ith DEE participation are tr~ted more favorably, Doc. # 13 at 1. I 3. Irreparable Harm The plaintiffs are substabtially likely to succeed in proving that, when the City requests bids with minority DBEparticipation and in fact favors bids with such, the plaintiffs will suffer racial discrimination in violation of the Equal Protection Clause. Minority DBEs qualify for the Program based solely on the race of their owners. At the same tirn.e, a losing bidder's ability to prove the injury in each instance would be next to impossible (whether rejected by a prime contractor, or part of a bid rejected by the City, was the rejection because of the subcontractor's status as a no'n-DBE?). On top of that, the measure of damages would be speculative. Plaintiffs therefore face the prospect of irreparable injury every time bids . are solicited and considered under the current " scheme. 4. Damage to the Movant versus Damage to the Defendant Augusta argues that it will be hanned by the delay to public works projects if the Court extends its injunction. Doc. # 9 at 13. As disCussed above, nothing in the Court's 2/14/07 Order prevents . the City from entering into public works contracts, it simply enjoins the City from using the DEE Program to enter con'l:raCts. Doc. # 6. Specific behavior (discrimination based on race), rather than the letting ofmunicip~ contracts, is the orily thing being halted here. 5. Adverse to the Public Interest The City argues that an injunction would be adverse to the public's interest in remedying 9 ,. . '~ - --,..~ .0 i O' d T\fJ,OJ, ! past discrimination.s Dolc. # 9 at 13. The plaintiffs argue that not issuing an injunction would be adverse to the Ipublic's interest in equal protection under the law. Doc. # 12 at 11 (citing Cone Corp. v. Hillsborough County, 723 I F. Supp. 669, 678 (M.D.Fla.. 1989)). I . Both arguments seem to beg ultimate questions at issue in the ~ase. For present purposes it is sufficient to ote that the City's reasoning would prevent TROs from ever issuing on legislation. ~or any piece of legislation 'With a rational brsis, no matter how constitutionally odious, the argument c<m be made that "the public has .in interest in [insert the rational basis for frle legislation), so enj oining the legislation proboting that interest is adverse to the. public into/est." In short, the Court draws a distinction between an injunction that is adverse to the public mterest and an . inj unction that merely lirrhts the ability of government to promote a perceived public interest. IV_ .cONCLUSION The City of Augusta is h9'eby ENJOINED, for the pendency of this action, from favoring contract bids that contain "ininority DBE" or "minority business enterpri~e" (or any other . I entity that qualifies as aDBE pased on the racial composition of its ovmership 1 participation over other bids. Furthermore, the City is ENJOINED, for the pendency of this action, from distributing bid solicitation material, or otlienvise publishing information in any manner, that would lead a ~idder.to beli.eve ~at his bid ~o~d ~ene:fit ~om mcluding "minonty DBE" or '~montybusmess I ./ ' l The City also reiterates the positioD tmt an injunction would harm the public's interest I in timely a-wm:di.ng construction contracts, As discussedpnpa."'till(4), nothing in a well-defIned injUIlction will delay any public project 'I I I r enterprise" (or any other entity that qualifies as a DBE based on the racial composition of its ownership) participation. The City shall, within 3 days of the date of this Order, post a copy of the Order in portable document format (Pdf) on the City's procurement department hbmepage (http://www. augustaga.govl dep artments/ PUIchasinglbome_asp) via a reasonably visible hyperlink entitled "Court Order Enjoining Race-Based Portion ofDBE Program." Finally, this injunction is binding upon the City, its officers, agents, servants, employees and attorneys, and upon those person in active concert. or participation with it who receive actual notice of this injunction by personal service or othenvise. &e F.R.Civ.P. 65(d). This ifday of March, 2007. ',j .