Loading...
HomeMy WebLinkAboutAPAC TENNESSEE INC RUNWAY REHABILITATION B USH FIELD AGREEMENT FOR Augusta Regional Airport at Bush Field Runway 17 -35 Rehabilitation THIS AGREEMENT, made this /9 day of October in the year Two Thousand and Ten, by and between the City of Augusta ( "Owner "), and APAC — Tennessee, Inc. ( "Contractor "). WITNESSETH: That the Owner and the Contractor, for the consideration hereinafter named, agree as follows: ARTICLE 1. The Contractor agrees to furnish all of the materials and all of the equipment and labor necessary and to perform all of the work entitled Runway 17-35 Rehabilitation — AIP #3 -13- 0011 - 033 -2010 (TERMS, CONDITIONS, SPECIFICATIONS and DRAWINGS) dated February 2010) prepared by Campbell & Paris Engineers, 313 Wingo Way, Mt Pleasant, South Carolina, 29464, in accordance with the requirements and provisions of the Contract Documents. ARTICLE 2. The Contractor agrees that the work under this Contract will be commenced within 10 calendar days after receipt of written notice by the Owner to the Contractor that the Contractor is authorized to proceed, and that the entire work under this Contract will be completed not later than the specified calendar days after the date of such notice to proceed, subject to adjustment as provided in the SPECIFICATIONS. The Contractor further agrees that the amount of "Liquidated Damages" stipulated in the SPECIFICATIONS and stated below for failure to complete the contract in the allotted time shall be $10,000.00 for each calendar day after the number of days specified for completion of each milestone as stated in the SPECIFICATIONS or as modified by Change Order, until the date of final acceptance by the Engineer. The amount of "Liquidated Damages" stipulated in the SPECIFICATIONS for failure to re -open a runway within the allotted time shall be $500.00 for each minute after the scheduled runway re- opening time as stated in the PLANS and SPECIFICATIONS until the runway is inspected and accepted by the Engineer and Airport personnel. The total contract time and specific milestones are established in Section 80 of the SPECIFICATIONS. ARTICLE 3. The Owner agrees to pay the Contractor for the performance of the Contract the amount of Fourteen Million Two Hundred Fifty Six Thousand Thirty -Three Dollars and Ninety Seven Cents ($14,256,033.97) subject to additions and deductions as provided in the SPECIFICATIONS. Subject to satisfactory completion of work performed, payments on account thereof shall be made as follows: a. On or about the 15th of each month, 90 percent of the value proportionate to the amount of the contract, of materials on the ground to be incorporated in the work and labor and materials incorporated in the work up to and including the last day of the previous month, as approved by the Engineer, less the aggregate of previous payments. b. Upon substantial completion of the entire work, a sum sufficient to increase the total payments to 95 percent of the Contract Price. c. Within 30 days after the date of the final acceptance of the work, the balance due under the Contract. ARTICLE 4. The Owner and the Contractor hereby agree that the General Provisions, General Requirements, Special Provisions, hereinafter called the SPECIFICATIONS and the DRAWINGS are as fully a part of the Contract as if hereto attached or herein repeated. AGR -1 AGREEMENT Additionally, the following specific items shall be considered a part of and are incorporated into the Contract Documents by reference when appropriately executed. ♦ 100% Labor and Materials Payment Bond ♦ 100% Performance Bond ♦ The Certificate of Insurance (as described in Section 70 of the Contract Specifications) ♦ The Contractor's completed Bid form dated September 2, 2010. The Owner and the Contractor, for themselves, their successors, executors, administrators, and assigns hereby agree to the full performance of the covenants herein contained. IN WITNESS WHEREOF, THEY HAVE EXECUTED THIS AGREEMENT THE DAY AND YEAR FIRST ABOVE WRITTEN: � V401/V) 44 OWNER: CITY O i.9�,,,, c , � a �, e ® 4 By k_ 11 /�- l a �' ld S aye,' Date {r� o / �` ` !% 7 7 / -na ' onrier, Cl r r' o � Gsnnmission Date i o G E ®B. Gyl A GUSTA VIATION C MISSION, AUGUSTA, GEORGIA U . eaDIO Rev. arl on Howard, Chairman D . e tress D e CONTRACTOR: Ap v — �1!'„r . � G C Y 4) _� .BOG fie Date Witness Date AGR -2 BOND NO. 8220 -23 -23 • Augusta Regional Airport C &PE No. 0733 -07 Runway 17 -35 Rehabilitation August 2010 PERFORMANCE BOND 100% of Contract Amount KNOW ALL MEN BY THESE PRESENTS: that APAC - TENNESSEE, INC. as Principal, hereinafter called Contractor, and FEDERAL INSURANCE COMPANY a corporation duly organized under the laws of the State of Georgia as Surety, hereinafter called Surety, are held firmly bound unto the City of Augusta, hereinafter called Owner, in the amount of FOURTEEN MILLION TWO HUNDRED FIFTY - SIX THOUSAND THIRTY THREE AND 97/100 DOLLARS ($14,256,033.97) for the payment where of Contractor and Surety bind themselves, their heirs, executors, administrators, successors, and assigns, jointly and severally, firm by these present. WHEREAS, the Contractor by written agreement dated entered into a contract with Owner for AUGUSTA REGIONAL AIRPORT AT BUSH FIELD , in accordance with Drawings and Specifications entitled Runway 17 -35 Rehabilitation dated August 2010 and prepared by Campbell & Paris Engineers; 313 Wingo Way; Mount Pleasant, SC 29464, which contract is by reference made a part hereof, and is herein after referred to as the Contract. NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Contractor shall promptly and faithfully perform said Contract, then this obligation shall be mill and void; otherwise it shall remain in full force and effect. The Surety hereby waives notice of any alteration or extension of time made by Owner. Whenever Contractor shall be, and declared by Owner to be in default under the Contract, the Owner having performed Owner's obligations thereunder, the Surety may promptly remedy the default, or shall promptly: (1) Complete the Contract in accordance with its terms and conditions, or (2) Obtain a bid or bids for completing the Contract in accordance with its terms and conditions, and upon determination by Surety of the lowest responsible bidder, or, if the Owner elects, upon determination by the Owner and the Surety jointly of the lowest responsible bidder, arrange for a contract between such bidder and owner, and made available as work progresses (even though there should be a default or a succession of defaults under this paragraph) sufficient funds to pay the cost of completion less the balance of the contract price: but not exceeding, including other costs and damages for which the Surety may be liable hereunder, the amount set forth in the first paragraph hereof. The term "balance of the contract price" as used in this paragraph, shall mean the total amount payable by Owner to Contractor under the Contract and any amendments thereto, less the amount properly paid by Owner to Contractor. Any suit under this bond must be instituted before the expiration of two (2) years from the date on which final payment under the contract falls due. PB -1 of 2 Augusta Regional Airport C &PE No. 0733 -07 Runway 17 -35 Rehabilitation August 2010 No right of action shall accrue on this bond to or for the use of any person or corporation other than the Owner names herein or the g Y P rP heirs, executors, administrators or successors of the Owner. Signedand sealed this 21 ST d SEPTEMBER , 2010. AP • - T NNESS �l►R . // ' //4— ��_ (Witness) 1' cipal) Seal) Vicd 6540,,E,ry (Title) RAL INS % PANY ��� 1/7" (Witness) ISA HALL (S ty) ( JEANNA ROMERO, ATTORNEY - IN - FACT tZ L1 icen§ed Resident Agent) GARY D. EKLUND PB -2 of 2 1 BOND NO. 8220 -23 -23 Augusta Regional Airport C &PE No. 0733 -07 Runway 17 -35 Rehabilitation August 2010 LABOR AND MATERIAL PAYMENT BOND 100% of Contract KNOW ALL MEN BY THESE PRESENTS: that APAC - TENNESSEE, INC. hereinafter called Principal, and FEDERAL INSURANCE COMPANY , a corporation duly organized under the laws of the State of Georgia as Surety, hereinafter called Surety, are held and firmly bound unto the City of Augusta, hereinafter called Owner, for the use and benefit of claimants as hereinbelow defmed, in the amount of FOURTEEN MILLION TWO HUNDRED FIFTY - SIX THOUSAND THIRTY THREE AND 97/100 DOLLARS ($14,256,033.97), for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has by written agreement dated entered into a contract with the Owner for the amount of FOURTEEN MILLION TWO HUNDRED FIFTY -SIX THOUSAND THIRTY THREE AND 97/100 DOLLARS ($14,256,033.97) in accordance with Drawings and Specifications entitled Runway 17 -35 Rehabilitation, dated July 2010, and prepared by Campbell & Paris Engineers; 313 Wingo Way; Mount Pleasant, SC 29464, which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Principal shall promptly make payment to all claimants as hereinafter defined, for all labor and material used or reasonably required for use in the performance of the Contract, then this obligation shall be void; otherwise it shall remain in full force and effect, subject, however, to the following conditions: 1. A claimant is defmed as one having a direct contract with the Principal or with a Subcontractor of the Principal for labor, material, or both, used or reasonably required for use in the performance of the Contract, labor and material being construed to include the part of water, gas, power, light, heat, oil, gasoline, telephone service or rental of equipment directly applicable to the Contractor. 