\ AUGUSTA-RICHMOND COUNTY COMMISSION "~ A STEPHEN E. SHEPARD County Attorney Augusta Law Department CillQUITA T. JOHNSON Staff Attorney Betty Beard Marion Williams Joe Bowles Bernard Harper Calvin Holland, Sr, Andy Cheek 'Jerry Brigham Jimmy Smith 1. R. Hatney Don Grantham DAVID S. COPENHAVER Mayor ANDREW G MACKENZIE Staff Attorney BETIY BEARD Mayor Pro Tern FROM: Jacques Ware~ HEERY International,(nc. Stephen E. Shepard Ii) L), MEMORANDUM Frederick L. Russell Administrator TO: Please Reply to: 701 Greene Street, Suite 104 Augusta, Georgia 30901 DATE: November 16, 2007 RE: Review of Contract Documents between Augusta and Cosby, Everett, Wright, LLC Environmental Engineering and UST Closure services for new main library I have reviewed the attached Environmental Engineering Services agreement and would like to make the following observations: 1) Final documents should be signed and executed by Cosby, Everett and Wright. /' 2) Cover page, add the word "Augusta" after Acting by and through the: Augusta Richmond V County Commission. 3) Please add on the front cover which SPLOST fund is being used for this project, i.e. SPLOST V IV, SPLOST V. 4) Gary Swint as Department Head and Bob Munger as HEERY Construction Program Manager are /' required to initial the signature pages in the final contract documents. 5) Page 19, Additional Provisions: Please delete "Uuless otherwise specified". Start sentence with ~ "This agreement, etc.". 6) Page 20, signature page: Add the word "Augusta" before Richmond County Commission. /' 7) Scope of services, Page 1 of Cosby, Everett and Wright, LLC document, please correct word "Green", should read "Greene" streets. . V- 8) An updated certificate of liability insurance is required as specified in Article 8, Insurance. y/ 9) Add Notices to Owner: Fred Russell, Administrator, with a copy of the notices to Garrett Weis, ./' City's Environmental Engineer. Please make the above corrections and return to me the final documents for initialing and further processing by the Mayor and Clerk of Commission. I may be contacted at (706) 724-6597 ifthere are any questions on this matter. SES/bc Attachment (as stated) Augusta Law Department 501 Greene Street, Suite 302, Augusta, Georgia 30901 (706) 842-5550 - Fax (706) 842-5556 County Attorney 701 Greene Street, Suite 104, Augusta, Georgia 30901 (706) 724-6597 - Fax (706) 722-4817 Tameka Allen, Interim Deputy Administrator Robert Leverett, Interim Deputy Administrator Room 801 . Municipal Building 5,0 Greene Stfee~. AUGUSTA, GA. 30~11 (706) 821-24<>0 - FAX (706) 821-2819 www.;lIIgustllga.gov Office Of The Administrator November 8, 2007 Mr. Gary Swint Director - ARC Library 902 Greene Street Augusta, GA 30901 Dear Gary: The Augusta-Richmond County Commission, at their regular meeting held on Thursday, November 8. 2007. approved a proposal from Cosby, Everett & Wright for Environmental Engineering and Underground Storage Tank abatement services associated with recently acquired property for the New Main Library.. . If you have any questions, please contact me. Yours truly, r h / . (//-4 Frederick L. Russell Administrator . cc: Ms. Donna Williams Ms. Geri Sams Mr. Bob Munger 11-06-07: #32 AUGUSTA-RICHMOND COUNTY COM~~JON STEPHEN E. SHEPARD County Attorney Augusta Law Department DAVID S. COPENHAVER Mayor CHIQUITA T. JOHNSON Interim General Counsel Betty Beard Marion Williams Joe Bowles Bernard Harper Calvin Holland, Sr. Andy Cheek Jerry Brigham Jimmy Smith J, R. Hatney Don Grantham BETTY BEARD Mayor Pro Tern ANDREW G MACKENZIE Staff Attorney Frederick L. Russell Administrator MEMORANDUM Please Reply to: 70 I Greene Street, Suite 104 Augusta, Georgia 30901 TO: DATE: Mayor Deke S. Copenhaver Steve Shepard ;J~ November 20, 2007 FROM: RE: Contract for Main Library Phase II Environmental Engineering Services Attached please find four original copies of the contract between Augusta and Cosby, Everett, Wright, LLC for Environmental Engineering and UST closure services for new main library for your signature and further execution by the Clerk of Commission. A Copy ofthe Commission approval letter dated November 8, 2007, item No. 32 is attached. If! may answer any questions on the above matter, please do not hesitate to contact me at (706) 724-6597. Once executed, please return three sets directly to Mr. Jacques Ware at HEERY International, Inc., Program Managers for this project, 501 Greene Street, Suite 313, Augusta, GA 30901. SES/bc Enclosures (as stated) cc: Gary Swint, Library Director Jacques Ware, HEERY Augusta Law Department 501 Greene Street, Suite 302, Augusta, Georgia 30901 (706) 842-5550 - Fax (706) 842-5556 County Attorney 701 Greene Street, Suite 104, Augusta, Georgia 30901 (706) 724-6597 - Fax (706) 722-4817