2. The above named Principal and Surety hereby jointly and severally agree with the Owner that every claimant as herein defined, who has not been paid in full before the expiration of a period of 180 days after the date on which the last of such a claimant's work or labor was done or performed, or materials were famished by such claimant, may sue on this bond for the use of such claimant, persecute the suit to final judgment for such sum or sums as may be justly due claimant, and have execution thereon. The Owner shall not be liable for the payment of any costs or expenses of any such suit. 3. No suit or action shall be commenced hereunder by any claimant: (a) Unless the claimant, other than one having a direct contract with the Principal, shall have given written notice to any two of the following: the Principal, the Owner, or the Surety above named within 180 days after such claimant did or performed the last of the work or labor, or fumished the last of the materials for which said claim is made, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were furnished, or for whom the work or labor was done or performed. Such notice shall be served by mailing the same by registered mail or certified mail, postage prepaid, in an envelope addressed to the Principal, Owner or Surety, at any place where an office is regularly maintained for the transaction of business, or served in any manner in which legal processes may be served in the state of which the aforesaid project is located, save that such service need not be made by a public officer. (b) After the expiration of one (1) year following the date on which Principal ceased Work on said Contract, it being under- stood, however, that of any limitation embodied in this bond is prohibited by any law controlling the construction hereof such limitation shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by such law. (c) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state in which the Project, or any part thereof, is situated, or in the United States District Court for the district in which the Project, or any part thereof, is situated and not elsewhere. LMPB -1 of 2 Augusta Regional Airport C &PE No. 0733 -07 Runway 17 -35 Rehabilitation August 2010 4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith hereunder, inclu- sive of the payment by Surety of mechanics' liens which may be filed of record against said improvement, whether or not claim for the amount of such lien be presented under and against this bond. Signed and sealed this 21ST day SEPTEMBER , 2010. a/Zee APA - 7N .SEE, (Witness) (Princip. (Seal) 14C i (/ / ERAL(TNS )) 4 RANGE • PANY (Witness) I ISA HALL ( (Surety (Seal) JEANNA ROMERO, ATTORNEY - IN - FACT (Title) -z" Licensed Resident Agen GARY D. EKLUND LMPB -2 of 2 Chubb POWER Federal Insurance Company Attn: Surety Department OF Vigilant Insurance Company 15 Mountain View Road Surety ATTORNEY Pacific Indemnity Company Warren, NJ 07059 Know All by These Presents, That FEDERAL INSURANCE COMPANY, an Indiana corporation, VIGILANT INSURANCE COMPANY, a New York corporation, and PACIFIC INDEMNITY COMPANY, a Wisconsin corporation, do each hereby constitute and appoint Tina Davis, Marcinda Drysdale and Jeanne Romero of Salt Lake City, Utah and Mary E. Strait of Tulsa, Oklahoma- --- - - - -- each as their true and lawful Attomey- in- Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise, bonds and undertakings and other writings obligatory in the nature thereof (other than bail bonds) given or executed in the course of business, and any instruments amending or altering the same, and consents to the modification or alteration of any instrument referred to in said bonds or obligations. In Witness Whereof, said FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY have each executed and attested these presents and affixed their corporate seals on this 20th day of November, 2009. Kenneth C. Wendel, Assistant Secretary Davi . orris, Jr., Vice Presid STATE OF NEW JERSEY ss. County of Somerset On this 20th day of November, 2009 before me, a Notary Public of New Jersey, personally came Kenneth C. Wendel, to me known to be Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY, the companies which executed the foregoing Power of Attomey, and the said Kenneth C. Wendel, being by me duly sworn, did depose and say that he is Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY and knows the corporate seals thereof, that the seals affixed to the foregoing Power of Attomey are such corporate seals and were thereto affixed by authority of the By- Laws of said Companies; and that he signed said Power of Attomey as Assistant Secretary of said Companies by like authority; and that he is acquainted with David B. Norris, Jr., and knows him to be Vice President of said Companies; and that the signature of David B. Norris, Jr., subscribed to said Power of Attomey is in the genuine handwriting of David B. Norris, Jr., and was thereto subscribed by authority of said By- Laws and in deponent's presence. Noted: � - T � STEPHEN B. BRADT Nosy Public, State of New Jersey pt:A R Y No. 2321097 ( - G • Cc nIssbn Expires Oct 25, 2014 A `� 4110"11U \ PUB.. • . ry Public \ \- JE . - CERTIFICATION Extract from the By- Laws of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY: "All powers of attorney for and on behalf of the Company may and shall be executed in the name and on behalf of the Company, either by the Chairman or the President or a Vice President or an Assistant Vice President, jointly with the Secretary or an Assistant Secretary, under their respective designations. The signature of such officers may be engraved, printed or lithographed. The signature of each of the following officers: Chairman, President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary and the seal of the Company may be affixed by facsimile to any power of attorney or to any certificate relating thereto appointing Assistant Secretaries or Attorneys- in- Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such power of attorney or certificate bearing such facsimile signature or facsimile seal shat be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached." 1, Kenneth C. Wendel, Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY (the `Companies') do hereby certify that (1) the foregoing extract of the By- Laws of the Companies is true and correct, (ii) the Companies are duly licensed and authorized to transact surety business in all 50 of the United States of America and the District of Columbia and are authorized by the U.S. Treasury Department; further, Federal and Vigilant are licensed in Puerto Rico and the U.S. Virgin Islands, and Federal Is licensed in American Samoa, Guam, and each of the Provinces of Canada except Prince Edward Island; and (iii) the foregoing Power of Attomey is true, correct and in full force and effect. Given under my hand and seals of said Companies at Warren, NJ this SEPTEMBER 21, 2010 ,.,""""te ,p • ‘ E ; ms it i • 4 VOtA0 �� At Y0.4 Kenneth C. Wen I, Assistant Secretary IN THE EVENT YOU WISH TO NOTIFY US OF A CLAIM, VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER, PLEASE CONTACT US AT ADDRESS LISTED ABOVE, OR BY Telephone (908) 903- 3493 Fax (908) 903 - 3656 e -mail: surety@chubb.com Form 15-10- 0225B- U (Ed. 5- 03) CONSENT Certificate of Insurance THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON YOU THE CERTIFICATE HOLDER. THIS CERTIFICATE IS NOT AN INSURANCE POLICY AND DOES NOT AMEND, EXTEND, OR ALTER THE COVERAGE AFFORDED BY THE POLICIES LISTED BELOW. POLICY LIMITS ARE NO LESS THAN THOSE LISTED, ALTHOUGH POLICIES MAY INCLUDE ADDITIONAL SUBLIMIT/LIMITS NOT LISTED BELOW. This is to Certify that A'' APAC Tennessee Inc "'rat t i NAME AND eI Lib erty PO Box 127 ADDRESS OF INSURED Greenville SC 29602 rfriL 1\'1UtLj1® is, at the issue date of this certificate, insured by the Company under the policy(ies) listed below. The insurance afforded by the listed policy(ies) is subject to all their terms, exclusions and Conditions and is not altered by any requirement, term or condition of any contract or other document with respect to which this certificate may be issued. EXP DATE TYPE OF POLICY ❑ CONTINUOUS POLICY NUMBER LIMIT OF LIABILITY ❑ EXTENDED ® POLICY TERM WORKERS WA7 -C8D- 004095 -020 COVERAGE AFFORDED UNDER WC EMPLOYERS LIABILITY 9/1 /2011 LAW OF THE FOLLOWING STATES: COMPENSATION WC7 -C81- 004095 -010 ALL STATES EXCLUDING Bodily Inury by Accident MONOPOLISTICS STATES AND $1,000,000 Each Accident NY Bodily Injury By Disease OR, WI $ 1,000,000 Policy l imij Bodily Injury By Disease $1.000.000 Farb Person COMMERCIAL TB2 -C81- 004095 -110 General Aggregate GENERAL LIABILITY 9/1/2011 $5,000,000 ❑ OCCURRENCE Products / Completed Operations Aggregate El CLAIMS MADE $5000 000 Each Occurrence $2.000.000 RETRO DATE Personal & Advertising Injury Includ Per Person / Organization D tdh Included in BI /PD Liability Gt FIIRE DAMAGE $100,000 PFR PRCIIFCT AC;C;RFC;ATF AUTOMOBILE 9/1/2011 AS2 -C81- 004095 -120 Each Accident — Single Limit LIABILITY $2,000,000 B.I. And P.D. Combined Each Person d OWNED El NON -OWNED Each Accident or Occurrence El HIRED Each Accident or Occurrence OTHER Auto: Comp Ded $10,000 /Coll Ded $10,000 EVIDENCE OF COVERAGE ADDITIONAL COMMENTS The City of Augusta, Campbell & Paris Engineers in Mount Pleasant, SC are named as additional insured. Bid #10 -169 Runway 17 -35 Rehab Project of Augusta Regional Airport * If the certificate expiration date is continuous or extended term, you will be notified if coverage is terminated or reduced before the certificate expiration date. Liberty Mutual NOTICE OF CANCELLATION: (NOT APPLICABLE UNLESS A NUMBER OF DAYS IS ENTERED BELOW.) Insurance Group BEFORE THE STATED EXPIRATION DATE THE COMPANY WILL NOT CANCEL OR REDUCE THE INSURANCE AFFORDED UNDER THE ABOVE POLICIES UNTIL AT LEAST 30 DAYS NOTICE OF SUCH CANCELLATION HAS BEEN MAILED TO: Bid #10 -169 Runway 17 -35 Rehab Project of Augusta / J [ity of Augusta ( ! � /( / /% Geri A Sams Judith Balazentis Procurement Department Pittsburgh / 0367 AUTHORIZED REPRESENTATIVE 12 Federal Street, Ste. 310 530 Greene Street Room 605 Pittsburgh PA 15212 -5706 412 - 231 -1331 9/23/2010 [Augusta GA 30901 I OFFICE PHONE DATE ISSUED This certificate is executed by LIBERTY MUTUAL INSURANCE GROUP as respects such insurance as is afforded by those Companies NM 772 07 - ACORD CERTIFICATE OF LIABILITY INSURANCE 9/17 / 0 MIDD/YYYY) 09/17/2010 PRODUCER THIS CERTIFICATION IS ISSUED AS A MATTER OF INFORMATION MARSH USA, INC. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE TWO ALLIANCE CENTER HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR 3560 LENOX ROAD, SUITE 2400 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. ATLANTA, GA 30326 J34420-..-EX-10-11 INSURERS AFFORDING COVERAGE NAIC # INSURED INSURER A: American Guarantee & Liability Ins Co 26247 APAC- TENNESSEE, INC. P.O. BOX 127 INSURER B: GREENVILLE, SC 29602 INSURER C: INSURER D: INSURER E: COVERAGES 1 THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADD'L TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POUCY EXPIRATION LIMITS LTR INSRC DATE (MMIDDIYYYY) DATE (MMIDDIYYYY) GENERAL LIABILITY EACH OCCURRENCE $ DAMAGE TO RENTED COMMERCIAL GENERAL LIABILITY PREMISES(Ea occurrence) $ CLAIMS MADE OCCUR MED EXP (My one person) $ PERSONAL & ADV INJURY $ GENERAL AGGREGATE $ GENERAL AGGREGATE LIMIT APPLIES PER PRODUCTS - COMP /OP AGG $ PRO- POLICY n JECT n LOC AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ ANY AUTO (Ea acddent) ALL OWNED AUTOS BODILY INJURY $ SCHEDULED AUTOS (Per person) HIRED AUTOS BODILY INJURY $ NON -OWNED AUTOS (Per acddent) PROPERTY DAMAGE (Per acddent) $ GARAGE LIABILITY AUTO ONLY - EA ACCIDENT $ ANY AUTO OTHER THAN EA ACC $ AUTO ONLY: AGG $ EXCESS / UMBRELLA LIABILITY AUC655102501 09/01/2010 09/01/2011 EACH OCCURR $ 9,000,000 A X OCCUR CLAIMS MADE AGGREGATE $ 9,000,000 $ DEDUCTIBLE $ RETENTION $ $ WORKERS COMPENSATION AND WC STATU- OTH- EMPLOYERS' LIABILITY TORY I IMITS FR ANY PROPRIETOR/PARTNER /EXECUTIVE Y/ N E.L. EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? E.L. DISEASE - EA EMPLOYEE $ (Mandatory in NH) If yes, describe under PECIAL PROVISIONS below E.L. DISEASE - POLICY LIMIT $ OTHER DESCRIPTION OF OPERATIONS /LOCATIONSNEHICLES/EXCLUSIONS ADDED BY ENDORSEMENT /SPECIAL PROVISIONS RE: AUGUSTA REGIONAL AIRPORT, RUNWAY 17 -35 REHABILITATION, AIP # 3 -13- 0011 -TBD THE CITY OF AUGUSTA, GA AND CAMPBELL & PARIS ENGINEERS IS (ARE) INCLUDED AS ADDITIONAL INSURED(S) PER WRITTEN CONTRACT. WAIVER OF SUBROGATION APPLIES. CERTIFICATE HOLDER ATL- 002159459 -01 CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE CITY OF AUGUSTA EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 530 GREENE STREET — ROOM 605 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, AUGUSTA, GA 30901 BUT FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR REPRESENTATIVES. AUTHORIZED REPRESENTATIVE of Marsh USA Inc. Donna Clampitt - ACORD 25 (2009/01) © 1998-2009 ACORD CORPORATION. All Rights Reserved The ACORD name and logo are registered marks of ACORD